Delaware
|
001-34600
|
26-2593535
|
||
(State or other jurisdiction of incorporation)
|
(Commission
File Number)
|
(IRS Employer
Identification No.)
|
£
|
Written communications pursuant to Rule 425 under the Securities Act (17 CFR 230.425)
|
£
|
Soliciting material pursuant to Rule 14a-12 under the Exchange Act (17 CFR 240.14a-12)
|
£
|
Pre-commencement communications pursuant to Rule 14d-2(b) under the Exchange Act (17 CFR 240.14d-2(b))
|
£
|
Pre-commencement communications pursuant to Rule 13e-4(c) under the Exchange Act (17 CFR 240.13e-4(c))
|
ITEM 1.01
|
ENTRY INTO A MATERIAL DEFINITIVE AGREEMENT
|
ITEM 1.02
|
TERMINATION OF A MATERIAL DEFINITIVE AGREEMENT
|
ITEM 3.02
|
UNREGISTERED SALES OF EQUITY SECURITIES
|
ITEM 9.01
|
FINANCIAL STATEMENTS AND EXHIBITS.
|
(d)
|
Exhibits
|
Date: November 16, 2011
|
Oxygen Biotherapeutics, Inc.
|
|
By: |
/s/
Michael B. Jebsen
|
|
Michael B. Jebsen
|
||
Chief Financial Officer and Interim Chief Executive Officer
|
OXYGEN BIOTHERAPEUTICS, INC. | |||
By:
|
/s/ Michael Jebsen
|
||
Name:
|
Michael Jebsen
|
||
Title:
|
President, Chief Financial Officer
|
JP SPC 1 VATEA, SEGREGATED PORTFOLIO | |||
By:
|
/s/ Gregory Pepin
|
||
Name:
|
Gregory Pepin
|
||
Title:
|
Investment Manager
|
A. | Project Title/Number: | cGMP Production Services | ||
B. | Bioserv Contact: | Kevin Koziatek | Vice President of Sales, North America | |
+1.314.575.0051 | Kevin.koziatek@gmail.com | |||
C. | Oxygen Biotherapeutics Contact: | Scott Webb Ph.D., MBA | Director, Pharmaceutical Research & Development | |
D. | Services to be performed and associated prices, not including raw material component, in-process testing, release testing, and additional costs | |||
E.
|
Schedule of services: | |||
o | Target Start Date: | TBD | ||
o | Target Completion Date: | TBD | ||
F. | Raw Materials may be provided by Client or procured by Bioserv: See Proposal. | |||
G. | Reports: Bioserv shall provide the following reports to Client: | |||
· | Executed and Client approved cGMP Batch History Records (“BHR”) | |||
· | Technology transfer of analytical methods to specified contract lab | |||
· | Technology Transfer of Client process and product to Bioserv | |||
· | Certificate of Release | |||
H. | Regulatory Jurisdiction: United States | |||
Milestone
1
|
Activity
|
Amount Due
|
Upfront Payment
Milestone 1
|
Full Execution and Approval of Proposal
|
$97,000
|
Milestone 2
|
Successful Installation of Equipment
|
$35,000
|
Milestone 3
|
Approved IQ/OQ/PQ Reports
|
$75,000
|
Milestone 4
|
Approved Sterilizer Validation Report
|
$36,000
|
Milestone 5
|
Acceptance of Feasibility Batch ($20,000 after each)
|
$60,000
|
Milestone 6
|
Release of Clinical Batch ($60,000 after each)
|
$60,000-180,000
|
Milestone 7
|
Release of Final Clinical Batch
|
Remaining
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
Oxygen Biotherapeutics, Inc.
|
Bioserv Corporation
|
|
Dba N
extPharma Technologies USA, Inc.
|
By:
/s/ Michael Jebsen
Print Name:
Michael Jebsen
Title:
President
Date:
November 15, 2011
|
By:
/s/ Martin Sellers
Print Name:
Martin Sellers
Title:
General Manager
Date:
November 15, 2011
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
November 15 th , 2011 | Revision B |
Contact Partner:
Scott Webb Ph.D., MBA
Senior Director, Research & Development
Oxygen Biotherapeutics
One Copley Parkway, Suite 490
Morrisville, North Carolina 27560
|
|
Tel: | 919-855-2103 | ||
email: | s.webb@oxygenbiomed.com | ||
Offer no: | 00047-11-D |
PROPOSAL
|
·
|
Costs are estimates and are based on time, labor and information known at this time which includes the following activities: facility modifications, receipt of equipment, set-up of equipment, create proper cGMP documentation for equipment.
|
·
|
Costs are estimates and based on time and labor known at this time for conducting proper cGMP IQ/OQ/PQ activities that are required for automation equipment.
|
·
|
If there is a change in scope, prices are subject to change.
|
·
|
Each bottle will be individually labeled, stored at Bioserv, and shipped to Client or appropriate Client distributor, in accordance with Client and Bioserv written approval of supplied specifications.
|
·
|
Terminal Sterilization will be accomplished through a validated rotary steam autoclave sterilization cycle at Bioserv.
|
·
|
Some specialized equipment and instruments will be supplied by Client, as itemized in Exhibit A. All equipment or instruments not supplied by Client must be supplied and maintained by Bioserv at Bioserv’s expense.
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
1)
|
Although this material is not defined as hazardous, standard lab safety including particulate mask, goggles, and gloves will be required during the handling of this material. Bioserv requires a MSDS for Client-provided components.
|
2)
|
Validation Services are included in this proposal and includes any added equipment (IQ/OQ) and the process (PQ) services.
|
3)
|
Preparation of the cGMP Batch Master Record and purchased component release specifications (if necessary) will be prepared and is based solely on Client’s protocols and information provided to Bioserv.
|
4)
|
Client materials may be received Client-approved with appropriate release paperwork.
|
5)
|
The manufacturing protocol must be finalized and approved by Client prior to Bioserv executing cGMP production.
|
6)
|
Lead-time for receipt of container/closure and other related production materials will need to be included in scheduling of production.
|
7)
|
Bioserv will not be responsible for any finished product or stability testing. Outsourcing is available for those activities.
|
8)
|
Pricing is in U.S. dollars. If any assumption listed above changes, the pricing for this project is subject to change upon written approval of the Client.
|
9)
|
Shipping and shipping insurance charges are estimated as a separate line item in this proposal located in the Additional Services section.
|
10)
|
Pricing includes maintaining Bioserv-owned Equipment and Accessories (“Bioserv-Owned EquipmentAny breakdown costs, repair costs, and/or routine preventative maintenance costs associated with Client-provided Equipment and Accessories (“Client-Provided Equipment”), as listed in Exhibit A attached hereto and incorporated herein by reference, for a minimum of twenty-four (24) months from date of cGMP Equipment Set Up milestone is achieved will be invoiced to Client at cost + 10%.
|
11)
|
Pass-through costs will be included with final milestone payment invoice. Consumables, listed in Exhibit A, shall initially be provided by Client but subsequent replacements will be included as Pass-through costs.
|
12)
|
Client shall incur no costs for removal of Client-Provided Equipment, including any costs for facility renovation.
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Activity
|
# of Bottles
|
# of Batches
|
Price per Batch
1
|
Price
1
|
Success Criteria
|
What is included
|
cGMP Equipment Set Up
|
$35,000
|
All necessary manufacturing and analytical equipment procured, and all necessary facility modifications complete, as evidenced by updated facility drawings and equipment transfer documentation
|
Cost for all materials other than Client-Provided Equipment and Associated Accessories, personnel labor and time for activities required to receive, install, set-up Client’s equipment, and associated cGMP documentation.
|
|||
cGMP Equipment IQ/OQ/PQ
Services
|
$75,000
|
All necessary manufacturing and analytical equipment, and all necessary facilities comply with cGMP standards, as evidenced by a satisfactory independent compliance audit report
|
Cost for personnel labor and time for conducting all of the necessary IQ/OQ/PQ activities:
Report generation; Execution of Initial Qualification; Execution of Operational Qualification; and Execution of Process Qualification to set up and install Client’s equipment and platforms and writing all cGMP documents (i.e. SOP’s, Training on equipment, etc.)
|
|||
Project Management
|
Included in batch pricing
|
N/A
|
Project Management of all cGMP activities per Batch which includes labor and time involved for ordering, receiving raw materials, shipping and handling of samples to 3
rd
party Analytical Labs, shipping and handling of materials to Client.
|
|||
Sterilization cycle verification
(transfer of cycle)
|
$12,000
|
Sterilization cycle is determined to be effective at loads between 60 and 90 bottles, as evidenced by acceptable F
0
calculation over the entire sterilizer load
|
Cost for personnel labor and time for conducting all of the necessary activities:
·
Generation of study report
·
Perform cycle verification X 3 for temperature mapping
·
Verification cycle with product X 1
·
Summary of finding/ final report
|
|||
Sterilization cycle validation
|
$24,000
|
Sterilization cycle is determined to be effective at loads between 60 and 90 bottles, as evidenced by an Client-approved sterilization validation report
|
Cost for personnel labor and time for conducting all of the necessary sterilization validation activities:
·
Generation of protocol
·
Perform cycle validation X 3 with product from Feasibility batches
·
Validation report summary
|
|||
cGMP Feasibility Batches
|
Up to 100
|
3
|
$39,950
|
$119,850
|
At least two of three batches, one of which must be the final feasibility batch, must meet all then-current product specifications and must be deemed acceptable for release by Client for preclinical supply purposes.
|
Write all cGMP Master Batch Records, Specifications and formatted and finalized as cGMP documentation with Client’s final approval.
Bioserv personnel will receive Client-approved raw materials, inspect, and release to items to WIP Inventory.
Preparation of Parts (Clean Steam Autoclave), if required. All bottles, glassware, and lab ware will be thoroughly washed and dried, and depyrogenated prior to production.
All cGMP Feasibility/Clinical Batches will take place in a Class 100,000 room using a Class 100 hood which includes but is not limited to:
·
Coarse Emulsion Process w/Nitrogen Purge
·
Following In-Process Analytical Protocols
·
Fine Emulsion Process w/Nitrogen Purge
·
Filtration of Fine Emulsion
·
Filling into 130mL Bottles w/Nitrogen Overlay
·
Capping all bottles
·
Terminal Sterilize using Rotary Autoclave
100% Inspection of product per cGMP Master Batch Record
Labeling/Packaging (see Labeling/Packaging Table 2)
Review documentation and release for shipment. Prepare documentation per cGMP Batch Record, if required.
Includes cost of manufacturing labor, utilities to operate general lab equipment, Class 10,000 room use, and campaign cleaning, cost of power, initial environmental monitoring, and room certifications.
|
cGMP Clinical Batches
|
Up to 100
|
2
1
|
$51,920
|
$103,840
|
Each batch must meet all then-current product specifications and be deemed acceptable for release by Client for clinical supply purposes .
|
|
Total Production Services Amount
|
$369,690
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Activity
|
# of Bottles
|
# of Batches
|
Price per Batch
1
|
Total Price
1
|
What is Included
|
Project Management
|
Included in Batch Price
|
Project Management of all cGMP activities per Batch which includes labor and time involved for ordering, receiving raw materials, shipping and handling of samples to 3
rd
party Analytical Labs, shipping and handling of materials to Client.
|
|||
cGMP Labeling Services
|
Up to 100
|
2
2
|
$6,897
|
$13,794
|
Labor to complete the following activities:
Complete all cGMP Master Batch Records, Specifications and formatted and finalized as cGMP documentation with Client’s final approval.
Bioserv personnel will receive work in process (WIP) product from manufacturing to be labeled and packaged in CTS Suite.
Printing and release of labels from text provided by Client
·
Label all Bottles
·
Transfer labeled Bottles into long term controlled temperature storage
Storage of printed materials are locked and secure in a limited access location
cGMP production suite specifically designed for Labeling and Packaging operations
All QA and CTS personnel specially trained in Labeling Services
·
cGMP Batch History Record review and QA release
·
Original copy of the cGMP batch history record and accompanying documentation will be forwarded to Client.
·
Transfer of product to Bioserv’s Long-Term Storage facilities (see cGMP Storage and Distribution Agreement for specific terms and conditions).
|
Total cGMP Labeling Services
|
$13,794
|
Description of Services
|
Unit
|
Cost/Unit
|
Mark-up
|
Comment
|
Raw Materials, Chemicals, Glassware, Labware, Filters, etc
1
|
Each
|
Cost
|
10%
|
|
Hazardous Waste Disposal, < five (5) gallons
2
|
Each
|
$750
|
N/A
|
3
rd
Party
|
Additional charges for change in scope by choices made by Client
|
Hourly
|
$250
|
N/A
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Table 5:
|
Price Summary Table
|
Activity
|
Price
1
|
# of Batches
|
Total Price
1
|
cGMP Equipment Set-Up
|
$35,000
|
n/a
|
$35,000
|
cGMP IOPQ Services
|
$75,000
|
N/A
|
$75,000
|
Sterilization cycle verification
(transfer of cycle)
|
$12,000
|
N/A
|
$12,000
|
Sterilization cycle validation
|
$24,000
|
N/A
|
$24,000
|
cGMP Feasibility Batches
|
$39,950
|
3
|
$119,850
|
cGMP Clinical Batches
|
$51,920
|
2
2
|
$103,840
|
cGMP Labeling Services
|
$6,897
|
2
2
|
$13,794
|
Raw Materials, Chemicals, Glassware, Labware, Filters, etc
1
|
Cost + 10%
|
Per Batch
|
TBD
|
Hazardous Waste Disposal, ≤ five (5) gallons
2
|
$750
|
Per Batch
|
TBD
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
1.
|
Bioserv will be responsible for performing instructions according to a batch record (BHR), which has been jointly agreed to by the Client and Bioserv. Client acknowledges that the work to be performed by Bioserv is experimental in nature and portions of the work may not have been fully validated within generally accepted standards of the pharmaceutical or medical device industry. Therefore, without limitation, Bioserv will not be responsible for unexpected results that can be attributed to a process or procedure either supplied by, or requested by Client, which has not been fully validated.
|
2.
|
All documentation and submissions to regulatory authorities in support of the Client product are the responsibility of Client. No documentation will be provided by Bioserv except as specifically contracted in writing between Client and Bioserv.
|
3.
|
Bioserv makes no representation or warranties regarding the suitability of the Client product for any purpose whatsoever, or for the efficacy of the product.
|
4.
|
Client is solely responsible for providing complete and accurate scientific data to Bioserv regarding the Client product and the Client requirements for formulation, fill and finish of Client product.
|
5.
|
In accepting its obligations under the terms of the Purchase Order, Bioserv has relied upon the accuracy, completeness and correctness of the data and information provided by Client in developing the project, any associated timeline and the estimated or fixed cost for the project. It is understood by Client that additional charges may be billed to Client in the event that any data or information provided by Client proves to be incorrect, incomplete or in error and as a result requires more effort by Bioserv than anticipated in the original project proposal.
|
6.
|
Client warrants to Bioserv that all substances delivered by Client to Bioserv will be free of hazardous or toxic material and that no specific safe handling instructions are applicable to any such substance or materials, except as already disclosed to Bioserv in writing by Client.
|
7.
|
Client represents and warrants to Bioserv that all finished product delivered by Bioserv to Client will be held and/or used or disposed of by Client in a safe and responsible manner, and in accordance with all applicable laws, rules and regulations.
|
8.
|
Prepayment fees (not including Project initiation fees), where applicable, are refundable less charges under Bioserv’s
Cancellation and Postponement Policy
and/or expenses incurred by Bioserv prior to the cancellation or postponement. Other payments including Project Initiation fees are non-refundable.
|
9.
|
The specific work to be invoiced by Bioserv is set forth in the proposal. Client acknowledges that the proposal may be inadequate due to unforeseen circumstances which increase the amount of work required to complete the project. Bioserv will be responsible for any charges in excess of the proposal if 1) the event causing the charge is within the scope of work; and 2) the occurrence of the event could be expected for a project similar to the current project. For other excess charges, Bioserv will notify Client immediately if the costs to complete the project exceed the proposed budget. No additional work involving charges in excess of the project proposal will commence without Client approval. After discussion of changes between Bioserv and Client, changes will be implemented by a written Change Order signed by Bioserv and Client.
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
10.
|
Despite any other provision of this Proposal Acceptance Sheet or otherwise, in no event shall Bioserv be liable for any indirect, consequential or special loss or damages, however caused, regardless of whether the other party knew or should have known of the possibility of such damages. Additionally, and without limiting the foregoing, Bioserv’s total liability for all actions and claims arising (including any claim for damages to or destruction of active pharmaceutical ingredients) shall not exceed the aggregate amounts paid to Bioserv relating to the Proposal. However, nothing in this clause shall limit or exclude Bioserv’s liability for death, personal injury, or damage to Client-Provided Equipment arising from its negligence. The parties each acknowledge that the limitation of liabilities and disclaimers contained herein constitute an agreed upon allocation of risk between the parties, have been factored into the pricing of the services, and are an essential element of the bargain between the parties.
|
11.
|
Client acknowledges and agrees that Bioserv’s obligations to Client are limited to performance by Bioserv of services (formulation, sterilization, fill and finish) in accordance with the master batch record and applicable Good Manufacturing Practices (cGMPs). Bioserv hereby warrants that its services will conform in all material respects with the terms of the master batch record and cGMPs; and that its services shall comply with relevant United States laws and regulations. EXCEPT FOR THE ABOVE EXPRESS WARRANTIES, BIOSERV DISCLAIMS ALL OTHER WARRANTIES, EXPRESS AND IMPLIED, INCLUDING BUT NOT LIMITED TO THE IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE.
|
12.
|
In the course of performing its obligations under the terms of the Proposal, Bioserv may purchase materials in anticipation of events identified by the project proposal to which a Purchase Order or duly signed Change Order has authorized work. Should those materials become unusable to the project as a consequence of delays in or changes to the project, including but not limited to postponement or cancellation, except where such delays or changes can be attributed to the actions or inactions of Bioserv or its contractors, the cost of such materials will be invoiced to the Client and the Client agrees to pay to Bioserv the amounts so invoiced.
|
13.
|
The arrangement between Bioserv and Client is one of service provider and Client. No joint venture, partnership or agency is to be created or deemed as between Bioserv and Client.
|
14.
|
Client shall indemnify, defend and hold harmless Bioserv and its officers, directors, employees, agents, successors and assigns from and against any and all obligations, costs, loss, damages, claims, attorneys fees and liability of any character in any way arising from or relating to any breach of their agreement by Client and/or any representation or warranty made by Client to Bioserv, including without limitation, any matter asserted by participants in any clinical trial of Client product. Nothing in this paragraph is intended to limit or waive any equitable or other rights to indemnification that Bioserv may otherwise be entitled.
|
15.
|
Any terms or conditions on any Purchase Order, invoice or similar documents, shall be null and void to the extent they are inconsistent with any terms of the Proposal and this Proposal Acceptance Sheet, unless they specifically express the intention of the parties to amend such documents and are signed by Bioserv and Client.
|
16.
|
Client shall be responsible for all sales and use taxes, duties and other government charges arising under the Proposal, excluding any income taxes on the payments received by Bioserv hereunder. If the product is shipped to a California destination, California sales tax will be charged unless a Tax Exempt Certificate is presented to Bioserv.
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
17.
|
No waiver of any provision or consent to any action shall constitute a waiver of any other provision or consent to any other action, whether or not similar. No waiver or consent shall constitute a continuing waiver or consent or commit a party to provide a waiver in the future except to the extent specifically set forth in writing.
|
18.
|
The agreement between Client and Bioserv shall be governed by the laws of the State of California and all claims arising hereunder shall be subject to the exclusive jurisdiction of the state and federal courts in the County of San Diego, California.
|
19.
|
Bioserv shall not be liable for delays in delivery due to acts of God, floods, fire, war, riot, terrorist acts, strikes and other matters beyond its reasonable control.
|
20.
|
All prices quoted and payments made shall be in U.S. Dollars. Late payments shall be subject to a late fee of one percent (1%) per month or twelve percent (12%) per annum. Bioserv shall have the right to reschedule and/or withhold services in the event of late payments.
|
21.
|
Each party will maintain, for the duration of this agreement, insurance in the amount up to two million U.S. dollars ($2,000,000) which is reasonably adequate to cover its obligations hereunder, and, upon request, each party will provide to the other party a certificate of insurance showing that such insurance is in place. Bioserv shall specifically provide insurance coverage for any damage incurred to Client-Provided Equipment and Product, whether raw, in-process, or finished, while Client-Provided Equipmenet and Product is in Bioserve’s possession or under their control, excluding the cost of API which must be provided by Client. Client shall maintain standard capital equipment insurance coverage on the Client-Provided Equipment during the term of this agreement.
|
22.
|
Client shall have forty-five (45) days from receipt of shipment to inspect Product. If Client believes any Product does not conform to the Client and Bioserv approved Specifications or applicable Good Manufacturing Practices, Client shall notify Bioserv in writing, including detailed explanation of the non-conformity. Upon receipt of such notice, Bioserv will investigate the alleged non-conformity and determine the root cause, and (a) if Bioserv agrees the Product is non-conforming due to errors, omissions or other manufacturing practices by Bioserv and , provided that Client returns all non-conforming Product to Bioserv excluding the cost of API which must be provided by Client, Bioserv will provide Client with replacement of Product or provide credit for the entire cost of the Product, on an expedited basis, including shipping costs (e.g. costs of transportation, insurance, and freight) for the non-conforming Product(s) and the replacement Product(s), immediately upon the return of the non-conforming Product, or (b) if Bioserv disagrees with Client’s determination that the Product is non-conforming, Bioserv will so notify Client within fourteen (14) days after the investigation by Bioserv. If the Parties dispute whether Product is conforming or non-conforming due to errors, omissions or other manufacturing practices by Bioserv, samples of the Product will be submitted to a mutually acceptable laboratory or consultant for resolution, whose determination of conformity or non-conformity shall be binding upon the Parties. Party who receives favorable judgment will be reimbursed by opposing Party for all expenses or fees incurred in dispute resolution. For clarification purposes, payments for Product are due net thirty (30) days from receipt unless written notice of rejection has been issued prior to such payments becoming due. Payments for Product which is rejected after thirty (30) days, shall be credited against future invoices or, where no future invoices are issued, refund of payment for rejected Product shall be made to Client within thirty (30) days of final determination that Product was in fact non-conforming
|
23.
|
A Quality Agreement shall be executed within five (5) business days of execution of this Proposal and shall thereafter be incorporated herein by reference as Exhibit B.
|
24.
|
All title, rights and ownership of Client-Provided Equipement shall remain with Client at all times. Use of Client-Provided Equipement for anything other than services performed for Client under this Agreement are expressly prohibited.
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
i)
|
Receipt of purchase order and requested deposit
|
ii)
|
All required validations/qualifications/engineering runs are performed and approved by Client
|
iii)
|
Production batch record approved by Client and Bioserv
|
iv)
|
All equipment and preparation items in-house and available for use
|
v)
|
Components, excipients and/or active ingredients have been received and released
|
1.
|
Project Start Dates will not be assigned without a valid Purchase Order.
|
2.
|
All Purchase Orders must be accompanied by the requested deposit.
|
3.
|
For Purchase Orders of Project(s)
CANCELLED
, the following fee schedule will apply.
|
For Notifications prior to…
|
Fee Assessed
|
180 days
|
20% of Total Project Amount
|
90 – 179 days
|
50% of Total Project Amount
|
60 – 89 days
|
75% of Total Project Amount
|
Less than 60 days
|
100% of Total Project Amount
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
|
|
CONFIDENTIAL |
1.
|
If a Purchase Order or specific project line item or project start date is
CANCELLED
by Client, all labor hours incurred will be totaled and charged to Client at two hundred and fifty dollars ($250) per hour in addition to the above fee.
|
2.
|
For Purchase Orders of Project(s)
POSTPONED
, the following fee schedule will apply.
|
For Notifications prior to…
|
Fee Assessed
|
180 days
|
No charge
|
90-179 days
|
25% of Total Project Amount
|
60-89 days
|
30% of Total Project Amount
|
30-59 days
|
40% of Total Project Amount
|
Less than or equal 30 days
|
50% of Total Project Amount
|
6.
|
A project postponement of greater than sixty (60) days will be considered a cancellation. A new proposal and Purchase Order will be required to renew the order. Based on the schedule, new date(s) selection may be limited.
|
7.
|
If a Purchase Order or specific project line item or project start date is
POSTPONED
by Client, all labor hours incurred will be totaled and charged to Client at two hundred and fifty dollars ($250) per hour in addition to the above fee.
|
Bioserv Corporation
dba NextPharma Technologies USA, Inc.
5340 Eastgate Mall
San Diego, CA. 92121
Tel 858-450-3123
Fax 858-450-0785
|
General Manager
Martin Sellers
Director of Finance
Alan Sanders
|
Director of Quality
Dave Braggs
|
Vice President of Sales, North America
Kevin Koziatek
Tel 314.575.0051
Kevin
.
koziatek@gmail.com
|
OXYGEN BIOTHERAPEUTICS, INC. | HOSPIRA WORLDWIDE, INC. | |||
/s/Michael Jebsen
|
/s/ Peter Larsen
|
|||
(Signature) | (Signature) | |||
NAME: Michael Jebsen
|
NAME: Peter Larsen
|
|||
TITLE: Exec. VP Finance & Admin, CFO
|
TITLE: Director, Global Program Management
|