UNITED STATES
SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

FORM 10-KSB

     
þ   Annual report under Section 13 or 15(d) of the Securities Exchange Act of 1934.

For the fiscal year ended December 31, 2004

OR

     
o   Transition report under Section 13 or 15(d) of the Exchange Act.

For the transition period from

Commission file number 333-112567

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC

(Exact name of small business issuer as specified in its charter)
     
Minnesota   41-1997390
(State or other jurisdiction of   (I.R.S. Employer Identification No.)
incorporation or organization)    

15045 Highway 23 S.E.
Granite Falls, Minnesota 56241-0216

(Address of principal executive offices)

(320) 564-3100
(Issuer’s telephone number)

     Securities registered under Section 12(b) of the Exchange Act: NONE.

     Securities registered under Section 12(g) of the Exchange Act: NONE.

     Check whether the issuer: (1) filed all reports required to be filed by Section 13 or 15(d) of the Exchange Act during the past 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. þ Yes No

     Check if there is no disclosure of delinquent filers in response to Item 405 of Regulation S-B is not contained in this form, and no disclosure will be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-KSB or any amendment to this Form 10-KSB. þ

     State issuer’s revenues for its most recent fiscal year. NONE.

     As of March 25, 2005, the aggregate market value of the units held by non-affiliates (computed by reference to the most recent offering price of such units) was $31,117,000.

     As of March 25, 2005, there were 31,117 units outstanding.

DOCUMENTS INCORPORATED BY REFERENCE NONE .

Transitional Small Business Disclosure Format (Check one): o Yes þ No

 
 

1


 

TABLE OF CONTENTS

PART I
ITEM 1. DESCRIPTION OF BUSINESS
ITEM 2. DESCRIPTION OF PROPERTY.
ITEM 3. LEGAL PROCEEDINGS.
ITEM 4. SUBMISSION OF MATTERS TO A VOTE OF SECURITY HOLDERS.
PART II
ITEM 5. MARKET FOR MEMBERSHIP UNITS AND RELATED MEMBER MATTERS
ITEM 6. MANAGEMENT’S DISCUSSION AND ANALYSIS.
ITEM 7. FINANCIAL STATEMENTS
REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM
ITEM 8. CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURES
ITEM 8A. CONTROLS AND PROCEDURES
PART III
ITEM 9. DIRECTORS, EXECUTIVE OFFICERS AND SIGNIFICANT EMPLOYEES
ITEM 10. EXECUTIVE COMPENSATION
ITEM 11. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED MEMBER MATTERS
ITEM 12. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS
ITEM 13. EXHIBITS AND REPORTS ON FORM 8-K
ITEM 14. PRINCIPAL ACCOUNTANT FEES AND SERVICES.
SIGNATURES
Design Build Agreement
Ethanol Marketing Agreement
Electric Service Agreement
Loan Agreement
Distiller's Grain Marketing Agreement
Trinity Rail Proposal for Rail Cars
Job Opportunity Building Zone Business Subsidy Agreement
Certificates Pursuant to 17 CFR 240 15d-14(a)
Certificates Pursuant to 18 U.S.C. Section 1350

FORWARD LOOKING STATEMENTS

     This report on Form 10-KSB, and particularly the information contained under the captions “DESCRIPTION OF BUSINESS”, “RISK FACTORS”, and “MANAGEMENT’S DISCUSSION AND ANALYSIS” contains statements relating to future results that are “forward-looking statements” as defined in the Private Securities Litigation Reform Act of 1995. When used in this report, the words “estimate,” “forecast,” “intend,” “expect,” “anticipate” and similar expressions identify forward-looking statements. Such statements are subject to risks and uncertainties that could cause actual results to differ materially from those contemplated in such forward-looking statements. Inevitably, some assumptions used to develop the forecasts will not be realized and unanticipated events and circumstances may occur. Therefore, there are likely to be differences between forecasts and actual results, and those differences may be material. For a discussion of certain of such risks and possible variations in risks, see “RISK FACTORS.”

PART I.

ITEM 1. DESCRIPTION OF BUSINESS.

     Granite Falls Community Ethanol Plant, LLC, a Minnesota limited liability company, now known as Granite Falls Energy, LLC for business purposes through our assumed name filing July 29, 2004, was organized on December 29, 2000 to construct and operate an ethanol plant. We plan to formally change our name to Granite Falls Energy, LLC, at our next annual meeting of members in 2005. Our principal business is a temporary facility located on our site with an address of 15045 Highway 23 S.E., Granite Falls, Minnesota 56241. We are managed by a seven member board of governors.

     We were organized to construct and operate an ethanol plant near Granite Falls, Minnesota, that would originally have an annual capacity to process approximately 15 million bushels of corn into approximately 40 million gallons of ethanol per year (mgy) and approximately 130,000 tons annually of livestock and poultry feed known as distillers grains, which may be sold as distillers dried grains with solubles, and under certain conditions distillers modified wet grains and distillers wet grains. These are the principal co-products of the ethanol production process.

     After further review and consideration, in October 2004, our board of governors determined that increasing our production capacity to 50 million gallons of ethanol per year and approximately 159,000 tons of distiller’s grains will likely result in more efficient operations for our ethanol plant. Our operations permit presently allows for the production of up to 47 million gallons of ethanol a year and will have to be amended in the event we desire to produce up to our plant’s capacity. This change is not expected to delay our anticipated date of operation. We will be filing an amendment to the operations permit by March 31, 2005.

     Based on the increased capacity of our ethanol plant, revised estimates for our utilities, and an expected early completion bonus to our design-builder, and other items, we expect that the project will cost approximately $62,667,000 instead of the $57,850,000 previously planned. We are still in the development phase, and until the proposed ethanol plant is operational, will generate no revenue. We anticipate that accumulated losses will continue to increase until the ethanol plant is operating.

     We gave our design-builder notice to proceed with plant construction on December 1, 2004. Based on estimates provided by our design-builder, and assuming no adverse weather conditions, or delays in receiving necessary equipment, we expect to complete construction of the plant and begin producing ethanol and by-products by the end of October 2005. This schedule also assumes that weather, interest rates and other factors beyond our control do not upset our timetable. Factors or events beyond our control could hamper our efforts to complete the project in a timely fashion.

2


 

     The plant will be located near Granite Falls, Minnesota on a 56 acre site which we had options to purchase and which we did purchase in August 2004.

Closing of Our Initial Public Offering and Update on our Debt Financing .

     To assist us with the construction of our proposed ethanol plant, we raised equity in a public offering registered with the Securities and Exchange Commission on Form SB-2 (SEC Registration No. 333-112567) which was declared effective on February 17, 2004, as amended by our post-effective registration statements filed in July and August 2004 (collectively, the “Registration Statement”). We commenced our initial public offering of our units shortly thereafter.

     Our initial public offering (the “Offering “) was for the sale of our membership units (“Unit(s)”) at $1,000 per Unit of an aggregate minimum of $18,000,000 (18,000 Units) and an aggregate maximum of $30,000,000 (30,000 Units). Our Offering required that we raise the $18,000,000 minimum in proceeds by August 31, 2004 and secure significant debt financing by September 30, 2004, both of which we timely accomplished.

     As of August 31, 2004, our escrow agent had received subscriptions proceeds of over $19 million from the sale of Units in our Offering. These proceeds included $6,500,000 and $2,500,000 received from Glacial Lakes Energy, LLC (“GLE”) and Fagen, Inc. (“Fagen”), respectively, our two significant investors. GLE and Fagen had originally provided “qualifying bridge loans” which we were able to count towards our $18,000,000 minimum and which were subsequently converted into 6,500 and 2,500 of our Units, respectively. GLE is providing consulting services to us in connection with the construction of our plant and eventually will manage and operate our plant. Fagen is the design-builder of our ethanol plant.

     On September 24, 2004, we released funds from escrow having obtained subscription proceeds in excess of $25,000,000 which when combined with a debt commitment we obtained in August 2004 would yield at least $57,850,000, our then estimated cost of constructing the proposed ethanol plant.

     Our Offering terminated on October 31, 2004. However, on October 15, 2004, we closed our Offering having sold 29,700 Units and raising equity proceeds of $29,700,000, which when combined with our debt commitment would yield over $62,667,000, our revised and current estimated cost of constructing the proposed ethanol plant. We sold these membership units without the use of an underwriter.

     On December 16, 2004, we entered into a Loan Agreement with First National Bank of Omaha (the “Bank”) for the purpose of funding a portion of the cost of our ethanol plant. Under the loan agreement, the Bank has provided to us a construction loan for approximately $34,000,000, a revolving line of credit of $3,500,000, and standby letters of credit in an amount up to $1,000,000. As security for the Bank’s loans to us, we have granted the Bank a security interest in all of our assets and a mortgage on our real estate. No amount is currently outstanding under these facilities. See “Strategic Partners and Material Contracts — Agreement with First National Bank of Omaha”.

Satisfaction of all of GLE’s and Fagen’s Conditions to Investment

     We satisfied all of the conditions to GLE’s and Fagen’s investment by entering into a consulting agreement with GLE, an operating and management agreement with GLE, a new grain procurement agreement with the Farmers Cooperative Elevator Company, and by obtaining from our members amendments to our operating and member control agreement. See “Strategic Partners and Material Contracts”.

3


 

Design-Build Contract; Submission of Change Order

     On August 31, 2004, we entered into our design-build contract with Fagen, one of our significant investors, for the construction of our ethanol plant. In connection with our determination to increase the capacity of our proposed plant, we submitted to Fagen a change order changing the scope of the original project to also include the equipment and design services necessary to expand the capacity of the plant to produce up to 50 million gallons of ethanol annually. The expansion would include adding one fermenter and one centrifuge for a total of four fermenters and five centrifuges, as well as other additional equipment. On October 28, 2004, the Company and Fagen accepted the change order. Our operations permit presently allows for the production of up to 47 million gallons of ethanol a year and we are in the process of amending this to produce up to our plant’s capacity.

     As a result of this and other change orders, we will pay Fagen (on progress basis) approximately $47,986,000, which is subject to further adjustments made in accordance with the terms of the design-build contract. See “Strategic Partners and Material Contracts — Design-Build Agreement”.

What is Ethanol?

     Ethanol is a chemical produced by the fermentation of sugars found in grains and other biomass. Ethanol can be produced from a number of different types of grains, such as wheat and sorghum, as well as from agricultural waste products such as sugar, rice hulls, cheese whey, potato waste, brewery and beverage wastes and forestry and paper wastes. However, according to the Council for Biotechnology Information, approximately 90% of ethanol in the United States today is produced from corn because corn produces large quantities of carbohydrates, which convert into glucose more easily than other kinds of biomass.

     According to the Argonne National Laboratory Transportation Technology R&D Center, ethanol contains 35% oxygen by weight. When combined with gasoline, ethanol acts as an oxygenate, which means that it increases the percentage of oxygen in gasoline. As a result, the gasoline burns more cleanly, and releases less carbon monoxide and other exhaust emissions into the atmosphere. Although not all scientists agree about the existence or extent of environmental benefits associated with the use of ethanol, the use of ethanol is commonly viewed as a way to improve the quality of automobile emissions. Most ethanol is used in its primary form for blending with unleaded gasoline and other fuel products.

What Drives Production and Use of Ethanol?

The production and use of ethanol as a fuel additive results from three principal factors:

  •   Environmental pressures to use oxygenates, such as ethanol, to reduce carbon monoxide emissions from automobiles;
 
  •   Environmental pressures to reduce the use of petroleum-based methyl tertiary butyl ether (“MTBE”) as an oxygenate additive to fuels; and
 
  •   Economic pressures to favor programs that use the nation’s large production of corn.

     These factors have led to a variety of federal and state initiatives encouraging the building of ethanol plants and the use of ethanol, including:

  •   Federal and state requirements for use of oxygenated fuels;
 
  •   Federal and state legislation to ban or reduce the use of MTBE as a fuel additive;

4


 

  •   Federal and state tax and other economic incentives to build ethanol plants and produce and sell ethanol.

     We will explain each of these initiatives below.

      Federal and State Requirements for Use of Oxygenated Fuels

     The U.S. Environmental Protection Agency (or EPA) oversees two primary programs enacted under the Clean Air Act Amendments of 1990 to encourage the use of oxygenate fuel additives, including ethanol: the Federal Oxygen Program and the Reformulated Gasoline Program.

     The Federal Oxygen Program is a recurring wintertime program designed to reduce carbon monoxide levels during the winter months. According to the most recent information available, the EPA required the use of oxygenated fuels in 18 metropolitan areas during the winter of 2001/2002 that were not in compliance with carbon monoxide standards. Eleven states also have programs for use of oxygenated fuels.

     The Reformulated Gasoline Program began in 1995 as an initiative to reduce ground level ozone or smog. The program requires the use of oxygenated fuels in metropolitan areas with severe ozone pollution. According to the EPA, 17 states and the District of Columbia are required to use reformulated gasoline.

     The state of California has requested a waiver from the EPA seeking to comply with fuel emission standards without the use of any federally-mandated oxygenated fuels. In June 2001, the EPA denied California’s waiver request. California is appealing the EPA’s action.

      Federal and State Legislation Regarding MTBE

     Historically, manufacturers have their choice of fuel additives to increase the oxygen content of their fuels. MTBE, a petroleum-based additive, is the most popular additive because it has a high octane rating, blends easily with gasoline and is produced by refiners.

     According to the U.S. Environmental Protection Agency, since MTBE was introduced and became a commonly used oxygenate, MTBE has been found in well water, lakes and streams. While MTBE has not been classified as a carcinogen, the Environmental Protection Agency reports that MTBE has been shown to cause cancer in animals and its continued use has raised serious environmental concerns. As a result, in March 2000, the Environmental Protection Agency called for a ban, or the significant reduction in use, of MTBE because of the environmental problems. No federal legislation has been enacted to date. However, a number of states have enacted legislation prohibiting the sale of gasoline containing specified levels of MTBE and/or requiring the phase-out of MTBE and other petroleum-based oxygenates. According to the Renewable Fuels Association, the following is a listing of states that have banned MTBE:

     
STATE   STATUS
Arizona
  Effective
California
  Effective (January 2004)
Colorado
  Effective
Connecticut
  Effective (January 2004)
Illinois
  Effective
Indiana
  Effective
Iowa
  Effective
Kansas
  Pending Federal action
Kentucky
  To be in place (January 2006)

5


 

     
STATE   STATUS
Maine
  To be in place (January 2007)
Michigan
  Effective
Minnesota
  Effective
Missouri
  To be in place (July 2005)
Nebraska
  Effective
New Hampshire
  Pending Federal action
New York
  Effective (January 2004)
Ohio
  To be in place (July 2005)
South Dakota
  Effective
Washington
  Effective
Wisconsin
  Effective

     Legislative efforts to implement or avoid a ban or reduction in the use of MTBE are ongoing. The outcome of these legislative activities may significantly impact the future market for ethanol. For example, in August 2001, the California Energy Commission estimated that demand in California for ethanol as a replacement to MTBE beginning in 2003 (the original ban year) represents a market of between 660 and 950 million gallons annually, a marked increase to the 60 million gallons consumed in California during 2000.

     During 2003 and 2004, the U.S. Congress considered passage of a comprehensive federal energy bill. Although a bill passed in the U.S. House of Representatives, the U.S. Senate rejected the bill in November 2003 through a filibuster process. Controversial parts of the legislation would phase out the use of MTBE nationally in exchange for limiting producer liability for environmental cleanup expenses, and establish a renewable fuels standard that could enhance ethanol use. We cannot predict whether Congress will reconsider this legislation in the new session of Congress starting in 2005.

      Federal and State Economic Incentives for Ethanol Production

     Recognizing the need for a cleaner source of energy, and appreciating that ethanol is also renewable and can be produced in the United States, legislators have created federal and state incentives for ethanol production. These tax incentives allow the ethanol industry to compete successfully in domestic fuel markets with gasoline blended with MTBE produced by the oil industry. If these tax incentives are reduced or eliminated, or not renewed upon expiration, the ethanol industry, and our plant, may not be financially viable.

      Federal Incentives. Congress currently provides federal tax incentives for oxygenated fuel producers and marketers, including those who purchase ethanol to blend with gasoline in order to meet federally mandated oxygenated fuel requirements. The Energy Tax Act of 1978 exempted ethanol blended gasoline from the federal gas tax. As amended, the federal tax exemption allowed the market price of ethanol to compete with the price of domestic gasoline. The excise tax credit for gasoline blended with at least 10% ethanol was 5.2¢ per gallon. The subsidy was scheduled to drop to 5.1¢ per gallon in 2005. A gasoline marketer that sells gas without ethanol must pay a federal tax of 18.4¢ per gallon compared to 13.2 ¢ per gallon for gas with 10% ethanol. The tax on gasoline blended with 10% ethanol was scheduled to increase to 13.3¢ per gallon in 2005. Smaller credits are available for gasoline blended with 7.7% and 5.7% ethanol. The federal excise tax credit was scheduled to expire on September 30, 2007, but has been replaced by a new volumetric ethanol excise tax credit (“VEETC”) discussed below.

     In October 2004, the American Jobs Creation Act of 2004 was signed into law, which included the VEETC and amended the federal excise tax structure as of January 1, 2005. Under VEETC, the ethanol excise tax exemption was eliminated, thereby allowing the full federal excise tax to be collected and allocated to the federal highway trust fund. In place of the previous exemption, the bill created the

6


 

VEETC of 5.1¢ per gallon of ethanol blended at 10%. Refiners and gasoline blenders would apply for this credit on the same tax form as before. This credit is funded by the federal government’s general fund, not just the highway trust fund. Based on the volume, the VEETC may allow greater refinery flexibility in blending ethanol since it makes the tax credit available on all ethanol blended gasoline, diesel and ethyl tertiary butyl ether (“ETBE”), including ethanol in E-85 and the proposed E-20 in Minnesota. The VEETC is scheduled to expire on December 31, 2010.

     In addition, federal law provides income tax credits for “small ethanol producers,” which has been defined as facilities that produce up to 30 million gallons per year. Legislation has been introduced in Congress in 2005 to change the definition of a “small ethanol producer” to include facilities that produce up to 60 million gallons per year. We do not know if this legislation will be passed by Congress.

     In May 2002, Congress enacted the Farm Security and Rural Investment Act of 2002. The act extends through 2006 an U.S. Department of Agriculture producer payment program. Under the program, eligible producers that use corn and other agricultural products to manufacture biodiesel or fuel grade ethanol may receive quarterly payments from the federal government based on total annual production. Annual producers of 65 million gallons or less are reimbursed 1 feedstock unit for each 2.5 feedstock units of corn or other eligible commodities used for increased production. We believe that our plant will qualify in this category. Larger producers are reimbursed 1 feedstock unit for each 3.5 feedstock units. A feedstock unit represents one bushel of corn. No single producer may receive annual payments totaling more than 5% of the annual federal appropriation for the program which for October 2004 through September 2005 was $100 million. The annual federal appropriation level for the year 2005-2006 has not yet been determined and there is no guarantee that the program will be funded. Payments are prorated among producers to the extent that annually appropriated funds are insufficient to make full payments to each producer.

      Minnesota Producer Tax Incentive. Subject to potential budget cuts, Minnesota makes cash payments to Minnesota ethanol plants in operation on or before June 30, 2000. The payments originally were 20¢ per gallon, but, due to state funding cutbacks, are currently 13¢ per gallon of ethanol produced up to 15 million gallons. The payments are scheduled to increase to the original 20¢ per gallon in 2007 when, subject to available state funding, an additional 7¢ per gallon becomes payable to make up the difference between the current and original payment rates over the years of payment reduction. The payments apply to production at a qualifying plant during the ten years after the plant’s start of production, but not after June 30, 2010. If a qualifying plant adds production capacity, the cash payments apply to the new capacity to the extent that the plant’s total annual production capacity does not exceed 15 million gallons. Because we did not have a plant in production on or before June 30, 2000, we will not receive any Minnesota cash payments.

Future Ethanol Demand

     According to the Renewable Fuels Association, demand for ethanol has increased to 3.57 billion gallons for 2004. The following table shows the use of ethanol by market in 2004:

         
Market   Millions of Gallons  
Federal reformulated gasoline (“RFG”)
    1,950  
Conventional gasoline
    1,050  
Federal winter oxygenated fuels
    290  
Minnesota ethanol program (at 10%)
    280  
 
       
Total
    3,570  

7


 

     In addition, automobile companies have begun developing ethanol-friendly vehicles. Downstream Alternatives, Inc. reports that gasoline blends containing up to 10% ethanol are approved under the warranties of most major domestic and foreign automobile manufacturers marketing vehicles in the United States, and many recommend the use of cleaner burning fuel, such as ethanol, in their vehicle owner manuals. Similarly, the Renewable Fuels Association reports that most major manufacturers of power equipment, motorcycles, snowmobiles and outboard motors endorse the use of ethanol blends in their products. In the last several years, automobile companies have introduced a growing number of flexible fuel vehicles that operate on fuel mixtures of up to 85% ethanol. In addition, ethanol industry advocates have developed new diesel fuels, commonly referred to as “OxyDiesel,” which are a blend of diesel fuel and ethanol.

     In any event, we cannot assure that there will be future demand at adequate prices for ethanol that we produce at our plant.

Ethanol Pricing

     Historical and projected ethanol, corn and gasoline prices are shown in the following chart. Ethanol prices tend to track the wholesale gasoline price plus the federal tax incentive (5.2¢ per gallon). In 1996, high corn prices caused many ethanol plants to curtail operations.

     We cannot assure that actual future prices of ethanol, gasoline and corn will be consistent with the projected prices shown in the following chart.

Average Actual and Projected U.S. Market Pricing of Ethanol, Gasoline and Corn

(AVERAGE ACTUAL AND PROJECTED U.S. MARKET PRICING OF ETHANOL, GASOLINE AND CORN LINE GRAPH)

Source: AgDM newsletter article, June 2004

8


 

Description of the Dry Mill Process

     Our ethanol plant will use a dry milling process to produce fuel-grade ethanol as its main product, in addition to the co-product dry distillers grain. Our plant will have a design capacity to produce 50 million gallons of ethanol per year (50 mgy), and we expect the plant to produce approximately 150,000 tons of dry distillers grain annually. Our ethanol plant will produce ethanol by processing corn. We plan to purchase all of our corn from the Farmers Cooperative Elevator Company (sometimes referred to as the “Elevator”). See “Strategic Partners and Material Contracts — Agreement with Farmers Cooperative Elevator Company”.

     As we receive the corn, we will weigh it and move it to a surge bin. We will then transport the corn to a scalper to remove rocks and debris before we convey the corn to storage bins. Thereafter, we will transport the corn to a hammermill or grinder, where it is ground into a mash and conveyed into a tank for processing.

     We will break the ground corn into a fine liquid by adding water, heat and enzymes. We will then pump this liquid into fermenters and add yeast to begin a 65 to 75-hour batch fermentation process. After fermentation is complete, our distillation process will separate the ethanol from the remaining corn “whole stillage.” We will further remove water from the distilled ethanol by using a molecular sieve. We will blend the resulting 200 proof (i.e., pure) ethanol with gasoline as it is pumped into storage tanks.

     We will pump the whole stillage from the distillation process into one of several centrifuges. This will separate a thin stillage (that we will dry into a thick syrup) from the remaining solids, or “wet cake.” We may be able to sell the thick syrup as a separate byproduct of our ethanol production, but are not planning for this. Normally, to produce livestock and poultry feed-grade dry distillers grains, we will add the thick syrup to the wet cake as it enters a dryer to remove moisture.

     The diagram below illustrates this process.

(DRY MILL PICTURE)

9


 

Our Principal Products and Their Markets

     The principal products we will produce at our ethanol plant are ethanol and dry distillers grain. A third product, concentrated distillers solubles syrup, is a potential co-product that is normally sprayed on the distillers grain and dried. While carbon dioxide is also a co-product of the ethanol production process, we have not determined the potential demand for carbon dioxide in our local market and therefore do not currently intend to capture and sell the carbon dioxide produced at the plant.

      Ethanol. Ethanol is ethyl alcohol, a fuel component made primarily from corn and various other grains, and can be used as:

  •   An octane enhancer in fuels,
 
  •   An oxygenated fuel additive that can reduce ozone and carbon monoxide vehicle emissions and
 
  •   A non-petroleum-based gasoline extender.

     Ethanol has important applications and is used primarily as a high quality octane enhancer and an oxygenate capable of reducing air pollution and improving automobile performance. Approximately 95% of all ethanol is used in its primary form for blending with unleaded gasoline and other fuel products. As a fuel additive, the demand for ethanol is derived from the overall demand for gasoline, as well as the competition of ethanol versus competing oxygenate products and technologies. Motor vehicles in the United States consume more than 130 billion gallons of gasoline every year.

      Distillers Grains. A principal co-product of the ethanol production process are distillers grains, a high protein, high-energy animal feed supplement primarily marketed to the dairy and beef industry. Dry mill ethanol processing creates three forms of distillers grains: wet distillers grains, modified wet distillers grains and dry distillers grains. Wet distillers grain is processed corn mash that contains approximately 70% moisture. It has a shelf life of approximately 3 summer days (5 winter days) and can be sold only to farms within the immediate vicinity of an ethanol plant. Modified wet distillers grain is similar except that it has been dried to approximately 50% moisture. It has a slightly longer shelf life of approximately two to three weeks and is often sold to nearby markets. Dried distillers grain is corn mash that has been dried to 10% moisture. It has an almost indefinite shelf life and may be sold and shipped to any market regardless of its vicinity to an ethanol plant. Based on our current production process, we will only produce modified and dry distillers grain.

Corn Supply and Corn Prices

     To produce 50 mgy of ethanol per year, our ethanol plant will need approximately 18 million bushels of corn per year, or approximately 49,000 bushels per day, as the feedstock for its dry milling process. The grain supply for our plant will be obtained primarily from local markets. We plan to purchase all of our corn from the Farmers Cooperative Elevator Company (sometimes referred to as the “Elevator”). We will need to seek alternative corn supplies if the Elevator cannot meet our needs. See “ Strategic Partners and Material Contracts — Agreement with Farmers Cooperative Elevator Company”.

     Between 2001 and 2004, the county in which our plant is to be located, and the nearby counties, together averaged approximately 188 million bushels of corn production annually. The following table provides a summary of this information based on 2004 Minnesota Agriculture Statistics and the Minnesota Corn Growers Association. From this total production, we believe approximately 65 million bushels of corn will be produced annually within a 25-mile radius of our plant.

10


 

                                         
County   2001     2002     2003     2004     Average  
Chippewa
    19,232,400       24,185,400       21,006,900       22,467,600       21,723,075  
Lac Qui Parle
    19,781,000       23,894,400       18,436,700       23,730,000       21,460,525  
Lyon
    21,918,400       26,270,100       23,842,000       28,256,000       25,071,625  
Kandiyohi
    17,379,800       23,786,100       20,173,600       21,576,000       20,728,875  
Redwood
    30,132,000       35,733,200       34,458,400       40,321,800       35,161,350  
Renville
    32,058,000       40,137,500       36,859,000       41,787,200       37,710,425  
Yellow Medicine
    23,769,500       26,148,600       24,745,500       28,519,000       25,795,650  
     
 
                                       
Total
    164,271,100       200,155,300       179,522,100       206,657,600       187,651,525  

     The price and availability of corn are subject to significant fluctuations depending upon a number of factors affecting commodity prices in general, including crop conditions, weather, governmental programs and foreign purchases. Because the market price of ethanol is not related to grain prices, ethanol producers are generally not able to compensate for increases in the cost of grain feedstock through adjustments in prices charged for their ethanol. We therefore anticipate that our plant’s profitability will be negatively impacted during periods of high grain prices.

     In an attempt to minimize the effects of the volatility of corn costs on operating profits, we will likely take hedging positions in corn futures markets. Hedging means protecting the price at which we buy corn and the price at which we will sell our products in the future. It is a way to attempt to reduce the risk caused by price fluctuation. The effectiveness of hedging activities is dependent upon, among other things, the cost of corn and our ability to sell sufficient amounts of ethanol and distillers grains to utilize all of the corn subject to the futures contracts. Hedging activities can result in costs to us because price movements in grain contracts are highly volatile and are influenced by many factors beyond our control and these costs may be significant.

     From time to time, we will use the services of a risk management commodities firm to help us make corn procurement decisions and maintain a hedge account.

Utilities

     The production of ethanol is a very energy intensive process that uses significant amounts of electricity and natural gas. Water supply and quality are also important considerations.

     In September 2004, we hired a consultant to provide consulting services for supplies of natural gas and electricity for our plant. We paid the consultant a one-time fee of $15,000 plus pre-approved travel expenses per month incurred during our construction period and we will pay the consultant $2,400 plus pre-approved travel expenses per month following plant completion. The agreement commenced October 1, 2004 and continues for six months following plant completion and is month-to-month thereafter. After the initial term, either party may terminate the agreement upon sixty days notice.

      Energy Services. Significant strides have been made over the past 15 years to reduce the energy intensiveness of ethanol production. According to the National Corn Growers Association, in 2000, the industry average dry mill consumed about 49,000 BTUs of energy to produce a gallon of ethanol. Based on the performance guarantees in the design-build contract, we expect to use about 32,000 BTUs of natural gas per gallon produced.

      Natural Gas. We anticipate that our plant will require a natural gas supply of at least 750 million cubic feet per year at a minimum rate of 200 MCF per hour and at a minimum of 200 psig near the plant site. To

11


 

access sufficient supplies of natural gas to operate the plant, we will need a connection to an underground distribution pipeline at our site.

     In December 2004, we entered into an agreement with Center Point Energy/Minnegasco for the construction and maintenance of approximately 9.5 miles of an underground natural gas pipeline for the delivery of natural gas to our plant which we may purchase from other companies. We will pay Center Point Energy/Minnegasco a per unit fee to move the natural gas through our pipeline and have guaranteed movement of a minimum of 350,000 DT in calendar year 2005 and 1,400,000 DT annually thereafter through December 31, 2015, the end of the term. The agreement automatically renews thereafter for one year terms and may be terminated by either party upon one year’s prior written notice.

     Natural gas prices have historically fluctuated dramatically, which could significantly affect the profitability of our operations.

     We are also working towards finalizing agreements with natural gas providers.

      Electricity. Our proposed plant will require a continuous supply of 4.5 megawatts of electricity. In August 2004, we executed our agreement with Minnesota Valley Rural Electric Cooperative, our electrical service provider. Under this agreement, we will pay them a base fee of $8,000 per month plus regular rates for our electricity. We estimate we will pay Minnesota Valley approximately $1,000,000 for our first full year of operations.

      Water. We will require a significant supply of water. Based on information from Fagen Engineering, our design-builder’s subcontractor and affiliate, our plant water requirements will be 416 gallons per minute or 599,040 gallons per day. We are currently working with Fagen Engineering to finalize our fresh water requirements, including water treatment.

     We have drilled two separate wells for our water supply. One of the wells is on property currently owned by the Farmers Cooperative Elevator Company located about one mile from our plant site. We will need to build a pipeline from the Elevator’s property to our plant site. Although we have negotiated the terms of an easement agreement with the Elevator to pump water from this well, we will need to obtain easements from the county for our pipeline. Our other well is located on property partly owned by our project coordinator for which we have obtained an easement. However, we will need to obtain additional easements from other property owners to build a pipeline from this well to our plant site.

     If we are unable to obtain these easements on satisfactory terms or at all, or if these wells do not supply adequate amounts of water, we will need to locate additional water sources. As a result, we had been working on an alternative with the Army Corp. of Engineers to obtain water from the Minnesota River. Obtaining waters from local wells is our preferred course of action. If this is not feasible, we will obtain our water from the Minnesota River and resume our discussion with the Army Corps. of Engineers.

     Before pumping water from the wells, we must obtain water appropriation permits from the Minnesota Department of Natural Resources, which will determine if the location of each well will support a sufficient water supply and whether it is safe from any soil or ground water contamination. We anticipate receiving a three year conditional permit which will require us to frequently monitor and test the impact of our use of this well water over the short term.

     Much of the water used in an ethanol plant is recycled back into the process. There are, however, certain areas of production where we need fresh water. Those areas include boiler makeup water and cooling tower water. Boiler makeup water is treated on-site to minimize elements that may harm the boiler, and recycled water cannot be used for this process. Cooling tower water does not come in contact with the corn mash and, therefore, can be recycled back into the cooling tower process. The makeup water

12


 

requirements for the cooling tower are primarily a result of evaporation. Recycling has the long-term effect of lowering waste water treatment costs. Based on preliminary estimates from Fagen Engineering, we anticipate approximately 147 gallons per minute of effluent. Our current discharge permit is for approximately 83 gallons per minute. We are working to finalize these numbers with Fagen Engineering. This may cause us to amend certain permits if we are not able to reduce effluent quantities.

Our Primary Competition

     We will be in direct competition with numerous other ethanol producers, many of whom have greater resources than we do. We also expect that additional ethanol producers will enter the market if the demand for ethanol continues to increase. Our proposed ethanol plant will compete with other ethanol producers on the basis of price and, to a lesser extent, delivery service. We believe we can compete favorably with other ethanol producers due to our proximity to ample corn supplies at favorable prices.

     During the last twenty years, ethanol production capacity in the United States has grown from almost nothing to an annual production record of 3.4 billion gallons in 2004, an increase of 21 percent from 2.81 billion gallons in 2003 according to the Renewable Fuels Association. Plans to construct new plants or to expand existing plants have been announced which will increase capacity. The increase in capacity may continue in the future. We cannot determine the effect of this type of an increase upon the demand or price of ethanol, although these plants may compete with us in the sale of ethanol and related products.

     As of February 2005, the ethanol industry has grown to 83 production facilities in the United States with 17 additional facilities under new or expansion construction . The largest ethanol producers include Abengoa Bioenergy Corp., Tate & Lyle, AGP, Archer Daniels Midland (ADM) , Aventine Renewable Energy, Inc., Cargill, Chief Ethanol, MGP Ingredients, Inc., Midwest Grain Processors, New Energy Corp. and VeraSun Energy Corporation, each of which is capable of producing more ethanol than we expect to produce. According to the Renewable Fuels Association, as of February 2005, the following table identifies most of the producers in the United States along with their production capacities.

                         
 
U.S. FUEL ETHANOL PRODUCTION                    
CAPACITY                    
million gallons per year (mgy)                    
                    Under
            Current   Construction/
            Capacity   Expansions
COMPANY   LOCATION   FEEDSTOCK   (mmgy)   (mmgy)
Abengoa Bioenergy Corp.
  York, NE   Corn/milo     55          
  Colwich, KS         25          
  Portales, NM         15       15  
ACE Ethanol, LLC
  Stanley, WI   Corn     30          
Adkins Energy, LLC*
  Lena, IL   Corn     40          
AGP*
  Hastings, NE   Corn     52          
Agra Resources Coop. d.b.a. EXOL*
  Albert Lea, MN   Corn     40          
Agri-Energy, LLC*
  Luverne, MN   Corn     21          
Alchem Ltd. LLLP
  Grafton, ND   Corn     10.5          
Al-Corn Clean Fuel*
  Claremont, MN   Corn     30          
Amaizing Energy, LLC*^
  Denison, IA   Corn             40  
Archer Daniels Midland
  Decatur, IL   Corn     1070          
  Cedar Rapids, IA   Corn                
  Clinton, IA   Corn                
  Columbus, NE   Corn                

13


 

                         
                    Under
            Current   Construction/
            Capacity   Expansions
COMPANY   LOCATION   FEEDSTOCK   (mmgy)   (mmgy)
  Marshall, MN   Corn                
  Peoria, IL   Corn                
  Wallhalla, ND   Corn/barley                
Aventine Renewable Energy, Inc.
  Pekin, IL   Corn     100          
  Aurora, NE   Corn     40          
Badger State Ethanol, LLC*
  Monroe, WI   Corn     48          
Big River Resources, LLC*
  West Burlington, IA   Corn     40          
Broin Enterprises, Inc.
  Scotland, SD   Corn     9          
Bushmills Ethanol, Inc.*^
  Atwater, MN   Corn             40  
Cargill, Inc.
  Blair, NE   Corn     85          
  Eddyville, IA   Corn     35          
Central Iowa Renewable Energy, LLC*^
  Goldfield, IA   Corn             50  
Central MN Ethanol Coop*
  Little Falls, MN   Corn     20.5          
Central Wisconsin Alcohol
  Plover, WI   Seed corn     4          
Chief Ethanol
  Hastings, NE   Corn     62          
Chippewa Valley Ethanol Co.*
  Benson, MN   Corn     45          
Commonwealth Agri-Energy, LLC*
  Hopkinsville, KY   Corn     23          
Corn Plus, LLP*
  Winnebago, MN   Corn     44          
Dakota Ethanol, LLC*
  Wentworth, SD   Corn     50          
DENCO, LLC*
  Morris, MN   Corn     21.5          
East Kansas Agri-Energy, LLC*^
  Garnett, KS   Corn             35  
ESE Alcohol Inc.
  Leoti, KS   Seed corn     1.5          
Ethanol2000, LLP*
  Bingham Lake, MN   Corn     30          
Glacial Lakes Energy, LLC*
  Watertown, SD   Corn     50          
Golden Cheese Company of California*
  Corona, CA   Cheese whey     5          
Golden Grain Energy, LLC*
  Mason City, IA   Corn     40          
Golden Triangle Energy, LLC*
  Craig, MO   Corn     20          
Grain Processing Corp.
  Muscatine, IA   Corn     20          
Granite Falls Energy, LLC^
  Granite Falls, MN   Corn             50  
Great Plains Ethanol, LLC*
  Chancellor, SD   Corn     50          
Hawkeye Renewables, LLC
  Iowa Falls, IA   Corn     45          
Heartland Corn Products*
  Winthrop, MN   Corn     36          
Heartland Grain Fuels, LP*
  Aberdeen, SD   Corn     8          
  Huron, SD   Corn     14          
Husker Ag, LLC*
  Plainview, NE   Corn     24          
Iowa Ethanol, LLC*
  Hanlontown, IA   Corn     55          
Illinois River Energy, LLC^
  Rochelle, IL   Corn             50  
James Valley Ethanol, LLC
  Groton, SD   Corn     50          
KAAPA Ethanol, LLC*
  Minden, NE   Corn     40          
Land O’ Lakes*
  Melrose, MN   Cheese whey     2.6          
Lincolnland Agri-Energy, LLC*
  Palestine, IL   Corn     40          
Lincolnway Energy, LLC*^
  Nevada, IA   Corn             50  
Liquid Resources of Ohio^
  Medina, OH   Waste                
      Beverage             4  
Little Sioux Corn Processors, LP*
  Marcus, IA   Corn     49          
Merrick/Coors
  Golden, CO   Waste beer     1.5          
Michigan Ethanol, LLC
  Caro, MI   Corn     50          
MGP Ingredients, Inc.
  Pekin, IL   Corn/wheat                
      starch     78          
  Atchison, KS                    
Mid-Missouri Energy, Inc.*
  Malta Bend, MO   Corn     45          
Midwest Grain Processors*
  Lakota, IA   Corn     50       45  
Midwest Renewable Energy, LLC
  Sutherland, NE   Corn     15          
Miller Brewing Co.
  Olympia, WA   Brewery waste     0.7          
Minnesota Energy*
  Buffalo Lake, MN   Corn     18          

14


 

                         
                    Under
            Current   Construction/
            Capacity   Expansions
COMPANY   LOCATION   FEEDSTOCK   (mmgy)   (mmgy)
New Energy Corp.
  South Bend, IN   Corn     102          
Northeast Missouri Grain, LLC*
  Macon, MO   Corn     40          
Northern Lights Ethanol, LLC*
  Big Stone City, SD   Corn     50          
Northstar Ethanol, LLC^
  Lake Crystal, MN   Corn             50  
Otter Creek Ethanol, LLC*
  Ashton, IA   Corn     55          
Panhandle Energies of Dumas, LP^
  Dumas, TX   Corn/Grain Sorghum             30  
Parallel Products
  Louisville, KY   Beverage waste     5.4          
  R. Cucamonga, CA                    
Permeate Refining
  Hopkinton, IA   Sugars &                
      starches     1.5          
Phoenix Biofuels^
  Goshen, CA   Corn             25  
Pine Lake Corn Processors, LLC*^
  Steamboat Rock,                    
  IA   Corn             20  
Platte Valley Fuel Ethanol, LLC
  Central City, NE   Corn     40          
Pro-Corn, LLC*
  Preston, MN   Corn     40          
Quad-County Corn Processors*
  Galva, IA   Corn     23          
Reeve Agri-Energy
  Garden City, KS   Corn/milo     12          
Siouxland Energy & Livestock Coop*
  Sioux Center, IA   Corn     22          
Sioux River Ethanol, LLC*
  Hudson, SD   Corn     55          
Tall Corn Ethanol, LLC*
  Coon Rapids, IA   Corn     49          
Tate & Lyle
  Loudon, TN   Corn     67          
Trenton Agri Products, LLC
  Trenton, NE   Corn     30          
Tri-State Ethanol Co., LLC*
  Rosholt, SD   Corn     18          
United WI Grain Producers, LLC*^
  Friesland, WI   Corn             40  
U.S. Energy Partners, LLC
  Russell, KS   Milo/wheat                
      starch     40          
Utica Energy, LLC
  Oshkosh, WI   Corn     48          
VeraSun Energy Corporation
  Aurora, SD   Corn     102          
VeraSun Fort Dodge, LLC^
  Ft. Dodge, IA   Corn             110  
Voyager Ethanol, LLC*
  Emmetsburg, IA   Corn     50          
Western Plains Energy, LLC*
  Campus, KS   Corn     30          
Western Wisconsin Renewable
Energy, LLC*^
  Boyceville, WI   Corn             40  
Wyoming Ethanol
  Torrington, WY   Corn     5          
Total Existing Capacity
            3738.7          
Total Under Construction/Expansions
                    694.0  
Total Capacity
            4432.7          


*   farmer-owned
 
^   under construction
 
    Last Updated: February 2005


© 2000 Renewable Fuels Association

15


 

Operating Ethanol Plants in Minnesota

     Currently, there are 13 operational ethanol plants and three under construction in Minnesota, as follows:

      Agra Resources Coop (Exol). This facility is located in Albert Lea, Minnesota. It began production in 1999 and can produce 41 million gallons of ethanol annually. In 2004, the plant used 15.2 million bushels of corn.

      Al-Corn Clean Fuel. This facility is located in Claremont, Minnesota. It began production in 1996 and can produce 34 million gallons of ethanol annually. In 2004, the plant used 12.6 million bushels of corn.

      Archer Daniels Midland. This facility is located in Marshall, Minnesota. It began production in 1988 and can produce 40 million gallons of ethanol annually. In 2004, the plant used 14.8 million bushels of corn for ethanol production. The plant can also grind an additional 40 million bushels of corn for starch, sweeteners and other products.

      Central MN Ethanol Coop. This facility is located in Little Falls, Minnesota. It began production in 1999 and can produce 22 million gallons of ethanol annually. In 2004, the plant used 8.1 million bushels of corn.

      Chippewa Valley Ethanol Co. This facility is located in Benson, Minnesota, approximately 38 miles from our plant. It began production in 1996 and can produce 45 million gallons of ethanol annually. In 2004, the plant used 16.7 million bushels of corn.

      Cornerstone. This facility is located in Luverne, Minnesota. It began production in 1998 and can produce 21 million gallons of ethanol annually. In 2004, the plant used 7.8 million bushels of corn.

      Corn Plus, LLP. This facility is located in Winnebago, Minnesota. It began production in 1994 and can produce 47 million gallons of ethanol annually. In 2004, the plant used 17.4 million bushels of corn.

      DENCO, LLC. This facility is located in Morris, Minnesota. It began production in 1991 and can produce 24 million gallons of ethanol annually. In 2004, the plant used 9.0 million bushels of corn.

      Ethanol2000, LLP. This facility is located in Bingham Lake, Minnesota. It began production in 1997 and can produce 31 million gallons of ethanol annually. In 2004, the plant used 11.5 million bushels of corn.

      Heartland Corn Products. This facility is located in Winthrop, Minnesota. It began production in 1995 and can produce 37 million gallons of ethanol annually. In 2004, the plant used 13.7 million bushels of corn.

      Land O’ Lakes. This facility is located in Melrose, Minnesota. It began production in 1986 and can produce 3 million gallons of ethanol annually. The plant uses cheese whey, rather than corn, to produce ethanol.

      Minnesota Energy. This facility is located in Buffalo Lake, Minnesota, 47 miles from our plant. It began production in 1997 and can produce 19 million gallons of ethanol annually. In 2004, the plant used 7 million bushels of corn.

      Pro-Corn, LLC. This facility is located in Preston, Minnesota. It began production in 1998 and can produce 42 million gallons of ethanol annually. In 2004, the plant used 15.2 million bushels of corn.

16


 

     There are also two additional ethanol plants under construction in Minnesota in addition to our plant. Bushmills Ethanol, Inc., is a 40 mgy plant under construction in Atwater, Minnesota, approximately 50 miles from our plant, and which is being constructed by Fagen, our design-builder. Northstar Ethanol, LLC., is a 50 mgy plant under construction in Lake Crystal, Minnesota.

Operating Ethanol Plants in Eastern South Dakota

     Currently, there are several plants operating in eastern South Dakota near our plant as follows:

      Northern Lights Ethanol. This facility is located in Big Stone City, South Dakota, approximately 61 miles from Granite Falls. It began production in the summer of 2002 and can produce 50 million gallons of ethanol annually.

      Glacial Lakes Energy. This facility is located in Watertown, South Dakota, approximately 85 miles from Granite Falls. It began production in August 2002 and can produce 50 million gallons of ethanol annually. GLE, a significant investor and intended operator of our plant is the owner of this facility.

      VeraSun Energy Corporation. This facility is located in Aurora, South Dakota, approximately 88 miles from Granite Falls. It began production in the fall of 2003 and can produce 102 million gallons of ethanol annually.

     The nearest ethanol plant listed above is the ADM facility in Marshall, Minnesota, which is approximately 30 miles from Granite Falls. Despite the proximity of this plant and others to our proposed plant site, we believe there will be sufficient feedstock available within the local community and surrounding counties to supply our ethanol plant.

Competition from Alternative Fuel Additives

     Alternative fuels, gasoline oxygenates and ethanol production methods are continually under development by ethanol and oil companies with far greater resources than we have. New products or methods of ethanol production developed by larger and better financed competitors could provide them competitive advantages over us and harm our business.

     We expect to compete with producers of MTBE, a petrochemical derived from methanol that costs less to produce than ethanol. MTBE is a commonly used oxygenate used in fuels for compliance with federal Clean Air Act mandates, and is a major competitor of ethanol. Many major oil companies produce MTBE and strongly favor its use because it is petroleum-based. These companies have significant resources to market MTBE and to influence legislation and public perception of MTBE. These companies also have sufficient resources to begin production of ethanol should they choose to do so.

     We also will compete with producers of ETBE, another fuel oxygenate. ETBE’s advantages over ethanol in a blend include its low affinity for water and low vapor pressure. Because petroleum pipelines and storage tanks contain water in various amounts, ETBE’s low affinity for water allows it to be distributed through existing pipeline systems, as contrasted with ethanol which must be shipped via transport truck or rail car. In addition, blending ETBE with gasoline reduces the overall vapor pressure of the blend. In turn, this reduces the normal volatile organic compound evaporative emissions. ETBE is not widely commercially available yet, and it may suffer from the same negative environmental effects as MTBE. Scientific research to better define the environmental properties of ETBE is underway.

Marketing of our Ethanol and Distillers Grains

      Ethanol. We believe that most of our ethanol will be sold into local, regional and national markets throughout the United States by Aventine Renewable Energy, Inc., the re-marketer of all of our ethanol production. The local and regional markets include Minnesota, as well as markets in Colorado, Illinois,

17


 

Indiana, Iowa, Kansas, Missouri, Nebraska, South Dakota and Wisconsin. The national target markets for the facility will include the Pacific Northwest, the Southern and Southwest markets, as well as potential new markets on the East Coast and California due to anticipated MTBE phase-outs. See “Strategic Partners and Material Contracts — Marketing Agreement with Aventine Renewable Energy”.

      Distillers Grains. We believe that most of our distillers grains will be sold to cattle feeders and dairy operators in the western United States and primarily by Commodity Specialists Company (CSC), the re- marketer of all of our distillers grains production by rail. We will market our distillers grains production which is shipped by truck unless we also sell this to CSC. We will utilize the feed marketer employed by GLE to sell out distillers grains in western Minnesota. See “Strategic Partners and Material Contracts — Marketing Agreement with Commodity Specialists Company”.

Transportation and Delivery

     Transporting our ethanol and distillers grains is a significant expense that will vary based on transportation method, load size and destination. Because we have not yet determined where we will sell our products, we cannot estimate these costs. The plant will have the facilities to load ethanol and distillers grains onto trucks and rail cars. We expect that shorter hauls will be by truck and longer hauls will be by rail. On October 31, 2004, we executed a rail construction agreement with MGA Railroad Construction, Inc., for the construction of railroad tracks and switches at our plant site. We will pay MGA a total of approximately $1,114,000 for its construction activities. Payment is to be made on a monthly basis for work completed subject to a 10% retainage to be paid upon final completion .

     We expect that TC&W Railway will provide rail service directly to the proposed site and transport our products to other railroads including the Burlington Northern Sante Fe Railroad, a short distance away from our plant, or to railroads located in Minneapolis-St. Paul. Generally, the marketers of our products will negotiate freight rates with TC&W Railway and other railroads as well as certain trucking rates. In terms of freight rates, rail is considerably more cost effective than is truck transportation to the more distant markets.

Employees

     On October 13, 2004, our then existing Board of Governors elected Thomas Branhan as our Chief Executive Officer and General Manager and Michael Nealon as our Chief Financial Officer and Controller both of whom are employees of GLE. Messrs. Branhan and Nealon were designated by GLE pursuant to our operating and management agreement with GLE entered into as a condition to GLE’s and Fagen’s investment in us. Under our consulting agreement with GLE, we pay GLE $10,000 per month for consulting services during the construction and development of our plant. GLE is responsible for compensating Messrs. Branhan and Nealon for their services rendered to us. See “Strategic Partners and Material Contracts - Agreements with Glacial Lakes Energy, LLC”.

     Prior to completion of the plant construction and commencement of operations, we intend to hire 31 employees. Approximately ten of our employees will be involved primarily in management and administration and the remainder will be involved primarily in plant operations.

     Under our operating and management agreement with GLE, GLE will supply its own personnel to act as part-time contract officers and managers of our plant for the positions of Chief Executive Officer or General Manager, Commodities Manager, Environmental, Health and Safety Manager and Chief Financial Officer which it will be responsible for compensating.

     The following table represents the anticipated positions within the plant and the number of individuals we intend to employ for each position:

18


 

                 
    Provided by   No. of
Position   GLE   Employees
CEO/General Manager
    1          
CFO
    1          
Commodities Manager
    1          
Environmental, Health and Safety Manager
    1          
Feed Manager
    1          
Plant Manager
            1  
Operations Manager
            1  
Plant Controller
            1  
Maintenance Manager
            1  
Maintenance Assistants and Electrician
            4  
Boiler Operators
            4  
Production Supervisors
            4  
Plant Operators
            8  
Lab Supervisor
            1  
Lab Assistant
            1  
Grains Supervisor
            1  
Grains Operators/Material Handlers
            3  
Administrative Assistant/HR Coordinator
            1  
 
               
Total
    5       31  
 
               

     The position titles, job responsibilities and numbers allocated to each position may differ when we begin to employ individuals for each position.

     We intend to enter into written confidentiality and assignment agreements with our officers and employees. Among other things, these agreements will require such officers and employees to keep strictly confidential all proprietary information developed or used by us in the course of our business.

Strategic Partners and Material Contracts

Design-Build Agreement

     On August 31, 2004, we entered into our design-build contract with Fagen, one of our significant investors, for the design and construction of our ethanol plant. Fagen purchased 2,500 of our units in our Offering.

      About Fagen. Fagen is a privately-owned, heavy industrial contractor headquartered in Granite Falls, Minnesota, with extensive experience in the construction of agricultural-based facilities. In particular, Fagen has been the principal contractor and has performed work on many ethanol plant projects throughout the United States since its founding in 1988. Fagen’s ethanol project experience includes

19


 

services provided to over 47 different ethanol plants including the construction of the ethanol plant owned and operated by GLE, our significant investor and eventually the operator of our plant.

     Fagen’s understanding of operational efficiencies and integration are essential to our success. Fagen also has knowledge and support to assist our management team in executing a successful start-up. Fagen is a meaningful project participant because of its investment and desire to facilitate the project’s successful transition from start-up to day-to-day profitable operation.

     We have no control over Fagen, nor do we have knowledge of how many ethanol plants it can simultaneously construct. If Fagen agrees to construct more ethanol plants at the time it is constructing our plant than it can construct either timely or successfully, then the construction of our plant may be either substantially delayed or cancelled.

      General Terms and Condition of Agreement . In connection with our determination to increase the capacity of our proposed plant, we submitted to Fagen a change order changing the scope of the original project to also include the equipment and services necessary to expand the capacity of the plant to produce up to 50 million gallons of ethanol annually. The expansion would include adding one fermenter and one centrifuge for a total of four fermenters and five centrifuges, as well as other additional equipment. On October 28, 2004, the Company and Fagen accepted the change order. Our operations permit presently allows for the production of up to 47 million gallons of ethanol a year and we are in the process of amending the permit so we can produce up to our plant’s capacity.

     Based on this and other change orders, we expect to pay Fagen (on progress basis) approximately $47,986,000 for the design and construction of the plant, subject to further adjustments made in accordance with the terms of the design-build contract.

     We will make payments to Fagen on a progress billing basis, based upon monthly applications for payment for all work performed as of the date of the application. We will retain 10% of the amount submitted in each payment application. However, when 50% of the work is completed, we will pay the full amount of each payment application. When the ethanol plant is substantially complete, we will pay Fagen all amounts we have retained. If we do not pay all undisputed amounts due within ten days after the due date, we will be charged interest at a rate of 18% per annum.

     If this contract is terminated by us without cause or by Fagen for cause, we will be required to pay Fagen a fee of $1,000,000 as compensation for the limited right to use the work product created by Fagen

     If Fagen encounters “differing site conditions,” then there will be an adjustment in the contract price and time of performance if these conditions adversely affect Fagen’s costs and performance time. “Differing site conditions” refers to any concealed physical conditions at the site that:

  •   Materially differ from the conditions contemplated in the contract; or
 
  •   Any unusual conditions which differ materially from the conditions ordinarily encountered in similar work.

     Under our design-build agreement, Fagen is responsible for:

  •   Providing design services, such as architectural and engineering design services;
 
  •   Obtaining and installing the production equipment;
 
  •   Performing all work in accordance with all legal requirements;

20


 

  •   Obtaining all permits, approvals, licenses and fees related to the construction of the ethanol plant, except for environmental permits that we are responsible for;
 
  •   Performing its responsibilities in a safe manner to prevent damage, injury or loss;
 
  •   Providing a warranty that the work performed for us is new, of good quality, conforms to the contract and is free of defect in materials and workmanship;
 
  •   Correcting defects in materials and workmanship for one year after substantial completion;
 
  •   Obtaining insurance covering us for claims for worker’s compensation, disability, damage or destruction of tangible personal property; and
 
  •   Indemnifying, defending and holding us, our officers, governors, agents and employees harmless against any claims, losses, damages, liabilities, including attorney’s fees and expenses, for any claims arising from Fagen’s negligent acts or omissions.

     Under our design–build agreement, we are responsible for:

  •   Liability insurance to protect us from claims which may arise from performance of our responsibilities;
 
  •   Property insurance for the full insurable value of the ethanol plant;
 
  •   Indemnifying, defending and holding Fagen, its officers, governors, agents and employees harmless against any claims, losses, damages, liabilities, including attorney’s fees for any claims arising from our negligent acts or omissions;
 
  •   Rough grading the construction site to Fagen’s specifications;
 
  •   Constructing at least one access road of sufficient quality to withstand semi-truck traffic;
 
  •   Obtaining air quality construction and operating permits;
 
  •   Obtaining state pollutant discharge elimination and storm water runoff permits;
 
  •   Providing a continuous supply of natural gas of at least 750 million cubic feet per year and supply meter and regulators to provide burner tip pressures as specified by Fagen;
 
  •   Providing a continuous 4.5 megawatt supply of electricity, a high voltage switch, a substation, if required, and meter as specified by the electric company;
 
  •   Providing a water supply adequate for Fagen’s specifications;
 
  •   Providing for water discharge, if required; and
 
  •   Installing rail tracks, ties and ballast to the ethanol plant at grades specified by the rail service contractor.

     Fagen has the right to stop or postpone work and to make reasonable adjustments to the time for completion of the ethanol plant if any of the following occurs:

  •   We do not provide reasonable evidence indicating we have adequate funds to fulfill all of our contractual obligations, or do not pay amounts properly due under the progress payments;

21


 

  •   Any acts, omissions, conditions, events or circumstances that require stopping or postponing work beyond Fagen’s control, unless caused by Fagen;
 
  •   There are any hazardous conditions at the construction site; or
 
  •   Work on the ethanol plant has stopped for 60 consecutive days, or more than 90 days total, because of any order from us or a court or governmental authority, if the stoppage is not because of any act or omission of Fagen.

     We have the right to terminate the design-build contract for any reason. However, if our termination is without cause, then we must provide Fagen with 10 days prior written notice. In addition, we must pay Fagen for:

  •   All work completed and any proven loss, cost or expense incurred in connection with Fagen’s work;
 
  •   Reasonable costs and expenses attributable to the termination, including demobilization costs and amounts due to settle terminated contracts with subcontractors and consultants; and

      Early Completion Bonus. If the plant is substantially complete within the 425 days (14 months) from the date Fagen began construction, we will pay Fagen an early performance bonus of $8,000 per day for each day that substantial completion is achieved prior to the 425 days after the date of commencement. Based on a start date of December 1, 2004 and an anticipated substantial completion date of October 31, 2005, we may pay Fagen an early completion bonus of up to $736,000.

      No Consequential Damages. Neither Fagen nor us will be liable to the other for any consequential damages or losses such as loss of use, profits, business, reputation or financing.

      Performance Surety Bond. Fagen is not required to provide us with a performance and labor and material payment bond, or other form of performance security. This means that if Fagen does not perform, there will be no surety bond proceeds that could be used to complete the project. If Fagen withdraws from the project, we might be unable to complete the construction. This might cause us to abandon our business and could significantly reduce the value of our units.

      Timetable for Completion of the Project. Preliminary construction of the proposed plant by Fagen began on October 26, 2004. We gave notice to proceed with plant construction on December 1, 2004 which is the official start date of construction by Fagen for purposes of determining the performance bonus under the design-build contract. Based on estimates provided by Fagen, and assuming no adverse weather conditions, or delays in receiving necessary equipment, we expect to complete construction of the plant and begin producing ethanol and by-products by the end of October 2005. This schedule also assumes that weather, interest rates and other factors beyond our control do not upset our timetable. Factors or events beyond our control could hamper our efforts to complete the project in a timely fashion.

Agreements with Glacial Lakes Energy, LLC. (“GLE”)

     As a condition to GLE’s purchase of 6,500 membership units from us, we entered into a consulting agreement with GLE and an operating and management agreement each discussed below.

      About GLE. GLE is located in Watertown, South Dakota approximately 85 miles from our plant, and was formed for the purpose of constructing and operating an ethanol plant. In August 2001, GLE began

22


 

construction of an ethanol production facility in Watertown, South Dakota. GLE began production at its facility in August 2002 and currently produces 50 million gallons of ethanol annually. We believe that GLE’s experience in the construction and operation of ethanol facilities benefit us greatly. We previously have had no relationship with GLE.

      Consulting Agreement with GLE. We entered into a consulting agreement with GLE effective July 2004, which we negotiated at arm’s length. Under the consulting agreement, GLE assists in planning, and directs and monitors, the construction of our proposed ethanol plant, including supervising any bidding process, letting all contracts, approving work schedules, making progress payments, securing lien waivers, enforcing our contractual rights and warranty claims and all other things necessary to bring construction of our facility to substantial completion. GLE services commenced in August 2004.

     As part of the agreement, GLE supplies its own personnel to act as part-time contract officers and managers of our plant for the positions of Chief Executive Officer or General Manager, and Chief Financial Officer. We pay GLE $10,000 per month for its consulting services and reimburse GLE for its pre-approved expenses, other than for travel to and from our facility. The consulting agreement will terminate upon the effective date of our operating and management agreement with GLE or sooner if we abandon our project.

      Operating and Management Agreement with GLE. We also entered into an operating and management agreement with GLE, which we have also negotiated at arm’s length. Under the operating and management agreement, it is anticipated that beginning one to three months prior to the estimated completion of our plant’s construction, GLE will begin to perform all services necessary for the equipping, start -up and ongoing operation of our ethanol plant. Subject in all cases to oversight by our Board of Governors (and, to the extent applicable, our audit committee), GLE’s contract services will include all activities incident to the day-to-day operations of our plant, such as:

  •   obtaining and maintaining compliance with all necessary permits and licenses for our plant;
 
  •   hiring, promoting, discharging and supervising the work of plant employees and arranging for payment of their wages;
 
  •   directing the audit and accounting functions with respect to our plant;
 
  •   within the budget set by the Board of Governors, contracting for the purchase of goods and services, equipment and fixtures for our plant;
 
  •   within the budget set by the Board of Governors, arranging for necessary repairs, additions and improvements to our plant;
 
  •   directing all grain purchasing and commodities risk management;
 
  •   directing the marketing of ethanol and other products manufactured at our facility;
 
  •   directing the preparation of our tax returns, SEC and other filings;
 
  •   commencing or defending litigation or other legal proceedings on our behalf; and
 
  •   preparing reports for our Board of Governors and members on our business and finances.

     As part of the agreement, GLE will supply its own personnel to act as part-time contract officers and managers of our plant for the positions of Chief Executive Officer or General Manager, Commodities Manager, Environmental, Health and Safety Manager and Chief Financial Officer.

23


 

     For GLE’s services, we have agreed to pay GLE a $35,000 monthly fee, plus an annual fee equal to 3% of our net income excluding revenues received under government programs. The monthly fee will be adjusted every three years for changes in the Consumer Price Index. We have also agreed to indemnify GLE against third parties claims brought against GLE on account of its contract services under the agreement, unless due to wrongful conduct by GLE.

     The initial term of the operating and management agreement is for five years. The agreement will automatically renew for successive one-year terms unless terminated 180 days prior to the start of a renewal term. We may also replace GLE upon notice by a vote of 75% of our disinterested governors if GLE materially breaches its obligations under the agreement.

Grain Procurement Agreement with Farmers Cooperative Elevator Company (the “Elevator”)

     At GLE’s request, in May 2004 we renegotiated our corn supply arrangements with the Elevator and entered into a new 12-year grain procurement agreement with the Elevator. Based on the new arrangements, the Elevator will no longer construct a new facility on the land it owns next to our site. We will construct the grain handling system on our site.

     The elevator will be the exclusive source of corn for our ethanol plant. We will pay weekly at market price (generally based on the daily posted board price at the Elevator’s Minnesota Falls branch) for corn delivered to us, subject to adjustments for corn of inferior quality or with excess moisture. We will also pay a weekly corn procurement fee of $0.05 per bushel of corn delivered. The corn procurement fee will increase in the fourth and eighth years of our agreement to $0.055 and $0.06, respectively, per bushel of corn delivered.

     The Elevator owns 605 of our membership units, of which 600 units were purchased in our Offering.

Marketing Agreement with Aventine Renewable Energy (“Aventine”)

     On August 31, 2004, we executed a two year renewable ethanol marketing agreement with Aventine whereby Aventine will purchase from us for re-marketing all of our ethanol production. We will receive the average net selling price (net of freight, transportation costs and commissions paid to Aventine) in a given month of ethanol sales by Aventine on behalf of us and eleven other ethanol plants. Our agreement begins with our first shipment of ethanol to Aventine. Aventine will be responsible for negotiating freight rates with railroads for the transport of our ethanol.

     Aventine purchased 500 of our membership units in our Offering.

Marketing Agreement with Commodity Specialists Company (“CSC”)

     On December 1, 2004, we executed a distillers grains marketing agreement with CSC whereby CSC will purchase from us for re-marketing all of our distillers grains that is shipped by rail from our plant and that amount of production that is shipped by truck that we choose to sell to CSC. The agreement commences upon the start-up of our plant and may be terminated by either party at any time upon 90 days notice after the first year. We will receive from CSC the net selling price (net of freight costs and commissions paid to CSC) that CSC receives from its customers. Our distillers grains must meet minimum quality feed trade standards. The price of distillers grains generally varies with grain prices, so that increases in grain costs are partially offset by increases in distillers grain prices. CSC will be responsible for negotiating freight rates with carriers for the transport of our distillers grains by rail.

     CSC purchased 100 of our membership units in our Offering.

24


 

Loan Agreement with First National Bank of Omaha (the “Bank”)

     On December 16, 2004, we entered into a Loan Agreement with the Bank to funding a portion of the cost of our ethanol plant. Under the loan agreement, the Bank has provided to us a construction loan up to $34,000,000, a revolving line of credit of $3,500,000, and standby letters of credit up to $1,000,000. As security for the Bank’s loans to us, we have granted the Bank a security interest in all of our assets and a mortgage on our real estate. We have no amounts outstanding yet under these facilities.

      Our Construction Loan From now until March 10, 2006, we will pay interest quarterly on amounts borrowed under the construction loan at a variable interest rate equal to one-month LIBOR plus 3.50%. Amounts borrowed under the construction loan will mature and convert into three term loans aggregating up to $34,000,000 on March 10, 2006 or earlier under certain conditions. The maturity date of each term loan will be March 10, 2011 and interest accrues on each term loan at a variable rate based upon one or three month LIBOR plus 3.00-3.50% depending on the particular loan. In addition to the required payments under the term loans, we will have to make an additional principal payment equal to 15% of our “excess cash flow” as defined in the loan agreement within 120 days of our calendar year-end.

      Our $3,500,000 Revolving Line of Credit and Letters of Credit. From now until December 15, 2005, we may borrow up to or request letters of credit not exceeding $3,500,000 in the aggregate under our revolving line of credit. We will pay interest monthly on amounts outstanding under the revolving line of credit at a variable rate based upon one month LIBOR plus 3.50%. We may also obtain up to an additional $1,000,000 in standby letters of credit.

      Commitment and Fees Payable to the Bank. We have paid the Bank $305,000 in due diligence, negotiation and commitment fees and we will pay the Bank an annual servicing fee of $30,000. Additionally, we will pay the Bank quarterly an unused commitment fee equal to 0.375% of the average unused portion of the $3,500,000 revolving line of credit beginning with the initial advance or March 10, 2006, whichever is earlier and the $5,000,000 long term revolving note which is one of the term loans beginning March 10, 2006. We are subject to a prepayment penalty ranging from 1-2% of the total facility if we were to prepay all or substantially all of the outstanding amounts prior to March 10, 2009.

      Loan Covenants and Indemnification Obligations. We are subject to various financial and non-financial loan covenants that include among other items minimum working capital amounts, minimum fixed charge coverage ratios and minimum net worth requirements. We are permitted to make distributions once a year (after the Bank’s receipt of a completed annual audit) of between 65% to 70% of our net income as long as we are in compliance with these and other loan covenants. After the conversion to the term loans, capital expenditures in excess of $500,000 in a fiscal year require the Bank’s prior approval. We have also agreed to indemnify the Bank for any claims or causes of actions arising out of the construction of our ethanol plant.

      Events of Default. We are subject to standard and customary events of default including (a) our failure to make timely payments to the Bank or other third parties who we owe more than $100,000, (b) our failure to perform our obligations under the Loan Agreement, (c) our failure to pay our debts as they mature, or we file or have filed against us a bankruptcy or similar proceeding, (d) a receiver or trustee is appointed for us or for our assets or a proceeding in dissolution or liquidation is commenced and is not discharged within 60 days, (e) Fagen ceases to be our general contractor under our design-build agreement, or (f) we abandon our ethanol plant project.

     If an event of default shall occur, the Bank may cease further disbursements, declare the loans terminated, declare the entire unpaid principal amount and any accrued and unpaid interest due and payable, and enforce its rights as a secured creditor including foreclosing upon its security interest and mortgage and taking possession of the property.

25


 

Regulatory Compliance and Permits

     Ethanol production involves the emission of various airborne pollutants, including particulate matter, carbon monoxide, carbon dioxide, nitrous oxide, volatile organic compounds and sulfur dioxide. To operate the ethanol plant, we require permits issued by the State of Minnesota. There is no assurance that we will be able to obtain all necessary permits to operate the ethanol plant. Further, we may be subject to regulations on emissions from the U.S. Environmental Protection Agency (“EPA”) or to additional regulations on emissions from the State of Minnesota. Currently, the EPA’s statutes and rules do not require us to obtain EPA approval to operate the ethanol plant, but this may change in the future. The EPA has in the past expressed concerns over the discovery of certain “volatile organic compounds” emissions some of which may be carcinogenic and has cautioned ethanol producers that it will sue companies whose plants do not comply with applicable laws and regulations. Additionally, the Minnesota Pollution Control Agency imposed penalties in 2002 on 12 Minnesota plants for alleged excessive air pollution resulting from inefficient control technology. The EPA has settled complaints for Clean Air Act violations with ethanol plants in Minnesota, Illinois, Wisconsin and Kansas. We intend to use the best available control technology, where required, in our proposed ethanol plant. There is no assurance that this will be sufficient to satisfy applicable EPA or Minnesota requirements or that such requirements will not change in the future.

     We continue to work towards obtaining all required permits for the construction of our ethanol plant. We have obtained a majority of the required air, water and other permits for our proposed plant which are summarized below.

      Minnesota Air Emissions Permits. We filed our Environmental Assessment Worksheet and Air Quality Permit Application with the Minnesota Pollution Control Agency (“MPCA”). Approval of the worksheet and our air emissions permit is required before beginning plant construction. Our air emissions permits were granted by MPCA in April 2004 and is valid for five years, subject to compliance monitoring.

      National Pollutant Discharge Elimination Permit. Before commencing operations at the plant, are required to obtain a National Pollutant Discharge Elimination Permit for any water discharges and surface water runoff. Specifically, we will use a significant amount of water per day to cool our closed circuit systems in the proposed ethanol plant and to produce ethanol. In April 2003, we filed for the National Pollutant Discharge Elimination Permit application with the MPCA. This was granted in May 2004 and is valid for five years, subject to compliance monitoring.

      Well Permits. We have drilled two separate wells for our water supply. One of the wells is on property currently owned by the Farmers Cooperative Elevator Company located about one mile from our plant site. Our other well is located on property partly owned by our project coordinator for which we have obtained an easement. Before pumping water from the wells, we must obtain water appropriation permits from the Minnesota Department of Natural Resources, which will determine if the location of each well will support a sufficient water supply and whether it is safe from any soil or ground water contamination. We anticipate receiving a three year conditional permit which will require us to frequently monitor and test the impact of our use of this well water over the short term.

      Spill Prevention, Control and Countermeasures Plan. We must prepare a spill prevention, control and countermeasures plan in accordance with standards set by the Environmental Protection Agency. The plan will outline our spill prevention measures for oil-based products such as denatured ethanol and will be supervised by the MPCA. The plan must be reviewed and certified by a professional engineer.

      Alcohol and Tobacco Tax and Trade Bureau (“TTB”) Requirements. Because ethanol is made from potentially human-consumable alcohol, we must comply with applicable TTB regulations. These regulations require us to apply for and obtain an alcohol fuel producer’s permit before commencing operations. The application must identify the principal persons involved in us and state whether any of

26


 

these persons has ever been convicted of a felony or misdemeanor under federal or state law. The term of the permit is indefinite until terminated, revoked or suspended. The permit also requires that we maintain particular security measures, secure an operations bond and comply with specific tax provisions. We sent an application for this permit on March 2, 2005.

      Construction Permit. Because our proposed plant site is within two miles of the City of Granite Falls, we are required to obtain a construction permit from the City which we received in October 2004. From time to time, we may need to seek an amendment to this permit depending upon our final construction designs for the plant.

     In addition to the foregoing, we have also obtained the following relevant permits:

  •   In June 2004, we received a Conditional Water Use Permit for the Minnesota River from Chippewa County;
 
  •   In July 2004, we received an Above Ground Storage Tank Permit (effective September 1, 2004) from the MPCA;
 
  •   In August 2004, we received a Construction Storm Water Permit from the MPCA.

Nuisance

     Even if we receive all Minnesota environmental permits for construction and operation of the ethanol plant, we may be subject to the regulations on emissions by the Environmental Protection Agency. We could also be subject to environmental or nuisance claims from adjacent property owners or residents in the area arising from odors or other air or water discharges from the plant.

27


 

RISK FACTORS

      You should be aware that there are various risks associated with constructing and operating an ethanol plant and owning and interest in our company You should carefully consider these risk factors, together with all of the other information included herein.

Risks Associated with Construction and Development

We may need to select an alternative water source for the ethanol plant, increasing our costs and delaying construction and our ability to generate revenues.

     There is not adequate underground well water at our site in Granite Falls, Minnesota. We have drilled two separate wells for our water supply. One of the wells is on property about one mile from our plant currently owned by the Farmers Cooperative Elevator Company a member of us whose general manager and one of its board members are two of our governors. Our other well is located on property partly owned by our project coordinator. We have obtained the necessary easements from both these parties. However, we must obtain additional easements from the county and other property owners to build the necessary pipelines from these wells to our plant site. If we are unable to obtain these easements on satisfactory terms or at all, we will need to locate additional wells. If we need to locate additional wells for our water supply for this or any other reason, we likely will incur delays in beginning construction, increasing our costs and delaying the time when we may begin to generate revenues from products manufactured at our plant. This could reduce the value of your membership units.

We will incur additional expense if the Farmers Cooperative Elevator Company fails to supply us with corn.

     Our plan of operations assumes that the Farmers Cooperative Elevator Company, a member of us whose general manager and one of its board members are two of our governors, will supply our entire corn requirements. We cannot assure that the Farmers Cooperative Elevator Company can supply corn to us at a competitive price. If we cannot obtain our requirements from the Farmers Cooperative Elevator Company, we will need to seek alternative sources. This could have a material adverse impact on our financial position and the value of your units.

The project could suffer delays that could postpone our ability to generate revenues and make it more difficult for us to pay our debts.

     We commenced construction of our plant in October 2004 following the closing of our offering. We expect that it will be an estimated 12 to 14 months after we begin construction before we begin operation of the proposed ethanol plant. Construction projects often involve delays in obtaining construction permits, construction delays due to weather conditions, environmental issues or other events that delay the construction schedule. If it takes longer to obtain necessary permits or construct the plant than we

28


 

anticipate, it would delay our ability to generate revenues and make it difficult for us to meet our debt service obligations. This could reduce the value of your membership units. Additionally, the longer it takes us to generate revenue, the longer you will have to wait to receive any distributions from us.

     The project could also be delayed if we encounter defective material or workmanship from Fagen which could delay production and our ability to generate revenues. We have not required Fagen to provide a performance bond or other guaranty that it can construct our plant. Under its proposed design-build contract, Fagen warrants that the ethanol plant will be free from defects in material or workmanship. If this warranty is breached and there are defects in material or workmanship, it may delay our commencing operations and delay our ability to generate revenues. If we discover defects after we begin operating, it could cause us to halt or discontinue our operations, which could damage our ability to generate revenues and reduce the value of your membership units. Our recourse in the event of a breach of this warranty by Fagen is to file an action against Fagen for breach of contract or breach of warranty which will be subject to the applicable statutes of limitations under the laws of the State of Minnesota.

Risks Associated with Our Formation and Operation

We are a newly formed company with limited working capital which could result in losses affecting the value of your membership units.

     We were organized on December 29, 2000 and have no operating history. We continue to be in our development stage. We have limited experience on which to base any conclusion as to whether we can be successful in the proposed construction and operation of the ethanol plant. We cannot assure you that our plans will materialize or prove successful. We cannot make representations about our future profit potential or our future income or losses. We do not know whether we will ever operate at a profit or if our membership units will appreciate in value. If our plans prove to be unsuccessful, you will lose all or a substantial part of your investment.

     The proceeds from our offering and our debt financing will be used to continue constructing the ethanol plant and to meet our initial operational needs. Our proposed use of such proceeds will pay our expenses for only a limited amount of time and there can be no assurance that the funds received through the offering and our debt financing will be sufficient to allow us to continue successfully.

GLE and Fagen may be able to control our business and affairs, and their interests may conflict with ours.

     Because of their right to appoint particular Governors, GLE and Fagen may be able to control, or significantly influence, decisions of our Board of Governors. In addition, we have entered into agreements with GLE giving it and its officers comprehensive, day-to-day management authority over our business and finances. As a result, GLE and Fagen could make decisions that adversely our other members. In addition, GLE’s and Fagen’s control over us could deter third parties from making an offer to acquire our business, which might harm investors.

We will depend on GLE and its officers, who will dedicate only part-time efforts to us.

     Under our agreement with GLE, GLE provides contract management of our business. GLE’s officers provide services to us on a part-time basis, without any specific time commitments. We cannot assure that the inherent conflicts of interest that will arise will not harm us.

29


 

Our success depends on hiring competent personnel, which may be difficult to attract to a rural community.

     Prior to completion of the plant, we plan to have 31 employees and the services from five personnel provided by GLE operating our business. Our success will depend in part on our ability to attract and retain competent personnel who will be able to help us achieve our goals. We must hire qualified managers, accounting, human resources and other personnel to staff our business. It may be difficult finding and hiring qualified employees at a salary that we will be able to afford. It may also be difficult to attract qualified employees to Granite Falls, Minnesota, a rural community. If we are unable to hire productive and competent personnel, our ability to produce and sell ethanol could be adversely affected. This would reduce our revenues and the value of your membership units.

Our Operating and Member Control Agreement contains restrictions on member’s rights to participate in corporate governance of our affairs.

     Our Operating and Member Control Agreement contains significant restrictions on a member’s rights to influence the manner or direction of management. Our Operating and Member Control Agreement contains restrictions on the ability of members to call a special meeting. A member or members owning at least 10% of the outstanding membership units may call a special meeting of the members. These restrictions may make it difficult for members to propose changes to our Operating and Member Control Agreement, without support from our Board of Governors. Our governors are divided into three classes. At each annual meeting of members, the members will elect governors of one class to serve for a three-year term. The classification of the Board of Governors will make it more difficult for members to change the composition of the Board because only a minority of the governors can be elected at one time. If a vacancy develops in our Board of Governors, the remaining governors may fill it.

     Our governors must discharge their duties with reasonable care, in good faith and in the best interest of us and our members. Despite this obligation, our Operating and Member Control Agreement generally eliminates governor liability to members and us unless it involves misconduct or negligence.

    We conduct business with affiliates whose interests may conflict with ours.

     We entered into material contracts negotiated at arms’ length with affiliates that own units in us and have been heavily involved in our formation and operation. Fagen, our ethanol design-build contractor, is a member of us and one of its employee is a member of our Board of Governors. GLE is a member of us and is providing contract management services to us and will eventually operate and manage our plant operations. One of the board members of the Farmers Cooperative Elevator Company is a member of our Board of Governors. We will be accessing our water requirements on property currently owned by the Elevator and we will obtain our entire supply of corn from the Elevator, which itself is a member of us. We cannot assure you that these conflicts will not harm our business. Most of the members of our Board of Governors have also purchased units for their own accounts, and may purchase additional units. The various conflicts are discussed in the section entitled “Certain Transactions and Conflicts of Interest.”

Risks Associated with the Ethanol Industry

    Competition from other and larger ethanol producers may impact our profitability.

     There is significant competition among ethanol producers. Our business faces a competitive challenge from larger producers, from plants that can produce a wider range of products than we can, and from other plants similar to our proposed ethanol plant. Our ethanol plant will be in direct competition with other ethanol producers, many of which have greater resources than we currently have. Large ethanol producers such as Archer Daniels Midland (ADM), Aventine Renewable Energy, Inc., Cargill and

30


 

VeraSun Energy Corporation, among others, are capable of producing a significantly greater amount of ethanol than we expect to produce. In addition, there are several Minnesota, Nebraska, South Dakota, Wisconsin and other Midwest regional ethanol producers which have recently formed, are in the process of forming or are under consideration, which are or would be of a similar size and have similar resources to us. There are currently 13 operational ethanol plants in Minnesota and two others under construction. ADM operates an ethanol plant approximately 30 miles from our proposed plant site.

Competition from large producers of petroleum-based gasoline additives and other competitive products may impact our profitability.

     Our proposed ethanol plant will also compete with producers of other gasoline additives made from raw materials other than corn having similar octane and oxygenate values as ethanol, such as producers of MTBE. MTBE is a petrochemical derived from methanol which generally costs less to produce than ethanol. Many major oil companies produce MTBE and strongly favor its use because it is petroleum-based. Alternative fuels, gasoline oxygenates and alternative ethanol production methods (including the use of cellulose-based biomass such as agricultural waste, forest residue, municipal solid waste and energy crops are also continually under development. The major oil companies have significantly greater resources than we have to market MTBE, to develop alternative products and to influence legislation and public perception of MTBE and ethanol. These companies also have significant resources to begin production of ethanol should they choose to do so.

    Our profits and the value of your investment are impacted by corn supply and prices.

     Ethanol production will require substantial amounts of corn. Corn, as with most other crops, is affected by weather, governmental policy, disease and other conditions. A significant reduction in the quantity of corn harvested due to adverse weather conditions, farmer planting decisions, domestic and foreign government farm programs and policies, global demand and supply or other factors could result in increased corn costs which would increase our cost to produce ethanol. The significance and relative impact of these factors on the price of corn is difficult to predict. Significant variations in actual growing conditions from normal growing conditions also may adversely affect our ability to procure corn for the proposed plant. Any events that tend to negatively impact the supply of corn will tend to increase prices and harm our business.

     Rising corn prices produce lower profit margins for the production of ethanol and therefore, represent unfavorable market conditions. This is especially true when market conditions do not allow us to pass along increased corn costs to our customers. The price of corn has fluctuated significantly in the past and may fluctuate significantly in the future. Substantial increases in the price of corn in 1996 caused some ethanol plants to temporarily cease production or lose money. We cannot assure you that we will be able to offset any increase in the price of corn by increasing the price of our products. If we cannot offset increases in the price of corn, our financial performance may be materially and adversely affected. We have entered into an agreement with the Farmers Cooperative Elevator Company, an affiliate of ours, to supply corn for our proposed ethanol plant. However, corn prices under this agreement will fluctuate with the market and will therefore be unpredictable.

    We may be unable to profitably resell our ethanol and dry distillers grains.

     We have entered into marketing agreements for marketing most of the ethanol and dry distillers grains we produce. The marketers will market our ethanol and byproducts in national, regional and local markets. As a result, we will be dependent on these marketers or distributors to sell our ethanol and dry distillers grains. We do not plan to build our own sales force or sales organization to support the sale of ethanol or byproducts. We cannot assure that we can resell our products profitably in this manner.

31


 

Low ethanol and gasoline prices could reduce our profitability, depressing the value of your membership units.

     Prices for ethanol products can vary significantly over time and decreases in price levels could adversely affect our profitability and viability. The price for ethanol has some relation to the price for gasoline. The price of ethanol tends to increase as the price of gasoline increases, and the price of ethanol tends to decrease as the price of gasoline decreases. Any lowering of gasoline prices will likely also lead to lower prices for ethanol and adversely affect our operating results. We cannot assure that we will be able to sell our ethanol profitably, or at all.

Ethanol production increases could reduce ethanol and dry distillers grains prices, reducing our profitability.

     New ethanol plants are under construction or planning throughout the United States. We also expect that existing ethanol plants will expand to increase their production. Despite the increased production, there may be no material or significant increases in ethanol demand. As a result, ethanol and dry distillers grain prices may fall. Further, this increased ethanol production could increase corn demand and prices, resulting in higher production costs and lower profits.

    We could lose money through our planned hedging activities.

     In an attempt to minimize the effects of the volatility of corn costs on operating profits, we will likely take hedging positions in corn futures markets. Hedging means protecting the price at which we buy corn and the price at which we will sell our products in the future. It is a way to attempt to reduce the risk caused by price fluctuation. The effectiveness of hedging activities is dependent upon, among other things, the cost of corn and our ability to sell sufficient amounts of ethanol and distillers grains to utilize all of the corn subject to the futures contracts. Hedging activities can result in costs to us because price movements in grain contracts are highly volatile and are influenced by many factors beyond our control. We may incur similar costs in connection with our hedging transactions and these costs may be significant.

Price increases or interruptions in energy supplies could impair our profitability.

     Ethanol production requires a constant and consistent supply of energy. If there is any interruption in our supply of energy for whatever reason, such as supply, delivery or mechanical problems, we may be required to halt production. If we halt production for any extended period of time, it will have a material adverse effect on our business. If we suffered interruptions in our energy supply, either during construction or after we begin operating the ethanol plant, our business would be harmed.

     Although we have begun preliminary negotiations with a natural gas supplier, we have no binding commitments for our natural gas requirements. If we are unable to obtain a natural gas supply or procure an alternative source of natural gas on terms that are satisfactory to us, the adverse impact on our plant and operations could be material. In addition, natural gas and electricity prices have historically fluctuated significantly. Increases in the price of natural gas or electricity would harm our business by increasing our energy costs.

     We will also need to purchase significant amounts of electricity to operate our proposed ethanol plant.The prices we pay for electrical power will have a direct impact on our costs of producing ethanol and our financial results.

32


 

    Transportation costs have a significant impact on our profitability.

     We will ship our ethanol mostly by railroad to other parts of the United States for sale. The marketers of our products are responsible for negotiating freight rates with the railroads that will transport our products. Transportation costs may affect demand for our ethanol or reduce our profitability if our marketers cannot pass the costs on to our customers.

Risks Associated with Government Regulation and Subsidization

    Federal regulations concerning tax incentives could expire or change which could reduce our revenues.

     Congress currently provides certain federal tax credits for ethanol producers and marketers. The ethanol industry and our business depend on continuation of these credits. The credits have supported a market for ethanol that might disappear without the credits. The credits are scheduled to expire December 31, 2010, based on the new volumetric ethanol excise tax credit (VEETC) included in the American Jobs Creation Act of 2004 passed in October 2004. These credits may not continue beyond their scheduled expiration date or, if they continue, the incentives may not be at the same level. The revocation or amendment of any one or more of these tax incentives could adversely affect the future use of ethanol in a material way, and we cannot assure you that any of these tax incentives will be continued. The elimination or reduction of federal tax incentives to the ethanol industry would have a material adverse impact on our business by making it more costly or difficult for us to produce and sell ethanol. If the federal ethanol tax incentives are eliminated or sharply curtailed, we believe that a decreased demand for ethanol will result.

We are not eligible for Minnesota state ethanol producer incentives, which will place us at a competitive disadvantage as compared to other producers who receive state payments.

     Subject to potential budget cuts, Minnesota makes cash payments to qualifying Minnesota ethanol plants in operation on or before June 30, 2000. The payments originally were 20¢ per gallon, but, due to state funding cutbacks, are currently 13¢ per gallon of ethanol produced up to 15 million gallons. The payments are scheduled to increase to the original 20¢ per gallon in 2007 when, subject to available state funding, an additional 7¢ per gallon becomes payable to make up the difference between the current and original payment rates over the years of payment reduction. The payments apply to production at a qualifying plant during the ten years after the plant’s start of production, but not after June 30, 2010. If a qualifying plant adds production capacity, the cash payments apply to the new capacity to the extent that the plant’s total annual production capacity does not exceed 15 million gallons. Because we did not have a plant in production on or before June 30, 2000, we will not receive any Minnesota cash payments. This could put us at a competitive disadvantage as compared to producers with qualifying plants who receive payments.

Lax enforcement of environmental and energy policy regulations may adversely affect demand for our ethanol.

     Our success will depend in part on effective enforcement of existing environmental and energy policy regulations. Many of our potential consumers are unlikely to switch from the use of conventional fuels unless compliance with applicable regulatory requirements leads, directly or indirectly, to the use of ethanol. Both additional regulation and enforcement of such regulatory provisions are likely to be vigorously opposed by the entities affected by such requirements. If existing emissions-reducing standards are weakened, or if governments are not active and effective in enforcing such standards, our business and results of operations could be adversely affected. Even if the current trend toward more stringent emissions standards continues, we will depend on the ability of ethanol to satisfy these emissions standards more efficiently than other alternative technologies. Certain standards imposed by

33


 

    regulatory programs may limit or preclude the use of our products to comply with environmental or energy requirements. Any decrease in the emission standards or the failure to enforce existing emission standards and other regulations could result in a reduced demand for ethanol. A significant decrease in the demand for ethanol will reduce the price of ethanol, adversely affect our profitability and decrease the value of your membership units.

Costs of compliance with environmental and operational safety regulations will reduce our profitability.

     Ethanol production involves the emission of various airborne pollutants, including particulate matter, carbon monoxide, carbon dioxide, nitrous oxide, volatile organic compounds and sulfur dioxide. Our plant also will discharge water into the environment. As a result, we are subject to complicated environmental regulations of the U.S. Environmental Protection Agency and regulations and permitting requirements of the State of Minnesota. These regulations are subject to change and such changes may require additional capital expenditures or increased operating costs. Consequently, considerable resources may be required to comply with future environmental regulations. In addition, our ethanol plant could be subject to environmental nuisance or related claims by employees, property owners or residents near the ethanol plant arising from air or water discharges. Ethanol production has been known to produce an unpleasant odor to which surrounding residents could object. Environmental and public nuisance claims, or tort claims based on emissions, or increased environmental compliance costs could significantly increase our operating costs.

     Our proposed ethanol plant is also subject to federal and state laws regarding occupational safety. Risks of substantial compliance costs and liabilities are inherent in ethanol production. We may be subject to costs and liabilities related to worker safety and job related injuries, some of which may be significant. Possible future developments, including stricter safety laws for workers and other individuals, regulations and enforcement policies and claims for personal or property damages resulting from operation of the ethanol plant could reduce the amount of cash that would otherwise be available to distribute to our members or to further enhance our business.

Risks Associated with Membership Units

    Because there is no public trading market for our units, you may be unable to resell them.

     There is no established public trading market for our membership units and an active trading market will not develop despite. To maintain our partnership tax status, you may not trade our membership units on an established securities market or readily trade our membership units on a secondary market (or a substantial equivalent). We therefore will not apply for listing of our membership units on any stock exchange or on the Nasdaq Stock Market. As a result, you will not be able to readily sell your membership units and could lose your investment.

    We have significant transfer restrictions that could make it difficult to sell your membership units.

          Your ability to transfer your membership units is also restricted by our Operating and Member Control Agreement. To help ensure that a secondary market does not develop, our Operating and Member Control Agreement prohibits transfers without the approval of our Board of Governors. The Board of Governors will not approve transfers unless they fall within “safe harbors” contained in the publicly-traded partnership rules under the tax code, which include:

  •   transfers by gift,
 
  •   transfer upon death of a member,

34


 

  •   transfers between family members and
 
  •   transfers that comply with the “qualifying matching services” requirements.

     Transfers of membership units in violation of the publicly traded partnership rules or without the prior consent of our Board are invalid.

     The illiquid nature of the membership units could impact the value of your membership units and result in a lower sale price in the event you are permitted to transfer your membership units. You must bear the economic risks associated with your investment in us for an indefinite period of time.

Our substantial debt service could limit our future borrowing and other activities and ability to make cash distributions to you.

     Our debt service requirements makes us vulnerable to economic or market downturns because we have floating interest rates over LIBOR, subject to quarterly adjustments. If we cannot service our debt, we may be forced to (a) reduce or delay planned capital expenditures, (b) sell assets, (c) restructure our indebtedness or (d) seek additional equity capital. In addition, our debt load and service requirements could have important consequences which could reduce the value of your investment, including:

  •   Limiting our ability to obtain additional financing;
 
  •   Reducing funds available for operations and distributions because a substantial portion or all of our cash flows will be used to pay interest and principal on our debt;
 
  •   Making us vulnerable to increases in prevailing interest rates;
 
  •   Placing us at a competitive disadvantage because we may be substantially more leveraged than some of our competitors;
 
  •   Subjecting all or substantially all of our assets to liens, which means that there could be no assets left for members in the event of a liquidation; and
 
  •   Limiting our ability to adjust to changing market conditions, which could make us more vulnerable to a downturn in general economic conditions or our business.

Our loan covenants could restrict our future borrowing and other activities and ability to make cash distributions to you.

     The terms of our debt financing agreement contains numerous financial, maintenance and other restrictive covenants. These covenants may limit our ability to, among other things:

  •   Incur additional indebtedness;
 
  •   Make capital expenditures in excess of prescribed thresholds;
 
  •   Make distributions to our members, redeem or repurchase our membership units;
 
  •   Make various investments;
 
  •   Create liens on our assets;
 
  •   Utilize asset sale proceeds; or

35


 

  •   Merge or consolidate or dispose of all or substantially all of our assets.

     A breach of these covenants could result in default under applicable debt agreements. If we default on any covenant, our lender could accelerate our indebtedness, in which case the entire debt would become immediately due and payable. If this occurs, we might not be able to repay our debt or borrow sufficient funds to refinance it. Even if new financing is available, it may not be on terms that are acceptable to us. These events could cause us to cease construction, or if the plant is constructed and operating, to cease operations.

    You may experience dilution to the value of your membership units.

     Any future sale of membership units or rights to purchase additional units by us could lower the value of your units by diluting your ownership interest in us, reducing your voting power and reducing distributions that we may make to you.

Risks Related to Tax Issues in a Limited Liability Company

    If we are not treated as a partnership for federal income tax purposes, the value of the units could decline.

     We expect to be taxed as a partnership for federal income tax purposes. This means that we will not pay any federal or state income tax, and our members will pay tax, and file tax returns, on their allocated share of our federal and state income. We cannot assure you, however, that we will be able to maintain partnership tax treatment. The Internal Revenue Service may from time to time review our tax status, and we cannot assure you that there will not be changes in the law or our operations that could cause us to lose our partnership tax status. We are not obtaining a ruling from the IRS on our tax status. If we lose our partnership tax status, then we may be taxed as a corporation. If we were treated as a corporation, we would be taxed on our net income at rates of up to 35% for federal income tax purposes. Further, you must treat distributions that we make to you as ordinary dividend income to the extent of our earnings and profits. These distributions are not deductible by us, thus resulting in double taxation of our earnings and profits. Our business and the value of your units may be harmed if we lose our partnership tax status. Please see “Income Tax Considerations of Owning Our Membership Units.”

    You may be required to pay taxes on your share of our income even if we make no distribution to you.

     Unless there is a change of law or trading in our membership units is sufficient to classify us as a “publicly traded partnership,” our profits and losses will “pass-through” to our members who will pay tax on their share of our profits. You will likely receive allocations of taxable income that exceed any cash distributions we make. This may occur because of various factors, including but not limited to, accounting methodology, lending covenants that restrict our ability to pay cash distributions or our decision to retain or use the cash generated by the business to fund our operating activities and obligations. Accordingly, you may be required to pay income tax on your allocated share of our taxable income with personal funds, even if you receive no cash distributions from us.

You may not be able to deduct your share of our losses, which could have adverse tax consequences to you.

     Your interest in us will likely be treated as a “passive activity.” If you are an individual and your interest (including an interest owned indirectly through a pass-through entity such as a partnership or S corporation) is deemed to be “passive activity,” then your allocated share of any loss we incur will be deductible only to the extent of income or gains that you have earned from other passive activities. Passive activity losses that are disallowed in any taxable year are suspended and may be carried forward

36


 

and used as an offset against passive activity income in future years. If your entire interest in a “passive activity” is disposed of to an unrelated person in a taxable transaction, then suspended losses with respect to that activity may then be deducted.

     These rules could restrict your ability to deduct any of our losses that pass through to you. Closely held C corporations also are subject to the passive activity limitations, but generally may deduct passive losses against a broader base of income.

ITEM 2. DESCRIPTION OF PROPERTY.

     Our ethanol plant is located on approximately 56 acres of real property consisting of two parcels located 1 1/2 miles east of Granite Falls, Minnesota between the City of Granite Falls and Minnesota Highway 23 located in Chippewa County, Minnesota. In August 2004, we exercised our option to purchase the two parcels for our industrial purposes for $336,000, or approximately $6,000 per acre. We have not obtained an independent appraisal of the property, although our Board of Governors believes the price represents fair market value for the property

     Our Board chose this plant site based on access to rail transportation, natural gas, and water, proximity and cost of raw material supplies, proximity to product markets and amenity to construction.

     Our principal business office is currently located in a temporary facility located on our site with an address of 15045 Highway 23 S.E., Granite Falls, Minnesota 56241. The permanent administration building is expected to be completed in April 2005.

     Our plant will consist principally of a raw storage and processing area, a fermentation area comprised principally of fermentation tanks, a finished product storage and distillation area and a drying unit for processing the distilled dried grains. In addition, the plant will include a fermenter walkway, gas dryer, evaporator and storage facilities for ethanol and distiller grains. The site will also contains improvements such as rail tracks and a rail spur, landscaping, drainage systems and paved access roads.

     On December 16, 2004, we executed a mortgage in favor of First National Bank of Omaha, N.A. of Omaha, Nebraska, creating a first lien on our real estate and a security interest in all of assets. See “Strategic Partners and Material Contracts — Loan Agreement with First National Bank of Omaha”.

ITEM 3. LEGAL PROCEEDINGS.

     None.

ITEM 4. SUBMISSION OF MATTERS TO A VOTE OF SECURITY HOLDERS.

     None.

37


 

PART II

ITEM 5. MARKET FOR MEMBERSHIP UNITS AND RELATED MEMBER MATTERS.

     There is no public trading market for our membership units. We have 31,117 Units issued and outstanding and a total of 911 Unit holders.

     Distributions are payable at the discretion of our Board of Governors, subject to the provisions of the Minnesota Limited Liability Company Act and our Operating and Member Control Agreement. The Board has no obligation to distribute profits, if any, to members. We have not declared or paid any distributions on our units. We do not expect to generate revenues until the ethanol plant construction is completed and the ethanol plant is operational. Once operational, subject to loan covenants and restrictions, we anticipate distributing our net cash flow to our members in proportion to the units held. By net cash flow, we mean our gross cash proceeds received less any portion, as determined by our governors in their sole discretion, used to pay or establish reserves for our expenses, debt payments, capital improvements, replacements and contingencies. If our financial performance and loan covenants permit, our governors will try to make cash distributions at times and in amounts that will permit unit holders to make income tax payments, but we may never be in a position to pay cash distributions.

     The Securities and Exchange Commission declared our registration statement on Form SB-2 (SEC Registration No. 333-96703) effective in February 2004. We commenced our Offering shortly thereafter.

     The following is a breakdown of Units registered and Units sold in the Offering:

                         
    Aggregate price of             Aggregate price of  
Amount   the             the  
Registered   amount registered     Amount Sold     amount sold  
30,000
  $ 30,000,000       29,700        $ 29,700,000  

     On October 15, 2004, we closed the Offering and stopped selling Units registered under our registration statement. During the Offering we sold 29,596 Units for an aggregate price of $29,596,000. In addition, we sold a total of 104 Units for consideration other than cash to several individuals and third parties in connection with their efforts in the Offering. We issued 79 Units for payment of services rendered by consultants (See “Certain Relationship and Related Transactions — Consulting Transactions”), 10 Units for payment of advertising conducted during 2003 and 15 Units to Granite Falls Bank, our escrow agent during the Offering, for payment of escrow account charges. We sold the Units without the assistance of an underwriter.

     As of December 31, 2004, our expenses related to the registration and issuance of these Units were $165,000.

     On September 24, 2004, we began releasing funds from escrow. On October 15, 2004, we issued a total of 29,700 Units consisting of 29,596 Units for cash to investor/members and 104 Units for consideration other than cash.

     As of December 31, 2004, our expenses related to the registration and issuance of these Units were $165,000 and were direct or indirect payments to others.

     Our net offering proceeds after deducting expenses related to the Offering were $29,535,000. As of December 31, 2004, we had used net offering proceeds of approximately $5,951,000 for construction of plant, building and facilities, approximately $1,700,000 for land and site development, $700,000 for repayment of indebtedness, and $793,000 for offering debt financing and organizational costs. All of these payments were direct or indirect payments to others except for $5,951,000 to Fagen, a member and our design-builder, for construction services and $700,000 to Granite Falls Bank, our former escrow agent and a member, for repayment of indebtedness. We also owe Fagen approximately $5,333,000 for construction services which we have retained but not paid yet in accordance with our design-build agreement with Fagen.

38


 

ITEM 6. MANAGEMENT’S DISCUSSION AND ANALYSIS.

     This Form 10-KSB contains forward-looking statements that involve risks and uncertainties. Actual events or results may differ materially from those indicated in such forward-looking statements. The following discussion of the financial condition and results of our operations should be read in conjunction with the Financial Statements and related notes thereto included elsewhere herein.

     We are a start-up limited liability company formed for the purpose of constructing and operating an ethanol plant near Granite Falls, Minnesota. We have begun construction of an ethanol plant that will produce ethanol and distillers grains for animal feed products. We purchased our 56- acre site for $336,000 in August 2004 located between the City of Granite Falls and Minnesota Highway 23. We expect the plant to have good access to both truck and rail transportation.

     We originally expected to build a 40 million gallon per year ethanol plant. We subsequently revised our business plan to expand the plant capacity to produce 50 million gallons of denatured fuel-grade ethanol. After further review, we determined that increasing our production capacity to 50 million gallons of denatured fuel-grade ethanol would likely result in more efficient operations for our ethanol plant. Our operations permit presently allows for the production of up to 47 million gallons of ethanol a year and we are in the process of amending this to produce up to our plant’s capacity. We do not expect this change to delay our anticipated date of start-up operation, which is currently the end of October 2005.

     Based on the increased capacity of our ethanol plant, we now expect that the project will cost approximately $62,667,000 instead of the $57,850,000 as previously planned. We are still in the development phase, and until the proposed ethanol plant is operational, we will generate no revenue. We anticipate that accumulated losses will continue to increase until the ethanol plant is operational.

     We have engaged experienced marketers to market ethanol and dry distillers grains to local, regional and national markets. We will be hiring staff to handle the direct operation of the plant, and currently expect to employ 31 people in addition to five personnel supplied by GLE, the intended operator of our plant.

      Plan of Operation for the Next 12 Months

     We expect to spend the next 12 months completing construction of the plant, site development and permitting and preparing for and commencing start-up operations.

      Plant Construction. In August 2004, we began site grading and dirt work at the plant site as part of our site preparation obligations under the design-build contract. These obligations included obtaining surveys, soil reports, and land disturbance and erosion control permits which we have accomplished, as well as, preparing the land such as site grading, preparing and stabilizing the soil in required areas, creating a replacement fill and storm water drainage and detention, as well as other similar items. We completed substantially all of the site preparation work in approximately the middle of November 2004 and will complete the remaining items in the spring and summer of 2005.

     On December 1, 2004, we instructed Fagen, our design-builder, to commence construction of the ethanol plant on our 56-acre site located near Granite, Falls Minnesota. We anticipate that we will need to purchase significant amounts of equipment in the next 12 months, all of which will be necessary for successful plant operations. Based on an estimates provided by Fagen, and assuming no adverse weather conditions, or delays in receiving necessary equipment, we expect to complete construction of the proposed plant and commence operations by the end of October 2005. This schedule assumes that weather, interest rates and other factors beyond our control do not upset our timetable. Factors or events beyond our control could hamper our efforts to complete the project in a timely fashion.

39


 

     Based on change orders signed to date, we will pay Fagen to build our plant a fixed fee of approximately $47,986,000. Fagen’s work will include construction of the following elements of our plant:

  •   Dust Collection and Milling Equipment . Fagen will build a dust collection system to process corn delivered to the plant to limit corn dust and a hammermill to grind the corn.
 
  •   Conversion and Liquefaction System, Fermentation System and Evaporation System . To create a cooked corn mash product, Fagen will build a system to mix ground corn in a tank and route the mash through a pressure vessel for steam cooking. The system will move the cooked mash through two additional tanks to add water and into one of three fermenters. As the fermenters fill, the system will add yeast to the cooked mash. The yeast will react chemically in the fermenters with the cooked mash to generate alcohol. After fermentation is complete, the system will pump the ethanol “beer” produced by the fermentation process to a different storage tank and then to a device (a beer column) that separates the ethanol from the mash.
 
  •   Distillation and Molecular Sieve. To produce pure (200 proof) ethanol, the Fagen system will remove water from the ethanol. The system will pump the pure ethanol to another tank for blending with 5% natural gasoline as the ethanol is pumped into final storage tanks. The natural gasoline is added to make the ethanol unfit for drinking (denaturing).
 
  •   Product Storage Area . Fagen will construct a tank farm including 190 proof ethanol storage (one 100,000 gal.), 200 proof ethanol storage, denaturant (gasoline) storage and denatured ethanol storage (two 750,000 gal. tanks). Fagen will cover the carbon steel tanks with floating roofs as required to comply with applicable environmental regulations.
 
  •   Liquid/ Solid Separation System and Dryers. Fagen will build a system to remove water from the remaining corn mash using centrifuges, evaporators and dryers to produce distillers grains.
 
  •   General Plant Infrastructure. Fagen will install necessary boilers, a cooling tower, a compressed air system and other processes, including a clean-in-place (CIP) system for cleaning. In order to remove volatile organic compounds (“VOCs”) that participate in the chemical formation of ozone in the atmosphere and particulate matter in the plant’s dryer exhaust, Fagen will install a thermal oxidizer system. Essentially, the thermal oxidizer burns off the VOCs and particulates. The system will capture the heat generated in the oxidation process for the plant’s boiler water. The plant will condition boiler feedwater by use of regenerative softeners and a deaerator and add appropriate boiler chemicals as the pre-heated water is pumped into the boiler. Fagen will install an ICM/ Phoenix Bio-Methanator to reduce organic acids in the process water, allowing water to recycle within the plant. To facilitate the plant operation, Fagen will also install a computer-based distributed control system with graphical user interface and three workstations.

     Fagen Engineering, LLC, an affiliate and subcontractor of Fagen, provides the civil engineering and site development designs for the ethanol plant and will continue to provide assistance in this area. As the designs are completed and approved, Fagen will construct the plant according to the designs.

      Other Construction Costs. In order to have Fagen continue construction during the winter, we are incurring other costs (such as frost removal). We have incurred approximately $60,000 through February 2005.

      Land and Site Development. We estimate that total land and site development costs will approximate $2,815,000 to meet Fagen’s requirements. These costs include:

40


 

  •   Purchasing the 56-acre land parcel near Granite Falls, Minnesota for $336,000 which we did in August 2004;
 
  •   obtaining all legal authority to use the site for its intended purposes, including obtaining proper zoning approvals, complying with elevation restrictions and conducting soil and water tests, grading the plant site to within six inches of final specifications, including rough grading for site roadways prior to breaking ground, testing and modifying the site’s soil to provide a minimum allowable soil bearing pressure of 4,000 pounds per square foot for fermentation foundations and 3,000 pounds per square foot for all other plant foundation elements; and
 
  •   installation of natural gas, electrical, water supply and water treatment infrastructure necessary for the operation of the plant.

      Administration Building and Furnishings. We anticipate expending approximately $210,000 to build a 2,600 square foot light office administration building on the site and to purchase and install $140,000 of computer and telephone systems, furniture and other office equipment.

      Railroad. We have budgeted $1,304,000 to design and construct a rail spur from our plant site to the TC& W main rail line and to purchase and install the associated switching gear.

      Construction Insurance Costs. We have budgeted approximately $300,000 for builder’s risk insurance, general liability insurance, workers’ compensation and property insurance. We have not yet determined our actual costs and they may exceed this estimate.

      Capitalized Interest. This consists of the interest we anticipate accruing during the development and construction period of our project. We plan to borrow between approximately approximately $34 million. Our actual capitalized interest will vary on the amount we borrow and the applicable interest rate.

      Offering and Debt Financing Costs. We expect to pay total finance costs of $541,000 in connection with obtaining our $34 million debt financing loans. These costs include bank origination and legal fees, loan processing fees, appraisal and title insurance charges, recording and deed registration tax, mortgage tax, our legal and accounting fees associated with securing the financing. Our actual financing costs will vary on the amount we borrow. We paid a total of $525,000 related to the two equity offerings ($325,000 expensed in 2003 as offering costs, $35,000 expensed in 2003 as legal fees and $165,000 for the Offering in 2004).

      Organizational Costs. We project approximately $1,050,000 for legal, accounting and other costs associated with our organization and operation as an entity.

      Start-up Costs. We project $4,630,000 of start-up costs. These represent costs of beginning production after the plant construction is finished but before we begin generating income. Start-up costs include $750,000 of pre-production period expenses, $1,300,000 of initial inventories of corn and other ingredients and chemicals, our initial $500,000 of work-in-process, $950,000 of ethanol and dry distillers grain inventories, $380,000 of spare parts and maintenance shop items, and $750,000 of working capital.

41


 

     The following chart summarizes the anticipated progress on the construction of our plant.

     
Timeline   Projects
March 2005
  Winbco start on Fermenters
Set Evaporators
Structural Steel Process Building
DDG Building
Tunnels & Auger cast at Silos
Excavate and pour Energy Center foundations
April 2005
  Set Process Building tanks
Install Dryer components & conveyors
Structural Steel Energy Center
Excavate and pour Cooling Tower basin
Pour 6” slabs in Process building and Energy Center
Masonry Process Building
Work on field-erected tanks
May 2005
  Slipform Silos
Install Piping & Equipment Process Building
Erect Cooling Tower
Install Dryer components
Install Boiler / T.O.
Install Chiller
Set Heat Exchangers
Masonry Process Building & Energy Center
Grains Receiving Building
Electrical & Instrumentation
Work on field-erected tanks
June 2005
  Set Centrifuges
Install Piping & Equipment Process Building
Work on field-erected tanks
Grains Receiving Building
Electrical & Instrumentation
July 2005
  Install Truck Scales & Probe
Install Piping & Equipment Process Building
Work on field-erected tanks
Energy Center Piping
Electrical & Instrumentation
Finishes Office/Lab Area Process Building
August 2005
  Install Piping & Equipment Process Building
Work on field-erected tanks
Energy Center Piping
Electrical & Instrumentation
Finishes Office/Lab Area Process Building
September 2005
  Electrical & Instrumentation
Energy Center Piping
Finishes Office/Lab Area Process Building
Train Plant Personnel
October 2005
  Electrical & Instrumentation
Piping & Equipment
Train Plant Personnel
Test Equipment and Prepare for Start-up Operations
Perform Water Trials and Hydrology Testing
Commence Operations
November 2005
  Seven day performance test
Punch list

Permitting Activity

     We continue to work towards obtaining all required permits for the construction of our ethanol plant as explained in detail under “Regulatory Compliance Permits”. We have obtained a majority of the required air, water and other permits. Over the past several months we have obtained the following important permits and other rights:

  •   In April 2004, we received an Air Emission Permit from the Minnesota Pollution Control Agency (the “MPCA”);
 
  •   In May, 2004 we received a National Pollution Discharge Elimination System (NPDES/SDS) from MPCA;
 
  •   In June 2004, we received a Conditional Water Use Permit for the Minnesota River from Chippewa County;
 
  •   In July 2004, we received an Above Ground Storage Tank Permit (effective September 1, 2004) from the MPCA;

42


 

  •   In August 2004, we received a Construction Storm Water Permit from the MPCA; and
 
  •   In October 2004, we obtained our building permit from the City of Granite Falls.

Contracting Activity

     We continue to work towards obtaining all contracts necessary for the construction and operation of our ethanol plant. In addition to the material contract explained under “Significant Partners and Material Contracts”, over the past several months we have entered into the following agreements:

     In August 2004, we executed our agreement with Minnesota Valley Rural Electric Cooperative, our electrical service provider. Under this agreement, we will pay them a base fee of $8,000 per month plus regular rates for our electricity. We estimate we will pay Minnesota Valley approximately $1,000,000 for our first full year of operations.

     In August 2004, we entered into a proposal with Trinity Rail Group, LLC whereby the parties indicated the basic terms for us to lease from Trinity Rail 75 hopper cars to assist in the transport of our product by rail from our plant. We would lease these cars for a term of five years at a rate of $640 per month per car or $48,000 per month. Although these terms are subject to a formal definitive agreement, we understand that Trinity Rail has begun to manufacture the cars and we indicated on the proposal that we would accept delivery of the cars in July 2005.

     In October 2004, the Company entered into a Job Opportunity Building Zone Business Subsidy Agreement (“JOBZ Agreement”) with the City of Granite Falls. Under the JOBZ Agreement, the Company and its members are allowed certain tax exemptions and tax credits under Minnesota law because the Company’s plant is located in a “job opportunity building zone” or “JOBZ” (as defined by Minnesota statutes). These exemptions primarily include: (i) exemption for individuals from state income tax on amounts we allocate to our members, (ii) exemption for the Company from state income taxes, (iii) exemption from sales and use tax payable by us, and (iv) exemption from real property taxes increases on our property. The Minnesota JOBZ laws were designed to enhance economic growth and diversity in areas outside of the Minneapolis-St. Paul metropolitan area, to provide job growth and to put vacant land to use. We will be able to avail ourselves of these tax benefits and exemptions until December 31, 2015, provided we fulfill our obligations under the JOBZ Agreement. Our obligations include creating 30 new full-time equivalent positions with an average wage of at least $10.00 over a period of three years and filing timely progress reports with the City of Granite Falls. If we do not fulfill our obligations or we cease to operate prior to December 31, 2015, we will need to repay a portion of our tax benefits.

     On October 31, 2004, we executed a rail construction agreement with MGA Railroad Construction, Inc., for the construction of railroad tracks and switches at our plant site. We will pay MGA a total of approximately $1,114,000 for its construction activities. Payment is to be made on a monthly basis for work completed subject to a 10% retainage to be paid upon final completion.

     In December 2004, we executed an agreement with Center Point Energy/Minnegasco for the construction and maintenance of approximately 9.5 miles of an underground natural gas pipeline for the delivery of natural gas to our plant which we may purchase from other companies. We will pay Center Point Energy/Minnegasco a per unit fee to move the natural gas through our pipeline and have guaranteed movement of a minimum of 350,000 DT in calendar year 2005 and 1,400,000 DT annually thereafter through December 31, 2015, the end of the term.

     We have had verbal conversations with both the TC&W railroad and the Burlington Northern Santa Fe railroad for rail service and freight rates at our plant.

     We are also working towards finalizing agreements with natural gas providers.

     GLE will operate and manage our plant once operational. Farmers Cooperative Company will provide our corn supply needs. Aventine Renewable Energy, Inc. and CSC will provide us with our ethanol and distillers grains marketing services respectively. We expect to be very dependent on these companies after we begin operations.

Updates to Our Sources and Uses of Cash

      Sources and Uses of Cash . We originally estimated that we would require approximately $58,750,000 of total cash to pay for all of our construction and start-up costs. However, based on our decision to expand the plant, new estimates for our utilities, an expected early completion bonus to our design-builder, and other items, we estimate that our construction and start-up costs will be approximately $62,667,000.

43


 

     On December 16, 2004, we closed on our debt financing commitment with First National Bank of Omaha (the “Bank”) for the purpose of funding a portion of the cost of our ethanol plant. Under our loan agreement with the Bank, the Bank has provided to us a construction loan up to $34,000,000, a revolving line of credit of $3,500,000, and standby letters of credit in an amount up to $1,000,000. As security for the Bank’s loans to us, we have granted the Bank a security interest in all of our assets and a mortgage on our real estate. We have no amounts outstanding under these facilities. See “Strategic Partners and Material Contracts - Loan Agreement with First National Bank of Omaha”.

     The following tables describe our revised estimated use of our offering and debt financing proceeds. The figures are estimates only, and the actual uses of proceeds may vary significantly from the descriptions given below.

Revised Estimated Use of Offering and Debt Proceeds :

                 
Plant Construction
  $ 47,986,375       77.4 %
Other Construction Costs
    60,366       0.1  
Land and Site Development
    2,815,025       4.0  
Utilities (natural gas, electric and water)
    1,355,000       2.2  
Repay Borrowings from Granite Falls Bank(1)
    700,000       1.1  
Rolling Stock
    200,000       0.3  
Administration Buildings and Furnishings
    350,000       0.6  
Railroad and Car Mover
    1,424,000       2.3  
Construction Insurance Costs
    300,000       0.5  
Capitalized Interest
    693,065       1.1  
Offering and Debt Financing Costs
    1,066,629       1.2  
Organizational Costs
    1,050,477       0.6  
Start-up Costs
    4,630,000       7.5  
Early Completion Bonus
    736,000       1.2  
 
           
 
               
Total Estimated Use of Proceeds
  $ 62,666,937       100.0 %
 
               
 
           


(1)   In July 2004, we borrowed $500,000 from Granite Falls Bank to enable us to purchase the land for our plant site (which we did in August 2004 for $334,000) and begin site preparation. Between February and June 2004, we borrowed an aggregate of $350,000 from Granite Falls Bank which we have used to fund legal, accounting and other costs associated with our organization and operation as an entity. We repaid these loans in September 2004 from proceeds of our Offering.

     Based upon offering proceeds of $29,700,000, and a term loan in the approximate amount of $34,000,000, we have approximately $63,700,000 of debt and equity available, which means we expect to have sufficient cash on hand to cover construction and related start-up costs necessary to make the plant operational.

Liquidity and Capital Resources

     As of December 31, 2004, we had cash and cash equivalents of $21,157,557 and total assets of $34,712,254. To date, we have sold 29,700 Units in our Offering raising proceeds of $29,700,000. We released proceeds of our Offering from escrow beginning on September 24, 2004.

44


 

     We placed approximately $4,655,000 of the proceeds in our money market account with Granite Falls Bank to cover our short-term development needs. The remaining proceeds were transferred to First National Bank of Omaha and placed in short-term, no risk to principal type investments such as commercial paper and quasi-governmental agency discounted notes. We may draw on these funds at any time, but do not intend to do so prior to the commencement of substantial construction of the ethanol plant.

     As of December 31, 2004, we had current liabilities of $5,724,685, which consists primarily of construction payables (primarily retainage to Fagen and other contractors) in the amount of $5,332,612, accounts payable in the amount of $330,592 and a Note to the City of Granite Falls in the amount of $47,800 due January 1, 2004, which has not been paid, and which we have been working with the City to extend and which may be forgiven under the terms of our Development Agreement with the City.

     Total members equity as of December 31, 2004 was $28,987,569. Since inception, we have generated no revenue from operations. For the year ended December 31, 2004, we have a net loss of $248,044 due to start-up costs.

      Repayment of Outstanding Bank Debt. As of September 24, 2004, we repaid all of our outstanding loans with Granite Falls Bank for operating expenses and land purchases in the aggregate amount of approximately $700,000.

      Sources of Funds. The following schedule sets forth our sources of funds from our Offering proceeds and our debt financing proceeds:

                 
            Percent of  
Source of Funds           Total  
Member Equity
  $ 29,700,000       46.6 %
Term Debt
  $ 34,000,000       53.4 %
Total Sources of Funds
  $ 63,700,000       100.00 %

     If we need additional cash, we may borrow additional funds or sell additional Units. However, we have access to our $3,500,000 revolving credit line for hedging purposes and operations. We cannot assure success in obtaining additional financing if needed on acceptable terms, or at all.

     We do not have any off-balance sheet arrangements.

45


 

ITEM 7. FINANCIAL STATEMENTS.

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a Granite Falls Energy, LLC

(A Development Stage Company)

Financial Statements

December 31, 2004

C O N T E N T S

Report of Independent Auditors

         
Financial Statements
       
Balance Sheet
    48  
Statement of Operations
    49  
Statement of Changes in Members’ Equity
    50  
Statement of Cash Flows
    51  
Notes to Financial Statements
    52  

46


 

REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

Board of Governors
Granite Falls Community Ethanol Plant, LLC,
d/b/a Granite Falls Energy, LLC
Granite Falls, Minnesota

We have audited the accompanying balance sheet of Granite Falls Community Ethanol Plant, LLC, d/b/a Granite Falls Energy, LLC (a developmental stage company), as of December 31, 2004 and 2003, and the related statements of operations, changes in members’ equity (deficit), and cash flows for the years ended December 31, 2004 and 2003, and from inception (December 29, 2000) to December 31, 2004. These financial statements are the responsibility of the Company’s management. Our responsibility is to express an opinion on these financial statements based on our audits.

We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement. An audit includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements. An audit also includes assessing the accounting principles used and significant estimates made by management, as well as evaluating the overall financial statement presentation. We believe that our audits provide a reasonable basis for our opinion.

In our opinion, the financial statements referred to above present fairly, in all material respects, the financial position of Granite Falls Community Ethanol Plant, LLC, d/b/a Granite Falls Energy, LLC (a developmental stage company) as of December 31, 2004 and 2003, and the results of its operations and its cash flows for the years ended December 31, 2004 and 2003 and from inception to December 31, 2004 in conformity with U.S. generally accepted accounting principles.

     
  /s/ Boulay Heutmaker, Zibell & Co. P.L.L.P.
  Certified Public Accountants

Minneapolis, Minnesota
February 18, 2005

47


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Balance Sheet

                 
   
    December 31,     December 31,  
    2004     2003  
 
ASSETS
               
Current Assets:
               
Cash and equivalents
  $ 21,157,557     $  
Interest receivable
    7,277        
Prepaid expenses
    32,517       2,000  
 
           
Total current assets
    21,197,351       2,000  
 
               
Property and Equipment:
               
Land
    351,928        
Construction in process
    12,791,239        
Office equipment
    6,317       6,317  
 
           
 
    13,149,484       6,317  
Less accumulated depreciation
    2,632       1,369  
 
           
Net property and equipment
    13,146,852       4,948  
 
               
Other Assets:
               
Deferred financing costs
    368,051        
 
           
Total other assets
    368,051        
 
           
 
               
Total Assets
  $ 34,712,254     $ 6,948  
 
           
 
               
LIABILITIES AND MEMBERS’ EQUITY
               
 
               
Current Liabilities:
               
Checks drawn in excess of funds on deposit
  $     $ 11,417  
Accounts payable
    330,592       86,937  
Payable to construction contractors
    5,332,612        
Accrued interest
    13,681       11,518  
Notes payable-City of Granite Falls
    47,800       47,800  
Notes payable-Granite Falls Bank
          149,000  
 
           
Total current liabilities
    5,724,685       306,672  
 
               
Commitments and Contingencies
               
 
               
Members’ Equity (Deficit):
               
Member contributions, net of costs related to capital contributions, 31,117 and 1,417 units outstanding at December 31, 2004 and 2003, respectively
    30,163,978       628,641  
Deficit accumulated during development stage
    (1,176,409 )     (928,365 )
 
           
Total members’ equity (deficit)
    28,987,569       (299,724 )
 
           
 
               
Total Liabilities and Members’ Equity (Deficit)
  $ 34,712,254     $ 6,948  
 
           

Notes to Financial Statements are an integral part of this Statement.

48


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC
(A Development Stage Company)

Statement of Operations

                         
   
                    From Inception  
    Year Ended     Year Ended     (December 29, 2000)  
    December 31,     December 31,     to December 31,  
    2004     2003     2004  
 
Revenues
  $     $     $  
 
                       
Operating Expenses
                       
Project coordinator
    36,121       56,218       185,480  
Surveying, site and permitting expense
    37,219       30,792       157,729  
Professional and consulting fees
    238,517       126,805       488,229  
General and administrative
    69,705       57,672       146,083  
 
                 
Total operating expenses
    381,562       271,487       977,521  
 
                 
 
                       
Operating Loss
    (381,562 )     (271,487 )     (977,521 )
 
                       
Other Income (Expense)
                       
Interest income
    151,931       748       155,900  
Miscellaneous income
    1,000             2,000  
Interest expense
    (19,413 )     (6,317 )     (32,034 )
Offering costs
          (324,754 )     (324,754 )
 
                 
Total other income (expense), net
    133,518       (330,323 )     (198,888 )
 
                 
 
                       
Net Loss
  $ (248,044 )   $ (601,810 )   $ (1,176,409 )
 
                 
 
                       
Weighted Average Units Outstanding
    8,820       1,417       1,219  
 
                 
 
                       
Net Loss Per Unit
  $ (28.12 )   $ (424.71 )   $ (965.06 )
 
                 

Notes to Financial Statements are an integral part of this Statement.

49


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Statement of Changes in Members’ Equity (Deficit)

                         
   
            Deficit        
            Accumulated        
            During        
    Members’     Development        
    Contributions     Stage     Total  
 
Balance - December 29, 2000
  $     $     $  
 
                       
Balance - December 31, 2000
                 
 
                       
Net loss for the year ended December 31, 2001
          (106,025 )     (106,025 )
 
                 
 
                       
Balance - December 31, 2001
          (106,025 )     (106,025 )
 
                       
Capital contributions:
                       
January 2002 - 200 units
    55,000             55,000  
March to July 2002 - 1,167 units, net of $35,962 of costs related to raising capital contributions
    547,538             547,538  
August 2002 - conversion of $25,000 note payable and accrued interest to the City of Granite Falls to 50 units
    26,103             26,103  
Net loss for the year ended December 31, 2002
          (220,530 )     (220,530 )
 
                 
 
                       
Balance - December 31, 2002
    628,641       (326,555 )     302,086  
Net loss for the year ended December 31, 2003
          (601,810 )     (601,810 )
 
                 
Balance - December 31, 2003
    628,641       (928,365 )     (299,724 )
Capital contributions:
                       
October 15, 2004 - 29,700 units, net of $164,663 of costs related to raising capital contributions
    29,535,337             29,535,337  
Net loss for the year ended December 31, 2004
          (248,044 )     (248,044 )
 
                 
 
Balance - December 31, 2004
  $ 30,163,978     $ (1,176,409 )   $ 28,987,569  
 
                 

Notes to Financial Statements are an integral part of this Statement.

50


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Statement of Cash Flows

                         
   
                    From Inception  
    Year Ended     Year Ended     (December 29, 2000)  
    December 31,     December 31,     to December 31,  
    2004     2003     2004  
 
Cash Flows from Operating Activities:
                       
Net loss
  $ (248,044 )   $ (601,810 )   $ (1,176,409 )
Adjustments to reconcile net loss to net cash used in operations:
                       
Depreciation
    1,263       1,264       2,632  
Offering costs
          324,754       324,754  
Changes in assets and liabilities:
                       
Prepaid expenses
    (30,517 )     (995 )     (32,517 )
Accrued receivable
    (7,277 )           (7,277 )
Accounts payable
    16,960       33,950       75,592  
Accrued interest
    2,163       6,317       14,784  
 
                 
Net cash used in operating activities
    (265,452 )     (236,520 )     (798,441 )
 
                       
Cash Flows from Investing Activities:
                       
Land acquisitions
    (351,928 )           (351,928 )
Capital equipment
                (6,317 )
Payments for construction in process
    (7,458,627 )           (7,458,627 )
 
                 
Net cash used in investing activities
    (7,810,555 )           (7,816,872 )
 
                       
Cash Flows from Financing Activities:
                       
Checks drawn in excess of cash
    (11,417 )     11,417        
Net proceeds (payments) on short term notes payable
    (149,000 )     149,000       72,800  
Member contributions
    29,596,000             30,338,500  
Payments for costs of raising capital
    (70,663 )           (200,625 )
Payments for offering costs
    (18,305 )     (175,884 )     (324,754 )
Payments for financing costs
    (113,051 )           (113,051 )
 
                 
Net cash provided by (used in) financing activities
    29,233,564       (15,467 )     29,772,870  
 
                 
 
                       
Net Increase (Decrease) in Cash and equivalents
    21,157,557       (251,987 )     21,157,557  
 
                       
Cash and equivalents – Beginning of Period
          251,987        
 
                 
 
                       
Cash and equivalents – End of Period
  $ 21,157,557     $     $ 21,157,557  
 
                 
 
                       
Supplemental Cash Flow Information
                       
 
                       
Cash paid during the year for:
                       
Interest
  $ 17,251     $     $ 18,354  
 
                 
 
                       
Supplemental Disclosure of Noncash Investing and Financing Activities
                       
 
                       
Deferred offering costs in accounts payable
  $     $ 18,305     $ 18,305  
 
                 
 
                       
Conversion of bank fees and offering costs into 94 member units in 2004. Conversion of note payable and accrued interest into 50 member units in 2002.
  $ 94,000     $     $ 120,103  
 
                 
 
                       
Construction costs in payable to construction contractors
  $ 5,332,612     $     $ 5,332,612  
 
                 
 
                       
Deferred financing costs in accounts payable
  $ 255,000     $     $ 255,000  
 
                 
 
                       
Conversion of accounts payable into 10 member units
  $ 10,000     $     $ 10,000  
 
                 

Notes to Financial Statements are an integral part of this Statement.

51


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

1. SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES

Nature of Business

Granite Falls Community Ethanol Plant, LLC (the “Company”), which started construction on its plant location near Granite Falls, Minnesota in 2004, was originally organized to fund and construct a 40 million gallon ethanol plant with distribution to upper midwest states. The Board of Governors of the Company has approved a proposal to increase the plant size to be capable of producing up to 50 million gallons of ethanol a year. The Company’s operations permit presently allows for the production of up to 47 million gallons of ethanol per year. The Company is currently in the process of amending this permit to produce up to the plant’s capacity. In addition, the Company intends to produce and sell dried distillers grains as a co-product of ethanol production. Construction began in the third quarter of 2004. As of December 31, 2004, the Company is in the development stage with its efforts being principally devoted to organizational and construction activities. The Company plans on beginning operations by the end of October 2005.

Fiscal Reporting Period

The Company has adopted a fiscal year ending December 31 for reporting financial operations.

Accounting Estimates

Management uses estimates and assumptions in preparing these financial statements in accordance with generally accepted accounting principles. Those estimates and assumptions affect the reported amounts of assets and liabilities, the disclosure of contingent assets and liabilities, and the reported revenues and expenses. Actual results could differ from those estimates.

Cash and Equivalents

The Company maintains some of its accounts at a financial institution which is a member of the Company. At times throughout the year, the Company’s cash balances at these financial institutions may exceed amounts insured by the Federal Deposit Insurance Corporation. Virtually all of the cash and cash equivalents at December 31, 2004 were short-term investments such as rated commercial paper with maturities less than ninety days and money market accounts.

52


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

Deferred Offering Costs

The Company defers the costs incurred to raise equity financing until that financing occurs. As of December 31, 2004, the Offering was completed and these costs have been netted against the proceeds received.

Deferred Financing Costs

Costs relating to the Company’s debt financing have been capitalized as incurred. Upon conversion of the Company’s construction loan to a term note, the Company will begin to amortize the debt issuance costs using the effective interest rate method.

Property and Equipment

Property and equipment is stated at the lower of cost or estimated fair value. Depreciation is provided over an estimated useful life by use of the straight line depreciation method. Depreciation expense for each year ending 2004 and 2003 was $1,264. Maintenance and repairs are expensed as incurred; major improvements and betterments are capitalized.

Fair Value of Financial Instruments

The fair value of the Company’s cash and equivalents and note payable to Granite Falls Bank approximates their carrying value. It is not currently practicable to estimate the fair value of the notes payable to the City of Granite Falls since these agreements contain unique terms, conditions, and restrictions, which were negotiated at arm’s length with the City of Granite Falls, as discussed in Note 3, there is no readily determinable similar instrument on which to base an estimate of fair value.

Grants

The Company will recognize grant income as other income for reimbursement of expenses incurred upon complying with the conditions of the grant. For reimbursements of capital expenditures, the grants are recognized as a reduction of the cost basis of the asset upon complying with the conditions of the grant.

53


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

Income Taxes

The Company is treated as a partnership for federal and state income tax purposes and generally does not incur income taxes. Instead, its earnings and losses are included in the income tax returns of the members. Therefore, no provision or liability for federal or state income taxes has been included in these financial statements.

2. DEVELOPMENT STAGE ENTERPRISE

The Company was formed on December 29, 2000 to have an indefinite life. The Company was initially capitalized by proceeds from notes payable to the City of Granite Falls, Minnesota and later by contributions from its founding members and additional seed capital investors. The seven founders contributed an aggregate of $55,000 for 700 units and subsequently the Board of Governors approved a 1:2 reverse membership unit split for the founding members. In addition, six of the seven founding members agreed to return to the Company one-half of each of their remaining units, thereby reducing the number of units held by each such founding member to twenty-five. Sixty-five members, including six of the founders or their affiliates, contributed an additional aggregate of $583,500 for 1,167 units that were issued between March and July 2002 pursuant to a private placement memorandum. On July 31, 2002, the Company discontinued selling units under the private placement memorandum. In August 2002, the Company converted a $25,000 note payable plus accrued interest to the City of Granite Falls to 50 membership units. Net Loss Per Unit retroactively reflects the two 1:2 reverse membership unit splits as well as the return of units to the Company by the founders.

Income and losses are allocated to all members based upon their respective percentage units held for the period being allocated. See Note 4 for further discussion of members’ equity.

3. NOTES PAYABLE

At December 31, 2004 and 2003, the Company has $47,800 of notes payable with the City of Granite Falls, Minnesota originally due on January 1, 2004, including interest at 7%. All notes are secured by terms and conditions of the Development Agreement dated February 2, 2001, and subsequently amended, between the City and the Company. The repayment of up to the entire amount may be forgiven subject to the covenants set forth in the Development Agreement.

54


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

Under the terms of the Development Agreement, the notes payable can be forgiven at a rate of $5,000 for each job created, up to ten jobs, within six months of the start-up of operations of the facility, provided each job pays a gross annual wage or salary of not less than $24,500. In addition, upon the completion of financing and organizational startup, $25,000 of the notes payable may be converted to equity with a market value of $25,000 or more. In August 2002, the City Council of Granite Falls approved the conversion of a $25,000 note due from the Company plus accrued interest into fifty membership units. The notes payable are completely forgiven, in their entirety, if the project is abandoned. As of December 31, 2004 the City has not required payment of this note as the City believes the Company is working towards the conditions of the Development Agreement.

As of December 31, 2003, the Company had a line of credit from a bank that expired January 15, 2004 at a maximum of $200,000 with an interest rate of 5.75% and secured by a separate security agreement and guaranteed by two members of the Company. The outstanding balance as of December 31, 2003 was $149,000 and was paid during 2004.

4. MEMBERS’ EQUITY

As specified in the Company’s operating agreement, the Company initially will have one class of membership units. No member shall transfer all or any portion of an interest without the prior written consent of the Board of Governors. The Company prepared an SB-2 Registration Statement for a minimum of 18,000 units which expired on December 27, 2003 because the Company did not raise the required minimum and, as a result, the related offering costs of $324,754 were expensed in 2003.

The Board voted to prepare a new offering and filed a Registration Statement with the United States Securities and Exchange Commission. This Registration Statement offered up to a minimum of 18,000 ($18,000,000) and a maximum of 30,000 ($30,000,000) of units for sale at $1,000 per unit. The minimum purchase was five units. The Registration Statement was declared effective in February 2004. The Company filed post-effective amendments to its Registration Statement in July and August 2004.

As of August 31, 2004, the Company’s escrow agent had received subscriptions proceeds of over $19 million from the sale of units in the Offering. These proceeds included $6,500,000 and $2,500,000 received from Glacial Lakes Energy, LLC (“GLE”) and Fagen, Inc. (“Fagen”), respectively, the Company’s two significant investors. GLE and Fagen had originally provided “qualifying bridge loans” which the Company was able to count towards the $18,000,000 minimum and which were subsequently converted into 6,500 and 2,500 of units, respectively.

55


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

The Company has raised the minimum of $18,000,000 through the Offering and has executed a non-binding debt financing commitment with First National Bank of Omaha for a total credit facility of approximately $37 million. On September 24, 2004, the Company released funds from escrow having obtained subscription proceeds in excess of $25,000,000 which when combined with the $34,000,000 construction loan commitment would yield sufficient funds to construct the then estimated cost of the plant. The Company closed the Offering effective October 15, 2004 after receiving cash proceeds of $29,596,000. In addition to the Units sold, we issued a total of 104 Units for consideration other than cash to several individuals and third parties. Of the 104 Units, 79 Units were for payment of services rendered by consultants, 10 Units were for payment of advertising conducted during 2003, and 15 Units were to Granite Falls Bank for payment of escrow charges.

5. FINANCING

On December 16, 2004, the Company entered into a Loan Agreement with First National Bank of Omaha (the “Bank”) for the purpose of funding a portion of the cost of the ethanol plant. Under the Loan Agreement, the Bank has provided a construction loan for approximately $34,000,000, a revolving line of credit of $3,5000,000, and standby letters of credit in an amount up to $1,000,000. The loans are secured by substantially all assets. No amounts were outstanding under this loan agreement at December 31, 2004.

The Loan Agreement includes due diligence, negotiation, and commitment fees of $305,000 and an annual servicing fee of $30,000. Additionally, the Company will pay the Bank quarterly an unused commitment fee equal to 0.375% of the average unused portion of the $3,500,000 revolving line of credit beginning with the initial advance or March 10, 2006, whichever is earlier and the $5,000,000 long term revolving note which is one of the term loans beginning March 10, 2006.

Under the construction loan, the Company is to make quarterly interest payments at a variable interest rate equal to one-month LIBOR plus 3.50% until March 10, 2006. The amounts borrowed under the construction loan will mature and convert into three term loans aggregating up to $34,000,000 on March 10, 2006. The maturity date of each loan will be March 10, 2011 and interest accrues on each term loan at a variable rate based upon one-month or three- month LIBOR plus 3.00-3.50% depending on the particular loan. In addition to the required payments under the term loans, the Company will have to make an additional principal payment equal to 15% of the Company’s “excess cash flow” as defined in the loan agreement within 120 days of year-end.

The Company is subject to various financial and non-financial loan covenants that include among other items minimum working capital amounts, minimum fixed charge coverage ratios and minimum net worth requirements. The Company is permitted to make distributions once a year (after the Bank’s receipt of a completed annual audit) of

56


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

between 65% to 70% of net income as long as they are in compliance with these and other loan covenants. After the conversion to the term loans, capital expenditures in excess of $500,000 in a fiscal year require the Bank’s prior approval.

On January 6, 2005, the Company entered into an interest rate swap agreement with the Bank (as required under the Loan Agreement) in order to change the interest on some of the anticipated borrowings from a variable rate to a fixed rate. Under the interest rate swap, the Company will pay the Bank the quarterly difference between interest charged at a fixed rate of 7.69% and the variable rate of three-month LIBOR plus 3.00% on the “notional” amount of 17,000,000. The “notional” balance under the interest rate swap will match the principal balance of one of the three term loans mentioned above. The interest rate swap will become effective on September 10, 2005 and will terminate on March 10, 2011.

6. INCOME TAXES

The differences between the financial statement basis and tax basis of assets are as follows:

                 
    December     December  
    2004     2003  
Financial statement basis of assets
  $ 34,712,254     $ 6,948  
Plus organization and start-up costs capitalized
    1,133,269       494,916  
Accumulated depreciation and amortization
    (1,525 )     (1,369 )
 
           
 
               
Income tax basis of assets
  $ 35,843,998     $ 500,495  
 
           

There were no differences between the financial statement basis and tax basis of the Company’s liabilities.

7. COMMITMENTS AND CONTINGENCIES

The Company has revised its estimate of total costs of the project from $57,850,000 to $62,667,000. The Company anticipates funding the development of the ethanol plant by using grants, the proceeds it raised through its offering, and utilizing debt financing for the remainder of the costs.

In fiscal 2001, the Company made a nominal payment to obtain an option to purchase approximately 31 acres of land for a price of $168,000. In August 2004, the Company exercised this option.

57


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

In March 2003, the Company made a nominal payment to obtain an option agreement to purchase approximately 25 acres of land, adjacent to the above 31 acres, for approximately $168,000. In August 2004, the Company exercised this option.

In March 2001, the Company executed an agreement, as subsequently amended, with a member to serve as project coordinator. The agreement pays a maximum of $5,000 per month, renews every thirty days, and may be terminated by the Company at any time with no less than 10 days written notice.

In February 2003, the Company entered into an agreement with an unrelated party to act as the Company’s project consultant. The agreement pays $1,250 per week, with a one-time bonus of $40,000. This bonus was paid, in member units as previously discussed, after the Company raised the minimum amount of equity required to close on its public offering and secured a loan commitment by a prospective lender sufficient to finance the Company’s project.

In October 2003, subsequently renegotiated in May 2004, the Company entered into a twelve year corn storage and grain handling agreement with a member. The Company will pay weekly at market price (generally based on the daily posted board price at the Elevator’s Minnesota Falls branch) for corn delivered, subject to adjustments for corn of inferior quality or with excess moisture. The Company will also pay a weekly corn procurement fee of $0.05 per bushel of corn delivered. The corn procurement fee will increase in the fourth and eighth years of the agreement to $0.055 and $0.06, respectively, per bushel of corn delivered. In addition, the member has purchased $605,000 of units.

In August 2004, the Company entered into an agreement with an electrical service provider to provide electrical service to the ethanol plant. Under the agreement, in addition to paying the stated electric rates, the Company is required to install, or have installed, transmission lines and a substation. The cost of the transmission lines and substation are included in the Company’s anticipated total project costs of the ethanol plant as discussed above. Based on the agreement, the Company will pay them a base fee of $8,000 per month plus regular rates for our electricity. The Company estimates they we will pay the provider approximately $1,000,000 for the first full year of operations.

In August 2004, the Company entered into a contract with Fagen, a member, to design and build the ethanol plant for $45,749,700. Based on the decision to expand the capacity of the plant and other change orders, the Company now expects to pay Fagen

58


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

approximately $47,986,375. If the contract is terminated by the Company without cause or Fagen for cause, the Company will be required to pay Fagen a fee of $1,000,000 as compensation for the limited right to use the work product. Substantial completion of the entire work shall be achieved no later than 425 calendar days after the date of commencement. If the plant is substantially complete within the 425 days, the Company will pay Fagen an early performance bonus of $8,000 per day for each day that substantial completion is achieved prior to the 425 days after the date of commencement. Based on a construction start date of December 1, 2004 and an anticipated completion date of October 31, 2005, the Company may pay Fagen an early completion bonus of up to $736,000.

In August 2004, the Company entered into an exclusive two year renewable Ethanol Marketing Agreement with a member, Aventine Renewable Energy, Inc., whereby they will purchase from the Company for re-marketing all of the Company’s ethanol production. The agreement begins with the Company’s first shipment of ethanol. In addition, the ethanol marketer has purchased an equity interest in the Company of $500,000.

In August 2004, the Company entered into a Consulting Agreement and an Operating and Management Agreement with GLE, who is also a member. Under the Consulting Agreement, GLE will provide assistance in planning and will direct and monitor the construction of the Company’s ethanol plant. The Company will pay GLE $10,000 plus pre-approved expenses per month. The Consulting Agreement will terminate upon the effective date of the Operating and Management Agreement under which GLE will operate and manage the Company’s plant. The Company will pay GLE $35,000 per month plus 3% of the plant’s operating profits, exclusive of income from government programs, under the Agreement. The initial term of the operating and management agreement is for five years and will automatically renew for successive one-year terms unless terminated 180 days prior to the start of a renewal term.

In August 2004, the Company signed a letter of intent with a rail car builder for the lease of 75 covered hopper cars that will be manufactured by the builder. Based on the letter of intent, the Company expects to sign a five year lease agreement for $640 per month, per car, subject to potential adjustment based on final manufacturing costs. As December 31, 2004, no formal lease document has been signed.

In September 2004, the Company entered into an agreement with a consultant to provide consulting services for supplies of natural gas and electricity for the plant. The fees during the construction period shall be $15,000 plus pre-approved travel expenses and upon plant completion the fees shall be $2,400 per month plus pre-approved travel expenses. This agreement shall commence on October 1, 2004 and continue until six

59


 

GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
d/b/a GRANITE FALLS ENERGY, LLC

(A Development Stage Company)

Notes to Financial Statements

December 31, 2004 and 2003

months after the plant’s completion date. The agreement shall be month- to-month after the initial term and may be terminated by either party effective after the initial term upon sixty days prior written notice.

On October 31, 2004, the Company executed a rail construction agreement with MGA Railroad Construction, Inc., for the construction of railroad tracks and switches at its plant site. The Company will pay MGA a total of approximately $1,114,000 for its construction activities. Payment is to be made on a monthly basis for work completed subject to a 10% retainage to be paid upon final completion.

In December 2004, the Company entered into an agreement with an unrelated company for the construction of and maintenance of 9.5 miles of natural gas pipeline that will serve the plant. The agreement requires the Company have delivery of a minimum of 350,000 DT of natural gas in calendar year 2005 and 1,400,000 DT of natural gas annually through the term of the agreement. The Company will be charged a fee based on the DT of natural gas delivered through the new pipeline. This agreement will continue in effect until December 31, 2015 at which time it will automatically renew for consecutive terms of 1 year. A twelve month prior written notice is required to be given by either party to terminate this agreement.

In December 2004, the Company executed a distillers grains marketing agreement with Commodity Specialist Company (CSC) whereby CSC will purchase from the Company for re-marketing all of the distillers grains that are shipped by rail from the plant and that amount of production that is shipped by truck that the Company chooses to sell to CSC. The agreement commences upon the start-up of the plant and may be terminated by either party at any time upon 90 days notice after the first year.

60


 

ITEM 8. CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURES.

     Boulay, Heutmaker, Zibell & Co., P.L.L.P. has been our independent registered public accounting firm since the Company’s inception and is the Company’s independent registered public accounting firm at the present time. The Company has had no disagreements with its independent registered public accounting firm.

ITEM 8A. CONTROLS AND PROCEDURES.

     Our management, including our Chief Executive Officer and Chief Manager (the principal executive officer), and our Chief Financial Officer (the principal financial officer), have reviewed and evaluated the effectiveness of our disclosure controls and procedures as of the end of the period covered by this report. Based upon this review and evaluation, these officers believe that our disclosure controls and procedures are effective in ensuring that material information related to us is recorded, processed, summarized and reported within the time periods required by the forms and rules of the Securities and Exchange Commission.

     Our management, including our principal executive officer and principal financial officer, have reviewed and evaluated any changes in our internal control over financial reporting that occurred as of the end of the period covered by this report and there has been no change that has materially affected or is reasonably likely to materially affect our internal control over financial reporting.

PART III

ITEM 9. DIRECTORS, EXECUTIVE OFFICERS AND SIGNIFICANT EMPLOYEES.

     On October 13, 2004, our then existing six member Board of Governors implemented the August 2004 amendments to our Operating and Member Control Agreement (the “2004 Amendments”). The 2004 Amendments require a seven member Board of Governors and permit Glacial Lakes Energy, LLC of Watertown, South Dakota (“GLE”) and Fagen, Inc. of Granite Falls, Minnesota (“Fagen”), our two significant investors and members, to elect three of the seven members of our Board of Governors. We adopted the 2004 Amendments in connection with and as a condition to GLE’s and Fagen’s purchase of $6,500,000 and $2,500,000 of our membership units, respectively. We also elected certain officers as designated by GLE pursuant to our operating and management agreement with GLE also entered into as a condition to GLE’s and Fagen’s investment in us.

     The 2004 Amendments require that we are governed by a Board of Governors of seven individuals. So long as GLE is a member and holds no less than 20% of our membership units, GLE has the right to designate two governors and an alternate governor to act in the absence of a GLE designated governor. So long as Fagen is a member and holds no less than 5% of our membership units, Fagen has the right to designate one governor.

     The remaining four governors constitute our “At-Large Governors” together with any governor to be elected to fill a vacancy created by a resignation of a GLE, Fagen or GLE appointee (an “At-Large Additional Governor”) shall be elected by the members of the Company. However, GLE, the Glacial appointee and Fagen shall not be entitled to vote with respect to the election of the At-Large Governors or any At-Large Additional Governor if GLE, the GLE appointee and/or Fagen, as applicable, continues to have the right to separately appoint one or more governors above. The At-Large Governors and any At-Large Additional Governors shall together (by majority vote of all such governors) designate an alternate (the “At-Large Alternate”) to serve as follows. If any At-Large Governor or At-Large Additional Governor is not available for, or during any part of, a meeting of the Board of Governors or to take action in writing in lieu of such a meeting, the At-Large Alternate is entitled to act as a Governor at such meeting, or during such part, or to take such action in writing (but only on behalf of one At-Large Governor or At-Large Additional Governor, if more than one is unavailable). The At-Large Governors and any At-Large Additional Governors shall together have the right to fill vacancies in the At-Large Governor and At-Large Additional Governor positions by majority vote.

61


 

     GLE designated Messrs. Terry Little and Doyle Thompson as governors and Mr. Terry Mudgett as the alternate governor. Fagen designated a current governor, Mr. Steve Core, as a governor. On October 13, 2004, our existing Board of Governors formerly accepted GLE’s and Fagen’s governor designations and appointed our four At-Large Governors to hold office until our first annual member meeting in 2005. Our At-Large Governors appointed a former governor, Myron Peterson, as the At-Large Alternate.

     Our At-Large Governors are classified into three classes. The Class I, II and III At-Large Governors will serve until the annual meeting of members in 2005, 2006 and 2007, respectively. At each annual meeting, our members will elect the At-Large Governors of the class up for election for a three year term.

     Our existing Board of Governors also elected as executive officers Messrs. Terry Little as Vice Chairman of the Board of Governors, Thomas Branhan as our Chief Executive Officer and General Manager and Michael Nealon as our Chief Financial Officer and Controller all of whom are currently associated with GLE as an employee or board member and all of whom were designated by GLE pursuant to our operating and management agreement with GLE.

     Our current executive officers and governors are as follows.

                 
Name   Age   Position   Class
Paul Enstad
    45     Governor and Chairman of the Board   III
Terry Little
    44     Governor and Vice Chairman of the Board  
Doyle Thompson
    50     Governor  
Steven H. Core
    55     Governor  
Julie
Oftedahl-Volstad
    50     Governor, Secretary and Treasurer   III
Scott Dubblede
    43     Governor   II
Shannon Johnson
    43     Governor   I
Myron Peterson
    59     At-Large Alternate  
Terry Mudgett
    50     GLE Alternate  
Thomas Branhan
    59     Chief Executive Officer and General Manager  
Michael Nealon
    43     Chief Financial Officer and Controller  

The following is a brief description of the business experience and background of the above individuals.

      Paul Enstad . Mr. Enstad has been farming near Granite Falls, Minnesota since 1978. He and his two brothers currently farm together as a partnership and raise corn and soybeans. He serves on the board of governors of the Farmers Cooperative Elevator Company, a member of us. In such capacity, he attends board meetings of the Farmers Cooperative Elevator Company and otherwise provides periodic, informal business advice. The Farmers Cooperative Elevator Company purchases agricultural products from its members and stores them for resale to food processors and sells agricultural goods and services to its members utilizing group buying leverage to obtain discounts not otherwise generally available to individual cooperative members.

      Terry Little . Mr. Little has been farming in Watertown, South Dakota since 1984. He and his brother currently farm together as a partnership and raise livestock and grain. He serves on the Board of Managers of GLE, our member. After growing up on a farm near Watertown, Mr. Little attended South Dakota State University and Iowa State University and received a degree in Veterinary Medicine. After a brief career in veterinary medicine, Mr. Little returned to the family farm and his current farming operation.

62


 

      Doyle Thompson . Mr. Thompson has been farming grain in Gary, South Dakota since 1975 until present. He also serves on the Board of Managers of GLE, our member. Mr. Thompson graduated from Gary High School and attended Canby Vo-Tech in Production Agriculture. Mr. Thompson also serves on the H-D Electric Board of Directors.

      Steven H. Core . Mr. Core became a governor in November 2002. He was our Vice President of Operations from November 2002 to October 2004. He worked for us on a part-time, unpaid basis. Mr. Core has over 30 years of agricultural business management experience. Since January 2002, Mr. Core has served as a contract employee to Fagen. on new ethanol plant construction. Between 1994 and 2002, he served as General Manager of Corn Plus, a Winnebago, Minnesota ethanol producer. During his tenure, he supervised a staff of 34 employees that produced 44.0 million gallons of ethanol annually. Between 1983 and 1994, he served in various management capacities (most recently as Agronomy, Credit and New Ventures Manager) with Grain Land Coop., a $90 million Delavan, Minnesota agricultural cooperative with six locations. Mr. Core is also a member of the Board of Directors of the Renewable Fuels Association and is a member of the Minnesota Ethanol Coalition and the Corn Growers Association. He received his Associates of Applied Sciences in Agricultural Business degree in 1970 from Eastern Iowa Community College.

      Julie Oftedahl-Volstad . Ms. Oftedahl-Volstad has been farming along the Yellow Medicine River near Hanley Falls, Minnesota since 1978 on a farm homesteaded in 1873 by her great-greatgrandfather. She farms in partnership with her three brothers and parents, principally growing corn and soybeans. She has a degree in Sociology from Southwest State University. She is an active member of Yellow Medicine Lutheran Church and has served on the church council in the past. She is also on the board of Neighbors United Resource Center, a support organization.

      Scott Dubbelde. Since 1992, Mr. Dubbelde has been the General Manager of the Farmers Cooperative Elevator Company, a member of us. He has over 17 years of experience in the grain elevator business. In his capacity with the Farmers Cooperative Elevator Company, he is responsible for all day-to-day business operations and has both financial and operational responsibility for the elevator. He is also currently on the Minnesota Grain and Feed Association Board of Directors. Mr. Dubbelde graduated from Southwest State University of Marshall, Minnesota with an Agricultural Finance degree.

      Shannon Johnson. Mr. Johnson has been farming in eastern Yellow Medicine County since 1976. He produces corn, soybeans and sugar beets on 1,000 acres. He is co-owner and secretary of a swine farrow to finish partnership and currently serves as the Hazel Run Township clerk. He formerly served on the Hazel Run Lutheran Church council. He is a Yellow Medicine County Corn board member and a Soybean Growers member.

      Myron D. Peterson . Mr. Peterson was designates by our At-Large Governors as our At-Large Alternate generally to act in the absence of an At-Large Governor. He was a former governor of the Company prior to the closing of the Offering. He farms with his four brothers and their families in a family farm partnership established in 1972, growing about 3,600 acres of corn and soybeans in western Renville County. Mr. Peterson served seven years as a director of the Minnesota Corn Growers Association Board, most recently as membership chairman and County Plot chairman. In 2003, he became a director of the Minnesota Corn Research and Production Council. He has been a supervisor for Hawk Creek Township for the past 24 years and County Township Secretary-Treasurer for Renville County for 21 years. He is also a member of the Monsanto Corn Growers Advisory Council. Mr. Peterson has served two terms on Our Saviors Lutheran Church Council in Sacred Heart, Minnesota and was Council President for two years. He has also been past member of the Minnesota State Planning Agency Task Force on Ag-Land Preservation.

      Terry Mudgett. Mr. Mudgett was designated by GLE as our alternate governor to act in the absence of any GLE designated governor. He also serves on the Board of Managers of GLE. He has been a farmer for the past 26 years in Clark County, South Dakota and currently has a grain operation and cattle feed and cow/calf operation. He has also been involved as a seed salesman for the past several years.

63


 

      Thomas Branhan . Mr. Branhan has been serving as GLE’s CEO and General Manager since December 2001. Mr. Branhan will continue to serve as GLE’s CEO and General Manager while also serving as our CEO and General Manager. From December 1997 to November 2001 Mr. Branhan managed a 40 million pound per year acrylic chemical plant in Southern California. Mr. Branhan received his mechanical engineering degree from the University of Cincinnati.

      Michael Nealon . Mr. Nealon has been serving as GLE’s Chief Financial Officer and Controller since May 2002. He will continue to serve in these positions while also serving as our CFO and Controller. From July 1999 to January 2002, Mr. Nealon worked for BankFirst, a credit card issuer, in Sioux Falls, South Dakota as Director of Finance. Prior thereto, Mr. Nealon spent 15 years in public accounting as a controller for publicly held companies and as an accountant for Deloitte & Touche. Mr. Nealon received a degree in Business Administration from Creighton University in Omaha, Nebraska. Mr. Nealon is a certified public accountant.

Project Coordinator

     In addition to our executive officers and governors, Robin W. Spaude serves as our project coordinator. Prior to joining us, Mr. Spaude was employed for 31 years by Plews/ Edelmann, a division of the Gates Rubber Company, most recently as Manufacturing and Engineering Manager with multi-plant manufacturing and engineering responsibilities in the U.S. and Mexico. He played a key role in the business growth of his division from $24 million in 1990 to $85 million by 1997 via acquisition, consolidation, and lean-manufacturing strategies. Mr. Spaude is a retired Army Reserve Officer with 21 years service in ordinance and logistics branches, a senior member of the Society of Manufacturing Engineers (SME) and, since 1988, has served the Granite Falls community as Chairman of the Granite Falls Airport Commission. He is a 1969 graduate of the Minnesota West Community and Technical College in Granite Falls.

Audit Committee

     On October 13, 2004, our Board of Governors established our audit committee consisting of Messrs. Enstad and Little and Ms. Oftedahl-Volstad. The audit committee is exempt from the independence listing standards because the Company’s securities are not listed on a national securities exchange or listed in an automated inter-dealer quotation system of a national securities association or to issuers of such securities. Nevertheless, each member of our audit committee is independent within the definition of independence provided by NASDAQ rules 4200 and 4350. Our board of governors has determined that we do not currently have an audit committee financial expert serving on our audit committee. We do not have an audit committee financial expert serving on our audit committee because no member of our board of governors has the requisite experience and education to qualify as an audit committee financial expert as defined in Item 401 of Regulation S-B and the board has not yet created a new director position expressly for this purpose. Our board of governors intends to consider such qualifications in future nominations to our board and appointments to the audit committee.

Board Nominations .

     The Company does not have a formal nominating committee.

Adoption of Code of Ethics

     Our Board of Directors has adopted a code of ethics that applies to our principal executive officer, Thomas Branhan and our principal financial officer, Michael Nealon. Our code of ethics is publicly available as an exhibit to our annual report on Form 10-KSB for the fiscal year ended December 31, 2003. Copies of our Code of Ethics are also available at no change by writing the Company at its address at 15045 Highway 23 S.E., Granite Falls, Minnesota 56241-0216, attn: Chief Financial Officer.

64


 

ITEM 10. EXECUTIVE COMPENSATION.

     We do not pay compensation directly to our executive officers. Under our consulting agreement with GLE, we pay GLE $10,000 per month to assist us in planning, directing and monitoring, the construction of our proposed ethanol plant. We also reimburse GLE for its pre-approved expenses, other than for travel to and from our facility. GLE services commenced in August 2004 and as of December 31, 2004, we paid GLE approximately $50,000 for services rendered to us pursuant to a consulting agreement.

     As part of the agreement, GLE supplies its own personnel to act as part-time contract officers and managers of our plant for the positions of Chief Executive Officer or General Manager, and Chief Financial Officer. GLE is responsible for compensating Messrs. Branhan and Nealon. See “Strategic Partners and Material Contracts — Agreements with Glacial Lakes Energy, LLC”.

     During 2004, and prior to GLE providing services to us under our consulting agreement, we paid our project manager approximately $36,000 for the services and out-of-pocket expenses.

     We do not have any compensatory security option plan for our executive officers and governors. None of our governors or officers has any options, warrants, or other similar rights to purchase our securities.

      In October 2004, our board of governors approved a governor compensation policy. The policy provides for payment to governors of a monthly fee based on attendance at the regular monthly board meeting. The fees we intend to pay are as follows: $600.00 per month to the Chairman, $600.00 per month to our governor who is also our corporate secretary and $500.00 per month to the other governors and alternates. We will also pay for mileage to and from the meeting at the standard mileage rate established from time to time by the IRS. We will not pay the fee if the governor does not attend the monthly meeting. We do not pay governors for attendance at committee meetings.

ITEM 11. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED MEMBER MATTERS.

Security Ownership of Certain Beneficial Owners

     The following table sets forth certain information regarding the beneficial ownership of our units as of March 15, 2005, by each person or entity known by us to be the beneficial owner of more than 5% of the outstanding units:

65


 

                 
    Amount and nature of        
Name and Address   beneficial owner     Percent of Class  
Glacial Lakes Energy, LLC
    6,500       20.9 %
301 20th Avenue SE
               
Watertown, SD 57201
               
 
               
Fagen, Inc.
    1,925       8.0 %
501 West Highway 212
               
P.O. Box 159
               
Granite Falls, MN 56241
               

Units Beneficially Owned By Governors and Officers(1)

     The following table describes the ownership of units by our governors and officers and by all of our governors and officers as a group as of the date of this report. Members of the Board and our management do not hold any outstanding options or other convertible securities giving them a right to additional units.

                                     
  Name   No. of Units     Percentage
Ownership
 
                               
  Paul Enstad(2)(3)       650            2.1    
 
Scott Dubbelde(3)
      615            1.9    
 
Steven H. Core
      20            *    
 
Julie Oftedahl-Volstad
      25            *    
 
Shannon Johnson
      35            *    
 
Myron Peterson(4)
      60            *    
 
All governors, alternate governors and officers as a group (eleven persons)(2)(3)
      1405            4.5    

* less than 1%.


(1)   The address of each individual is in care of us at 15045 Highway 23 S.E., Granite Falls, Minnesota 56241-0216.
 
(2)   Includes 20 units purchased by the Enstad Brothers partnership.
 
(3)   Includes 605 units purchased by the Farmers Cooperative Elevator Company, of which Mr. Dubbelde is general manager and Mr. Enstad is a director.
 
(4)   Includes 25 units purchased by Peterson Partners.

66


 

ITEM 12. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS.

     Conflicts of interest may arise in the future as a result of the relationships between and among our members, officers, governors and their affiliates, although our officers and governors have fiduciary duties to us. We do not have a committee of independent governors or members or an otherwise disinterested body to consider transactions or arrangements that result from conflicts of interest. Our Operating and Member Control Agreement permits us to enter into agreements with governors, officers, members and their affiliates, provided that any such transactions are on terms no more favorable to the governors, officers, members (or their affiliates) than generally afforded to non-affiliated parties in a similar transaction. A majority of our governors who are disinterested in such a transaction must approve the transactions and, acting as fiduciaries, conclude that it is in the best interests of us.

     We consider all of our governors other than Messrs. Little and Doyle, Fagen, GLE, the City of Granite Falls and the Farmers Cooperative Elevator Company to be our founders and promoters. One of our former governors, Steve Lindholm, is also one of our founders and may be considered a promoter. We have engaged, or plan to engage, in the following transactions involving our founders, governors and officers and their affiliates:

      Unit Purchase Transactions. We have issued units to our governors, founders and officers in transactions approved by our governors. In January 2002, Messrs. Enstad and Johnson and Ms. Oftedahl-Volstad, along with the Farmers Cooperative Elevator Company, Peterson Partners and Granite Falls Bank (whose President and majority owner is Mr. Lindholm), each purchased 25 units for $5,000, or $200 per unit. Mr. Dubbelde is the general manager, and Mr. Enstad is a director, of the Farmers Cooperative Elevator Company. Mr. Peterson is a partner of Peterson Partners. Messrs. Enstad, Johnson, Dubbelde and Ms. Oftedahl-Volstad are governors of us and Mr. Peterson is an At-Large Governor of us. At the same time, we sold Fagen 50 units for $25,000, or $500 per unit.

     Between October and December 2001, the City of Granite Falls loaned us $72,800 to assist us with the organization of our business and our initial feasibility review of our proposed ethanol plant. The loans bear interest at 7% per annum. Originally, the loans were due in January 2003. In July 2002, the City extended the due date on the loans to January 2004. However, the loans are forgiven based on particular job creation goals upon completion of the ethanol plant. In any event, in August 2002, the City converted $25,000 of its loans and the accrued interest into 50 units. We are working with the City to extend the due date of the balance of this loan.

     Between March and July 2002, we conducted a private placement of units at $500 per unit. Messrs. Dubbelde and Johnson each purchased 10 units, the Farmers Cooperative Elevator Company, Mr. Core and the Enstad Brothers Partnership (of which Mr. Enstad is a partner) each purchased 20 units and Fagen purchased 120 units, in the private placement on the same terms as other purchasers. Mr. Core became one of our governors and our former Vice President of Operations in November 2002 and is a consultant to Fagen.

     On August 31, 2004, GLE and Fagen converted bridge loans in the amount of $6,500,000 and $2,500,000, respectively, into 6,500 and 2,500 units in the Offering at $1,000 per unit, respectively.

      Banking and Loan Transactions. Granite Falls Bank served as escrow agent for us in connection with the Offering. We also use the bank as our regular depository institution. In addition, in the future, should we need additional financing, the bank may lend us funds. We expect that Mr. Lindholm will negotiate with us on behalf of the bank, as he is no longer affiliated with us.

     In September 2003, Fagen and the Farmers Cooperative Elevator Company guaranteed and collateralized a $200,000 line of credit at Granite Falls Bank to provide us with working capital after we depleted the funds raised in our 2002 private placement. The line of credit bore interest at 5.75% per

67


 

annum on the outstanding balance, which was $149,000 on December 31, 2003. The outstanding balance was due on January 15, 2004 and was extended until June 1, 2004. On February 19, 2004, we borrowed an additional $100,000 with interest at 5.75% from Granite Falls Bank pursuant to a promissory note due on October 31, 2004. We repaid the line of credit, and thereby retired the guarantors’ obligations, out of the net proceeds of the Offering.

      Consulting Transactions. In February 2003, we engaged Value Add Ventures, LLC, or (“VAV”), for services to assist us as a project consultant in our negotiation of contracts, planning of our equity marketing efforts, securing debt financing and other responsibilities related to the development of our proposed plant. We paid VAV $1,250 per week for its services and a bonus of $40,000 upon receipt of our binding commitment for debt financing, all of which was paid through the issuance of 79 of our units in October 2004. VAV’s principals, Messrs. William Riechers and Paul Casper, are associated with Fagen and other ethanol plants. Consequently, VAV may have conflicts of interest when advising us regarding contracts and agreements that we must enter into with Fagen.

      Operations Transactions. In October 2003, we entered into a Corn Storage and Delivery Agreement with Farmers Cooperative Elevator Company which was renegotiated in May 2004. We will purchase our entire requirements for corn from the Elevator. The Elevator purchased 600 units in the Offering and owns a total of 605 units.

     We also have drilled a well on property currently owned by the Elevator about a mile from our plant site and, subject to negotiating an acceptable agreement, plan to pipe groundwater from the Elevator’s property to our plant site. Subject to negotiating an acceptable agreement, we may also engage the Elevator to serve as our commodities manager to manage our corn supply and hedging position.

     Although Messrs. Enstad and Dubbelde will not participate as governors in our decisions regarding the Farmers Cooperative Elevator Company, Mr. Dubbelde will negotiate with us on behalf of the Farmers Cooperative Elevator Company. All of this presents a potential conflict of interest for Messrs. Enstad and Dubbelde when advising us regarding contracts and agreements that we plan to enter into with the Elevator.

      Construction Transactions. In August 2004, we signed our design-build agreement with Fagen to build our ethanol plant. Fagen is a member of us and one of our Governors, Mr. Core, is a consultant to Fagen. Although Mr. Core will not participate as a governor in our decisions regarding Fagen, his position as a consultant presents a potential conflict of interest when advising us regarding contracts and agreements that we have entered into or will enter into with Fagen.

     We may need to obtain an additional construction permit for our plant from the City of Granite Falls.

     Additional conflicts of interest could arise in the situations described below:

  •   We may engage in transactions with our governors or officers or their affiliates for the purchase of corn and the sale of distillers grains, although these transactions will be on the same terms and conditions as with non-affiliated persons or entities. Members will have no right to individually enforce the obligations of our governors or officers or their affiliates in our favor.
 
      Our governors’ decisions regarding various matters, including expenditures that we make for our business, reserves for accrued expenses, including salaries for officers and reimbursement of governors’ expenses, loan covenants, capital improvements and contingencies will affect the amount of cash available for distribution to members.
 
  •   We will reimburse our governors for out-of-pocket expenses relating to our business. We do not have a reimbursement policy or guideline for determining what expenses will be reimbursed. We

68


 

      will review and reimburse all reasonable expenses that governors submit to us.
 
  •   We have retained counsel that has assisted us in various aspects of our formation and development. We have not retained separate counsel on behalf of unit holders.

ITEM 13. EXHIBITS AND REPORTS ON FORM 8-K.

      Exhibits Filed as Part of this Report and Exhibits Incorporated by Reference.

     (a) The following exhibits are filed as part of this report. Exhibits previously filed are incorporated by reference, as noted.

             
Exhibit   Description   Method of Filing
3.1
  Articles of Organization     1  
 
           
3.2
  Form of Fifth Amended and Restated Operating and Member Control Agreement     2  
 
           
4.1
  Form of membership unit certificate     1  
 
           
4.2
  Form of Escrow Agreement     3  
 
           
10.2
  Grain Procurement Agreement with Farmers Cooperative Elevator Company     7  
 
           
10.4
  Operating and Management Agreement with Glacial Lakes Energy, LLC     7  
 
           
10.5
  Consulting Agreement with Glacial Lakes Energy, LLC     7  
 
           
10.10
  Design Build Agreement dated August 31, 2004 with Fagen, Inc.     *  
 
           
10.11
  Ethanol Marketing Agreement dated August 31, 2004 with Aventine Renewable Energy, Inc.+     *
 
           
10.12
  Rail Construction Agreement with MGA Railroad Construction, Inc. dated October 30, 2004     7  
 
           
10.13
  Electric Service Agreement dated August, 2004 with Minnesota Valley Cooperative Light and Power     *  
 
           
10.14
  Loan Agreement with First National Bank of Omaha     *  
 
           
10.15
  Distiller’s Grain Marketing Agreement with Commodity Specialists Company     *  
 
           
10.16
  Trinity Rail Proposal for Rail Cars     *  
 
           
10.17
  Job Opportunity Building Zone Business Subsidy Agreement     *  
 
           
14.1
  Code of Ethics     6  
 
           
31
  Certificates pursuant to 17 CFR 240 15d-14(a)     *  
 
           

69


 

             
Exhibit   Description   Method of Filing
32
  Certificates pursuant to 18 U.S.C. Section 135     *  


(1)   Incorporated by reference to the exhibit of the same number on our Registration Statement on Form SB-2, No. 333-99065, originally filed on August 30, 2002.
 
(2)   Incorporated by reference as Appendix A to our Post Effective Amendment No. 1 filed July 21, 2004 to our Registration Statement on Form SB-2, No. 333-112567, originally filed on February 6, 2004.
 
(3)   Incorporated by reference to the exhibit of the same number in Pre-Effective amendment No. 1 filed on February 12, 2004 to our Registration Statement on Form SB-2, No. 333-112567, originally filed on February 6, 2004.
 
(4)   Incorporated by reference to the exhibit of the same number in Post Effective Amendment No. 2 filed July 29, 2004 to our Registration Statement on Form SB-2, No. 333-112567, originally filed on February 6, 2004.
 
(5)   Incorporated by reference to the exhibit on the same number in Post-Effective Amendment No. 3 filed on August 23, 2004 to our Registration Statement on Form SB-2, No. 333-112567, originally filed on February 6, 2004.
 
(6)   Incorporated by reference to the exhibit of the same number in our 10-KSB for the period ended December 31, 2003.
 
(7)   Incorporated by reference to the exhibit of the same number in our 10-QSB for the period ended September 30, 2004.
 
(*)   Filed herewith.
 
(+)   Material has been omitted pursuant to a request for confidential treatment and such materials have been filed separately with the Securities and Exchange Commission.

     (b)  Reports on Form 8-K. We filed reports on Form 8-K on (i) October 19, 2004 relating to the approval of our designated governors and the appointment of at-large governors, our executive officers and members of our audit committee, and (ii) December 22, 2004 relating to executing a definitive loan agreement with First National Bank of Omaha for our debt financing.

ITEM 14. PRINCIPAL ACCOUNTANT FEES AND SERVICES.

     The aggregate fees billed for professional services by Boulay, Heutmaker, Zibell & Co. P.L.L.P, our independent registered public accounting firm, in 2004 and 2003, consisted solely of audit fees and were as follows:

                 
Type of Fees   2004     2003  
Audit Fees(1)
  $ 51,000     $ 44,000  


(1)   Annual audit fees are the fees billed for professional services rendered for the audit of the Company’s annual financial statements and reviews of quarterly financial statements. This category also includes fees for consents, assistance with and review of documents filed with the SEC, attest services, work done by tax professionals in connection with the audit or quarterly reviews and accounting consultations and research work necessary to comply with generally accepted auditing standards.

     Our Audit Committee approves all audit, audit-related, tax services and other services performed for us by our independent auditors.

70


 

SIGNATURES

     In accordance with the requirements of the Exchange Act, the Registrant caused this report to be signed on its behalf by the undersigned, thereunto duly authorized this 31 st day of March, 2005.

             
  GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC
   
             
  By /s/ THOMAS BRANHAN  
             
       
    Thomas Branhan,  
    Chief Executive Officer and Chief Manager  

     Pursuant to the requirements of the Exchange Act, this report has been signed by the following persons in the capacities indicated on the dates indicated.

         
/s/ PAUL ENSTAD   Governor and Chairman of the Board   March 31, 2005

   
Paul Enstad    
     
/s/ TERRY LITTLE   Governor and Vice Chairman of the Board   March 30, 2005

   
Terry Little    
     
/s/ SCOTT DUBBELDE   Governor   March 31, 2005

   
Scott Dubbelde    
     
/s/ JULIE OFTEDAHL-VOLSTAD   Governor   March 31, 2005

   
Julie Oftedahl-Volstad    
     
/s/ DOYLE THOMPSON   Governor   March 31, 2005

   
Doyle Thompson    
     
/s/ SHANNON JOHNSON   Governor   March 30, 2005

   
Shannon Johnson    
     
  Governor  

   
Steven H. Core    
     
/s/ THOMAS BRANHAN   Chief Executive Officer and General Manager   March 31, 2005

  ( Principal Executive Officer)
Thomas Branhan    
     
/s/ MICHAEL NEALON   Chief Financial Officer and Controller   March 31, 2005

  (Principal Financial and Accounting Officer)
Michael Nealon    

71

 

Exhibit 10.10

(DBIA LOGO)

Standard Form of Agreement Between
Owner and Design-Builder - Lump Sum

This document has important legal consequences. Consultation with
an attorney is recommended with respect to its completion or modification.

     This AGREEMENT is made as of the 31st day of August in the year of 2004, by and between the following parties, for services in connection with the Project identified below.

OWNER:
(Name and address)

Granite Falls Energy, LLC
2448 – 540th Street, Suite 1
PO Box 216
Granite Falls, MN 56241

DESIGN-BUILDER:
(Name and address)

Fagen, Inc.
501 W. Highway 212
P. O. Box 159
Granite Falls, MN 56241

PROJECT :
(Include Project name and location
as it will appear in the Contract
Documents)

40 MGY Dry Grind Ethanol Plant

In consideration of the mutual covenants and obligations contained herein, Owner and Design-Builder agree as set forth herein.

     
 
DBIA Document No. 525 $ Standard Form of Agreement
  Page 1
Between Owner and Design-Builder C Lump Sum
   
8 1998 Design-Build Institute of America
   

 


 

Article 1

Scope of Work

1.1 Design-Builder shall perform all design and construction services, and provide all material, equipment, tools and labor, necessary to complete the Work described in and reasonably inferable from the Contract Documents.

Article 2

Contract Documents

2.1 The Contract Documents are comprised of the following:

  .1    All written modifications, amendments and change orders to this Agreement issued in accordance with DBIA Document No. 535, Standard Form of General Conditions of Contract Between Owner and Design-Builder (1998 Edition) (“General Conditions of Contract”);
 
  .2    This Agreement, including all exhibits and attachments, executed by Owner and Design-Builder, said Exhibits being:

     
  Exhibit A — Performance Guarantee Criteria – (2) Pages;
  Exhibit B — General Project Scope — (3) Pages;
  Exhibit C –Owner’s Responsibilities — (6) Pages;
  Exhibit D – License of Proprietary Property of ICM, Inc. – (4) Pages;
  Exhibit E – Start-up Services to be Provided to Owner (1) Page.
  Exhibit F - Exclusive Future Constructions Rights

  .3    Written Supplementary Conditions, consisting of two pages, to the General Conditions of Contract;
 
  .4    The General Conditions of Contract;
 
  .5    Construction Documents prepared and approved in accordance with Section 2.4 of the General Conditions of Contract;
 
  .6    Design-Builder’s Deviation List, if any, contained in Design-Builder’s Proposal, which shall specifically identify any and all deviations from Owner’s Project Criteria;
 
  .7    Owner’s Project Criteria;
 
  .8    Design-Builder’s Proposal, except for the Deviation List, submitted in response to Owner’s Project Criteria; and
 
  .9    The following other documents, if any: N/A

     
 
Page 2
  DBIA Document No. 525 $ Standard Form of Agreement
  Between Owner and Design-Builder C Lump Sum
  8 1998 Design-Build Institute of America

 


 

Article 3

Interpretation and Intent

3.1 The Contract Documents are intended to permit the parties to complete the Work and all obligations required by the Contract Documents within the Contract Time(s) for the Contract Price. The Contract Documents are intended to be complementary and interpreted in harmony so as to avoid conflict, with words and phrases interpreted in a manner consistent with construction and design industry standards. In the event of any inconsistency, conflict, or ambiguity between or among the Contract Documents, the Contract Documents shall take precedence in the order in which they are listed in Section 2.1 hereof.

3.2 Terms, words and phrases used in the Contract Documents, including this Agreement, shall have the meanings given them in the Supplementary Conditions and General Conditions of Contract.

3.3 The Contract Documents form the entire agreement between Owner and Design-Builder and by incorporation herein are as fully binding on the parties as if repeated herein. The Contract Documents supercede any prior letters of intent between the parties, and such letters of intent are now null and void. No oral representations or other agreements have been made by the parties except as specifically stated in the Contract Documents.

Article 4

Ownership of Work Product

4.1 Work Product . All drawings, specifications and other documents and electronic data furnished by Design-Builder to Owner under this Agreement (“Work Product”) are deemed to be instruments of service and Design-Builder shall retain the ownership and property interests therein, including the copyrights thereto.

4.2 Owner’s Limited License Upon Payment in Full. Upon Owner’s payment in full for all Work performed under the Contract Documents, Design-Builder shall vest in Owner a limited license to use the Work Product in connection with Owner’s occupancy, repair, remodeling or enlargement of the Project and Design-Builder shall provide Owner with a copy of the “as built” plans, conditioned on Owner’s express understanding that its use of the Work Product and its acceptance of the “as built” plans is at Owner’s sole risk and without liability or legal exposure to Design-Builder or anyone working by or through Design-Builder, including Design Consultants of any tier (collectively the “Indemnified Parties”), provided, however, that any performance guarantees and warranties (of equipment or otherwise) shall remain in effect according to the terms of this Agreement. The limited license to use the work product shall be limited by and construed according to the terms contained in the License Agreement between Owner and ICM, Inc., attached hereto and made a part hereof as Exhibit D.

4.3 Owner’s Limited License Upon Owner’s Termination for Convenience or Design-Builder’s Election to Terminate. If Owner terminates the Project for its convenience as set forth in Article 8 hereof, or if Design-Builder elects to terminate this Agreement in accordance with Section 11.4 of the General Conditions of Contract, Design-Builder shall, then upon Owner’s payment in full of the amounts due Design-Builder under the Contract Documents, vest in Owner a limited license to use the Work Product to complete the Project and subsequently occupy, repair, remodel or enlarge the Project, subject to the following:

  .1    Use of the Work Product is at Owner’s sole risk without liability or legal exposure to any Indemnified Party; provided, however, that any “pass through” warranties regarding equipment or express warranties regarding equipment provided by this Agreement shall remain in effect according to their terms; and

     
 
DBIA Document No. 525 $ Standard Form of Agreement
  Page 3
Between Owner and Design-Builder C Lump Sum
   
8 1998 Design-Build Institute of America
   

 


 

  .2    If the termination for convenience is by Owner or if Design-Builder elects to terminate this Agreement in accordance with Section 11.4 of the General Conditions of Contract, then Owner agrees to pay Design-Builder the additional sum of One Million Dollars ($1,000,000.00) as compensation for the limited right to use the Work Product (completed “as is” on the date of termination) in accordance with this Article 4.

     The limited license to use the work product shall be limited by and construed according to the terms contained in the License Agreement between Owner and ICM, Inc., attached hereto and made a part hereof as Exhibit D.

4.4 Owner’s Limited License Upon Design-Builder’s Default. If this Agreement is terminated due to Design-Builder’s default pursuant to Section 11.2 of the General Conditions of Contract and (i) it is determined that Design-Builder was in default and (ii) Owner has fully satisfied all of its obligations under the Contract Documents through the time of Design-Builder’s default, then Design-Builder shall grant Owner a limited license to use the Work Product in connection with Owner’s completion and occupancy, repair, remodeling, or enlargement of the Project. This limited license is conditioned on Owner’s express understanding that its use of the Work Product is at Owner’s sole risk and without liability or legal exposure to any Indemnified Party; provided, however, that any “pass through” warranties regarding equipment or express warranties regarding equipment provided by this Agreement shall remain in effect according to their terms. This limited license would grant Owner the ability to repair, remodel or expand the Project at Owner’s discretion. The limited license to use the work product shall be limited by and construed according to the terms contained in the License Agreement between Owner and ICM, Inc., attached hereto and made a part hereof as Exhibit D.

4.5 Owner’s Indemnification for Use of Work Product. If Owner uses the Work Product under any of the circumstances identified in this Article 4, Owner shall defend, indemnify and hold harmless the Indemnified Parties from and against any and all claims, damages, liabilities, losses and expenses, including attorneys’ fees, arising out of or resulting from the use of the Work Product; provided, however, that any “pass through” warranties regarding equipment or express warranties regarding equipment provided by this Agreement shall remain in effect according to their terms.

Article 5

Contract Time

5.1 Date of Commencement. The Work shall commence within five (5) days of Design-Builder’s receipt of Owner’s written Notice to Proceed (“Date of Commencement”) unless the parties mutually agree otherwise in writing. The parties agree that a valid Owner’s Notice to Proceed cannot be given until: 1) Owner has title to the real estate on which the project will be constructed; 2) a Letter of Commitment for all necessary financing to construct the project is received; 3) the Phase I and all soil stabilization site work required of Owner, as described in Exhibit “C” is completed; 4) the air permit(s) and/or other applicable local, state or federal permits necessary so that construction can begin, have been obtained; 5) it appears reasonable that financial close on the Letter of Commitment will occur within sixty (60) days of the issuance of said Notice to Proceed; and 6) Owner shall execute a sales tax exemption certificate and provide to Design-Builder.

5.2 Substantial Completion and Final Completion

5.2.1 Substantial Completion of the entire Work shall be achieved no later than Four hundred twenty-five (425) calendar days after the Date of Commencement.

5.2.2 Interim milestones and/or Substantial Completion of identified portions of the Work shall be achieved as follows: Owner shall provide the following within 90 days of Design-Builder’s receipt of Owner’s Notice to Proceed, as described in Section 5.1 of this Agreement:

     •   Owner shall determine its water source and provide Design-Builder an independent analysis of the water source, and

     
 
Page 4
  DBIA Document No. 525 $ Standard Form of Agreement
  Between Owner and Design-Builder C Lump Sum
  8 1998 Design-Build Institute of America

 


 

     •   Owner shall provide the name of its property/all risk insurance carrier and the specific requirements for fire protection.

5.2.3 Final Completion of the Work or identified portions of the Work shall be achieved as expeditiously as reasonably practicable.

5.2.4 All of the dates set forth in this Article 5 (“Contract Time(s)”) shall be subject to adjustment in accordance with the General Conditions of Contract. Specifically, if delays in the Contract Time occur because of delay in the delivery of materials or equipment that is beyond the control of Design-Builder, the Contract Time will be adjusted, without penalty to Design-Builder, pursuant to Sections 8.2.1 and 8.2.2 of the General Conditions of Contract.

5.3 Time is of the Essence. Owner and Design-Builder mutually agree that time is of the essence with respect to the dates and times set forth in the Contract Documents.

5.4 Early Completion Bonus.

5.4.1 If Substantial Completion is attained within 425 days after the Date of Commencement, Owner shall pay Design-Builder at the time of Final Payment under Section 7.3 hereof an early completion bonus of $8,000.00 per day, for each day that Substantial Completion occurred in advance of said 425 days.

5.4.2 In all events, payment of said bonus, if applicable, at the time of Final Payment is subject to release of funds by senior lender. If senior lender does not allow release of funds at the time of Final Payment to pay said early completion bonus in full, any unpaid balance shall be converted to an unsecured Promissory Note payable by Owner to Design-Builder, accruing interest at ten percent (10%), as such rate may change from time to time. On each anniversary of the Note, any unpaid accrued interest shall be converted to principal and shall accrue interest as principal thereafter. Owner shall pay said Promissory Note as soon as allowed by senior lender; in any event, the Note, plus accrued interest, shall be paid in full before Owner pays or makes any distributions to or for the benefit of its owners (shareholders, members, partners, etc.). All payments shall be applied first to accrued interest and then to principal.

Article 6

Contract Price

6.1 Contract Price. Owner shall pay Design-Builder in accordance with Article 6 of the General Conditions of Contract the sum of Forty-five million seven hundred forty-nine thousand seven hundred and 00/100 Dollars ($45,749,700.00) (“Contract Price”), subject to adjustments made in accordance with the General Conditions of Contract. Unless otherwise provided in the Contract Documents, the Contract Price is deemed to include all sales, use, consumer and other taxes mandated by applicable Legal Requirements.

6.2 Markups for Changes. If the Contract Price requires an adjustment due to changes in the Work, and the cost of such changes is determined under Sections 9.4.1.3 or 9.4.1.4 of the General Conditions of Contract, the following markups shall be allowed on such changes: The parties agree that changes shall not occur pursuant to Sections 9.4.1.3 or 9.4.1.4 of the General Conditions of Contract, but may occur pursuant to the other provisions therein.

Article 7

Procedure for Payment

7.0 Payment at Financial Close . As part of the Contract Price, Owner shall pay Design-Builder Three Million Dollars ($3,000,000) as soon as allowed by its organizational documents, the Escrow Agreement and any

     
 
DBIA Document No. 525 $ Standard Form of Agreement
  Page 5
Between Owner and Design-Builder C Lump Sum
   
8 1998 Design-Build Institute of America
   

 


 

other relevant agreements or laws (such payment to possibly occur prior to Financial Close) as a mobilization fee. Provided, however, that said payment, if not made earlier, shall be paid at Financial Close. Financial Close is defined as Owner executing final loan documents obtaining all necessary financing to construct the project and funds are available to pay disbursements. Said Three Million ($3,000,000) Dollar payment shall be subject to the retainage as provided by Article 7.2.1.

7.1 Progress Payments

7.1.1 Design-Builder shall submit to Owner on the twenty-fifth ( 25 th ) day of each month, beginning with the first month after the Date of Commencement, Design-Builder’s Application for Payment in accordance with Article 6 of the General Conditions of Contract.

7.1.2 Owner shall make payment within ten (10) days after Owner’s receipt of each properly submitted and accurate Application for Payment in accordance with Article 6 of the General Conditions of Contract, but in each case less the total of payments previously made, and less amounts properly withheld under Section 6.3 of the General Conditions of Contract.

7.2 Retainage on Progress Payments

7.2.1 Owner will retain ten percent ( 10%) of each payment provided, however, that when fifty percent (50%) of the Work ($22,874,850.00 aggregate payment) has been completed by Design-Builder, Owner will not retain any additional amounts from Design-Builder’s subsequent payments, unless there is less than $2,287,485.00 total retainage. Owner will also reasonably consider reducing retainage for Subcontractors completing their work early in the Project.

7.2.2 Upon Substantial Completion of the entire Work or, if applicable, any portion of the Work, pursuant to Section 6.6 of the General Conditions of Contract, Owner shall release to Design-Builder all retained amounts relating, as applicable, to the entire Work or completed portion of the Work, less an amount equal to the reasonable value of all remaining or incomplete items of Work as noted in the Certificate of Substantial Completion, provided that such payment shall only be made if Design-Builder has met the Performance Guarantee Criteria listed in Exhibit A.

7.3 Final Payment. Design-Builder shall submit its Final Application for Payment to Owner in accordance with Section 6.7 of the General Conditions of Contract. Owner shall make payment on Design-Builder’s properly submitted and accurate Final Application for Payment within thirty (30) days after Owner’s receipt of the Final Application for Payment, provided that Design-Builder has satisfied the requirements for final payment set forth in Section 6.7.2 of the General Conditions of Contract and Design-Builder has met the Performance Guarantee Criteria listed in Exhibit A.

7.4 Interest. Payments which are due and unpaid by Owner to Design-Builder, whether progress payments or final payment, shall bear interest commencing five (5) days after payment is due at the rate of eighteen percent (18%) per annum.

7.5 Record Keeping and Finance Controls. With respect to changes in the Work performed on a cost basis by Design-Builder pursuant to the Contract Documents, Design-Builder shall keep full and detailed accounts and exercise such controls as may be necessary for proper financial management, using accounting and control systems in accordance with generally accepted accounting principles and as may be provided in the Contract Documents. During the performance of the Work and for a period of three (3) years after Final Payment, Owner and Owner’s accountants shall be afforded access from time to time, upon reasonable notice, to Design-Builder’s records, books, correspondence, receipts, subcontracts, purchase orders, vouchers, memoranda and other data relating to changes in the Work performed on a cost basis in accordance with the Contract Documents, all of which Design-Builder shall preserve for a period of three (3) years after Final Payment.

     
 
Page 6
  DBIA Document No. 525 $ Standard Form of Agreement
  Between Owner and Design-Builder C Lump Sum
  8 1998 Design-Build Institute of America

 


 

Article 8

Termination for Convenience

8.1 Upon ten (10) days’ written notice to Design-Builder, Owner may, for its convenience and without cause, elect to terminate this Agreement. In such event, Owner shall pay Design-Builder for the following:

  .1    All Work executed, and for proven loss, cost or expense in connection with the Work;
 
  .2    The reasonable costs and expenses attributable to such termination, including demobilization costs and amounts due in settlement of terminated contracts with Subcontractors and Design Consultants; and
 
  .3    Overhead and profit margin in the amount of fifteen percent ( 15 %) on the sum of items .1 and .2 above, except that overhead and profit shall not be due regarding amounts due in settlement of terminated contracts with subcontractors and design consultants.

8.2 In addition to the amounts set forth in Section 8.1 above, Design-Builder shall be entitled to receive one of the following as applicable: all retainage withheld by Owner.

8.3 If Owner terminates this Agreement pursuant to Section 8.1 above and proceeds to design and construct the Project through its employees, agents or third parties, Owner’s rights to use the Work Product shall be as set forth in Section 4.3 hereof.

Article 9

Representatives of the Parties

9.1 Owner’s Representatives

9.1.1 Owner designates the individual listed below as its Senior Representative (“Owner’s Senior Representative”), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2.3 of the General Conditions of Contract: (Identify individual’s name, title, address and telephone numbers)

      TBD

9.1.2 Owner designates the individual listed below as its Owner’s Representative, which individual has the authority and responsibility set forth in Section 3.4 of the General Conditions of Contract: (Identify individual’s name, title, address and telephone numbers)

      TBD

9.2 Design-Builder’s Representatives

9.2.1 Design-Builder designates the individual listed below as its Senior Representative (“Design-Builder’s Senior Representative”), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2.3 of the General Conditions of Contract: (Identify individual’s name, title, address and telephone numbers)

     
  Roland “Ron” Fagen, CEO and President
  501 W. Highway 212
  P.O. Box 159
  Granite Falls, MN 56241
  Telephone: (320) 564-3324
     
 
DBIA Document No. 525 $ Standard Form of Agreement
  Page 7
Between Owner and Design-Builder C Lump Sum
   
8 1998 Design-Build Institute of America
   

 


 

9.2.2 Design-Builder designates the individual listed below as its Design-Builder’s Representative, which individual has the authority and responsibility set forth in Section 2.1.1 of the General Conditions of Contract: (Identify individual’s name, title, address and telephone numbers)

      TBD

Article 10

Bonds and Insurance

10.1    Insurance. Design-Builder shall procure in accordance with Article 5 of the General Conditions of Contract the following insurance coverage: A certificate of insurance will be provided prior to starting construction. Policy limits shall be as follows:

         
Commercial General Liability:
       
General Aggregate
  $ 2,000,000  
Products-Comp/Op AGG
  $ 2,000,000  
Personal & Adv Injury
  $ 1,000,000  
Each Occurrence
  $ 1,000,000  
Fire Damage (Any one fire)
  $ 50,000  
Med Exp (Any one person)
  $ 5,000  
 
       
Automobile Liability:
       
Combined Single Limit
  $ 1,000,000  
 
       
Excess Liability – Umbrella Form
       
Each Occurrence
  $ 20,000,000  
Aggregate
  $ 20,000,000  
 
       
Workers Compensation and Employers’ Liability:
       
Statutory Limits:
       
Each Accident
  $ 1,000,000  
Disease-Policy Limit
  $ 1,000,000  
Disease-Each Employee
  $ 1,000,000  

    Owner shall obtain a builder’s risk policy naming Owner as the insured, with Design-Builder as additional insured, in an amount not less than the Contract Price. Owner shall also obtain Boiler and Machinery Insurance protecting Owner, Design-Builder, Design Consultants, Subcontracts and Subcontractors. In addition, Owner shall obtain terrorism coverage as described by the Terrorism Risk Insurance Act of 2002.

Article 11

Other Provisions

11.1    Other provisions, if any, are as follows:

  •   Performance Guarantee: The Design-Builder guarantees the Criteria listed in Exhibit A. If there is a performance shortfall, Design-Builder will pay all design and construction costs associated

     
 
Page 8
  DBIA Document No. 525 $ Standard Form of Agreement
  Between Owner and Design-Builder C Lump Sum
  8 1998 Design-Build Institute of America

 


 

    with making the necessary corrections. Design-Builder retains the right to use its sole discretion in determining the method to remedy any performance related issues.

  •   Price Guarantee: The Design-Builder guarantees the Contract Price for the Work delineated by the Contract Documents. Any and all price increases would require, in addition to Owner’s approval, the approval of Owner’s senior lender.
 
  •   Winter Construction: Owner shall have no responsibility for any winter construction related activities including, but not limited to, special material costs, sheltering, heating, and equipment rental, except that Owner shall pay all the reasonable costs incurred for frost removal including, but not limited to, equipment costs, equipment rental costs, and associated labor costs so that winter construction can proceed.
 
  •   Design-Builder shall obtain or cooperate in obtaining a performance bond if such a bond is requested by Owner. If the bond is obtained by Design-Builder, Owner shall pay Design-Builder for the cost of the bond, plus pay Design-Builder a fee of 7.5%, said fee calculated by multiplying 7.5% on the cost of the bond. If purchased by Owner, Owner shall pay all costs of obtaining the bond.
 
  •   Design-Builder warrants that within six (6) months following the date of Substantial Completion, the atmospheric emissions of the ethanol plant shall meet the requirements as currently prescribed, as of the date hereof, by the State of Minnesota Pollution Control Agency. Verification shall be provided by a written report from Design-Builder.

In executing this Agreement, Design-Builder represents that it has the necessary financial resources to fulfill its obligations under this Agreement and has the necessary corporate approvals to execute this Agreement and perform the services described herein. Owner represents that it has the necessary organizational approvals to execute this Agreement; that Owner is seeking financing for the project and that Owner agrees to keep Design-Builder informed of Owner’s progress in obtaining commitments for and closing on such financing. Owner and Design-Builder agree that this Agreement is subject to Owner receiving a complete full funding commitment within 180 days of the signing of this Agreement, and if a full funding commitment is not received within 180 days of the signing of this Agreement, the terms and conditions of this Agreement terminate.

     
OWNER:   DESIGN-BUILDER:
Granite Falls Energy, LLC
  Fagen, Inc.
 
   
(Name of Owner)
  (Name of Design-Builder)
 
   
/s/ Tom Branhan
  /s/ Ron Fagen
 
   
(Signature)
  (Signature)
 
   
Tom Branhan
  Roland “Ron” Fagen
 
   
(Printed Name)
  (Printed Name)
 
   
CEO/GM
  CEO and President
 
   
(Title)
  (Title)                     
 
Date 8-31-04
  Date: 8/31/04
     
 
DBIA Document No. 525 $ Standard Form of Agreement
  Page 9
Between Owner and Design-Builder C Lump Sum
   
8 1998 Design-Build Institute of America
   

 

 

Exhibit 10.11

ETHANOL MARKETING AGREEMENT

This Ethanol Marketing Agreement (“Agreement”) is made and entered into as of the 31st day of August, 2004 by and between Granite Falls Energy, LLC a Minnesota limited liability company (“GFE”) and AVENTINE RENEWABLE ENERGY, INC., a Delaware corporation (“ARE”) (each a “Party”, and collectively the “Parties”).

In consideration of the mutual terms and conditions contained herein, the Parties agree as follows:

1.   Term and Termination : The term of this Agreement shall commence on the date hereof and shall continue for a primary term of two (2) years from the first day of the first month commencing after the date of the first Bill of Lading delivered hereunder and thereafter; automatically renewing for successive one (1) year terms, unless terminated on the expiration date of the two (2) year primary term, or on the expiration date of any subsequent one (1) year renewal term, in each case by either Party with at least one (1) year written notice prior to such expiration date.

2.   ARE Investment in GFE: ARE has purchased an equity interest in GFE at a cost of $500,000 (such initial equity interest in GFE and any subsequent equity or other investment by ARE in GFE and/or any of its direct or indirect subsidiaries (if any) is herein referred to as the “Investment”). In the event this Agreement is terminated for any reason, including without limitation by either Party pursuant to Section 1. Term and Termination , then ARE shall have the option, to be exercised in ARE’s sole discretion concurrent with or at any time after ARE receives or delivers written notice of such termination, or if no such written notice is provided with or at any time after such termination, to cause GFE to purchase the Investment. ARE shall exercise such option by providing written notice to GFE specifying (i) the date on which such purchase is to occur, which shall be no sooner than ten (10) days after ARE provides such written notice to GFE and (ii) the purchase price for the Investment, which shall be the actual cost ARE originally paid for such Investment (the “Cost”). On the date specified in such written notice (i) GFE shall pay to ARE, in immediately available funds, the Cost of the Investment and (ii) upon receipt of such amount, ARE shall transfer and assign to GFE the Investment. GFE shall be responsible for obtaining any member approval and/or any other approvals which may be required, if any, of such transfer of the Investment to GFE, and ARE shall cooperate in obtaining such approvals. If GFE fails to purchase the Investment on the specified date in accordance with the foregoing, ARE shall have the right to set off any amounts owed by ARE to GFE under this or any other agreement with GFE, against the amount owed by GFE for the purchase of the Investment from ARE (i.e. the Cost). Upon receipt of such Cost by ARE, whether through such set off of otherwise, ARE shall, subject to receiving any necessary approvals, transfer and assign the

1


 

    Investment to GFE. The provisions of this section shall survive termination of this Agreement.

3.   Quantity and Quality

  A.   GFE shall sell exclusively to ARE the total output of fuel grade ethanol (“Ethanol”) produced at GFE’s Granite Falls, MN facility (“Plant”), currently anticipated to be forty (40) million gallons per year. Ethanol shall be delivered FOB the Plant, and title shall pass on the date of the Bill of Lading. Ethanol produced for the intended use as an alternative or racing fuel shall not be excluded from this agreement.
 
  B.   Such Ethanol shall meet or exceed all industry standards or any specifications so required by the customer. ARE shall have the right to reject any Ethanol which does meet such standards and such standards are subject to change by ARE.

4.   ARE shall :

  A.   Market all of the Ethanol produced by GFE at the Plant, at the price outlined in Section 6;
 
  B.   Remit payment to GFE for the Ethanol as provided in Section 6; and
 
  C.   Be responsible for scheduling all shipments of Ethanol with GFE.

5.   GFE shall:

A. Provide to ARE on a timely basis annual production forecasts, monthly updates to the rolling twelve month production forecasts, monthly updates, daily plant inventory balances and shipment information, and other information reasonably requested by ARE; GFE shall use its reasonable best efforts to meet the monthly production targets reflected in the then-current annual production forecast;

B. Notify ARE promptly of any material unscheduled shut-down, suspension or significant decrease in production at the Plant that was not reported in the rolling twelve month production forecasts or monthly updates provided under Section 5.A. above;

C. Provide to ARE specifications and certificates of analysis of the Ethanol sold to ARE that are consistent with the specifications referred to in Section 3.B. above; GFE shall, at its expense, provide or cause to be provided all testing and related test equipment at or in the vicinity of the Plant to determine compliance with such specifications and

2


 

ARE or its representative shall, at ARE’S expense, have the right to perform periodic tests to determine compliance with such specifications.

D. Be responsible for compliance with all federal, state and local rules, regulations and requirements regarding the shipment of Ethanol from the Plant, including but not limited to, all U.S. Department of Transportation (“DOT”) requirements relating to shipment of hazardous materials (e.g. proper paperwork, railcars meeting DOT requirements, etc.).

  E.   Provide for a minimum of eight days storage on GFE’s premises at GFE’s cost;
 
  F.   For all gallons sold to ARE, use certified meters or weight-scales that provide both gross and net 60° Fahrenheit temperature compensated gallons; and
 
  G.   Provide any of the information to be provided by GFE pursuant to this Section 5 to ARE electronically in data form, if such information is available in such form.

6.   Pricing and Commission

A. Sales Price . The per gallon sale price GFE shall receive for the Ethanol sold to ARE under this Agreement shall be based on the Alliance Net Pool Price, as defined below, which shall be adjusted to reflect the Pooled Volume Adjustment and/or Pooled Volume True-Up, as applicable. An illustrative example of the calculation of Alliance Net Pool Price is attached as Exhibit A hereto.

      Alliance Net Pool Price ” shall mean, with respect to any month, (i) the weighted average gross price per gallon received by ARE for all fuel grade Ethanol that was (A) supplied by an alliance partner or produced by ARE and (B) sold during such month by ARE, minus (ii) all costs (on a per gallon basis) incurred by ARE in conjunction with the handling, movement and sale of such Ethanol, including but not limited to terminal lease charges, throughput charges, terminal shrinkage costs, freight charges, tariffs, costs of leasing railcars, trucks, river barges and ocean going vessels, government taxes and assessments, insurance, inspection fees, administrative costs, working capital carrying costs, bad debt expense, costs of purchasing and delivering replacement ethanol due to lost or interrupted Ethanol production and other costs, but excluding direct marketing costs incurred in marketing such Ethanol. ARE shall use commercially reasonable efforts to contain the costs described in clause (ii) above so as to maximize the Alliance Net Pool Price.
 
      If ARE’s pooled volume of fuel grade Ethanol at the end of a month is higher than its pooled volume at the end of the immediately preceding month because pooled sales volumes were less than the aggregate volume supplied by the alliance partners or produced by ARE during such month, the Alliance Net Pool Price for

3


 

      such month shall be calculated as if the amount of such increase was included as gallons supplied by the alliance partners and/or produced by ARE and sold by ARE during such month at a price per gallon equal to the estimated Alliance Net Pool Price for the immediately following month (as determined in good faith by ARE). The amount by which the Alliance Net Pool Price for any month is increased or decreased as a result of the foregoing sentence is the “Pooled Volume Adjustment” for such month.
 
      In the event that the actual Alliance Net Pool Price for a month is different from the estimated Alliance Net Pool Price used in calculating the Pooled Volume Adjustment for the immediately preceding month, an adjustment to the Alliance Net Pool Price in the current month shall be made by an offset which is equal to the amount of such difference. Such adjustment is the “Pooled Volume True-Up.” Payment shall be made in accordance with paragraph C below. A Pooled Volume True-Up shall occur at the time of payment for the last delivery of Ethanol under this Agreement to reflect the actual Alliance Net Pool Price for the final month of the term of this Agreement.

B. Commission . For each gallon of Ethanol sold to ARE under this Agreement, ARE shall deduct from the Alliance Net Pool Price a commission equal to *** of the Alliance Net Pool Price.

*** Material has been omitted pursuant to a request for confidential treatment and such material has been filed separately with the Securities and Exchange Commission .

C. Payment . For all quantities of Ethanol purchased by ARE from GFE and shipped from the Plant during a one-week period beginning on Monday and ending on the following Sunday, ARE shall pay the estimated Alliance Net Pool Price referred to in Section 6.A. less commissions referred to in Section 6.B., to GFE by ACH or wire no later than fifteen (15) business days following the end of said one-week period. If at calendar month’s end, the actual Alliance Net Pool Price exceeds the estimated Alliance Net Pool Price, ARE shall pay GFE on or before the 15 th business day of the following calendar month an amount equal to the product of (x) the difference between the actual and estimated Alliance Net Pool Price (in each case less commissions) and (y) the aggregate quantity of Ethanol purchased by ARE from GFE and shipped from the Plant under this Agreement during the prior calendar month. If the actual Alliance Net Pool Price is less than the estimated Alliance Net Pool Price, GFE shall pay ARE and ARE shall have the right to withhold and set off from future payments to GFE, an amount equal to the product of (x) the difference between the actual and estimated Alliance Net Pool Price (in each case less commissions) and (y) the aggregate quantity of Ethanol purchased by ARE from GFE and shipped from the Plant under this Agreement during such month.

4


 

D. Supporting Records . ARE shall keep a set of books and records in accordance with generally accepting accounting principals with respect to all sales of Ethanol hereunder and all costs and commissions associated therewith, and shall make such books and records reasonably available to GFE’s independent outside accounting representatives (upon execution by such independent outside accounting representative of a mutually agreeable confidentiality agreement) at ARE’s office at any time by appointment during normal business hours upon at least five (5) business days prior written notice; provided that GFE shall be entitled to no more than one (1) such visit in any year and GFE’s independent outside accounting representatives shall be permitted to disclose to GFE only aggregate summary information of the results of its review, and not any contract or customer specific information. In addition, ARE shall provide GFE by e-mail or fax with supporting documentation regarding the calculation of the estimated Alliance Net Pool Price with each weekly payment for Ethanol.

7. Responsibility for Dedicated Railcars . GFE acknowledges that ARE will enter into leases or other arrangements intended to secure the availability of sufficient railcars to ship the Ethanol produced at the Plant as contemplated by this Agreement (“Dedicated Railcars”). ARE shall promptly notify GFE of such arrangements. In the event GFE or ARE terminates this Agreement and ARE’s commitments with respect to the Dedicated Railcars continue past the date of such termination, GFE shall be responsible for all of ARE’s costs and expenses (including without limitation carrying costs and finance charges) related to such Dedicated Railcars after the date of such termination. ARE and GFE shall cooperate in good faith to minimize the amount of any such costs and expenses, including using commercially reasonable efforts to assign ARE’s rights and obligations with respect to the Dedicated Railcars to GFE. Without limiting the generality of the foregoing, except as may otherwise be agreed by ARE and GFE and recognizing that ARE will make a good faith effort to accommodate any start-up issues and schedule rail cars accordingly, in the event that the Plant does not start up or fails to provide substantially the contemplated volumes of Product, any costs incurred for such Dedicated Railcars not so utilized shall be for GFE’s account.

8. Indemnity : ARE shall indemnify, defend, and hold GFE and its affiliates, subsidiaries, parents, and its and their respective directors, officers, stockholders, employees, and agents harmless from and against any and all claims, losses, awards, judgments, settlements, fines, penalties, liabilities, damages, costs or expenses (including reasonable out-of-pocket Attorney’s fees and expenses) incurred on account of any injury or death of persons or damages to property to the extent caused by or arising out of the negligence or willful misconduct of ARE, its officers, employees, or agents in performing ARE’s obligations under this Agreement.

GFE shall indemnify, defend, and hold ARE and its affiliates, subsidiaries, parents, and its and their respective directors, officers, stockholders, employees, and agents harmless from and against any and all claims, losses, awards, judgments, settlements, fines, penalties, liabilities, damages, costs or expenses (including reasonable out-of-pocket Attorney’s fees and expenses) incurred on account of any injury to or death of persons or damages to property to the extent caused by or arising out of the negligence or willful misconduct of GFE, its officers, employees,

5


 

or agents in performing GFE’s obligations under this Agreement. In addition, GFE shall indemnify and hold ARE and its affiliates, subsidiaries, parents, and its and their respective directors, officers, stockholders, employees, and agents harmless from and against any and all claims, losses, awards, judgments, settlements, fines, penalties, liabilities, damages, costs or expenses (including reasonable out-of-pocket Attorney’s fees and expenses) to the extent caused by or arising out of (i) any defects in, or otherwise relating to the quality or condition of, the Ethanol supplied by GFE and (ii) noncompliance with applicable federal, state or local rules, regulations or requirements regarding shipment of Ethanol from the Plant as more fully set forth in Section 5.D above.

9. Force Majeure :

A. In the event either Party is rendered unable, wholly or in part, by Force Majeure to carry out its obligations under this Agreement, it is agreed that on such Party’s giving notice in writing, or by telephone and confirmed in writing, to the other Party as soon as possible after the commencement of such Force Majeure event, the obligations of the Party giving such notice, so far as and to the extent they are affected by such Force Majeure, shall be suspended from the commencement of such Force Majeure and during the remaining period of such Force Majeure, but for no longer period, and such Force Majeure shall so far as possible remedied with all reasonable dispatch; provided, however, the obligation to make payments then accrued hereunder prior to the occurrence of such Force Majeure shall not be suspended.

B. The term “Force Majeure” as used in this Agreement shall mean strikes, lockouts or industrial disturbances; riots or civil disturbances; interference by civil or military authorities; wars, blockades, insurrection, or acts of other public enemy or acts of terrorism; epidemics, landslides, lightning, earthquakes, fires, storms, floods, washouts or other acts of God; arrests or restraints of governments and people; compliance with federal, state or local laws, rules or regulations, acts, orders, directives, requisitions or requests of any official or agency of federal, state or local governments; fires, explosions, freezing, failures, disruptions, breakdowns or accidents to transportation equipment or facilities; prorationing by transporters; the necessity of testing, making repairs, alterations or enlargements to transportation equipment or facilities; embargoes, priorities, expropriation or condemnation by government or governmental authorities; and any other cause which is not reasonably within the control of the Party claiming suspension.

10.   Limitation of Damages : NEITHER PARTY SHALL BE LIABLE OR OTHERWISE RESPONSIBLE TO THE OTHER PARTY HEREUNDER FOR CONSEQUENTIAL, EXEMPLARY, SPECIAL, INCIDENTAL OR PUNITIVE DAMAGES AS TO ANY ACTION OR OMISSION, WHETHER CHARACTERIZED AS A CONTRACT BREACH OR TORT OR OTHERWISE THAT ARISES OUT OF OR RELATES TO THIS AGREEMENT OR ITS PERFORMANCE EXCEPT FOR ANY SUCH AMOUNTS PAID BY A PARTY TO A NON-AFFILIATE THIRD PARTY, WHICH

6


 

    WOULD THEREFORE BE CONSIDERED ACTUAL DAMAGES INCURRED BY SUCH PARTY.

11.   Independent Contractor : It is expressly understood that the relationship of ARE to GFE is that of an independent contractor and nothing contained herein shall be construed to create any partnership, agency, or employer/employee relationship. ARE may freely choose the customers from whom business shall be solicited and the time and place for solicitation.

12.   Notices : Any notices required to be given under this Agreement shall be in writing and be sufficiently given when delivered in person or deposited in the U.S. mail (registered or certified), postage prepaid, addressed as follows:

         
  GFE:   Granite Falls Energy, LLC
      P.O. Box 216
      Granite Falls, MN 56241
      Attn: Thomas E. Branhan
 
       
  ARE:   Aventine Renewable Energy, INC
      P. O. Box 10
      Pekin, IL 61555
      Attn: Ron Miller

13.   Insurance : Each Party shall maintain, at all times while this Agreement is in effect, and each at its own sole cost and expense, comprehensive general liability insurance with a combined single limit for bodily injury and property damage of not less than $1,000,000 for any one occurrence. Each Party shall promptly after execution of this Agreement furnish the other Party a Certificate of Insurance evidencing the foregoing insurance coverage, and shall promptly provide the other Party with prior written notice of any change to or cancellation of such Certificate of Insurance or insurance coverage. The insurance requirements set forth herein are minimum coverage requirements and are not to be construed in any way as a limitation on liability under this Agreement.

14.   Entire Agreement : This Agreement contains the entire agreement between the Parties and supersedes all previous agreements, either oral or written, between the Parties. The language of this Agreement shall not be construed in favor of or against either Party, but shall be construed as if, the language was drafted mutually by both Parties. No modifications hereof shall be valid unless made in writing and signed by both Parties.

15.   Waiver : The failure of either Party to enforce any of its rights hereunder on any particular occasion shall not constitute a waiver of such rights on any subsequent occasion.

7


 

16.   Assignment : This Agreement may not be assigned by either Party without the prior written consent of the other Party, which consent shall not be unreasonably withheld.

17.   Headings : Any paragraph headings are used for convenience only and are not intended and shall not be used in interpreting any provisions of this Agreement.

18.   No Third Party Beneficiary : Except as otherwise provided herein, nothing contained in this Agreement shall be considered or construed as conferring any right or benefit on a person not a Party to this Agreement and neither this Agreement nor the performance hereunder shall be deemed to have created a joint venture or partnership between the Parties.

19.   Governing Law : This Agreement shall be governed by the laws of the State of New York without regard to the conflict of laws provisions thereof.

20.   Arbitration : Any dispute arising out of or in connection with this Agreement shall be submitted to arbitration. The arbitration shall be conducted according to the Commercial Arbitration Rules of the American Arbitration Association. The place of arbitration shall be New York, New York or such other place as may be agreed upon by the Parties. Both Parties shall attempt to agree upon one arbitrator, but if they are unable to agree, each shall appoint an arbitrator and these two shall appoint a third arbitrator. Expenses of the arbitrator(s) shall be divided equally between the Parties. Judgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction thereof, and shall be enforceable against the Parties in accordance with the 1958 Convention on the Recognition and Enforcement of Foreign Arbitral Awards, as amended.

21.   Severability : If any term or provision of this Agreement is held by a court of competent jurisdiction to be invalid, void or unenforceable, the remainder of the terms and provisions of this Agreement shall remain in full force and effect and shall in no way be affected, impaired or invalidated so long as the economic or legal substance of the transactions contemplated hereby is not affected in any manner materially adverse to a Party. Upon such determination, the Parties shall negotiate in good faith to modify this Agreement so as to effect the original intent of the Parties as closely as possible in an acceptable manner so that the transactions contemplated hereby be consummated as originally contemplated to the fullest extent possible.

22.   Confidentiality : The terms of this Agreement and any non-public information provided to GFE pursuant to this Agreement (including without limitation pursuant to Section 6.D. hereof) are confidential and GFE will hold, and will cause its agents, accountants and advisors to hold, all such information in confidence, unless it is compelled to disclose such information by judicial or administrative process or by other requirements of law.

8


 

     In WITNESS WHEREOF, the Parties hereto have caused this Agreement to be duly executed as of the date first written above.

             
Aventine Renewable Energy, INC   Granite Falls Energy, LLC
 
           
By:
  /s/ Ronald Miller   By:   /s/ Thomas E. Branhan
           
  Ronald Miller, President       Thomas E. Branhan, General Manager
 
           
Date:
  August 31, 2004   Date:   August 31, 2004

9


 

EXHIBIT A

ILLUSTRATIVE EXAMPLE OF CALCULATION OF
ALLIANCE NET POOL PRICE

                 
              $/GALLON  
Gross Ethanol price (alliance producers and ARE)
            1.250  
 
               
Less: Terminal Lease Charges, Throughput Charges, Terminal Shrinkage Costs, Freight, Tariffs, Tank Car, Truck, River Barge and Ocean Going Vessel Leasing Costs, Government Taxes and Assessments, Insurance, Inspection Fees and other costs (except for those separately set forth below) under item (ii) of the definition of Alliance Net Pool Price.
            0.100  
 
               
Working Capital including Inventory Carrying Costs
            0.006  
 
               
Indirect Marketing Costs including Bad Debt Expense
            0.001  
 
               
ALLIANCE POOL PRICE before POOLED VOLUME ADJUSTMENT
            1.143  
 
               
Pooled Volume Adjustment Plus or (Minus)
            + 0.002  
 
               
ALLIANCE POOL PRICE before POOLED VOLUME TRUE-UP
            1.145  
 
               
Prior Month Pooled Volume True-Up Plus or (Minus)
            (0.001 )
 
               
ALLIANCE NET POOL PRICE
            1.144  

10

 

Exhibit 10.13

ELECTRIC SERVICE AGREEMENT

This Agreement made and entered into August, 2004, by and between Minnesota Valley Cooperative Light and Power Association, Montevideo, Minnesota (hereinafter called the Cooperative) and Granite Falls Community Ethanol Plant, LLC, Granite Falls, Minnesota (hereinafter called the Customer).

      WITNESSETH:

      WHEREAS , the Customer is constructing an ethanol plant located in the Northeast Quarter of Section 1, Township 115 North, Range 39 West, Minnesota Falls Township, Yellow Medicine County, Minnesota (hereinafter called the Facility); and

      WHEREAS , the Customer desires to have the Cooperative provide all of the electric power and energy requirements of the Facility and related Facilities on the described property, and the Cooperative is willing and able to provide these requirements.

      NOW, THEREFORE , in consideration of the mutual promises, covenants and conditions contained herein, the Cooperative and the Customer agree as follows:

1.    Description of Facility.
 
    The Facility shall include the Customer-owned ethanol plant and related facilities located in the Northeast Quarter of Section 1, Township 115 North, Range 39 West, Minnesota Falls Township, Yellow Medicine County, Minnesota.
 
2.    Agreement to Sell and Purchase.
 
    The Cooperative hereby agrees to sell and deliver to the Customer and the Customer agrees to purchase and receive from the Cooperative all of the electric power and energy requirements of the Facility upon the terms and conditions hereinafter provided.
 
3.    Service Characteristics.

  a.   Service Delivery. Service hereunder shall be provided at the Customer property boundary. The Cooperative shall install or cause to be installed, operated and maintained approximately 6.5 miles of 69 kV transmission line and a 69/12.5 kV, 14,000 kVA substation. If requested, the Cooperative will provide service to the distribution transformers on the plant site, the terms of which will be provided under separate agreement.
 
  b.   Capacity. Electrical service to the Facility under this Agreement shall be limited to 4,500 kW at 95% power factor. Service to additional load above 4,500 kW shall require an amendment to this Agreement.
 
  c.   Firm Service. Service hereunder shall be firm without scheduled interruptions. Power interruptions may occur as the result of planned and coordinated maintenance and circumstances beyond the control of the Cooperative as provided for in Section 4i of this Agreement.

 


 

4.    Service Conditions and Requirements.

  a.   Cooperative-Owned Facilities. The Cooperative will furnish or cause to be furnished, installed and maintained all electric equipment and facilities required to deliver electric power and energy to the Customer for the Facility to the point of connection. The point of connection shall be the Customer property line. If electric service is furnished beyond the property line under separate agreement, equipment furnished, installed, operated and maintained by the Cooperative, as identified in Section 3a, on the property of the Customer shall remain the property of the Cooperative and may be removed upon termination of this Agreement.
 
  b.   Customer-Owned Facilities. The Customer shall be solely responsible for the design, installation, maintenance and safety of any and all Customer supplied electric facilities or equipment. The Customer shall provide and maintain the necessary protection equipment to protect its own facilities from harm from any electrical cause as well as to protect the Cooperative’s equipment and members from any damages, interruption of service, or faulty service due to faults or operations of the Customer’s equipment.
 
  c.   Location of Cooperative Facilities. If necessary, the Customer will provide to the Cooperative suitable locations for the installation of electric facilities on the property of the Customer. The Customer shall provide the Cooperative or its power supplier, at no cost, a warranty deed for the substation property and permanent easements for all other electric power supply facilities located on site, including but not limited to, in and out transmission and distribution lines to permit multiple use of said facilities, on-site distribution lines and distribution transformer sites. The Customer will provide site grading for the substation at no cost to the Cooperative and further will provide a concrete pad for all service transformers in accordance with specifications provided by the Cooperative.
 
  d.   Accessibility to Cooperative Facilities. Duly authorized representatives of the Cooperative shall be permitted to enter on the property of the Customer to the extent necessary to maintain and service electric facilities at all reasonable times in order to carry out the provisions of this Agreement.
 
  e.   Operation of Cooperative Equipment. The Customer will do nothing to interfere with the operation of any Cooperative-owned electric equipment or facilities, including any metering or signaling equipment. The Customer shall advise the Cooperative as soon as possible if the Customer discovers any apparent problem with the condition or functioning of the Cooperative’s equipment or facilities.
 
  f.   Operation of Customer Equipment. The Customer’s electric service, electric facilities and load characteristics will conform to the National Electric Code and National Electric Safety Code, IEEE/ANSI standards and Prudent Utility Practice. If the operation of any of the Customer’s equipment causes power quality or operational problems to the Cooperative’s electric system, the Customer shall promptly correct or remove the cause of the problem. If the Customer does not eliminate the problem, the Cooperative can correct or remove the problem from the electric system and the Customer will be responsible for the costs. The Customer shall notify the Cooperative immediately if the Customer discovers that the condition

 


 

      or operation of any of the Customer-supplied electric equipment or facilities may pose a risk to any persons or property.
 
  g.   Cooperative Membership. The Customer shall be a member of the Cooperative during the term of this Agreement.
 
  h.   Power Factor. The Customer agrees to maintain unity power factor as nearly as practical. The demand charges shall be adjusted to correct for average power factors less than five percent (5%) unity (lagging) or greater than five percent (5%) unity (leading) by increasing the measured demand one percent (1%) for each one percent (1%) by which the average power factor is less than five percent (5%) unity (lagging) or more than five percent (5%) unity (leading).
 
  i.   Hold Harmless. If the supply of electric power and energy provided by the Cooperative should fail or be interrupted, or become defective, through (a) compliance with any law, ruling, order, regulation, requirement or instruction of any federal, state or municipal governmental department or agency or any court of competent jurisdiction; (b) Customer action or omissions; or (c) acts of God, fires, strikes, embargos, wars, insurrection, riot, equipment failures, operation of protective devices, or other causes beyond the reasonable control of the Cooperative, the Cooperative shall not be liable for any loss or damages incurred by the Customer or be deemed to be in breach of this Agreement. The Customer acknowledges that the delivery of electric power and energy may at times be subject to interruption by causes beyond the control of the Cooperative including weather conditions, vandalism, accidents and other interruptions, and that the Customer assumes the risk of those potential interruptions. The Cooperative will use its best efforts to return the interrupted electric service in the shortest reasonable time under the circumstances.

5.    Metering.

  a.   Point of Metering. Metering will measure the demand and energy of the total Facility, and will be located at the 69/12.5 kV substation on the 7,200/12,470 volt secondary bus.
 
  b.   Metering Responsibility. All meters shall be furnished, installed, maintained and read by the Cooperative.
 
  c.   Meter Testing Procedure. The metering shall be tested yearly for accuracy. If any test discloses the inaccuracy of said meters to the extent of more than two percent (2%) fast or slow, an adjustment in billing, according to the percentage of inaccuracy found, shall be made for the period elapsed subsequent to the date of the last preceding test.
 
  d.   Meter Failure. Should the metering equipment at any time fail to register proper amounts or should the registration thereof be so erratic as to be meaningless, the capacity and energy delivered shall be determined from the best information available.

 


 

6.    Rates and Payment.

  a.   Rate Schedule Application. The Customer shall pay the Cooperative for service rendered hereunder at the rates and upon the terms and conditions set forth in Rate Schedule Ethanol Plant, attached to and made a part of this Agreement and any revisions thereto or substitutions thereof adopted by the Cooperative’s Board of Directors.
 
  b.   Minimum Charge. Irrespective of the Customer’s requirements for kW demand or use of kWh energy, the minimum charge for billing purposes hereunder shall not be less than $8,000 for any billing month.
 
  c.   Future Rate Charges. The Distribution Demand Charges shall be those provided in Rate Schedule Ethanol Plant and shall remain the same for the five years after commencement of significant service to the Customer. The rates shown do not include applicable state and local sales taxes. Power Supply Demand and Energy Charges may change when Basin Electric rates change to the Cooperative.
 
      The rate charges in Rate Schedule Ethanol Plant are for electric service taken to the Customer’s property. Facilities beyond the property may be assessed a Facilities Charge set forth in Part d. below.
 
      The Parties further agree that the rate hereunder may be adjusted by the amount of any new or increased level of income, property or other direct tax imposed on the Cooperative.
 
      As a Cooperative member, the Customer will receive fair and equitable treatment in the establishment of rates to be applied to this facility.
 
  d.   Facilities Charge. For the term of this Agreement, the Customer will pay a monthly Facilities Charge in the amount set forth in Schdule Ethanol Plant. If the Cooperative installs additional facilities that are not a part of this Agreement, and such facilities are not paid for initially by the Customer, the Customer shall be subject to additional Facilities Charges.
 
  e.   Payment Arrangements. All charges for service shall be paid to the Cooperative at its Montevideo office, through the mail, or by electronic transfer. The monthly billing periods shall be from the first day of the month through the last day of the month. The Customer agrees to prepay the monthly bill based on the estimated demand and energy use. Payment is due 5 days prior to the first day of the month. If payment is not received or postmarked by the Cooperative by the first day of the month, the Customer agrees that the Cooperative may disconnect service to the facility until the payment is made.
 
  f.   Monthly True-up of Charges. An employee of the Cooperative will read the meter(s) on or about the first day of each month. At the end of the billing month, the amount of Monthly Prepayment described in Section 6.e. above, shall be subtracted from the total amount derived from actual demand and energy values that were read and applied to Rate Schedule Ethanol Plant. This amount will be added to the next

 


 

      month’s prepayment. Both parties will strive to keep True-up values as close to zero as possible by providing accurate demand and energy projections.
 
  g.   Disputed Bills. The Customer shall pay all bills for services and/or energy timely and in accordance with billing procedures herein contained even though said charges may be disputed. If it is determined that the Customer is entitled to a refund or credit for a disputed bill, the Cooperative shall, in addition to the principal amount refunded or credited, pay interest on said amount at the rate authorized for interest on judgments in the State of Minnesota. Neither party shall be obligated to settle disputes by arbitration or mediation without the mutual consent of the parties.

7.    Commencement and Termination.

  a.   Commencement Date. This Agreement shall be in effect as of the date executed and the Customer’s obligation to purchase electricity hereunder shall commence upon the startup of the commercial operation of the Facility but no later than January 1, 2006, whichever comes first.
 
  b.   Obligation for Reimbursement of Cooperative Investment. The Customer is responsible for paying for the Cooperative’s cost associated with installing the facilities required to provide electric service to the Customer’s facilities. In the event that this Agreement is terminated and the Customer ceases to use the facilities described in Section 3a, the Customer agrees to pay to the Cooperative 50% of the balance of any unamortized investment less the salvage value of any removed facilities. To secure this obligation, the Customer shall provide an irrevocable bank letter of credit to the beneficiary of the Cooperative in the amount of $500,000 for a period of 5 years.
 
  c.   Default and Termination. The Customer shall be in default if it fails to timely pay for service under this Agreement, if it breaches any other of its obligations to the Cooperative, or if it becomes the subject of bankruptcy or insolvency proceedings. If the Customer fails to cure that default within ten (10) days after the Customer received written notice of default from the Cooperative, the Cooperative may, at its sole option, suspend or terminate its further performance under this Agreement, disconnect electric service to the Customer, terminate this Agreement, or take other action to address the Customer’s default. This provision shall not limit the Cooperative’s right to take immediate action to suspend services if the Customer’s act or omission interferes with the safe and efficient operation of the Cooperative’s electric system, nor shall it limit the Cooperative’s right to pursue any other or further remedy available to it by law.

8.    Patronage Capital Credits.
 
    Service under the rates provided for in this Agreement is subject to a special allocation of capital credits to the Customer by the Cooperative. This allocation will take into account the incremental cost allocation associated with the market-based rates that are included in this Agreement. For the purpose of this Agreement, the Customer acknowledges that it is not a natural person under Minnesota law.

 


 

9.    Disclaimer of Warranty and Limitation of Liability.
 
    Each party shall be responsible for its own facilities and personnel provided or used in the performance of this Agreement. Neither the Cooperative nor the Customer shall be responsible to the other party for damage to or loss of any property, wherever located, unless the damage or loss is caused by its own negligence or intentional conduct or by the negligence or intentional conduct of that party’s officers, employees, or agents, in which case the damage or loss shall be borne by the responsible party. The Cooperative shall not be responsible or liable to the Customer or to any other party for any indirect, special or consequential damages, or for loss of revenues from any cause.
 
10.    Indemnification.
 
    The Customer agrees to indemnify and holds the Cooperative harmless from and against any liability for any claims or demands arising out of property damage, bodily injury, or interruptions to the Customer’s electric service caused by electric equipment or facilities owned by the Customer, or the Customer’s possession, use, or operation of electric equipment or facilities.
 
11.    General.

  a.   Governing Law. This Agreement and the rights and obligations of the parties hereunder shall be construed in accordance with and shall be governed by the laws of the State of Minnesota.
 
  b.   Notices. All notices under this Agreement shall be given in writing and shall be delivered personally or mailed by first class U.S. mail to the respective parties as follows:

         
    To Customer:
      Manager
      Granite Falls Energy, LLC
      150 th Street South East and Minnesota Highway 23 North
      Granite Falls, Minnesota 57006
 
       
    To Cooperative:
      Manager/ CEO
      Minnesota Valley Cooperative Light and Power Association
      P.O. Box 717
      Montevideo, Minnesota 56265

  c.   No Waiver. No course of dealing nor any failure or delay on the part of a party in exercising any right, power or privilege under this Agreement shall operate as a waiver of any such right, power or privilege. The rights and remedies herein expressly provided are cumulative and not exclusive of any rights or remedies, which a party would otherwise have.
 
  d.   Entire Agreement/ Amendment. This Agreement represents the entire Agreement between the parties with respect to the matters addressed in this Agreement, except as provided in the Cooperative’s bylaws, rules and regulations applicable to similarly situated customers, which are incorporated herein. This Agreement may be changed,

 


 

      waived, or terminated only by written agreement signed by both parties as set forth herein.
 
  e.   Assignment. The Cooperative may assign this Agreement to an affiliate or affiliates of the Cooperative, to a partnership(s) in which the Cooperative or an affiliate has an interest, or to any entity which succeeds to all or substantially all the Cooperative’s assets by sale, merger or operation of law. The Customer may not assign this Agreement without the written consent of the Cooperative, which consent will not be reasonably withheld.
 
  f.   Severability. Should any part, term or provision of this Agreement be, by a court of competent jurisdiction, decided to be illegal or in conflict with any applicable law, the validity of the remaining portions or provisions shall not be affected thereby.
 
  g.   Temporary Service. The Cooperative will extend temporary service to the Customer prior to Customer production for the purpose of construction of such facilities and testing, as required. Such loading shall not be of such a nature as to cause power quality problems for the Cooperative. The Customer and its contractors shall coordinate with the Cooperative on any questionable load.
 
  h.   Cost of Temporary Service. The cost of such Temporary Service shall be borne by the Customer and shall include cost of construction including materials, plus the cost of retirement less the salvage value of such Temporary Service. Power and energy for such services shall be provided under existing single and/or three phase rate schedules, as appropriate.

 


 

  i.   IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their duly authorized representatives, all as of the day and year first above written.

             
Attest:       MINNESOTA VALLEY COOPERATIVE LIGHT AND
POWER ASSOCIATION
 
           
      By:   /s/ Pat Carruth
         
 
           
Title:
      Title:   General Manager
 
           
Attest:       GRANITE FALLS COMMUNITY
        ETHANOL PROJECT LLC
 
           
      By:   /s/ Tom Branhan
         
 
           
Title:
      Title:   CEO/General Manager

 


 

     
Minnesota Valley Cooperative
  Effective Date: ___
Light & Power Association
   
501 South 1 st Street
   
Montevideo, Minnesota 56265
   

SCHEDULE ETHANOL PLANT

INDUSTRIAL SERVICE

Availability

     Available to Granite Falls Community Ethanol Project (Ethanol Plant) near Granite Falls, Minnesota.

Character of Service

     Three-Phase, 60 Hertz, at standard primary distribution voltages.

Monthly Rate

     
Facilities Charge:
  $8,000.00 per month
Distribution Demand Charges:
  $2.15 per kW-Month
Power Supply Demand Charges:
  $6.70 per kW-Month
Energy Charge:
  $0.01964 per kWh

     The Power Supply Demand and Energy Charge may be revised any time the Basin Electric Power Cooperative (Basin) wholesale rate to Minnesota Valley is changed.

Determination of Billing kW

     The billing kW shall be Ethanol Plant half-hour integrated metered kilowatt demand each month. The metered kW shall be adjusted for power factor as provided hereafter.

Facilities Charge

     The Facilities Charge is a charge for use of Cooperative electric facilities used to serve the Ethanol Plant load up to the Ethanol Plant property. Such charge includes interest, depreciation, operation, maintenance and taxes associated with these facilities.

Distribution Demand Charge

     The Distribution Demand Charge recovers carrying cost of the facilities necessary to serve the load and not directly assignable to the Ethanol Plant. Such charge shall remain the same for a period of five years after commencement of the rate. Adjustments thereafter shall be made based upon an allocation of cost for the non-directly assignable facilities.

 


 

     
Minnesota Valley Cooperative
  Effective Date: ___
Light & Power Association
   
501 South 1 st Street
   
Montevideo, Minnesota 56265
   

SCHEDULE ETHANOL PLANT

INDUSTRIAL SERVICE

(Continued)

Power Supply Demand Charge

     The Power Supply Demand Charge is the actual cost of Basin Electric’s Demand Charge plus transmission losses. This Charge may increase if Basin Electric cost increases to the Cooperative.

Power Factor Adjustment

     Ethanol Plant shall maintain unity power factor as nearly as practicable. Demand charges will be adjusted to correct for an average monthly power factor lower than 95%. Such adjustments will be made by increasing the measured demand 1% for each 1% by which the average power factor is less than 95% lagging or leading.

Minimum Monthly Charge

     The minimum monthly charge under the above rates shall be $8,000.

Special Conditions of Service

     Where it is necessary to extend or reinforce existing facilities in order to provide service under this schedule and additional investment is thereby required, such service will be rendered only after the following conditions are met:

1.   Ethanol Plant will give satisfactory assurance by means of written agreement as to the character, amount, and duration of the business offered.

2.   Ethanol Plant shall guarantee a minimum monthly bill for the service which will be computed on the basis of 1/60 th of the investment, which includes the cost of transformers, meters, and all costs of additions to or alterations of lines and equipment necessary to make the service available.

 


 

     
Minnesota Valley Cooperative
  Effective Date: ___
Light & Power Association
   
501 South 1 st Street
   
Montevideo, Minnesota 56265
   

SCHEDULE ETHANOL PLANT

INDUSTRIAL SERVICE

(Continued)

3.   This minimum bill will be effective for a period of five (5) years from the date on which service commences. After this period the regular monthly minimum charge will be effective.

4.   In no case, however, will the minimum bill under this agreement be less than the previously specified “Minimum Monthly Charge.”

Delivery Point

     The delivery point shall be the metering point. The delivery point shall be the point of attachment of Ethanol Plant’s primary line to the Cooperative’s substation structure. All wiring, pole lines, and other equipment (except metering equipment) on the load side of the delivery point may be owned and maintained by Ethanol Plant or the Cooperative.

Billing Method

  a.   Payment Arrangements. All charges for service shall be paid to the Cooperative at its Montevideo office, through the mail, or by electronic transfer. The monthly billing periods shall be from the first day of the month through the last day of the month. The Customer agrees to prepay the monthly bill based on the estimated demand and energy use. Payment is due 5 days prior to the first day of the month. If payment is not received or postmarked by the Cooperative by the first day of the month, the Customer agrees that the Cooperative may disconnect service to the facility until the payment is made.
 
  b.   Monthly True-up of Charges. An employee of the Cooperative will read the meter(s) on or about the first day of each month. At the end of the billing month, the amount of Monthly Prepayment described above, shall be subtracted from the total amount derived from actual demand and energy values that were read and applied to Rate Schedule Ethanol Plant. This amount will be added to the next month’s prepayment. Both parties will strive to keep True-up values as close to zero as possible by providing accurate demand and energy projections.

 

 

EXECUTION COPY

EXHIBIT 10.14

LOAN AGREEMENT

      THIS LOAN AGREEMENT (this “Agreement”) is dated as of the 16th day of December, 2004, and is by and between GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC , d/b/a GRANITE FALLS ENERGY, LLC, a Minnesota limited liability company (the “Borrower”), and FIRST NATIONAL BANK OF OMAHA (the “Bank” or “Lender”), a national banking association established at Omaha, Nebraska.

     WHEREAS, the Borrower has requested the Bank to lend to the Borrower the sum of up to $34,000,000 for the purpose of partially funding the cost of construction (the “Construction Loan”) for an ethanol plant on the real estate described in Exhibit F (the “Property”) and the subsequent replacement of such Construction Loan with a term loan for the ethanol plant and Property (the “Term Loan”), together with a $3,500,000 revolving line of credit (the “Revolving Loan”) and a standby letter of credit in an amount up to $1,000,000 (“Letter of Credit”); and

     WHEREAS, the Bank is willing to provide such credit facilities to the Borrower upon the terms and conditions herein set forth.

ARTICLE I

DEFINITIONS

     “ Assignment of Design/Build Construction Contract ” means the assignment of the agreement between the Borrower and Fagen, Inc. (the “General Contractor”) for preparation of plans and construction of the Project in accordance with Plans therein described (the “Design/Build Construction Contract”) by which the Borrower assigns, as additional security for repayment of the Obligations, the Borrower’s interest in the Design/Build Construction Contract in a form reasonably acceptable to the Bank.

     “ Assignment of Rents ” means the assignment of rents and leases as to the Property between the Borrower, as assignor, and the Bank, as assignee, as security for payment of the Obligations in a form acceptable to the Bank.

     “ Banking Day ” means a day on which the Bank is open for substantially all of its business.

     “ Borrowing Base ” means the lesser of:

     (a) $3,500,000, less the amount of any Letters of Credit issued and outstanding on the Borrower’s account; or

     (b) The aggregate of (i) 75% of the Borrower’s Inventory of corn, at current value on the date reported, plus (ii) 75% of the Borrower’s Finished Goods-Distiller’s Grains Inventory, at current value on the date reported, plus (iii) 75% of the Borrower’s

 


 

Finished Goods-Ethanol Inventory, valued at the lower of cost or market, plus (iv) 75% of the amount of the Borrower’s current sales Accounts Receivable aged thirty (30) days or less, and (v) 75% of the amount of the Borrower’s current state incentives Accounts Receivable aged less than 120 days, excluding any accounts reasonably deemed ineligible by the Bank.

     “ Capital Leases ” shall have the same meaning in this Agreement as those terms are defined by GAAP.

     “ Closing ” shall mean the date on which the Bank receives this Agreement, executed by the Borrower, together with the Construction Note and the Revolving Note.

     “ Completion Date ” means March 10, 2006.

     “ Construction Loan ” shall mean an amount of up to the lesser of 58% of the total cost of the Project or $34,000,000 loaned to the Borrower under the terms and conditions of this Agreement for the purpose of partially funding the cost of construction of the Project.

     “ Construction Loan Termination Date ” means the earlier of (a) the Completion Date or (b) such earlier date upon which the Bank’s commitment to make a disbursement under the Construction Loan is terminated.

     “ Construction Note ” means the promissory note of the Borrower in the form of Exhibit A evidencing borrowings under the Construction Loan of up to a maximum amount of $34,000,000.

     “ Draw Request ” means forms acceptable to the Bank to be submitted to the Bank by the Borrower when a disbursement is requested under the Construction Note.

     “ EBITDA ” means earnings before interest, taxes, depreciation and amortization, all experienced during the applicable reporting period.

     “ Eurodollar Business Day ” means a Banking Day on which commercial banks are open for international business (including dealings in dollar deposits) in London, England.

     “ Event of Default ” has the meaning provided for in Article VII of this Agreement.

     “ Excess Cash Flow ” means EBITDA less: scheduled payments to the Bank (excluding payments required under Section 6.02(c)); payments to Bank-approved subordinated debt (excluding unscheduled payments on subordinated debt); and less allowable capital expenditures.

     “ Farmer’s Cooperative Elevator Contract ” means that written contract between the Borrower and Farmer’s Cooperative Elevator Co. dated May 14, 2004.

     “ Finished Goods-Ethanol Inventory ” means ethanol that conforms to minimum quality standards as developed by current industry standards, including, but not limited to, ASTM D 4806 specifications for E-Grade denatured ethanol.

2


 

     “ Fixed Charge Coverage Ratio ” means the ratio derived when comparing (i) EBITDA, less capital expenditures, dividends and taxes to (ii) the Borrower’s payments on the principal and interest of the Obligations and Subordinated Debt made during the applicable reporting period.

     “ GAAP ” means generally accepted accounting principles, applied on a basis consistent with the accounting principles applied in the preparation of the annual financial statements of the Borrower referred to in Section 6.01 of this Agreement and the Projections described in Section 5.07 of this Agreement. All accounting terms not otherwise defined in this Agreement have the meaning assigned to them in accordance with GAAP.

     “ General Contractor ” shall mean Fagen, Inc.

     “ Indebtedness ” means, as to the Borrower, all items of indebtedness, Obligation or liability, whether matured or unmatured, liquidated or unliquidated, direct or contingent, joint or several including, but without limitation:

     (a) All indebtedness guaranteed, directly or indirectly, in any manner, or endorsed (other than for collection or deposit in the ordinary course of business) or discounted with recourse;

     (b) All indebtedness in effect guaranteed, directly or indirectly, through agreements, contingent or otherwise (i) to purchase such indebtedness; or (ii) to purchase, sell or lease (as lessee or lessor) property, products, materials or supplies or to purchase or sell services, primarily for the purpose of enabling the debtor to make payment of such Indebtedness or to insure the owner of the Indebtedness against loss;

     (c) All indebtedness secured by (or for which the holder of such Indebtedness has a right, contingent or otherwise, to be secured by) any mortgage, deed of trust, pledge, lien, security interest or other charge or encumbrance upon property owned or acquired subject thereto, whether or not the liabilities secured thereby have been assumed;

     (d) All indebtedness incurred as the lessee of goods or services under leases that, in accordance with GAAP, should not be reflected on the lessee’s balance sheet; and

     (e) The Borrower’s Obligations for payment of the negative termination value of any interest rate swap agreement.

     “ Independent Inspector ” means the firm which will be retained by the Bank, at the Borrower’s cost, to conduct on-site inspections of the work in progress on the Project, and to issue periodic reports to the Bank as to the progress of construction and adherence to the Plans. The Bank’s selection of the Independent Inspector shall be subject to the Borrower’s approval, which approval will not be unreasonably withheld.

     “ Interest Period ” means, initially, the period commencing on the date of the Construction Note, Short Term Operating Note, Swap Note, Variable Rate Loan or the Long Term Revolving Note, as applicable, and ending (i) on the one-month anniversary of note for the Construction

3


 

Note, (ii) on the one-month anniversary of the Note for the Revolving Note, (iii) on the three-month anniversary of the Note for the Swap Note, (iv) on the three-month anniversary for the Variable Rate Note and (v) on the one-month anniversary of the Note for the Long Term Revolving Note, and thereafter each period commencing on the first day immediately following the last day of the immediately preceding Interest Period and ending after the applicable period set forth above thereafter, provided that:

     (a) subject to clauses (b) and (c) below, any Interest Period which would otherwise end on a day which is not a Eurodollar Business Day shall be extended to the next succeeding Eurodollar Business Day unless such Eurodollar Business Day falls in another calendar month, in which case such Interest Period shall end on the immediately preceding Eurodollar Business Day;

     (b) subject to clause (c) below, any Interest Period which begins on the last Eurodollar Business Day of a calendar month (or a day for which there is no numerically corresponding day in the calendar month at the end of such Interest Period) shall end on the last Eurodollar Business Day of a calendar month; and

     (c) no Interest Period shall extend beyond the Loan Termination Date.

     “ Letter of Credit ” has the meaning set forth in the preamble.

     “ LIBOR ” shall mean the London interbank offered rate.

     “ LIBOR Base Rate ” shall mean, with respect to the applicable Interest Period, (a) the LIBOR Index Rate for such Interest Period, if such rate is available, or (b) if the LIBOR Index Rate cannot be determined, the average (rounded upward, if necessary, to the next higher 1/100 of 1%) of the respective rates per annum of interest at which deposits in dollars are offered to the Bank in the London interbank market by two Eurodollar dealers of recognized standing, selected by the Bank in its sole discretion, at such time on the date two Eurodollar Business Days before the first day of such Interest Period as the Bank in its sole discretion elects, for delivery on the first day of the applicable Interest Period for a number of days comparable to the number of days in such Interest Period and in an amount approximately equal to the principal amount of the Obligations.

     “ LIBOR Index Rate ” shall mean, with respect to the applicable Interest Period, the rate per annum (rounded upwards, if necessary, to the next higher 1/100 of 1%) for deposits in U.S. Dollars for a period equal to such Interest Period, which appears on the Bank’s information vendor as of 9:00 a.m. (Omaha time) on the day two Eurodollar Business Days before the first day of such Interest Period. The term “the Bank’s information vendor” means the Bloomberg service or such other vendor chosen by the Bank for the purpose of displaying British the Bankers’ Association Interest Settlement Rates for U.S. Dollar Deposits.

     “ LIBOR Rate ” shall mean the quotient of the (i) LIBOR Base Rate divided by (ii) one minus the applicable LIBOR Reserve Percentage. The LIBOR Rate shall be adjusted automatically on and as of the effective date of any change in the LIBOR Reserve Percentage.

4


 

     “ LIBOR Reserve Percentage ” shall mean for any day that percentage (expressed as a decimal) which is in effect on such day, as prescribed by the Board of Governors of the Federal Reserve System (or any successor), for determining the maximum reserve requirement for a member bank of the Federal Reserve System with respect to “Eurocurrency liabilities” (or in respect of any other category of liabilities which includes deposits by reference to which the interest rate on LIBOR loans is determined or any category of extensions of credit or other assets which include loans by a non-United States office of any bank to United States residents). The LIBOR Rate shall be adjusted automatically on and as of the effective date of any change in the LIBOR Reserve Percentage.

     “ Loan Documents ” means this Agreement and each document referred to in Article IV of this Agreement.

     “ Management Contract ” means the agreement between the Borrower and Glacial Lakes Energy, LLC for management of the property of the Borrower in accordance with the terms thereof.

     “ Marketing Contract ” means that written contract between the Borrower and one or more entities approved by the Bank, which approval will not be unreasonably withheld, by which the latter agrees to provide marketing services to the Borrower for the Borrower’s ethanol products, as well as the written contracts between the Borrower and one or more entities approved by the Bank, which approval will not be unreasonably withheld, by which the latter agrees to provide marketing services as to the Borrower’s distiller’s grains.

     “ Mortgage ” means the agreement between the Borrower and the Bank creating a first lien on the Property and a security interest in all of the personal property located thereon as security for payment of the Obligations.

     “ Net Worth ” means total assets less total liabilities and less the following types of assets: (a) leasehold improvements; (b) receivables (other than those created by sale of goods) to a member and other investments in or amounts due from any member, employee or other person or entity related to or affiliated with the Borrower; (c) goodwill, patents, copyrights, mailing lists, trade names, trademarks, servicing rights, organizational and franchise costs, bond underwriting costs and other like assets properly classified as intangible; and (d) treasury stock or treasury membership units. Net Worth shall not include any debt due to the Borrower not acceptable to the Bank in the exercise of its reasonable discretion.

     “ Note ” or “ Notes ” means any promissory note delivered by the Borrower to the Bank.

     “ Obligations ” means the obligation of the Borrower:

     (a) to pay the principal of and interest on the Notes in accordance with the terms thereof and to satisfy all of its other liabilities to the Bank, whether hereunder or otherwise, whether now existing or hereafter incurred, matured or unmatured, direct or contingent, joint or several, including any extensions, modifications, renewals thereof and substitutions therefor and including, but not limited to, any obligations under Letter of Credit agreements;

5


 

     (b) to repay to the Bank all amounts advanced by the Bank hereunder or otherwise on behalf of the Borrower, including, but without limitation, advances for principal or interest payments to prior secured parties, mortgagees or licensers, or taxes, levies, insurance, rent or repairs to, or maintenance or storage of, any of the real or personal property securing the Borrower’s payment and performance of this Agreement; and

     (c) to reimburse the Bank, on demand, for the Bank’s reasonable and necessary out-of-pocket expenses and costs, including the reasonable fees and expenses of its counsel, in connection with the preparation, administration, amendment, modification, or enforcement of this Agreement and the Loan Documents required hereunder, including, without limitation, any proceeding brought or threatened to enforce payment of any of the Obligations referred to in the foregoing subparagraphs (a) and (b).

     “ Permit ” or “ Permits ” means any license or permit, and all licenses or permits, required under any environmental law or regulation required to construct and operate the facility on the Property after completion of the Project at its operational capacity, including without limitation the following:

     (a) An air emissions permit, which allows, or will allow, the Borrower after the Completion Date to operate the ethanol plant on the Property after construction of the Project at maximum capacity.

     (b) All permits required in connection with the construction and operation of all aboveground storage tanks included in the Plans for the ethanol plant.

     (c) A National Pollution Discharge Elimination System Construction Permit for any storm water that is discharged during construction and after construction of the Project.

     “ Plans ” means the plans and specifications prepared by ICM, Inc. and Fagen Engineering LLC on behalf of the Borrower for the Project and identified to this Agreement by the General Contractor, the Borrower and the Bank.

     “ Project ” means the design and construction of an ethanol plant, together with all necessary and appropriate fixtures, equipment, attachments and accessories, as described in the Plans, to be constructed on the Property.

     “ Revolving Loan ” shall mean an amount of up to $3,500,000 loaned to the Borrower under the terms and conditions of this Agreement to provide Borrower a revolving line of credit.

     “ Revolving Loan Termination Date ” means the earliest to occur of the following: (a) December 15, 2005, (b) the date the Obligations are accelerated pursuant to this Agreement and (c) the date the Bank has received (i) notice in writing from the Borrower of the Borrower’s election to terminate this Agreement and (ii) indefeasible payment in full of the Obligations.

6


 

     “ Revolving Note ” means that promissory note of the Borrower to the Bank evidencing the revolving credit facility described in Section 2.06 of this Agreement and as set forth in the attached Exhibit B, its renewals, modifications and extensions.

     “ Security Agreement ” means the agreement between the Borrower, as debtor, and the Bank, as secured party, creating a first security interest in all the Borrower’s assets, including general intangibles, securing the Obligations.

     “ Subcontractor ” means any person who contracts with the General Contractor or the Borrower to perform any work or supply any of the materials or equipment necessary to complete the Project.

     “ Subordinated Debt ” means Indebtedness of the Borrower to entities other than the Bank that has been subordinated, in form acceptable to the Bank, to the Obligations.

     “ Subsidiary ” means, as to the Borrower, a corporation or other entity of which shares of stock or membership interests, having ordinary voting power (other than stock or membership interests, having such power only by reason of the happening of a contingency) to elect a majority of the board of directors or other managers or governors of such corporation or other entity are at the time owned, or the management of which is otherwise controlled, directly or indirectly through one or more intermediaries, or both, by the Borrower.

     “ SWAP Contract ” or “ SWAP Contracts ” means (a) any and all rate swap transactions, basis swaps, credit derivative transactions, forward rate transactions, commodity swaps, commodity options, forward commodity contracts, equity or equity index swaps or options, bond or bond price or bond index swaps or options or forward bond or forward bond price or forward bond index transactions, interest rate options, forward foreign exchange transactions, cap transactions, floor transactions, collar transactions, currency swap transactions, cross-currency rate swap transactions, currency options, spot contracts or any other similar transactions or any combination of any of the foregoing (including any options to enter into any of the foregoing), whether or not any such transaction is governed by or subject to any master agreement and (b) any and all transactions of any kind, and the related confirmations, which are subject to the terms and conditions of, or governed by, any form of master agreement published by the International Swaps and Derivatives Association, Inc.; provided, however, the term “SWAP Contract” shall not, for the purposes of this Agreement, include commodity hedging or commodity risk management contracts. “Commodity” includes grain, natural gas and other traded commodities.

     “ Term Loan ” shall mean an amount of up to $34,000,000 loaned to the Borrower under the terms and conditions of this Agreement to provide the Borrower funds to pay the Construction Loan in full.

     “ Term Loan Termination Date ” means the earliest to occur of the following: (a) March 10, 2011, (b) the date the Obligations are accelerated pursuant to this Agreement and (c) the date the Bank has received (i) notice in writing from the Borrower of the Borrower’s election to terminate this Agreement and (ii) indefeasible payment in full of the Obligations.

7


 

     “ Term Notes ” means those promissory notes of the Borrower to the Bank which evidences permanent financing to pay the Construction Note as described in Article II of this Agreement, its renewals, modifications and extensions and which shall include the Swap Note, the Variable Note and the Long Term Revolving Note.

     “ USDA CCC Bio-Energy Accounts Receivable ” shall mean cash incentives offered by the United States Department of Agriculture (“USDA”) to the Borrower after the Borrower has commenced operations and provided that the Borrower has complied with other applicable requirements, terms and conditions of the USDA.

     “ Working Capital ” means current assets (including any amount available under the Long Term Revolving Loan at the time of determination), less investments in or other amounts due from any member, employee or any person or entity related to or affiliated with the Borrower and less prepayments, less current liabilities (less any portion of such current liabilities that constitute debt that is expressly subordinated to the Bank in a writing acceptable to the Bank, in the exercise of its reasonable discretion).

ARTICLE II

AMOUNT AND TERMS OF THE LOANS

      Section 2.01. Construction Loan . The Bank agrees, on the terms and subject to the conditions set forth in this Agreement, to make, from time to time during the period beginning on the date of execution of this Agreement and ending on the Construction Loan Termination Date, disbursements to the Borrower in an aggregate principal amount not to exceed the lesser of $34,000,000 or 58% of the total cost of the Project for the sole purpose of paying approved construction costs of the Project. If, prior to the Completion Date, there is paid to the Bank a third-party payment (a grant payment, for example) that is applied to the Construction Loan, the Bank may, in its sole discretion, reduce the amount to be advanced to a lesser sum, which the Bank reasonably determines is necessary to complete the Project. Approved construction costs are costs actually incurred in connection with the construction of the Project. Such approved construction costs shall include but shall not be limited to costs of permits, licenses, labor, supplies, materials, services, equipment, insurance premiums, real estate taxes and interest on disbursements and operating costs of the ethanol plant. Construction costs shall not include the cost associated with payment of lost profits connected with termination under Section 14.1.3 of the General Conditions of Contract to the Design/Build Construction Contract.

      Section 2.02. Construction Note . The Obligation of the Borrower to repay the Construction Loan shall be evidenced by a promissory note (the “Construction Note”) in the form attached hereto as Exhibit A.

      Section 2.03. Interest on Construction Note . Interest shall be payable at the rate provided therein only on such portions of the Construction Loan proceeds as actually have been disbursed pursuant to this Agreement. Interest on the Construction Note shall accrue at the one (1) month LIBOR Rate plus 350 basis points prior to acceleration or maturity, and 650 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise.

8


 

      Section 2.04. Repayment of Construction Note . Interest only shall be payable quarterly on the Construction Note. All outstanding principal and accrued but unpaid interest shall be payable on the Construction Loan Termination Date.

      Section 2.05. Revolving Loan . The Bank agrees, on the terms and subject to the conditions set forth in this Agreement, to lend up to $3,500,000 to the Borrower. At the Borrower’s request, on the Borrower’s account, pursuant to the Bank’s customary policies and with its standardized documents, the Bank will issue its letters of credit up to the same amount so long as the combined amount of letters of credit and Revolving Note does not exceed the amount available under the Revolving Loan. The Bank will credit proceeds of the Revolving Loan to the Borrower’s deposit account with the Bank, bearing number 110118183. Subject to the terms hereof, the Bank will lend the Borrower, from time to time until the Revolving Loan Termination Date such sums in integral multiples of $10,000 as the Borrower may request by reasonable same-day notice to the Bank, received by the Bank not later than 11:00 a.m. of such day, but which shall not exceed in the aggregate principal amount at any one time outstanding $3,500,000, less the aggregate amounts of any issued and outstanding letters of credit issued by the Bank at the request of and on the account of the Borrower (the “Loan Commitment”). The Borrower may borrow, repay without penalty or premium and reborrow hereunder, from the date of this Agreement until the Revolving Loan Termination Date, either the full amount of the Loan Commitment or any lesser sum which is $10,000 or an integral multiple thereof. It is the intention of the parties that the outstanding balance of the Revolving Loan, at all such times after July 10, 2006, shall not exceed the Borrowing Base, as defined herein, and if at any time said balance exceeds the Borrowing Base, the Borrower shall forthwith pay the Bank sufficient funds to reduce the balance of the Revolving Loan until it is in compliance with this requirement.

      Section 2.06. Revolving Note . The Revolving Loan shall be evidenced by a Promissory Note (the “Revolving Note”) having stated maturity on the Revolving Loan Termination Date, in the form attached hereto as Exhibit B.

      Section 2.07. Interest on Revolving Note . Interest on the Revolving Note shall accrue at the one (1) month LIBOR Rate plus 350 basis points, prior to acceleration or maturity, and 650 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise.

      Section 2.08. Incentive Pricing . The interest rate applicable to the Variable Rate Loan and the Long Term Revolving Loan and the Revolving Loan shall, upon the request of the Borrower, be subject to periodic temporary adjustments commencing six months subsequent to the Completion Date, based on the business results of the Borrower. If, at any time during the preceding three (3) month period ending on the date six (6) months after the date of the Completion Date and each three (3) month period thereafter, as applicable, the ratio of Borrower’s Indebtedness to its Net Worth has been (a) greater than or equal to 1.25 to 1.0, then the interest rate shall remain or shall be increased to 350 basis points over the LIBOR Rate, (b) less than 1.25 to 1.0 but greater than or equal to 1.0 to 1.0, then the interest rate shall change to 325 basis points over the LIBOR Rate, (c) less than 1.0 to 1.0 but greater than or equal to .75 to 1.0, then the interest rate shall change to 300 basis points over the LIBOR Rate, and/or (d) less than .75 to 1.0, then the interest rate shall change to 275 basis points over the LIBOR Rate.

9


 

     Any such adjustment under this Section shall be applied and effective for the following Interest Rate Period.

      Section 2.09. Term Loans and Term Notes . So long as Bank is lender, all of the terms, conditions and covenants of this Agreement have been complied with and there has not been at any time an Event of Default, on the Completion Date, the Construction Loan shall be paid in full by the following Swap Loan, Variable Rate Loan and Long Term Revolving Loan (collectively, the “Term Loans”) and execution of the following Swap Note, Variable Rate Note and Long Term Revolving Note (collectively, the “Term Notes”):

     (a) Swap Loan . A loan in the amount of $17,000,000 (the “Swap Loan”) evidenced by the execution and delivery of a promissory note dated March 10, 2006 and subject to the terms and conditions of this Agreement, in the principal amount of $17,000,000 and having a maturity date of March 10, 2011 (the “Swap Note”) in the form attached hereto as Exhibit C;

     (b) Variable Rate Loan . A loan in the amount of $12,000,000 (the “Variable Rate Loan”) evidenced by the execution and delivery of a promissory note dated March 10, 2006 and subject to the terms and conditions of this Agreement, in the principal amount of $12,000,000 and having a maturity date of March 10, 2011 (the “Variable Rate Note”) in the form attached hereto as Exhibit D; and

     (c) Long Term Revolving Loan . A loan in the amount of $5,000,000 (the “Long Term Revolving Loan”) evidenced by the execution and delivery of a promissory note dated March 10, 2006 and subject to the terms and conditions of this Agreement, in the principal amount of $5,000,000 and having a maturity date of March 10, 2011 (the “Long Term Revolving Note”) in the form attached hereto as Exhibit E.

      Section 2.10. Interest on Term Notes . Interest on the Term Notes shall accrue at the following rates:

     (a) Swap Note . At all times for the Swap Note, interest shall accrue at a variable rate equal to the three-month LIBOR Rate plus 300 basis points prior to acceleration or maturity, and 600 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise.

     (b) Variable Rate Note . At all times for the Variable Rate Note, interest shall accrue at a variable rate equal to the three-month LIBOR Rate plus 350 basis points prior to acceleration or maturity, and 650 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise.

     (c) Long Term Revolving Note . At all times for the Long Term Revolving Note, interest shall accrue at a variable rate equal to the one-month LIBOR Rate plus 350 basis points prior to acceleration or maturity, and 650 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise.

10


 

      Section 2.11. Repayment of Term Notes . The Term Notes shall be repaid as follows:

     (a) On the 10 th day of every third month, commencing June 10 th , 2006, the Borrower shall pay to the Bank the scheduled principal payment shown in Schedule I, attached hereto and by this reference made a part hereof, plus accrued interest on the Swap Note.

     (b) On the 10 th day of every third month, commencing June 10 th , 2006, the Borrower shall pay the sum of $600,053.89 to the Bank, which shall be allocated as follows: (i) first to accrued interest on the Long Term Revolving Note, (ii) next to accrued interest on the Variable Rate Note, and (iii) next to principal on the Variable Rate Note.

     (c) After the Variable Rate Note has been fully paid, such quarterly payments shall be allocated first to accrued interest on the Long Term Revolving Note, and thence to principal on such Note, thereby reducing available loan capacity by such amount.

     (d) Notwithstanding the foregoing, all unpaid principal and accrued interest for all Term Notes shall be due and payable on the Term Loan Termination Date, if not sooner paid.

      Section 2.12. Letter of Credit . Bank will issue its Letter of Credit at Borrower’s request, on Borrower’s account, pursuant to the Bank’s customary policies and with its standardized documents, in amounts outstanding at no time exceeding $1,000,000 in the aggregate.

      Section 2.13. Payments and Prepayments for All Obligations . All principal, interest and fees due under this Agreement, the Notes and the Loan Documents shall be paid in immediately available funds as contracted in this Agreement and no later than the payment due date set forth in the periodic statements mailed to the Borrower by the Bank. Should a payment come due on a day other than a Banking Day, the payment shall be made no later than the next the Banking Day and interest shall continue to accrue during the extended period.

     On the occasion of any prepayment of all or substantially all of the outstanding Obligations by the Borrower, and the direct or indirect source of funds to pay such Obligations was one or more loans from a financial institution, the Borrower will pay to the Bank a prepayment fee calculated as follows: If the prepayment occurs during the construction of the Project or within the first three years of the Term Loan, a fee of 2% if during the construction period or within the first year of the Term Loan and 1% if within the second year or third year shall be paid to the Bank.

     The Borrower also agrees to pay, at the time of any such prepayment of the Construction Note or Term Note, any additional amounts as may be provided in the Notes evidencing the Obligations for compensation to the Bank for prepayment of such Notes evidencing fixed interest rates.

11


 

      Section 2.14. Fees .

     (a) At or before the Closing, the Borrower shall pay to the Bank a due diligence and negotiation fee in the sum of $50,000 at or before Closing. At the Closing, the Borrower shall pay to the Bank a commitment fee of $255,000. At the Completion Date, and on each annual anniversary of the Completion Date for five years subsequent to the Completion Date, the Borrower shall pay to the Bank an annual servicing fee of $30,000.

     (b) The Borrower agrees to pay the Bank an unused commitment fee equal to 37.5 basis points of the average unused portion of the Long Term Revolving Note and the Revolving Note, calculated and payable on a quarterly basis in arrears; provided, however, the unused commitment fee on the Revolving Note shall not apply and shall be payable by the Borrower only after the earlier of (i) such time as the Borrower has requested, and the Bank has deposited, the initial advance of the Revolving Loan into the Borrower’s deposit account with the Bank or (ii) the Completion Date.

     (c) The Borrower shall pay the Bank fees for issuance of letters of credit according to the Bank’s customary fee schedule. The Borrower shall pay all costs associated with the Closing of the Loan, including, but not limited to, title, survey, environmental and appraisal reports, costs of disbursement agent, independent construction inspector, mortgage fees and taxes and the Bank’s legal fees.

      Section 2.15. Appraisal . If the Bank is required by any government entity with regulatory authority over the Bank to obtain a real estate appraisal, the Bank will obtain, at the Borrower’s expense, an appraisal of the Project and the Property providing values obtained by use of the cost approach, the income approach and the replacement cost approach. If such appraisal shows that the outstanding Construction Loan amount at that time exceeds the value of the Project and the Property as determined by the appraisal, using the replacement cost approach, then the Borrower shall, within 30 days of notice by the Bank and without penalty or premium, pay the difference between the outstanding Construction Loan amount and the appraised value amount of the Project and the Property as determined by such appraisal, and no further advances shall be made on the Construction Loan thereafter until such time as the appraised value of the Project and the Property exceeds the Construction Loan amount.

ARTICLE III

DISBURSEMENT PROCEDURES

      Section 3.01. Submission of Draw Requests . Whenever the Borrower desires a disbursement under the Construction Loan, which at all times shall be pursuant to disbursement agreement, which shall be entered into by the Parties in a mutually agreeable form and with a mutually agreeable disbursing agent, and shall be no more often than three times a month, unless the Bank agrees otherwise, the Borrower shall submit to the Bank a Draw Request, duly executed on behalf of the Borrower, setting forth the information requested therein. Each Draw Request shall be delivered to the Bank at least five days before the date the disbursement is desired.

12


 

      Section 3.02. Amount of Draw Request . Each Draw Request shall be limited to amounts equal to (a) the total of costs actually incurred and paid or owing by the Borrower to the date of such Draw Request for work performed or materials incorporated in the Project as described in the Plans, plus (b) the cost of materials and equipment not incorporated in the Project, but delivered to and suitably stored at the Project site, plus (c) prepayments for equipment when prepayment is required by the manufacturer or supplier; less (d) prior disbursements for such costs and from the Construction Loan or the Borrower’s Working Capital for such costs. Notwithstanding anything herein to the contrary, no disbursements for materials stored at the Project site will be made by the Bank unless the Borrower shall advise the Bank of its intention to store materials prior to their delivery, and provide suitable security for such storage.

      Section 3.03. Other Documents . At the time of submission of each Draw Request, the Borrower shall submit or cause to be submitted to the Bank the following:

     (a) A written general lien waiver from the General Contractor for work done and materials supplied by it which were paid for by the Draw Request.

     (b) A written lien waiver from the General Contractor and each Subcontractor for work done and materials supplied by it which were paid for pursuant to the next preceding Draw Request with copies of all invoices supporting the Draw Request.

     (c) A document from the Borrower and the General Contractor, and, if applicable, the Independent Inspector, requesting and/or approving payment of the relevant Draw Request.

     (d) Such other supporting evidence as may be reasonably requested by the Bank to substantiate all payments which are to be made out of the relevant Draw Request and/or to substantiate all payments then made with respect to the Project.

      Section 3.04. Cost Overruns . The Borrower agrees that all cost overruns on the Project shall be paid solely by the Borrower and that the Borrower shall deliver additional funds to the Bank in accordance with Section 3.06 of this Agreement to pay any cash required to fund cost overruns on the Project.

      Section 3.05. Making Disbursements . Provided that on the date a Draw Request is received by the Bank (a) the Borrower has performed all of its agreements and complied with all requirements of this Agreement to be performed or complied with including, but not limited to, satisfaction of all applicable conditions precedent contained in Article IV of this Agreement, and (b) if required by the Bank, the Bank has received a current report from the Independent Inspector documenting material compliance with the Plans for those portions of the Project indicated as completed in the Draw Request and otherwise confirming the acceptability of the Project work represented by the Draw Request, the Bank shall pay to the Borrower the amount of the requested disbursement. Each disbursement disbursed to the Title Company as Disbursing Agent under the Construction Loan shall bear interest at the rate provided in the Construction Note evidencing the disbursement from the date such disbursement is so disbursed to the Borrower or deposited into the Borrower’s account.

13


 

      Section 3.06. Deposit of Funds by Borrower . If the Independent Inspector shall at any time in good faith determine that the undisbursed amount of the Construction Loan is less than the amount required to pay costs and expenses of any kind which reasonably may be anticipated in connection with the completion of the Project after application of all funds received from the Borrower’s equity and shall thereupon send written notice thereof to the Borrower specifying the amount required to be deposited by the Borrower with the Bank to provide sufficient funds to complete the Project, the Borrower agrees that it will, within 30 calendar days of receipt of any such notice, deposit with the Bank the amount of funds specified in the Bank’s notice. The Borrower agrees that any such funds deposited with the Bank may be disbursed before any further disbursement of Construction Loan proceeds from the Bank to pay any and all costs and expenses of any kind in connection with completion of the Project.

      Section 3.07. Disbursements Without Receipt of Draw Request . Notwithstanding anything herein to the contrary, the Bank shall have the irrevocable right at any time and from time to time to apply funds which it agrees to disburse hereunder to pay interest on the Construction Note as and when such interest becomes due, and to pay any and all of the expenses of the Bank related to the Project and the Construction Loan, all without receipt of a Draw Request.

      Section 3.08. Miscellaneous Procedures . The Bank may establish additional procedures regarding disbursements and Draw Requests as are reasonable to assure the proceeds of the Construction Loan are paid only to those persons and entities entitled to the same, and that the liens securing the Obligations are in all cases first and paramount liens on the Property.

      Section 3.09. Appointment of Independent Inspector . No Draw Request shall be honored after commencement of construction unless and until the Borrower has consented to the appointment of an Independent Inspector.

      Section 3.10. Limitation on Advances . Notwithstanding any other provision of this section, the Bank is not required to advance any sum under the Construction Loan until the Bank has obtained participation agreements with other Lenders satisfactory to the Bank.

ARTICLE III

CONDITIONS OF LENDING

      Section 4.01. Conditions Precedent to All Disbursements . The obligation of the Bank to make each disbursement under any Loans (including the initial disbursement) shall be subject to the further conditions precedent that on the date of such disbursement:

     (a) The Borrower shall have paid costs of the Project in an amount equal to its total equity and all subordinated debt which exists on the date of this Agreement.

     (b) The representations and warranties contained in Article V of this Agreement are correct on and as of the date of such disbursement as though made on and as of such date, except to the extent that such representations and warranties relate solely to an earlier date and except to the extent of changes permitted under the terms of this Agreement.

14


 

     (c) No event has occurred and is continuing, or would result from such disbursement, which constitutes an Event of Default.

     (d) No determination shall have been made by the Bank that the undisbursed amount of the Construction Loan is less than the amount required to pay all costs and expenses of any kind which reasonably may be anticipated in connection with the completion of the Project; or, if such a determination has been made and notice thereof sent to the Borrower in accordance with this Agreement, the Borrower shall have deposited the necessary funds with the Bank in accordance with Section 3.06 of this Agreement.

     (e) The disbursement requirements of Article III of this Agreement have been satisfied.

     (f) If required by the Bank, the Bank shall be furnished with a statement from the Borrower and the General Contractor, in form and substance satisfactory to the Bank, in the exercise of its reasonable discretion, setting forth the names, addresses and amounts due or to become due, as well as the amounts previously paid, to every Subcontractor.

     (g) No Permit necessary for the construction of the Project shall have been revoked or the issuance thereof subjected to challenge before any court or other governmental authority having or asserting jurisdiction as to the Project.

     (h) The parties intend that the Construction Loan is available to fund the lesser of 58% of the total cost of the Project, including all other approved expenses as set forth in the final version of the Sources and Uses of Funds document furnished to the Bank by the Borrower prior to the Closing, or $34,000,000. No advances or disbursements under the Construction Loan shall exceed such levels, unless the Bank consents in writing to the same.

     (i) The Bank shall have entered into agreements with at least two (2) other entities whereby such other entities have agreed to participate in the Construction Loan and Term Loan under the terms and conditions of this Agreement.

     (j) The Borrower shall have entered into and delivered to the Bank the Swap Contract.

      Section 4.02. Conditions Precedent to Initial Disbursement . The obligation of the Bank to make its initial disbursement under the Construction Loan is subject to the condition precedent that the Borrower shall be in compliance with the conditions set forth in Section 4.01 of this Agreement and to the further condition precedent that the Bank shall have received on or before the Closing all of the following, each dated (unless otherwise indicated) such day, in form and substance satisfactory to the Bank:

     (a) The Construction Note, duly executed on behalf of the Borrower.

     (b) The Mortgage duly executed on behalf of the Borrower.

15


 

     (c) The Security Agreement duly executed by the Borrower, together with (i) acknowledgment copies of the Financing Statements (UCC-1) duly filed under the Uniform Commercial Code of all jurisdictions necessary or, in the opinion of the Bank, desirable to perfect the security interest created by the Security Agreement; and (ii) certified copies of Requests for Copies or Information (Form UCC-11) identifying all of the financing statements on file with respect to the Borrower in all jurisdictions referred to under (i), including the Financing Statement filed by the Bank against the Borrower, indicating that no party claims an interest in any of the Collateral.

     (d) Certified (as of the date of this Agreement) copies of all corporate action taken by the Borrower, including resolutions of its Board of Governors, authorizing the execution, delivery and performance of the Loan Document to which it is a party and each other document to be delivered pursuant to this Agreement.

     (e) A certificate (dated as of the date of this Agreement) of the Secretary of the Borrower certifying the names and true signatures of the officers of the Borrower authorized to sign the Loan Documents to which it is a party and the other documents to be delivered by the Borrower under this Agreement and performance with their terms.

     (f) A favorable opinion of counsel for the Borrower, in substantially the form of Exhibit G, addressed to the Bank and containing customary qualifications, opining that (i) the Borrower is duly organized and in good standing in the state of Minnesota; (ii) the Borrower is qualified in each state in which it does business and is legally required to be qualified; (iii) the Borrower has the requisite power to execute and deliver the Loan Documents to which it is a party and to borrow money and perform in accordance with the terms of such Loan Documents; (iv) all actions and consents by the Borrower necessary to the validity of the Loan Documents to which it is a party have been obtained; (v) the Loan Documents to which it is a party have been duly signed and are the valid and binding Obligation of the Borrower and enforceable in accordance with their terms; and (vi) the Loan Documents to which it is a party and the transactions contemplated thereunder do not conflict with any provision of the articles of organization of the Borrower or its operating agreement, or any agreement binding upon the Borrower or its properties.

     (g) The Assignment of Rents, duly executed on behalf of the Borrower.

     (h) A financing statement or statements sufficient when filed to perfect the security interests granted under the Mortgage, the Assignment of Rents, the Security Agreement, and the Assignment of the Design/Build Construction Contract, to the extent such security interests are capable of being perfected by filing.

     (i) A copy of the Plans, certified by the General Contractor and the Borrower.

     (j) The Assignment of the Construction Contract, duly executed by the Borrower and consented to by the General Contractor, and a copy of the Construction Contract, together with the general conditions of the contract referred to herein.

16


 

     (k) The Assignment of the Ethanol Marketing Contract, duly executed by the Borrower and consented to by the ethanol marketer, and a copy of the Ethanol Marketing Contract, together with the general conditions of the contract referred to herein.

     (l) The Assignment of the DDGS Marketing Contract, duly executed by the Borrower and consented to by the DDGS marketer, and a copy of the DDGS Marketing Contract, together with the general conditions of the contract referred to herein.

     (m) Execution of the Control Agreement with respect to the Borrower’s commodity derivative transaction account with FCStone Trading, LLC, duly executed by the Borrower and consented to by the other parties to the account, and a copy of the applicable agreement, together with the general conditions of the contract referred to herein.

     (n) Execution of the Control Agreement with respect to the Borrower’s commodity contracts account with FCStone, LLC, duly executed by the Borrower and consented to by the other parties to the account, and a copy of the applicable agreement, together with the general conditions of the contract referred to herein.

     (o) The Assignment of the Consulting Agreement with Glacial Lakes Energy, LLC, duly executed by the Borrower and consented to by Glacial Lakes Energy, LLC, and a copy of the Consulting Agreement, together with the general conditions of the contract referred to herein.

     (p) The Assignment of the Borrower’s Farmer’s Cooperative Elevator Contract, duly executed by the Borrower and consented to by the authorized representative of such cooperative, and a copy of the Farmer’s Cooperative Elevator Contract, together with the general conditions of the contract referred to herein.

     (q) The Assignment of the Borrower’s Rail Infrastructure Agreement, duly executed by the Borrower and consented to by the other parties to the Agreement, and a copy of the Rail Infrastructure Agreement, together with the general conditions of the contract referred to herein.

     (r) The Assignment of the Borrower’s Management Contract, duly executed by the Borrower and consented to by the other parties to the Management Contract, and a copy of the Management Contract, together with the general conditions of the contract referred to herein.

     (s) The Assignment of the Glacial Lakes Energy LLC Management Contract, duly executed by Glacial Lakes Energy LLC and consented to by the other parties to the Management Contract, and a copy of the Management Contract, together with the general conditions of the contract referred to herein.

     (t) The Assignment of the Borrower’s Job Opportunity Building Zone Business Subsidy Agreement, duly executed by Borrower and consented to by the other parties to the Agreement, and a copy of the Job Opportunity Building Zone Business

17


 

Subsidy Agreement, together with the general conditions of the contract referred to herein.

     (u) A total project cost statement on the Project duly executed by the Borrower, setting forth the anticipated total cost of the Project’s completion, and a construction cost statement duly executed by the General Contractor, setting forth its anticipated construction costs of the Project.

     (v) An ALTA (American Land Title Association) Survey of the Property, prepared at the Borrower’s expense, currently certified by a licensed, registered surveyor and incorporating the legal description of the Property, showing the location of all points and lines referred to in the legal description, the location of any existing improvements, the proposed location of the Project (including parking) as being within the exterior boundaries of the Property and in compliance with all applicable building set-back requirements, and the location of all utilities and the location of all easements and encroachments onto or from the Property that are visible on the Property, known to the surveyor preparing the survey or of record, identifying easements of record by recording data and currently certified by the surveyor that there are no such easements or encroachments upon the Property except as shown on the survey.

     (w) An as-built appraisal based upon the Plans to be performed by Natwick Associates Appraisal Services which shows the as-completed value of the Property and Project addressed to and otherwise acceptable to the Bank.

     (x) A title binder, issued by Ag Star Financial Services, ACA (the “Title Company”), at the Borrower’s expense, constituting a commitment by the Title Company to issue a mortgagee’s title policy in favor of the Bank under the Mortgage, that will be free from all standard exceptions, including mechanics’ liens and all other exceptions not previously approved by the Bank and that will insure the Mortgage to be a valid first lien on the Property, and with the ALTA endorsements as set forth as Exhibit I.

     (y) A soil report on the Property certified by a registered engineer including structural design recommendations in form and substance satisfactory to the Bank. Such report shall include soil borings and geo-technical analyses.

     (z) A Phase I Environmental Report of the Property, as well as any subsequent limited environmental site assessments issued prior to the Closing, all in form and content satisfactory to the Bank.

     (aa) Copies of all Construction Permits from the applicable regulatory agencies from whom such permit or license is required.

     (bb) Copies of documents from the appropriate state, federal, city or county authority having jurisdiction over the Property and the Project that provide to the reasonable satisfaction of the Bank that the Project when constructed in accordance with the Plans will comply in all material respects with all applicable ordinances, zoning, subdivision, platting, environmental and land use requirements, without special variance or exception, and such other evidence as the Bank shall reasonably request to establish

18


 

that the Project and the contemplated use thereof are permitted by and comply in all material respects with all applicable use or other restrictions and requirements in prior conveyances, zoning ordinances, environmental laws and regulations, watershed district regulations and all other applicable laws or regulations and governmental authorities having jurisdiction over the Project. The Borrower is not required to obtain advance confirmation from any governmental body that the Project will comply with such ordinances, regulations and requirements.

     (cc) Copies of the policy of property/casualty insurance and comprehensive general liability insurance and a certificate of the workers’ compensation insurance required under Article VI of this Agreement, with all such insurance in full force and effect and approved by the Bank, in the exercise of its reasonable discretion, and naming the Bank as a mortgage and additional named insured, together with appropriate flood insurance, if the Property is in a flood hazard area. Notwithstanding the foregoing, the Borrower is not required to obtain workers’ compensation insurance until required by Minnesota law.

     (dd) A recently certified copy of the Borrower’s operating agreement, and any amendments, if applicable.

     (ee) A recently certified copy of the Borrower’s Articles of Organization and any amendments, if applicable.

     (ff) A certificate of good standing for the Borrower from the office of the Minnesota Secretary of State.

     (gg) By the Closing, proof of injection of equity capital into the Borrower of no less than $24,000,000, including Subordinated Debt.

     (hh) A copy of any existing contracts for the Borrower’s natural gas, electricity and water service and assignments thereof in favor of the Bank in form satisfactory to the Bank.

      Section 4.03. Conditions Precedent to Final Disbursements on Construction Loan . The obligation of the Bank to make the final disbursement on the Construction Loan shall be subject to the condition precedent that the Borrower shall be in compliance with all conditions set forth in Sections 4.01 and 4.02 of this Agreement and, further, that the following conditions shall have been satisfied on or prior to the Completion Date:

     (a) The Project has been completed in material compliance with the Plans and the Bank shall have received a certificate of completion from the General Contractor, certifying that (i) work on the Project has been completed in material compliance with the Plans and all labor, services, materials and supplies used in such work have been paid for and (ii) the completed Project conforms in all material respects with all applicable zoning, land use planning, building and environmental laws and regulations of the governmental authorities having jurisdiction over the Project.

19


 

     (b) The Bank has received satisfactory evidence that all work requiring inspection by municipal or other governmental authorities having jurisdiction has been duly inspected and approved by such authorities and by the rating or inspection organization, bureau, corporation or office having jurisdiction.

     (c) The Bank or the Title Company, on the Bank’s behalf, shall have received a lien waiver from each Subcontractor and the General Contractor for all work done and for all materials furnished by it for the Project.

     (d) The Bank has received an itemized list from the Borrower of all equipment and fixtures, which are at that time subject to the Bank’s security interest.

      Section 4.04. Conditions Precedent to All Revolving Loans . The obligation of the Bank to make each Revolving Loan (including the initial Revolving Loan) shall be in addition to the conditions set forth in Section 4.01 and 4.02, subject to the further conditions precedent on the date of such Revolving Loan:

     (a) The following statements shall be true and the Bank shall have received a certificate signed by a duly authorized officer of the Borrower dated the date of such Revolving Loan, stating that:

     (i) The representations and warranties contained in Article V of this Agreement, and all provisions of the Security Agreement, are correct on and as of the date of such Loan as though made on and as of such date; and

     (ii) No Default or Event of Default has occurred and is continuing, or would result from such Loan.

     (b) The Bank shall have received such other approvals, opinions or documents as the Bank may reasonably request.

      Section 4.05. No Waiver . The making of any disbursement under any Loan prior to fulfillment of any condition thereto shall not be construed as a waiver of such condition, and the Bank reserves the right to require fulfillment of any and all such conditions prior to making any subsequent disbursements under the Construction Loan or any other Loan.

ARTICLE IV

REPRESENTATIONS AND WARRANTIES

     To induce the Bank to enter into this Agreement, the Borrower makes the following representations and warranties and agrees that each Draw Request constitutes a reaffirmation of these representations and warranties:

      Section 5.01. Existence and Power . The Borrower is a limited liability company duly formed and in good standing under the laws of the State of Minnesota. The Borrower has accomplished all necessary actions required by a corporate entity under applicable law to own

20


 

the Property and construct the Project, and to execute and deliver, and to perform all of its Obligations under, the Loan Documents to which it is a party.

      Section 5.02. Authorization of Borrowing; No Conflict as to Law or Other Agreements . The execution, delivery and performance by the Borrower of the Loan Documents and the borrowings from time to time hereunder have been duly authorized by all necessary actions of the Borrower and do not and will not (a) require any material consent or approval, or authorization, by any governmental department, commission, board, bureau, agency or instrumentality, domestic or foreign, other than those obtained and in full force and effect, (b) violate, in any material respect, any provision of any law, rule or regulation or of any order, writ, injunction or decree presently in effect having applicability to the Borrower, or violate any provision of the Articles of Organization or operating agreement of the Borrower, (c) result in a breach of or constitute a default beyond any applicable cure period under any indenture or loan or credit agreement or any other agreement, lease or instrument to which the Borrower is a party or by which it or its properties may be bound or affected, or (d) result in, or require, the creation or imposition of any mortgage, deed of trust, pledge, lien, security interest or other charge or encumbrance of any nature to or with any other creditor of the Borrower, in the aggregate exceeding $50,000 annually, upon or with respect to any of the properties now owned or hereafter acquired by the Borrower.

      Section 5.03. Legal Agreements . The Loan Documents to which it is a party constitute the legal, valid and binding Obligations of the Borrower enforceable against the Borrower in accordance with their respective terms, and as to the Loan Documents to which the Borrower is not a party, the Borrower believes such documents constitute the legal, valid and binding obligations of the parties thereto, enforceable against such parties in accordance with their respective terms, except (a) as limited by applicable bankruptcy, insolvency, reorganization, moratorium and other laws of general application affecting enforcement of creditors’ rights generally and (b) as limited by laws relating to the availability of specific performance, injunctive relief or other equitable remedies.

      Section 5.04. License and Permits . The Borrower has all necessary Permits required for construction and operation of the Project except those which are not required for the current stage of construction of the Project, or which cannot be obtained until completion of the Project.

      Section 5.05. Construction of Project . The Project will be constructed in material compliance with the Plans and will not encroach upon or overhang any easement or right-of-way on land not constituting part of the Property. The Project, both during construction and on the Completion Date, and the contemplated use thereof will not violate in any material respect any applicable zoning or use statute, ordinance, building code, rule or regulation, or any covenant or agreement of record. The Borrower agrees that it will furnish from time to time such satisfactory evidence with respect thereto as may be required by the Bank.

      Section 5.06. Ownership and Liens . The Borrower and each Subsidiary have good and marketable fee simple title to, or valid leasehold interests in, all of their properties and assets, real and personal, including the properties and assets and leasehold interest reflected in the financial statements referred to in Section 5.07 (other than any properties or assets disposed of in the ordinary course of business), and none of the properties and assets owned by the Borrower or

21


 

any Subsidiary and none of their leasehold interests are subject to any Lien, except such as may be permitted under this Agreement.

      Section 5.07. Financial Condition . The Borrower has furnished to the Bank its compiled cash flow projection of the Borrower prepared in accordance with GAAP which projections were dated July 15, 2003 together with the supplementary material attached hereto as Exhibit H (the “Projections”). The Projections fairly present the projected financial condition of the Borrower on the dates thereof, and were prepared in GAAP format and on the basis of assumptions deemed reasonable by the Borrower. There has been no material adverse change in the operations, properties or condition (financial or otherwise) of the Borrower since the date of the Projections and no additional borrowings have been made by the Borrower other than the borrowing contemplated hereby or approved by the Bank. No certificate or statement furnished to the Bank by or on behalf of the Borrower in connection with the transactions contemplated hereby contains any untrue statement of a material fact or omits to state a material fact necessary in order to make the statements contained therein or herein not misleading. To the best of the knowledge of the Borrower, there is no fact which materially adversely affects or in the future (so far as the Borrower now foresees) may materially adversely affect the operation or prospects or condition (financial or other) of the Borrower or its properties or assets which has not been set forth herein or in a certificate or statement furnished to the Bank by the Borrower.

      Section 5.08. Litigation . There are no actions, suits or proceedings pending or, to the knowledge of the Borrower, threatened against or affecting the Borrower or the properties of the Borrower before any court or governmental department, commission, board, bureau, agency or instrumentality, domestic or foreign, which, if determined adversely to the Borrower, would have a material adverse effect on the financial condition, properties, or operations of the Borrower.

      Section 5.09. Taxes . The Borrower has filed all federal, state and local tax returns which to the knowledge of the Borrower are required to be filed, and the Borrower has paid or caused to be paid to the respective taxing authorities all taxes as shown on said returns or on any assessment received by it to the extent such taxes have become due except those which the Borrower is contesting in good faith and with respect to which adequate reserves have been set aside.

      Section 5.10. No Default . There is no event, which is, or with notice or the lapse of time would be, an Event of Default under this Agreement.

      Section 5.11. ERISA . The Borrower is in compliance in all material respects with the Employee Retirement Income Security Act of 1974, as amended, and has received no notice to the contrary from the Internal Revenue Service, the Department of Labor, the Pension Benefit Guaranty Corporation or any other governmental entity or notice of any claims or pending claims under ERISA.

      Section 5.12. Environmental Matters . Except as set forth in the Phase I Environmental Report referenced in Section 4.01 of this Agreement (a) the Borrower is in compliance in all material respects with all health and environmental laws applicable to the Borrower and its operations and knows of no conditions or circumstances that could materially interfere with such compliance in the future; (b) except for Permits that cannot be obtained until completion of the

22


 

Project, the Borrower has obtained all Permits, and approvals required by law for the operation of its business; and (c) the Borrower has not identified any “recognized environmental conditions,” as that term is defined by the American Society for Testing and Materials in its standards for environmental due diligence which could subject the Borrower to enforcement action if brought to the attention of appropriate governmental authorities.

      Section 5.13. Necessary Utilities, Etc . As required by the completion of the Project, the Borrower will make suitable arrangements so that the Project has all necessary electrical, gas, water and sewer facilities in place for the proper construction and operation of its ethanol plant. The Borrower has made adequate provision for all storage facilities, equipment and product supplies, including corn, as specified by its engineers for the maximum output and operation of the plant.

ARTICLE V

ADDITIONAL COVENANTS OF BORROWER

      Section 6.01. Financial Information and Reporting . Except as otherwise stated in this Agreement, all financial information provided to the Bank shall be compiled using GAAP consistently applied. During the time period that any amounts are outstanding under the Construction Note or this Agreement or the Loan Documents to which it is a party, unless the Bank shall otherwise agree in writing:

     (a) The Borrower shall provide the Bank within 120 days of the Borrower’s fiscal year end the Borrower’s consolidated, annual financial statements. The statements must be audited with an unqualified opinion by a certified public accountant reasonably acceptable to the Bank, with such opinion directed both to the Borrower and to the Bank, and must be accompanied by a certificate of such accountants stating whether, in conducting their audit, they have become aware of any event of default under this Agreement, or of any event which would, after the lapse of time or the giving of notice, or both, constitute an Event of Default, specifying the nature and duration of the default. Such audit statement shall be accompanied by the accountants’ calculations of the Borrower’s compliance with the covenants contained in Section 6.02 of this Agreement as of the said fiscal year end.

     (b) After the Completion Date, the Borrower will furnish to the Bank within 30 days after the end of each calendar month consolidated financial statements of the Borrower for such period and year to date all in reasonable detail.

     (c) For each full calendar quarter ending after the Completion Date, the Borrower will deliver to the Bank, within 30 days of each calendar quarter end, a certificate in a form reasonably acceptable to the Bank that has been signed by an officer or member of the Board of Governors of the Borrower, which (i) certifies that the statements required by Section 6.01(a) and (b) have been accurately prepared in accordance with GAAP applied consistently (except for the absence of financial footnotes to the statements furnished under Section 6.01(b)); (ii) certifies that the officer or member of the Board of Governors has no knowledge of any Event of Default under

23


 

this Agreement or the Loan Documents, or of any event which would, after the lapse of time or the giving of notice, or both, constitute an event of default under this Agreement or the Loan Documents and that the Borrower is in full compliance with all Covenants contained in this Agreement and the Loan Documents.

     (d) After the Completion Date, the Borrower will deliver to the Bank each month, within 30 days of each month end, a monthly production report, in form acceptable to the Bank, which shall, at a minimum, report for each such month the Borrower’s input and output amounts of corn or other grain usage, natural gas usage, electrical usage, dry distillers grains and wet distillers grains output, ethanol output and, if applicable, CO 2 output.

     (e) Prior to the end of each fiscal year, the Borrower shall provide the Bank projected financial statements for the following fiscal year which shall include, but not be limited to, proposed capital projects and expenditures.

     (f) The Borrower shall notify the Bank of the existence of any Event of Default promptly after such Event of Default becomes known to any manager, officer or member of the Board of Governors of the Borrower.

     (g) The Borrower shall authorize all federal, state and municipal authorities to furnish reports of examinations, records and other information relating to the condition and affairs of the Borrower and its ethanol plant, and any information from reports, returns, files and records by such authorities regarding the Borrower upon request to the Bank.

     (h) The Borrower will give the Bank prompt written notice of any material violation as to any environmental matter by the Borrower and of the commencement of any judicial or administrative proceeding relating to health, safety or environmental matters (i) in which an adverse determination or result could result in the revocation of or have a material adverse effect on any Permits held by the Borrower which are material to the operations of the Borrower and (ii) which will or threatens to impose a material liability on the Borrower to any person or party or which will require a material expenditure by the Borrower to cure any alleged problem or violation.

     (i) The Borrower will give prompt notice to the Bank of (i) any litigation or proceeding in which it is a party if an adverse decision therein would require it to pay more than $100,000 or deliver assets the value of which exceeds such sum (whether or not the claim is considered to be covered by insurance); and (ii) the institution of any other suit or proceeding involving it that might materially and adversely affect its operations, financial condition, property or business prospects.

     (j) The Borrower shall provide monthly Borrowing Base certificates in a form reasonably acceptable to the Bank, calculating advance rates under the Revolving Loan pursuant to the Borrowing Base beginning with the certificate with respect to the fourth month following the Completion Date.

24


 

     (k) The Borrower will provide the Bank with such other information as it may reasonably request.

      Section 5.02. Financial Covenants . At all times that any amounts are outstanding under the Construction Note, the Term Note, this Agreement or the Loan Documents to which the Borrower is a party, unless the Bank shall otherwise agree in writing, the Borrower agrees to comply with the financial covenants described below, which shall be calculated using GAAP consistently applied, except as they otherwise may be modified by the capitalized definitions:

     (a) The Borrower shall maintain a Fixed Charge Coverage Ratio, measured on a trailing four quarters basis at the end of each full calendar quarter, of no less than 1.25:1.0, for all periods following the Completion Date; provided, however, the Fixed Charge Coverage Ratio shall be measured as follows for the first three quarters after the Completion Date:

first quarter: on a trailing one quarter basis at the end of the calendar quarter second quarter: on a trailing two quarter basis at the end of each calendar quarter third quarter: on a trailing three quarter basis at the end of each calendar quarter.

     (b) The Borrower shall maintain Net Worth of not less than $21,000,000 at all times. The required minimum Net Worth of Borrower, which is to be measured annually at the end of each fiscal year of Borrower, shall increase each fiscal year by an amount equal to the greater of (a) $250,000 or (b) the amount of undistributed earnings accumulated during the fiscal year just ended, but not including allowable distributions attributable to the just ended fiscal year’s earnings.

     (c) The Borrower shall determine, at each fiscal year and following the Completion Date, the amount of its Excess Cash Flow for said fiscal year, and within one hundred twenty (120) days following such fiscal year end, pay fifteen percent (15%) of such sum to the Bank, to be applied to the outstanding principal amount of the Term Note, and after the Term Note is repaid, to the Long Term Revolving Note, and after Long Term Revolving Note is repaid, to the Swap Note. Such annual payment shall not release the Borrower from making any payment of principal or interest otherwise required by this Agreement. No payment of Excess Cash Flow shall be the cause of a payment to the Bank for interest rate breakage fees or otherwise result in any prepayment fee.

     (d) The Borrower shall maintain the following minimum Working Capital during the periods stated below, measured continuously:

         
Period   Minimum Working Capital  
Beginning on July 31, 2006 through October 31, 2006
  $ 2,500,000  
From November 1, 2006 through February 28, 2007
  $ 3,500,000  
From March 1, 2007 until payment in full of the Term Loan
  $ 5,000,000  

25


 

     For the purpose of this covenant, the amount of any availability to draw under the terms of the Long Term Revolving Note shall constitute an addition to Working Capital in such amount available.

      Section 6.03. Affirmative Covenants . During the time period that any amounts are outstanding under the Notes, this Agreement or the Loan Documents to which the Borrower is a party, unless the Bank shall otherwise agree in writing, the Borrower shall:

     (a) diligently proceed with construction of the Project in material compliance with the Plans and in accordance in all material respects with all applicable laws and ordinances, and complete the Project by the Completion Date;

     (b) use the proceeds of each of the disbursements under the Construction Loan solely for the purposes set forth in this Agreement;

     (c) retain Fagen, Inc. as the General Contractor. In the event that Fagen, Inc. is no longer the General Contractor for the Project, the Borrower shall replace Fagen, Inc. with another General Contractor, subject to the reasonable approval of the Bank and shall provide the Bank with proof of a performance completion bond in such form and in such amount as the Bank deems reasonably satisfactory;

     (d) use its reasonable best efforts to require the General Contractor and each Subcontractor to comply in all material respects with all rules, regulations, ordinances and laws bearing on its conduct of work on the Project;

     (e) provide and maintain at all times during the process of building the Project and, from time to time at the request of the Bank, furnish the Bank with such additional insurance, which the Bank, in its sole discretion, deems necessary and with proof of payment of premiums on:

     (i) Builders’ Risk completed value form insurance, in form and content satisfactory to the Bank, and placed with financially sound and reputable insurers insuring the Project (and after completion of the Project, comprehensive, all risk casualty insurance) against all risks, including flood, earthquake and mechanical and electrical breakdown including testing to the full value of the Project (subject to reasonable loss deductible provisions). The Bank’s interest shall be protected by naming the Bank as a “loss payee” and shall contain an agreement of the insurer to give not less than 30 days’ advance written notice to the Bank in the event of cancellation of such policy or change affecting the coverage thereunder;

     (ii) Insurance against loss, damage or destruction by fire and other casualty, including theft, vandalism and malicious mischief, flood (if the Premises is in a location designated by the Federal Emergency Management Administration as a Special Flood Hazard Area), earthquake (if the Premises is in an area subject to destructive earthquakes within recorded history), boiler explosion (if there is any boiler upon the Premises), plate glass breakage, sprinkler damage (if the Premises have a sprinkler system), all matters covered by a standard extended

26


 

coverage endorsement, special coverage endorsement commonly known as an “all risk” endorsement and such other risks as Lender may reasonably require, insuring the Mortgaged Property for not less than 100% of their full insurable replacement cost;

     (iii) Commercial General Liability insurance, (including products and completed operations, operations of subcontractors and contractual liability insurance), in form and content satisfactory to the Bank, and placed with financially sound and reputable insurers with limits reasonably acceptable to the Bank, but in no event for less than $2,000,000;

     (iv) State Worker’s compensation insurance in the statutorily mandated limits, employer’s liability insurance with limits not less than $500,000 or such greater amount as Lender may from time to time require and such other insurance as may be necessary to comply with applicable laws;

     (v) By the Completion Date, business income insurance equal to 100% of the principal and interest payable under the Note for a period of not less than six months.

     (vi) Business automobile liability insurance insuring all vehicles on the site, including hired and non-owned liability;

     (vii) Environmental coverage for clean up and removal once the Project becomes operational, but only insofar as it is reasonably required by the Bank;

     (viii) All insurance policies shall provide that any “no other insurance” clause in the insurance policy shall exclude any policies of insurance maintained by Lender and that the insurance policy shall not be brought into contribution with insurance maintained by Lender;

     (ix) All insurance policies shall contain a standard without contribution mortgage clause endorsement in favor of Lender and its successors and assigns as their interests may appear and any other lender designated by Lender;

     (x) All insurance policies shall provide that the policy of insurance shall not be terminated, cancelled or substantially modified without at least thirty (30) days’ prior written notice to Lender and to any lender covered by any standard mortgage clause endorsement;

     (xi) All insurance policies shall provide that the insurer shall not have the option to restore the Premises if Lender elects to terminate the Mortgage in accordance with the terms hereof;

     (xii) All insurance policies shall be issued by insurance companies licensed to do business in the state in which the Premises is located and which are rated A:VI or better by Best’s Insurance Guide or otherwise approved by Lender;

27


 

     (xiii) It is expressly understood and agreed that the foregoing minimum limits of insurance coverage shall not limit the liability of Borrower for its acts or omission as provided in the Mortgage. All liability insurance policies (with the exception of worker’s compensation insurance to the extent not available under statutory law) shall designate Lender and its successors and assigns as “loss payee.” All such policies shall be written as primary policies, with deductibles not to exceed 10% of the amount of coverage. Any other policies, including any policy now or hereafter carried by Lender, shall serve as excess coverage. Borrower shall procure policies for all insurance for periods of not less than one year and shall provide to Lender certificates of insurance or, upon Lender’s request, duplicate originals of insurance policies evidencing that insurance satisfying the requirements of the Mortgage is in effect as all times.

     (f) assign to the Bank, in form acceptable to the Bank, all equipment and systems warranties relating to the Project, together with all contracts for natural gas, electricity, water and other utilities, as the same are obtained by the Borrower following the Closing;

     (g) maintain accurate and complete books, accounts and records pertaining to the Property and the Project and its ongoing and continuing operations in form and substance reasonably satisfactory to the Bank. The Borrower will permit the Bank, at the Bank’s expense if the Bank employees make the inspection, but at the Borrower’s expense if the Bank contracts with third parties at reasonable expense to make the inspection, to examine upon reasonable notice all books, records, contracts, plans, drawings, Permits, bills and statements of account pertaining to the Project and to inspect upon reasonable notice all books and records pertaining to its operations and to make extracts therefrom and copies thereof;

     (h) cause to be paid to the proper authorities when due all federal, state and local taxes, including taxes on the Property, required to be paid or withheld by it except those which the Borrower is contesting in good faith and with respect to which adequate reserves have been set aside;

     (i) allow the Bank and its participants, upon reasonable notice, and at its expense, to conduct such inspections of the Project and the Borrower’s personal property subject to the Bank’s security interest as the Bank may deem necessary for the protection of the Bank’s interest; provided, however, such inspections shall occur during regular business hours, or such other time as the Borrower and the Bank may agree, and shall not unreasonably interfere with the Borrower’s business operations. Any such inspections shall be made and any certificates issued are solely for the benefit and protection of the Bank, and the Borrower shall not be entitled to rely thereon;

     (j) make all repairs, renewals or replacements necessary to keep its plant, properties and equipment in good working condition;

     (k) comply in all material respects with all laws applicable to its form of organization and business and the ownership of its property;

28


 

     (l) maintain and preserve all Permits, licenses, rights, privileges, charters and franchises that it is required to hold to construct and operate the Project;

     (m) observe and comply with all laws, rules, regulations and orders of any government or government agency relating to health, safety, pollution, hazardous materials or other environmental matters to the extent noncompliance could result in a material liability or otherwise have a material adverse effect on the Borrower;

     (n) maintain primary operating accounts (including those accounts containing the Borrower’s equity capital) at the Bank, other than local operating accounts approved by the Bank, such approval not to be unreasonably withheld by the Bank; and

     (o) preserve and maintain, and cause each Subsidiary to preserve and maintain, its corporate existence and good standing in the jurisdiction of its incorporation, and qualify and remain qualified, and cause each Subsidiary to qualify and remain qualified, as a foreign corporation in each jurisdiction in which such qualification is required.

      Section 6.04. Negative Covenants . During the time period that any amounts are outstanding under the Notes or this Agreement or the Loan Documents to which the Borrower is a party, unless the Bank shall otherwise agree in writing, the Borrower shall not:

     (a) permit any security interest or mortgage or lien on the Property or Project or other real or personal property the Borrower owns now or in the future, or assign any interest that it may have in any assets or subordinate any rights that it may have in any assets now or in the future, except (i) liens, assignments or subordinations in favor of the Bank; (ii) liens, assignments or subordinations outstanding on the date of this Agreement and disclosed in advance to the Bank in writing and approved by the Bank; (iii) liens for taxes or assessments or other governmental charges not delinquent or which the Borrower is contesting in good faith; (iv) liens which secure purchase money indebtedness allowed under this Agreement; (v) liens that are imposed by law for obligations for labor or materials not overdue for more than 120 days, such as mechanics’, materialmen’s, carriers’, landlords’ and warehousemen’s liens or liens, pledges or deposits under workers’ compensation, unemployment insurance, Social Security or similar legislation; and (vi) liens securing Subordinated Debt;

     (b) agree or consent to any material changes in the Plans, any material changes in the terms and provisions of the Design/Build Construction Contract, any one change order in an amount exceeding $50,000, all change orders which when combined exceed $100,000 or any material change to any other contract identified in Article IV of this Agreement;

     (c) change or permit any changes to the marketing contracts;

     (d) incorporate in the Project any materials, fixtures or property that are subject to the claims of any other person, whether pursuant to a conditional sales contract, security agreement, lease or mortgage, except as permitted under Article VI;

29


 

     (e) lease, sell, transfer, convey, assign or otherwise transfer all or any material part of the interest of the Borrower in the Project or the Property;

     (f) cause or suffer any change to the management contracts without the Bank’s approval, which will not be withheld unreasonably;

     (g) engage in any line of business materially different from that presently engaged in by the Borrower;

     (h) change its legal form of organization;

     (i) make any material changes in its accounting procedures for tax or other purposes unless such change is, or becomes, required under the Internal Revenue Code;

     (j) incur any Indebtedness except (i) debt arising under this or another agreement with the Bank; (ii) trade credit incurred in the ordinary course of business; (iii) indebtedness in existence on the date of this Agreement and disclosed in advance to the Bank in writing; and (iv) Subordinated Debt. The Borrower shall not borrow other than pursuant to this Agreement without permission of the Bank; provided, however, the Bank consents to the Borrower in the ordinary course of its business, borrowing up to an aggregate amount of $50,000 each year, without further permission from the Bank;

     (k) consolidate, merge, pool, syndicate or otherwise combine with any other entity, give any preferential treatment or make any advance, directly or indirectly, by way of loan, gift, bonus or otherwise to any entity directly or indirectly controlling or affiliated with or controlled by the Borrower or any other entity or to any partner or employee of the Borrower or of any such entity;

     (l) make, or commit to make, capital expenditures (including the total amount of any capital leases, but excluding the Bank-approved plant construction) in an aggregate amount exceeding $500,000 in any single fiscal year;

     (m) make or pay, without the written consent of the Bank, which written consent will not be unreasonably withheld, in any fiscal year distributions to members of the Borrower which would result in the Borrower at the time of such distribution not being in compliance with any of the covenants set forth in this Agreement after payment of such distribution or in excess of the following amounts:

         
 
  If Owner Equity (as a percentage of combined liabilities and Net Worth) is:   The Allowable Distribution (as a percentage of Net Income) shall be:
         
  • Less than or equal to 60%   • 65%
 
       
  • Greater than 60%   • 70%

30


 

     Any such distributions allowed hereunder shall be made only once per fiscal year, and only after receipt by the Bank of the Borrower’s annual audited financial statements and compliance statements as required herein, and if no Event of Default has occurred or is continuing.

     (n) assume, guarantee, endorse or otherwise become contingently liable for any obligations of any other person, except for those guaranties outstanding at the time of execution of this Agreement and disclosed to the Bank in writing;

     (o) make sales to or purchases from any affiliate of the Borrower or extend credit or make payments for services rendered by any affiliate of the Borrower unless such sales or purchases are made or such services are rendered in the ordinary course of business and on terms and conditions at least as favorable to the Borrower as the terms and conditions which would apply in a similar transaction with a person or party not an affiliate of the Borrower;

     (p) sell or dispose of all or substantially all its assets; and

     (q) redeem, purchase or retire any of its membership units or capital stock or grant or issue, or purchase or retire for any consideration, any warrant, right or option pertaining thereto, or permit any redemption, retirement or other acquisition by the Borrower of the ownership of the outstanding membership units or capital stock of the Borrower.

ARTICLE VII

EVENTS OF DEFAULT, RIGHTS AND REMEDIES

      Section 7.01. Events of Default . Each of the following shall be an Event of Default and give the Bank the right to exercise its remedies under this Agreement:

     (a) the Borrower shall fail to pay when due any Obligations or any other installment of principal or interest or fee payable to the Bank;

     (b) the Borrower shall fail to timely provide reports to the Bank as provided in Article VI;

     (c) the Borrower shall fail to observe or perform any other obligation to be observed or performed by it hereunder or under any of the Loan Documents;

     (d) the Borrower shall fail to pay any Indebtedness in an aggregate principal amount in excess of $100,000 due any third persons and such failure shall continue beyond any applicable grace period, or the Borrower shall default under any material agreement binding the Borrower and such default shall continue beyond any applicable grace period;

     (e) the Security Agreement shall at any time after its execution and delivery and for any reason cease (i) to create a valid and perfected first priority security interest

31


 

in and to the property purported to be subject to such Security Agreement; or (ii) to be in full force and effect or shall be declared null and void, or the validity or enforceability thereof shall be contested by the Borrower, or the Borrower shall deny it has any further liability or obligation under the Security Agreement, or the Borrower shall fail to perform any of its obligations under the Security Agreement;

     (f) any financial statement, representation, warranty or certificate made or furnished by or with respect to the Borrower to the Bank in connection with this Agreement, or as an inducement to the Bank to enter into this Agreement, or in any separate statement or document to be delivered to the Bank hereunder, shall be materially false, incorrect or incomplete when made;

     (g) the Borrower shall admit its inability to pay its debts as they mature or shall make an assignment for the benefit of itself or any of its creditors;

     (h) proceedings in bankruptcy, or for reorganization of the Borrower, or for the readjustment of debt under the Bankruptcy Code, as amended, or any part thereof, or under any other laws, whether state or federal, for the relief of debtors, now or hereafter existing, shall be commenced against or by the Borrower and, except with respect to any such proceedings instituted by the Borrower, shall not be discharged or stayed within 60 days of their commencement;

     (i) a receiver or trustee shall be appointed for the Borrower or for any substantial part of its respective assets, or any proceedings shall be instituted for the dissolution or the full or partial liquidation of the Borrower, and except with respect to any such appointments requested or instituted by the Borrower such receiver or trustee shall not be discharged within 60 days of his appointment, and except with respect to any such proceedings instituted by the Borrower such proceedings shall not be discharged within 60 days of their commencement, or the Borrower shall discontinue business or materially change the nature of its business;

     (j) the Borrower shall suffer final judgments for payment of money aggregating in excess of $100,000 which are not covered, without reservation, by insurance and shall not discharge the same within a period of 30 days unless, pending further proceedings, execution has not been commenced or, if commenced, has been effectively stayed;

     (k) a judgment creditor of the Borrower shall obtain possession of any of the Bank’s collateral by any means, including (without implied limitation) levy, distraint, replevin or self-help;

     (l) the construction of the Project is abandoned or shall be unreasonably delayed or be discontinued for a period of 15 consecutive calendar days, in each instance for reasons other than acts of God, fire, storm, adverse weather, strikes, blackouts, labor difficulties, riots, inability to obtain materials, equipment or labor, governmental restrictions or any similar cause not subject to the Borrower’s control and other than a change in the General Contractor as provided in Section 7.01(o);

32


 

     (m) the Borrower at any time prior to the completion of the Project shall delay construction or suffer construction to be delayed for any period of time, for any reason whatsoever, so that the completion of the Project cannot be accomplished, in the reasonable judgment of the Bank, by the Completion Date;

     (n) the Project is materially damaged or destroyed by fire or other casualty and the loss, in the reasonable judgment of the Bank, is not adequately covered by insurance actually collected or in the process of collection;

     (o) Fagen, Inc. shall cease to be the General Contractor and the Borrower has not replaced the General Contractor and provided a performance completion bond within 30 days following the termination of the same to the satisfaction of the Bank, which Bank approval shall not be unreasonably withheld;

     (p) the entities contracting with the Borrower under the Marketing Contracts, or their permitted assignees, shall cease to be the marketing agents of the Borrower as to sale of its products, or the entity contracting with the Borrower in the Management Contract shall cease to be the manager of the Borrower, and the Borrower has not within 30 days following termination of the foregoing hired a replacement to the Bank’s satisfaction, which Bank approval will not be unreasonably withheld; or

     (q) the Borrower pays any amount other than the required monthly management fee pursuant to the Management Contract prior to the Bank’s receipt of scheduled payments on the Obligations and the Bank’s acknowledgment that all required covenants have been met by the Borrower.

      Section 7.02. Rights and Remedies . If an Event of Default shall have occurred and be continuing, the Bank may refrain from making any further disbursements hereunder (but the Bank may make disbursements after the occurrence of such an Event of Default without thereby waiving its rights and remedies hereunder), and the Bank may exercise any or all of the following rights and remedies:

     (a) the Bank may declare any or all Loans to be terminated, whereupon the same shall forthwith terminate;

     (b) the Bank may declare the entire unpaid principal amount of any or all Notes then outstanding, all interest accrued and unpaid thereon and all other amounts payable under this Agreement to be forthwith due and payable, whereupon such Notes, all such accrued interest and all such amounts shall become and be forthwith due and payable, without presentment, demand, protest or further notice of any kind, all of which are hereby expressly waived by the Borrower;

     (c) the Bank may exercise and enforce its rights and remedies under any or all of the Loan Documents;

     (d) the Bank may enter upon the Property, if allowed under applicable law, and take possession thereof, together with the Project then in the course of construction, and proceed either in its own name or in the name of the Borrower, as the attorney-in-fact

33


 

of the Borrower (which authority is coupled with an interest and is irrevocable by the Borrower) to complete or cause to be completed the Project, at the cost and expense of the Borrower. If the Bank elects to complete or cause to be completed the Project, it may do so according to the Plans or according to such changes, alterations or modifications in and to the Plans as the Bank may deem reasonable and appropriate; and the Bank may enforce or cancel all contracts let by the Borrower relating to construction of the Project, and/or let other contracts which in the Bank’s sole judgment may seem advisable; and the Borrower shall forthwith turn over and duly assign to the Bank, as the Bank may from time to time require, contracts not already assigned to the Bank relating to construction of the Project, blueprints, shop drawings, bonds, building permits, bills and statements of accounts pertaining to the Project, whether paid or not, and any other instruments or records in the possession of the Borrower pertaining to the Project. The Borrower shall be liable under this Agreement to pay to the Bank, on demand, any amount or amounts reasonably expended by the Bank in so completing the Project, together with any reasonable costs, charges or expenses incident thereto or resulting therefrom, all of which shall be secured by the Loan Documents. In the event that a proceeding is instituted against the Borrower for recovery and reimbursement of any moneys expended by the Bank in connection with the completion of the Project, a statement of such expenditures, verified by the affidavit of an officer of the Bank, shall be prima facie evidence of the amounts so expended and of the propriety of the necessity for such expenditures, and the burden of proving to the contrary shall be upon the Borrower. The Bank shall have the right to apply any funds which it agrees to disburse hereunder to bring about the completion of the Project and to pay the costs thereof and, if such money so agreed to be disbursed is insufficient, in the sole judgment of the Bank, to complete the Project, the Borrower agrees to promptly deliver and pay to the Bank such sum or sums of money as the Bank may from time to time demand for the purpose of completing the Project or of paying any liability, charge or expense which may have been incurred or assumed by the Bank under or in performance of this Agreement or for the purpose of completing the Project. It is expressly understood and agreed that in no event shall the Bank be obligated, or liable in any way to complete the Project or to pay for the costs of construction thereof beyond the amount of the Construction Loan.

     (e) The Bank may exercise any other rights and remedies available to it by law or agreement.

ARTICLE VIII

MISCELLANEOUS

      Section 8.01. Inspections . The Borrower and the General Contractor shall be responsible for making inspections of the Project during the course of construction and shall determine to their own satisfaction that the work done or materials supplied by the General Contractor or any Subcontractor to whom payment is to be made out of each disbursement has been properly done or supplied in accordance with the Design/Build Construction Contract. If any work done or materials supplied by the General Contractor or any Subcontractor are not satisfactory to the Borrower and/or its General Contractor and the same is not remedied within 15 days of the discovery thereof, the Borrower will immediately notify the Bank in writing of

34


 

such fact. It is expressly understood and agreed that the Bank and any party designated by the Bank may conduct such inspections of the Project, subject to the limitations expressed in this Agreement, as the Bank may deem necessary for the protection of the Bank’s interest, and that any inspections which may be made of the Project by the Bank will be made, solely for the benefit and protection of the Bank and that the Borrower will not rely thereon.

      Section 8.02. Indemnification by Borrower . The Borrower shall bear all loss, expense (including reasonable attorneys’ fees) and damage in connection with, and agrees to indemnify and hold harmless the Bank, its agents, servants and employees from, all claims, demands and judgments made or recovered against the Bank, its agents, servants and employees because of bodily injuries, including death at any time resulting therefrom, and/or because of damages to property (including loss of use) from any cause whatsoever, arising out of, incidental to or in connection with the construction of the Project, whether or not due to any act of omission or commission, including negligence of the Borrower or the General Contractor or of his or their employees, servants or agents, other than gross negligence or willful misconduct of the Bank or its agents. The Borrower’s liability hereunder shall not be limited to the extent of insurance carried by or provided by the Borrower or subject to any exclusion from coverage in any insurance policy. The obligations of the Borrower under this Section shall survive the payment of the Construction Note.

      Section 8.03. No Waiver; Cumulative Remedies . No failure or delay on the part of the Bank in exercising any right, power or remedy under the Loan Documents shall operate as a waiver thereof nor shall any single or partial exercise of any such right, power or remedy preclude any other or further exercise thereof or the exercise of any other right, power or remedy under the Loan Documents. The remedies provided in the Loan Documents are cumulative and not exclusive of any remedies provided by law.

      Section 8.04. Amendments, Etc . No amendment, modification, termination or waiver of any provision of any of the Loan Documents or consent to any departure by the Borrower therefrom shall be effective unless the same shall be in writing and signed by the Bank and the Borrower, and then such waiver or consent shall be effective only in the specific instance and for the specific purpose for which given. No notice to or demand on the Borrower in any case shall entitle the Borrower to any other or further notice or demand in similar or other circumstances.

      Section 8.05. Addresses for Notices, Etc . Except as otherwise expressly provided herein, all notices, requests, demands and other communications provided for under the Loan Documents shall be in writing and sent by mail or telecopy (if by telecopy with a confirmation mailed within two Business Days thereafter), to the applicable party at its address indicated below:

         
 
  If to the Borrower:   Granite Falls Community Ethanol Plant, LLC
      15045 Highway 23 Southeast
      Granite Falls, MN 56241
      Attention: General Manager
      Facsimile: (320) 564-3190

35


 

         
  If to the Bank:   First National Bank of Omaha
      1620 Dodge Street STOP 1050
      Omaha, NE 68197-1050
      Attention: Natalie E. Mason
      Facsimile: (402) 633-3519

or, as to each party, at such other address as shall be designated by such party in a written notice to the other party complying as to delivery with the terms of this Section. All such notices, requests, demands and other communications, when mailed, shall be effective when deposited in the mails, addressed as aforesaid, or, when telecopied, shall be effective when confirmation of receipt is received, except that notices or requests to the Bank pursuant to any of the provisions hereunder shall not be effective until received by the Bank.

      Section 8.06. Time of Essence . Time is of the essence in the performance of this Agreement.

      Section 8.07. Execution in Counterparts . The Loan Documents may be executed in any number of counterparts, each of which when so executed and delivered shall be deemed to be an original and all of which counterparts of each instrument or agreement, taken together, shall constitute but one and the same instrument.

      Section 8.08. Binding Effect, Assignment . The Loan Documents to which they are parties shall be binding upon and inure to the benefit of the Borrower and the Bank and their respective successors and assigns, except that the Borrower shall not have the right to assign its rights thereunder or any interest therein without the prior written consent of the Bank.

      Section 8.09. Governing Law . The Loan Documents, to the extent they do not otherwise provide, shall be governed by, and construed in accordance with, the laws of the State of Nebraska.

      Section 8.10. Severability of Provisions . Any provision of this Agreement which is prohibited or unenforceable shall be ineffective to the extent of such prohibition or unenforceability without invalidating the remaining provisions hereof.

      Section 8.11. Headings . Section headings in this Agreement are included herein for convenience of reference only and shall not constitute a part of this Agreement for any other purpose.

      Section 8.12. Integration . This Agreement supersedes, replaces and terminates any prior oral offers, negotiations, understandings or agreements and any commitment letters or similar writings relating to any of the matters contemplated herein.

      Section 8.13. Participations . Notwithstanding any other provision of this Agreement, the Borrower understands that the Bank may enter into participation agreements with other lenders whereby the Bank will allocate a certain percentage of the Loans to them. The Borrower specifically permits and authorizes the Bank to exchange financial information about the Borrower with actual or potential participants. The Borrower acknowledges that, for the convenience of all parties, this Agreement is being entered into with the Bank only and that its

36


 

obligations under this Agreement are undertaken for the benefit of, and as an inducement to, each of the Participating Lenders as well as the Bank, and the Borrower hereby grants to each of the Participating Lenders to the extent of its participation in any Loan the right to set off deposit accounts maintained by the Borrower with the Bank. The Borrower understands that the terms of such participation agreements with any of the participants will limit the Bank’s rights to amend, waive or modify the terms and conditions of this Agreement without the express written consent of all or a designated percentage of such participants.

37


 

     IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their respective officers thereunto duly authorized, as of the date first above written.

                 
            GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC d/b/a
            GRANITE FALLS ENERGY, LLC, a Minnesota limited liability company
 
               
          By   /s/ Paul Eustad
               
          Its   Chairman
               
 
               
            FIRST NATIONAL BANK OF OMAHA
 
               
          By   /s/ Natalie E. Mason
               
              Natalie E. Mason, Commercial Loan Officer
STATE OF MINNESOTA
  )            
 
  ) ss.        
COUNTY OF YELLOW MEDICINE
  )            

     On this 16th day of December, 2004, before me, the undersigned, a Notary Public, personally appeared Paul Eustad, on behalf of said entity as Chairman of Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, a Minnesota limited liability company, who executed the foregoing instrument, and acknowledged that he executed the same as his voluntary act and deed, as well as that of the corporation.

             
          /s/ Patti Herber
          Notary Public

38


 

EXHIBIT A

CONSTRUCTION NOTE

Note Date: December 16, 2004
Maturity Date: March 10, 2006
  $34,000,000

FOR VALUE RECEIVED, Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, a Minnesota limited liability company (the “Borrower”), promises to pay to the order of First National Bank of Omaha (the “Bank”), at its principal office or such other address as the Bank or holder may designate from time to time, the principal sum of $34,000,000, or the amount shown on the Bank’s records to be outstanding, plus interest (calculated on the basis of actual days elapsed in a 360-day year) accruing each day on the unpaid principal balance at the annual interest rates defined below. Absent manifest error, the Bank’s records shall be conclusive evidence of the principal and accrued interest owing hereunder.

This Construction Note is executed pursuant to the loan agreement (the “Loan Agreement”) between the Borrower and the Bank dated as of December 16, 2004. All capitalized terms not otherwise defined in this Construction Note shall have the meanings provided in the Loan Agreement.

Interest Accrual . Interest on the principal amount outstanding shall accrue based on the one month LIBOR Rate plus 350 basis points prior to acceleration or maturity, and 650 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise. Interest shall be calculated on the basis of a 360-day year, counting the actual number of days elapsed.

Repayment Terms . Until the Construction Loan Termination Date, interest only shall be payable every three months, commencing on January 10, 2005. On the Construction Loan Termination Date, all principal and accrued interest are due and payable.

Prepayment . The Loan Agreement contains provisions regarding prepayment.

Additional Terms and Conditions . The Loan Agreement, and any amendments or substitutions, contains additional terms and conditions, including default and acceleration provisions, which are incorporated into this Construction Note by reference. The Borrower agrees to pay all costs of collection, including reasonable attorneys’ fees and legal expenses incurred by the Bank, if this Construction Note is not paid as provided above. This Construction Note shall be governed by the substantive laws of the State of Nebraska.

 


 

Waiver of Presentment and Notice of Dishonor . The Borrower and any other person who signs, guarantees or endorses this Construction Note, to the extent allowed by law, hereby waives presentment, demand for payment, notice of dishonor, protest and any notice relating to the acceleration of the maturity of this Construction Note.

                 
            GRANITE FALLS COMMUNITY ETHANOL
          PLANT, LLC d/b/a GRANITE FALLS
          ENERGY, LLC, a Minnesota limited liability company
 
               
          By      
             
          Its    
             
STATE OF ___________________
    )          
 
               
    ) ss.      
COUNTY OF __________________
    )          

     On this 16th day of December, 2004, before me, the undersigned, a Notary Public, personally appeared            , on behalf of said entity as            of Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, a Minnesota limited liability company, who executed the foregoing instrument, and acknowledged that he executed the same as his voluntary act and deed, as well as that of the corporation.

     
   
  Notary Public

 


 

EXHIBIT B

REVOLVING NOTE

Note Date: December 16, 2004
Maturity Date: December 15, 2005
  $3,500,000

     On or before December 15, 2005, Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, a Minnesota limited liability company (the “Borrower”), promises to pay to the order of First National Bank of Omaha (the “Bank”) at any of its offices in Omaha, Nebraska the principal sum hereof, which shall be $3,500,000 or so much thereof as may have been advanced by the Bank and shown on the records of the Bank to be outstanding under this Revolving Note and the loan agreement executed by the Bank and the Borrower dated as of December 16, 2004 (the “Loan Agreement”), as it may from time to time be amended.

     Interest on the principal amount outstanding shall accrue based on the one month LIBOR Rate plus 350 basis points prior to acceleration or maturity, and 650 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise. Interest shall be calculated on the basis of a 360-day year, counting the actual number of days elapsed. Interest on this Revolving Note shall be payable monthly in arrears.

     The interest rate applicable to this Revolving Note is subject to reduction after a date six months subsequent to the Completion Date, based on the business results of the Borrower. During any three month Interest Period that the Borrower maintains the following ratios, measured for the prior Interest Period, and after Bank receipt of a quarter compliance certificate which quarter shall include the prior Interest Period, the interest rates will be adjusted accordingly for the next Interest Period:

     
If Indebtedness to    
Net Worth is:   Interest Rate will be:
Greater than or equal to 1.25 : 1.00
  One month LIBOR Rate plus 350 basis
points
Less than 1.25 : 1.00 but greater than or equal to 1.00 : 1.00
  One month LIBOR Rate plus 325 basis
points
Less than 1.00 : 1.00 but greater than or equal to .75 : 1.00
  One month LIBOR Rate plus 300 basis
points
Less than .75 : 1.00
  One month LIBOR Rate plus 275 basis
points

     This Revolving Note is executed pursuant to the Loan Agreement. The Loan Agreement contains additional terms of this Revolving Note, including, but not limited to, enumerated events of default and the granting of liens to secure the Borrower’s performance. All capitalized terms not otherwise defined herein shall have the same meanings as set forth in the Loan Agreement.

     As provided in the Loan Agreement, upon any such enumerated default, the Bank may accelerate the due date of this Revolving Note and declare all obligations set forth herein immediately due and payable, and the Bank shall also have such other remedies as are described

 


 

in the Loan Agreement and are provided by law. All makers and endorsers hereby waive presentment, demand, protest and notice of dishonor, consent to any number of extensions and renewals for any period without notice and consent to any substitution, exchange or release of collateral and to the addition or releases of any other party primarily or secondarily liable.

     Executed as of the 16th day of December, 2004.

                     
                GRANITE FALLS COMMUNITY ETHANOL
                PLANT, LLC d/b/a GRANITE FALLS
                ENERGY, LLC, a Minnesota limited liability company
 
                   
              By    
                   
              Its    
                   
 
                   
STATE OF                                  
    )              
    )     ss.        
COUNTY OF                              
    )              

     On this 16th day of December, 2004, before me, the undersigned, a Notary Public, personally appeared                 , on behalf of said entity as                 of Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, who executed the foregoing instrument, and acknowledged that he executed the same as his voluntary act and deed, as well as that of the corporation.

     
 
   
   
  Notary Public

 


 

EXHIBIT C

SWAP NOTE

     
Note Date:                     
Maturity Date:                     
  $17,000,000

FOR VALUE RECEIVED, Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, a Minnesota limited liability company (the “Borrower”), promises to pay to the order of First National Bank of Omaha (the “Bank”), at its principal office or such other address as the Bank or holder may designate from time to time, the principal sum of $17,000,000, or the amount shown on the Bank’s records to be outstanding, plus interest (calculated on the basis of actual days elapsed in a 360-day year) accruing each day on the unpaid principal balance at the annual interest rates defined below. Absent manifest error, the Bank’s records shall be conclusive evidence of the principal and accrued interest owing hereunder.

This Swap Note is executed pursuant to the loan agreement (the “Loan Agreement”) between the Borrower and the Bank dated as of December 16, 2004. All capitalized terms not otherwise defined in this Swap Note shall have the meanings provided in the Loan Agreement.

Interest Accrual . Interest on the principal amount outstanding shall accrue based on the three-month LIBOR Rate plus 300 basis points prior to acceleration or maturity, and 600 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise. Interest shall be calculated on the basis of a 360-day year, counting the actual number of days elapsed.

Repayment Terms .

(a) On the 10 th day of every third month, commencing June 10 th , 2006, the Borrower shall pay to the Bank the scheduled principal payment shown in Schedule I, attached to the Loan Agreement, plus accrued interest on the Swap Note.

(b) Notwithstanding the foregoing, all unpaid principal and accrued interest for all Term Notes shall be due and payable on the Term Loan Termination Date, if not sooner paid.

Prepayment . The Loan Agreement contains provisions regarding prepayment.

Additional Terms and Conditions . The Loan Agreement, and any amendments or substitutions, contains additional terms and conditions, including default and acceleration provisions, which are incorporated into this Swap Note by reference. The Borrower agrees to pay all costs of collection, including reasonable attorneys’ fees and legal expenses incurred by the Bank, if this Swap Note is not paid as provided above. This Swap Note shall be governed by the substantive laws of the State of Nebraska.

Waiver of Presentment and Notice of Dishonor . The Borrower and any other person who signs, guarantees or endorses this Swap Note, to the extent allowed by law, hereby waives

 


 

presentment, demand for payment, notice of dishonor, protest and any notice relating to the acceleration of the maturity of this Swap Note.

                     
                GRANITE FALLS COMMUNITY ETHANOL
                PLANT, LLC d/b/a GRANITE FALLS
                ENERGY, LLC, a Minnesota limited liability company
 
                   
              By    
                   
              Its    
                   
 
                   
STATE OF                     
    )              
    )     ss.        
COUNTY OF                     
    )              

     On this 16th day of December, 2004, before me, the undersigned, a Notary Public, personally appeared                      , on behalf of said entity as                      of Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, a Minnesota limited liability company, who executed the foregoing instrument, and acknowledged that he executed the same as his voluntary act and deed, as well as that of the corporation.

     
 
   
   
  Notary Public

 


 

EXHIBIT D

VARIABLE RATE NOTE

     
Note Date:                                          
  $12,000,000
Maturity Date:                                          
   

     On or before                                           , Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, a Minnesota limited liability company (the “Borrower”), promises to pay to the order of First National Bank of Omaha (the “Bank”) at any of its offices in Omaha, Nebraska the principal sum hereof, which shall be $12,000,000 or so much thereof as may have been advanced by the Bank and shown on the records of the Bank to be outstanding under this Variable Rate Note and the loan agreement executed by the Bank and the Borrower dated as of December 16, 2004 (the “Loan Agreement”), as it may from time to time be amended.

     Interest on the principal amount outstanding shall accrue based on the three-month LIBOR Rate plus 350 basis points prior to acceleration or maturity, and 650 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise. Interest shall be calculated on the basis of a 360-day year, counting the actual number of days elapsed. Interest on this Variable Rate Note shall be payable quarterly in arrears.

     The interest rate applicable to this Variable Rate Note is subject to reduction after a date six months subsequent to the Completion Date, based on the business results of the Borrower. During any three month Interest Period that the Borrower maintains the following ratios, measured for the prior Interest Period, and after Bank receipt of a quarter compliance certificate which quarter shall include the prior Interest Period, the interest rates will be adjusted accordingly for the next Interest Period:

     
If Indebtedness to    
Net Worth is:   Interest Rate will be:
Greater than or equal to 1.25 : 1.00
  One month LIBOR Rate plus 350 basis points
Less than 1.25 : 1.00 but greater than or equal to 1.00 : 1.00
  One month LIBOR Rate plus 325 basis points
Less than 1.00 : 1.00 but greater than or equal to .75 : 1.00
  One month LIBOR Rate plus 300 basis points
Less than .75 : 1.00
  One month LIBOR Rate plus 275 basis points

     This Variable Rate Note is executed pursuant to the Loan Agreement. The Loan Agreement contains additional terms of this Variable Rate Note, including, but not limited to, the repayment provisions enumerated in Section 2.11(b), enumerated events of default and the granting of liens to secure the Borrower’s performance. All capitalized terms not otherwise defined herein shall have the same meanings as set forth in the Loan Agreement.

     As provided in the Loan Agreement, upon any such enumerated default, the Bank may accelerate the due date of this Variable Rate Note and declare all obligations set forth herein immediately due and payable, and the Bank shall also have such other remedies as are described

 


 

in the Loan Agreement and are provided by law. All makers and endorsers hereby waive presentment, demand, protest and notice of dishonor, consent to any number of extensions and renewals for any period without notice and consent to any substitution, exchange or release of collateral and to the addition or releases of any other party primarily or secondarily liable.

     Executed as of the 16th day of December, 2004.

         
    GRANITE FALLS COMMUNITY ETHANOL
    PLANT, LLC d/b/a GRANITE FALLS
    ENERGY, LLC, a Minnesota limited liability
    company
 
       
  By                                                                 
  Its                                                                 
     
STATE OF                          
)  
)  ss.
COUNTY OF                      
)  

     On this 16th day of December, 2004, before me, the undersigned, a Notary Public, personally appeared                      , on behalf of said entity as                      of Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, who executed the foregoing instrument, and acknowledged that he executed the same as his voluntary act and deed, as well as that of the corporation.

     
                                                                
  Notary Public

 


 

EXHIBIT E

LONG TERM REVOLVING NOTE

         
Note Date:                     
  $ 5,000,000  
Maturity Date:                     
       

     On or before                      , Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, a Minnesota limited liability company (the “Borrower”), promises to pay to the order of First National Bank of Omaha (the “Bank”) at any of its offices in Omaha, Nebraska the principal sum hereof, which shall be $5,000,000 or so much thereof as may have been advanced by the Bank and shown on the records of the Bank to be outstanding under this Long Term Revolving Note and the loan agreement executed by the Bank and the Borrower dated as of December 16, 2004 (the “Loan Agreement”), as it may from time to time be amended.

     Interest on the principal amount outstanding shall accrue based on the one month LIBOR Rate plus 350 basis points prior to acceleration or maturity, and 650 basis points in excess of the LIBOR Rate in effect from time to time after maturity, whether by acceleration or otherwise. Interest shall be calculated on the basis of a 360-day year, counting the actual number of days elapsed. Interest on this Long Term Revolving Note shall be payable quarterly in arrears.

     The interest rate applicable to this Long Term Revolving Note is subject to reduction after a date six months subsequent to the Completion Date, based on the business results of the Borrower. During any three month Interest Period that the Borrower maintains the following ratios, measured for the prior Interest Period, and after Bank receipt of a quarter compliance certificate which quarter shall include the prior Interest Period, the interest rates will be adjusted accordingly for the next Interest Period:

     
If Indebtedness to    
Net Worth is:   Interest Rate will be:
Greater than or equal to 1.25 : 1.00
  One month LIBOR Rate plus 350 basis points
Less than 1.25 : 1.00 but greater than or equal to 1.00 : 1.00
  One month LIBOR Rate plus 325 basis points
Less than 1.00 : 1.00 but greater than or equal to .75 : 1.00
  One month LIBOR Rate plus 300 basis points
Less than .75 : 1.00
  One month LIBOR Rate plus 275 basis points

     This Long Term Revolving Note is executed pursuant to the Loan Agreement. The Loan Agreement contains additional terms of this Long Term Revolving Note, including, but not limited to, the repayment provisions enumerated in Section 2.11(b), enumerated events of default and the granting of liens to secure the Borrower’s performance. All capitalized terms not otherwise defined herein shall have the same meanings as set forth in the Loan Agreement.

     As provided in the Loan Agreement, upon any such enumerated default, the Bank may accelerate the due date of this Long Term Revolving Note and declare all obligations set forth

 


 

herein immediately due and payable, and the Bank shall also have such other remedies as are described in the Loan Agreement and are provided by law. All makers and endorsers hereby waive presentment, demand, protest and notice of dishonor, consent to any number of extensions and renewals for any period without notice and consent to any substitution, exchange or release of collateral and to the addition or releases of any other party primarily or secondarily liable.

     Executed as of the 16th day of December, 2004.

         
    GRANITE FALLS COMMUNITY ETHANOL
    PLANT, LLC d/b/a GRANITE FALLS
    ENERGY, LLC, a Minnesota limited liability
    company
 
       
  By                                                                 
  Its                                                                 
     
STATE OF                           
)  
)  ss.
COUNTY OF                       
)  

     On this 16th day of December, 2004, before me, the undersigned, a Notary Public, personally appeared                      , on behalf of said entity as                      of Granite Falls Community Ethanol Plant, LLC d/b/a Granite Falls Energy, LLC, who executed the foregoing instrument, and acknowledged that he executed the same as his voluntary act and deed, as well as that of the corporation.

     
                                                                
  Notary Public

 


 

EXHIBIT F

LEGAL DESCRIPTION

LAND DESCRIPTION — 46.70 ACRE PARCEL

That part of the East Half of the Northeast Quarter of Section 1, Township 115 North, Range 39 West of the Fifth Principal Meridian, Granite Falls Township, Chippewa County, Minnesota, described as follows:

Commencing at the northwest corner of Parcel 3, as shown on the record plat entitled STATE HIGHWAY RIGHT OF WAY PLAT NO. 12-1, on file in the office of the Chippewa County Recorder; thence on an assumed bearing of South 1 degree 56 minutes 15 seconds West, along the west line of Parcel 3, as shown on said record plat entitled STATE HIGHWAY RIGHT OF WAY PLAT No. 12-1, a distance of 182.53 feet to southerly right of way boundary line of the railroad, which is also the southwest corner of said Parcel 3 and the point of beginning of the land to be described; thence on a bearing of South 87 degrees 01 minutes 14 seconds West, along the southerly right of way line of the railroad, a distance of 911.97 feet to the west line of the East Half of the Northeast Quarter of said Section 1; thence on a bearing of South 0 degrees 44 minutes 38 seconds West, along the west line of the East Half of the Northeast Quarter of said Section 1, a distance of 2290.26 feet to the northwest corner of Parcel 213, as shown on the record plat entitled MINNESOTA DEPARTMENT OF TRANSPORTATION RIGHT OF WAY PLAT NO. 12-24, on file in the office of the Chippewa County Recorder; thence on a bearing of South 88 degrees 21 minutes 26 seconds East, along the north boundary line of said Parcel 213, a distance of 729.81 feet; thence on a bearing of North 47 degrees 28 minutes 37 seconds East, along the boundary line of said Parcel 213, a distance of 143.46 feet to the west line of Parcel 1, as shown on said record plat entitled STATE HIGHWAY RIGHT OF WAY PLAT NO. 12-1; thence on a bearing of North 3 degrees 18 minutes 35 seconds East, along the west line of said Parcel 1, a distance of 1123.61 feet to the northwest corner of said Parcel 1; thence continuing on a bearing of North 3 degrees 18 minutes 35 seconds East, along the west line of Parcel 2, as shown on said record plat entitled STATE HIGHWAY RIGHT OF WAY PLAT NO. 12-1, a distance of 75.63 feet; thence on a bearing of North 1 degree 56 minutes 15 seconds East, along the west line of Parcel 2, as shown on said record plat entitled STATE HIGHWAY RIGHT OF WAY PLAT NO. 12-1, a distance of 1064.80 feet to the point of beginning.

 


 

EXHIBIT G

OPINION OF COUNSEL FOR BORROWER

December 16, 2004

First National Bank of Omaha
1620 Dodge Street STOP 1050
Omaha, NE 68197-1050
Attention: Natalie E. Mason

Granite Falls Community Ethanol Plant, LLC
15045 Highway 23 Southeast
Granite Falls, MN 56241
Attention: General Manager

     
Re:
  Loan Agreement dated as of December 16, 2004 (the “Loan Agreement”) between Granite Falls Community Ethanol Plant, LLC, a Minnesota limited liability company (the “Borrower”) and First National Bank of Omaha (the “Lender”) Our File No. 19201-001

Ladies and Gentlemen:

     This legal opinion is being delivered to the Lender pursuant to Section 4.02(f) of the Loan Agreement upon the express instructions and request of our client, the Borrower. For purposes of this opinion letter only, the Lender is deemed to be in privity with this firm. Capitalized terms used but not otherwise defined herein are used herein as defined in the Loan Agreement.

     We have acted as counsel for the Borrower in connection with the Loan Agreement.

     In preparation of this opinion, we have examined originals, or copies certified or otherwise identified to our satisfaction, of the following limited liability company records and documents of the Borrower:

     a. Fifth Amended and Restated Operating and Member Control Agreement dated October 13, 2004 (the “Operating Agreement”).

     b. Articles of Organization filed December 29, 2000.

     c. Amendment of Articles of Organization filed March 15, 2003.

 


 

     d. Unanimous Written Action of Governors, dated ___ ______, 2004

     e. Loan Agreement.

     In preparation of this opinion, we have assumed the genuineness of all signatures, the legal capacity of individual parties or signatories, the authenticity of all documents submitted to us as originals, the conformity to the originals of all documents submitted as certified, photostatic or conformed copies and the authenticity of the originals of such latter documents. We have assumed the accuracy of the material and factual matters contained therein.

     Our opinions expressed below as to certain factual matters are qualified as being limited “to our actual knowledge” or by other words, to the same or similar effect. Such words, as used herein, mean that during the course of our representation of the Borrower with respect to the Loan Agreement, no contrary information came to the attention of the undersigned, the attorney who has represented the Borrower in connection with the transactions contemplated by the transaction documents.

     In addition, in rendering the opinions expressed below, we have assumed that the Loan Agreement constitutes the legal, valid, and binding obligation of each party (other than the Borrower) thereto, enforceable against each such party in accordance with its terms. We have also assumed that there has not been any mutual mistake of fact or misunderstanding, fraud, duress, or undue influence in connection with the negotiation and execution of the Loan Agreement.

     You have agreed that this letter is subject to these conditions and those expressed elsewhere in this letter.

     This opinion is solely for your information only in connection with the transaction described above and should not be quoted or otherwise relied upon or referred to in whole or in part, in any financial statement or other document or furnished to any other person or agency without prior written consent.

     Based upon the foregoing and subject to the comments, exceptions, and qualifications set forth below, we are of the opinion that:

     1. The Borrower is a Minnesota limited liability company duly organized and validly existing and in good standing under the laws of the State of Minnesota and is authorized to transact business in those jurisdictions in which it is now doing business;

     2. The Borrower has the requisite power and authority and has taken all requisite action necessary to enable it to execute and deliver the Loan Agreement to which it is a party and to consummate the transactions contemplated thereby and the execution of any agreements specifically related to the Loan Agreement. The loan documents to which Borrower is a party have been duly and validly authorized, executed and delivered and are valid and binding obligations, enforceable against Borrower in accordance with their respective terms;

 


 

     3. The execution, delivery and performance of the Loan Agreement and the consummation of the transactions contemplated thereunder will not violate or conflict with the (i) Articles of Organization of the Borrower, nor with the Operating Agreement (ii) any agreement, contract or instrument to which Borrower is now a party or by which it is bound, except to the extent consents are necessary and have not been received or (iii) any judgment, decree, order, statute, rule or regulation of any court or any public, governmental or regulatory agency or body having jurisdiction over Borrower or any of their respective properties or assets.

     4. There are no actions, suits, investigations or proceedings pending or, to the best of our knowledge, threatened before any court, commission, agency or other administrative authority against Borrower that would question the validity of, or interfere with Borrower’s power or authority to enter into and perform, the loan documents to which each is a party, as applicable.

     5. No authorization, approval or consent of, or filing or registration with any governmental authority or agency is necessary to execute, deliver and perform the loan documents by Borrower except such authorization, approval or consent as has been obtained;

     6. Upon the execution of the loan documents, the loans shall become effective in accordance with the terms of the Loan Agreement;

     7. The provisions of the loan documents that purport to create security interests in favor of the Lender are effective to create valid security interests therein;

     8. Each of the UCC financing statements attached hereto is an appropriate form for filing in the Office of the Secretary of State of the State of Minnesota. Upon the proper filing of each such UCC financing statement, the security interest in favor of the Lender will be perfected to the extent a security interest in such Property can be perfected by such filing of a financing statement; and

     9. The indebtedness under the loan documents does not violate the usury laws of the State of Minnesota.

     The opinions expressed above are subject to the following exclusions and qualifications:

     1. We express no opinion as to the validity, binding effect, or enforceability of any right or obligation to the extent that such right or obligation may be limited by (i) applicable bankruptcy, insolvency, reorganization, moratorium, fraudulent transfer, or other laws relating to or affecting creditors’ rights generally, or (ii) general principles of equity (regardless of whether considered in a proceeding in equity or at law), including without limitation those relating to the availability of the remedy of specific performance or injunctive relief.

     2. We express no opinion as to any laws other than the laws of the State of Minnesota and the United States, and we express no opinion with respect to the laws, regulations, or ordinances of any county, municipality, or governmental subdivision or agency thereof.

 


 

     3. We have made no independent examination of the condition of title to any real estate collateral securing the obligations of any party to the Loan Agreement, and we express no opinion as to whether the Borrower have rights to any real estate collateral described in the Loan Agreement.

     Our opinions are as of December 16, 2004, and we have no responsibility to update this opinion for events or circumstances occurring after the date hereof or as to facts relating to prior events which are subsequently brought to our attention. This opinion is rendered solely to the Lender as a condition to the effectiveness of the Loan Agreement and is not to be used, circulated, quoted, or otherwise relied upon by any third party without our prior written consent.

     This opinion is limited to the laws of the States of Minnesota and the federal laws of the United States of America.

     
  Very truly yours,

 


 

EXHIBIT H

SUPPLEMENTARY MATERIAL TO FINANCIAL PROJECTIONS

 


 

Granite Falls Energy, LLC
Estimated Sources and Uses

                 
Sources:
               
Public Offering
          $ 29,780,000  
Initial Investors
          $ 638,500  
Construction Loan
          $ 34,000,000  
Equipment Loans or Capital Leases
          $ 270,000  
Items Paid for with Cash Flow from Operations
          $ 350,000  
 
               
 
             
Total Sources
          $ 65,038,500  
 
             
 
               
Use of Proceeds:
               
Fixed Assets:
               
Plant Construction (with Fagen):
               
Original Contract
  $ 43,050,000          
Grain Receiving Elevator
  $ 2,850,000          
Adjustment of Sales Taxes (due to JOBZ)
  $ (150,300 )        
Production Enhancements (change order)
  $ 2,270,000          
Projected Early Completion Bonus
  $ 480,000          
 
             
Total Plant Construction
      $ 48,499,700  
Land and Site Development
          $ 2,371,000  
Railroad and Car Mover
          $ 1,424,000  
Utilities (natural gas, electric and water)
          $ 1,340,000  
Rolling Stock
          $ 200,000  
Administrative Building
          $ 200,000  
Computers, Phones and Office Equipment
          $ 140,000  
 
               
Financial and Organizational:
               
Organizational Costs
          $ 950,000  
Capitalized Interest
          $ 900,000  
Stock Offering Costs: First Offering (2003)
          $ 325,000  
Stock Offering Costs: Second Offering (2004)
          $ 250,000  
Loan Financing Costs
          $ 480,000  
Construction Insurance Costs
          $ 300,000  
Grants and Interest Income
          $ (76,000 )
 
               
Beginning Operations:
               
Inventory
          $ 2,750,000  
Pre-Production Costs
          $ 750,000  
Working Capital
          $ 750,000  
Spare Parts
          $ 320,000  
Shop and Safety Equipment
          $ 60,000  
 
               
 
             
Total Use of Proceeds
          $ 61,933,700  
 
             
Excess / (Shortage) of Proceeds
          $ 3,104,800  
 
             

 


 

EXHIBIT I

TITLE AND ALTA INFORMATION

 


 

ENDORSEMENTS
FOR
GRANITE FALLS COMMUNITY ETHANOL PLANT, LLC

The following endorsements will be issued by Old Republic and attached to the final lender’s policy for First National Bank of Omaha:

1.   Form 3.1 (zoning-completed structure.) This can only be issued if accompanied by a letter from the municipal zoning authority. Cost to issue: $1,875.00
 
2.   Form 6 (variable rate mortgage). Cost to issue: $50.00
 
3.   Form 8.1 (environmental protection). Cost to issue: None
 
4.   Form 9 (comprehensive). Cost to issue: None
 
5.   Form 14 (future advance). Cost to issue: $50.00
 
6.   Form 15.1 (no imputations). Cost to issue: None
 
7.   Form 17 (access and entry). Cost to issue: None
 
8.   Form 18.1 (multiple tax parcel). Can be issued only if the tax parcels do not cover additional land. Cost to issue: None
 
9.   Fairway endorsement. Cost to issue: None
 
10.   Arbitration endorsement. Cost to issue: None
 
11.   Doing business endorsement. Cost to issue: None
 
12.   Survey endorsement. Cost to issue: None

 


 

SCHEDULE I

AMORTIZATION SCHEDULE – U.S. RULE (NO COMPOUNDING), 360 DAY YEAR

             
    Date   Principal  
 
Loan
  3/10/2006        
1
  6/10/2006     299,836.55  
2
  9/10/2006     304,893.79  
3
  12/10/2006     313,042.13  
2006 Totals
        917,772.47  
 
           
4
  3/10/2007     321,213.13  
5
  6/10/2007     320,734.10  
6
  9/10/2007     326,143.82  
7
  12/10/2007     334,415.70  
2007 Totals
        1,302,506.75  
 
           
8
  3/10/2008     339,994.87  
9
  6/10/2008     343,019.84  
10
  9/10/2008     348,805.44  
11
  12/10/2008     357,209.07  
2008 Totals
        1,389,029.22  
 
           
12
  3/10/2009     365,623.47  
13
  6/10/2009     366,880.40  
14
  9/10/2009     373,068.45  
15
  12/10/2009     381,613.14  
2009 Totals
        1,487,185.46  
 
           
16
  3/10/2010     390,162.03  
17
  6/10/2010     392,378.14  
18
  9/10/2010     398,996.25  
19
  12/10/2010     407,691.69  
2010 Totals
        1,589,228.11  
 
           
20
  3/10/2011   Entire remaining balance due

 

 

EXHIBIT 10.15

DISTILLER’S GRAIN MARKETING AGREEMENT

     THIS DISTILLER’S GRAIN MARKETING AGREEMENT (the “Agreement”), is entered into effective as of December 1, 2004, by Granite Falls Ethanol LLC, a Minnesota Limited Liability Company (“Seller”), and Commodity Specialist Company, a Delaware corporation (“Buyer”).

WITNESSETH:

     WHEREAS, Seller desires to sell and Buyer desires to purchase the Distiller’s Dried Grains with Solubles (“DDGS”), hereinafter DDGS, output of the ethanol production plant which Seller owns in Granite Falls, Minnesota; and

     WHEREAS, Seller and Buyer wish to agree in advance of such sale and purchase to the price formula, payment, delivery and other terms thereof in consideration of the mutually promised performance of the other;

     NOW, THEREFORE, in consideration of the promises and the mutual covenants and conditions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged by both parties, it is hereby agreed:

     1.  BUYER PERFORMANCE . Buyer agrees to perform the services that it provides for Seller in a professional and competent manner.

     2.  PURCHASE AND SALE . Seller agrees to sell to Buyer and Buyer agrees to purchase from Seller the entire bulk feed grade DDGS, output from Seller’s plant at Granite Falls, Minnesota. (hereinafter the “Plant”) that is shipped from Plant by rail, and so much output that is shipped by truck that Seller in its discretion elects to sell to Buyer, subject to all terms and conditions set forth in this Agreement. Buyer shall label all Product that is sold by Buyer and shall register all labels with the states where the Products are sold.

     3.  TRADE RULES . All purchases and sales made hereunder shall be governed by the Feed Trade Rules of the National Grain and Feed Association unless otherwise specified. Said Trade Rules, a copy of which is appended hereto as Exhibit A, shall, to the extent applicable, be a part of this Agreement as if fully set forth herein.

     4.  TERM . The term of this Agreement shall be for one year commencing as of completion and start-up of production of the Plant. Start-up is anticipated to be October 1, 2005. Thereafter this agreement shall remain in effect until terminated by either party at its unqualified option by providing the other party hereto not less than 90 days written notice of its election to terminate this Agreement.

1


 

     5.  DELIVERY AND TITLE .

          A. The place of delivery for all the Products sold pursuant to this Agreement shall be FOB Plant. Buyer and Buyer’s agents shall be given access to Seller’s Plant in a manner and at all times reasonably necessary and convenient for Buyer to take delivery as provided herein. Buyer shall coordinate the loading and shipping of all outbound Products purchased hereunder which is shipped by truck or rail with Seller. All labor and equipment necessary to load trucks or rail cars shall be supplied by Seller without charge to Buyer. Seller agrees to handle the Products in a good and workmanlike manner in accordance with Buyer’s reasonable requirements and in accordance with normal industry practice. Seller shall maintain the truck and rail loading facilities in safe operating condition in accordance with normal industry standards.

          B. Seller further warrants that storage space for not less than seven days production of DDGS shall be reserved for Buyer’s use at the Plant and shall be continuously available for storage of DDGS purchased by Buyer hereunder at no charge to Buyer. Seller shall be responsible at all times for the quantity, quality and condition of any the Products in storage at the Plant. Seller shall not be responsible for the quantity, quality and condition of any of the Products stored by Buyer at locations other than the Plant.

          C. Buyer shall give to Seller a schedule of quantities of the Products to be removed by truck and rail with sufficient advance notice reasonably to allow Seller to provide the required services. Seller shall provide the labor, equipment and facilities necessary to meet Buyer’s loading schedule and, except for any consequential or indirect damages, shall be responsible for Buyer’s actual costs or damages resulting from Seller’s failure to do so. Buyer shall order and supply trucks and rail cars as scheduled for truck and rail shipments. All freight charges shall be the responsibility of Buyer and shall be billed directly to Buyer.

          D. Buyer shall provide loading orders as necessary to permit Seller to maintain Seller’s usual production schedule, provided, however, that Buyer shall not be responsible for failure to schedule removal of the Products unless Seller shall have provided to Buyer production schedules as follows: Five (5) days prior to the beginning of each calendar month during the term hereof, Seller shall provide to Buyer a tentative schedule for production in the next calendar month. Seller shall inform Buyer daily of inventory and production status. For purposes of this paragraph, notification will be sufficient if made by e-mail or facsimile as follows:

If to Buyer, to the attention of Steve Markham, Facsimile number 612-330-9894 or e-mail to smarkham@csc-world.com, and

If to Seller, to the attention of    . Or to such other representatives of Buyer and Seller as they may designate to the other in writing.

          E. Title, risk of loss and full shipping responsibility shall pass to Buyer upon loading the Products into trucks or rail cars and delivering to Buyer a the bill of lading for each such shipment.

2


 

     6.  PRICE AND PAYMENT

          A. Buyer agrees to pay Seller as follows: for all DDGS removed by Buyer from the Plant a price equal to ninety eight (98%) of the FOB Plant price actually received by Buyer from its customers. For purposes of this provision, the FOB Plant price shall be the actual sale price, less all freight costs incurred by Buyer in delivering the Product to its customer. Buyer agrees that it shall not sell Product for delivery more than 90 days from the date of entering into a sale without the consent of Seller. Buyer agrees to use commercially reasonable efforts to achieve the highest resale price available under prevailing market conditions. Seller’s sole and exclusive remedy for breach of Buyer’s obligations hereunder shall be to terminate this Agreement. Buyer shall collect all applicable state tonnage taxes on Products sold by Buyer and shall remit to the appropriate governmental agency.

          B. Within three (3) business days following receipt of certified weight certificates, which certificates shall be presented to Buyer each Thursday for all shipments during the preceding week, Buyer shall pay Seller the full price, determined pursuant to paragraph 6A above, for all properly documented shipments. Buyer agrees to maintain accurate sales records and to provide such records to Seller upon request. Seller shall have the option to audit Buyer’s sales invoices at any time during normal business hours and during the term of this Agreement. If any such audit shall reveal a deficiency together with interest from the date that such payment should have been made at the prime rate then in effect as reported in the Wall Street Journal.

     7.  QUANTITY AND WEIGHTS .

          A. It is understood that the output of the Products shall be determined by Seller’s production schedule and that no warranty or representation has been made by Seller as to the exact quantities of Products to be sold pursuant to this Agreement.

          B. The quantity of Products delivered to Buyer from Seller’s Plant shall be established by weight certificates obtained from scale at the Plant which is certified as of the time of weighing and which complies with all applicable laws, rules and regulations or in the event that the scale at the Plant is inoperable then at other scales which are certified as of the time of weighing and which comply with all applicable laws, rules and regulations. The outbound weight certificates shall be determinative of the quantity of the Products for which Buyer is obligated to pay pursuant to Section 5.

     8.  QUALITY .

          A. Seller understands that Buyer intends to sell the Products purchased from Seller as a primary animal feed ingredient and that said Products are subject to minimum quality standards for such use. Seller agrees and warrants that the Products produced at its plant and delivered to Buyer shall be accepted in the feed trade under current industry standards.

3


 

          B. Seller warrants that all Products, unless the parties agree otherwise, sold to Buyer hereunder shall, at the time of delivery to Buyer, conform to the following minimum quality standard:

                                                                                 
    Protein     Fat     Fiber     Moisture     Ash  
    Min     Max     Min     Max     Min     Max     Min     Max     Min     Max  
DDGS
    27               10                       15               12               6  

The standard for DDGS will be determined on an as is basis per original sample rather than a dry weight basis.

          C. Seller warrants that at the time of loading, the Products will not be adulterated or misbranded within the meaning of the Federal Food, Drug and Cosmetic Act and that each shipment may lawfully be introduced into interstate commerce under said Act. Payment of invoice does not waive Buyer’s rights if goods do not comply with terms or specifications of this Agreement. Unless otherwise agreed between the parties to this Agreement, and in addition to other remedies permitted by law, the Buyer may, without obligation to pay, reject either before or after delivery, any of the Products which when inspected or used fail in a material way to conform to this Agreement. Should any of the Products be seized or condemned by any federal or state department or agency for any reason except noncompliance by Buyer with applicable federal or state requirements, such seizure or condemnation shall operate as a rejection by Buyer of the goods seized or condemned and Buyer shall not be obligated to offer any defense in connection with the seizure or condemnation. When rejection occurs before or after delivery, at its option, Buyer may:

               (1) Dispose of the rejected goods after first offering Seller a reasonable opportunity of examining and taking possession thereof, if the condition of the goods reasonably appears to Buyer to permit such delay in making disposition; or

               (2) Dispose of the rejected goods in any manner directed by Seller which Buyer can accomplish without violation of applicable laws, rules, regulations or property rights; or

               (3) If Buyer has no available means of disposal of rejected goods and Seller fails to direct Buyer to dispose of it as provided herein, Buyer may return the rejected goods to Seller, upon which event Buyer’s obligations with respect to said rejected goods shall be deemed fulfilled. Title and risk of loss shall pass to Seller promptly upon rejection by Buyer.

               (4) Seller shall reimburse Buyer for all costs reasonably incurred by Buyer in storing, transporting, returning and disposing of the rejected goods. Buyer shall have no obligation to pay Seller for rejected goods and may deduct reasonable costs and expenses to be reimbursed by Seller from amounts otherwise owed by Buyer to Seller.

4


 

               (5) If Seller produces Products which comply with the warranty in Section C above but which do not meet applicable industry standards, Buyer agrees to purchase such Products for resale but makes no representation or warranty as to the price at which such Product can be sold. If the Products deviate so severely from industry standard as to be unsalable, then it shall be disposed of in the manner provided for rejected goods in Section C above.

          D. If Seller knows or reasonably suspects that any of the Products produced at its Plant are adulterated or misbranded, or outside of industry quality standards, Seller shall promptly so notify Buyer so that such Product can be tested before entering interstate commerce. If Buyer knows or reasonably suspects that any of the Products produced by Seller at its Plant are adulterated, misbranded or outside of industry quality standards, then Buyer may obtain independent laboratory tests of the affected goods. If such goods are tested and found to comply with all warranties made by Seller herein, then Buyer shall pay all testing costs; and if the goods are found not to comply with such warranties, Seller will pay all testing costs.

     9.  RETENTION OF SAMPLES . Seller will take an origin sample of Products from each truck and rail car before it leaves the Plant using standard sampling methodology. Seller will label these samples to indicate the date of shipment and the truck or railcar number involved. Seller will also retain the samples and labeling information for no less than one year.

     10.  INSURANCE .

          A. All employees engaged in the removal of the Products from Seller’s Plant shall be covered as required by law by worker’s compensation and unemployment compensation insurance.

          B. Seller agrees to maintain throughout every term of this Agreement commercial general liability insurance, including product liability coverage, with combined single limits of not less than $2,000,000. Seller’s policies of comprehensive general liability insurance shall be endorsed to require at least thirty (30) days advance notice to Buyer prior to the effective date of any decrease in or cancellation of coverage. Seller shall cause Buyer to be named as an additional insured on Seller’s insurance policy and shall provide a certificate of insurance to Buyer to establish the coverage maintained by Seller not later than fourteen (14) days prior to completion and start-up of production of the Plant.

          C. Buyer agrees to carry such insurance on its vehicles operating on Seller’s property as Seller reasonably deems appropriate. The parties acknowledge that Buyer may elect to self insure its vehicles. Upon request, Buyer shall provide certificate of insurance to Seller to establish the coverage maintained by Buyer.

          D. Notwithstanding the foregoing, nothing herein shall be construed to constitute a waiver by either party of claims, causes of action or other rights which either party may have or hereafter acquire against the other for damage or injury to its agents, employees, invitees, property, equipment or inventory, or third party claims against the other for damage or injury to

5


 

other persons or the property of others.

11. REPRESENTATIONS AND WARRANTIES

          A. Seller represents and warrants that all of the Products delivered to Buyer shall not be adulterated or misbranded within the meaning of the Federal Food, Drug and Cosmetic Act and may lawfully be introduced into interstate commerce pursuant to the provisions of the Act. Seller further warrants that the Products shall fully comply with any applicable state laws governing quality, naming and labeling of product. Payment of invoice shall not constitute a waiver by Buyer of Buyer’s rights as to goods which do not comply with this Agreement or with applicable laws and regulations.

          B. Seller represents and warrants that the Products delivered to Buyer shall be free and clear of liens and encumbrances.

          C.  EXCEPT AS SPECIFICALLY STATED IN THIS AGREEMENT, SELLER MAKES NO WARRANTY OR REPRESENTATIONS, EXPRESS OR IMPLIED, INCLUDING WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTIBILITY OR FITNESS FOR A PARTICULAR PURPOSE.

     12.  EVENTS OF DEFAULT . The occurrence of any of the following shall be an event of default under this Agreement (“Event of Default”): (1) failure of either party to make payment to the other when due; (2) default by either party in the performance of the covenants and agreements set forth in this Agreement; (3) if either party shall become insolvent, or make a general assignment for the benefit of creditors or to an agent authorized to liquidate any substantial amount of its assets, or be adjudicated bankrupt, or file a petition in bankruptcy, or apply to a court for the appointment of a receiver for any of its assets or properties with or without consent, and such receiver shall not be discharged within sixty (60) days following appointment.

     13.  REMEDIES . Upon the happening of an Event of Default, the parties hereto shall have all remedies available under applicable law with respect to an Event of Default by the other party. Without limiting the foregoing, the parties shall have the following remedies whether in addition to or as one of the remedies otherwise available to them; (1) to declare all amounts owed immediately due and payable; and (2) immediately to terminate this Agreement effective upon receipt by the party in default of the notice of termination, provided, however, the parties shall be allowed 10 days from the date of receipt of notice of default for to cure any default. Notwithstanding any other provision of this Agreement, Buyer may offset against amounts otherwise owed to Seller the price of any product which fails to conform to any requirements of this Agreement.

     14.  FORCE MAJEURE . Neither Seller nor Buyer will be liable to the other for any failure or delay in the performance of any obligation under this Agreement due to events beyond its reasonable control, including, but not limited to, fire, storm, flood, earthquake, explosion, act of the public enemy, riots, civil disorders, sabotage, strikes, lockouts, labor disputes, labor

6


 

shortages, war stoppages or slowdowns initiated by labor, transportation embargoes, failure or shortage of materials, acts of God, or acts or regulations or priorities of the federal, state or local government or branches or agencies thereof.

     15.  INDEMNIFICATION .

          A. Seller shall indemnify, defend and hold Buyer and its officers, directors, employees and agents harmless, from any and all losses, liabilities, damages, expenses (including reasonable attorneys’ fees), costs, claims, demands, that Buyer or its officers, directors, employees or agents may suffer, sustain or become subject to, or as a result of (i) any misrepresentation or breach of warranty, covenant or agreement of Seller contained herein or (ii) the Seller’s negligence or willful misconduct.

          B. Buyer shall indemnify, defend and hold Seller and its officer, directors, employees and agents harmless, from any and all losses, liabilities, damages, expenses (including reasonable attorneys’ fees), costs, claims, demands, that Seller or its officers, directors, employees or agents may suffer, sustain or become subject to, or as a result of (i) any misrepresentation or breach of warranty, covenant or agreement of Buyer contained herein or (ii) the Buyer’s negligence or willful misconduct.

          C. Where such personal injury, death or loss of or damage to property is the result of negligence on the part of both Seller and Buyer, each party’s duty of indemnification shall be in proportion to the percentage of that party’s negligence or faults.

          D. Seller acknowledges that in order to maximize the total revenue to be generated through the sale of the Products, Buyer may take positions by selling Product in anticipation of Seller providing the Products. Notwithstanding the fact that Seller’s obligation is to provide Buyer with the output of the Plant the parties acknowledge that Buyer may suffer losses as a result of positions taken by Buyer if Seller discontinues operations for any reason whatsoever including Force Majeure. Therefore, Seller shall indemnify, defend and hold Buyer and its officers, directors, employees and agents harmless from any and all losses, liabilities, damages, expenses (including reasonable attorney’s fees), costs, claims, demands that Buyer or its officers, directors, employees, or agents may suffer, sustain or become subject to as a result of any sale or purchase of product taken by Buyer in anticipation of Seller delivering the Products hereunder, provided Buyer has taken commercially reasonable steps to avoid the loss. Notwithstanding the above, Seller shall not be liable for any loss resulting from Seller discontinuing operations related to a position taken by Buyer for delivery more than 90 days from the date of entering into a sale without the consent of Seller nor shall Seller be liable to Buyer for any positions taken by Buyer that result in Buyer being over contracted beyond the Seller’s production capacity.

     16.  GOVERNMENTAL ACTION . The parties recognize that the value of the Products could change as a result of various governmental programs, be they foreign or domestic. In the event that a significant value change of the Products as a result of any such governmental program, Buyer may request re-negotiation of the contract price for the Products

7


 

by providing written notice to Seller. Buyer shall be required to demonstrate that the value of the Products has significantly changed in the market. Should such a change take place, the parties agree to negotiate, in good faith, a revised sale price for the Products. If, after a good faith effort, the parties are unable to agree on a new price within the 90 day period immediately following notice to the other party, then in such event and notwithstanding the other provisions hereof, Buyer may terminate this Agreement upon 90 days prior written notice.

     17.  RELATIONSHIP OF PARTIES . This Agreement creates no relationship other than that of buyer and seller between the parties hereto. Specifically, there is no agency, partnership, joint venture or other joint or mutual enterprise or undertaking created hereby. Nothing contained in this Agreement authorizes one party to act for or on behalf of the other and neither party is entitled to commissions from the other.

     18.  MISCELLANEOUS .

          A. This writing is intended by the parties as a final expression of their agreement and a complete and exclusive statement of the terms thereof.

          B. No course of prior dealings between the parties and no usage of trade, except where expressly incorporated by reference, shall be relevant or admissible to supplement, explain, or vary any of the terms of this Agreement.

          C. Acceptance of, or acquiescence in, a course of performance rendered under this or any prior agreement shall not be relevant or admissible to determine the meaning of this Agreement even though the accepting or acquiescing party has knowledge of the nature or the performance and an opportunity to make objection.

          D. No representations, understandings or agreements have been made or relied upon in the making of this Agreement other than as specifically set forth herein.

          E. This Agreement can only be modified by a writing signed by all of the parties or their duly authorized agents.

          F. The paragraph headings herein are for reference purposes only and shall not in any way affect the meaning or interpretation of this Agreement.

          G. This Agreement shall be construed and performed in accordance with the laws of the State of Minnesota.

          H. The respective rights, obligations and liabilities of the parties under this Agreement are not assignable or delegable without the prior written consent of the other party.

          I. Notice shall be deemed to have been given to the party to whom it is addressed ninety-six (96) hours after it is deposited in certified U.S. mail, postage prepaid, return receipt requested, addressed as follows:

8


 

     
 
Buyer: Commodity Specialist Company
  310 Grain Exchange Bldg.
  400 South Fourth Street,
  Minneapolis, MN 55415
  ATTN: Steve J. Markham
 
   
 
Seller: Granite Falls Ethanol LLC

     IN WITNESS THEREOF, the parties have caused this Agreement to be executed the day and year first above written.

         
      COMMODITY SPECIALISTS COMPANY
       
      By   /s/ Philip Lindau
      Its  EVP
       
      Granite Falls Ethanol LLC
       
      By  /s/ Thomas E. Branhan
      Its  CEO / General Manager

9

 

EXHIBIT 10.16

August 8, 2004

Via Mail / Fax: 612-330-9894

Mr. Steve Markham
Senior Merchandiser
Commodity Specialists Co.
310 South Bldg.
Grain Exchange Bldg.
301 Fourth Ave. South
Minneapolis, MN 55415

Dear Steve:

     We are pleased to update this proposal covering 100-150 new 6351 cubic foot covered hopper cars for the Granite Falls plant.

     Thank you for your continued interest in these hopper cars. The following proposal will demonstrate Trinity Rail’s ability to meet this current need for hopper cars required by CSC and your DDG customers.
         
  Sincerely,


/s/ Kerry Stokes
Kerry Stokes
Vice President, Sales
Trinity Rail Group, LLC
D40201
 
 
     
     
     
 

     
cc:
  Tim Schitter
Kimberly Myers
 
Enc:
  Specifications to follow

 


 

     
PRICING AND TERMS
   
 
CUSTOMER
  Commodity Specialists Company
 
CAR DESCRIPTION
  6351 Cubic foot capacity, 286,000 lb.
GRL Covered Hopper car with 24”
Trough Hatch and (4) 30” X 30” Gravity
Gates, per Trinity Rail Specification
Number L-40433 dated July 23, 2004 to
follow under separate cover.
 
QUANTITY
  75 Cars
 
FULL SERVICE LEASE PROPOSAL
  $640 per month for a 5 year term
 
LEASE RATE PER CAR
  $625 per month for a 7 year term

The lease rates offered herein are based upon current steel and other raw material costs of our manufacturing affiliate which may fluctuate subsequent to this offer. As such, we reserve the right to adjust the offered lease rate $0.90 for each $100 in additional costs incurred by our manufacturing affiliate directly or indirectly as a result of cost increases in steel or other raw materials. Any such adjustment will be communicated in writing to you and will be reflected in the effective lease rate determined on or before the date of delivery of any cars ordered pursuant to this offer.

     
TERMS AND CONDITIONS
  The terms and conditions of the lease offer
will be governed by the Trinity Industries
Leasing Company (“TILC”) lease agreement.
 
DELIVERY
  Commencing July 05 /s/ Branjam
Deliver is to Granite Falls, MN Freight
Included in lease rate offered.

 


 

PROPOSAL CONDITIONS AND QUALIFICATIONS

This proposal is subject to modifications or adjustments due to changes arising from a final agreement on the specification of the subject equipment. This agreement is expected to result from an engineering and production-planning meeting between Commodity Specialists Co and Trinity Rail. The adjustments, if any, may include, but are not limited to sales price or lease rates, car specifications and delivery quoted.

The manufacturing and administrative processes will be in accordance with Trinity AAR-Certified Quality Assurance System. Steel surface and exterior coatings are quoted in accordance with Trinity Quality Standards QS-1024, QS-1026 and QS-1038 (to be discussed during specification review meeting).

This offer is subject to the TILC Lease Agreement or Trinity Terms and Conditions. Any agreement will be subject to Trinity credit approval. Delivery timing will be subject to prior commitment of production space. This proposal is valid until August 30,2004.

For your convenience, a space is provided below which allows you to select your option and sign the proposal to confirm your order. The confirmed order can be faxed to our office at 530-571-5724.

AGREED AND ACCEPTED BY:
COMMODITY SPECIALISTS COMPANY
         
/s/ Tom Branham
Signature


TOM BRANHAM
Printed Name


CEO/General Manager
Title


8-13-04
Date
 
 

 

 

EXHIBIT 10.17

JOB OPPORTUNITY BUILDING ZONE
BUSINESS SUBSIDY AGREEMENT

     This Agreement is made on September 20, 2004, (the “Approval Date”), by and between the City of Granite Falls, Minnesota, a Minnesota municipal corporation and statutory city, (the “City”); and Granite Falls Energy, a Minnesota limited liability company and a trade or business organized and operating under the laws of the State of Minnesota (the “Qualified Business”). In order to satisfy the provisions of the Job Opportunity Building Zone Law (Minnesota Statutes, Sections 469.310 through 469.320) and the Business Subsidy Law (Minnesota Statutes, Sections 116J.993 through 116J.995), the City and the Qualified Business acknowledge and agree as follows:

     Whereas, the Qualified Business is the owner of the real property located at 15045 Highway 23 S.E. in the City of Granite Falls, Chippewa and Yellow Medicine Counties, Minnesota, as described in Exhibit A (the “Property”);

     Whereas, the Property is located within a designated Job Opportunity Building Zone, as described in the Granite Falls Community Ethanol Plant Zone Application; and is currently comprised of vacant land;

     Whereas, the Qualified Business has been identified by the Subzone Administrator as a non-retail, non-commercial new trade or business start-up within the Subzone;

     Whereas, the Qualified Business began business operations in the subzone on August 15, 2004 when it commence site preparation of the Property;

     Whereas, the Qualified Business agrees to satisfy the provisions of the business subsidy reporting requirements under the Business Subsidy Law and as required by Minnesota Statutes, Section 469.320 Subd. 1 identified in Article II of this Agreement.

ARTICLE I

DEFINITIONS

     Section 1.1. “Agreement” means this Job Opportunity Building Zone Business Subsidy Agreement by and between the City and the Qualified Business.

     Section 1.2. “Approval Date” means the date on which the last party to this Agreement whose signature is required, signs the agreement as indicated in the first paragraph of this Agreement; and after which a Qualified Business is deemed approved by the City.

     Section 1.3. “Benefit Date” is the date after which tax benefits shall begin to accrue to the Qualified Business; for purposes of this Agreement, August 15, 2004.

     Section 1.4. “Business Subsidy” means tax exemptions or tax credits available to the Qualified Business located in the Zone as provided in Section 2.1, and/or any state or local government agency grant, contribution of personal property, real property, infrastructure, the

 


 

principal amount of a loan at rates below those commercially available to the recipient, any reduction or deferral of any tax or any fee, any guarantee of any payment under any loan, lease, or other obligation, or any preferential use of government facilities given to a business, and as defined by the Business Subsidy statute.

     Section 1.5. “Business Subsidy Law” means Minnesota Statutes, Sections 116J.993 through 116J.995.

     Section 1.6. “Business Subsidy Report” means the annual report required to comply with Minnesota Statutes, Section 116J.994, Subd. 7(b).

     Section 1.7. “Capital Investment” means any investment that is defined as depreciable for purposes of the U.S. Internal Revenue Service.

     Section 1.8. “City” means the City of Granite Falls, Minnesota which is also a “Grantor” as defined in Minnesota Statutes, Section 116J.993, Subd. 4.

     Section 1.9. “Construction Plans” means the plans, specifications, drawings and related documents of the construction work to be performed by the Qualified Business on the Project and the Property and the plans (a) shall be as detailed as the plans, specifications drawings and related documents which are submitted to the building inspector of the City, and (b) shall include at least the following: (1) site plan; (2) foundation plan; (3) basement plans, if any; (4) floor plan for each floor; (5) cross sections of each (length and width); (6) elevations (all sides); (7) grading and drainage; and (8) landscape;

     Section 1.10. “DEED” means Minnesota Department of Employment and Economic Development.

     Section 1.11. “Job Zone Term” shall mean January 1, 2004 through December 31, 2015.

     Section 1.12. “JOBZ” means Job Opportunity Building Zone as defined in Minnesota Statutes, Section 469.310.

     Section 1.13. “JOBZ Law” means Minnesota Statutes, Sections 469.310 through 469.320.

     Section 1.14. “Person” includes an individual, corporation, partnership, limited liability company, association, or any other entity.

     Section 1.15. “Project” means the approximately 40,000,000 gallon per year dry mill ethanol production plant to be constructed by the Qualified Business on the Property.

     Section 1.16. “Property” means the parcel or parcels located within the Subzone, as modified, on which the Qualified Business is or will be operating, excluding any building footprint of a business operating in the Subzone prior to January 1, 2004; and as identified in Exhibit A.

2


 

     Section 1.17. “Qualified Business” means, generally, a person that carries on a trade or business at a place of business located within a Job Opportunity Building Zone as referenced in Minnesota Statutes, Section 469.310 Subd. 11; and, for purposes of this Agreement, means Granite Falls Energy

     Section 1.18. “Recipient” means any business entity that receives a business subsidy as defined by Minnesota Statutes, Section 116J.993, and that has signed a Business Subsidy Agreement with a “Grantor” as defined in Minnesota Statutes, Section 116J.993, Subd. 4.

     Section 1.19. “Relocation Agreement” means a binding written agreement between a relocating qualified business and the commissioner of DEED pledging that the qualified business will either:

          (1) increase full-time for full-time equivalent employment in the first full year of operation within the job opportunity building zone by at least 20 percent and maintains that level of employment for the Job Zone Term, or

          (2) make a Capital Investment on the property equivalent to 10% of the gross revenues of operation that was relocated in the immediately preceding taxable year;

     and provides for repayment of all tax benefits if the requirements of (a) or (b) are not met.

     Section 1.20. “Subzone” means the parcel or parcel of land designated by the Commissioner of Employment and Economic Development within the Zone within the boundaries of the City of Granite Falls to receive certain tax credits and exemptions specified under Minnesota Statutes, Sections 469.310 through 469.320.

     Section 1.21. “Subzone Administrator” means the Community Development Director or such other person who has been designated by the City to administer the Subzone.

     Section 1.22. “Unavoidable Delays” means delays, outside the control of the party claiming its occurrence, which are the direct result of strikes, other labor troubles, unusually severe or prolonged bad weather, acts of God, fire or other casualty to the Project, litigation commenced by third parties which, by injunction or other similar judicial action or by the exercise of reasonable discretion, directly results in delays, or acts of any federal, state or local governmental unit (other than the City) which directly result in delays.

     Section 1.23. “Zone” means, generally, a Job Opportunity Building Zone or an Agricultural Processing Facility Zone designated by the commissioner of Employment and Economic Development under Minnesota Statutes, Section 469.314; and, for purposes of this Agreement, the Granite Falls Community Ethanol Plant Zone.

3


 

ARTICLE II

BUSINESS SUBSIDY REQUIREMENTS

     Whereas, compliance with provisions of the Minnesota Business Subsidy Law requires the following and the parties agree that:

     Section 2.1. The Business Subsidy shall include all tax exemptions, job credits or other business subsidies provided from January 1, 2004 until the last date of the Job Zone Term, including but not limited to:

          (a) Exemption from individual income taxes as provided under Minnesota Statutes, Section 469.316, provided to the individuals operating and having made a qualifying investment in the Qualified Business; and

          (b) Exemption from corporate franchise taxes as provided under Minnesota Statutes, Section 469.317; and

          (c) Exemption from the state sales and use tax and any local sales and use taxes on qualifying purchases as provided in Minnesota Statutes, Section 297A.68, subdivision 37; and

          (d) Exemption from the state sales tax on motor vehicles and any local sales tax on motor vehicles as provided under Minnesota Statutes, Section 297B.03; and

          (e) Exemption from the property tax as provided in Minnesota Statutes, Section 272.02, subdivision 64; and

          (f) Exemption from the wind energy production tax under Minnesota Statutes, Section 272.029, subdivision 7; and

          (g) The jobs credit allowed under Minnesota Statutes, Section 469.318.

     Section 2.2. Other business subsidies provided to the Qualified Business, as described in the Business Subsidy statute at Minnesota Statutes, Sections 116J.993 through 116J.995, shall be identified, including the amounts and type of subsidy provided, specifically:

          (a) A no interest loan provided by the City or its Economic Development Authority in the aggregate principal amount of $500,000.

          (b) A three 3% low interest loan provided by the City, its Economic Development Authority or other governmental entity or entities in the aggregate principal amount of $100,000.

          (c) A 5% interest West Minnesota Revolving Loan Fund loan provided by the Upper Minnesota Valley Regional Development Commission in the aggregate principal amount of $110,000.

4


 

     Section 2.3. The public purposes for the Business Subsidy agreed to by the parties hereto shall include, but not be limited to:

          (a) The enhancement of economic growth and diversity;

          (b) The retention of jobs and high quality job growth; and

          (c) Stabilizing the community by putting vacant land to use.

     Section 2.4. The measurable, specific, and tangible goals for the Business Subsidy shall include:

          (a) In accordance with the Business Subsidy Law, the Qualified Business shall create at least 10 new full-time equivalent positions within the Subzone boundaries at an average wage of at least $10.00 per hour within fourteen months of the Benefit Date and at least 10 additional new full-time equivalent positions within the Subzone boundaries at an average wage of at least $10.00 per hour within two years of the Benefit Date for a total of 20 full-time equivalent jobs within two years of the Benefit Date.

          (b) In addition, the Qualified Business shall create at least 10 additional new full-time equivalent positions within the Subzone boundaries at an average wage of at least $10.00 per hour within three years of the Benefit Date for a total of 30 full-time equivalent jobs within three years of the Benefit Date.

     Section 2.5. The City has adopted, after holding a properly noticed public hearing, a Business Subsidy Policy identifying the criteria that a Recipient must meet in order to be eligible to receive a Business Subsidy as required by Minnesota Statutes, Section 116J.994, Subd. 2. The City has submitted a copy of the criteria to the Department of Employment and Economic Development along with the first annual report.

     Section 2.6. A properly noticed public hearing was held by the City’s Economic Development Authority on the Business Subsidy by the City on September 15, 2004 as required by Minnesota Statutes, Section 116J.994, Subd. 5.

     Section 2.7. If the goals set forth in Section 2.4(a) (the “Goals”) are not met or the Qualified Business ceases operations on the Property during the Job Zone Term, the Qualified Business agrees to repay the amount of the total tax reduction pursuant to Section 2.1(a) through (f) and any refund under pursuant to Section 2.1(g) in excess of tax liability, received during the two years immediately before it ceased to operate in the Zone to the Minnesota Department of Revenue or Chippewa County (in the case of property or county sales tax reductions) or the City of Granite Falls (in the case of city sales tax reductions), as required by Minnesota Statutes, Section 469.319.

     Section 2.8. If the Goals set forth in Section 2.4(a) are not met, the Qualified Business agrees to repay all or a part of the Business Subsidy (including but not limited to the total tax reduction and any refund in excess of tax liability) to the City, plus interest (“Interest”) set at the implicit price deflator defined in Minnesota Statutes, Section 275.70, Subd. 2, accruing from and after the Benefit Date, compounded semiannually. If the Goals are met in part, the Qualified

5


 

Business will repay a portion of the Business Subsidy (plus Interest) determined by multiplying the Business Subsidy by a fraction, the numerator of which is the number of jobs in the Goals which were not created at the wage level set forth above and the denominator of which is 20 (i.e. number of jobs set forth in Section 2.4(a)), as required by Minnesota Statutes, Section 116J.994, Subd. 6; provided, however, the City agrees that if Section 469.319 of the JOBZ Law is subsequently interpreted by the Commissioner of Revenue or a court of competent jurisdiction or amended by the legislature in a manner that would indicate that Section 469.319 of the JOBZ Law supercedes Section 116J.994, Subd. 6 of the Business Subsidy Law, the City will waive the repayment provisions of this Section 2.8.

     Section 2.9. The Qualified Business shall continue operations on the Property for at least twelve (12) years after the Benefit Date.

     Section 2.10. The Qualified Business agrees to (i) report its progress on achieving the Goals to the City until the later of the date the Goals are met or the end of the JOBZ term, or, if the Goals are not met, until the date the Business Subsidy is repaid, (ii) include in the report the information required in Minnesota Statutes, Section 116J.994, Subd. 7 on forms developed by DEED, and (iii) send completed reports to the City. The Qualified Business agrees to file these reports no later than March 1 of each year commencing March 1, 2005, and within 30 days after the deadline for meeting the Goals. The City agrees that if it does not receive the reports, it will mail the Qualified Business a warning within one week of the required filing date. If within 14 days of the post marked date of the warning the reports are not made, the Qualified Business agrees to pay to the City a penalty of $100 for each subsequent day until the report is filed up to a maximum of $1,000, as required in Minnesota Statutes, Section 116J.994, Subd. 7.

     Section 2.11. The City will provide the Qualified Business with all of the local tax benefits and property tax benefits permitted under Minnesota Statutes, Section 469.315.

     Section 2.12. The Qualified Business receiving sales tax exemptions provided under Minnesota Statutes, Section 297A.68, subdivision 37(b) and (c) and (d) shall comply with prevailing wages requirements under Minnesota Statutes, Section 116J.871 to the extent projects were not bid prior to May 2004.

     Section 2.13. During the Job Zone Term, the Qualified Business shall not sell, lease, assign or otherwise convey its interest in the Property without the prior written consent of the City, which shall not be unreasonably withheld.

ARTICLE III

REPRESENTATIONS, WARRANTIES AND ADDITIONAL COVENANTS OF THE QUALIFIED BUSINESS

     Section 3.1. The Qualified Business makes the following representations and warranties:

          (a) The Qualified Business is a Minnesota limited liability company and has the power and authority to conduct business within the State, to enter into this Agreement and to

6


 

perform its obligations hereunder and is not in violation of its articles, operating agreement or member control agreement or the laws of the State.

          (b) Neither the execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, nor the fulfillment of or compliance with the terms and conditions of this Agreement is prevented, limited by or conflicts with or results in a breach of, the terms, conditions or provision of any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which the Qualified Business is now a party or by which it is bound, or constitutes a default under any of the foregoing.

          (c) The Qualified Business has conducted its own independent investigations into the requirements of the JOBZ Law and the process taken by the City to approve the business subsidy agreement.

     Section 3.2. The Qualified Business shall pay the City’s administrative costs for initial review, including the fees of the City’s legal counsel and fiscal consultants, and for participation in the program as well as annual fees for monitoring and reporting as required by the JOBZ Law or the Business Subsidy Law.

     Section 3.3. The Qualified Business will cooperate fully with the City with respect to any litigation commenced with respect to the Project.

     Section 3.4. The Qualified Business will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety or public nuisance problems which may arise in connection with the operation of the Project.

     Section 3.5. If the Qualified Business fails to observe or perform any covenant, condition, obligation or agreement on their part to be observed or performed under this Agreement and such failure continues for more than 30 days after notice of such failure from the City, and if the City employs attorneys or incurs other expenses for the collection of payments due or to become due or for the enforcement or performance or observance of any obligation or agreement on the part of the Qualified Business herein contained, the Qualified Business agrees that it shall, on demand therefor, pay to the City the reasonable fees of such attorneys and such other expenses so incurred by the City.

     Section 3.6. (a) The Qualified Business covenants and agrees that the City, its governing body members, officers, agents, including the independent contractors, consultants and legal counsel, servants and employees thereof (hereinafter, for purposes of this Section, collectively the “Indemnified Parties”) shall not be liable for and agrees to indemnify and hold harmless the Indemnified Parties against any loss or damage to property or any injury to or death of any person occurring at or about or resulting from any defect in the Project, provided that the foregoing indemnification shall not be effective for any actions of the Indemnified Parties that are not contemplated by this Agreement.

          (b) Except for any willful misrepresentation or any willful or wanton misconduct of the Indemnified Parties, the Qualified Business agrees to protect and defend the Indemnified Parties, now and forever, and further agrees to hold the Indemnified Parties harmless from any claim, demand, suit, action or other proceeding whatsoever by any person or

7


 

entity whatsoever arising or purportedly arising from the actions or inactions of the Qualified Business (or if other persons acting on its behalf or under its direction or control) under this Agreement, or the transactions contemplated hereby or the acquisition, construction, installation, ownership, and operation of the Project; provided, that this indemnification shall not apply to the warranties made or obligations undertaken by the City in this Agreement or to any actions undertaken by the City which are not contemplated by this Agreement.

          (c) The Qualified Business agrees to protect and defend the Indemnified Parties, now and forever, and further agrees to hold the Indemnified Parties harmless from any claim, demand, suit, action or other proceeding whatsoever by any person or entity whatsoever in the event that the agreement is found to be invalid, or Chippewa County or the State of Minnesota fails to make any required or expected payment or benefit to the Qualified Business.

          (d) All covenants, stipulations, promises, agreements and obligations of the City contained herein shall be deemed to be the covenants, stipulations, promises, agreements and obligations of the City and not of any governing body member, officer, agent, servant or employee of the City.

ARTICLE IV

EVENTS OF DEFAULT

     Section 4.1. The following shall be “Events of Default” under this Agreement and the term “Event of Default” shall mean whenever it is used in this Agreement any one or more of the following events:

          (a) Failure by the Qualified Business to construct the Project pursuant to the terms, conditions and limitations of this Agreement.

          (b) Failure of the Qualified Business to observe or perform any other covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement.

          (c) If the Qualified Business shall:

          (1) file any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the United States Bankruptcy Act of 1978, as amended or under any similar federal or state law; or

          (2) make an assignment for the benefit of its creditors; or

          (3) admit in writing its inability to pay its debts generally as they become due; or

          (4) be adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of the Qualified Business as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall

8


 

be filed in any court and such petition or answer shall not be discharged or denied within sixty (60) days after the filing thereof; or a receiver, trustee or liquidator of the Qualified Business, or of the Project, or part thereof, shall be appointed in any proceeding brought against the Qualified Business, and shall not be discharged within sixty (60) days after such appointment, or if the Qualified Business, shall consent to or acquiesce in such appointment.

     Section 4.2. Whenever any Event of Default referred to in Section 4.1 occurs and is continuing, the City, as specified below, may take any one or more of the following actions after the giving of thirty (30) days’ written notice to the Qualified Business, but only if the Event of Default has not been cured within said thirty (30) days:

          (a) The City may cancel and rescind the Agreement.

          (b) The City may take any action, including legal or administrative action, in law or equity, which may appear necessary or desirable to enforce performance and observance of any obligation, agreement, or covenant of the Qualified Business under this Agreement.

     Section 4.3. No remedy herein conferred upon or reserved to the City is intended to be exclusive of any other available remedy or remedies, but each and every such remedy shall be cumulative and shall be in addition to every other remedy given under this Agreement or now or hereafter existing at law or in equity or by statute. No delay or omission to exercise any right or power accruing upon any default shall impair any such right or power or shall be construed to be a waiver thereof, but any such right and power may be exercised from time to time and as often as may be deemed expedient.

     Section 4.4. In the event any agreement contained in this Agreement should be breached by any party and thereafter waived by any other party, such waiver shall be limited to the particular breach so waived and shall not be deemed to waive any other concurrent, previous or subsequent breach hereunder.

     Section 4.5. Whenever any Event of Default occurs and the City shall employ attorneys or incur other expenses for the collection of payments due or to become due or for the enforcement or performance or observance of any obligation or agreement on the part of the Qualified Business herein contained, the Qualified Business agrees that it shall, on demand therefor, pay to the City the reasonable fees of such attorneys and such other expenses so incurred by the City.

ARTICLE V

MISCELLANEOUS

     Section 5.1. Any titles of the several parts, articles and sections of the Agreement are inserted for convenience of reference only and shall be disregarded in construing or interpreting any of its provisions.

     Section 5.2. Except as otherwise expressly provided in this Agreement, a notice, demand or other communication under this Agreement by any party to any other shall be

9


 

sufficiently given or delivered if it is dispatched by registered or certified mail, postage prepaid, return receipt requested, or delivered personally, and

          (a) in the case of the Qualified Business is addressed to or delivered personally to:

     
  Granite Falls Energy
  P.O. Box 216
  Granite Falls, MN 56241-0216
  Telephone Number: (320) 564-3100

          (b) in the case of the City is addressed to or delivered personally to the City at:

     
  City of Granite Falls, Minnesota
  885 Prentice Street
  Granite Falls, MN 56241-1520
  Phone: (320) 564-3011

     or at such other address with respect to any such party as that party may, from time to time, designate in writing and forward to the other, as provided in this Section.

     Section 5.3. This Agreement may be executed in any number of counterparts, each of which shall constitute one and the same instrument.

     Section 5.4. This Agreement will be governed and construed in accordance with the laws of the State of Minnesota.

     Section 5.5. This agreement shall become effective upon its Approval Date and shall expire upon the expiration of the Job Zone Term, unless earlier terminated or rescinded in accordance with its terms.

     Section 5.6. In the event the JOBZ Law is repealed or substantially modified, the City shall have no obligations under this Agreement except to the extent authorized by law.

10


 

     IN WITNESS WHEREOF, the City and the Qualified Business have acknowledged their assent to this agreement and agree to be bound by its terms through the signatures entered below:

         
  GRANITE FALLS ENERGY
       
  By         /s/ Tom Branhan
     
  Title         CEO/General Manager
     
  Date         10-16-04
     

S-1


 

             
      CITY OF GRANITE FALLS, MINNESOTA
           
      By /s/ David Smiglewski
        Its Mayor
           
      Attes ted By William P. Lavin
        Its Manager
           
      Date October 19, 2004

S-2


 

Exhibit A

     Approximately 56 acres of real property located in Chippewa County, Minnesota described as:

     The Northeast Quarter of the Northeast Quarter (NE 1 / 4 NE 1 / 4 ) and part of the East one-half of the Northeast Quarter (E 1 / 2 NE 1 / 4 ) of Section One (1), Township One Hundred Fifteen (115), Range Thirty-nine (39), excepting therefrom the right of way of Minnesota Highway 23.

A-1

 

Exhibit 31

CERTIFICATION PURSUANT TO
SECTION 302 OF THE SARBANES-OXLEY ACT OF 2002

I, Thomas Branhan, certify that:

1.   I have reviewed this annual report on Form 10-KSB of Granite Falls Community Ethanol Plant, LLC;

2.   Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

3.   Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the Registrant as of, and for, the periods presented in this report;

4.   The Registrant’s other certifying officers and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e) for the Registrant and have:

  a)   designed such disclosure controls and procedures, or caused such disclosure controls and procedures, to ensure that material information relating to the Registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
 
  b)   evaluated the effectiveness of the Registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report, based on such evaluation; and
 
  c)   disclosed in this report any change in the Registrant’s internal control over financial reporting that occurred during the Registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the Registrant’s internal control over financial reporting; and

5.   The Registrant’s other certifying officers and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the Registrant’s auditors and the audit committee of the Registrant’s board of governors (or persons performing the equivalent functions):

  a)   all significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the Registrant’s ability to record, process, summarize and report financial information; and
 
  b)   any fraud, whether or not material, that involves management or other employees who have a significant role in the Registrant’s internal control over financial reporting.

Date: March 31, 2005 /s/ Thomas Branhan
  Thomas Branhan
Chief Executive Officer and
General Manager
(Principal Executive Officer)


 

CERTIFICATION PURSUANT TO
SECTION 302 OF THE SARBANES-OXLEY ACT OF 2002

I, Michael Nealon, certify that:

1.   I have reviewed this annual report on Form 10-KSB of Granite Falls Community Ethanol Plant, LLC;

2.   Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

3.   Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the Registrant as of, and for, the periods presented in this report;

4.   The Registrant’s other certifying officers and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e) for the Registrant and have:

  a)   designed such disclosure controls and procedures, or caused such disclosure controls and procedures, to ensure that material information relating to the Registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
 
  b)   evaluated the effectiveness of the Registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report, based on such evaluation; and
 
  c)   disclosed in this report any change in the Registrant’s internal control over financial reporting that occurred during the Registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the Registrant’s internal control over financial reporting; and

5.   The Registrant’s other certifying officers and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the Registrant’s auditors and the audit committee of the Registrant’s board of governors (or persons performing the equivalent functions):

  a)   all significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the Registrant’s ability to record, process, summarize and report financial information; and
 
  b)   any fraud, whether or not material, that involves management or other employees who have a significant role in the Registrant’s internal control over financial reporting.

     
Date: March 31, 2005
  /s/ Michael Nealon
  Michael Nealon
  Chief Financial Officer and Controller
  ( Principal Accounting Officer)
 

Exhibit 32

CERTIFICATION PURSUANT TO
18 U.S.C. SECTION 1350
AS ADOPTED PURSUANT TO
SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002

In connection with the Annual Report of Granite Falls Community Ethanol Plant, LLC (the “Company”) on Form 10-KSB for the period ended December 31, 2004, as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I Thomas Branhan, Chief Executive Officer and General Manager certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that:

(1)   The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and

(2)   The information contained in the accompanying Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

     
Date: March 31, 2005
  /s/ Thomas Branhan
  Thomas Branhan
  Chief Executive Officer and General Manager
  (Principal Executive Officer)

CERTIFICATION PURSUANT TO
18 U.S.C. SECTION 1350
AS ADOPTED PURSUANT TO
SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002

In connection with the Annual Report of Granite Falls Community Ethanol Plant, LLC (the “Company”) on Form 10-KSB for the period ended December 31, 2004, as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, Michael Nealon, Chief Financial Officer and Controller of the Company, certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that:

(1)   The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and

(2)   The information contained in the accompanying Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

     
Date: March 31, 2005
  /s/ Michael Nealon
  Michael Nealon
  Chief Financial Officer and Controller
  (Principal Accounting Officer)