UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
WASHINGTON, DC 20549
FORM 10-Q
☒ |
QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
For the quarterly period ended June 30, 2018
Or
☐ |
TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
For the transition period from to
Commission File No. 001-37660
Avangrid, Inc.
(Exact Name of Registrant as Specified in its Charter)
New York |
|
14-1798693 |
( State or other jurisdiction of incorporation or organization ) |
|
(I.R.S. Employer
|
|
|
|
180 Marsh Hill Road Orange, Connecticut |
|
06477 |
(Address of principal executive offices) |
|
(Zip Code) |
Registrant’s telephone number, including area code: (207) 629-1200
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes ☒ No ☐
Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§ 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes ☒ No ☐
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, smaller reporting company, or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer,” “smaller reporting company,” and “emerging growth company” in Rule 12b-2 of the Exchange Act.
Large accelerated filer |
|
☒ |
|
Accelerated filer |
|
☐ |
|
|
|
|
|||
Non-accelerated filer |
|
☐ (Do not check if a small reporting company) |
|
Smaller reporting company |
|
☐ |
|
|
|
|
|
|
|
Emerging growth company |
|
☐ |
|
|
|
|
If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes ☐ No ☒
As of July 31, 2018, the registrant had 309,005,272 shares of common stock, par value $0.01, outstanding.
REPORT ON FORM 10-Q
For the Quarter Ended June 30, 2018
INDEX
3 |
||
5 |
||
Item 1. |
5 |
|
Item 2. |
Management’s Discussion and Analysis of Financial Condition and Results of Operations |
47 |
Item 3. |
64 |
|
Item 4. |
64 |
|
66 |
||
Item 1. |
66 |
|
Item 1A. |
66 |
|
Item 2. |
66 |
|
Item 3. |
66 |
|
Item 4. |
66 |
|
Item 5. |
66 |
|
Item 6. |
67 |
|
68 |
2
GLOSSARY OF TERMS AND ABBREVIATIONS
Unless the context indicates otherwise, the terms “we,” “our” and the “Company” are used to refer to Avangrid, Inc. and its subsidiaries.
Consent order refers to the partial consent order issued by the Connecticut Department of Energy and Environmental Protection in August 2016.
English Station site refers to the former generation site on the Mill River in New Haven, Connecticut.
Form 10-K refers to Avangrid, Inc.’s Annual Report on Form 10-K for the year ended December 31, 2017, filed with the Securities and Exchange Commission on March 26, 2018.
Ginna refers to the Ginna Nuclear Power Plant, LLC and the R.E. Ginna Nuclear Power Plant.
Iberdrola refers to Iberdrola, S.A., which owns 81.5% of the outstanding shares of Avangrid, Inc.
Iberdrola Group refers to the group of companies controlled by Iberdrola, S.A.
Installed capacity refers to the production capacity of a power plant or wind farm based either on its rated (nameplate) capacity or actual capacity.
Joint Proposal refers to the Joint Proposal, filed with the NYPSC on February 19, 2016 by NYSEG, RG&E and certain other signatory parties for a three-year rate plan for electric and gas service at NYSEG and RG&E commencing May 1, 2016.
Klamath Plant refers to the Klamath gas-fired cogeneration facility located in the city of Klamath, Oregon.
Non-GAAP refers to the financial measures that are not prepared in accordance with U.S. GAAP, including adjusted gross margin, adjusted EBITDA, adjusted net income and adjusted earnings per share.
AOCI |
|
Accumulated other comprehensive income |
|
|
|
ARHI |
|
Avangrid Renewables Holdings, Inc. |
|
|
|
ARP |
|
Alternative Revenue Programs |
|
|
|
ASC |
|
Accounting Standards Codification |
|
|
|
AVANGRID |
|
Avangrid, Inc. |
|
|
|
Bcf |
|
One billion cubic feet |
|
|
|
BGC |
|
The Berkshire Gas Company |
|
|
|
Cayuga |
|
Cayuga Operating Company, LLC |
|
|
|
CfDs |
|
Contracts for Differences |
|
|
|
CL&P |
|
The Connecticut Light and Power Company |
|
|
|
CMP |
|
Central Maine Power Company |
|
|
|
CNG |
|
Connecticut Natural Gas Corporation |
|
|
|
DEEP |
|
Connecticut Department of Energy and Environmental Protection |
|
|
|
DIMP |
|
Distribution Integrity Management Program |
|
|
|
DOE |
|
Department of Energy |
|
|
|
DPA |
|
Deferred Payment Arrangements |
|
|
|
EBITDA |
|
Earnings before interest, taxes, depreciation and amortization |
|
|
|
ESM |
|
Earnings sharing mechanism |
|
|
|
Evergreen Power |
|
Evergreen Power, LLC |
|
|
|
Exchange Act |
|
The Securities Exchange Act of 1934, as amended |
|
|
|
FASB |
|
Financial Accounting Standards Board |
|
|
|
FERC |
|
Federal Energy Regulatory Commission |
|
|
|
3
|
FirstEnergy Corp. |
|
|
|
|
Gas |
|
Enstor Gas, LLC |
|
|
|
HLBV |
|
Hypothetical Liquidation at Book Value |
|
|
|
ISO |
|
Independent system operator |
|
|
|
LDCs |
|
Local distribution companies |
|
|
|
LIBOR |
|
The London Interbank Offered Rate |
|
|
|
MNG |
|
Maine Natural Gas Corporation |
|
|
|
MPUC |
|
Maine Public Utility Commission |
|
|
|
MtM |
|
Mark-to-market |
|
|
|
MW |
|
Megawatts |
|
|
|
MWh |
|
Megawatt-hours |
|
|
|
Networks |
|
Avangrid Networks, Inc. |
|
|
|
New York TransCo |
|
New York TransCo, LLC. |
|
|
|
NYPSC |
|
New York State Public Service Commission |
|
|
|
NYSEG |
|
New York State Electric & Gas Corporation |
|
|
|
NYSERDA |
|
New York State Energy Research and Development Authority |
|
|
|
OCI |
|
Other comprehesive income |
|
|
|
PJM |
|
PJM Interconnection, L.L.C. |
|
|
|
PURA |
|
Connecticut Public Utilities Regulatory Authority |
|
|
|
Renewables |
|
Avangrid Renewables, LLC |
|
|
|
RDM |
|
Revenue Decoupling Mechanism |
|
|
|
RG&E |
|
Rochester Gas and Electric Corporation |
|
|
|
ROE |
|
Return on equity |
|
|
|
RSSA |
|
Reliability Support Services Agreement |
|
|
|
SCG |
|
The Southern Connecticut Gas Company |
|
|
|
SEC |
|
United States Securities and Exchange Commission |
|
|
|
Tax Act |
|
Tax Cuts and Jobs Act of 2017 enacted by the U.S. federal government on December 22, 2017 |
|
|
|
TEF |
|
Tax equity financing arrangements |
|
|
|
UI |
|
The United Illuminating Company |
|
|
|
UIL |
|
UIL Holdings Corporation |
|
|
|
U.S. GAAP |
|
Generally accepted accounting principles for financial reporting in the United States. |
|
|
|
VIEs |
|
Variable interest entities |
4
PART I. FINANCI AL INFORMATION
Avangrid, Inc. and Subsidiaries
Condensed Consolidated Statements of Income
(unaudited)
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions, except for number of shares and per share data) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Operating Revenues |
|
$ |
1,402 |
|
|
$ |
1,331 |
|
|
$ |
3,267 |
|
|
$ |
3,089 |
|
Operating Expenses |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Purchased power, natural gas and fuel used |
|
|
279 |
|
|
|
242 |
|
|
|
855 |
|
|
|
707 |
|
Loss from assets held for sale |
|
|
10 |
|
|
|
— |
|
|
|
15 |
|
|
|
— |
|
Operations and maintenance |
|
|
533 |
|
|
|
493 |
|
|
|
1,060 |
|
|
|
1,015 |
|
Depreciation and amortization |
|
|
215 |
|
|
|
206 |
|
|
|
418 |
|
|
|
403 |
|
Taxes other than income taxes |
|
|
143 |
|
|
|
138 |
|
|
|
294 |
|
|
|
285 |
|
Total Operating Expenses |
|
|
1,180 |
|
|
|
1,079 |
|
|
|
2,642 |
|
|
|
2,410 |
|
Operating Income |
|
|
222 |
|
|
|
252 |
|
|
|
625 |
|
|
|
679 |
|
Other Income and (Expense) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Other expense |
|
|
(20 |
) |
|
|
(21 |
) |
|
|
(41 |
) |
|
|
(37 |
) |
Earnings from equity method investments |
|
|
5 |
|
|
|
1 |
|
|
|
7 |
|
|
|
3 |
|
Interest expense, net of capitalization |
|
|
(70 |
) |
|
|
(68 |
) |
|
|
(144 |
) |
|
|
(139 |
) |
Income Before Income Tax |
|
|
137 |
|
|
|
164 |
|
|
|
447 |
|
|
|
506 |
|
Income tax expense |
|
|
27 |
|
|
|
44 |
|
|
|
99 |
|
|
|
147 |
|
Net Income |
|
|
110 |
|
|
|
120 |
|
|
|
348 |
|
|
|
359 |
|
Less: Net income (loss) attributable to noncontrolling interests |
|
|
3 |
|
|
|
— |
|
|
|
(3 |
) |
|
|
— |
|
Net Income Attributable to Avangrid, Inc. |
|
$ |
107 |
|
|
$ |
120 |
|
|
$ |
351 |
|
|
$ |
359 |
|
Earnings Per Common Share, Basic |
|
$ |
0.35 |
|
|
$ |
0.39 |
|
|
$ |
1.13 |
|
|
$ |
1.16 |
|
Earnings Per Common Share, Diluted |
|
$ |
0.34 |
|
|
$ |
0.39 |
|
|
$ |
1.13 |
|
|
$ |
1.16 |
|
Weighted-average Number of Common Shares Outstanding: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Basic |
|
|
309,517,854 |
|
|
|
309,520,718 |
|
|
|
309,515,758 |
|
|
|
309,514,836 |
|
Diluted |
|
|
309,719,584 |
|
|
|
309,826,185 |
|
|
|
309,711,682 |
|
|
|
309,799,839 |
|
Cash Dividends Declared Per Common Share |
|
$ |
0.432 |
|
|
$ |
0.432 |
|
|
$ |
0.864 |
|
|
$ |
0.864 |
|
The accompanying notes are an integral part of our condensed consolidated financial statements.
5
Avangrid, Inc. and Subsidiaries
Condensed Consolidated Statements of Comprehensive Income
(unaudited)
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Net Income |
|
$ |
110 |
|
|
$ |
120 |
|
|
$ |
348 |
|
|
$ |
359 |
|
Other Comprehensive (Loss) Income, Net of Tax |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Amounts arising during the period: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Gain on defined benefit plans, net of income taxes of $0.2 for the three and six months ended |
|
|
1 |
|
|
|
— |
|
|
1 |
|
|
|
— |
|
|
Unrealized (loss) gain during the period on derivatives qualifying as cash flow hedges, net of income tax of $(1.5) for the three months ended and $(1.5) and $1.1 for the six months ended, respectively |
|
|
(5 |
) |
|
|
— |
|
|
|
(5 |
) |
|
|
2 |
|
Reclassification to net income of (gains) losses on cash flow hedges, net of income taxes of $(0.1) for the three months ended and $(7.2) and $13.5, for the six months ended, respectively |
|
|
— |
|
|
|
(1 |
) |
|
|
(10 |
) |
|
|
22 |
|
Other Comprehensive (Loss) Income |
|
|
(4 |
) |
|
|
(1 |
) |
|
|
(14 |
) |
|
|
24 |
|
Comprehensive Income |
|
|
106 |
|
|
|
119 |
|
|
|
334 |
|
|
|
383 |
|
Less: Net income (loss) attributable to noncontrolling interests |
|
|
3 |
|
|
|
— |
|
|
|
(3 |
) |
|
|
— |
|
Comprehensive Income Attributable to Avangrid, Inc. |
|
$ |
103 |
|
|
$ |
119 |
|
|
$ |
337 |
|
|
$ |
383 |
|
The accompanying notes are an integral part of our condensed consolidated financial statements.
6
Avangrid, Inc. and Subsidiaries
Condensed Consolidated Balance Sheets
(unaudited)
|
|
June 30, |
|
|
December 31, |
|
||
As of |
|
2018 |
|
|
2017 |
|
||
(Millions) |
|
|
|
|
|
|
|
|
Assets |
|
|
|
|
|
|
|
|
Current Assets |
|
|
|
|
|
|
|
|
Cash and cash equivalents |
|
$ |
52 |
|
|
$ |
41 |
|
Accounts receivable and unbilled revenues, net |
|
|
986 |
|
|
|
1,040 |
|
Accounts receivable from affiliates |
|
|
3 |
|
|
|
10 |
|
Derivative assets |
|
|
20 |
|
|
|
18 |
|
Fuel and gas in storage |
|
|
88 |
|
|
|
99 |
|
Materials and supplies |
|
|
122 |
|
|
|
115 |
|
Prepayments and other current assets |
|
|
141 |
|
|
|
273 |
|
Assets held for sale |
|
|
— |
|
|
|
357 |
|
Regulatory assets |
|
|
288 |
|
|
|
307 |
|
Total Current Assets |
|
|
1,700 |
|
|
|
2,260 |
|
Total Property, Plant and Equipment ($1,276 and $1,303 related to VIEs, respectively) |
|
|
22,917 |
|
|
|
22,669 |
|
Equity method investments |
|
|
362 |
|
|
|
352 |
|
Other investments |
|
|
65 |
|
|
|
63 |
|
Regulatory assets |
|
|
2,700 |
|
|
|
2,738 |
|
Deferred income taxes regulatory |
|
|
22 |
|
|
|
— |
|
Other Assets |
|
|
|
|
|
|
|
|
Goodwill |
|
|
3,127 |
|
|
|
3,127 |
|
Intangible assets |
|
|
327 |
|
|
|
328 |
|
Derivative assets |
|
|
63 |
|
|
|
63 |
|
Other |
|
|
93 |
|
|
|
71 |
|
Total Other Assets |
|
|
3,610 |
|
|
|
3,589 |
|
Total Assets |
|
$ |
31,376 |
|
|
$ |
31,671 |
|
The accompanying notes are an integral part of our condensed consolidated financial statements.
7
Avangrid, Inc. and Subsidiaries
Condensed Consolidated Balance Sheets
(unaudited)
|
|
June 30, |
|
|
December 31, |
|
||
As of |
|
2018 |
|
|
2017 |
|
||
(Millions, except share information) |
|
|
|
|
|
|
|
|
Liabilities |
|
|
|
|
|
|
|
|
Current Liabilities |
|
|
|
|
|
|
|
|
Current portion of debt |
|
$ |
362 |
|
|
$ |
183 |
|
Tax equity financing arrangements - VIEs |
|
|
— |
|
|
|
38 |
|
Notes payable |
|
|
218 |
|
|
|
757 |
|
Notes payable to affiliates |
|
|
31 |
|
|
|
29 |
|
Interest accrued |
|
|
58 |
|
|
|
57 |
|
Accounts payable and accrued liabilities |
|
|
940 |
|
|
|
1,071 |
|
Accounts payable to affiliates |
|
|
58 |
|
|
|
89 |
|
Dividends payable |
|
|
134 |
|
|
|
134 |
|
Taxes accrued |
|
|
11 |
|
|
|
89 |
|
Derivative liabilities |
|
|
29 |
|
|
|
22 |
|
Liabilities held for sale |
|
|
— |
|
|
|
137 |
|
Other current liabilities |
|
|
307 |
|
|
|
330 |
|
Regulatory liabilities |
|
|
192 |
|
|
|
178 |
|
Total Current Liabilities |
|
|
2,340 |
|
|
|
3,114 |
|
Regulatory liabilities |
|
|
3,294 |
|
|
|
3,239 |
|
Deferred income taxes regulatory |
|
|
— |
|
|
|
13 |
|
Other Non-current Liabilities |
|
|
|
|
|
|
|
|
Deferred income taxes |
|
|
1,511 |
|
|
|
1,452 |
|
Deferred income |
|
|
1,415 |
|
|
|
1,446 |
|
Pension and other postretirement |
|
|
1,033 |
|
|
|
1,049 |
|
Tax equity financing arrangements - VIEs |
|
|
— |
|
|
|
60 |
|
Derivative liabilities |
|
|
97 |
|
|
|
92 |
|
Asset retirement obligations |
|
|
202 |
|
|
|
196 |
|
Environmental remediation costs |
|
|
355 |
|
|
|
358 |
|
Other |
|
|
400 |
|
|
|
360 |
|
Total Other Non-current Liabilities |
|
|
5,013 |
|
|
|
5,013 |
|
Non-current Debt |
|
|
5,261 |
|
|
|
5,196 |
|
Total Non-current Liabilities |
|
|
13,568 |
|
|
|
13,461 |
|
Total Liabilities |
|
|
15,908 |
|
|
|
16,575 |
|
Commitments and Contingencies |
|
|
|
|
|
|
|
|
Equity |
|
|
|
|
|
|
|
|
Stockholders’ Equity: |
|
|
|
|
|
|
|
|
Common stock, $.01 par value, 500,000,000 shares authorized, 309,752,140 and 309,670,932 shares issued; 309,005,272 shares outstanding, respectively |
|
|
3 |
|
|
|
3 |
|
Additional paid in capital |
|
|
13,655 |
|
|
|
13,653 |
|
Treasury Stock |
|
|
(12 |
) |
|
|
(8 |
) |
Retained earnings |
|
|
1,550 |
|
|
|
1,475 |
|
Accumulated other comprehensive loss |
|
|
(61 |
) |
|
|
(46 |
) |
Total Stockholders’ Equity |
|
|
15,135 |
|
|
|
15,077 |
|
Non-controlling interests |
|
|
333 |
|
|
|
19 |
|
Total Equity |
|
|
15,468 |
|
|
|
15,096 |
|
Total Liabilities and Equity |
|
$ |
31,376 |
|
|
$ |
31,671 |
|
The accompanying notes are an integral part of our condensed consolidated financial statements.
8
Avangrid, Inc. and Subsidiaries
Condensed Consolidated Statements of Cash Flows
(unaudited)
|
|
Six Months Ended |
|
|||||
|
|
June 30, |
|
|||||
|
|
2018 |
|
|
2017 |
|
||
(Millions) |
|
|
|
|
|
|
|
|
Cash Flow from Operating Activities: |
|
|
|
|
|
|
|
|
Net income |
|
$ |
348 |
|
|
$ |
359 |
|
Adjustments to reconcile net income to net cash provided by operating activities: |
|
|
|
|
|
|
|
|
Depreciation and amortization |
|
|
418 |
|
|
|
403 |
|
Loss from assets held for sale |
|
|
15 |
|
|
|
— |
|
Accretion expenses |
|
|
6 |
|
|
|
5 |
|
Regulatory assets/liabilities amortization |
|
|
34 |
|
|
|
28 |
|
Regulatory assets/liabilities carrying cost |
|
|
3 |
|
|
|
11 |
|
Pension cost |
|
|
62 |
|
|
|
56 |
|
Stock-based compensation |
|
|
— |
|
|
|
4 |
|
Earnings from equity method investments |
|
|
(7 |
) |
|
|
(3 |
) |
Amortization of debt premium |
|
|
(2 |
) |
|
|
(2 |
) |
Gain on disposal of property and equity method investment |
|
|
— |
|
|
|
(1 |
) |
Unrealized gain on marked-to-market derivative contracts |
|
|
(4 |
) |
|
|
(18 |
) |
Deferred taxes |
|
|
106 |
|
|
|
142 |
|
Other non-cash items |
|
|
(15 |
) |
|
|
(30 |
) |
Changes in operating assets and liabilities: |
|
|
|
|
|
|
|
|
Accounts receivable and unbilled revenues |
|
|
61 |
|
|
|
143 |
|
Inventories |
|
|
8 |
|
|
|
(14 |
) |
Other assets/liabilities |
|
|
27 |
|
|
|
(22 |
) |
Cash distribution from equity method investments |
|
|
7 |
|
|
|
7 |
|
Accounts payable and accrued liabilities |
|
|
(104 |
) |
|
|
(168 |
) |
Taxes accrued |
|
|
3 |
|
|
|
4 |
|
Regulatory assets/liabilities |
|
|
17 |
|
|
|
21 |
|
Net Cash Provided by Operating Activities |
|
|
983 |
|
|
|
925 |
|
Cash Flow from Investing Activities: |
|
|
|
|
|
|
|
|
Capital expenditures |
|
|
(751 |
) |
|
|
(1,069 |
) |
Contributions in aid of construction |
|
|
23 |
|
|
|
21 |
|
Proceeds from sale of assets |
|
|
136 |
|
|
|
3 |
|
Proceeds from sale of equity method and other investment |
|
|
— |
|
|
|
5 |
|
Cash distribution from equity method investments |
|
|
2 |
|
|
|
2 |
|
Other investments and equity method investments, net |
|
|
(16 |
) |
|
|
(7 |
) |
Net Cash Used in Investing Activities |
|
|
(606 |
) |
|
|
(1,045 |
) |
Cash Flow from Financing Activities: |
|
|
|
|
|
|
|
|
Non-current note issuance |
|
|
325 |
|
|
|
294 |
|
Repayments of non-current debt |
|
|
(65 |
) |
|
|
(23 |
) |
(Repayments) receipts of other short-term debt, net |
|
|
(539 |
) |
|
|
158 |
|
Payments on tax equity financing arrangements |
|
|
— |
|
|
|
(60 |
) |
Repayments of capital leases |
|
|
(12 |
) |
|
|
(31 |
) |
Repurchase of common stock |
|
|
(4 |
) |
|
|
(3 |
) |
Issuance of common stock |
|
|
(2 |
) |
|
|
(1 |
) |
Distributions to noncontrolling interests |
|
|
(22 |
) |
|
|
— |
|
Contributions from noncontrolling interests |
|
|
220 |
|
|
|
— |
|
Dividends paid |
|
|
(267 |
) |
|
|
(268 |
) |
Net Cash (Used in) Provided by Financing Activities |
|
|
(366 |
) |
|
|
66 |
|
Net Increase (Decrease) in Cash, Cash Equivalents and Restricted Cash |
|
|
11 |
|
|
|
(54 |
) |
Cash, Cash Equivalents and Restricted Cash, Beginning of Period |
|
|
46 |
|
|
|
96 |
|
Cash, Cash Equivalents and Restricted Cash, End of Period |
|
$ |
57 |
|
|
$ |
42 |
|
Supplemental Cash Flow Information |
|
|
|
|
|
|
|
|
Cash paid for interest, net of amounts capitalized |
|
$ |
113 |
|
|
$ |
99 |
|
Cash (refund)/paid for income taxes |
|
$ |
(13 |
) |
|
$ |
8 |
|
The accompanying notes are an integral part of our condensed consolidated financial statements.
9
Avangrid, Inc. and Subsidiaries
Condensed Consolidated Statements of Changes in Equity
(unaudited)
|
|
Avangrid, Inc. Stockholders |
|
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||||||||||
(Millions, except for number of shares ) |
|
Number of shares (*) |
|
|
Common Stock |
|
|
Additional paid-in capital |
|
|
Treasury Stock |
|
|
Retained Earnings |
|
|
Accumulated Other Comprehensive Loss |
|
|
Total Stockholders’ Equity |
|
|
Non controlling Interests |
|
|
Total |
|
|||||||||
As of December 31, 2016 |
|
|
308,993,149 |
|
|
$ |
3 |
|
|
$ |
13,653 |
|
|
$ |
(5 |
) |
|
$ |
1,630 |
|
|
$ |
(86 |
) |
|
$ |
15,195 |
|
|
$ |
13 |
|
|
$ |
15,208 |
|
Net Income |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
359 |
|
|
|
— |
|
|
|
359 |
|
|
|
— |
|
|
|
359 |
|
Other comprehensive loss, net of tax of $14.6 |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
24 |
|
|
|
24 |
|
|
|
— |
|
|
|
24 |
|
Comprehensive income |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
383 |
|
Dividends declared |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(268 |
) |
|
|
— |
|
|
|
(268 |
) |
|
|
— |
|
|
|
(268 |
) |
Release of common stock held in trust |
|
|
5,649 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Issuance of common stock |
|
|
70,493 |
|
|
|
— |
|
|
|
(1 |
) |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(1 |
) |
|
|
— |
|
|
|
(1 |
) |
Repurchase of common stock |
|
|
(64,019 |
) |
|
|
— |
|
|
|
— |
|
|
|
(3 |
) |
|
|
— |
|
|
|
— |
|
|
|
(3 |
) |
|
|
— |
|
|
|
(3 |
) |
Stock-based compensation |
|
|
— |
|
|
|
— |
|
|
|
3 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
3 |
|
|
|
— |
|
|
|
3 |
|
Transaction with noncontrolling interests |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
4 |
|
|
|
— |
|
|
|
4 |
|
|
|
1 |
|
|
|
5 |
|
As of June 30, 2017 |
|
|
309,005,272 |
|
|
$ |
3 |
|
|
$ |
13,655 |
|
|
$ |
(8 |
) |
|
$ |
1,725 |
|
|
$ |
(62 |
) |
|
$ |
15,313 |
|
|
$ |
14 |
|
|
$ |
15,327 |
|
As of December 31, 2017 |
|
|
309,005,272 |
|
|
$ |
3 |
|
|
$ |
13,653 |
|
|
$ |
(8 |
) |
|
$ |
1,475 |
|
|
$ |
(46 |
) |
|
$ |
15,077 |
|
|
$ |
19 |
|
|
$ |
15,096 |
|
Adoption of accounting standards |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(3 |
) |
|
|
(1 |
) |
|
|
(4 |
) |
|
|
140 |
|
|
|
136 |
|
Net Income (loss) |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
351 |
|
|
|
— |
|
|
|
351 |
|
|
|
(3 |
) |
|
|
348 |
|
|
Other comprehensive income, net of tax of $(8.5) |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(14 |
) |
|
|
(14 |
) |
|
|
— |
|
|
|
(14 |
) |
Comprehensive income |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
334 |
|
Dividends declared |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(267 |
) |
|
|
— |
|
|
|
(267 |
) |
|
|
— |
|
|
|
(267 |
) |
Issuance of common stock |
|
|
81,208 |
|
|
|
— |
|
|
|
1 |
|
|
|
— |
|
|
|
(3 |
) |
|
|
— |
|
|
|
(2 |
) |
|
|
— |
|
|
|
(2 |
) |
Repurchase of common stock |
|
|
(81,208 |
) |
|
|
— |
|
|
|
— |
|
|
|
(4 |
) |
|
|
— |
|
|
|
— |
|
|
|
(4 |
) |
|
|
— |
|
|
|
(4 |
) |
Stock-based compensation |
|
|
— |
|
|
|
— |
|
|
|
1 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
1 |
|
|
|
— |
|
|
|
1 |
|
Distributions to noncontrolling interests |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(41 |
) |
|
|
(41 |
) |
Contributions from noncontrolling interests |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(3 |
) |
|
|
— |
|
|
|
(3 |
) |
|
|
218 |
|
|
|
215 |
|
As of June 30, 2018 |
|
|
309,005,272 |
|
|
$ |
3 |
|
|
$ |
13,655 |
|
|
$ |
(12 |
) |
|
$ |
1,550 |
|
|
$ |
(61 |
) |
|
$ |
15,135 |
|
|
$ |
333 |
|
|
$ |
15,468 |
|
(*) |
Par value of share amounts is $0.01 |
The accompanying notes are an integral part of our condensed consolidated financial statements.
10
Avangrid, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements
(unaudited)
Note 1. Background and Nature of Operations
Avangrid, Inc., formerly Iberdrola USA, Inc. (AVANGRID, we or the Company), is an energy services holding company engaged in the regulated energy distribution business through its principal subsidiary Avangrid Networks, Inc. (Networks) and in the renewable energy generation business through its principal subsidiary, Avangrid Renewables Holding, Inc. (ARHI). ARHI in turn holds subsidiaries including Avangrid Renewables, LLC (Renewables). Iberdrola, S.A. (Iberdrola), a corporation organized under the laws of the Kingdom of Spain, owns 81.5% the outstanding common stock of AVANGRID. The remaining outstanding shares are publicly traded on the New York Stock Exchange and owned by various shareholders.
In December 2017, management committed to a plan to sell the gas storage and trading businesses because they represented non-core businesses that were not aligned with our strategic objectives. At that time, we determined that the assets and liabilities associated with our gas trading and storage businesses met the criteria for classification as assets held for sale, but did not meet the criteria for classification as discontinued operations. On March 1, 2018, the Company closed a transaction to sell Enstor Energy Services, LLC, which operated AVANGRID’s gas trading business, to CCI U.S. Asset Holdings LLC, a subsidiary of Castleton Commodities International, LLC (CCI). On May 1, 2018, the Company closed a transaction to sell Enstor Gas, LLC, which operated AVANGRID’s gas storage business, to Amphora Gas Storage USA, LLC.
Note 2. Basis of Presentation
The accompanying notes should be read in conjunction with the notes to the consolidated financial statements of Avangrid, Inc. and subsidiaries as of December 31, 2017 and 2016 and for the three years ended December 31, 2017 included in AVANGRID’s Annual Report on Form 10-K for the fiscal year ended December 31, 2017.
The accompanying unaudited financial statements are prepared on a consolidated basis and include the accounts of AVANGRID and its consolidated subsidiaries Networks and ARHI. Intercompany accounts and transactions have been eliminated in consolidation. The year-end balance sheet data was derived from audited financial statements. The unaudited condensed consolidated financial statements for the interim periods have been prepared in accordance with accounting principles generally accepted in the United States of America (U.S. GAAP) for interim financial information and with the instructions to Form 10-Q and Article 10 of Regulation S-X. Accordingly, the interim condensed consolidated financial statements do not include all the information and note disclosures required by U.S. GAAP for complete financial statements.
We believe the disclosures made are adequate to make the information presented not misleading. In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments necessary to present fairly our condensed consolidated balance sheets, condensed consolidated statements of income, comprehensive income, cash flows and changes in equity for the interim periods described herein. All such adjustments are of a normal and recurring nature, except as otherwise disclosed. The results for the three and six months ended June 30, 2018, are not necessarily indicative of the results for the entire fiscal year ending December 31, 2018.
Note 3. Significant Accounting Policies and New Accounting Pronouncements
As of June 30, 2018, the new accounting pronouncements that we have adopted as of January 1, 2018, and reflected in our consolidated financial statements are described below. There have been no other material changes to the significant accounting policies described in our consolidated financial statements as of December 31, 2017 and 2016, and for the three years ended December 31, 2017.
Adoption of New Accounting Pronouncements
(a) Revenue from contracts with customers
In May 2014, the Financial Accounting Standards Board (FASB) issued Accounting Standards Codification (ASC), Topic 606, Revenue from Contracts with Customers (ASC 606) replacing the existing accounting standard and industry specific guidance for revenue recognition with a five-step model for recognizing and measuring revenue from contracts with customers. The FASB further amended ASC 606 through various updates issued thereafter. The core principle is for an entity to recognize revenue to represent the transfer of promised goods or services to customers in amounts that reflect the consideration to which the entity expects to be entitled in exchange for those goods or services. We adopted ASC 606 effective January 1, 2018, and applied the modified retrospective method, for which we did not have a cumulative effect adjustment to retained earnings for initial application of the guidance. Refer to Note 4 for further details.
11
(b) Clarifying the scope of asset derecognition guidance and accounting for partial sales of nonfinancial assets
The FASB issued amendments in February 2017 concerning asset derecognition and partial sales of nonfinancial assets. The amendments clarify the scope of asset derecognition guidance and accounting for partial sales of nonfinancial assets, and also define in-substance nonfinancial assets. Those amendments apply to a company that: sells nonfinancial assets (land, buildings, materials and supplies, intangible assets) to noncustomers; sells nonfinancial assets and financial assets (cash, receivables) when the value is concentrated in the nonfinancial assets; or sells partial ownership interests in nonfinancial assets. The amendments do not apply to sales to customers or to sales of businesses. The new guidance in ASC 610-20 on accounting for derecognition of a nonfinancial asset and an in-substance nonfinancial asset applies only when the asset (or asset group) does not meet the definition of a business and is not a not-for-profit activity. An entity must apply the amendments at the same time that it applies the new ASC 606 revenue recognition standard. We adopted ASC 610-20 effective January 1, 2018, and applied the modified retrospective method, which affected the accounting for our tax equity investments. As shown in the table below, we recorded a cumulative adjustment that decreased retained earnings. The cumulative adjustment relates to the reclassification of our tax equity investments to noncontrolling interests. As a result, we recorded our tax equity investments based on the Hypothetical Liquidation at Book Value (HLBV) accounting method and we will record changes in the HLBV at each reporting period within net income/loss attributable to noncontrolling interests.
The cumulative effects of the changes to our consolidated balance sheet as of January 1, 2018, for our adoption of ASC 606 and ASC 610-20 were as follows:
Balance Sheet |
|
Balance at December 31, 2017 |
|
|
Adjustments Due to ASC 606 |
|
|
Adjustments Due to ASC 610-20 |
|
|
Balance at January 1, 2018 |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Liabilities |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Tax equity financing arrangements - VIEs |
|
$ |
98 |
|
|
$ |
— |
|
|
$ |
(98 |
) |
|
$ |
— |
|
Deferred income taxes |
|
$ |
1,452 |
|
|
$ |
— |
|
|
$ |
(40 |
) |
|
$ |
1,412 |
|
Equity |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Retained earnings |
|
$ |
1,475 |
|
|
$ |
— |
|
|
$ |
(2 |
) |
|
$ |
1,473 |
|
Non-controlling interests |
|
$ |
19 |
|
|
$ |
— |
|
|
$ |
140 |
|
|
$ |
159 |
|
We also adopted the following standards as of their effective date of January 1, 2018, none of which had a material effect on our consolidated results of operations, financial position, cash flows, and disclosures.
(c) Classifying and measuring financial instruments
In January 2016, the FASB issued final guidance on the classification and measurement of financial instruments. As a result of our adoption we reclassified immaterial amounts from AOCI to retained earnings.
(d) Certain classifications in the statement of cash flows
In August 2016, the FASB issued amendments to address existing diversity in practice concerning the classification of certain cash receipts and payments on the statement of cash flows, which must be applied on a full retrospective basis. Upon adoption, we had no changes to our cash flow classifications and disclosures in our consolidated financial statements.
(e) Improving the presentation of net periodic benefit costs
In March 2017, the FASB issued amendments to improve the presentation of net periodic pension cost and net periodic postretirement benefit cost in the financial statements. We retrospectively adopted the amendments that require us to present the service cost component separately from the other (non-service) components of net benefit cost, to report the service cost component in the income statement line item where we report the corresponding compensation cost, and to present all non-service components outside of operating cost. As a result, we have reclassified the non-service components – interest cost, expected return on plan assets, amortization of prior service cost (benefit), amortization of net loss, and settlement charge – from Operations and maintenance to Other income/(expense) within the statement of income. Prospectively, from adoption, we will capitalize only the service cost component when applicable (for example, as a cost of a self-constructed asset). We elected to apply the practical expedient that allows us to retrospectively apply the amendments on adoption to net benefit costs for comparative periods by using the amounts disclosed in our notes to financial statements for Post-retirement and Similar Obligations as the basis for those periods. In addition to those amounts, we included amortization of net benefit costs recorded as regulatory deferrals as a result of purchase accounting in a prior year. In connection with applying the practical expedient, in periods after adoption we will continue to include in operating income all legacy net benefit costs previously capitalized as a cost of self-constructed assets and other deferred regulatory costs. Our adoption of the amendments did not affect prior period net income attributable to AVANGRID. Beginning in 2018, non-service cost components incurred by the Networks utilities are no longer eligible for construction capitalization, but such costs can be deferred and included as
12
a component of customer rates if permitted by their regulator. For the t hree and six months ended June 30, 2018, immaterial additional expense has been incurred as a result of the adoption of this standard.
The effect of the change in retrospective presentation related to the net periodic cost of our defined benefit pension and other postretirement employee benefits plans on our consolidated statement of income was as follows:
|
|
Three Months Ended June 30, 2017 |
|
|
Six Months Ended June 30, 2017 |
|
||||||||||||||||||
Statement of Income |
|
As Revised |
|
|
As Previously Reported |
|
|
Effect of Change Higher/(Lower) |
|
|
As Revised |
|
|
As Previously Reported |
|
|
Effect of Change Higher/(Lower) |
|
||||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Operations and maintenance |
|
$ |
493 |
|
|
$ |
522 |
|
|
$ |
(29 |
) |
|
$ |
1,015 |
|
|
$ |
1,073 |
|
|
$ |
(58 |
) |
Other income / (expense) |
|
$ |
(21 |
) |
|
$ |
8 |
|
|
$ |
(29 |
) |
|
$ |
(37 |
) |
|
$ |
21 |
|
|
$ |
(58 |
) |
We have also revised the segment information related to our Networks reportable segment provided in Note 13 for the three and six months ended June 30, 2017, to reflect the change as a result of the adoption of these amendments.
Accounting Pronouncements Issued But Not Yet Adopted
The following are new accounting pronouncements issued since December 31, 2017, that we have evaluated or are evaluating to determine their effect on our consolidated financial statements.
(a) Leases, amendments and updates
In January 2018, the FASB issued amendments to clarify the application of the new leases guidance to land easements (also commonly called rights of way) and provide relief concerning adoption efforts for existing land easements that are not accounted for as leases under current GAAP. The updated guidance is effective for public entities for fiscal years beginning after December 15, 2018, including interim periods within those fiscal years, and early application is permitted. In July 2018 the FASB issued a number of technical corrections and improvements to the new leases guidance, which affect narrow aspects of the guidance and are effective as noted above. We will assess the corrections and improvements, but they are not expected to have a significant effect. Also, in July 2018 the FASB issued amendments to the leases standard to allow entities an additional option for transition. The guidance currently requires a modified retrospective transition method of adoption, under which lessees and lessors are to recognize and measure leases at the beginning of the earliest period presented. The additional, optional transition method allows an entity to initially apply the requirements of the leases standard at the adoption date. If this transition method is adopted, reporting for comparative periods presented in the consolidated financial statements would not be restated. We will assess the additional transition option to decide which method to adopt.
We continue to review our contracts and are executing a broad implementation plan as we prepare for our adoption of the new leases guidance on January 1, 2019. The key components of our implementation plan and steps that are currently underway include: 1) uploading complete and pertinent lease contract data into a new accounting system that integrates with existing systems; 2) identifying, evaluating and documenting related technical accounting issues, industry implementation issues, policy considerations and financial reporting implications; 3) identifying and implementing changes to process and controls to ensure all aspects of the new guidance are effectively addressed; and 4) simulating the effects of the leases standard to assess the expected impact upon adoption and to finalize transition option and practical expedient selections. Through June 2018, we are substantially complete with step 1; however, we are still undergoing final reviews of uploaded information and lease contract data in the new accounting system database, and validating the simulation and outputs from the new lease accounting system. Steps 2 through 4 are currently in process and we expect to complete them in the fourth quarter of 2018. We expect our adoption of the new leases guidance will materially affect our financial position through the recording of operating leases on the balance sheet as right-of-use assets, along with the corresponding liabilities. However, we do not expect significant changes to our pattern of expense recognition under the new leases standard.
(b) Reclassification of certain tax effects from accumulated other comprehensive income
In February 2018, the FASB issued amendments to address a narrow-scope financial reporting issue that arose as a consequence of the Tax Cuts and Jobs Act of 2017 (the Tax Act) enacted on December 22, 2017, by the U.S. federal government. Under current guidance, the adjustment of deferred taxes for the effect of a change in tax laws or rates is required to be included in income from continuing operations, thus the associated tax effects of items within AOCI (referred to as stranded tax effects) do not reflect the appropriate tax rate. The amendments allow a reclassification from AOCI to retained earnings for stranded tax effects resulting from the Tax Act. As a result, the amendments eliminate the stranded tax effects resulting from the Tax Act and will improve the usefulness of information reported to financial statement users. The amendments only relate to the reclassification of the income tax effects of the Tax Act, and do not affect the underlying guidance that requires the effect of a change in tax laws or rates to be included in income from continuing operations. The amendments are effective for all entities for fiscal years beginning after December 15, 2018, and interim periods within those fiscal years. Early adoption is permitted including, for public entities, adoption in any interim period for which financial statements have not been issued. An entity has the option to apply the amendments either in the period of adoption or retrospectively
13
to each period (or periods) in whic h it recognizes the effect of the change in the U.S. federal corporate income tax rate in the Tax Act. An entity is required to disclose its accounting policy election, including its policy for reclassifying material stranded tax effects in AOCI to earning s (specific identification or portfolio method). We have not early adopted the amendments as of June 30, 2018. We expect our adoption of the amendments will not materially affect our consolidated results of operations, financial position, cash flows, and d isclosures.
Note 4. Revenue
On January 1, 2018, we adopted ASC 606 and all related amendments using the modified retrospective method, which we applied only to contracts that were not completed as of January 1, 2018. For reporting periods beginning on January 1, 2018, we present revenue in accordance with ASC 606, and have not adjusted comparative prior period information, which we continue to report under the legacy accounting standards in effect for those prior periods. For the three and six months ended June 30, 2018, the effect of applying ASC 606 to recognize revenue as compared to applying the legacy accounting standards was not material.
We recognize revenue when we have satisfied our obligations under the terms of a contract with a customer, which generally occurs when the control of promised goods or services transfers to the customer. We measure revenue as the amount of consideration we expect to receive in exchange for providing those goods or services. Contracts with customers may include multiple performance obligations. For such contracts, we allocate revenue to each performance obligation based on its relative standalone selling price. We generally determine standalone selling prices based on the prices charged to customers. Certain revenues are not within the scope of ASC 606, such as revenues from leasing, derivatives, other revenues that are not from contracts with customers and other contractual rights or obligations, and we account for such revenues in accordance with the applicable accounting standards. We exclude from revenue amounts collected on behalf of third parties, including any such taxes collected from customers and remitted to governmental authorities. We do not have any material significant payment terms because we receive payment at or shortly after the point of sale.
The following describes the principal activities, by reportable segment, from which we generate revenue. For more detailed information about reportable segments, refer to Note 13.
Networks Segment
Networks derives its revenue primarily from tariff-based sales of electricity and natural gas service to customers in New York, Connecticut, Maine and Massachusetts, with no defined contractual term. For such revenues, we recognize revenues in an amount derived from the commodities delivered to customers. Other major sources of revenue are electricity transmission and wholesale sales of electricity and natural gas.
Tariff-based sales are subject to the corresponding state regulatory authorities, which determine prices and other terms of service through the ratemaking process. Maine state law prohibits the utility from providing the electricity commodity to customers. In New York, Connecticut and Massachusetts, customers have the option to obtain the electricity or natural gas commodity directly from the utility or from another supplier. For customers that receive their commodity from another supplier, the utility acts as an agent and delivers the electricity or natural gas provided by that supplier. Revenue in those cases is only for providing the service of delivery of the commodity. Networks entities calculate revenue earned but not yet billed based on the number of days not billed in the month, the estimated amount of energy delivered during those days and the estimated average price per customer class for that month. Differences between actual and estimated unbilled revenue are immaterial.
Transmission revenue results from others’ use of the utility’s transmission system to transmit electricity and is subject to Federal Energy Regulatory Commission (FERC) regulation, which establishes the prices and other terms of service. Long-term wholesale sales of electricity are based on individual bilateral contracts. Short-term wholesale sales of electricity are generally on a daily basis based on market prices and are administered by the Independent System Operator-New England (ISO-NE) and the New York Independent System Operator (NYISO), or PJM Interconnection, L.L.C. (PJM), as applicable. Wholesale sales of natural gas are generally short-term based on market prices through contracts with the specific customer.
The performance obligation in all arrangements is satisfied over time because the customer simultaneously receives and consumes the benefits as Networks delivers or sells the electricity or natural gas or provides the transmission service. We record revenue for all of those sales based upon the regulatory-approved tariff and the volume delivered or transmitted, which corresponds to the amount that we have a right to invoice. There are no material initial incremental costs of obtaining a contract in any of the arrangements. Networks does not adjust the promised consideration for the effects of a significant financing component if it expects, at contract inception, that the time between the delivery of promised goods or service and customer payment will be one year or less. Networks does not have any material significant payment terms because it receives payment at or shortly after the point of sale. For its New York utilities, Networks assesses its deferred payment arrangements at each balance sheet date for the existence of significant financing components, but has had no material adjustments as a result.
Certain Networks entities record revenue from Alternative Revenue Programs (ARPs), which is not ASC 606 revenue. Such programs represent contracts between the utilities and their regulators. The Networks ARPs include revenue decoupling mechanisms, other
14
ratemaking mechanisms, annual revenue requirement reconciliations, and other demand side management progra ms. The Networks entities recognize and record only the initial recognition of “originating” ARP revenues (when the regulatory-specified conditions for recognition have been met). When they subsequently include those amounts in the price of utility service billed to customers, they record such amounts as a recovery of the associated regulatory asset or liability. When they owe amounts to customers in connection with ARPs, they evaluate those amounts on a quarterly basis and include them in the price of util ity service billed to customers and do not reduce ARP revenues.
Networks also has various other sources of revenue including billing, collection, other administrative charges, sundry billings, rent of utility property, and miscellaneous revenue. It classifies such revenues as other ASC 606 revenues to the extent they are not related to revenue generating activities from leasing, derivatives, or ARPs.
Renewables Segment
Renewables derives its revenue primarily from the sale of energy, transmission, capacity and other related charges from its renewable wind, solar, and thermal energy generating sources. For such revenues, we will recognize revenues in an amount derived from the commodities delivered and from services as they are made available. Renewables has bundled power purchase agreements consisting of electric energy, transmission, capacity and/or renewable energy credits (RECs). The related contracts are generally long-term with no stated contract amount, that is, the customer is entitled to all of the unit’s output. Renewables also has unbundled sales of electric energy and capacity, RECs and natural gas, which are generally for periods of less than a year. The performance obligations in substantially all of both bundled and unbundled arrangements for electricity and natural gas are satisfied over time, for which we record revenue based on the amount invoiced to the customer for the actual energy delivered. The performance obligation for stand-alone RECs is satisfied at a point in time, for which we record revenue when the performance obligation is satisfied upon delivery of the REC. Renewables does not have any material significant payment terms because it receives payment at or shortly after the point of sale. There are no material initial incremental costs of obtaining a contract or significant financing elements in any of the arrangements.
Renewables classifies certain contracts for the sale of electricity as either leases or derivatives, in accordance with the applicable accounting standards. Renewables also has revenue from its energy trading operations, which it generally classifies as derivative revenue. However, trading contracts not classified as derivatives are within the scope of ASC 606, with the performance obligation of the delivery of energy (electricity, natural gas) and settlement of the contracts satisfied at a point in time at which time we recognize the revenue. Renewables also has other ASC 606 revenue, which we recognize based on the amount invoiced to the customer.
Certain customers may receive cash credits, which we account for as variable consideration. Renewables estimates those amounts based on the expected amount to be provided to customers and reduces revenues recognized. We believe that there will not be significant changes to our estimates of variable consideration.
Other
Other, which does not represent a segment, derives its revenues primarily from providing natural gas storage services to customers, gas trading operations generally classified as derivative revenue in accordance with the applicable accounting standards, gas trading contracts not classified as derivatives, and other miscellaneous revenues including intersegment eliminations. See Note 20 – Assets Held For Sale for further discussion of the sale of the gas storage and trading businesses in the six months ended June 30, 2018.
Contract Costs and Practical Expedient
We recognize an asset for incremental costs of obtaining a contract with a customer when we expect the benefit of those costs to be longer than one year. Renewables has an origination sharing bonus plan that meets the requirements for capitalization. Costs incurred prior to 2018 were insignificant and not capitalized. Costs capitalized to date in 2018 are also insignificant, with amortization on a straight-line basis over the term of the related contract for which the terms may be from three years to 20 years. We apply a practical expedient to expense as incurred costs to obtain a contract when the amortization period is one year or less. We record costs incurred to obtain a contract within operating expenses, including amortization of capitalized costs.
Revenues disaggregated by major source for our reportable segments for the three and six months ended June 30, 2018 are as follows:
15
|
Three Months Ended June 30, 2018 |
|
||||||||||||||
|
|
Networks |
|
|
Renewables |
|
|
Other (b) |
|
|
Total |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Regulated operations – electricity |
|
$ |
800 |
|
|
$ |
— |
|
|
$ |
— |
|
|
$ |
800 |
|
Regulated operations – natural gas |
|
|
266 |
|
|
|
— |
|
|
|
— |
|
|
|
266 |
|
Nonregulated operations – wind |
|
|
— |
|
|
|
180 |
|
|
|
— |
|
|
|
180 |
|
Nonregulated operations – solar |
|
|
— |
|
|
|
6 |
|
|
|
— |
|
|
|
6 |
|
Nonregulated operations – thermal |
|
|
— |
|
|
|
1 |
|
|
|
— |
|
|
|
1 |
|
Nonregulated operations – gas storage |
|
|
— |
|
|
|
— |
|
|
|
6 |
|
|
|
6 |
|
Other (a) |
|
|
6 |
|
|
|
(10 |
) |
|
|
(6 |
) |
|
|
(10 |
) |
Revenue from contracts with customers |
|
|
1,072 |
|
|
|
177 |
|
|
|
— |
|
|
|
1,249 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Leasing revenue |
|
|
9 |
|
|
|
98 |
|
|
|
— |
|
|
|
107 |
|
Derivative revenue |
|
|
— |
|
|
|
22 |
|
|
|
— |
|
|
|
22 |
|
Alternative revenue programs |
|
|
25 |
|
|
|
— |
|
|
|
— |
|
|
|
25 |
|
Other revenue |
|
|
(1 |
) |
|
|
— |
|
|
|
— |
|
|
|
(1 |
) |
Total operating revenues |
|
$ |
1,105 |
|
|
$ |
297 |
|
|
$ |
— |
|
|
$ |
1,402 |
|
|
|
Six Months Ended June 30, 2018 |
|
|||||||||||||
|
|
Networks |
|
|
Renewables |
|
|
Other (b) |
|
|
Total |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Regulated operations – electricity |
|
$ |
1,726 |
|
|
$ |
— |
|
|
$ |
— |
|
|
$ |
1,726 |
|
Regulated operations – natural gas |
|
|
838 |
|
|
|
— |
|
|
|
— |
|
|
|
838 |
|
Nonregulated operations – wind |
|
|
— |
|
|
|
348 |
|
|
|
— |
|
|
|
348 |
|
Nonregulated operations – solar |
|
|
— |
|
|
|
8 |
|
|
|
— |
|
|
|
8 |
|
Nonregulated operations – thermal |
|
|
— |
|
|
|
14 |
|
|
|
— |
|
|
|
14 |
|
Nonregulated operations – gas storage |
|
|
— |
|
|
|
— |
|
|
|
10 |
|
|
|
10 |
|
Other (a) |
|
|
31 |
|
|
|
(33 |
) |
|
|
9 |
|
|
|
7 |
|
Revenue from contracts with customers |
|
|
2,595 |
|
|
|
337 |
|
|
|
19 |
|
|
|
2,951 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Leasing revenue |
|
|
18 |
|
|
|
179 |
|
|
|
— |
|
|
|
197 |
|
Derivative revenue |
|
|
— |
|
|
|
65 |
|
|
|
10 |
|
|
|
75 |
|
Alternative revenue programs |
|
|
44 |
|
|
|
— |
|
|
|
— |
|
|
|
44 |
|
Other revenue |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Total operating revenues |
|
$ |
2,657 |
|
|
$ |
581 |
|
|
$ |
29 |
|
|
$ |
3,267 |
|
|
(a) |
Primarily includes certain intra-month trading activities, billing, collection, and administrative charges, sundry billings, and other miscellaneous revenue. |
|
(b) |
Does not represent a segment. Includes Corporate, Gas and intersegment eliminations. |
As of June 30, 2018, accounts receivable balances related to contracts with customers were approximately $946 million, which are included in “ Accounts receivable and unbilled revenues, net” on our condensed consolidated balance sheets.
As of June 30, 2018, for contracts with durations greater than one year (1) the aggregate amount of the transaction price allocated to performance obligations that are unsatisfied (or partially unsatisfied), and (2) when we expect to recognize the revenue, were as follows:
16
|
|
|
||||||||||||||||||||||||||
As of June 30, 2018 |
|
2019 |
|
|
2020 |
|
|
2021 |
|
|
2022 |
|
|
2023 |
|
|
Thereafter |
|
|
Total |
|
|||||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Revenue expected to be recognized on multiyear retail energy sales contracts in place |
|
$ |
4 |
|
|
$ |
7 |
|
|
$ |
8 |
|
|
$ |
9 |
|
|
$ |
9 |
|
|
$ |
34 |
|
|
$ |
71 |
|
Revenue expected to be recognized on multiyear capacity and carbon- free energy sale contracts |
|
|
4 |
|
|
|
14 |
|
|
|
8 |
|
|
|
3 |
|
|
|
3 |
|
|
|
4 |
|
|
|
36 |
|
Revenue expected to be recognized on multiyear renewable energy credit sale contracts |
|
|
9 |
|
|
|
17 |
|
|
|
10 |
|
|
|
8 |
|
|
|
4 |
|
|
|
9 |
|
|
|
57 |
|
Total operating revenues |
|
$ |
17 |
|
|
$ |
38 |
|
|
$ |
26 |
|
|
$ |
20 |
|
|
$ |
16 |
|
|
$ |
47 |
|
|
$ |
164 |
|
We do not disclose information about remaining performance obligations for (i) contracts with an original expected duration of one year or less and (ii) contracts for which we recognize revenue in the amount to which we have the right to invoice (e.g., usage-based pricing terms).
Note 5. Regulatory Assets and Liabilities
Pursuant to the requirements concerning accounting for regulated operations, our utilities capitalize, as regulatory assets, incurred and accrued costs that are probable of recovery in future electric and natural gas rates. We base our assessment of whether recovery is probable on the existence of regulatory orders that allow for recovery of certain costs over a specific period, or allow for reconciliation or deferral of certain costs. When costs are not treated in a specific order, we use regulatory precedent to determine if recovery is probable. Our operating utilities also record, as regulatory liabilities, obligations to refund previously collected revenue or to spend revenue collected from customers on future costs. The primary items that are not included in the rate base or accruing carrying costs are the regulatory assets for qualified pension and other postretirement benefits, which reflect unrecognized actuarial gains and losses, debt premium, environmental remediation costs, which is primarily the offset of accrued liabilities for future spending, unfunded future income taxes, which are the offset to the unfunded future deferred income tax liability recorded , asset retirement obligations, hedge losses and contracts for differences. The total net amount of these items is approximately $1,803 million.
The regulatory assets and regulatory liabilities shown in the tables below result from various regulatory orders that allow for the deferral and/or reconciliation of specific costs. Regulatory assets and regulatory liabilities are classified as current when recovery or refund in the coming year is allowed or required through a specific order or when the rates related to a specific regulatory asset or regulatory liability are subject to automatic annual adjustment.
On August 25, 2014, the Maine Public Utility Commission (MPUC) approved a stipulation agreement that provided for a distribution rate increase for Central Maine Power (CMP) of approximately $24.3 million, effective July 1, 2014, with an allowed return on equity (ROE) of 9.45% and an allowed equity ratio of 50%. The stipulation provided for the implementation of a revenue decoupling mechanism (RDM), reserve accounting and sharing of incremental storm costs, a separate proceeding for recovery of a new billing system and no earning sharing. On May 29, 2018, a ten-person complaint was filed with the MPUC against CMP, Networks and AVANGRID. The complaint requested that the MPUC open a rate case to determine if CMP is making excessive returns on investment and, therefore, whether CMP’s retail rates should be lower. The complaint also requested the MPUC deny certain costs associated with the October 2017 windstorm. On July 24, 2018, the MPUC issued an order dismissing the complaint and its associated request to deny the recovery of costs associated with the October 2017 windstorm. The order initiated an investigation into CMP’s rates and revenue requirement and directed CMP to make a filing consistent with the requirements for a general rate case no later than October 15, 2018. We cannot predict the outcome of this matter.
On June 15, 2016, the New York State Public Service Commission (NYPSC) approved the Joint Proposal filed with the NYPSC by New York State Electric & Gas Corporation (NYSEG) and Rochester Gas and Electric Corporation (RG&E) and by certain other signatory parties on February 19, 2016, in connection with a three-year rate plan for electric and gas service at NYSEG and RG&E effective May 1, 2016. Following the approval of the Joint Proposal most of these items related to NYSEG are amortized over a five-year period, except the portion of storm costs to be recovered over ten years, unfunded deferred taxes being amortized over a period of fifty years and plant related tax items which are amortized over the life of associated plant. Annual amortization expense for NYSEG is approximately $16.5 million per rate year. RG&E items that are being amortized are plant related tax items, which are amortized over the life of associated plant, and unfunded deferred taxes being amortized over a period of fifty years. A majority of the other items related to RG&E, which net to a regulatory liability, remain deferred and will not be amortized until future proceedings.
The approved Joint Proposal provides for annual rate increases and an allowed rate of return on common equity of 9.0% for each of NYSEG and RG&E. The equity ratio for each company is 48%; however, the equity ratio is set at the actual up to 50% for earnings
17
sharing calculation purposes. The customer share of any earnings above allowed levels increases as the ROE increases, with cus tomers receiving 50%, 75% and 90% of earnings over 9.5%, 10.0% and 10.5% ROE, respectively, in the first rate year covering the period May 1, 2016 – April 30, 2017. The earnings sharing levels increase in rate year two (May 1, 2017 – April 30, 2018) to 9. 65%, 10.15% and 10.65% ROE, respectively . The earnings sharing levels further increase in rate year three (May 1, 2018 – April 30, 2019) to 9.75%, 10.25% and 10.75% ROE, respectively. The rate plans also include the implementation of a rate adjustment mech anism designed to return or collect certain defined reconciled revenues and costs, new depreciation rates, and continuation of the existing RDM for each company.
In December 2016, the Connecticut Public Utilities Regulatory Authority (PURA) approved new distribution rate schedules for The United Illuminating Company (UI) for three years, which became effective January 1, 2017. These new distribution schedules provide for, among other things, annual tariff increases and an ROE of 9.10% based on a 50% equity ratio, continued UI’s existing earnings sharing mechanism (ESM) pursuant to which UI and its customers share on a 50/50 basis all distribution earnings above the allowed ROE in a calendar year, and the continued existence of a decoupling mechanism. The schedules also approved the continuation of the requested storm reserve. Any dollars due to customers from the ESM continue to be first applied against any storm regulatory asset balance (if one exists at that time) or refunded to customers through a bill credit if such storm regulatory asset balance does not exist.
In December 2017, PURA approved new tariffs for the Southern Connecticut Gas Company (SCG) effective January 1, 2018 for a three-year rate plan with rate increases of $1.5 million, $4.7 million and $5.0 million in 2018, 2019, and 2020, respectively. The new tariff also includes an RDM and Distribution Integrity Management Program (DIMP) mechanism similar to the mechanisms authorized for Connecticut Natural Gas Corporation (CNG) , ESM, the amortization of certain regulatory liabilities (most notably accumulated hardship deferral balances and certain accumulated deferred income taxes) and tariff increases based on a ROE of 9.25% and approximately 52% equity level. Any dollars due to customers from the ESM will be first applied against any environmental regulatory asset balance as defined in the settlement agreement (if one exists at that time) or refunded to customers through a bill credit if such environmental regulatory asset balance does not exist.
On May 17, 2018, The Berkshire Gas Company (BGC) filed a petition with the Department of Public Utilities (DPU) for approval of a general increase in its gas distribution rates to be effective April 1, 2019. BGC requested an increase to the base distribution rate revenue requirement of $4.54 million, offset by decreases in other factors of $1.43 million, resulting in a net change in operating revenue of $3.11 million, and a 10.35% ROE applied to existing capital structure. BGC’s filing takes into account the reduction in the federal corporate income tax rate that results from the Tax Act, which became effective January 1, 2018. As part of the filing, BGC also proposed an alternative ratemaking mechanism (ARM) that will allow it to annually adjust its rates without filing for a base rate proceeding. The proposed ARM has a five-year term that begins in 2019 with the establishment of rates approved in this proceeding and is followed by four annual rate adjustments in 2020 through 2023. Further, BGC proposed to implement a rate mechanism to decouple its gas revenues from its sales and a reconciling mechanism to recover costs associated with pension and other post-retirement employee benefits.
On June 29, 2018, Connecticut Natural Gas Corporation (CNG) filed an application with PURA for new tariffs to become effective January 1, 2019. CNG requested a three-year rate plan for calendar years 2019, 2020 and 2021. The Application requests an increase in rates of $16.6 million in 2019, an incremental increase of $10.1 million in 2020, and an incremental increase of $1.1 million in 2021. In addition, the application proposes to implement a customer rate credit of $1.25 million per year through 2027 as an offset in base rates, arising from the merger commitments made in connection with AVANGRID’s acquisition of UIL Holdings Corporation (UIL) in December 2015; a return to customers of the full tax benefits resulting from the reduction in the corporate federal income tax rate in the Tax Act; and ratemaking proposals to transition the DIMP mechanism to operate as a true-up mechanism, and to apply CNG’s current decoupling mechanism to all firm customers going forward .
Current and non-current regulatory assets as of June 30, 2018 and December 31, 2017, respectively, consisted of:
18
|
June 30, |
|
|
December 31, |
|
|||
As of |
|
2018 |
|
|
2017 |
|
||
(Millions) |
|
|
|
|
|
|
|
|
Current |
|
|
|
|
|
|
|
|
Pension and other post-retirement benefits cost deferrals |
|
$ |
24 |
|
|
$ |
24 |
|
Pension and other post-retirement benefits |
|
|
12 |
|
|
|
7 |
|
Storm costs |
|
|
52 |
|
|
|
46 |
|
Temporary supplemental assessment surcharge |
|
|
1 |
|
|
|
— |
|
Reliability support services |
|
|
26 |
|
|
|
27 |
|
Revenue decoupling mechanism |
|
|
19 |
|
|
|
21 |
|
Transmission revenue reconciliation mechanism |
|
|
4 |
|
|
|
8 |
|
Electric supply reconciliation |
|
|
2 |
|
|
|
— |
|
Hedges losses |
|
|
— |
|
|
|
3 |
|
Contracts for differences |
|
|
7 |
|
|
|
9 |
|
Hardship programs |
|
|
13 |
|
|
|
14 |
|
Deferred property tax |
|
|
10 |
|
|
|
10 |
|
Plant decommissioning |
|
|
6 |
|
|
|
6 |
|
Deferred purchased gas |
|
|
1 |
|
|
|
31 |
|
Deferred transmission expense |
|
|
42 |
|
|
|
37 |
|
Environmental remediation costs |
|
|
13 |
|
|
|
13 |
|
Other |
|
|
56 |
|
|
|
51 |
|
Total Current Regulatory Assets |
|
|
288 |
|
|
|
307 |
|
Non-current |
|
|
|
|
|
|
|
|
Pension and other post-retirement benefits cost deferrals |
|
|
113 |
|
|
|
110 |
|
Pension and other post-retirement benefits |
|
|
1,076 |
|
|
|
1,162 |
|
Storm costs |
|
|
350 |
|
|
|
254 |
|
Deferred meter replacement costs |
|
|
28 |
|
|
|
29 |
|
Unamortized losses on reacquired debt |
|
|
16 |
|
|
|
17 |
|
Environmental remediation costs |
|
|
276 |
|
|
|
283 |
|
Unfunded future income taxes |
|
|
369 |
|
|
|
376 |
|
Asset retirement obligation |
|
|
19 |
|
|
|
18 |
|
Deferred property tax |
|
|
4 |
|
|
|
14 |
|
Federal tax depreciation normalization adjustment |
|
|
153 |
|
|
|
155 |
|
Merger capital expense target customer credit |
|
|
1 |
|
|
|
2 |
|
Debt premium |
|
|
124 |
|
|
|
131 |
|
Reliability support services |
|
|
— |
|
|
|
10 |
|
Plant decommissioning |
|
|
6 |
|
|
|
9 |
|
Contracts for differences |
|
|
92 |
|
|
|
84 |
|
Hardship programs |
|
|
10 |
|
|
|
13 |
|
Deferred income taxes regulatory |
|
|
22 |
|
|
|
— |
|
Other |
|
|
63 |
|
|
|
71 |
|
Total Non-current Regulatory Assets |
|
$ |
2,722 |
|
|
$ |
2,738 |
|
“Pension and other post-retirement benefits” represent the actuarial losses on the pension and other post-retirement plans that will be reflected in customer rates when they are amortized and recognized in future pension expenses. “Pension and other post-retirement benefits cost deferrals” include the difference between actual expense for pension and other post-retirement benefits and the amount provided for in rates for certain of our regulated utilities. The recovery of these amounts will be determined in future proceedings.
“Storm costs” for CMP, NYSEG and RG&E are allowed in rates based on an estimate of the routine costs of service restoration. The companies are also allowed to defer unusually high levels of service restoration costs resulting from major storms when they meet certain criteria for severity and duration. Storm costs in the amount of $123 million at NYSEG are being recovered over a ten-year period and the remaining portion is being amortized over five years following the approval of the Joint Proposal by the NYPSC. UI is allowed to defer costs associated with any storm totaling $1 million or greater for future recovery. UI’s storm regulatory asset balance was $0 as of June 30, 2018.
“Deferred meter replacement costs” represent the deferral of the book value of retired meters that were replaced by advanced metering infrastructure meters. This amount is being amortized over the initial depreciation period of related retired meters.
19
“Unamortized losses on reacquired debt” represent deferred losses on debt reacquisitions that will be recovered over the remaining origina l amortization period of the reacquired debt.
“Unfunded future income taxes” represent unrecovered federal and state income taxes primarily resulting from regulatory flow through accounting treatment and are the offset to the unfunded future deferred income tax liability recorded. The income tax benefits or charges for certain plant related timing differences, such as removal costs, are immediately flowed through to, or collected from, customers. This amount is being amortized as the amounts related to temporary differences that give rise to the deferrals are recovered in rates. Following the approval of the Joint Proposal by the NYPSC, these amounts will be collected over a fifty-year period, and the NYPSC Staff has initiated an audit, as required, of the unfunded future income taxes and other tax assets to verify the balances.
“Asset retirement obligations” (ARO) represent the differences in timing of the recognition of costs associated with our AROs and the collection of such amounts through rates. This amount is being amortized at the related depreciation and accretion amounts of the underlying liability.
“Deferred property taxes” represents the customer portion of the difference between actual expense for property taxes and the amount provided for in rates. The amount for NYSEG and RG&E is being amortized over a five year period following the approval of the Joint Proposal by the NYPSC.
“Federal tax depreciation normalization adjustment” represents the revenue requirement impact of the difference in the deferred income tax expense required to be recorded under the IRS normalization rules and the amount of deferred income tax expense that was included in cost of service for rates years covering 2011 forward. The recovery period in New York is from 27 to 39 years and for CMP this will be determined in future MPUC rate proceedings.
“Hardship Programs” represent hardship customer accounts deferred for future recovery to the extent they exceed the amount in rates.
“Deferred Purchased Gas” represents the difference between actual gas costs and gas costs collected in rates.
“Environmental remediation costs” includes spending that has occurred and is eligible for future recovery in customer rates. Environmental costs are currently recovered through a reserve mechanism whereby projected spending is included in rates with any variance recorded as a regulatory asset or a regulatory liability. The amortization period will be established in future proceedings and will depend upon the timing of spending for the remediation costs. It also includes the anticipated future rate recovery of costs that are recorded as environmental liabilities since these will be recovered when incurred. Because no funds have yet been expended for the regulatory asset related to future spending, it does not accrue carrying costs and is not included within rate base.
“Contracts for Differences” (CfDs) represent the deferral of unrealized gains and losses on contracts for differences derivative contracts. The balance fluctuates based upon quarterly market analysis performed on the related derivatives. The amounts, which do not earn a return, are fully offset by a corresponding derivative asset/liability.
“Debt premium” represents the regulatory asset recorded to offset the fair value adjustment to the regulatory component of the non-current debt of UIL at the acquisition date. This amount is being amortized to interest expense over the remaining term of the related outstanding debt instruments.
“Deferred Transmission Expense” represents deferred transmission income or expense and fluctuates based upon actual revenues and revenue requirements.
“Reliability support services” represents the difference between actual expenses for reliability support services and the amount provided for in rates.
“Other” includes post term amortization deferrals and various items subject to reconciliation including rate change levelization and loss on re-acquired debt.
Current and non-current regulatory liabilities as of June 30, 2018 and December 31, 2017, respectively, consisted of:
20
|
June 30, |
|
|
December 31, |
|
|||
As of |
|
2018 |
|
|
2017 |
|
||
(Millions) |
|
|
|
|
|
|
|
|
Current |
|
|
|
|
|
|
|
|
Non by-passable charges |
|
$ |
— |
|
|
$ |
5 |
|
Energy efficiency portfolio standard |
|
|
47 |
|
|
|
37 |
|
Gas supply charge and deferred natural gas cost |
|
|
11 |
|
|
|
4 |
|
Transmission revenue reconciliation mechanism |
|
|
10 |
|
|
|
14 |
|
Pension and other post-retirement benefits |
|
|
— |
|
|
|
1 |
|
Pension and other post-retirement benefits cost deferrals |
|
|
14 |
|
|
|
14 |
|
Carrying costs on deferred income tax bonus depreciation |
|
|
21 |
|
|
|
21 |
|
Carrying costs on deferred income tax - Mixed Services 263(a) |
|
|
5 |
|
|
|
5 |
|
Yankee DOE Refund |
|
|
— |
|
|
|
4 |
|
Merger related rate credits |
|
|
— |
|
|
|
1 |
|
Revenue decoupling mechanism |
|
|
3 |
|
|
|
4 |
|
Stranded costs |
|
|
8 |
|
|
|
17 |
|
Other |
|
|
73 |
|
|
|
51 |
|
Total Current Regulatory Liabilities |
|
|
192 |
|
|
|
178 |
|
Non-current |
|
|
|
|
|
|
|
|
Accrued removal obligations |
|
|
1,148 |
|
|
|
1,132 |
|
2017 Tax Act |
|
|
1,562 |
|
|
|
1,515 |
|
Asset sale gain account |
|
|
10 |
|
|
|
10 |
|
Carrying costs on deferred income tax bonus depreciation |
|
|
62 |
|
|
|
72 |
|
Economic development |
|
|
27 |
|
|
|
32 |
|
Merger capital expense target customer credit account |
|
|
6 |
|
|
|
6 |
|
Pension and other post-retirement benefits cost deferrals |
|
|
67 |
|
|
|
74 |
|
Positive benefit adjustment |
|
|
38 |
|
|
|
39 |
|
New York state tax rate change |
|
|
5 |
|
|
|
6 |
|
Theoretical reserve flow thru impact |
|
|
17 |
|
|
|
19 |
|
Deferred property tax |
|
|
22 |
|
|
|
19 |
|
Net plant reconciliation |
|
|
18 |
|
|
|
10 |
|
Variable rate debt |
|
|
38 |
|
|
|
33 |
|
Carrying costs on deferred income tax - Mixed Services 263(a) |
|
|
18 |
|
|
|
20 |
|
Rate refund – FERC ROE proceeding |
|
|
27 |
|
|
|
27 |
|
Transmission congestion contracts |
|
|
21 |
|
|
|
19 |
|
Merger-related rate credits |
|
|
19 |
|
|
|
20 |
|
Accumulated deferred investment tax credits |
|
|
13 |
|
|
|
13 |
|
Asset retirement obligation |
|
|
13 |
|
|
|
13 |
|
Earning sharing provisions |
|
|
14 |
|
|
|
22 |
|
Middletown/Norwalk local transmission network service collections |
|
|
18 |
|
|
|
19 |
|
Excess generation service charge |
|
|
— |
|
|
|
2 |
|
Low income programs |
|
|
37 |
|
|
|
42 |
|
Non-firm margin sharing credits |
|
|
13 |
|
|
|
8 |
|
Deferred income taxes regulatory |
|
|
— |
|
|
|
13 |
|
Other |
|
|
81 |
|
|
|
67 |
|
Total Non-current Regulatory Liabilities |
|
$ |
3,294 |
|
|
$ |
3,252 |
|
“Non by-passable charges” represent the non by-passable charges paid by all customers. An asset or liability is recognized resulting from differences between actual revenues and the underlying cost being recovered. This liability will be refunded to customers within the next year.
21
“Energy efficiency portfolio standard” represents the difference between amounts bille d to customers through an energy efficiency charge and the costs of our energy efficiency programs as approved by the state authorities. This may be refunded to customers within the next year.
“Accrued removal obligations” represent the differences between asset removal costs recorded and amounts collected in rates for those costs. The amortization period is dependent upon the asset removal costs of underlying assets and the life of the utility plant.
“Asset sale gain account” represents the gain on NYSEG’s 2001 sale of its interest in Nine Mile Point 2 nuclear generating station located in Oswego, New York. The net proceeds from the Nine Mile Point 2 nuclear generating station were placed in this account and will be used to benefit customers. The amortization period is five years following the approval of the Joint Proposal by the NYPSC.
“Carrying costs on deferred income tax bonus depreciation” represent the carrying costs benefit of increased accumulated deferred income taxes created by the change in tax law allowing bonus depreciation. The amortization period is five years following the approval of the Joint Proposal by the NYPSC.
“Economic development” represents the economic development program which enables NYSEG and RG&E to foster economic development through attraction, expansion and retention of businesses within its service territory. If the level of actual expenditures for economic development allocated to NYSEG and RG&E varies in any rate year from the level provided for in rates, the difference is refunded to ratepayers. The amortization period is five years following the approval of the Joint Proposal by the NYPSC.
“Merger capital expense target customer credit” account was created as a result of NYSEG and RG&E not meeting certain capital expenditure requirements established in the order approving the purchase of AVANGRID (formerly Energy East Corporation) by Iberdrola. The amortization period is five years following the approval of the Joint Proposal by the NYPSC.
“Pension and other postretirement benefits” represent the actuarial gains on other postretirement plans that will be reflected in customer rates when they are amortized and recognized in future expenses. Because no funds have yet been received for this, a regulatory liability is not reflected within the rate base. They also represent the difference between actual expense for pension and other postretirement benefits and the amount provided for in rates. Recovery of these amounts will be determined in future proceedings.
“Positive benefit adjustment” resulted from Iberdrola’s 2008 acquisition of AVANGRID (formerly Energy East Corporation). This is being used to moderate increases in rates. The amortization period is five years following the approval of the Joint Proposal by the NYPSC and included in the Ginna RSSA settlement.
“New York state tax rate change” represents excess funded accumulated deferred income tax balance caused by the 2014 New York state tax rate change from 7.1% to 6.5%. The amortization period is five years following the approval of the Joint Proposal by the NYPSC.
“Post term amortization” represents the revenue requirement associated with certain expired joint proposal amortization items. The amortization period is five years following the approval of the Joint Proposal by the NYPSC.
“Theoretical reserve flow thru impact” represents the differences from the rate allowance for applicable federal and state flow through impacts related to the excess depreciation reserve amortization. It also represents the carrying cost on the differences. The amortization period is five years following the approval of the Joint Proposal by the NYPSC.
“2017 Tax Act” represents the impact from remeasurement and over-recoveries as a result of the Tax Act. Reductions in accumulated deferred income tax balances due to the reduction in the corporate income tax rates from 35% to 21% under the provisions of the Tax Act will result in amounts previously and currently collected from utility customers for these deferred taxes to be refundable to such customers, generally through reductions in future rates. The NYPSC, MPUC, PURA and DPU have instituted separate proceedings in New York, Maine, Connecticut and Massachusetts, respectively, to review and address the implications associated with the Tax Act on the utilities providing service in such states.
“Merger-related rate credits” resulted from the acquisition of UIL. This is being used to moderate increases in rates. In the three and six months ended June 30, 2018, respectively, $1 million and $2 million of rate credits were applied against customer bills. In the three and six months ended June 30, 2017, respectively, $0 and $2 million of rate credits were applied against customer bills.
“Excess generation service charge” represents deferred generation-related and non by-passable federally mandated congestion costs or revenues for future recovery from or return to customers. The amount fluctuates based upon timing differences between revenues collected from rates and actual costs incurred.
22
“Low Income Progr ams” represent various hardship and payment plan programs approved for recovery.
“Other” includes cost of removal being amortized through rates and various items subject to reconciliation including variable rate debt, Medicare subsidy benefits and stray voltage collections.
Note 6. Fair Value of Financial Instruments and Fair Value Measurements
We determine the fair value of our derivative assets and liabilities and available for sale non-current investments associated with Networks’ activities utilizing market approach valuation techniques:
• |
We measure the fair value of our noncurrent investments using quoted market prices in active markets for identical assets and include the measurements in Level 1. The available for sale investments, which are Rabbi Trusts for deferred compensation plans, primarily consist of money market funds and are included in Level 1 fair value measurement. |
• |
NYSEG and RG&E enter into electric energy derivative contracts to hedge the forecasted purchases required to serve their electric load obligations. They hedge their electric load obligations using derivative contracts that are settled based upon Locational Based Marginal Pricing published by the NYISO. NYSEG and RG&E hedge approximately 70% of their electric load obligations using contracts for a NYISO location where an active market exists. The forward market prices used to value the companies’ open electric energy derivative contracts are based on quoted prices in active markets for identical assets or liabilities with no adjustment required and therefore we include the fair value in Level 1. |
• |
NYSEG and RG&E enter into natural gas derivative contracts to hedge their forecasted purchases required to serve their natural gas load obligations. The forward market prices used to value open natural gas derivative contracts are exchange-based prices for the identical derivative contracts traded actively on the New York Mercantile Exchange (NYMEX). Because we use prices quoted in an active market we include the fair value measurements in Level 1. |
• |
NYSEG, RG&E and CMP enter into fuel derivative contracts to hedge their unleaded and diesel fuel requirements for their fleet vehicles. Exchange-based forward market prices are used, but because an unobservable basis adjustment is added to the forward prices, we include the fair value measurement for these contracts in Level 3. |
• |
UI enters into CfDs, which are marked-to-market based on a probability-based expected cash flow analysis that is discounted at risk-free interest rates and an adjustment for non-performance risk using credit default swap rates. We include the fair value measurement for these contracts in Level 3 (See Note 7 for further discussion of CfDs). |
We determine the fair value of our derivative assets and liabilities associated with Renewables and Gas activities utilizing market approach valuation techniques. Exchange-traded transactions, such as NYMEX futures contracts, that are based on quoted market prices in active markets for identical product with no adjustment are included in the Level 1 fair value. Contracts with delivery periods of two years or less which are traded in active markets and are valued with or derived from observable market data for identical or similar products such as over-the-counter NYMEX, foreign exchange swaps, and fixed price physical and basis and index trades are included in Level 2 fair value. Contracts with delivery periods exceeding two years or that have unobservable inputs or inputs that cannot be corroborated with market data for identical or similar products are included in Level 3 fair value. The unobservable inputs include historical volatilities and correlations for tolling arrangements and extrapolated values for certain power swaps. The valuation for this category is based on our judgments about the assumptions market participants would use in pricing the asset or liability since limited market data exists.
We determine the fair value of our interest rate swap derivative instruments based on a model whose inputs are observable, such as the London Interbank Offered Rate (LIBOR) forward interest rate curves. We include the fair value measurement for these contracts in Level 2 (See Note 7 for further discussion of interest rate swaps).
The carrying amounts for cash and cash equivalents, restricted cash, accounts receivable, accounts payable, notes payable and interest accrued approximate their estimated fair values and are considered Level 1.
Restricted cash was $5 million as of both June 30, 2018 and December 31, 2017, which is included in “Other Assets” on the balance sheet.
23
The financial instruments measured at fair value as of June 30, 2018 and December 31, 2017, respectively, consisted of:
As of June 30, 2018 |
|
Level 1 |
|
|
Level 2 |
|
|
Level 3 |
|
|
Netting |
|
|
Total |
|
|||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Securities portfolio (available for sale) |
|
$ |
41 |
|
|
$ |
— |
|
|
$ |
— |
|
|
$ |
— |
|
|
$ |
41 |
|
Derivative assets |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative financial instruments - power |
|
|
11 |
|
|
|
30 |
|
|
|
81 |
|
|
|
(46 |
) |
|
76 |
|
|
Derivative financial instruments - gas |
|
|
— |
|
|
|
9 |
|
|
|
41 |
|
|
|
(50 |
) |
|
|
— |
|
Contracts for differences |
|
|
— |
|
|
|
— |
|
|
|
7 |
|
|
|
— |
|
|
7 |
|
|
Total |
|
|
11 |
|
|
|
39 |
|
|
|
129 |
|
|
|
(96 |
) |
|
|
83 |
|
Derivative liabilities |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative financial instruments - power |
|
|
(9 |
) |
|
|
(25 |
) |
|
|
(15 |
) |
|
|
44 |
|
|
|
(5 |
) |
Derivative financial instruments - gas |
|
|
— |
|
|
|
(14 |
) |
|
|
(8 |
) |
|
|
15 |
|
|
|
(7 |
) |
Contracts for differences |
|
|
— |
|
|
|
— |
|
|
|
(107 |
) |
|
|
— |
|
|
|
(107 |
) |
Derivative financial instruments – Other |
|
|
— |
|
|
|
(7 |
) |
|
|
— |
|
|
|
— |
|
|
|
(7 |
) |
Total |
|
$ |
(9 |
) |
|
$ |
(46 |
) |
|
$ |
(130 |
) |
|
$ |
59 |
|
|
$ |
(126 |
) |
As of December 31, 2017 |
|
Level 1 |
|
|
Level 2 |
|
|
Level 3 |
|
|
Netting |
|
|
Total |
|
|||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Securities portfolio (available for sale) |
|
$ |
41 |
|
|
$ |
— |
|
|
$ |
— |
|
|
$ |
— |
|
|
$ |
41 |
|
Derivative assets |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative financial instruments - power |
|
|
14 |
|
|
|
30 |
|
|
|
74 |
|
|
|
(49 |
) |
|
|
69 |
|
Derivative financial instruments - gas |
|
|
89 |
|
|
|
18 |
|
|
|
64 |
|
|
|
(146 |
) |
|
|
25 |
|
Contracts for differences |
|
|
— |
|
|
|
— |
|
|
|
12 |
|
|
|
— |
|
|
|
12 |
|
Total |
|
|
103 |
|
|
|
48 |
|
|
|
150 |
|
|
|
(195 |
) |
|
|
106 |
|
Derivative liabilities |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative financial instruments - power |
|
|
(14 |
) |
|
|
(17 |
) |
|
|
(15 |
) |
|
|
37 |
|
|
|
(9 |
) |
Derivative financial instruments - gas |
|
|
(80 |
) |
|
|
(20 |
) |
|
|
(25 |
) |
|
|
110 |
|
|
|
(15 |
) |
Contracts for differences |
|
|
— |
|
|
|
— |
|
|
|
(104 |
) |
|
|
— |
|
|
|
(104 |
) |
Total |
|
$ |
(94 |
) |
|
$ |
(37 |
) |
|
$ |
(144 |
) |
|
$ |
147 |
|
|
$ |
(128 |
) |
Included in the derivative financial instruments – gas are derivative assets and liabilities of the Gas segment classified as held for sale on the condensed consolidated balance sheet as of December 31, 2017. See Note 20 – Assets Held For Sale for further discussion.
The reconciliation of changes in the fair value of financial instruments based on Level 3 inputs for the three and six months ended June 30, 2018 and 2017, respectively, is as follows:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
(Millions) |
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
Fair Value Beginning of Period, |
|
$ |
(9 |
) |
|
$ |
33 |
|
|
$ |
6 |
|
|
$ |
31 |
|
Gains recognized in operating revenues |
|
|
9 |
|
|
|
— |
|
|
|
14 |
|
|
|
11 |
|
(Losses) recognized in operating revenues |
|
|
(2 |
) |
|
|
(2 |
) |
|
|
(6 |
) |
|
|
(3 |
) |
Total gains recognized in operating revenues |
|
|
7 |
|
|
|
(2 |
) |
|
|
8 |
|
|
|
8 |
|
Gains recognized in OCI |
|
|
2 |
|
|
|
— |
|
|
|
— |
|
|
|
1 |
|
(Losses) recognized in OCI |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(1 |
) |
Total gains recognized in OCI |
|
|
2 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Net change recognized in regulatory assets and liabilities |
|
|
3 |
|
|
|
7 |
|
|
|
(8 |
) |
|
|
2 |
|
Purchases |
|
|
(1 |
) |
|
|
(5 |
) |
|
|
(3 |
) |
|
|
(2 |
) |
Settlements |
|
|
(3 |
) |
|
|
(1 |
) |
|
|
(4 |
) |
|
|
(7 |
) |
Fair Value as of June 30, |
|
$ |
(1 |
) |
|
$ |
32 |
|
|
$ |
(1 |
) |
|
$ |
32 |
|
Gains (losses) for the period included in operating revenues attributable to the change in unrealized gains (losses) relating to financial instruments still held at the reporting date |
|
$ |
7 |
|
|
$ |
(2 |
) |
|
$ |
8 |
|
|
$ |
8 |
|
For assets and liabilities that are recognized in the condensed consolidated financial statements at fair value on a recurring basis, we determine whether transfers have occurred between levels in the hierarchy by re-assessing categorization based on the lowest level of
24
input that is significant to the fair value measurement as a whole at the end of each reporting period. There have been no transfers between Level 1 and Level 2 during the per iods reported.
Level 3 Fair Value Measurement
The tables below illustrate the significant sources of unobservable inputs used in the fair value measurement of our Level 3 derivatives and the variability in prices for those transactions classified as Level 3 derivatives.
As of June 30, 2018 |
|
|
|
|
|
|
|
|
|
|
|
|||||||||
Instruments |
|
Instrument Description |
|
Valuation Technique |
|
Valuation Inputs |
|
Index |
|
Avg. |
|
|
Max. |
|
|
Min. |
|
|||
Fixed price power and gas swaps |
|
Transactions with delivery periods |
|
Transactions are valued against forward market prices |
|
Observable and extrapolated forward gas and power prices not all of which can be |
|
NYMEX ($/MMBtu) |
|
$ |
2.94 |
|
|
$ |
3.93 |
|
|
$ |
2.50 |
|
with delivery |
|
exceeding two |
|
on a |
|
corroborated by |
|
Indiana hub ($/MWh) |
|
$ |
30.54 |
|
|
$ |
53.90 |
|
|
$ |
19.10 |
|
period > two |
|
years |
|
discounted |
|
market data for identical or |
|
Mid C ($/MWh) |
|
$ |
23.11 |
|
|
$ |
46.50 |
|
|
$ |
(0.50 |
) |
years |
|
|
|
basis |
|
similar products |
|
Minn hub ($/MWh) |
|
$ |
25.13 |
|
|
$ |
49.85 |
|
|
$ |
12.51 |
|
Our Level 3 valuations primarily consist of NYMEX gas and fixed price power swaps with delivery periods extending through 2024 and 2032, respectively. The gas swaps are used to hedge both gas inventory in firm storage and merchant wind positions. The power swaps are used to hedge merchant wind production in the West and Midwest.
We performed a sensitivity analysis around the Level 3 gas and power positions to changes in the valuation inputs. Given the nature of the transactions in Level 3, the only material input to the valuation is the market price of gas or power for transactions with delivery periods exceeding two years. The fixed price power swaps are economic hedges of future power generation, with decreases in power prices resulting in unrealized gains and increases in power prices resulting in unrealized losses. The gas swaps are economic hedges of merchant generation, with decreases in gas prices resulting in unrealized gains and increases in gas prices resulting in unrealized losses. As all transactions are economic hedges of the underlying position, any changes in the fair value of these transactions will be offset by changes in the anticipated purchase/sales price of the underlying commodity.
Two elements of the analytical infrastructure employed in valuing transactions are the price curves used in the calculation of market value and the models themselves. We maintain and document authorized trading points and associated forward price curves, and we develop and document models used in valuation of the various products.
Transactions are valued in part on the basis of forward price, correlation and volatility curves. We maintain and document descriptions of these curves and their derivations. Forward price curves used in valuing the transactions are applied to the full duration of the transaction.
The determination of the fair value of the CfDs (see Note 7 for further discussion of CfDs) was based on a probability-based expected cash flow analysis that was discounted at risk-free interest rates, as applicable, and an adjustment for non-performance risk using credit default swap rates. Certain management assumptions were required, including development of pricing that extended over the term of the contracts. We believe this methodology provides the most reasonable estimates of the amount of future discounted cash flows associated with the CfDs. Additionally, on a quarterly basis, we perform analytics to ensure that the fair value of the derivatives is consistent with changes, if any, in the various fair value model inputs. Significant isolated changes in the risk of non-performance, the discount rate or the contract term pricing would result in an inverse change in the fair value of the CfDs. Additional quantitative information about Level 3 fair value measurements of the CfDs is as follows:
|
|
Range at |
Unobservable Input |
|
June 30, 2018 |
Risk of non-performance |
|
0.63% - 0.68% |
Discount rate |
|
2.33% - 2.85% |
Forward pricing ($ per MWh) |
|
$4.30 - $9.55 |
25
As of June 30, 2018 and December 31, 2017, debt consisted of first mortgage bonds, fixed and variable unsecured pollution control notes, other various non-current debt securities and obligations under capital leases. The estimated fair value of debt amounted to $5,816 million and $5,799 million as of June 30, 2018 and December 31, 2017, respectively. The estimated fair value was determined, in most cases, by discounting the future cash flows at market interest rates. The interest rates used to make these calculations take into account the risks associated with the electricity industry and the credit ratings of the borrowers in each case. The fair value hierarchy pertaining to the fair value of debt is considered Level 2, except for unsecured pollution control notes-variable with a fair value of $61 million as of December 31, 2017, which were repaid in the second quarter of 2018 and were considered Level 3. The fair value of these unsecured pollution control notes-variable were determined using unobservable interest rates as the market for these notes is inactive.
On June 29, 2018, NYSEG and RG&E remarketed $326 million in aggregate principal amount of 1994 Series Pollution Control Revenue Bonds and 2004 Series Pollution Revenue Bonds, issued through the New York State Energy Research and Development Authority , with mandatory tender dates in 2023 and 2025 and interest rates ranging 2.625% - 3.00%.
Note 7. Derivative Instruments and Hedging
Our Networks, Renewables and Gas activities are exposed to certain risks, which are managed by using derivative instruments. All derivative instruments are recognized as either assets or liabilities at fair value on the condensed consolidated balance sheets in accordance with the accounting requirements concerning derivative instruments and hedging activities.
(a) Networks activities
NYSEG and RG&E each have an electric commodity charge that passes through rates costs for the market price of electricity. We use electricity contracts, both physical and financial, to manage fluctuations in electricity commodity prices in order to provide price stability to customers. We include the cost or benefit of those contracts in the amount expensed for electricity purchased when the related electricity is sold. We record changes in the fair value of electric hedge contracts to derivative assets and / or liabilities with an offset to regulatory assets and / or regulatory liabilities, in accordance with the accounting requirements concerning regulated operations.
The amount recognized in regulatory liabilities and assets for electricity derivatives was a gain of $2.0 million and a loss of $0.2 million as of June 30, 2018 and December 31, 2017, respectively. The amount reclassified from regulatory assets and liabilities into income, which is included in electricity purchased, was a loss of $1.2 million and a gain $4.6 million for the three and six months ended June 30, 2018, respectively, and a loss of $10.4 million and $21.3 million for the three and six months ended June 30, 2017, respectively.
NYSEG and RG&E each have purchased gas adjustment clauses that allow them to recover through rates any changes in the market price of purchased natural gas, substantially eliminating their exposure to natural gas price risk. NYSEG and RG&E use natural gas futures and forwards to manage fluctuations in natural gas commodity prices to provide price stability to customers. We include the cost or benefit of natural gas futures and forwards in the commodity cost that is passed on to customers when the related sales commitments are fulfilled. We record changes in the fair value of natural gas hedge contracts to derivative assets and / or liabilities with an offset to regulatory assets and / or regulatory liabilities in accordance with the accounting requirements for regulated operations.
The amount recognized in regulatory liabilities and assets for natural gas hedges was a gain of $0.1 million and a loss of $2.5 million as of June 30, 2018 and December 31, 2017, respectively. The amount reclassified from regulatory assets and liabilities into income, which is included in natural gas purchased, was a loss of $0 and $1.7 million for the three and six months ended June 30, 2018, respectively, and a gain of $0 and $0.6 million for the three and six months ended June 30, 2017, respectively.
Pursuant to a PURA order, UI and Connecticut’s other electric utility, The Connecticut Light and Power Company (CL&P), each executed two long-term CfDs with certain incremental capacity resources, each of which specifies a capacity quantity and a monthly settlement that reflects the difference between a forward market price and the contract price. The costs or benefits of each contract will be paid by or allocated to customers and will be subject to a cost-sharing agreement between UI and CL&P pursuant to which approximately 20% of the cost or benefit is borne by or allocated to UI customers and approximately 80% is borne by or allocated to CL&P customers.
PURA has determined that costs associated with these CfDs will be fully recoverable by UI and CL&P through electric rates, and UI has deferred recognition of costs (a regulatory asset) or obligations (a regulatory liability), including carrying costs. For those CfDs signed by CL&P, UI records its approximate 20% portion pursuant to the cost-sharing agreement noted above. As of June 30, 2018, UI has recorded a gross derivative asset of $7 million ($0 of which is related to UI’s portion of the CfD signed by CL&P), a regulatory asset of $99 million, a gross derivative liability of $107 million ($98 million of which is related to UI’s portion of the CfD signed by
26
CL&P) and a regulatory liability of $0. As of December 31, 2017, UI had recorded a gross derivative asset of $12 million ($0 of which is related to UI’s portion of the CfD signed by CL&P), a regulatory a sset of $93 million, a gross derivative liability of $104 million ($90 million of which is related to UI’s portion of the CfD signed by CL&P) and a regulatory liability of $0.
The unrealized gains and losses from fair value adjustments to these derivatives, which are recorded in regulatory assets or regulatory liabilities, for the three and six months ended June 30, 2018 and 2017, respectively, were as follows:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
$ |
(2 |
) |
|
$ |
(9 |
) |
|
$ |
(4 |
) |
|
$ |
(4 |
) |
Derivative liabilities |
|
$ |
6 |
|
|
$ |
5 |
|
|
$ |
(3 |
) |
|
$ |
6 |
|
The net notional volumes of the outstanding derivative instruments associated with Networks activities as of June 30, 2018 and December 31, 2017, respectively, consisted of:
|
|
June 30, |
|
|
December 31, |
|
||
As of |
|
2018 |
|
|
2017 |
|
||
(Millions) |
|
|
|
|
|
|
|
|
Wholesale electricity purchase contracts (MWh) |
|
|
3.7 |
|
|
|
3.9 |
|
Natural gas purchase contracts (Dth) |
|
|
6.7 |
|
|
|
6.1 |
|
Fleet fuel purchase contracts (Gallons) |
|
|
2.0 |
|
|
|
2.1 |
|
The offsetting of derivatives, location in the condensed consolidated balance sheet and amounts of derivatives associated with Networks activities as of June 30, 2018 and December 31, 2017, respectively, consisted of:
As of June 30, 2018 |
|
Current Assets |
|
|
Noncurrent Assets |
|
|
Current Liabilities |
|
|
Noncurrent Liabilities |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Not designated as hedging instruments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
$ |
14 |
|
|
$ |
5 |
|
|
$ |
7 |
|
|
$ |
2 |
|
Derivative liabilities |
|
|
(7 |
) |
|
|
(2 |
) |
|
|
(20 |
) |
|
|
(97 |
) |
|
|
|
7 |
|
|
|
3 |
|
|
|
(13 |
) |
|
|
(95 |
) |
Designated as hedging instruments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Derivative liabilities |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Total derivatives before offset of cash collateral |
|
|
7 |
|
|
|
3 |
|
|
|
(13 |
) |
|
|
(95 |
) |
Cash collateral receivable |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Total derivatives as presented in the balance sheet |
|
$ |
7 |
|
|
$ |
3 |
|
|
$ |
(13 |
) |
|
$ |
(95 |
) |
As of December 31, 2017 |
|
Current Assets |
|
|
Noncurrent Assets |
|
|
Current Liabilities |
|
|
Noncurrent Liabilities |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Not designated as hedging instruments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
$ |
20 |
|
|
$ |
5 |
|
|
$ |
13 |
|
|
$ |
— |
|
Derivative liabilities |
|
|
(13 |
) |
|
|
— |
|
|
|
(32 |
) |
|
|
(88 |
) |
|
|
|
7 |
|
|
|
5 |
|
|
|
(19 |
) |
|
|
(88 |
) |
Designated as hedging instruments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Derivative liabilities |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Total derivatives before offset of cash collateral |
|
|
7 |
|
|
|
5 |
|
|
|
(19 |
) |
|
|
(88 |
) |
Cash collateral receivable |
|
|
— |
|
|
|
— |
|
|
|
3 |
|
|
|
— |
|
Total derivatives as presented in the balance sheet |
|
$ |
7 |
|
|
$ |
5 |
|
|
$ |
(16 |
) |
|
$ |
(88 |
) |
27
The effect of derivatives in cash flow hedging relationships on Other Comprehensive Income (OCI) and income for the three and six months ended June 30, 2018 and 2017, respectively, consisted of:
Three Months Ended June 30, |
|
(Loss) Recognized in OCI on Derivatives |
|
|
Location of Loss Reclassified from Accumulated OCI into Income |
|
Loss Reclassified from Accumulated OCI into Income |
|
||
(Millions) |
|
Effective Portion (a) |
|
|
Effective Portion (a) |
|
||||
2018 |
|
|
|
|
|
|
|
|
|
|
Interest rate contracts |
|
$ |
— |
|
|
Interest expense |
|
$ |
2 |
|
Commodity contracts |
|
|
— |
|
|
Operating expenses |
|
|
— |
|
Total |
|
$ |
— |
|
|
|
|
$ |
2 |
|
2017 |
|
|
|
|
|
|
|
|
|
|
Interest rate contracts |
|
$ |
— |
|
|
Interest expense |
|
$ |
2 |
|
Commodity contracts |
|
|
— |
|
|
Operating expenses |
|
|
— |
|
Total |
|
$ |
— |
|
|
|
|
$ |
2 |
|
Six Months Ended June 30, |
|
(Loss) Recognized in OCI on Derivatives |
|
|
Location of Loss Reclassified from Accumulated OCI into Income |
|
Loss Reclassified from Accumulated OCI into Income |
|
||
(Millions) |
|
Effective Portion (a) |
|
|
Effective Portion (a) |
|
||||
2018 |
|
|
|
|
|
|
|
|
|
|
Interest rate contracts |
|
$ |
— |
|
|
Interest expense |
|
$ |
4 |
|
Commodity contracts |
|
|
— |
|
|
Operating expenses |
|
|
— |
|
Total |
|
$ |
— |
|
|
|
|
$ |
4 |
|
2017 |
|
|
|
|
|
|
|
|
|
|
Interest rate contracts |
|
$ |
— |
|
|
Interest expense |
|
$ |
4 |
|
Commodity contracts |
|
|
(1 |
) |
|
Operating expenses |
|
|
— |
|
Total |
|
$ |
(1 |
) |
|
|
|
$ |
4 |
|
(a) Changes in accumulated OCI are reported on a pre-tax basis. The reclassified amounts of commodity contracts are included within “Purchased power, natural gas and fuel used” line item within operating expenses in the condensed consolidated statements of income.
The net loss in accumulated OCI related to previously settled forward starting swaps and accumulated amortization is $64.1 million and $68.8 million as of June 30, 2018 and December 31, 2017, respectively. We recorded $2.0 million and $4.0 million in net derivative losses related to discontinued cash flow hedges for both three and six months ended June 30, 2018 and 2017. We will amortize approximately $4.0 million of discontinued cash flow hedges for the remainder of 2018. During the three and six months ended June 30, 2018 and 2017, there was no ineffective portion for cash flow hedges.
The unrealized loss of $0.2 million on hedge activities is reported in accumulated OCI because the forecasted transaction is considered to be probable as of June 30, 2018. We expect that $0.2 million of these losses will be reclassified into earnings within the next twelve months. The maximum length of time over which we are hedging our exposure to the variability in future cash flows for forecasted fleet fuel transactions is twelve months.
(b) Renewables and Gas activities
The below presented quantitative information includes derivative financial instruments associated with Gas activities, which were classified as held for sale in the condensed consolidated balance sheet as of December 31, 2017 (see Note 20 - Assets Held for Sale).
We sell fixed-price gas and power forwards to hedge our merchant wind assets from declining commodity prices for our Renewables business. We also purchase fixed-price gas and basis swaps and sell fixed-price power in the forward market to hedge the spark spread or heat rate of our merchant thermal assets. We also enter into tolling arrangements to sell the output of our thermal generation facilities.
Renewables has proprietary trading operations that enter into fixed-price power and gas forwards in addition to basis swaps. The intent is to speculate on fixed-price commodity and basis volatility in the U.S. commodity markets.
Renewables will periodically designate derivative contracts as cash flow hedges for both its thermal and wind portfolios. To the extent that the derivative contracts are effective in offsetting the variability of cash flows associated with future power sales and gas
28
purchases, the fair value changes are recorded in OCI. Any hedge ineffectiveness is recorded in current period earnings. For thermal operations, Renewables will periodically de signate both fixed price NYMEX gas contracts and natural gas basis swaps that hedge the fuel requirements of its Klamath Plant in Klamath, Oregon. Renewables will also designate fixed price power swaps at various locations in the U.S. market to hedge futur e power sales from its Klamath facility and various wind farms.
The net notional volumes of outstanding derivative instruments associated with Renewables and Gas activities as of June 30, 2018 and December 31, 2017, respectively, consisted of:
|
|
June 30, |
|
|
December 31, |
|
||
As of |
|
2018 |
|
|
2017 |
|
||
(MWh/Dth in millions) |
|
|
|
|
|
|
|
|
Wholesale electricity purchase contracts |
|
|
3 |
|
|
|
4 |
|
Wholesale electricity sales contracts |
|
|
5 |
|
|
|
6 |
|
Natural gas and other fuel purchase contracts |
|
|
23 |
|
|
|
285 |
|
Financial power contracts |
|
|
11 |
|
|
|
12 |
|
Basis swaps – purchases |
|
|
38 |
|
|
|
68 |
|
Basis swaps – sales |
|
|
2 |
|
|
|
62 |
|
The fair values of derivative contracts associated with Renewables and Gas activities as of June 30, 2018 and December 31, 2017, respectively, consisted of:
|
|
June 30, |
|
|
December 31, |
|
||
As of |
|
2018 |
|
|
2017 |
|
||
(Millions) |
|
|
|
|
|
|
|
|
Wholesale electricity purchase contracts |
|
$ |
6 |
|
|
$ |
(3 |
) |
Wholesale electricity sales contracts |
|
|
2 |
|
|
|
8 |
|
Natural gas and other fuel purchase contracts |
|
|
(1 |
) |
|
|
19 |
|
Financial power contracts |
|
|
61 |
|
|
|
55 |
|
Basis swaps – purchases |
|
|
(6 |
) |
|
|
(13 |
) |
Basis swaps – sales |
|
|
— |
|
|
|
4 |
|
Total |
|
$ |
62 |
|
|
$ |
70 |
|
The effect of trading derivatives associated with Renewables and Gas activities for the three and six months ended June 30, 2018 and 2017, respectively, consisted of:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Wholesale electricity purchase contracts |
|
$ |
5 |
|
|
$ |
1 |
|
|
$ |
6 |
|
|
$ |
(2 |
) |
Wholesale electricity sales contracts |
|
|
(2 |
) |
|
|
(4 |
) |
|
|
(1 |
) |
|
|
3 |
|
Financial power contracts |
|
|
(1 |
) |
|
|
3 |
|
|
|
(2 |
) |
|
|
— |
|
Financial and natural gas contracts |
|
|
— |
|
|
|
— |
|
|
|
3 |
|
|
|
4 |
|
Total Gain |
|
$ |
2 |
|
|
$ |
— |
|
|
$ |
6 |
|
|
$ |
5 |
|
The effect of non-trading derivatives associated with Renewables and Gas activities for the three and six months ended June 30, 2018 and 2017, respectively, consisted of:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Wholesale electricity purchase contracts |
|
$ |
3 |
|
|
$ |
4 |
|
|
$ |
4 |
|
|
$ |
(2 |
) |
Wholesale electricity sales contracts |
|
|
(7 |
) |
|
|
(5 |
) |
|
|
(7 |
) |
|
|
6 |
|
Financial power contracts |
|
|
(2 |
) |
|
|
(10 |
) |
|
|
1 |
|
|
|
6 |
|
Financial and natural gas contracts |
|
|
(1 |
) |
|
|
(1 |
) |
|
|
4 |
|
|
|
(5 |
) |
Total (Loss) Gain |
|
$ |
(7 |
) |
|
$ |
(12 |
) |
|
$ |
2 |
|
|
$ |
5 |
|
Such gains and losses are included in Operating revenues and in Purchased power, natural gas and fuel used operating expenses in the condensed consolidated statements of income, depending upon the nature of the transaction.
29
The offsetting of derivatives, location in the condensed consolidated balance sheet and amounts of derivatives associated with Renewables and Gas activities as of June 30, 2018 and December 31, 2017, respectively, consis ted of:
As of June 30, 2018 |
|
Current Assets |
|
|
Noncurrent Assets |
|
|
Current Liabilities |
|
|
Noncurrent Liabilities |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Not designated as hedging instruments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
$ |
23 |
|
|
$ |
103 |
|
|
$ |
20 |
|
|
$ |
5 |
|
Derivative liabilities |
|
|
(5 |
) |
|
|
(7 |
) |
|
|
(30 |
) |
|
|
(14 |
) |
|
|
|
18 |
|
|
|
96 |
|
|
|
(10 |
) |
|
|
(9 |
) |
Designated as hedging instruments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
|
3 |
|
|
|
2 |
|
|
|
1 |
|
|
|
3 |
|
Derivative liabilities |
|
|
— |
|
|
|
— |
|
|
|
(1 |
) |
|
|
(4 |
) |
|
|
|
3 |
|
|
|
2 |
|
|
|
— |
|
|
|
(1 |
) |
Total derivatives before offset of cash collateral |
|
|
21 |
|
|
|
98 |
|
|
|
(10 |
) |
|
|
(10 |
) |
Cash collateral receivable (payable) |
|
|
(8 |
) |
|
|
(38 |
) |
|
|
1 |
|
|
|
8 |
|
Total derivatives as presented in the balance sheet |
|
$ |
13 |
|
|
$ |
60 |
|
|
$ |
(9 |
) |
|
$ |
(2 |
) |
As of December 31, 2017 |
|
Current Assets |
|
|
Noncurrent Assets |
|
|
Current Liabilities |
|
|
Noncurrent Liabilities |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Not designated as hedging instruments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
$ |
111 |
|
|
$ |
99 |
|
|
$ |
31 |
|
|
$ |
4 |
|
Derivative liabilities |
|
|
(82 |
) |
|
|
(5 |
) |
|
|
(51 |
) |
|
|
(10 |
) |
|
|
|
29 |
|
|
|
94 |
|
|
|
(20 |
) |
|
|
(6 |
) |
Designated as hedging instruments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Derivative assets |
|
|
24 |
|
|
|
4 |
|
|
|
— |
|
|
|
2 |
|
Derivative liabilities |
|
|
— |
|
|
|
(1 |
) |
|
|
(3 |
) |
|
|
(3 |
) |
|
|
|
24 |
|
|
|
3 |
|
|
|
(3 |
) |
|
|
(1 |
) |
Total derivatives before offset of cash collateral |
|
|
53 |
|
|
|
97 |
|
|
|
(23 |
) |
|
|
(7 |
) |
Cash collateral receivable (payable) |
|
|
(17 |
) |
|
|
(39 |
) |
|
|
3 |
|
|
|
3 |
|
Total derivatives as presented in the balance sheet, including assets and liabilities held for sale |
|
$ |
36 |
|
|
$ |
58 |
|
|
$ |
(20 |
) |
|
$ |
(4 |
) |
The effect of derivatives in cash flow hedging relationships on accumulated OCI and income for the three and six months ended June 30, 2018 and 2017, respectively, consisted of:
Three Months Ended June 30, |
|
Gain Recognized in OCI on Derivatives |
|
|
Location of Loss (Gain) Reclassified from Accumulated OCI into Income |
|
(Gain) Reclassified from Accumulated OCI into Income |
|
||
(Millions) |
|
Effective Portion (a) |
|
|
Effective Portion (a) |
|
||||
2018 |
|
|
|
|
|
|
|
|
|
|
Commodity contracts |
|
$ |
— |
|
|
Operating revenues |
|
$ |
(1 |
) |
Total |
|
$ |
— |
|
|
|
|
$ |
(1 |
) |
2017 |
|
|
|
|
|
|
|
|
|
|
Commodity contracts |
|
$ |
— |
|
|
Operating revenues |
|
$ |
(3 |
) |
Total |
|
$ |
— |
|
|
|
|
$ |
(3 |
) |
30
Six Months Ended June 30, |
|
(Loss) Gain Recognized in OCI on Derivatives |
|
|
Location of Loss (Gain) Reclassified from Accumulated OCI into Income |
|
(Gain) Loss Reclassified from Accumulated OCI into Income |
|
||
(Millions) |
|
Effective Portion (a) |
|
|
Effective Portion (a) |
|
||||
2018 |
|
|
|
|
|
|
|
|
|
|
Commodity contracts |
|
$ |
(1 |
) |
|
Operating revenues |
|
$ |
(20 |
) |
Total |
|
$ |
(1 |
) |
|
|
|
$ |
(20 |
) |
2017 |
|
|
|
|
|
|
|
|
|
|
Commodity contracts |
|
$ |
4 |
|
|
Operating revenues |
|
$ |
30 |
|
Total |
|
$ |
4 |
|
|
|
|
$ |
30 |
|
|
(a) |
Changes in accumulated OCI are reported on a pre-tax basis. |
Amounts are reclassified from accumulated OCI into income in the period during which the transaction being hedged affects earnings or when it becomes probable that a forecasted transaction being hedged would not occur. Notwithstanding future changes in prices, approximately $2.3 million of gain included in accumulated OCI at June 30, 2018, is expected to be reclassified into earnings within the next twelve months. We recorded a net loss of $0.3 million and $0.2 million in the three and six months ended June 30, 2018, respectively, and a net gain of $0.8 million and $0.5 million, in the three and six months ended June 30, 2017, respectively, in earnings as a result of ineffectiveness from cash flow hedges. The net loss in accumulated OCI related to a discontinued cash flow hedge is $0.4 million as of June 30, 2018, out of which an immaterial amount will be amortized in the remainder of 2018. We recorded $0 and $0.1 million in net derivative losses related to discontinued cash flow hedges for the three and six months ended June 30, 2018, respectively.
(c) Interest rate swaps
AVANGRID uses financial derivative instruments from time to time to alter its fixed and floating rate debt balances or to hedge fixed rates in anticipation of future fixed rate issuances. In the second quarter of 2018, AVANGRID entered into two forward interest rate swaps, with a total notional amount of $500 million, to hedge the issuance of forecasted fixed rate debt in 2019. The forward interest rate swaps are designated and qualify as cash flow hedges, have mandatory termination dates of June 28, 2019, and are expected to be settled upon the forecasted debt issuance. The effective portion of the gain or loss on the interest rate swap derivative is reported as a component of accumulated OCI and reclassified into earnings in the period or periods during which related interest payments of the forecasted debt will occur.
Pre-tax losses of $4.4 million were recognized in accumulated OCI for the three and six months ended June 30, 2018 from the effective portion of changes in the fair value of the interest rate swap derivative instruments. We estimate no amounts will be reclassified into earnings within the next twelve months. During both the three and six months ended June 30, 2018, no ineffectiveness was recorded from cash flow hedges.
The forward interest rate swap derivative liabilities of $4.4 million are included in current liabilities on the balance sheet and do not have related offsetting cash collateral or other derivative assets/liabilities to be offset with.
(d) Counterparty credit risk management
NYSEG and RG&E face risks related to counterparty performance on hedging contracts due to counterparty credit default. We have developed a matrix of unsecured credit thresholds that are applicable based on the respective counterparty’s or the counterparty guarantor’s credit rating, as provided by Moody’s or Standard & Poor’s. When our exposure to risk for a counterparty exceeds the unsecured credit threshold, the counterparty is required to post additional collateral or we will no longer transact with the counterparty until the exposure drops below the unsecured credit threshold.
The wholesale power supply agreements of UI contain default provisions that include required performance assurance, including certain collateral obligations, in the event that UI’s credit rating on senior debt falls below investment grade. If such an event had occurred as of June 30, 2018, UI would have had to post an aggregate of approximately $11 million in collateral.
We have various master netting arrangements in the form of multiple contracts with various single counterparties that are subject to contractual agreements that provide for the net settlement of all contracts through a single payment. Those arrangements reduce our exposure in the event of a counterparty default or contract termination. For financial statement presentation purposes, we offset fair value amounts recognized for derivative instruments and fair value amounts recognized for the right to reclaim or the obligation to return cash collateral arising from derivative instruments executed with the same counterparty under a master netting arrangement. The amounts of cash collateral under master netting arrangements that have not been offset against net derivative positions were $6
31
million and $30 million as of June 30, 2018 and December 31, 2017, respectively. Derivative instruments settlements and collateral payments are included in “Other assets/liabilities” of operating activities in the condensed consolidated sta tements of cash flows.
Certain of our derivative instruments contain provisions that require us to maintain an investment grade credit rating on our debt from each of the major credit rating agencies. If our debt were to fall below investment grade, we would be in violation of those provisions and the counterparties to the derivative instruments could request immediate payment or demand immediate and ongoing full overnight collateralization on derivative instruments in net liability positions. The aggregate fair value of all derivative instruments with credit risk related contingent features that are in a liability position as of June 30, 2018 is $0.
Note 8. Contingencies
We are party to various legal disputes arising as part of our normal business activities. We assess our exposure to these matters and record estimated loss contingencies when a loss is likely and can be reasonably estimated. We do not provide for accrual of legal costs expected to be incurred in connection with a loss contingency.
Transmission - ROE Complaint – CMP and UI
On September 30, 2011, the Massachusetts Attorney General, Massachusetts Department of Public Utilities, Connecticut Public Utilities Regulatory Authority, New Hampshire Public Utilities Commission, Rhode Island Division of Public Utilities and Carriers, Vermont Department of Public Service, numerous New England consumer advocate agencies and transmission tariff customers collectively filed a complaint (Complaint I) with the FERC pursuant to sections 206 and 306 of the Federal Power Act. The filing parties sought an order from the FERC reducing the 11.14% base ROE used in calculating formula rates for transmission service under the ISO-New England Open Access Transmission Tariff (OATT) to 9.2%. CMP, MEPCO and UI are New England Transmission Owners (NETOs) with assets and service rates that are governed by the OATT and will thereby be affected by any FERC order resulting from the filed complaint.
On June 19, 2014, the FERC issued its decision in Complaint I, establishing an ROE methodology and setting an issue for a paper hearing. On October 16, 2014, the FERC issued its final decision in Complaint I setting the base ROE at 10.57% and a maximum total ROE of 11.74% (base plus incentive ROEs) for the October 2011 – December 2012 period as well as prospectively from October 16, 2014, and ordered the NETOs to file a refund report. On November 17, 2014, the NETOs filed the requested refund report.
On March 3, 2015, the FERC issued an order on requests for rehearing of its October 16, 2014 decision. The March order upheld the FERC’s June 19, 2014 decision and further clarified that the 11.74% ROE cap will be applied on a project specific basis and not on a transmission owner’s total average transmission return. In June 2015, the NETOs and complainants both filed an appeal of the FERC’s final order in the U.S. Court of Appeals for the District of Columbia (the Court). On April 14, 2017, the Court vacated FERC’s decision on Complaint I and remanded it to the FERC. The Court held that the FERC, as directed by statute, did not determine first that the existing ROE was unjust and unreasonable before determining a new ROE. The Court ruled that the FERC should have first determined that the then existing 11.14% base ROE was unjust and unreasonable before selecting the 10.57% as the new base ROE. The Court also found that the FERC did not provide reasoned judgment as to why an ROE of 10.57% at the midpoint of the upper end of the zone of reasonableness is a just and reasonable ROE. Instead, FERC had only explained in its order that the midpoint of 9.39% was not just and reasonable and a higher base ROE was warranted. On June 5, 2017, the NETOs made a filing with the FERC seeking to reinstate transmission rates to the status quo ante (effect of the Court vacating order is to return the parties to the rates in effect prior to the FERC final decision) as of June 8, 2017, the date the Court decision became effective. In that filing, the NETOs stated that they will not begin billing at the higher rates until 60 days after the FERC has a quorum of commissioners. On October 6, 2017, the FERC issued an order rejecting the NETOs request to collect transmission revenue requirements at the higher ROE of 11.14%, pending a FERC order on remand. In reaching this decision, the FERC stated that it has broad remedial authority to make whatever ROE it eventually determines to be just and reasonable effective for the Complaint I refund period and prospectively from October 2014, the effective date of the Complaint I Order. Therefore, the FERC reasoned that the NETOs will not be harmed financially by not immediately returning to their pre-Complaint I ROE. We expect the FERC to address the Court decision during 2018. We cannot predict the outcome of this matter .
On December 26, 2012, a second ROE complaint (Complaint II) for a subsequent rate period was filed requesting the then effective ROE of 11.14% be reduced to 8.7%. On June 19, 2014, the FERC accepted Complaint II, established a 15-month refund effective date of December 27, 2012, and set the matter for hearing using the methodology established in Complaint I.
On July 31, 2014, a third ROE complaint (Complaint III) was filed for a subsequent rate period requesting the then effective ROE of 11.14% be reduced to 8.84%. On November 24, 2014, the FERC accepted Complaint III, established a 15-month refund effective date of July 31, 2014, and consolidated this matter with Complaint II for hearing in June 2015. Hearings relating to the refund periods and going forward period were held in June 2015 on Complaints II and III before a FERC administrative law judge. On July 29, 2015, post-hearing briefs were filed by parties and on August 26, 2015 reply briefs were filed by parties. On July 13, 2015, the NETOs filed
32
a peti tion for review of the FERC’s orders establishing hearing and consolidation procedures for Complaints II and III with the Court. The FERC administrative law judge issued an Initial Decision on March 22, 2016. The Initial Decision determined that: (1) for t he 15-month refund period in Complaint II, the base ROE should be 9.59% and that the ROE Cap (base ROE plus incentive ROEs) should be 10.42% and (2) for the 15-month refund period in Complaint III and prospectively, the base ROE should be 10.90% and that t he ROE Cap should be 12.19%. The Initial Decision is the FERC administrative law judge’s recommendation to the FERC Commissioners. The FERC is expected to make its final decision in 2018.
CMP and UI reserved for refunds for Complaints I, II and III consistent with the FERC’s March 3, 2015 final decision in Complaint I. Refunds were provided to customers for Complaint I. The CMP and UI total reserve associated with Complaints II and III is $22.9 million and $4.4 million, respectively, as of June 30, 2018, which has not changed since December 31, 2017, except for the accrual of carrying costs. These reserve amounts were calculated consistent with the methodology set forth in the FERC’s March 3, 2015 order. If adopted as final by the FERC, the impact of the initial decision by the FERC administrative law judge would be an additional aggregate reserve for Complaints II and III of $17.1 million, which is based upon currently available information for these proceedings. We cannot predict the outcome of the Complaint II and III proceedings.
On April 29, 2016, a fourth ROE complaint (Complaint IV) was filed for a rate period subsequent to prior complaints requesting the then existing base ROE of 10.57% be reduced to 8.61% and the ROE Cap be set at 11.24%. The NETOs filed a response to the Complaint IV on June 3, 2016. On September 20, 2016, the FERC accepted the Complaint IV, established a 15-month refund effective date of April 29, 2016, and set the matter for hearing and settlement judge procedures. In April 2017, the NETOs filed for a stay in the hearings pending the FERC taking action on the Court order described above. That request was denied by the FERC administrative law judge. On November 21, 2017, the parties submitted updates to their ROE analyses and recommendations with the NETOs continuing to advocate that the existing base ROE of 10.57% should remain in effect. Hearings were held in December 2017. On March 27, 2018, the FERC administrative law judge issued an initial decision rejecting Complaint IV, finding the currently-filed base ROE of 10.57%, which, with incentive adders, may reach a maximum ROE of 11.74%, is not unjust and unreasonable, and hence is not unlawful. Briefs on Exceptions to the FERC administrative law judge’s initial decision were filed on April 26, 2018, and Briefs Opposing Exceptions were filed on May 23, 2018. The FERC has not yet issued its final decision in this docket. We cannot predict the outcome of the Complaint IV proceeding.
On October 5, 2017, the NETOs filed a Motion for Dismissal of Pancaked Return on Equity Complaints in light of the decision by the Court in April 2017 that became effective on June 8, 2017. The NETOs assert that all four complaints should be dismissed because the complainants have not shown that the existing ROE of 11.14% is unjust and unreasonable as the Court decision requires. In addition, the NETOs assert that Complaints II, III and IV should also be dismissed because the Court decision implicitly found that the FERC’s acceptance of Pancaked FPA Section 206 complaints was statutorily improper as Congress intended that the 15-month refund period under Section 206 applies whenever the FERC does not complete its review of a complaint within the 15-month period. In the event the FERC chooses not to dismiss the complaints, the NETOs request that the FERC consolidate the complaints for decision as the evidentiary records are either closed or advanced enough for the FERC to address the requirements of the Court decision and expeditiously issue a final order. The FERC has not yet ruled on this Motion. We cannot predict the outcome of this proceeding.
New York State Department of Public Service Investigation of the Preparation for and Response to the March 2017 Windstorm
On March 11, 2017 the New York State Department of Public Service (the Department) commenced an investigation of NYSEG’s and RG&E’s preparation for and response to the March 2017 windstorm, which affected more than 219,000 NYSEG and RG&E customers. The Department Staff issued a report (the Staff Report) of the findings from their investigation on November 16, 2017. The Staff Report made several recommendations for future storm response and also alleged that NYSEG and RG&E had violated their own emergency response plan in a number of respects.
Also on November 16, 2017, the NYPSC issued an Order Instituting Proceeding and to Show Cause (the Order) requiring the companies to address whether the NYPSC should mandate, reject or modify, in whole or in part the recommendations made in the Staff Report . The Order also required the companies to show cause why the NYPSC should not commence an administrative penalty proceeding. On May 18, 2018, NYSEG and RG&E filed a settlement joint proposal and investment joint proposal before the NYPSC to settle potential penalties and avoid litigation related to the March 2017 windstorm, pursuant to which, among other things, NYSEG and RG&E have agreed to make $3.9 million in investments in 2018 designed to increase resiliency and improve emergency response in the areas impacted by the storm. The investments will not be reflected in rate base or operating expenses in establishing future delivery rates. The joint proposals are subject to public comment and NYPSC approval . We cannot predict the final outcome of this matter .
33
New York State Department of Public Service Investigation of the Preparation for and Response to the March 2018 Winter Storms
In March 2018, following two severe winter storms that impacted over more than a million electric utility customers in New York, including 520,000 NYSEG and RG&E customers, the NYPSC initiated a comprehensive investigation of all the New York electric utilities’ preparation and response to those events. The investigation has been expanded to include other 2018 New York spring storm events. We cannot predict the final outcome of this matter.
California Energy Crisis Litigation
Two California agencies brought a complaint in 2001 against a long-term power purchase agreement entered into by Renewables, as seller, to the California Department of Water Resources, as purchaser, alleging that the terms and conditions of the power purchase agreement were unjust and unreasonable. The FERC dismissed Renewables from the proceedings; however, the Ninth Circuit Court of Appeals reversed the FERC's dismissal of Renewables from the proceeding.
Joining with two other parties, Renewables filed a petition for certiorari in the United States Supreme Court on May 3, 2007. In an order entered on June 27, 2008, the Supreme Court granted Renewables’ petition for certiorari, vacated the appellate court's judgment, and remanded the case to the appellate court for further consideration in light of the Supreme Court’s decision in a similar case. In light of the Supreme Court's order, on December 4, 2008, the Ninth Circuit Court of Appeals vacated its prior opinion and remanded the complaint proceedings to the FERC for further proceedings consistent with the Supreme Court's rulings. In 2014, the FERC assigned an administrative law judge to conduct evidentiary hearings. Following discovery, the FERC trial staff recommended that the complaint against Renewables be dismissed .
A hearing was held before a FERC administrative law judge in November and early December 2015. A preliminary proposed ruling by the administrative law judge was issued on April 12, 2016. The proposed ruling found no evidence that Renewables had engaged in any unlawful market contract that would justify finding the Renewables power purchase agreements unjust and unreasonable. However, the proposed ruling did conclude that price of the power purchase agreements imposed an excessive burden on customers in the amount of $259 million. Renewables position, as presented at hearings and agreed to by FERC trial staff, is that Renewables entered into bilateral power purchase contracts appropriately and complied with all applicable legal standards and requirements. The parties have submitted briefs on exceptions to the administrative law judge’s proposed ruling to the FERC. In April 2018 Renewables requested, based on the nearly two years of delay from the preliminary proposed ruling and the Supreme Court precedent, that the FERC issue a final decision expeditiously. We cannot predict the outcome of this proceeding.
Class Action Regarding LDC Gas Transportation Service on Algonquin Gas Transmission
On November 16, 2017, a class action lawsuit was filed in the U.S. District Court for the District of Massachusetts on behalf of customers in New England against the Company and Eversource alleging that certain of their respective subsidiaries that take gas transportation service over the Algonquin Gas Transmission (AGT), which for AVANGRID would be its indirect subsidiaries SCG and CNG, engaged in pipeline capacity scheduling practices on AGT that resulted in artificially increased electricity prices in New England. These allegations were based on the conclusions of a White Paper issued by the Environmental Defense Fund (EDF), an environmental advocacy organization, on October 10, 2017, purporting to analyze the relationship between the New England electricity market and the New England local gas distribution companies. The plaintiffs assert claims under federal antitrust law, state antitrust, unfair competition and consumer protection laws, and under the common law of unjust enrichment. They seek damages, disgorgement, restitution, injunctive relief, and attorney fees and costs. The Company filed a Motion to Dismiss all of the claims on January 29, 2018. On February 27, 2018, the FERC released the results of a FERC staff inquiry into the pipeline capacity scheduling practices on the AGT. The inquiry arose out of the allegations made by the EDF in its White Paper. FERC announced that, based on an extensive review of public and non-public data, it had determined that the EDF study was flawed and led to incorrect conclusions. FERC also stated that the staff inquiry revealed no evidence of anticompetitive withholding of natural gas pipeline capacity on the AGT and that it would take no further action on the matter. On March 28, 2018, the plaintiffs filed a consolidated amended complaint, repeating the prior claims, except omitting the common law claim of unjust enrichment. On April 27, 2018, the Company filed a Motion to Dismiss all of the claims based on federal preemption and lack of any evidence of antitrust behavior, citing, among other reasons, the results of the FERC staff inquiry conclusion. The plaintiffs filed opposition to the motion to dismiss on May 25, 2018. The U.S. District Court for the District of Massachusetts held a hearing on the motion on August 1, 2018. We cannot predict the outcome of this class action lawsuit.
Guarantee Commitments to Third Parties
As of June 30, 2018, we had approximately $2.3 billion of standby letters of credit, surety bonds, guarantees and indemnifications outstanding. These instruments provide financial assurance to the business and trading partners of AVANGRID and its subsidiaries in their normal course of business. The instruments only represent liabilities if AVANGRID or its subsidiaries fail to deliver on
34
contractual obligations. We therefore believe it is unlikely that any material liabilities associated with these instruments will be incurred and, accordingly, as of June 30, 2018 , ne ither we nor our subsidiaries have any liabilities recorded for these instruments.
Note 9. Environmental Liabilities
Environmental laws, regulations and compliance programs may occasionally require changes in our operations and facilities and may increase the cost of electric and natural gas service. We do not provide for accruals of legal costs expected to be incurred in connection with loss contingencies.
Waste sites
The Environmental Protection Agency and various state environmental agencies, as appropriate, have notified us that we are among the potentially responsible parties that may be liable for costs incurred to remediate certain hazardous substances at twenty-five waste sites, which do not include sites where gas was manufactured in the past. Fifteen of the twenty-five sites are included in the New York State Registry of Inactive Hazardous Waste Disposal Sites; six sites are included in Maine’s Uncontrolled Sites Program and one site is included on the Massachusetts Non-Priority Confirmed Disposal Site list. The remaining sites are not included in any registry list. Finally, nine of the twenty-five sites are also included on the National Priorities list. Any liability may be joint and severable for certain sites.
We have recorded an estimated liability of $5 million related to ten of the twenty-five sites. We have paid remediation costs related to the remaining fifteen sites and do not expect to incur additional liabilities. Additionally, we have recorded an estimated liability of $8 million related to another ten sites where we believe it is probable that we will incur remediation costs and or monitoring costs, although we have not been notified that we are among the potentially responsible parties or that we are regulated under State Resource Conservation and Recovery Act programs. We recorded a corresponding regulatory asset because we expect to recover these costs in rates. It is possible the ultimate cost to remediate these sites may be significantly more than the accrued amount. Our estimate for costs to remediate these sites ranges from $12 million to $21 million as of June 30, 2018. Factors affecting the estimated remediation amount include the remedial action plan selected, the extent of site contamination, and the allocation of the clean-up costs.
Manufactured Gas Plants
We have a program to investigate and perform necessary remediation at our fifty-three sites where gas was manufactured in the past (Manufactured Gas Plants, or MGPs). Eight sites are included in the New York State Registry; twelve sites are included in the New York Voluntary Cleanup Program; three sites are part of Maine’s Voluntary Response Action Program and two sites are part of Maine’s Uncontrolled Sites Program. The remaining sites are not included in any registry list. We have entered into consent orders with various environmental agencies to investigate and where necessary remediate forty-nine of the fifty-three sites.
Our estimate for all costs related to investigation and remediation of the fifty-three sites ranges from $213 million to $442 million as of June 30, 2018. Our estimate could change materially based on the facts and circumstances derived from site investigations, changes in required remedial actions, changes in technology relating to remedial alternatives and changes to current laws and regulations.
Certain of our Connecticut and Massachusetts regulated gas companies own or have previously owned properties where MGPs had historically operated. MGP operations have led to contamination of soil and groundwater with petroleum hydrocarbons, benzene and metals, among other things, at these properties, the regulation and cleanup of which is regulated by the federal Resource Conservation and Recovery Act as well as other federal and state statutes and regulations. Each of the companies has or had an ownership interest in one or more such properties contaminated as a result of MGP-related activities. Under the existing regulations, the cleanup of such sites requires state and at times, federal, regulators’ involvement and approval before cleanup can commence. In certain cases, such contamination has been evaluated, characterized and remediated. In other cases, the sites have been evaluated and characterized, but not yet remediated. Finally, at some of these sites, the scope of the contamination has not yet been fully characterized; no liability was recorded for these sites as of June 30, 2018 and no amount of loss, if any, can be reasonably estimated at this time. In the past, the companies have received approval for the recovery of MGP-related remediation expenses from customers through rates and will seek recovery in rates for ongoing MGP-related remediation expenses for all of their MGP sites.
As of June 30, 2018 and December 31, 2017, the liability associated with our MGP sites in Connecticut, the remediation costs of which could be significant and will be subject to a review by PURA as to whether these costs are recoverable in rates, was $99 million and $100 million, respectively.
Our total recorded liability to investigate and perform remediation at all known inactive MGP sites discussed above and other sites was $385 million and $389 million as of June 30, 2018 and December 31, 2017, respectively. We recorded a corresponding regulatory asset, net of insurance recoveries and the amount collected from FirstEnergy, as described below, because we expect to recover the net
35
costs in rates. Our environmental liability accruals are recorded on an undiscounted basis and are expected to be paid through the year 2054.
FirstEnergy
NYSEG sued FirstEnergy under the Comprehensive Environmental Response, Compensation, and Liability Act to recover environmental cleanup costs at sixteen former manufactured gas sites, which are included in the discussion above. In July 2011, the District Court issued a decision and order in NYSEG’s favor, requiring FirstEnergy to pay NYSEG approximately $60 million for past and future clean-up costs at the sixteen sites in dispute. On September 9, 2011, FirstEnergy paid NYSEG $30 million, representing their share of past costs of $27 million and pre-judgment interest of $3 million.
FirstEnergy appealed the decision to the Second Circuit Court of Appeals. On September 11, 2014, the Second Circuit Court of Appeals affirmed the District Court’s decision in NYSEG’s favor, but modified the decision for nine sites, reducing NYSEG’s damages for incurred costs from $27 million to $22 million, excluding interest, and reducing FirstEnergy’s allocable share of future costs at these sites. NYSEG refunded FirstEnergy the excess $5 million in November 2014.
FirstEnergy remains liable for a substantial share of clean up expenses at nine MGP sites. Based on current projections, FirstEnergy’s share is estimated at approximately $22 million. This amount is being treated as a contingent asset and has not been recorded as either a receivable or a decrease to the environmental provision. Any recovery will be flowed through to NYSEG ratepayers.
Century Indemnity and OneBeacon
On August 14, 2013, NYSEG filed suit in federal court against two excess insurers, Century Indemnity and OneBeacon, who provided excess liability coverage to NYSEG. NYSEG seeks payment for clean-up costs associated with contamination at 22 former manufactured gas plants. Based on estimated clean-up costs of $282 million, the carriers’ allocable share could equal or exceed approximately $89 million, excluding pre-judgment interest, although this amount may change substantially depending upon the determination of various factual matters and legal issues during the case.
Century Indemnity and OneBeacon have answered, admitting issuance of the excess policies, but contesting coverage and providing documentation proving they received notice of the claims in the 1990s. On March 31, 2017, the District Court granted motions filed by Century Indemnity and One Beacon dismissing all of NYSEG’s claims against both defendants on the grounds of late notice. NYSEG filed a motion with the District Court on April 14, 2017 seeking reconsideration of the Court’s decision, which was denied by an order dated March 27, 2018. NYSEG filed a notice appealing the District Court’s dismissal on April 9, 2018. We cannot predict the outcome of this matter; however, any recovery will be flowed through to NYSEG ratepayers.
English Station
In January 2012, Evergreen Power, LLC (Evergreen Power) and Asnat Realty LLC (Asnat), then and current owners of a former generation site on the Mill River in New Haven (the English Station site) that UI sold to Quinnipiac Energy in 2000, filed a lawsuit in federal district court in Connecticut against UI seeking, among other things: (i) an order directing UI to reimburse the plaintiffs for costs they have incurred and will incur for the testing, investigation and remediation of hazardous substances at the English Station site and (ii) an order directing UI to investigate and remediate the site. This proceeding had been stayed in 2014 pending resolutions of other proceedings before the Connecticut Department of Energy and Environmental Protection (DEEP) concerning the English Station site. In December 2016, the court administratively closed the file without prejudice to reopen upon the filing of a motion to reopen by any party. In December 2013, Evergreen Power and Asnat filed a subsequent lawsuit in Connecticut state court seeking among other things: (i) remediation of the English Station site; (ii) reimbursement of remediation costs; (iii) termination of UI’s easement rights; (iv) reimbursement for costs associated with securing the property; and (v) punitive damages. This lawsuit had been stayed in May 2014 pending mediation. Due to lack of activity in the case, the court terminated the stay and scheduled a status conference for July 6, 2017. On July 5, 2017, Asnat filed a pretrial memorandum claiming damages of $10 million for “environmental remediation activities” and lost use of the property. In December 2017, Plaintiffs filed a Request for Leave to Amend Complaint and Motion to Cite-In Additional Parties, including former UIL officers and employees and other UI officers, which motion was approved in February 2018. Plaintiffs filed a revised complaint with the court on April 16, 2018 alleging fraud and unjust enrichment against UIL and UI and adding former UIL officers as named defendants alleging fraud. The complaint was further revised July 3, 2018. We cannot predict the outcome of this matter.
On April 8, 2013, DEEP issued an administrative order addressed to UI, Evergreen Power, Asnat and others, ordering the parties to take certain actions related to investigating and remediating the English Station site. Mediation of the matter began in the fourth quarter of 2013 and concluded unsuccessfully in April 2015. This proceeding was stayed while DEEP and UI continue to work through the remediation process pursuant to the consent order described below. Status reports are periodically filed with the DEEP.
36
On August 4, 2016, DEEP issued a partial consent order (the consent order), that, subject to its terms and conditions, requires UI to investigate and remediate cert ain environmental conditions within the perimeter of the English Station site. Under the consent order, to the extent that the cost of this investigation and remediation is less than $30 million, UI will remit to the State of Connecticut the difference bet ween such cost and $30 million to be used for a public purpose as determined in the discretion of the Governor of the State of Connecticut, the Attorney General of the State of Connecticut and the Commissioner of DEEP. UI is obligated to comply with the te rms of the consent order even if the cost of such compliance exceeds $30 million. Under the terms of the consent order, the State will discuss options with UI on recovering or funding any cost above $30 million such as through public funding or recovery fr om third parties; however, it is not bound to agree to or support any means of recovery or funding . UI has initiated its process to investigate and remediate the environmental conditions within the perimeter of the English Station site pursuant to the cons ent order.
As of June 30, 2018 and December 31, 2017, the amount reserved for this matter was $23 million and $25 million, respectively. We cannot predict the outcome of this matter.
Note 10. Post-retirement and Similar Obligations
We made $6 million and $8 million of pension contributions for the three and six months ended June 30, 2018, respectively. We expect to make additional contributions of $40 million for the remainder of 2018.
The components of net periodic benefit cost for pension benefits for the three and six months ended June 30, 2018 and 2017, respectively, consisted of:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Service cost |
|
$ |
11 |
|
|
$ |
11 |
|
|
$ |
22 |
|
|
$ |
22 |
|
Interest cost |
|
|
32 |
|
|
|
34 |
|
|
|
64 |
|
|
|
69 |
|
Expected return on plan assets |
|
|
(50 |
) |
|
|
(49 |
) |
|
|
(100 |
) |
|
|
(99 |
) |
Amortization of: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Prior service costs |
|
|
1 |
|
|
|
1 |
|
|
|
1 |
|
|
|
1 |
|
Actuarial loss |
|
|
37 |
|
|
|
31 |
|
|
|
75 |
|
|
|
63 |
|
Net Periodic Benefit Cost |
|
$ |
31 |
|
|
$ |
28 |
|
|
$ |
62 |
|
|
$ |
56 |
|
The components of net periodic benefit cost for postretirement benefits for the three and six months ended June 30, 2018 and 2017, respectively, consisted of:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Service cost |
|
$ |
1 |
|
|
$ |
1 |
|
|
$ |
2 |
|
|
$ |
2 |
|
Interest cost |
|
|
5 |
|
|
|
5 |
|
|
|
9 |
|
|
|
10 |
|
Expected return on plan assets |
|
|
(2 |
) |
|
|
(2 |
) |
|
|
(4 |
) |
|
|
(4 |
) |
Amortization of: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Prior service costs |
|
|
(2 |
) |
|
|
(2 |
) |
|
|
(4 |
) |
|
|
(4 |
) |
Actuarial loss |
|
|
2 |
|
|
|
1 |
|
|
|
3 |
|
|
|
2 |
|
Net Periodic Benefit Cost |
|
$ |
4 |
|
|
$ |
3 |
|
|
$ |
6 |
|
|
$ |
6 |
|
Beginning in 2018, in the condensed consolidated statements of income, we include the service cost component in other operating expenses net of capitalized portion, and include the components of net periodic benefit cost other than the service cost component in other expense.
Note 11. Equity
As of June 30, 2018, our share capital consisted of 500,000,000 shares of common stock authorized, 309,752,140 shares issued and 309,005,272 shares outstanding, 81.5% of which are owned by Iberdrola, each having a par value of $0.01, for a total value of common stock capital of $3 million and additional paid in capital of $13,655 million. As of December 31, 2017, our share capital consisted of 500,000,000 shares of common stock authorized, 309,670,932 shares issued and 309,005,272 shares outstanding, 81.5% of which were owned by Iberdrola, each having a par value of $0.01, for a total value of common stock capital of $3 million and
37
additional paid in capit al of $13,653 million. We had 485,810 shares of common stock held in trust and no convertible preferred shares outstanding as of both June 30, 2018 and December 31, 2017, respectively. During the six months ended June 30, 2018, we issued 81,208 shares of c ommon stock each having a par value of $0.01 and released no shares of common stock held in trust. During the six months ended June 30, 2017, we issued 70,493 shares of common stock and released 5,649 shares of common stock held in trust each having a par value of $0.01.
On April 28, 2016, we entered into a repurchase agreement with J.P. Morgan Securities, LLC. (JPM), pursuant to which JPM will, from time to time, acquire, on behalf of AVANGRID, shares of common stock of AVANGRID. The purpose of the stock repurchase program is to allow AVANGRID to maintain the relative ownership percentage by Iberdrola at 81.5%. The stock repurchase program may be suspended or discontinued at any time upon notice. Out of a total of 261,058 treasury shares of common stock of AVANGRID as of June 30, 2018, 115,831 shares were repurchased during 2016, 64,019 shares were repurchased in May 2017 and 81,208 shares were repurchased in May 2018, all in the open market. The total cost of all repurchases, including commissions, was $12 million as of June 30, 2018.
Accumulated Other Comprehensive Loss
Accumulated Other Comprehensive Loss for the three months ended June 30, 2018 and 2017, respectively, consisted of:
|
|
As of March 31, |
|
|
Adoption of new accounting |
|
|
Three Months Ended June 30, |
|
|
As of June 30, |
|
|
As of March 31, |
|
|
Three Months Ended June 30, |
|
|
As of June 30, |
|
|||||||
|
|
2018 |
|
|
standard |
|
|
2018 |
|
|
2018 |
|
|
2017 |
|
|
2017 |
|
|
2017 |
|
|||||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Gain on revaluation of defined benefit plans, net of income tax expense of $0.2 for 2018 |
|
$ |
(14 |
) |
|
$ |
— |
|
|
$ |
1 |
|
|
$ |
(13 |
) |
|
$ |
(14 |
) |
|
$ |
— |
|
|
$ |
(14 |
) |
Loss for nonqualified pension plans |
|
|
(7 |
) |
|
|
— |
|
|
|
— |
|
|
|
(7 |
) |
|
|
(7 |
) |
|
|
— |
|
|
|
(7 |
) |
Unrealized loss during period on derivatives qualifying as cash flow hedges, net of income tax (benefit) of $(1.5) for 2018 |
|
|
30 |
|
|
|
— |
|
|
|
(5 |
) |
|
|
25 |
|
|
|
7 |
|
|
|
— |
|
|
|
7 |
|
Reclassification to net income of gains on cash flow hedges, net of income tax (benefit) of $(0.1) for 2017(a) |
|
|
(66 |
) |
|
|
— |
|
|
|
— |
|
|
|
(66 |
) |
|
|
(47 |
) |
|
|
(1 |
) |
|
|
(48 |
) |
Loss on derivatives qualifying as cash flow hedges |
|
|
(36 |
) |
|
|
— |
|
|
|
(5 |
) |
|
|
(41 |
) |
|
|
(40 |
) |
|
|
(1 |
) |
|
|
(41 |
) |
Accumulated Other Comprehensive Loss |
|
$ |
(57 |
) |
|
$ |
— |
|
|
$ |
(4 |
) |
|
$ |
(61 |
) |
|
$ |
(61 |
) |
|
$ |
(1 |
) |
|
$ |
(62 |
) |
Accumulated Other Comprehensive (Loss) Gain for the six months ended June 30, 2018 and 2017, respectively, consisted of:
|
|
As of December 31, |
|
|
Adoption of new accounting |
|
|
Six Months Ended June 30, |
|
|
As of June 30, |
|
|
As of December 31, |
|
|
Six Months Ended June 30, |
|
|
As of June 30, |
|
|||||||
|
|
2017 |
|
|
standard |
|
|
2018 |
|
|
2018 |
|
|
2016 |
|
|
2017 |
|
|
2017 |
|
|||||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Gain on revaluation of defined benefit plans net of tax expense of $0.2 for 2018 |
|
$ |
(14 |
) |
|
$ |
— |
|
|
$ |
1 |
|
|
$ |
(13 |
) |
|
$ |
(14 |
) |
|
$ |
— |
|
|
$ |
(14 |
) |
Loss for nonqualified pension plans |
|
|
(6 |
) |
|
|
(1 |
) |
|
|
— |
|
|
|
(7 |
) |
|
|
(7 |
) |
|
|
— |
|
|
|
(7 |
) |
Unrealized (loss) gain during period on derivatives qualifying as cash flow hedges, net of income tax (benefit)expense of $(1.5) for 2018 and $1.1 for 2017 |
|
|
30 |
|
|
|
— |
|
|
|
(5 |
) |
|
|
25 |
|
|
|
5 |
|
|
|
2 |
|
|
|
7 |
|
Reclassification to net income of (gains) losses on cash flow hedges, net of income tax (benefit) expense of $(7.2) for 2018 and $13.5 for 2017(a) |
|
|
(56 |
) |
|
|
— |
|
|
|
(10 |
) |
|
|
(66 |
) |
|
|
(70 |
) |
|
|
22 |
|
|
|
(48 |
) |
(Loss) gain on derivatives qualifying as cash flow hedges |
|
|
(26 |
) |
|
|
— |
|
|
|
(15 |
) |
|
|
(41 |
) |
|
|
(65 |
) |
|
|
24 |
|
|
|
(41 |
) |
Accumulated Other Comprehensive (Loss) Gain |
|
$ |
(46 |
) |
|
$ |
(1 |
) |
|
$ |
(14 |
) |
|
$ |
(61 |
) |
|
$ |
(86 |
) |
|
$ |
24 |
|
|
$ |
(62 |
) |
(a) |
Reclassification is reflected in the operating expenses line item in the condensed consolidated statements of income. |
38
Basic earnings per share is computed by dividing net income attributable to AVANGRID by the weighted-average number of shares of our common stock outstanding. During the three and six months ended June 30, 2018 and 2017, while we did have securities that were dilutive, these securities did not result in a change in our earnings per share calculation for the three months ended June 30, 2017 and the six months ended June 30, 2018 and 2017. The dilutive securities, which consist of performance and restricted units, did result in a change in our earnings per share calculation for the three months ended June 30, 2018.
The calculations of basic and diluted earnings per share attributable to AVANGRID, for the three and six months ended June 30, 2018 and 2017, respectively, consisted of:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions, except for number of shares and per share data) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Numerator: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Net income attributable to AVANGRID |
|
$ |
107 |
|
|
$ |
120 |
|
|
$ |
351 |
|
|
$ |
359 |
|
Denominator: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Weighted average number of shares outstanding - basic |
|
|
309,517,854 |
|
|
|
309,520,718 |
|
|
|
309,515,758 |
|
|
|
309,514,836 |
|
Weighted average number of shares outstanding - diluted |
|
|
309,719,584 |
|
|
|
309,826,185 |
|
|
|
309,711,682 |
|
|
|
309,799,839 |
|
Earnings per share attributable to AVANGRID |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Earnings Per Common Share, Basic |
|
$ |
0.35 |
|
|
$ |
0.39 |
|
|
$ |
1.13 |
|
|
$ |
1.16 |
|
Earnings Per Common Share, Diluted |
|
$ |
0.34 |
|
|
$ |
0.39 |
|
|
$ |
1.13 |
|
|
$ |
1.16 |
|
Note 13. Segment Information
Our segment reporting structure uses our management reporting structure as its foundation to reflect how AVANGRID manages the business internally and is organized by type of business. We report our financial performance based on the following two reportable segments:
• |
Networks: includes all of the energy transmission and distribution activities, any other regulated activity originating in New York and Maine and regulated electric distribution, electric transmission and gas distribution activities originating in Connecticut and Massachusetts. The Networks reportable segment includes eight rate regulated operating segments. These operating segments generally offer the same services distributed in similar fashions, have the same types of customers, have similar long-term economic characteristics and are subject to similar regulatory requirements, allowing these operations to be aggregated into one reportable segment. |
• |
Renewables: activities relating to renewable energy, mainly wind energy generation and trading related with such activities. |
Based on the quantitative assessment and due to the disposition of gas trading and storage businesses (see Note 20 – Assets Held For Sale for further discussion) the Gas business no longer meets the reportable segment criteria effective in the first quarter of 2018. Additionally, to better align the evaluation of the segment information for both internal and external purposes, effective in the second quarter of 2018, the evaluation of the segments performance by the chief operating decision maker was changed from adjusted EBITDA (Earnings Before Interest, Taxes, Depreciation and Amortization) used in the prior periods to adjusted net income. As a result, the prior periods segment information has been restated to conform to the 2018 presentation.
We define adjusted net income as net income adjusted to exclude restructuring charges, mark-to-market adjustments to reflect the effect of mark-to-market changes in the fair value of derivative instruments used by AVANGRID to economically hedge market price fluctuations in related underlying physical transactions for the purchase and sale of electricity, loss from held for sale measurement, income from release of collateral, impact of the Tax Act and adjustments for the non-core Gas business.
Products and services are sold between reportable segments and affiliate companies at cost. Segment income, expense, and assets presented in the accompanying tables include all intercompany transactions that are eliminated in the condensed consolidated financial statements.
39
Segment information for the three months ended June 30, 2018, consisted of:
Three Months Ended June 30, 2018 |
|
Networks |
|
|
Renewables |
|
|
Other (a) |
|
|
AVANGRID Consolidated |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Revenue - external |
|
$ |
1,103 |
|
|
$ |
296 |
|
|
$ |
3 |
|
|
$ |
1,402 |
|
Revenue - intersegment |
|
|
2 |
|
|
|
1 |
|
|
|
(3 |
) |
|
|
— |
|
Loss from assets held for sale |
|
|
— |
|
|
|
— |
|
|
|
10 |
|
|
|
10 |
|
Depreciation and amortization |
|
|
128 |
|
|
|
87 |
|
|
|
— |
|
|
|
215 |
|
Operating income (loss) |
|
|
183 |
|
|
|
55 |
|
|
|
(16 |
) |
|
|
222 |
|
Earnings (losses) from equity method investments |
|
|
4 |
|
|
|
1 |
|
|
|
— |
|
|
|
5 |
|
Interest expense, net of capitalization |
|
|
65 |
|
|
|
7 |
|
|
|
(2 |
) |
|
|
70 |
|
Income tax expense (benefit) |
|
|
23 |
|
|
|
(24 |
) |
|
|
28 |
|
|
|
27 |
|
Adjusted net income |
|
|
79 |
|
|
|
68 |
|
|
|
(18 |
) |
|
|
128 |
|
(a) Includes Corporate, Gas and intersegment eliminations.
Included in revenue-external for the three months ended June 30, 2018, are: $864 million from regulated electric operations, $242 million from regulated gas operations and $(3) million from other operations of Networks; $296 million primarily from renewable energy generation of Renewables.
Segment information for the three months ended June 30, 2017, consisted of:
Three Months Ended June 30, 2017 |
|
Networks |
|
|
Renewables |
|
|
Other (a) |
|
|
AVANGRID Consolidated |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Revenue - external |
|
$ |
1,065 |
|
|
$ |
263 |
|
|
$ |
3 |
|
|
$ |
1,331 |
|
Revenue - intersegment |
|
|
2 |
|
|
|
2 |
|
|
|
(4 |
) |
|
|
— |
|
Depreciation and amortization |
|
|
120 |
|
|
|
80 |
|
|
|
6 |
|
|
|
206 |
|
Operating income (loss) |
|
|
225 |
|
|
|
50 |
|
|
|
(23 |
) |
|
|
252 |
|
Earnings (losses) from equity method investments |
|
|
3 |
|
|
|
(2 |
) |
|
|
— |
|
|
|
1 |
|
Interest expense, net of capitalization |
|
|
58 |
|
|
|
8 |
|
|
|
2 |
|
|
|
68 |
|
Income tax expense (benefit) |
|
|
56 |
|
|
|
6 |
|
|
|
(18 |
) |
|
|
44 |
|
Adjusted net income |
|
|
96 |
|
|
|
37 |
|
|
|
10 |
|
|
|
143 |
|
(a) Includes Corporate, Gas and intersegment eliminations.
Included in revenue-external for the three months ended June 30, 2017, are: $821 million from regulated electric operations, $248 million from regulated gas operations and $(4) million from other operations of Networks; $263 million primarily from renewable energy generation of Renewables.
Segment information as of and for the six months ended June 30, 2018, consisted of:
Six Months Ended June 30, 2018 |
|
Networks |
|
|
Renewables |
|
|
Other (a) |
|
|
AVANGRID Consolidated |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Revenue - external |
|
$ |
2,652 |
|
|
$ |
579 |
|
|
$ |
36 |
|
|
$ |
3,267 |
|
Revenue - intersegment |
|
|
5 |
|
|
|
2 |
|
|
|
(7 |
) |
|
|
— |
|
Loss from assets held for sale |
|
|
— |
|
|
|
— |
|
|
|
15 |
|
|
|
15 |
|
Depreciation and amortization |
|
|
246 |
|
|
|
172 |
|
|
|
— |
|
|
|
418 |
|
Operating income (loss) |
|
|
527 |
|
|
|
99 |
|
|
|
(1 |
) |
|
|
625 |
|
Earnings (losses) from equity method investments |
|
|
6 |
|
|
|
1 |
|
|
|
— |
|
|
|
7 |
|
Interest expense, net of capitalization |
|
|
125 |
|
|
|
15 |
|
|
|
4 |
|
|
|
144 |
|
Income tax expense (benefit) |
|
|
87 |
|
|
|
(32 |
) |
|
|
44 |
|
|
|
99 |
|
Adjusted net income |
|
|
280 |
|
|
|
115 |
|
|
|
(23 |
) |
|
|
371 |
|
Capital expenditures |
|
|
522 |
|
|
|
229 |
|
|
|
— |
|
|
|
751 |
|
As of June 30, 2018 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Property, plant and equipment |
|
|
14,162 |
|
|
|
8,747 |
|
|
|
8 |
|
|
|
22,917 |
|
Equity method investments |
|
|
144 |
|
|
|
218 |
|
|
|
— |
|
|
|
362 |
|
Total assets |
|
$ |
21,336 |
|
|
$ |
11,121 |
|
|
$ |
(1,081 |
) |
|
$ |
31,376 |
|
(a) |
Includes Corporate, Gas and intersegment eliminations. |
40
Included in revenue-external for the six months ended Jun e 30, 2018, are: $1,819 million from regulated electric operations, $842 million from regulated gas operations and $(9) million from other operations of Networks; $579 million primarily from renewable energy generation of Renewables.
Segment information for the six months ended June 30, 2017, consisted of:
Six Months Ended June 30, 2017 |
|
Networks |
|
|
Renewables |
|
|
Other (a) |
|
|
AVANGRID Consolidated |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Revenue - external |
|
$ |
2,525 |
|
|
$ |
548 |
|
|
$ |
16 |
|
|
$ |
3,089 |
|
Revenue - intersegment |
|
|
1 |
|
|
|
4 |
|
|
|
(5 |
) |
|
|
— |
|
Depreciation and amortization |
|
|
233 |
|
|
|
158 |
|
|
|
12 |
|
|
|
403 |
|
Operating income (loss) |
|
|
590 |
|
|
|
106 |
|
|
|
(17 |
) |
|
|
679 |
|
Earnings (losses) from equity method investments |
|
|
7 |
|
|
|
(4 |
) |
|
|
— |
|
|
|
3 |
|
Interest expense, net of capitalization |
|
|
121 |
|
|
|
16 |
|
|
|
2 |
|
|
|
139 |
|
Income tax expense (benefit) |
|
|
172 |
|
|
|
(15 |
) |
|
|
(10 |
) |
|
|
147 |
|
Adjusted net income |
|
|
268 |
|
|
|
96 |
|
|
|
5 |
|
|
|
369 |
|
Capital expenditures |
|
|
534 |
|
|
|
531 |
|
|
|
4 |
|
|
|
1,069 |
|
As of December 31, 2017 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Property, plant and equipment |
|
|
13,876 |
|
|
|
8,786 |
|
|
|
7 |
|
|
|
22,669 |
|
Equity method investments |
|
|
147 |
|
|
|
205 |
|
|
|
— |
|
|
|
352 |
|
Total assets |
|
$ |
21,411 |
|
|
$ |
11,308 |
|
|
$ |
(1,048 |
) |
|
$ |
31,671 |
|
(a) |
Includes Corporate, Gas and intersegment eliminations. |
Included in revenue-external for the six months ended June 30, 2017, are: $1,742 million from regulated electric operations, $785 million from regulated gas operations and $(2) million from other operations of Networks; $548 million primarily from renewable energy generation of Renewables.
Reconciliation of Adjusted Net Income to Net Income attributable to AVANGRID for the three and six months ended June 30, 2018 and 2017, respectively, is as follows:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
(Millions) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Adjusted Net Income Attributable to Avangrid, Inc. |
|
$ |
128 |
|
|
$ |
143 |
|
|
$ |
371 |
|
|
$ |
369 |
|
Adjustments, net of tax: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Loss from assets held for sale (1) |
|
|
(16 |
) |
|
|
— |
|
|
|
(30 |
) |
|
|
— |
|
Mark-to-market adjustments - Renewables (2) |
|
|
(2 |
) |
|
|
(7 |
) |
|
|
1 |
|
|
|
4 |
|
Restructuring charges (3) |
|
|
— |
|
|
|
— |
|
|
|
(1 |
) |
|
|
— |
|
Income from release of collateral - Renewables (4) |
|
|
5 |
|
|
|
— |
|
|
|
5 |
|
|
|
— |
|
Impact of the Tax Act (5) |
|
|
(7 |
) |
|
|
— |
|
|
|
(7 |
) |
|
|
— |
|
Gas Storage (6) |
|
|
(2 |
) |
|
|
(16 |
) |
|
|
11 |
|
|
|
(14 |
) |
Net Income Attributable to Avangrid, Inc. |
|
$ |
107 |
|
|
$ |
120 |
|
|
$ |
351 |
|
|
$ |
359 |
|
|
(1) |
Represents loss from measurement of assets and liabilities held for sale in connection with the committed plan to sell the gas trading and storage businesses (See Note 20 - Assets Held for Sale – for further details). |
|
(2) |
Mark-to-market adjustments relate to changes in the fair value of derivative instruments used by AVANGRID to economically hedge market price fluctuations in related underlying physical transactions for the purchase and sale of electricity and gas. |
|
(3) |
Restructuring and severance related charges relate to costs resulted from restructuring actions involving initial targeted voluntary workforce reductions and related costs in our plan to vacate a lease, predominantly within the Networks segment (See Note 19 - Restructuring and Severance Related Expenses – for further details). |
|
(4) |
Relates to cash collateral released in excess of outstanding receivables from a bankruptcy proceeding with a Renewables customer regarding two power purchase agreements. |
|
(5) |
Represents the impact from measurement of deferred income tax balances as a result of the Tax Act enacted by the U.S. federal government on December 22, 2017 . |
|
(6) |
Removal of the impact from Gas activity in the reconciliation to the AVANGRID Net Income. |
41
Note 14. Related Party Transactions
We engage in related party transactions that are generally billed at cost and in accordance with applicable state and federal commission regulations.
Related party transactions for the three and six months ended June 30, 2018 and 2017, respectively, consisted of:
Three Months Ended June 30, |
|
2018 |
|
|
2017 |
|
||||||||||
(Millions) |
|
Sales To |
|
|
Purchases From |
|
|
Sales To |
|
|
Purchases From |
|
||||
Iberdrola Canada Energy Services, Ltd |
|
$ |
— |
|
|
$ |
— |
|
|
$ |
— |
|
|
$ |
(10 |
) |
Iberdrola Renovables Energía, S.L. |
|
|
— |
|
|
|
(4 |
) |
|
|
— |
|
|
|
(3 |
) |
Iberdrola, S.A. |
|
|
— |
|
|
|
(12 |
) |
|
|
— |
|
|
|
(9 |
) |
Iberdrola Energia Monterrey, S.A. de C.V. |
|
|
— |
|
|
|
— |
|
|
|
14 |
|
|
|
— |
|
Other |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(2 |
) |
Six Months Ended June 30, |
|
2018 |
|
|
2017 |
|
||||||||||
(Millions) |
|
Sales To |
|
|
Purchases From |
|
|
Sales To |
|
|
Purchases From |
|
||||
Iberdrola Canada Energy Services, Ltd |
|
$ |
— |
|
|
$ |
(4 |
) |
|
$ |
— |
|
|
$ |
(20 |
) |
Iberdrola Renovables Energía, S.L. |
|
|
— |
|
|
|
(7 |
) |
|
|
— |
|
|
|
(5 |
) |
Iberdrola, S.A. |
|
|
— |
|
|
|
(26 |
) |
|
|
— |
|
|
|
(18 |
) |
Iberdrola Energia Monterrey, S.A. de C.V. |
|
|
3 |
|
|
|
— |
|
|
|
29 |
|
|
|
— |
|
Other |
|
|
1 |
|
|
|
(1 |
) |
|
|
1 |
|
|
|
(2 |
) |
In addition to the statements of income items above, we made purchases of turbines for wind farms from Siemens-Gamesa, in which Iberdrola has an 8.1% ownership. The amounts capitalized for these transactions were $1 million and $266 million for the periods ended June 30, 2018 and December 31, 2017, respectively.
Related party balances as of June 30, 2018 and December 31, 2017, respectively, consisted of:
As of |
|
June 30, 2018 |
|
|
December 31, 2017 |
|
||||||||||
(Millions) |
|
Owed By |
|
|
Owed To |
|
|
Owed By |
|
|
Owed To |
|
||||
Iberdrola Canada Energy Services, Ltd. |
|
$ |
— |
|
|
$ |
(32 |
) |
|
$ |
— |
|
|
$ |
(31 |
) |
Siemens-Gamesa |
|
|
— |
|
|
|
(22 |
) |
|
|
2 |
|
|
|
(51 |
) |
Iberdrola, S.A. |
|
|
2 |
|
|
|
(27 |
) |
|
|
1 |
|
|
|
(32 |
) |
Iberdrola Renovables Energía, S.L. |
|
|
— |
|
|
|
(7 |
) |
|
|
— |
|
|
|
— |
|
Iberdrola Energia Monterrey, S.A. de C.V. |
|
|
— |
|
|
|
— |
|
|
|
1 |
|
|
|
— |
|
Other |
|
|
1 |
|
|
|
(1 |
) |
|
|
6 |
|
|
|
(4 |
) |
Transactions with Iberdrola, our majority shareholder, relate predominantly to the provision and allocation of corporate services and management fees. All costs that can be specifically allocated, to the extent possible, are charged directly to the company receiving such services. In situations when Iberdrola corporate services are provided to two or more companies of AVANGRID, any costs remaining after direct charges are allocated using agreed upon cost allocation methods designed to allocate such costs. We believe that the allocation method used is reasonable.
Transactions with Iberdrola Canada Energy Services (ICES) predominantly relate to the purchase of gas for ARHI’s gas-fired cogeneration facility in Klamath, Oregon. Included in the amounts owed to ICES are notes payable of $31 million and $29 million as of June 30, 2018 and December 31, 2017, respectively.
Transactions with Iberdrola Energia Monterrey predominantly relate to the sale of gas by Enstor Gas for the power generation plant in Monterrey, Mexico.
There have been no guarantees provided or received for any related party receivables or payables. These balances are unsecured and are typically settled in cash. Interest is not charged on regular business transactions but is charged on outstanding loan balances. There have been no impairments or provisions made against any affiliated balances.
Networks holds an approximate 20% ownership interest in the regulated New York TransCo, LLC (New York TransCo). Through New York TransCo, Networks has formed a partnership with Central Hudson Gas and Electric Corporation, Consolidated Edison, Inc., National Grid, plc and Orange and Rockland Utilities, Inc. to develop a portfolio of interconnected transmission lines and
42
substations to fulfill the objectives of the New York energy highway initiative, which is a proposal to install up to 3,200 MW of new electric generation and transmission capacity in order to deliver more power generated from upstate New York power plant s to downstate New York. As of June 30, 2018 and December 31, 2017, the amount receivable from New York TransCo was $1 million and $6 million, respectively.
Renewables holds a 50% ownership in Vineyard Wind, LLC (Vineyard), a joint venture with Copenhagen Infrastructure Partners. Vineyard acquired a lease from the U.S. Bureau of Ocean Energy Management containing rights to develop offshore wind generation in a 260 square mile area located southeast of Martha’s Vineyard. The leased area has the capacity for siting up to approximately 3,000 MW. In May 2018, Vineyard was selected by the Massachusetts Electric Distribution Companies (EDCs) to construct and operate Vineyard’s proposed 800 MW wind farm and electricity transmission project pursuant to the Massachusetts Green Communities Act Section 83C RFP for offshore wind energy projects. We account for Vineyard under the equity method of accounting. Under the provisions of the LLC agreement, Renewables has committed $92 million in total contributions, of which $26 million has been funded to date.
AVANGRID manages its overall liquidity position as part of the Iberdrola Group and is a party to a liquidity agreement with a financial institution, along with certain members of the Iberdrola Group. Cash surpluses remaining after meeting the liquidity requirements of AVANGRID and its subsidiaries may be deposited at the financial institution. Deposits, or credit balances, serve as collateral against the debit balances of other parties to the liquidity agreement. The balance at both June 30, 2018 and December 31, 2017, was zero.
On June 18, 2018, AVANGRID entered into a credit facility with Iberdrola Financiacion, S.A.U., a company of the Iberdrola Group. The facility has a limit of $500 million and matures on June 18, 2023. AVANGRID pays a facility fee of 10.5 basis points annually on the facility. As of June 30, 2018, there was no outstanding amount under this credit facility.
Note 15. Supplemental Balance Sheet Information
Accounts receivable
Accounts receivable include amounts due under deferred payment arrangements (DPA). A DPA allows the account balance to be paid in installments over an extended period of time, which generally exceeds one year, by negotiating mutually acceptable payment terms and not bearing interest. The utility company generally must continue to serve a customer who cannot pay an account balance in full if the customer (i) pays a reasonable portion of the balance; (ii) agrees to pay the balance in installments; and (iii) agrees to pay future bills within 30 days until the DPA is paid in full. Failure to make payments on a DPA results in the full amount of a receivable under a DPA being due. These accounts are part of the regular operating cycle and are classified as current.
We establish provisions for uncollectible accounts for DPAs by using both historical average loss percentages to project future losses and by establishing specific provisions for known credit issues. Amounts are written off when reasonable collection efforts have been exhausted. DPA receivable balances were $61 million and $55 million at June 30, 2018 and December 31, 2017, respectively. The allowance for doubtful accounts for DPAs at June 30, 2018 and December 31, 2017, was $32 million and $30 million, respectively. Furthermore, the provision for bad debts associated with the DPAs for the three and six months ended June 30, 2018 was $1 million and $2 million, respectively, and for the three and six months ended June 30, 2017 was $2 million and $3 million, respectively.
Prepayments and other current assets
Included in “Prepayments and other current assets” are $67 million and $194 million of prepaid other taxes as of June 30, 2018 and December 31, 2017, respectively.
Property, plant and equipment and intangible assets
The accumulated depreciation and amortization as of June 30, 2018 and December 31, 2017, respectively, were as follows :
|
|
June 30, |
|
|
December 31, |
|
||
As of |
|
2018 |
|
|
2017 |
|
||
(Millions) |
|
|
|
|
|
|
|
|
Property, plant and equipment |
|
|
|
|
|
|
|
|
Accumulated depreciation |
|
$ |
7,951 |
|
|
$ |
7,497 |
|
Intangible assets |
|
|
|
|
|
|
|
|
Accumulated amortization |
|
$ |
283 |
|
|
$ |
276 |
|
Note 16. Income Tax Expense
The effective tax rates, inclusive of federal and state income tax, for the three and six months ended June 30, 2018, were 19.7% and 22.1%, respectively, which, for the three months ended June 30, 2018 is lower than the 21% statutory federal income tax rate
43
applicable in 2018, predominantly due to discrete tax adjustments recorded during the period offset by the recognition of production tax credits associated with wind production, and for the six months ended June 30, 2018 is higher than the 21% statutory federal income tax rate applicable in 2018, predominantly due to $21.6 million of tax expense recorded in connection with the disposal of the Gas business and discrete adjustments recorded during the period offset by the recognition of production tax credi ts associated with wind production. The effective tax rates, inclusive of federal and state income tax, for the three and six months ended June 30, 2017, were 26.8% and 29.1%, respectively, which were lower than the 35% statutory federal income tax rate ap plicable in 2017, predominantly due to the recognition of production tax credits associated with wind production in both periods. Additionally, $14 million in income tax expense for the six months ended June 30, 2017, is due to unfunded future income tax t o reflect the change from a flow through to normalization method, which was recorded as an increase to revenue, with an offsetting and equal increase to income tax expense. This was offset by other discrete tax adjustments during the period.
Upon enactment of the Tax Act, the Company remeasured its existing deferred income tax balances as of December 31, 2017 to reflect the decrease in the corporate income tax rate from 35% to 21%, which resulted in a material decrease to its net deferred income tax liability balances. In connection with the Tax Act, the U.S. Securities and Exchange Commission issued guidance in Staff Accounting Bulletin 118 (SAB 118), which clarified accounting for income taxes under ASC 740, Income Taxes, if information was not yet available or complete and provided up to a one year measurement period in which to complete the required analyses and accounting. Following SAB 118 guidance, the Company recorded provisional income tax amounts as of December 31, 2017 related to the Tax Act based on reasonable estimates that could be determined at that time. As of June 30, 2018, we are continuing to refine our accounting for income taxes related to the Tax Act and no material impacts have been recorded for the three and six months ended June 30, 2018. The main items we are working to finalize relate to estimates of the income tax accounting for plant related adjustments impacting our Networks entities. The Company expects final adjustments to the provisional amounts to be recorded in the third and fourth quarters of 2018 and the adjustments could be material to the Company’s future results of operations or financial positions.
Note 17. Stock-Based Compensation Expense
Pursuant to the 2016 Avangrid, Inc. Omnibus Incentive Plan 34,361 additional performance stock units (PSUs) were granted to certain officers and employees of AVANGRID in March and June 2018. The PSUs will vest upon achievement of certain performance- and market-based metrics related to the 2016 through 2019 plan and will be payable in three equal installments in 2020, 2021 and 2022. The fair value on the grant date was determined based on $31.80 per share.
In June 2018, pursuant to the Avangrid, Inc. Omnibus Incentive Plan 60,000 restricted stock units (RSUs) were granted to the Chief Executive Officer of AVANGRID. The RSUs vest in full in one installment on the date of AVANGRID’s regular annual shareholders meeting occurring in calendar year 2020, provided that the award holder remains continuously employed with AVANGRID through such date. The fair value on the grant date was determined based on $50.40 per share.
The total stock-based compensation expense, which is included in operations and maintenance of the condensed consolidated statements of income, for the three and six months ended June 30, 2018 was $0.5 million and $0.4 million, respectively, and for the three and six months ended June 30, 2017 was $2.6 million and $3.9 million, respectively .
Before 2016, AVANGRID’s historical stock-based compensation expense and liabilities were based on shares of Iberdrola and not on shares of AVANGRID. These Iberdrola shares-based awards were early terminated at the end of 2015, and the remaining liability was settled in March 2018. The total liability relating to those awards, which was included in other current liabilities, was $5.5 million as of December 31, 2017.
Note 18. Variable Interest Entities
We participate in certain partnership arrangements that qualify as variable interest entities (VIEs). These arrangements consist of tax equity financing arrangements (TEFs) and partnerships in which an investor holds a noncontrolling interest and does not have substantive kick-out or participating rights.
The sale of a membership interest in the TEFs represents the sale of an equity interest in a structure that is considered a sale of non-financial assets. Under the sale of non-financial assets, the membership interests in the TEFs we sell to third-party investors are reflected as noncontrolling interest in the condensed consolidated balance sheets valued based on a HLBV model. Earnings from the TEFs are recognized in net income attributable to noncontrolling interests in the condensed consolidated statements of income. We consolidate the entities that have TEFs based on being the primary beneficiary for these VIEs.
The assets and liabilities of the VIEs totaled approximately $1,461 million and $123 million, respectively, at June 30, 2018. As of December 31, 2017, the assets and liabilities of VIEs totaled approximately $1,441 million and $185 million, respectively. At June 30, 2018 and December 31, 2017, the assets and liabilities of the VIEs consisted primarily of property, plant and equipment, equity method investments and TEF liabilities. At June 30, 2018 and December 31, 2017, equity method investments of VIEs were approximately $104 million and $107 million, respectively.
44
In May 2018, tax equity financing was completed on El Cabo Wind, LLC (El Cabo) through contributions of $213 million fr om the tax equity investors. In addition to El Cabo, at June 30, 2018, we consider Aeolus Wind Power II LLC and Aeolus Wind Power IV LLC (collectively, Aeolus) to be VIEs. In July 2018, Renewables distributed $18 million of accrued dividends to the tax equ ity investors.
Under the Aeolus structures, we contribute certain wind assets, relating both to existing wind farms and wind farms that are being placed into operation at the time of the relevant transaction, and other parties invest in the share equity of the Aeolus limited liability holding company. As consideration for their investment, the third parties make either an upfront cash payment or a combination of upfront cash and issuance of fixed and contingent notes. We retain a class of membership interest and day-to-day operational and management control of Aeolus, subject to investor approval of certain major decisions. The third-party investors do not receive a lien on any Aeolus assets and have no recourse against us for their upfront cash payments.
The third party investors receive a disproportionate amount of the profit or loss, cash distributions and tax benefits resulting from the wind farm energy generation until the investor recovers its investment and achieves a cumulative annual after-tax return. Once this target return is met, the relative sharing of profit or loss, cash distributions and taxable income or loss between the Company and the third party investor flips, with the Company taking a disproportionate share of such amounts thereafter. We also have a call option to acquire the third party investors’ membership interest within a defined time period after this target return is met.
Our Aeolus and El Cabo interests are not subject to any rights of investors that may restrict our ability to access or use the assets or to settle any existing liabilities associated with the interests.
Note 19. Restructuring and Severance Related Expenses
In 2017, we announced initial targeted voluntary workforce reductions predominantly within the Networks segment. Those actions primarily include: reducing our workforce through voluntary programs in various other areas to better align our people resources with business demands and priorities; reorganizing our human resources function to substantially consolidate in Connecticut, as well as related costs to vacate a lease and relocate employees; and reducing our information technology (IT) workforce to make increasing use of external services for operations, support, and development of systems. Those decisions and transactions resulted in restructuring charges recorded in the three and six months ended June 30, 2018 for severance expenses of $0 and $1.2 million, which are included in operations and maintenance in the condensed consolidated statements of income. The remaining costs for severance agreements are being accrued ratably over the remaining service periods, which span intermittent periods through December 2018. Accordingly, the Company expects additional costs to be incurred in 2018 related to the remaining employee service periods under the severance plans. There were no amounts accrued at June 30, 2017. In the six months ended June 30, 2018, the severance and lease restructuring charges reserves, which are recorded in other current liabilities and other liabilities, consisted of:
|
|
Six Months Ended June 30, 2018 |
|
|
|
|
(Millions) |
|
|
Beginning Balance |
|
$ |
5 |
|
Restructuring and severance related expenses |
|
|
1 |
|
Payments |
|
|
(3 |
) |
Ending Balance |
|
$ |
3 |
|
Note 20. Assets Held For Sale
In December 2017, our management committed to a plan to sell the gas trading and storage businesses because they represented non-core businesses that were not aligned with our strategic objectives. At that time, we determined that the assets and liabilities associated with our gas trading and storage businesses met the criteria for classification as assets held for sale, but did not meet the criteria for classification as discontinued operations. On March 1, 2018, the Company closed a transaction to sell Enstor Energy Services, LLC, which operated AVANGRID’s gas trading business, to CCI U.S. Asset Holdings LLC, a subsidiary of Castleton Commodities International, LLC for $66 million, subject to working capital, cash and other adjustments. The transaction price did not differ materially from the estimated fair value of our gas trading business at December 31, 2017, but is subject to adjustment based on closing and other contract provisions, including certain transition services. On May 1, 2018, the Company closed a transaction to sell Enstor Gas, LLC, which operated AVANGRID’s gas storage business, to Amphora Gas Storage USA, LLC for $66 million, subject to working capital, cash, and other adjustments. The agreement to sell Enstor Gas, LLC contains, among other things, a transition services agreement which obligates ARHI to provide certain transition services for up to one year after the closing date, along with representations, warranties, and covenants customary for a transaction of this nature. In connection with the held for sale classification, we recorded a loss from held for sale measurement of $9.8 million and $15.1 million in the three and six months ended
45
June 30, 2018, respectively, which is included in Loss from assets held for sale in the condensed consolidated statements of income related to final purchase price negotiations and working capital adjustments. Income (loss) before income tax, adjust ed for corporate overhead, attributed to the gas businesses was $(13.8) million and $4.5 million for the three and six months ended June 30, 2018, respectively, and $(23.5) million and $(20.9) million for the three and six months ended June 30, 2017, respe ctively. The current assets and current liabilities held for sale relating to our gas trading and storage businesses consisted of the following as of December 31, 2017:
|
|
December 31, |
|
|
As of |
|
2017 |
|
|
(Millions) |
|
|
|
|
Accounts receivable, net |
|
$ |
137 |
|
Derivative assets |
|
|
25 |
|
Fuel and gas in storage |
|
|
77 |
|
Prepayments and other current assets |
|
|
19 |
|
Property, plant and equipment |
|
|
71 |
|
Intangible assets |
|
|
28 |
|
Assets held for sale |
|
$ |
357 |
|
|
|
|
|
|
Accounts payable and accrued liabilities |
|
|
107 |
|
Derivative liabilities |
|
|
14 |
|
Other liabilities |
|
|
16 |
|
Liabilities held for sale |
|
$ |
137 |
|
The fair values of the assets held for sale were determined using Level 3 inputs and were estimated based on recent market analysis studies, recent offers, and management has performed its own fair valuation modeling using discounted cash flows updated for market participant assumptions as completed by third party valuation firms. Unobservable inputs obtained from third parties were adjusted as necessary for the condition and attributes of the specific assets.
Note 21. Subsequent Events
On July 11, 2018, the board of directors of AVANGRID declared a quarterly dividend of $0.44 per share on its common stock. This dividend is payable on October 1, 2018 to shareholders of record at the close of business on September 7, 2018 .
On July 30, 2018, AVANGRID increased the limit of its commercial paper program from $1 billion to $2 billion. The commercial paper program is backstopped by the AVANGRID Credit Facility that provides for maximum borrowings of up to $2.5 billion in the aggregate.
46
Item 2 . Mana gement’s Discussion and Analysis of Financial Condition and Results of Operations
You should read the following discussion of our financial condition and results of operations in conjunction with the condensed consolidated financial statements and the notes thereto included elsewhere in this Quarterly Report on Form 10-Q and with our audited consolidated financial statements as of December 31, 2017 and 2016, and for the three years ended December 31, 2017, included in our Annual Report on Form 10-K for the year ended December 31, 2017, filed with the Securities and Exchange Commission, or the SEC, on March 26, 2018, which we refer to as our “Form 10-K.” In addition to historical condensed consolidated financial information, the following discussion contains forward-looking statements that reflect our plans, estimates, and beliefs. Our actual results could differ materially from those discussed in the forward-looking statements. The foregoing and other factors are discussed and should be reviewed in our Form 10-K and other subsequent filings with the SEC.
Overview
AVANGRID is a leading sustainable energy company with approximately $31 billion in assets and operations in 24 states. AVANGRID has two primary lines of business - Avangrid Networks and Avangrid Renewables. Avangrid Networks owns eight electric and natural gas utilities, serving 3.2 million customers in New York and New England. Avangrid Renewables owns and operates 7.1 gigawatts of electricity capacity, primarily through wind power, with a presence in 22 states across the United States. AVANGRID supports the U.N.’s Sustainable Development Goals, received a Climate Development Project climate score of “A-”, the top score received in the utilities sector, and has been recognized for two consecutive years by Ethical Boardroom as North American utility with the “best corporate governance practices.” AVANGRID employs approximately 6,500 people. Iberdrola S.A., a corporation (sociedad anónima) organized under the laws of the Kingdom of Spain, a worldwide leader in the energy industry, directly owns 81.5% of outstanding shares of AVANGRID common stock. Our primary business is ownership of our operating businesses, which are described below.
Our direct, wholly-owned subsidiaries include Avangrid Networks, Inc., or Networks, and Avangrid Renewables Holdings, Inc., or Renewables. Networks owns and operates our regulated utility businesses through its subsidiaries, including electric transmission and distribution and natural gas distribution, transportation and sales. Renewables operates a portfolio of renewable energy generation facilities primarily using onshore wind power and also solar, biomass and thermal power.
In December 2017, our management committed to a plan to sell the gas storage and trading businesses because they represented non-core businesses that are not aligned with our strategic objectives. At that time, we determined that the assets and liabilities associated with our gas trading and storage businesses met the criteria for classification as assets held for sale, but did not meet the criteria for classification as discontinued operations. On March 1, 2018, the Company closed a transaction to sell Enstor Energy Services, LLC, which operated AVANGRID’s gas trading business, to CCI U.S. Asset Holdings LLC, a subsidiary of Castleton Commodities International, LLC. On May 1, 2018, the Company closed a transaction to sell Enstor Gas, LLC, which operated the AVANGRID’s gas storage business, to Amphora Gas Storage USA, LLC. The agreement included, among other things, a transition services agreement which obligates ARHI to provide certain transition services for up to one year after the closing date and includes a guarantee the Company will release certain obligations to Amphora Gas Storage USA, LLC.
Through Networks, we own electric generation, transmission and distribution companies and natural gas distribution, transportation and sales companies in New York, Maine, Connecticut and Massachusetts, delivering electricity to approximately 2.2 million electric utility customers and delivering natural gas to approximately 1 million natural gas public utility customers as of June 30, 2018.
Networks, a Maine corporation, holds our regulated utility businesses, including electric transmission and distribution and natural gas distribution, transportation and sales. Networks serves as a super-regional energy services and delivery company through eight regulated utilities it owns directly:
|
• |
New York State Electric & Gas Corporation, or NYSEG, which serves electric and natural gas customers across more than 40% of the upstate New York geographic area; |
|
• |
Rochester Gas and Electric Corporation, or RG&E, which serves electric and natural gas customers within a nine-county region in western New York, centered around Rochester; |
|
• |
The United Illuminating Company, or UI, which serves electric customers in southwestern Connecticut; |
|
• |
Central Maine Power Company, or CMP, which serves electric customers in central and southern Maine; |
|
• |
The Southern Connecticut Gas Company, or SCG, which serves natural gas customers in southern Connecticut; |
|
• |
Connecticut Natural Gas Corporation, or CNG, which serves natural gas customers in Connecticut; |
47
|
• |
The Berkshire Gas Company, or BGC, which serves natural gas customers in western Massachusetts; and |
|
• |
Maine Natural Gas Corporation, or MNG, which serves natural gas customers in several communities in central and southern Maine. |
Through Renewables, we had a combined wind, solar and thermal installed capacity of 7,136 megawatts, or MW, as of June 30, 2018, including Renewables’ share of joint projects, of which 6,385 MW was installed wind capacity. Approximately 70% of the capacity was contracted as of June 30, 2018, for an average period of 9.0 years. Being among the top three largest wind operators in the United States based on installed capacity as of June 30, 2018, Renewables strives to lead the transformation of the U.S. energy industry to a competitive, clean energy future. Renewables currently operates 58 wind farms in 21 states across the United States.
Summary of Results of Operations
Our operating revenues increased by 5%, from $1.3 billion for the three months ended June 30, 2017 to $1.4 billion for the three months ended June 30, 2018.
Networks business revenues increased due to the impact of higher average rates and an increase in heating degree days from colder weather. Renewables had an increase in revenue mainly due to an increase in wind capacity along with higher average prices in the period.
Net income attributable to AVANGRID decreased by 11% from $120 million for the three months ended June 30, 2017 to $107 million for the three months ended June 30, 2018. Networks net income decreased primarily due to higher non-deferrable storm costs. Renewables net income increased as a result of higher wind capacity and increase in average prices.
Adjusted EBITDA (a non-GAAP financial measure) decreased by 4% from $495 million for the three months ended June 30, 2017 to $477 million for the three months ended June 30, 2018. Adjusted gross margin (a non-GAAP financial measure) increased by 9%, from $974 million for the three months ended June 30, 2017 to $1,066 million for the three months ended June 30, 2018. The decrease and increase, respectively, in the non-GAAP adjusted EBITDA and non-GAAP adjusted gross margin is primarily driven by higher non-deferrable storm costs and the adverse impact of the Tax Act on regulated revenue along with higher average rates and an increase in heating degree days from colder weather in the period at Networks as well as increased capacity and higher production tax credits, or PTCs, in the period at Renewables.
Adjusted net income (a non-GAAP financial measure) decreased by 10% from $143 million for the three months ended June 30, 2017 to $128 million for the three months ended June 30, 2018. The decrease is primarily due to $17 million decrease in Networks driven by higher non-deferrable storm costs in the period, $28 million decrease in Corporate mainly driven by lower interest income on intercompany loans due to the sale of the gas business in 2018 and higher income tax expense from effective tax rate adjustment, offset by $30 million increase in Renewables due to increased capacity and higher PTCs in the period.
The non-GAAP adjusted net income increased by 1%, from $369 million for the six months ended June 30, 2017 to $371 million for the six months ended June 30, 2018. The increase is primarily due to $12 million increase in Networks driven by higher average rates and an increase in heating degree days from colder weather, $18 million increase in Renewables due to increased capacity and higher PTCs in the period, offset by $28 million decrease in Corporate mainly driven by lower interest income on intercompany loans due to the sale of the gas business in 2018 and higher income tax expense from effective tax rate adjustment.
For additional information and reconciliation of the non-GAAP adjusted EBITDA, the non-GAAP adjusted gross margin, and adjusted net income to net income attributable to AVANGRID, see “— Non-GAAP Financial Measures ”.
See “— Results of Operations ” for further analysis of our operating results for the quarter.
Legislative and Regulatory Update
We are subject to complex and stringent energy, environmental and other laws and regulations at the federal, state and local levels as well as rules within the independent system operator, or ISO, markets in which we participate. Federal and state legislative and regulatory actions continue to change how our business is regulated. We are actively participating in these debates at the federal, regional, state and ISO levels. Significant updates are discussed below. For a further discussion of the environmental and other governmental regulations that affect us, see our Form 10-K for the year ended December 31, 2017.
BGC and CNG rate cases
On May 17, 2018, BGC filed a petition with the Department of Public Utilities, or DPU, for approval of a general increase in its gas distribution rates to be effective April 1, 2019. BGC requested an increase to the base distribution rate revenue requirement of $4.54 million, offset by decreases in other factors of $1.43 million, resulting in a net change in operating revenue of $3.11 million, and
48
a 10.35% return on equity, or ROE, applied to existing capital structure. BGC’s filing takes into account the reduction in the federal corporate income tax rate that results from the Tax Act, which became effective January 1, 2018. As part of the filing, BGC also proposed an alternative ratemaking mechanism, or ARM, that will allow it to annually adjust its rates without filing for a base rate proceeding. The proposed ARM has a five-year term that begins in 2019 with the establishment of rates approved in this proceeding and is followed by four annual rate adjustments in 2020 through 2023. Further, BGC proposed to implement a rate mechanism to decouple its gas revenues from its sales and a reconciling mechanism to recover costs associated with p ension and other post-retirement employee benefits.
On June 29, 2018, CNG filed an application with Connecticut Public Utilities Regulatory Authority, or PURA, for new tariffs to become effective January 1, 2019. CNG requested a three-year rate plan for calendar years 2019, 2020 and 2021. The Application requests an increase in rates of $16.6 million in 2019, an incremental increase of $10.1 million in 2020 and an incremental increase of $1.1 million in 2021. In addition, the application proposes to implement a customer rate credit of $1.25 million per year through 2027 as an offset in base rates, arising from the merger commitments made in connection with AVANGRID’s acquisition of UIL Holdings Corporation, or UIL, in December 2015; a return to customers of the full tax benefits resulting from the reduction in the corporate federal income tax rate in the Tax Cuts and Jobs Act of 2017, or the Tax Act; and ratemaking proposals to transition the DIMP mechanism to operate as a true-up mechanism, and to apply CNG’s current decoupling mechanism to all firm customers going forward.
New York State Department of Public Service Investigation of the Preparation for and Response to the March 2017 Windstorm
On March 11, 2017 the New York State Department of Public Service, or the Department, commenced an investigation of NYSEG’s and RG&E’s preparation for and response to the March 2017 windstorm, which affected more than 219,000 NYSEG and RG&E customers. The Department Staff issued a report, or the Staff Report, of the findings from their investigation on November 16, 2017. The Staff Report made several recommendations for future storm response and also alleged that NYSEG and RG&E had violated their own emergency response plan in a number of respects.
Also on November 16, 2017, the New York State Public Service Commission, or the NYPSC, issued an Order Instituting Proceeding and to Show Cause, or the Order, requiring the companies to address whether the NYPSC should mandate, reject or modify, in whole or in part the recommendations made in the Staff Report. The Order also required the companies to show cause why the NYPSC should not commence an administrative penalty proceeding. On May 18, 2018, NYSEG and RG&E filed a settlement joint proposal and investment joint proposal before the NYPSC to settle potential penalties and avoid litigation related to the March 2017 windstorm, pursuant to which, among other things, NYSEG and RG&E have agreed to make $3.9 million in investments designed to increase resiliency and improve emergency response in the areas impacted by the storm. The investments will not be reflected in rate base or operating expenses in establishing future delivery rates. The joint proposals are subject to public comment and NYPSC approval. We cannot predict the final outcome of this matter.
New York State Department of Public Service Investigation of the Preparation for and Response to the March 2018 Winter Storms
In March 2018, following two severe winter storms that impacted over more than a million electric utility customers in New York, including 520,000 NYSEG and RG&E customers, the NYPSC initiated a comprehensive investigation of all the New York electric utilities’ preparation and response to those events. The investigation has been expanded to include other 2018 New York spring storm events. We cannot predict the final outcome of this matter.
CMP rate case
On August 25, 2014, the Maine Public Utility Commission, or the MPUC, approved a stipulation agreement that provided for a distribution rate increase for CMP of approximately $24.3 million, effective July 1, 2014, with an allowed ROE of 9.45% and an allowed equity ratio of 50%. The stipulation provided for the implementation of a revenue decoupling mechanism, or RDM, reserve accounting and sharing of incremental storm costs, a separate proceeding for recovery of a new billing system and no earning sharing. On May 29, 2018, a ten-person complaint was filed with the MPUC against CMP, Networks and AVANGRID. The complaint requested that the MPUC open a rate case to determine if CMP is making excessive returns on investment and, therefore, whether CMP’s retail rates should be lower. The complaint also requested the MPUC deny certain costs associated with the October 2017 windstorm. On July 24, 2018, the MPUC issued an order dismissing the complaint and its associated request to deny the recovery of costs associated with the October 2017 windstorm. The order initiated an investigation into CMP’s rates and revenue requirement and directed CMP to make a filing consistent with the requirements for a general rate case no later than October 15, 2018. We cannot predict the outcome of this matter.
49
CMP Customer Billing System Investigation and Class Action
On March 1, 2018, the MPUC issued a Notice of Investigation initiating a summary investigation into CMP’s metering, billing, and customer communications practices. Due to the highly technical nature of CMP’s customer billing system, on March 22, 2018 the MPUC issued an Order Initiating Audit commencing a forensic audit of CMP’s customer billing system to identify any errors that have, or continue to be resulting in billing inaccuracies. On July 10, 2018, the MPUC issued an Order Modifying Scope of Audit, which expanded the scope of the audit to include CMP’s customer communication practices. We cannot predict the outcome of this matter.
On July 19, 2018, a class action lawsuit was filed against CMP in the Cumberland County Superior Court on behalf of all CMP customers alleging that CMP’s new billing software and metering system improperly overcharged customers. The plaintiff asserts this claim under the common law of unjust enrichment and seeks damages and attorney fees and costs. We cannot predict the outcome of this class action lawsuit.
Transmission - ROE Complaint IV
On November 21, 2017, the parties to the Complaint IV submitted updates to their ROE analyses and recommendations with the NETOs continuing to advocate that the existing base ROE of 10.57% should remain in effect. Hearings were held in December 2017. On March 27, 2018, the administrative law judge issued an initial decision rejecting Complaint IV, finding the currently-filed base ROE of 10.57%, which, with incentive adders, may reach a maximum ROE of 11.74%, is not unjust and unreasonable, and hence is not unlawful. Briefs on Exceptions to the Administrative Law Judge ’s initial decision were filed on April 26, 2018, and Briefs Opposing Exceptions were filed on May 23, 2018. The Federal Energy Regulatory Commission, or FERC, has not yet issued its final decision in this matter. We cannot predict the outcome of this proceeding.
Tax Act proceedings
The Tax Act significantly changed the federal taxation of business entities including, among other things, implementing a federal corporate tax rate decrease from 35% to 21% for tax years beginning after December 31, 2017. Reductions in accumulated deferred income tax balances due to the reduction in the corporate income tax rates will result in amounts previously and currently collected from utility customers for these deferred taxes to be refundable to such customers, generally through reductions in future rates. The NYPSC, MPUC, PURA, DPU and the FERC have instituted separate proceedings in New York, Maine, Connecticut, Massachusetts and the FERC, respectively, to review and address the implications of the Tax Act on the utilities.
In New York, the NYPSC Staff issued a proposal on March 29, 2018, whereby the staff recommends that Tax Act benefits be returned to customers beginning October 1, 2018. Comments on this staff proposal were submitted by the Joint Utilities of New York with a separate Appendix by each respective major utility on June 27, 2018, including our New York utility companies. NYSEG and RG&E have stated that they believe Tax Act benefits should be utilized for utility programs for the benefit of customers, including for new projects such as Automated Metering Infrastructure, or AMI, other future resiliency investments and to recover deferred regulatory assets. We expect a NYPSC decision in the third quarter of 2018. In Connecticut, UI and SCG expect Tax Act savings to be deferred until they are reflected in tariffs in a future rate case, unless PURA determines otherwise. CNG and Berkshire included Tax Act savings in rate cases that were filed with PURA and the DPU, respectively, in the second quarter of 2018. In Maine, CMP adjusted rates beginning July 2, 2018 to pass back to customers the Tax Act savings after offsetting for recovery of deferred 2017 storm costs. At the FERC, CMP transmission and UI transmission adjusted its tariffs in June 2018 to reflect the income statement value of Tax Act savings.
Upon enactment of the Tax Act, the Company remeasured its existing deferred income tax balances as of December 31, 2017 to reflect the decrease in the corporate income tax rate from 35% to 21%, which resulted in a material decrease to its net deferred income tax liability balances. In connection with the Tax Act, the U.S. Securities and Exchange Commission issued guidance in Staff Accounting Bulletin 118, or SAB 118, which clarified accounting for income taxes under ASC 740, Income Taxes, if information was not yet available or complete and provided up to a one year measurement period in which to complete the required analyses and accounting. Following SAB 118 guidance, the Company recorded provisional income tax amounts as of December 31, 2017 related to the Tax Act based on reasonable estimates that could be determined at that time. As of June 30, 2018, we are continuing to refine our accounting for income taxes related to the Tax Act and no material impacts have been recorded for the three and six months ended June 30, 2018. The main items we are working to finalize relate to estimates of the income tax accounting for plant related adjustments impacting our Networks entities. The Company expects final adjustments to the provisional amounts to be recorded in the third and fourth quarters of 2018 and the adjustments could be material to the Company’s future results of operations or financial positions.
Power Tax Audits
In 2015, we implemented power tax software to track and measure deferred tax amounts for CMP, NYSEG and RG&E. In connection with this change, we identified historical updates needed with deferred taxes recognized by CMP, NYSEG and RG&E. We
50
incr eased our deferred tax liabilities in 2015, with a corresponding increase to regulatory assets, to reflect the updated amounts calculated by the power tax software. Since 2015, the NYPSC and MPUC accepted certain adjustments to deferred taxes and associate d regulatory assets for this item in recent distribution rate cases, resulting in a regulatory asset balance of approximately $166 million for this item at June 30, 2018 and December 31, 2017.
In 2017, audits of the power tax regulatory assets were commenced by the NYPSC and MPUC. On January 11, 2018, the NYPSC issued an order opening an operations audit on NYSEG and RG&E and certain other New York utilities regarding tax accounting. The audit report is expected to be completed during 2018. In January 2018, the MPUC published the power tax audit report with respect to CMP, which indicated that the auditor was unable to verify the “acquisition value” of the power tax regulatory assets. The audit report requires that CMP must provide support for the beginning balance of the regulatory assets or will be unable to recover the value of the assets, which is approximately $10 million. CMP expects to respond in the third quarter 2018, but we cannot predict the outcome of this proceeding.
Results of Operations
The following table sets forth financial information by segment for each of the periods indicated. Based on the quantitative assessment and due to the disposition of gas trading and storage businesses (see Note 20 – Assets Held For Sale for further discussion), the Gas business no longer meets the reportable segment criteria effective in the first quarter of 2018. As a result, the prior period segment information has been restated to conform to the 2018 presentation. Additionally, as a result of the adoption of the amendments to improve the presentation of net periodic pension cost and net periodic postretirement benefit cost, we have reclassified the non-service components of those costs from operations and maintenance to other expense within the condensed consolidated statements of income and applied these amendments retrospectively to prior periods. For further details, refer to Note 3 of our condensed consolidated financial statements for the three and six months ended June 30 , 2018.
|
|
Three Months Ended |
|
|
Three Months Ended |
|
||||||||||||||||||||||||||
|
|
June 30, 2018 |
|
|
June 30, 2017 |
|
||||||||||||||||||||||||||
|
|
Total |
|
|
Networks |
|
|
Renewables |
|
|
Other(1) |
|
|
Total |
|
|
Networks |
|
|
Renewables |
|
|
Other(1) |
|
||||||||
|
|
(in millions) |
|
|||||||||||||||||||||||||||||
Operating Revenues |
|
$ |
1,402 |
|
|
$ |
1,105 |
|
|
$ |
297 |
|
|
$ |
— |
|
|
$ |
1,331 |
|
|
$ |
1,067 |
|
|
$ |
265 |
|
|
$ |
(1 |
) |
Operating Expenses |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Purchased power, natural gas and fuel used |
|
|
279 |
|
|
|
229 |
|
|
|
50 |
|
|
|
— |
|
|
|
242 |
|
|
|
210 |
|
|
|
33 |
|
|
|
(1 |
) |
Loss from assets held for sale |
|
|
10 |
|
|
|
— |
|
|
|
— |
|
|
|
10 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Operations and maintenance |
|
|
533 |
|
|
|
438 |
|
|
|
91 |
|
|
|
4 |
|
|
|
493 |
|
|
|
392 |
|
|
|
88 |
|
|
|
13 |
|
Depreciation and amortization |
|
|
215 |
|
|
|
128 |
|
|
|
87 |
|
|
|
— |
|
|
|
206 |
|
|
|
120 |
|
|
|
80 |
|
|
|
6 |
|
Taxes other than income taxes |
|
|
143 |
|
|
|
127 |
|
|
|
14 |
|
|
|
2 |
|
|
|
138 |
|
|
|
120 |
|
|
|
14 |
|
|
|
4 |
|
Total Operating Expenses |
|
|
1,180 |
|
|
|
922 |
|
|
|
242 |
|
|
|
16 |
|
|
|
1,079 |
|
|
|
842 |
|
|
|
215 |
|
|
|
22 |
|
Operating income (loss) |
|
|
222 |
|
|
|
183 |
|
|
|
55 |
|
|
|
(16 |
) |
|
|
252 |
|
|
|
225 |
|
|
|
50 |
|
|
|
(23 |
) |
Other Income (Expense) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Other income (expense) |
|
|
(20 |
) |
|
|
(19 |
) |
|
|
— |
|
|
|
(1 |
) |
|
|
(21 |
) |
|
|
(18 |
) |
|
|
(3 |
) |
|
|
— |
|
Earnings (losses) from equity method investments |
|
|
5 |
|
|
|
4 |
|
|
|
1 |
|
|
|
— |
|
|
|
1 |
|
|
|
3 |
|
|
|
(2 |
) |
|
|
— |
|
Interest expense, net of capitalization |
|
|
(70 |
) |
|
|
(65 |
) |
|
|
(7 |
) |
|
|
2 |
|
|
|
(68 |
) |
|
|
(58 |
) |
|
|
(8 |
) |
|
|
(2 |
) |
Income (Loss) Before Income Tax |
|
|
137 |
|
|
|
103 |
|
|
|
49 |
|
|
|
(15 |
) |
|
|
164 |
|
|
|
152 |
|
|
|
37 |
|
|
|
(25 |
) |
Income tax expense (benefit) |
|
|
27 |
|
|
|
23 |
|
|
|
(24 |
) |
|
|
28 |
|
|
|
44 |
|
|
|
56 |
|
|
|
6 |
|
|
|
(18 |
) |
Net Income (Loss) |
|
|
110 |
|
|
|
80 |
|
|
|
73 |
|
|
|
(43 |
) |
|
|
120 |
|
|
|
96 |
|
|
|
31 |
|
|
|
(7 |
) |
Less: Net income attributable to noncontrolling interests |
|
|
3 |
|
|
|
1 |
|
|
|
2 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Net Income (Loss) Attributable to Avangrid, Inc. |
|
$ |
107 |
|
|
$ |
79 |
|
|
$ |
71 |
|
|
$ |
(43 |
) |
|
$ |
120 |
|
|
$ |
96 |
|
|
$ |
31 |
|
|
$ |
(7 |
) |
51
|
|
Six Months Ended |
|
|
Six Months Ended |
|
||||||||||||||||||||||||||
|
|
June 30, 2018 |
|
|
June 30, 2017 |
|
||||||||||||||||||||||||||
|
|
Total |
|
|
Networks |
|
|
Renewables |
|
|
Other(1) |
|
|
Total |
|
|
Networks |
|
|
Renewables |
|
|
Other(1) |
|
||||||||
|
|
(in millions) |
|
|||||||||||||||||||||||||||||
Operating Revenues |
|
$ |
3,267 |
|
|
$ |
2,657 |
|
|
$ |
581 |
|
|
$ |
29 |
|
|
$ |
3,089 |
|
|
$ |
2,526 |
|
|
$ |
552 |
|
|
$ |
11 |
|
Operating Expenses |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Purchased power, natural gas and fuel used |
|
|
855 |
|
|
|
747 |
|
|
|
106 |
|
|
|
2 |
|
|
|
707 |
|
|
|
628 |
|
|
|
91 |
|
|
|
(12 |
) |
Loss from assets held for sale |
|
|
15 |
|
|
|
— |
|
|
|
— |
|
|
|
15 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Operations and maintenance |
|
|
1,060 |
|
|
|
874 |
|
|
|
177 |
|
|
|
9 |
|
|
|
1,015 |
|
|
|
825 |
|
|
|
170 |
|
|
|
20 |
|
Depreciation and amortization |
|
|
418 |
|
|
|
246 |
|
|
|
172 |
|
|
|
— |
|
|
|
403 |
|
|
|
233 |
|
|
|
158 |
|
|
|
12 |
|
Taxes other than income taxes |
|
|
294 |
|
|
|
263 |
|
|
|
27 |
|
|
|
4 |
|
|
|
285 |
|
|
|
250 |
|
|
|
27 |
|
|
|
8 |
|
Total Operating Expenses |
|
|
2,642 |
|
|
|
2,130 |
|
|
|
482 |
|
|
|
30 |
|
|
|
2,410 |
|
|
|
1,936 |
|
|
|
446 |
|
|
|
28 |
|
Operating income (loss) |
|
|
625 |
|
|
|
527 |
|
|
|
99 |
|
|
|
(1 |
) |
|
|
679 |
|
|
|
590 |
|
|
|
106 |
|
|
|
(17 |
) |
Other Income (Expense) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Other income (expense) |
|
|
(41 |
) |
|
|
(41 |
) |
|
|
— |
|
|
|
— |
|
|
|
(37 |
) |
|
|
(36 |
) |
|
|
(1 |
) |
|
|
— |
|
Earnings (losses) from equity method investments |
|
|
7 |
|
|
|
6 |
|
|
|
1 |
|
|
|
— |
|
|
|
3 |
|
|
|
7 |
|
|
|
(4 |
) |
|
|
— |
|
Interest expense, net of capitalization |
|
|
(144 |
) |
|
|
(125 |
) |
|
|
(15 |
) |
|
|
(4 |
) |
|
|
(139 |
) |
|
|
(121 |
) |
|
|
(16 |
) |
|
|
(2 |
) |
Income (Loss) Before Income Tax |
|
|
447 |
|
|
|
367 |
|
|
|
85 |
|
|
|
(5 |
) |
|
|
506 |
|
|
|
440 |
|
|
|
85 |
|
|
|
(19 |
) |
Income tax expense (benefit) |
|
|
99 |
|
|
|
87 |
|
|
|
(32 |
) |
|
|
44 |
|
|
|
147 |
|
|
|
172 |
|
|
|
(15 |
) |
|
|
(10 |
) |
Net Income (Loss) |
|
|
348 |
|
|
|
280 |
|
|
|
117 |
|
|
|
(49 |
) |
|
|
359 |
|
|
|
268 |
|
|
|
100 |
|
|
|
(9 |
) |
Less: Net income (loss) attributable to noncontrolling interests |
|
|
(3 |
) |
|
|
1 |
|
|
|
(4 |
) |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Net Income (Loss) Attributable to Avangrid, Inc. |
|
$ |
351 |
|
|
$ |
279 |
|
|
$ |
121 |
|
|
$ |
(49 |
) |
|
$ |
359 |
|
|
$ |
268 |
|
|
$ |
100 |
|
|
$ |
(9 |
) |
(1) Other amounts represent Corporate, Gas and intersegment eliminations.
Comparison of Period to Period Results of Operations
Three Months Ended June 30, 2018 Compared to Three Months Ended June 30, 2017
Operating Revenues
Our operating revenues increased by $71 million, or 5%, from $1.3 billion for the three months ended June 30, 2017 to $1.4 billion for the three months ended June 30, 2018, as detailed by segment below:
Networks
Operating revenues increased by $38 million, or 4%, from $1,067 million for the three months ended June 30, 2017 to $1,105 million for the three months ended June 30, 2018. Electricity revenues increased by $40 million and gas revenues decreased by $4 million, primarily due to the impact, respectively, of higher and lower average rates in the three months period ended June 30, 2018 compared to the same period of 2017. Electricity and gas revenues for the same period increased by $5 million and $25 million, respectively, due to higher volumes largely driven by increase in heating degree days from colder weather. W holesale electricity revenues increased by $4 million for the three months ended June 30, 2018 compared to the same period of 2017 due to an increase in average prices. Revenue related regulatory activities in the period decreased by $32 million primarily due to decreases in the revenue decoupling mechanism of $4 million, energy supply reconciliation of $26 million, a decrease of $22 million from deferrals of excess deferred income taxes due to the changes in federal tax rates as a result of the Tax Act, primarily offset within income tax expense, offset by an increase in recoveries on the Ginna RSSA of $20 million due to the termination of the contract in 2017.
Renewables
Operating revenues increased by $32 million, or 12%, from $265 million for the three months ended June 30, 2017 to $297 million for the three months ended June 30, 2018. The increase in operating revenues was primarily due to an increase of $21 million from wind capacity with output increasing 456 GWh, an increase in thermal revenue of $1 million driven by colder weather, income of $7 million from cash collateral released in excess of outstanding receivables from a bankruptcy proceeding with a customer regarding two power purchase agreements and favorable marked to market, or MtM, changes of $9 million on energy derivative
52
transactions entered into for economic hedging purposes, which was offset by a decrease of $6 million from energy sales in organized markets .
Purchased Power, Natural Gas and Fuel Used
Our purchased power, natural gas and fuel used increased by $37 million, or 15%, from $242 million for the three months ended June 30, 2017 to $279 million for the three months ended June 30, 2018, as detailed by segment below:
Networks
Purchased power, natural gas and fuel used increased by $19 million, or 9%, from $210 million for the three months ended June 30, 2017 to $229 million for the three months ended June 30, 2018. The increase is primarily driven by $8 million and $7 million increases in average prices and overall units of electricity and gas, respectively, procured due to an increase in heating degree days from colder weather combined with a $3 million increase in other power supply purchases.
Renewables
Purchased power, natural gas and fuel used increased by $17 million, or 52%, from $33 million for the three months ended June 30, 2017 to $50 million for the three months ended June 30, 2018. The increase is primarily driven by an increase of $18 million in power purchases and transmission costs mainly due to the addition of new capacity, and unfavorable MtM changes on derivatives of $2 million due to market price changes in the current period, offset by a decrease of $4 million from energy purchases in organized markets .
Operations and Maintenance
Our operations and maintenance increased by $40 million, or 8%, from $493 million for the three months ended June 30, 2017 to $533 million for the three months ended June 30, 2018 , as detailed by segment below:
Networks
Operations and maintenance increased by $46 million, or 12% from $392 million for the three months ended June 30, 2017 to $438 million for the three months ended June 30, 2018. The increase is primarily due to a $15 million increase driven mainly by higher non-deferrable storm costs, a $4 million increase in uncollectible expenses, lower capitalized labor costs of $8 million, insurance reimbursements of $6 million in the prior period, and $12 million in recoveries on the Ginna RSSA, which decreased operations and maintenance expense in the three months ended June 30, 2017, as the contract was terminated in 2017.
Renewables
Operations and maintenance expenses increased by $3 million, or 3%, from $88 million for the three months ended June 30, 2017 to $91 million for the three months ended June 30, 2018. The increase is primarily due to increased costs resulting from increased capacity, with higher salary costs of $2 million related to headcount increases and higher maintenance costs of $1 million in the three month period ended June 30, 2018 compared with the same period of 2017.
Depreciation and Amortization and Loss From Assets Held for Sale
Depreciation and amortization and loss from assets held for sale for the three months ended June 30, 2018 was $225 million compared to $206 million for the three months ended June 30, 2017, representing an increase of $19 million. The increase is primarily due to a loss of $10 million from remeasurement of assets held for sale driven by final purchase price negotiations and working capital adjustments, an increase of $6 million and $8 million in depreciation expense as a result of plant additions in Networks and new capacity in Renewables, respectively, in the period, offset by $5 million lower depreciation expense in Other driven by the cessation of depreciation for assets held for sale.
Other Income (Expense) and Earnings (Losses) from Equity Method Investments
Other income (expense) and equity earnings (losses) decreased by $5 million from $(20) million for the three months ended June 30, 2017 to $(15) million for the three months ended June 30, 2018, primarily due to a $5 million write-off of certain development projects within Renewables in the three months ended June 30, 2017, an increase of $4 million in equity earnings offset by $4 million higher non-service component of pension and other post-retirement cost in the current period .
53
Interest Expense, Net of Capitalization
Interest expense for the three months ended June 30, 2018 and 2017 was $70 million and $68 million, respectively. Networks and Other added $3 million and $5 million of interest expense, respectively, from new debt issued in 2017. In addition, Networks had $2 million of higher interest expense on regulatory deferrals in the current period. This is offset by $8 million lower interest expense in Other driven by sale of gas business in 2018.
Income Tax Expense
The effective tax rate, inclusive of federal and state income tax, for the three months ended June 30 , 2018 was 19.7%, which is lower than the 21% statutory federal income tax rate applicable in 2018, predominantly due to discrete tax adjustments recorded during the period offset by the recognition of production tax credits associated with wind production. The effective tax rate, inclusive of federal and state income tax, for the three months ended June 30, 2017 was 26.8%, which is lower than the 35% statutory federal income tax rate applicable in 2017 predominately due to the recognition of production tax credits associated with wind production.
Six Months Ended June 30, 2018 Compared to Six Months Ended June 30, 2017
Operating Revenues
Our operating revenues increased by $178 million, or 6%, from $3.1 billion for the six months ended June 30, 2017 to $3.3 billion for the six months ended June 30, 2018, as detailed by segment below:
Networks
Operating revenues increased by $131 million, or 5%, from $2,526 million for the six months ended June 30, 2017 to $2,657 million for the six months ended June 30, 2018. Electricity and gas revenues increased by $56 million and $3 million, respectively, primarily due to the impact of higher average rates in the six months ended June 30, 2018 compared to the same period in 2017. Electricity and gas revenues for the same period increased by $34 million and $68 million due to higher volumes largely driven by the increase in heating degree days from colder weather. W holesale electricity revenues increased by $13 million for the six months ended June 30, 2018 compared to the same period of 2017 due to an increase in average prices. In the six months ended June 30, 2018, Networks also had a n increase of $13 million from other revenues including mainly revenue generated from the Puerto Rico mutual aid, with offsetting associated costs included in operations and maintenance. Revenue related regulatory activities in the period decreased by $55 million primarily due to an adjustment of $14 million to unfunded future income tax to reflect the change from a flow through to normalization method, which was recorded in the six months ended June 30, 2017 as an increase to revenue, with an offsetting and equal increase to income tax expense, decreases in recoveries on the Ginna RSSA of $10 million, revenue decoupling mechanism of $9 million, a decrease of $68 million from deferrals of excess deferred income taxes due to changes in federal tax rates as a result of the Tax Act, primarily offset within income tax expense, offset by increases in energy supply reconciliation of $9 million, stranded cost of $31 million and an increase of $6 million in other regulatory adjustments.
Renewables
Operating revenues increased by $29 million, or 5%, from $552 million for the six months ended June 30, 2017 to $581 million for the six months ended June 30, 2018. The increase in operating revenues was primarily due to an increase of $62 million from wind capacity with output increasing 1,129 GWh, an increase in thermal revenue of $6 million driven by colder weather and income of $7 million from cash collateral released in excess of outstanding receivables from a bankruptcy proceeding with a customer regarding two power purchase agreements, offset by a decrease of $13 million in average prices due to the production mix and the expiration of PTCs in the period, unfavorable MtM changes of $25 million on energy derivative transactions entered into for economic hedging purposes and a decrease of $8 million from energy sales in organized markets .
Purchased Power, Natural Gas and Fuel Used
Our purchased power, natural gas and fuel used increased by $148 million, or 21%, from $707 million for the six months ended June 30, 2017 to $855 million for the six months ended June 30, 2018, as detailed by segment below:
Networks
Purchased power, natural gas and fuel used increased by $119 million, or 19%, from $628 million for the six months ended June 30, 2017 to $747 million for the six months ended June 30, 2018. The increase is primarily driven by $79 million and $35 million increases in average prices and overall units of electricity and gas, respectively, procured due to an increase in heating degree days from colder weather combined with a $5 million increase in other power supply purchases.
54
Purchased power, natural gas and fuel used increased by $15 million, or 16%, from $91 million for the six months ended June 30, 2017 to $106 million for the six months ended June 30, 2018. The increase is primarily driven by an increase of $13 million in power purchases and $19 million of transmission costs due to the addition of new capacity, an increase of $6 million in renewable energy credits, or RECs, and thermal purchases, offset by MtM changes on derivatives of $17 million that were favorable due to market price changes in the current period and a decrease of $6 million from energy purchases in organized markets .
Operations and Maintenance
Our operations and maintenance increased by $45 million, or 4%, from $1,015 million for the six months ended June 30, 2017 to $1,060 million for the six months ended June 30, 2018 , as detailed by segment below:
Networks
Operations and maintenance increased by $49 million, or 6% from $825 million for the six months ended June 30, 2017 to $874 million for the six months ended June 30, 2018. The increase is primarily due to a $26 million increase mainly driven by non-deferrable storm costs, a $10 million increase in uncollectible expenses, $9 million in purchases of renewable and zero-emission energy certificates related to a new program to adopt clean energy standards, lower capitalized labor costs of $14 million, insurance reimbursements of $12 million in the prior period, offset by a decrease of $22 million in expenses from the Ginna RSSA driven by the termination of the contract in 2017.
Renewables
Operations and maintenance expenses increased by $7 million, or 4%, from $170 million for the six months ended June 30, 2017 to $177 million for the six months ended June 30, 2018. The increase is primarily due to increased costs resulting from increased capacity, with higher salary costs of $3 million related to headcount increases, and $5 million higher maintenance costs and corporate charges in the six months ended June 30, 2018 compared with the same period of 2017, offset by a decrease of $1 million from favorable changes in rents.
Depreciation and Amortization and Loss From Assets Held for Sale
Depreciation and amortization and loss from assets held for sale for the six months ended June 30, 2018 was $433 million compared to $403 million for the six months ended June 30, 2017, an increase of $30 million. The increase is primarily due to a loss of $15 million from remeasurement of assets held for sale driven by final purchase price negotiations and working capital adjustments, an increase of $12 million and $15 million in depreciation expense as a result of plant additions in Networks and new capacity in Renewables, respectively, in the period, offset by $12 million lower depreciation expense in Other driven by the cessation of depreciation for assets held for sale.
Other Income (Expense) and Earnings (Losses) from Equity Method Investments
Other income (expense) and equity earnings (losses) were $(34) million for both the six months ended June 30, 2018 and 2017. The non-service component of pension and other post-retirement cost increased by $6 million, offset by an increase in equity earnings of $4 million, and a $3 million decrease in Renewables mainly driven by a write-off of certain development projects in the three months ended June 30, 2017.
Interest Expense, Net of Capitalization
Interest expense for the six months ended June 30, 2018 and 2017 was $144 million and $139 million, respectively.
Networks and Other added $7 million and $10 million of interest expense from new debt issued in 2017. In addition, Networks had $3 million of higher interest expense on regulatory deferrals in the current period. This is offset
by $15 million lower interest expense in Other driven by the sale of the gas business in 2018.
Income Tax Expense
The effective tax rate, inclusive of federal and state income tax, for the six months ended June 30 , 2018 was 22.1%, which is higher than the 21% statutory federal income tax rate applicable in 2018, predominantly due to $21.6 million of tax expense recorded in connection with the disposal of the Gas business and discrete adjustments recorded during the period, offset by the recognition of production tax credits associated with wind production. The effective tax rate, inclusive of federal and state income tax, for the six months ended June 30, 2017 was 29.1%, which is lower than the 35% statutory federal income tax rate applicable in 2017 predominately due to the recognition of production tax credits associated with wind production. Additionally, $14 million in income tax expense for the six months ended June 30, 2017, is due to unfunded future income tax to reflect the change from a flow through to normalization method, which was recorded as an increase to revenue, with an offsetting and equal increase to income tax expense. This was partially offset by other discrete tax adjustments during the period.
55
To supplement our consolidated financial statements presented in accordance with U.S. GAAP, we consider certain non-GAAP financial measures that are not prepared in accordance with U.S. GAAP, including adjusted gross margin, adjusted EBITDA, adjusted net income and adjusted earnings per share, or adjusted EPS. The non-GAAP financial measures we use are specific to AVANGRID and the non-GAAP financial measures of other companies may not be calculated in the same manner. We use these non-GAAP financial measures, in addition to U.S. GAAP measures, to establish operating budgets and operational goals to manage and monitor our business, evaluate our operating and financial performance and to compare such performance to prior periods and to the performance of our competitors. We believe that presenting such non-GAAP financial measures is useful because such measures can be used to analyze and compare profitability between companies and industries because it eliminates the impact of financing and certain non-cash charges. In addition, we present non-GAAP financial measures because we believe that they and other similar measures are widely used by certain investors, securities analysts and other interested parties as supplemental measures of performance.
We define adjusted net income as net income adjusted to exclude restructuring charges, mark-to-market adjustments to reflect the effect of mark-to-market changes in the fair value of derivative instruments used by AVANGRID to economically hedge market price fluctuations in related underlying physical transactions for the purchase and sale of electricity, loss from held for sale measurement, income from release of collateral, impact of the Tax Act and adjustments for the non-core Gas storage business. We believe adjusted net income is more useful in understanding and evaluating actual and projected financial performance and contribution of AVANGRID core lines of business and to more fully compare and explain our results. Additionally, we evaluate the nature of our revenues and expenses and adjust to reflect classification by nature for evaluation of our non-GAAP financial measures as opposed to by function. The most directly comparable U.S. GAAP measure to adjusted EBITDA and adjusted net income is net income. We define adjusted EBITDA as net income attributable to AVANGRID, adding back net income attributable to noncontrolling interests , income tax expense, depreciation, amortization, impairment and interest expense, net of capitalization, and then subtracting other income and earnings from equity method investments. We also define adjusted gross margin as adjusted EBITDA adding back operations and maintenance and taxes other than income taxes. We also define adjusted earnings per share, or adjusted EPS, as adjusted net income converted to an earnings per share amount.
The use of non-GAAP financial measures is not intended to be considered in isolation or as a substitute for, or superior to, AVANGRID’s U.S. GAAP financial information, and investors are cautioned that the non-GAAP financial measures are limited in their usefulness, may be unique to AVANGRID, and should be considered only as a supplement to AVANGRID’s U.S. GAAP financial measures. The non-GAAP financial measures may not be comparable to other similarly titled measures of other companies and have limitations as analytical tools.
Non-GAAP financial measures are not primary measurements of our performance under U.S. GAAP and should not be considered as alternatives to operating income, net income or any other performance measures determined in accordance with U.S. GAAP.
The following tables provide a reconciliation between Net Income attributable to AVANGRID and adjusted net income (non-GAAP), adjusted gross margin (non-GAAP) and adjusted EBITDA (non-GAAP) by segment for the three and six months ended June 30, 2018 and 2017, respectively:
56
|
Three Months Ended June 30, 2018 |
|
|
Six Months Ended June 30, 2018 |
|
|||||||||||||||||||||||||||||||||||
|
|
Total |
|
|
Networks |
|
|
Renewables |
|
|
Corporate* |
|
|
Gas Storage |
|
|
Total |
|
|
Networks |
|
|
Renewables |
|
|
Corporate* |
|
|
Gas Storage |
|
||||||||||
|
|
(in millions) |
|
|
(in millions) |
|
||||||||||||||||||||||||||||||||||
Net Income Attributable to Avangrid, Inc. |
|
$ |
107 |
|
|
$ |
79 |
|
|
$ |
71 |
|
|
$ |
(25 |
) |
|
$ |
(18 |
) |
|
$ |
351 |
|
|
$ |
279 |
|
|
$ |
121 |
|
|
$ |
(30 |
) |
|
$ |
(19 |
) |
Adjustments: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Mark-to-market adjustments - Renewables |
|
|
3 |
|
|
|
— |
|
|
|
3 |
|
|
|
— |
|
|
|
— |
|
|
|
(1 |
) |
|
|
— |
|
|
|
(1 |
) |
|
|
— |
|
|
|
— |
|
Restructuring charges |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
1 |
|
|
|
1 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Loss from held for sale measurement |
|
|
10 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
10 |
|
|
|
15 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
15 |
|
Income from release of collateral - Renewables |
|
|
(7 |
) |
|
|
— |
|
|
|
(7 |
) |
|
|
— |
|
|
|
— |
|
|
|
(7 |
) |
|
|
— |
|
|
|
(7 |
) |
|
|
— |
|
|
|
— |
|
Impact of the Tax Act |
|
|
7 |
|
|
|
— |
|
|
|
— |
|
|
|
7 |
|
|
|
— |
|
|
|
7 |
|
|
|
— |
|
|
|
— |
|
|
|
7 |
|
|
|
— |
|
Income tax impact of adjustments (1) |
|
|
7 |
|
|
|
— |
|
|
|
1 |
|
|
|
— |
|
|
|
6 |
|
|
|
17 |
|
|
|
— |
|
|
|
2 |
|
|
|
— |
|
|
|
15 |
|
Gas Storage, net of tax |
|
|
2 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
2 |
|
|
|
(11 |
) |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
(11 |
) |
Adjusted Net Income (6) |
|
$ |
128 |
|
|
$ |
79 |
|
|
$ |
68 |
|
|
$ |
(18 |
) |
|
$ |
— |
|
|
$ |
371 |
|
|
$ |
280 |
|
|
$ |
115 |
|
|
$ |
(23 |
) |
|
$ |
— |
|
Add: Net loss attributable to noncontrolling interests |
|
|
3 |
|
|
|
1 |
|
|
|
2 |
|
|
|
— |
|
|
|
— |
|
|
|
(3 |
) |
|
|
1 |
|
|
|
(4 |
) |
|
|
— |
|
|
|
— |
|
Income tax expense (2) |
|
|
37 |
|
|
|
25 |
|
|
|
(4 |
) |
|
|
16 |
|
|
|
— |
|
|
|
117 |
|
|
|
88 |
|
|
|
14 |
|
|
|
15 |
|
|
|
— |
|
Depreciation and amortization (3) |
|
|
274 |
|
|
|
162 |
|
|
|
112 |
|
|
|
— |
|
|
|
— |
|
|
|
529 |
|
|
|
309 |
|
|
|
220 |
|
|
|
— |
|
|
|
— |
|
Interest expense, net of capitalization (4) |
|
|
40 |
|
|
|
24 |
|
|
|
15 |
|
|
|
1 |
|
|
|
— |
|
|
|
78 |
|
|
|
48 |
|
|
|
24 |
|
|
|
6 |
|
|
|
— |
|
Less: Other income and (expense) |
|
|
1 |
|
|
|
1 |
|
|
|
— |
|
|
|
— |
|
|
|
|
|
|
|
1 |
|
|
|
1 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Earnings (losses) from equity method investments |
|
|
5 |
|
|
|
4 |
|
|
|
1 |
|
|
|
— |
|
|
|
— |
|
|
|
7 |
|
|
|
6 |
|
|
|
1 |
|
|
|
— |
|
|
|
— |
|
Adjusted EBITDA (6) |
|
$ |
477 |
|
|
$ |
286 |
|
|
$ |
191 |
|
|
$ |
(1 |
) |
|
$ |
— |
|
|
$ |
1,085 |
|
|
$ |
719 |
|
|
$ |
367 |
|
|
$ |
(2 |
) |
|
$ |
— |
|
Add: Operations and maintenance (5) |
|
|
457 |
|
|
|
387 |
|
|
|
69 |
|
|
|
1 |
|
|
|
— |
|
|
|
837 |
|
|
|
703 |
|
|
|
132 |
|
|
|
2 |
|
|
|
— |
|
Taxes other than income taxes |
|
|
132 |
|
|
|
119 |
|
|
|
13 |
|
|
|
— |
|
|
|
— |
|
|
|
273 |
|
|
|
250 |
|
|
|
23 |
|
|
|
— |
|
|
|
— |
|
Adjusted gross margin (6) |
|
$ |
1,066 |
|
|
$ |
792 |
|
|
$ |
273 |
|
|
$ |
— |
|
|
$ |
— |
|
|
$ |
2,195 |
|
|
$ |
1,672 |
|
|
$ |
522 |
|
|
$ |
— |
|
|
$ |
— |
|
|
|
Three Months Ended June 30, 2017 |
|
|
Six Months Ended June 30, 2017 |
|
||||||||||||||||||||||||||||||||||
|
|
Total |
|
|
Networks |
|
|
Renewables |
|
|
Corporate* |
|
|
Gas Storage |
|
|
Total |
|
|
Networks |
|
|
Renewables |
|
|
Corporate* |
|
|
Gas Storage |
|
||||||||||
|
|
(in millions) |
|
|
(in millions) |
|
||||||||||||||||||||||||||||||||||
Net Income Attributable to Avangrid, Inc. |
|
$ |
120 |
|
|
$ |
96 |
|
|
$ |
31 |
|
|
$ |
10 |
|
|
$ |
(16 |
) |
|
$ |
359 |
|
|
$ |
268 |
|
|
$ |
100 |
|
|
$ |
5 |
|
|
$ |
(14 |
) |
Adjustments: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Mark-to-market adjustments - Renewables |
|
|
11 |
|
|
|
— |
|
|
|
11 |
|
|
|
— |
|
|
|
— |
|
|
|
(6 |
) |
|
|
— |
|
|
|
(6 |
) |
|
|
— |
|
|
|
— |
|
Income tax impact of adjustments (1) |
|
|
(4 |
) |
|
|
— |
|
|
|
(4 |
) |
|
|
— |
|
|
|
— |
|
|
|
2 |
|
|
|
— |
|
|
|
2 |
|
|
|
— |
|
|
|
— |
|
Gas Storage, net of tax |
|
|
16 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
16 |
|
|
|
14 |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
14 |
|
Adjusted Net Income (6) |
|
$ |
143 |
|
|
$ |
96 |
|
|
$ |
38 |
|
|
$ |
10 |
|
|
$ |
— |
|
|
$ |
369 |
|
|
$ |
268 |
|
|
$ |
97 |
|
|
$ |
5 |
|
|
$ |
— |
|
Add: Income tax expense (2) |
|
|
71 |
|
|
|
56 |
|
|
|
24 |
|
|
|
(9 |
) |
|
|
— |
|
|
|
167 |
|
|
|
158 |
|
|
|
9 |
|
|
|
— |
|
|
|
— |
|
Depreciation and amortization (3) |
|
|
253 |
|
|
|
144 |
|
|
|
108 |
|
|
|
— |
|
|
|
— |
|
|
|
493 |
|
|
|
284 |
|
|
|
209 |
|
|
|
— |
|
|
|
— |
|
Interest expense, net of capitalization (4) |
|
|
28 |
|
|
|
25 |
|
|
|
8 |
|
|
|
(5 |
) |
|
|
— |
|
|
|
64 |
|
|
|
58 |
|
|
|
15 |
|
|
|
(9 |
) |
|
|
— |
|
Less: Earnings (losses) from equity method investments |
|
|
— |
|
|
|
4 |
|
|
|
(3 |
) |
|
|
— |
|
|
|
— |
|
|
|
1 |
|
|
|
7 |
|
|
|
(6 |
) |
|
|
— |
|
|
|
— |
|
Adjusted EBITDA (6) |
|
$ |
495 |
|
|
$ |
318 |
|
|
$ |
182 |
|
|
$ |
(4 |
) |
|
$ |
— |
|
|
$ |
1,093 |
|
|
$ |
761 |
|
|
$ |
336 |
|
|
$ |
(4 |
) |
|
$ |
— |
|
Add: Operations and maintenance (5) |
|
|
352 |
|
|
|
283 |
|
|
|
66 |
|
|
|
4 |
|
|
|
— |
|
|
|
735 |
|
|
|
609 |
|
|
|
124 |
|
|
|
2 |
|
|
|
— |
|
Taxes other than income taxes |
|
|
127 |
|
|
|
114 |
|
|
|
11 |
|
|
|
1 |
|
|
|
— |
|
|
|
264 |
|
|
|
239 |
|
|
|
22 |
|
|
|
3 |
|
|
|
— |
|
Adjusted gross margin (6) |
|
$ |
974 |
|
|
$ |
715 |
|
|
$ |
259 |
|
|
$ |
1 |
|
|
$ |
— |
|
|
$ |
2,092 |
|
|
$ |
1,609 |
|
|
$ |
483 |
|
|
$ |
1 |
|
|
$ |
— |
|
|
(1) |
Income tax impact of adjustments: 2018 - $(0.7) million and $0.3 million from MtM adjustment, $1.9 million and $1.9 million from release of collateral, $0 and $(0.3) million from restructuring charges, $6 million and $15 million from loss from held for sale measurement for the three and six months ended June 30, 2018, respectively; 2017 - $(4) million and $2 million from MtM adjustment for the three and six months ended June 30, 2017, respectively. |
|
|
(2) |
2018: Adjustments have been made for production tax credit adjustments for the amount of $20 million and $48 million for the three and six months ended June 30, 2018, respectively, as they have been included in operating revenues in Renewables. After reflecting these by nature classification adjustments the calculated effective income tax rates are impacted for both periods presented under this by nature classification presentation. |
|
2017: Adjustments have been made for production tax credit adjustments for the amount of $14 million and $26 million for three and six months ended June 30, 2017, respectively, as they have been included in operating revenues in Renewables, and $14 million of unfunded future income taxes in Networks have been reclassified from revenues to reflect classification by nature in the six month period ended June 30, 2017, as discussed above.
|
(3) |
2018: Adjustments have been made for the inclusion of vehicle depreciation and bad debt provision within depreciation and amortization from operations and maintenance based on the by nature classification. Vehicle depreciation was $5 million and $9 million and bad debt provision was $21 million and $38 million in Networks, for the three and six months ended June 30, 2018, respectively. Additionally, government grants and investment tax credits amortization have been presented within other operating income and not within depreciation and amortization based on the by nature classification as follows: government grants of $1.0 million and $2.0 million in Networks and investment tax credits of $22 million and $44 million in Renewables, for the three and six month periods ended June 30, 2018, respectively. |
|
2017: Adjustments have been made for the inclusion of vehicle depreciation and bad debt provision within depreciation and amortization from operations and maintenance based on the by nature classification. Vehicle depreciation was $4 million and $9 million and bad debt provision was $15 million and $27 million in Networks, for the three and six months ended June 30, 2017, respectively. Additionally, government grants and investment tax credits amortization have been presented within other operating income and not within depreciation and amortization based on the
57
by nature classification as follows: government grants of $1.6 million and $3.2 million in Networks and investment tax credits of $23 million and $45 million in Renewables, for the thr ee and six month periods ended June 30, 2017, respectively.
|
(4) |
Adjustments have been made for allowance for funds used during construction, debt portion, to reflect these amounts within other income and expenses in Networks for the periods presented. |
|
|
(5) |
Adjustments have been made for regulatory amounts to reflect amounts in revenues based on the by nature classification of these items for the periods presented. In addition, the vehicle depreciation and bad debt provision have been reflected within depreciation and amortization in Networks for the periods presented. |
|
|
(6) |
Adjusted Net Income, adjusted EBITDA and adjusted gross margin are non-GAAP financial measures and are presented after adjustments to reflect the classification of revenues and expenses by nature and after excluding restructuring charges, loss from held for sale measurement, income from release of collateral, impact of the Tax Act, the impact from mark-to-market activities in Renewables and Gas storage business explained in notes (1)-(5) above. |
|
* Includes corporate and other non-regulated entities as well as intersegment eliminations.
Three Months Ended June 30, 2018 Compared to Three Months Ended June 30, 2017
Our adjusted gross margin increased by $92 million, or 9%, from $974 million for the three months ended June 30, 2017 to $1,066 million for the three months ended June 30, 2018.
Our adjusted EBITDA decreased by $18 million, or 4%, from $495 million for the three months ended June 30, 2017 to $477 million for the three months ended June 30, 2018.
Details of the period to period comparison are described below at the segment level.
Networks
Adjusted gross margin increased by $77 million, or 11%, from $715 million for the three months ended June 30, 2017 to $792 million for the three months ended June 30, 2018. The increase is primarily driven by higher average rates and an increase in heating degree days from colder weather in the period along with the adverse impact of the Tax Act on regulated revenue with an offsetting decrease to income tax expense.
Adjusted EBITDA decreased by $32 million, or 10%, from $318 million for the three months ended June 30, 2017 to $286 million for the three months ended June 30, 2018. The decrease is primarily driven by higher non-deferrable storm costs in the period along with the adverse impact of the Tax Act on regulated revenue with an offsetting decrease to income tax expense.
Renewables
Adjusted gross margin increased by $14 million, or 6%, from $259 million for the three months ended June 30, 2017 to $273 million for the three months ended June 30, 2018. The increase was primarily due to increased capacity and higher PTCs in the period.
Adjusted EBITDA increased by $9 million, or 5%, from $182 million for the three months ended June 30, 2017 to $191 million for the three months ended June 30, 2018. The increase was due to the same reasons noted above in the discussion of adjusted gross margin.
Adjusted net income
Our adjusted net income decreased by $15 million, or 10%, from $143 million for the three months ended June 30, 2017 to $128 million for the three months ended June 30, 2018. The decrease is primarily due to $17 million decrease in Networks driven by higher non-deferrable storm costs in the period, $28 million decrease in Corporate mainly driven by lower interest income on intercompany loans due to the sale of the gas business in 2018 and higher income tax expense from effective tax rate adjustment, offset by $30 million increase in Renewables due to increased capacity and higher PTCs in the period.
Six Months Ended June 30, 2018 Compared to Six Months Ended June 30, 2017
Our adjusted gross margin increased by $103 million, or 5%, from $2,092 million for the six months ended June 30, 2017 to $2,195 million for the six months ended June 30, 2018.
Our adjusted EBITDA decreased by $8 million, or 1%, from $1,093 million for the six months ended June 30, 2017 to $1,085 million for the six months ended June 30, 2018.
58
Details of the period to period comparison are described below at the segment level.
Networks
Adjusted gross margin increased by $63 million, or 4%, from $1,609 million for the six months ended June 30, 2017 to $1,672 million for the six months ended June 30, 2018. The increase is primarily driven by higher average rates and an increase in heating degree days from colder weather along with the adverse impact of the Tax Act on regulated revenue with an offsetting decrease to income tax expense.
Adjusted EBITDA decreased by $42 million, or 6%, from $761 million for the six months ended June 30, 2017 to $719 million for the six months ended June 30, 2018. The decrease is primarily driven by higher non-deferrable storm costs in the period along with the adverse impact of the Tax Act on regulated revenue with an offsetting decrease to income tax expense.
Renewables
Adjusted gross margin increased by $39 million, or 8%, from $483 million for the six months ended June 30, 2017 to $522 million for the six months ended June 30, 2018. The increase was primarily due to increased capacity and higher PTCs in the period.
Adjusted EBITDA increased by $31 million, or 9%, from $336 million for the six months ended June 30, 2017 to $367 million for the six months ended June 30, 2018. The increase was due to the same reasons noted above in the discussion of adjusted gross margin.
Adjusted net income
Our adjusted net income increased by $2 million, or 1%, from $369 million for the six months ended June 30, 2017 to $371 million for the six months ended June 30, 2018. The increase is primarily due to $12 million increase in Networks driven by higher average rates and an increase in heating degree days from colder weather, $18 million increase in Renewables due to increased capacity and higher PTCs in the period, offset by $28 million decrease in Corporate mainly driven by lower interest income on intercompany loans due to the sale of the gas business in 2018 and higher income tax expense from effective tax rate adjustment.
The following tables reconcile Net Income attributable to AVANGRID to Adjusted Net Income (non-GAAP), and EPS attributable to AVANGRID to adjusted EPS (non-GAAP) for the three and six months ended June 30, 2018 and 2017, respectively:
|
|
Three Months Ended |
|
|
Six Months Ended |
|
||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
(in millions) |
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
Networks |
|
$ |
79 |
|
|
$ |
96 |
|
|
$ |
279 |
|
|
$ |
268 |
|
Renewables |
|
|
71 |
|
|
|
31 |
|
|
|
121 |
|
|
|
100 |
|
Corporate (1) |
|
|
(25 |
) |
|
|
10 |
|
|
|
(30 |
) |
|
|
5 |
|
Gas Storage |
|
|
(18 |
) |
|
|
(16 |
) |
|
|
(19 |
) |
|
|
(14 |
) |
Net Income |
|
$ |
107 |
|
|
$ |
120 |
|
|
$ |
351 |
|
|
$ |
359 |
|
Adjustments: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Restructuring charges (2) |
|
|
— |
|
|
|
— |
|
|
|
1 |
|
|
|
— |
|
Mark-to-market adjustments - Renewables (3) |
|
|
3 |
|
|
|
11 |
|
|
|
(1 |
) |
|
|
(6 |
) |
Loss from held for sale measurement (4) |
|
|
10 |
|
|
|
— |
|
|
|
15 |
|
|
|
— |
|
Income from release of collateral - Renewables (5) |
|
|
(7 |
) |
|
|
— |
|
|
|
(7 |
) |
|
|
— |
|
Impact of the Tax Act (6) |
|
|
7 |
|
|
|
— |
|
|
|
7 |
|
|
|
— |
|
Income tax impact of adjustments |
|
|
7 |
|
|
|
(4 |
) |
|
|
17 |
|
|
|
2 |
|
Gas Storage, net of tax |
|
|
2 |
|
|
|
16 |
|
|
|
(11 |
) |
|
|
14 |
|
Adjusted Net Income (7) |
|
$ |
128 |
|
|
$ |
143 |
|
|
$ |
371 |
|
|
$ |
369 |
|
59
|
Three Months Ended |
|
|
Six Months Ended |
|
|||||||||||
|
|
June 30, |
|
|
June 30, |
|
||||||||||
|
|
2018 |
|
|
2017 |
|
|
2018 |
|
|
2017 |
|
||||
Networks |
|
$ |
0.26 |
|
|
$ |
0.31 |
|
|
$ |
0.90 |
|
|
$ |
0.87 |
|
Renewables |
|
|
0.23 |
|
|
|
0.10 |
|
|
|
0.39 |
|
|
|
0.32 |
|
Corporate (1) |
|
|
(0.08 |
) |
|
|
0.03 |
|
|
|
(0.10 |
) |
|
|
0.02 |
|
Gas Storage |
|
|
(0.06 |
) |
|
|
(0.05 |
) |
|
|
(0.06 |
) |
|
|
(0.05 |
) |
Net Income |
|
|
0.35 |
|
|
|
0.39 |
|
|
|
1.13 |
|
|
|
1.16 |
|
Adjustments: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Restructuring charges (2) |
|
|
— |
|
|
|
— |
|
|
|
— |
|
|
|
— |
|
Mark-to-market adjustments - Renewables (3) |
|
|
0.01 |
|
|
|
0.04 |
|
|
|
(0.00 |
) |
|
|
(0.02 |
) |
Loss from held for sale measurement (4) |
|
|
0.03 |
|
|
|
— |
|
|
|
0.05 |
|
|
|
— |
|
Income from release of collateral - Renewables (5) |
|
|
(0.02 |
) |
|
|
— |
|
|
|
(0.02 |
) |
|
|
— |
|
Impact of the Tax Act (6) |
|
|
0.02 |
|
|
|
— |
|
|
|
0.02 |
|
|
|
— |
|
Income tax impact of adjustments |
|
|
0.02 |
|
|
|
(0.01 |
) |
|
|
0.05 |
|
|
|
0.01 |
|
Gas Storage, net of tax |
|
|
0.01 |
|
|
|
0.05 |
|
|
|
(0.03 |
) |
|
|
0.05 |
|
Adjusted Earnings Per Share (7) |
|
$ |
0.41 |
|
|
$ |
0.46 |
|
|
$ |
1.20 |
|
|
$ |
1.19 |
|
|
(1) |
Includes corporate and other non-regulated entities as well as intersegment eliminations. |
|
(2) |
Restructuring and severance related charges relate to costs resulted from restructuring actions involving initial targeted voluntary workforce reductions and related costs in our plan to vacate a lease, predominantly within the Networks segment. |
|
(3) |
Mark-to-market adjustments relate to changes in the fair value of derivative instruments used by AVANGRID to economically hedge market price fluctuations in related underlying physical transactions for the purchase and sale of electricity and gas. |
|
(4) |
Represents loss from measurement of assets and liabilities held for sale in connection with the committed plan to sell the gas trading and storage businesses. |
|
(5) |
Relates to cash collateral released in excess of outstanding receivables from a bankruptcy proceeding with a Renewables customer regarding two power purchase agreements. |
|
(6) |
Represents the impact from measurement of deferred income tax balances as a result of the Tax Act enacted by the U.S. federal government on December 22, 2017. |
|
(7) |
Adjusted net income and adjusted earnings per share are non-GAAP financial measures and are presented after excluding restructuring charges, loss from held for sale measurement, income from release of collateral, impact of the Tax Act, the impact from mark-to-market activities in Renewables and Gas storage business. |
Liquidity and Capital Resources
Our operations, capital investment and business development require significant short-term liquidity and long-term capital resources. Historically, we have used cash from operations and borrowings under our credit facilities and commercial paper program as our primary sources of liquidity. Our long-term capital requirements have been met primarily through retention of earnings and borrowings in the investment grade debt capital markets. Continued access to these sources of liquidity and capital are critical to us. Risks may increase due to circumstances beyond our control, such as a general disruption of the financial markets and adverse economic conditions.
We and our subsidiaries are required to comply with certain covenants in connection with our respective loan agreements. The covenants are standard and customary in financing agreements, and we and our subsidiaries were in compliance with such covenants as of June 30, 2018.
Liquidity Position
At June 30, 2018 and December 31, 2017, available liquidity was approximately $2.8 billion and $784 million, respectively.
We manage our overall liquidity position as part of the group of companies controlled by Iberdrola, or the Iberdrola Group, and are a party to a liquidity agreement with Bank of America, N.A. along with certain members of the Iberdrola Group. The liquidity agreement aids the Iberdrola Group in efficient cash management and reduces the need for external borrowing by the pool participants. Parties to the agreement, including us, may deposit funds with or borrow from the financial institution, provided that the net balance of funds deposited or borrowed by all pool participants in the aggregate is not less than zero. The balance at June 30, 2018 was zero. Any deposit amounts would be reflected in our condensed consolidated balance sheets under cash and cash equivalents because our deposited surplus funds under the cash pooling agreement are highly-liquid short-term investments. We also have a bi-lateral demand note agreement with a Canadian affiliate of the Iberdrola Group under which we had notes payable balance outstanding of $31 million at June 30, 2018.
60
We optimize our liquidity within the United States through a series of arms-length intercompany lending arrangements with our subsidiaries and among the regulated utilities to provide for lending of surplus cash to subsidiaries with liquidity needs, subject to the limitation that the regulated utilities may not lend to unregulated affiliates. These arrangements minimize overall short-term funding costs and maximize returns on the temporary cash investments of the subsidiaries. We have the capacity to borrow up to $2.5 billion from the lenders committed to the AVANGRID Credit Facility and $0.5 billion from an Iberdrola Group Credit Facility, both of which are describe d below.
The following table provides the components of our liquidity position as of June 30, 2018 and December 31, 2017, respectively:
|
|
As of June 30, |
|
|
As of December 31, |
|
||
|
|
2018 |
|
|
2017 |
|
||
|
|
(in millions) |
|
|||||
Cash and cash equivalents |
|
$ |
52 |
|
|
$ |
41 |
|
AVANGRID Credit Facility |
|
|
2,500 |
|
|
|
1,500 |
|
Iberdrola Group Credit Facility |
|
|
500 |
|
|
|
— |
|
Less: borrowings |
|
|
(218 |
) |
|
|
(757 |
) |
Total |
|
$ |
2,834 |
|
|
$ |
784 |
|
AVANGRID Commercial Paper Program
On May 13, 2016, AVANGRID established a commercial paper program with a limit of $1 billion that is backstopped by the AVANGRID Credit Facility (described below). On July 30, 2018, AVANGRID increased this limit from $1 billion to $2 billion. As of June 30, 2018 and July 31, 2018, there was $218 million and $399 million of commercial paper outstanding, respectively.
AVANGRID Credit Facility
On June 29, 2018, AVANGRID and its subsidiaries, NYSEG, RG&E, CMP, UI, CNG, SCG and BGC entered into a revolving credit facility with a syndicate of banks, or the AVANGRID Credit Facility , that provides for maximum borrowings of up to $2.5 billion in the aggregate.
Under the terms of the AVANGRID Credit Facility, each joint borrower has a maximum borrowing entitlement, or sublimit, which can be periodically adjusted to address specific short-term capital funding needs, subject to the maximum limit established by the banks. AVANGRID’s maximum sublimit is $2 billion, NYSEG, RG&E, CMP and UI have maximum sublimits of $400 million, CNG and SCG have maximum sublimits of $150 million and BGC has a maximum sublimit of $40 million. Under the AVANGRID Credit Facility, each of the borrowers will pay an annual facility fee that is dependent on their credit rating. The initial facility fees will range from 12.5 to 17.5 basis points. The maturity date for the AVANGRID Credit Facility is June 29, 2023.
This AVANGRID Credit Facility replaces and supersedes the prior revolving credit facility entered into by AVANGRID and its subsidiaries, NYSEG, RG&E, CMP, UI, CNG, SCG and BGC, with a syndicate of banks on April 5, 2016 with a maturity date of April 5, 2021, which provided for maximum borrowings of up to $1.5 billion in the aggregate on substantially similar terms as the AVANGRID Credit Facility.
Since the facility is a backstop to the AVANGRID commercial paper program, the amounts available under the facility as of June 30, 2018 and July 31, 2018, were $2,282 million and $2,101 million, respectively.
Iberdrola Group Credit Facility
On June 18, 2018 AVANGRID entered into a credit facility with Iberdrola Financiacion, S.A.U., a company of the Iberdrola Group. The facility has a limit of $500 million and matures on June 18, 2023. AVANGRID pays a facility fee of 10.5 basis points annually on the facility. As of both June 30, 2018 and July 31, 2018, there was no outstanding amount under this credit facility.
Capital Resources
On May 3, 2018, Renewables closed on the sale of a tax equity interest in its El Cabo wind project which resulted in proceeds of $213 million.
On June 29, 2018, NYSEG remarketed $74 million 1994 Series Pollution Control Revenue Bonds that mature in 2023 and $100 million 2004 Series Pollution Control Revenue Bonds with a mandatory tender in 2023. The Bonds were issued through the New York State Energy Research and Development Authority, or NYSERDA, on which NYSEG is the obligor. These securities had previously been held in treasury.
61
On June 29, 2018, RG&E remarketed 1997 and 2004 Series Pollution Co ntrol Revenue Bonds in the aggregate principal amount of $152.4 million and with mandatory tenders in 2025, issued through NYSERDA, on which RG&E is the obligor. $90.3 million of these securities had previously been held in treasury.
Capital Requirements
We expect to fund our capital requirements, including, without limitation, any quarterly shareholder dividends and capital investments primarily from the cash provided by operations of our businesses and through the access to the capital markets in the future. We have a revolving credit facility, as described above, to fund short-term liquidity needs and we believe that we will have access to the capital markets should additional, long-term growth capital be necessary.
We expect to accrue approximately $1.3 billion in capital expenditures through the remainder of 2018.
Cash Flows
Our cash flows depend on many factors, including general economic conditions, regulatory decisions, weather, commodity price movements and operating expense and capital spending control.
The following is a summary of the cash flows by activity for the six months ended June 30, 2018 and 2017, respectively:
|
|
Six Months Ended |
|
|||||
|
|
June 30, |
|
|||||
|
|
2018 |
|
|
2017 |
|
||
|
|
(in millions) |
|
|||||
Net cash provided by operating activities |
|
$ |
983 |
|
|
$ |
925 |
|
Net cash used in investing activities |
|
|
(606 |
) |
|
|
(1,045 |
) |
Net cash (used in) provided by financing activities |
|
|
(366 |
) |
|
|
66 |
|
Net increase (decrease) in cash, cash equivalents and restricted cash |
|
$ |
11 |
|
|
$ |
(54 |
) |
Operating Activities
For the six months ended June 30, 2018, net cash provided by operating activities was $983 million. During the six months ended June 30, 2018, Renewables contributed $289 million of operating cash flow associated with wholesale sales of energy and Networks contributed $524 million of operating cash as the result of regulated transmission and distribution sales of electricity and natural gas. Additionally, $34 million in cash was used associated with corporate operating expenses in support of the operating segments and changes in working capital provided $203 million in cash. The cash from operating activities for the six months ended June 30, 2018 compared to the six months ended June 30, 2017 increased by $57 million, primarily attributable to increased operating revenues. The $19 million net change in operating assets and liabilities during the six months ended June 30, 2018 was primarily attributable to a net decrease of $43 million in accounts receivable and payable due to impacts from sales and purchases, decrease in inventories and other assets/liabilities of $8 million and $27 million, respectively, offset by cash distribution received from equity method investment of $7 million, taxes accrued of $3 million and increase of $17 million in regulatory assets/liabilities in the period.
For the six months ended June 30, 2017, net cash provided by operating activities was $925 million. During the six months ended June 30, 2017, Renewables contributed $240 million of operating cash flow associated with wholesale sales of energy, and Networks contributed $502 million of operating cash as the result of regulated transmission and distribution sales of electricity and natural gas. Additionally, $5 million in cash was provided associated with corporate operating expenses in support of the operating segments and changes in working capital provided $181 million in cash. The cash from operating activities for the six months ended June 30, 2017 compared to the six months ended June 30, 2016 increased by $19 million, primarily attributable to increased operating revenues, excluding the impact of a non-cash adjustment of unfunded future income tax discussed above. The $29 million net change in operating assets and liabilities during the six months ended June 30, 2017 was primarily attributable to a net decrease of $25 million in accounts receivable and payable due to impacts from sales and purchases, cash distribution received from equity method investment of $7 million, offset by increase in taxes accrued of $4 million, increase in inventories and other assets/liabilities of $14 million and $22 million, respectively, and an increase of $21 million in regulatory assets/liabilities.
Investing Activities
For the six months ended June 30, 2018, net cash used in investing activities was $606 million, which was comprised of $522 million associated with capital expenditures at Networks and $229 million of capital expenditures at Renewables primarily associated with payments in support of construction projects. This was offset by $23 million of contributions in aid of construction, $2 million of cash distributions from equity method investments and proceeds from sale of assets of $136 million primarily related to the sale of assets held for sale .
62
For the six months ended June 30, 2017, net cash used in investing activities was $1,045 million, which was comprised of $534 million associated with capital expenditures at Networks and $531 million of capital expenditures at Renewables primarily associated with payments in support of the El C abo construction project. This was offset by $21 million of contributions in aid of construction, $2 million of cash distributions from equity method investments and proceeds of $5 million from the sale of other investment.
Financing Activities
For the six months ended June 30, 2018, financing activities used $366 million in cash reflecting primarily an issuance of Pollution Control Revenue Bonds at NYSEG and RG&E with the net proceeds of $325 million, contributions from non-controlling interests of $220 million, offset by a net decrease in non-current debt and current notes payable of $604 million, distributions to non-controlling interests of $22 million, payments on capital leases of $12 million and dividends of $267 million.
For the six months ended June 30, 2017, financing activities provided $66 million in cash reflecting primarily an issuance of First Mortgage Bonds at RG&E with the net proceeds of $294 million, a net increase in non-current debt and current notes payable of $135 million, payments on the tax equity financing arrangements of $60 million, payments on capital leases of $31 million and dividends of $268 million.
Off-Balance Sheet Arrangements
There have been no material changes in the off-balance sheet arrangements during the six months ended June 30, 2018 as compared to those reported for the fiscal year ended December 31, 2017 in our Form 10-K.
Contractual Obligations
There have been no material changes in contractual and contingent obligations during the six months ended June 30, 2018 as compared to those reported for the fiscal year ended December 31, 2017 in our Form 10-K.
Critical Accounting Policies and Estimates
The accompanying financial statements provided herein have been prepared in accordance with U.S. GAAP. In preparing the accompanying financial statements, our management has applied accounting policies and made certain estimates and assumptions that affect the reported amounts of assets, liabilities, stockholders’ equity, revenues and expenses, and the disclosures thereof. While we believe that these policies and estimates used are appropriate, actual future events can and often do result in outcomes that can be materially different from these estimates. The accounting policies and related risks described in our Form 10-K are those that depend most heavily on these judgments and estimates. As of June 30, 2018, the only notable changes to the significant accounting policies described in our consolidated financial statements as of December 31, 2017 and 2016, and for the three years ended December 31, 2017, are with respect to our adoption of the new accounting pronouncements described in the Note 3 of our condensed consolidated financial statements for the three and six months ended June 30, 2018.
New Accounting Standards
We review new accounting standards to determine the expected financial impact, if any, that the adoption of each such standard will have. As of June 30, 2018, the new accounting pronouncements that we have adopted as of January 1, 2018, and reflected in our consolidated financial statements are described in Note 3 of our condensed consolidated financial statements for the three and six months ended June 30, 2018 . There have been no other material changes to the significant accounting policies described in our consolidated financial statements as of December 31, 2017 and 2016, and for the three years ended December 31, 2017.
63
CAUTIONARY STATEMENT REGARDING FORWARD-LOOKING STATEMENTS
This Quarterly Report on Form 10-Q contains a number of forward-looking statements. Forward-looking statements may be identified by the use of forward-looking terms such as “may,” “will,” “should,” “would,” “could,” “can,” “expects,” “believes,” “anticipates,” “intends,” “plans,” “estimates,” “projects,” “assumes,” “guides,” “targets,” “forecasts,” “is confident that” and “seeks” or the negative of such terms or other variations on such terms or comparable terminology. Such forward-looking statements include, but are not limited to, statements about our plans, objectives and intentions, outlooks or expectations for earnings, revenues, expenses or other future financial or business performance, strategies or expectations, or the impact of legal or regulatory matters on business, results of operations or financial condition of the business and other statements that are not historical facts. Such statements are based upon the current beliefs, expectations, and assumptions of our management and are subject to significant risks and uncertainties that could cause actual outcomes and results to differ materially. The foregoing and other factors are discussed and should be reviewed in our Form 10-K and other subsequent filings with the SEC. Specifically, forward-looking statements may include statements relating to:
|
• |
future financial performance, anticipated liquidity and capital expenditures; |
|
• |
actions or inactions of local, state or federal regulatory agencies; |
|
• |
success in retaining or recruiting our officers, key employees or directors; |
|
• |
changes in levels or timing of capital expenditures; |
|
• |
adverse developments in general market, business, economic, labor, regulatory and political conditions; |
|
• |
fluctuations in weather patterns; |
|
• |
technological developments; |
|
• |
the impact of any cyber breaches or other incidents, grid disturbances, acts of war or terrorism or natural disasters; |
|
• |
the impact of any change to applicable laws and regulations affecting operations, including those relating to environmental and climate change, taxes, price controls, regulatory approval and permitting; |
|
• |
the implementation of changes in accounting standards; |
|
• |
the remediation of the material weakness in our internal control over financial reporting; and |
|
• |
other presently unknown unforeseen factors. |
Should one or more of these risks or uncertainties materialize, or should any of the underlying assumptions prove incorrect, actual results may vary in material respects from those expressed or implied by these forward-looking statements. You should not place undue reliance on these forward-looking statements. We do not undertake any obligation to update or revise any forward-looking statements to reflect events or circumstances after the date of this report, whether as a result of new information, future events or otherwise, except as may be required under applicable securities laws.
Item 3. Quantitative and Qualitative Disclosures about Market Risk
There have been no material changes in our market risk during the six months ended June 30, 2018, as compared to those reported for the fiscal year ended December 31, 2017 in our Form 10-K.
Item 4. Controls and Procedures
Evaluation of Disclosure Controls and Procedures
Our management, with the participation of our Chief Executive Officer, or CEO, and our Chief Financial Officer, or CFO, has evaluated the effectiveness of our disclosure controls and procedures (as defined in Rules 13a- 15(e) and 15d- 15(e) under the Securities Exchange Act of 1934, as amended (Exchange Act)), as of the end of the period covered by this Quarterly Report on Form 10-Q. Based on such evaluation, our CEO and CFO have concluded that as of such date, our disclosure controls and procedures were not effective, as a result of the material weakness that exists in our internal control over financial reporting as previously described in our Annual Report on Form 10-K for the year ended December 31, 2017.
Previously Identified Material Weakness
As of December 31, 2017, management concluded that certain deficiencies rose to the level of a material weakness in controls related to the measurement and disclosure of income taxes. As a result of the identified material weakness, management concluded that, as of December 31, 2017, our internal control over financial reporting was not effective.
A material weakness is a deficiency, or combination of deficiencies, in internal control over financial reporting such that there is a reasonable possibility that a material misstatement of our annual or interim financial statements will not be prevented or detected on a timely basis.
Notwithstanding the material weakness in internal control over financial reporting, our management concluded that our unaudited condensed consolidated financial statements in this report fairly present, in all material respects, the Company’s financial
64
position, results of operations and cash flows as of the dates, and for the periods presented, in conformity with generally accepted accounting principles.
Remediation Plans and Other Information
Our management, with oversight from the Audit and Compliance Committee of the Board of Directors, is actively engaged in remediation efforts to address the 2017 material weakness. The remediation plans for the 2017 material weakness include the following:
|
- |
Further acceleration of the deadline of key activities to allow sufficient time for the execution of consolidated deferred income tax controls that were newly designed during the third and fourth quarter of 2017 that management has determined through testing are more precise; |
|
- |
Further increase of the capabilities of income tax accounting resources to devote additional time and internal control resources to consolidated income tax accounting and reporting processes and controls; and |
|
- |
Enhancing the automation of certain income tax processes and controls to allow for the more timely completion and enhanced review of internal controls surrounding consolidated deferred income tax financial information and disclosures. |
These improvements are targeted at strengthening the Company's internal control over financial reporting and remediating the material weakness. The Company remains committed to an effective internal control environment and management believes that these actions, and the improvements management expects to achieve as a result, will remediate the material weakness. However, the material weakness in our internal control over financial reporting will not be considered remediated until the controls operate for a sufficient period of time and management has concluded, through testing, that these controls operate effectively. We currently expect that the remediation of this material weakness will be completed by December 31, 2018.
Changes in Internal Control
Except for the control deficiencies discussed above that have been assessed as a material weakness as of December 31, 2017, and the remediation as described within “Remediation Plans and Other Information” above, there has been no change in our internal control over financial reporting identified in management’s evaluation pursuant to Rules 13a-15(d) or 15d-15(d) of the Exchange Act during the period covered by this Quarterly Report on Form 10-Q that materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.
Limitations on Effectiveness of Controls and Procedures
In designing and evaluating the disclosure controls and procedures, management recognizes that any controls and procedures, no matter how well designed and operated, can provide only reasonable assurance of achieving the desired control objectives. In addition, the design of disclosure controls and procedures must reflect the fact that there are resource constraints and that management is required to apply judgment in evaluating the benefits of possible controls and procedures relative to their costs.
65
Please read “Note 8—Contingencies” and “Note 9—Environmental Liabilities” to the accompanying unaudited condensed consolidated financial statements under Part I, Item 1of this report for a discussion of legal proceedings that we believe could be material to us.
Shareholders and prospective investors should carefully consider the risk factors disclosed in our Form 10-K for the fiscal year ended December 31, 2017. There have been no material changes to such risk factors.
Item 2. Unregistered Sales of Equity Securities and Use of Proceeds
None.
Item 3. Defaults Upon Senior Securities
None.
Item 4. Mine Safety Disclosures
Not applicable.
None.
66
The following documents are included as exhibits to this Form 10-Q:
Exhibit
|
|
Description |
|
|
|
|
|
|
10.1 |
|
|
|
|
|
10.2 |
|
|
|
|
|
10.3 |
|
|
|
|
|
10.4 |
|
|
|
|
|
10.5 |
|
|
|
|
|
10.6 |
|
|
|
|
|
10.7 |
|
|
|
|
|
10.8 |
|
|
|
|
|
10.9 |
|
|
|
|
|
10.10 |
|
|
|
|
|
31.1 |
|
|
|
|
|
31.2 |
|
|
|
|
|
32 |
|
|
|
|
|
101.INS |
|
XBRL Instance Document.* |
|
|
|
101.SCH |
|
XBRL Taxonomy Extension Schema Document.* |
|
|
|
101.CAL |
|
XBRL Taxonomy Extension Calculation Linkbase Document.* |
|
|
|
101.DEF |
|
XBRL Taxonomy Extension Definition Linkbase Document.* |
|
|
|
101.LAB |
|
XBRL Taxonomy Extension Label Linkbase Document.* |
|
|
|
101.PRE |
|
XBRL Taxonomy Extension Presentation Linkbase Document.* |
|
|
|
* Filed herewith.
† Compensatory plan or agreement.
67
Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.
|
|
Avangrid, Inc. |
|
|
|
Date: August 2, 2018 |
By: |
/s/ James P. Torgerson |
|
|
James P. Torgerson |
|
|
Director and Chief Executive Officer |
Date: August 2, 2018 |
By: |
/s/ Douglas K. Stuver |
|
|
Douglas K. Stuver |
|
|
Senior Vice President - Chief Financial Officer |
68
Exhibit 10.1
AVANGRID, inc.
AMENDED AND RESTATED Omnibus incentive plan
RESTRICTED STOCK UNIT GRANT NOTICE
2018 SPECIAL LONG TERM INCENTIVE AWARD
Avangrid, Inc., a Delaware corporation (the “ Company ”), pursuant to its Amended and Restated Omnibus Incentive Plan, as amended from time to time (the “ Plan ”), hereby grants to the holder listed below (“ Participant ”) the number of Restricted Stock Units (the “ RSUs ”) set forth below. The RSUs are subject to the terms and conditions set forth in this Restricted Stock Unit Grant Notice (the “ Grant Notice ”) and the Restricted Stock Unit Agreement attached hereto as Exhibit A (the “ Agreement ”) and the Plan, which are incorporated herein by reference. Unless otherwise defined herein, the terms defined in the Plan shall have the same defined meanings in the Grant Notice and the Agreement.
Participant: |
James P. Torgerson |
Grant Date: |
June 7, 2018 |
Number of RSUs: |
60,000 |
Vesting Schedule: |
The RSUs shall vest in full in one installment on the date of the Company’s regular annual shareholders meeting occurring in calendar year 2020, provided that the Participant remains continuously employed with the Company through such date. In addition, to the extent not previously forfeited, the RSUs shall also vest in full upon (i) the Participant’s death or termination of employment due to Disability, (ii) retirement with the consent of the Company, or (iii) termination of the Participant’s employment by the Company for Cause or the Participant’s resignation of his employment on account of a Constructive Termination, in either case following the occurrence of a Change in Control. “ Cause ” and “ Constructive Termination ” shall have the meanings set forth in the Participant’s employment agreement previously entered into with the Company. |
By his or her signature, and the Company’s signature below, Participant agrees to be bound by the terms and conditions of the Plan, the Agreement and the Grant Notice. Participant has reviewed the Agreement, the Plan and the Grant Notice in their entirety, has had an opportunity to obtain the advice of counsel prior to executing the Grant Notice and fully understands all provisions of the Grant Notice, the Agreement and the Plan. Participant hereby agrees to accept as binding, conclusive and final all decisions or interpretations of the Administrator upon any questions arising under the Plan, the Grant Notice or the Agreement.
AVANGRID, Inc. Holder: |
|
|
PARTICIPANT |
||
By: |
/ s/ Sheila Duncan |
|
|
By: |
/s/ James P. Torgerson |
Print Name: |
Sheila Duncan |
|
|
Print Name: |
James P. Torgerson |
Title: |
Senior Vice President – Human Resources & Corporate Administration |
|
|
|
|
TO RESTRICTED STOCK UNIT Grant Notice
RESTRICTED STOCK UNIT AGREEMENT
Pursuant to the Grant Notice to which this Agreement is attached, the Company has granted to Participant the number of RSUs set forth in the Grant Notice.
ARTICLE I.
general
1.1 Defined Terms . Capitalized terms not specifically defined herein shall have the meanings specified in the Plan or the Grant Notice.
1.2 Incorporation of Terms of Plan . The RSUs and the shares of Common Stock (“ Stock ”) to be issued to Participant hereunder (“ Shares ”) are subject to the terms and conditions set forth in this Agreement and the Plan, which is incorporated herein by reference. In the event of any inconsistency between the Plan and this Agreement, the terms of the Plan shall control.
ARTICLE II.
award of restricted stock UNITS and DIVIDEND EQUIVALENTS; RESTRICTIVE COVENANTS
2.1 Award of RSUs and Dividend Equivalents .
(a) In consideration of Participant’s past and/or continued employment with or service to the Company or a Subsidiary and for other good and valuable consideration, effective as of the grant date set forth in the Grant Notice (the “ Grant Date ”), the Company has granted to Participant the number of RSUs set forth in the Grant Notice, upon the terms and conditions set forth in the Grant Notice, the Plan and this Agreement, subject to adjustments as provided in Section 8 of the Plan. Each RSU represents the right to receive one Share or, at the option of the Company, an amount of cash as set forth in Section 2.3(b), in either case, at the times and subject to the conditions set forth herein, subject to the provisions of Section 2.3(c). However, unless and until the RSUs have vested, Participant will have no right to the payment of any Shares subject thereto. Prior to the actual delivery of any Shares, the RSUs will represent an unsecured obligation of the Company, payable only from the general assets of the Company.
(b) The Company hereby grants to Participant an Award of Dividend Equivalents with respect to each RSU granted pursuant to the Grant Notice for all ordinary cash dividends which are paid to all or substantially all holders of the outstanding shares of Stock, to be credited as of dividend payment dates with respect to dividends with record dates that occur between the Grant Date and the date when the applicable RSU is distributed or paid to Participant or is forfeited or expires. The Dividend Equivalents for each RSU shall be equal to the amount of cash which is paid as a dividend on one share of Stock. All such Dividend Equivalents shall be credited to Participant and be deemed to be reinvested in additional RSUs as of the date of payment of any such dividend based on the Fair Market Value of a share of Stock on such date. Each additional RSU which results from such deemed reinvestment of Dividend Equivalents granted hereunder shall be subject to the same vesting, distribution or payment, adjustment and other provisions which apply to the underlying RSU to which such additional RSU relates.
A-1
2.2 Vesting of RSUs and Dividend Equivalents .
(a) Subject to Participant’s continued employment with or service to the Company or a Subsidiary on each applicable vesting date and subject to the terms of this Agreement, the RSUs shall vest in such amounts and at such times as are set forth in the Grant Notice. Each additional RSU which results from deemed reinvestments of Dividend Equivalents pursuant to Section 2.1(b) hereof shall vest whenever the underlying RSU to which such additional RSU relates vests.
(b) In the event Participant incurs a Termination of Service, except as may be otherwise provided by the Administrator or as set forth in a written agreement between Participant and the Company, Participant shall immediately forfeit any and all RSUs and Dividend Equivalents granted under this Agreement which have not vested or do not vest on or prior to the date on which such Termination of Service occurs, and Participant’s rights in any such RSUs and Dividend Equivalents which are not so vested shall lapse and expire.
2.3 Distribution or Payment of RSUs .
(a) Participant’s RSUs shall be distributed in Shares (either in book-entry form or otherwise) or, at the option of the Company, paid in an amount of cash as set forth in Section 2.3(b), in either case, as soon as administratively practicable following the vesting of the applicable RSU pursuant to Section 2.2, and, in any event, within sixty (60) days following such vesting. Notwithstanding the foregoing, the Company may delay a distribution or payment in settlement of RSUs if it reasonably determines that such payment or distribution will violate Federal securities laws or any other Applicable Law, provided that such distribution or payment shall be made at the earliest date at which the Company reasonably determines that the making of such distribution or payment will not cause such violation, as required by Treasury Regulation Section 1.409A-2(b)(7)(ii), and provided further that no payment or distribution shall be delayed under this Section 2.3(a) if such delay will result in a violation of Section 409A of the Code.
(b) In the event that the Company elects to make payment of Participant’s RSUs in cash, the amount of cash payable with respect to each RSU shall be equal to the Fair Market Value of a Share on the day immediately preceding the applicable distribution or payment date set forth in Section 2.3(a). All distributions made in Shares shall be made by the Company in the form of whole Shares, and any fractional share shall be distributed in cash in an amount equal to the value of such fractional share determined based on the Fair Market Value as of the date immediately preceding the date of such distribution.
2.4 Conditions to Issuance of Certificates . The Company shall not be required to issue or deliver any certificate or certificates for any Shares prior to the fulfillment of all of the following conditions: (A) the admission of the Shares to listing on all stock exchanges on which such Shares are then listed, (B) the completion of any registration or other qualification of the Shares under any state or federal law or under rulings or regulations of the Securities and Exchange Commission or other governmental regulatory body, which the Administrator shall, in its absolute discretion, deem necessary or advisable, and (C) the obtaining of any approval or other clearance from any state or federal governmental agency that the Administrator shall, in its absolute discretion, determine to be necessary or advisable.
A-2
2.5 Tax Withholding . Notwithstanding any other provision of this Agreement:
(a) The Company and its Subsidiaries have the authority to deduct or withhold, or require Participant to remit to the Company or the applicable Subsidiary, an amount sufficient to satisfy applicable federal, state, local and foreign taxes (including the employee portion of any FICA obligation) required by law to be withheld with respect to any taxable event arising pursuant to this Agreement. The Company and its Subsidiaries may withhold or Participant may make such payment in one or more of the forms specified below:
(i) by cash or check made payable to the Company or the Subsidiary with respect to which the withholding obligation arises;
(ii) by the deduction of such amount from other compensation payable to Participant;
(iii) with respect to any withholding taxes arising in connection with the distribution of the RSUs, with the consent of the Administrator, by requesting that the Company and its Subsidiaries withhold a net number of vested shares of Stock otherwise issuable pursuant to the RSUs having a then current Fair Market Value not exceeding the amount necessary to satisfy the withholding obligation of the Company and its Subsidiaries based on the minimum applicable statutory withholding rates for federal, state, local and foreign income tax and payroll tax purposes;
(iv) with respect to any withholding taxes arising in connection with the distribution of the RSUs, with the consent of the Administrator, by tendering to the Company vested shares of Stock having a then current Fair Market Value not exceeding the amount necessary to satisfy the withholding obligation of the Company and its Subsidiaries based on the minimum applicable statutory withholding rates for federal, state, local and foreign income tax and payroll tax purposes;
(v) with respect to any withholding taxes arising in connection with the distribution of the RSUs, through the delivery of a notice that Participant has placed a market sell order with a broker acceptable to the Company with respect to shares of Stock then issuable to Participant pursuant to the RSUs, and that the broker has been directed to pay a sufficient portion of the net proceeds of the sale to the Company or the Subsidiary with respect to which the withholding obligation arises in satisfaction of such withholding taxes; provided that payment of such proceeds is then made to the Company or the applicable Subsidiary at such time as may be required by the Administrator, but in any event not later than the settlement of such sale; or
(vi) in any combination of the foregoing.
(b) With respect to any withholding taxes arising in connection with the RSUs, in the event Participant fails to provide timely payment of all sums required pursuant to Section 2.5(a), the Company shall have the right and option, but not the obligation, to treat such failure as an election by Participant to satisfy all or any portion of Participant’s required payment obligation pursuant to Section 2.5(a)(ii) or Section 2.5(a)(iii) above, or any combination of the foregoing as the Company may determine to be appropriate. The Company shall not be obligated to deliver any certificate representing shares of Stock issuable with respect to the RSUs to Participant or his or her legal representative unless and until Participant or his or her legal representative shall have paid or otherwise satisfied in full the amount of all federal, state, local and foreign taxes applicable with respect to the taxable income of Participant resulting from the vesting or settlement of the RSUs or any other taxable event related to the RSUs.
A-3
(c) In the event any tax withholding obligation arising in connection with the RSUs will be satisfied under Section 2.5(a)(iii) above , the Company may elect to instruct any brokerage firm determined acceptable to the Company for such purpose to sell on Participant’s behalf a whole number of shares from those shares of Stock then issuable to Participant pursuant to the RSUs as the Company determines to be appropriate to generate cash proceeds sufficient to satisfy the tax withholding obligation and to remit the proceeds of such sale to the Company or the Subsidiary with respect to which the withholding obligation arises. Participant’s acceptance of this Award constitutes Participant’s instruction and authorization to the Company and such brokerage firm to complete the transactions described in this Section 2.5(c), including the transactions described in the previous sentence, as applicable. The Company may refuse to issue any shares of Stock in settlement of the RSUs to Participant until the foregoing tax withholding obligations are satisfied, provided that no payment shall be delayed under this Section 2.5(c) if such delay will result in a violation of Section 409A of the Code .
(d) Participant is ultimately liable and responsible for all taxes owed in connection with the RSUs, regardless of any action the Company or any Subsidiary takes with respect to any tax withholding obligations that arise in connection with the RSUs. Neither the Company nor any Subsidiary makes any representation or undertaking regarding the treatment of any tax withholding in connection with the awarding, vesting or payment of the RSUs or the subsequent sale of the Shares. The Company and the Subsidiaries do not commit and are under no obligation to structure the RSUs to reduce or eliminate Participant’s tax liability.
2.6 Rights as Stockholder . Neither Participant nor any person claiming under or through Participant will have any of the rights or privileges of a stockholder of the Company in respect of any Shares deliverable hereunder unless and until certificates representing such Shares (which may be in book-entry form) will have been issued and recorded on the records of the Company or its transfer agents or registrars and delivered to Participant (including through electronic delivery to a brokerage account). Except as otherwise provided herein, after such issuance, recordation and delivery, Participant will have all the rights of a stockholder of the Company with respect to such Shares, including, without limitation, the right to receipt of dividends and distributions on such Shares.
ARTICLE III.
other provisions
3.1 Administration . The Administrator shall have the power to interpret the Plan, the Grant Notice and this Agreement and to adopt such rules for the administration, interpretation and application of the Plan, the Grant Notice and this Agreement as are consistent therewith and to interpret, amend or revoke any such rules. All actions taken and all interpretations and determinations made by the Administrator will be final and binding upon Participant, the Company and all other interested persons. To the extent allowable pursuant to Applicable Law, no member of the Committee or the Board will be personally liable for any action, determination or interpretation made with respect to the Plan, the Grant Notice or this Agreement.
3.2 RSUs Not Transferable . The RSUs may not be sold, pledged, assigned or transferred in any manner other than by will or the laws of descent and distribution, unless and until the Shares underlying the RSUs have been issued, and all restrictions applicable to such Shares have lapsed. No RSUs or any interest or right therein or part thereof shall be liable for the debts, contracts or engagements of Participant or his or her successors in interest or shall be subject to disposition by transfer, alienation, anticipation, pledge, encumbrance, assignment or any other means whether such disposition be voluntary or involuntary or by operation of law by judgment, levy, attachment, garnishment or any other legal or equitable proceedings (including bankruptcy), and any attempted disposition thereof shall be null and void and of no effect, except to the extent that such disposition is permitted by the preceding sentence.
A-4
3.3 Adjustments . The Administrator may accelerate the vesting of all or a portion of the RSUs in such circumstances as it, in its sole discretion, may determine. Participant acknowledges that the RSUs and the Shares subject to the RSUs are subject to adjustment, modification and termination in certain events as provided in this Agreement and Section 8 of the Plan.
3.4 Titles . Titles are provided herein for convenience only and are not to serve as a basis for interpretation or construction of this Agreement.
3.5 Governing Law . The laws of the State of Delaware shall govern the interpretation, validity, administration, enforcement and performance of the terms of this Agreement regardless of the law that might be applied under principles of conflicts of laws.
3.6 Conformity to Securities Laws . Participant acknowledges that the Plan, the Grant Notice and this Agreement are intended to conform to the extent necessary with all Applicable Laws, including, without limitation, the provisions of the Securities Act and the Exchange Act, and any and all regulations and rules promulgated thereunder by the Securities and Exchange Commission, and state securities laws and regulations. Notwithstanding anything herein to the contrary, the Plan shall be administered, and the RSUs are granted, only in such a manner as to conform to Applicable Law. To the extent permitted by Applicable Law, the Plan and this Agreement shall be deemed amended to the extent necessary to conform to Applicable Law.
3.7 Amendment, Suspension and Termination . To the extent permitted by the Plan, this Agreement may be wholly or partially amended or otherwise modified, suspended or terminated at any time or from time to time by the Administrator or the Board , provided that, except as may otherwise be provided by the Plan, no amendment, modification, suspension or termination of this Agreement shall adversely affect the RSUs in any material way without the prior written consent of Participant.
3.8 Successors and Assigns . The Company may assign any of its rights under this Agreement to single or multiple assignees, and this Agreement shall inure to the benefit of the successors and assigns of the Company. Subject to the restrictions on transfer set forth in Section 3.2 and the Plan, this Agreement shall be binding upon and inure to the benefit of the heirs, legatees, legal representatives, successors and assigns of the parties hereto.
3.9 Limitations Applicable to Section 16 Persons . Notwithstanding any other provision of the Plan or this Agreement, if Participant is subject to Section 16 of the Exchange Act, the Plan, the RSUs (including RSUs which result from the deemed reinvestment of Dividend Equivalents), the Dividend Equivalents, the Grant Notice and this Agreement shall be subject to any additional limitations set forth in any applicable exemptive rule under Section 16 of the Exchange Act (including any amendment to Rule 16b-3 of the Exchange Act) that are requirements for the application of such exemptive rule. To the extent permitted by Applicable Law, this Agreement shall be deemed amended to the extent necessary to conform to such applicable exemptive rule.
3.10 Not a Contract of Employment . Nothing in this Agreement or in the Plan shall confer upon Participant any right to continue to serve as an employee or other service provider of the Company or any Subsidiary or shall interfere with or restrict in any way the rights of the Company and its Subsidiaries, which rights are hereby expressly reserved, to discharge or terminate the services of Participant at any time for any reason whatsoever, with or without cause, except to the extent expressly provided otherwise in a written agreement between the Company or a Subsidiary and Participant.
A-5
3.11 Entire Agreement . The Plan, the Grant Notice and this Agreement (including any exhibit hereto) constitute the entire agreement of the parties and supersede in their entirety all prior undertakings and agreements of the Company and Participant with respect to the subject matter hereof.
3.12 Section 409A . This Award is not intended to constitute “nonqualified deferred compensation” within the meaning of Section 409A of the Code (together with any Department of Treasury regulations and other interpretive guidance issued thereunder, including without limitation any such regulations or other guidance that may be issued after the date hereof, “ Section 409A ”). However, notwithstanding any other provision of the Plan, the Grant Notice or this Agreement, if at any time the Administrator determines that this Award (or any portion thereof) may be subject to Section 409A, the Administrator shall have the right in its sole discretion (without any obligation to do so or to indemnify Participant or any other person for failure to do so) to adopt such amendments to the Plan, the Grant Notice or this Agreement, or adopt other policies and procedures (including amendments, policies and procedures with retroactive effect), or take any other actions, as the Administrator determines are necessary or appropriate for this Award either to be exempt from the application of Section 409A or to comply with the requirements of Section 409A.
3.13 Limitation on Participant’s Rights . Participation in the Plan confers no rights or interests other than as herein provided. This Agreement creates only a contractual obligation on the part of the Company as to amounts payable and shall not be construed as creating a trust. Neither the Plan nor any underlying program, in and of itself, has any assets. Participant shall have only the rights of a general unsecured creditor of the Company with respect to amounts credited and benefits payable, if any, with respect to the RSUs and Dividend Equivalents.
3.14 Counterparts . The Grant Notice may be executed in one or more counterparts, including by way of any electronic signature, subject to Applicable Law, each of which shall be deemed an original and all of which together shall constitute one instrument.
* * *
A-6
Exhibit 10.2
TRANSMISSION SERVICE AGREEMENT
by and between
CENTRAL MAINE POWER COMPANY,
as Owner,
and
NSTAR ELECTRIC COMPANY D/B/A EVERSOURCE ENERGY,
as Distribution Company
Dated: as of June 13, 2018
|
|
Page |
|
|
|
Article I DEFINITIONS AND RULES OF INTERPRETATION |
|
2 |
Section 1.1 Definitions |
|
2 |
Section 1.2 Interpretation |
|
14 |
|
|
|
Article II REGULATORY FILINGS AND REQUIRED APPROVALS |
|
16 |
Section 2.1 MDPU Filing; FERC Filing |
|
16 |
Section 2.2 Modifications to FERC Order |
|
16 |
Section 2.3 Modifications Pursuant to Unfavorable MDPU Order |
|
17 |
Section 2.4 Cooperation |
|
17 |
Section 2.5 No Inconsistent Action |
|
18 |
|
|
|
Article III EFFECTIVE DATE; TERM |
|
18 |
Section 3.1 Effective Date |
|
18 |
Section 3.2 Term |
|
18 |
Section 3.3 Termination Rights |
|
18 |
Section 3.4 Termination Payments |
|
20 |
Section 3.5 Effect of Termination |
|
21 |
|
|
|
Article IV COMMERCIAL OPERATION |
|
21 |
Section 4.1 Critical Milestones. |
|
21 |
Section 4.2 Commercial Operation Date |
|
23 |
Section 4.3 Conditions Precedent to Commercial Operation |
|
24 |
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation |
|
25 |
|
|
|
Article V GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES |
|
27 |
Section 5.1 Responsibilities of the Parties |
|
27 |
Section 5.2 Schedules and Reports |
|
27 |
Section 5.3 Insurance and Events of Loss |
|
28 |
Section 5.4 Compliance with Laws |
|
29 |
Section 5.5 Third Party Contracts |
|
29 |
Section 5.6 Continuity of Rights and Responsibilities |
|
29 |
|
|
|
Article VI PROCEDURES FOR OPERATION AND MAINTENANCE OF THE NECEC TRANSMISSION LINE |
|
29 |
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control |
|
29 |
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements |
|
30 |
Section 6.3 Scheduled Maintenance |
|
30 |
|
|
|
Article VII DISTRIBUTION COMPANY’S TRANSMISSION RIGHTS OVER THE NECEC TRANSMISSION LINE |
|
31 |
Section 7.1 Transmission Service |
|
31 |
Section 7.2 Excused Outages or Reductions |
|
31 |
Section 7.3 Non-Excused Outages or Reductions |
|
32 |
Section 7.4 Allocation of Outages |
|
33 |
Section 7.5 Metering |
|
33 |
i
|
33 |
|
|
|
|
Article VIII PAYMENTS FOR TRANSMISSION SERVICE OVER THE NECEC TRANSMISSION LINE |
|
33 |
Section 8.1 Transmission Service Payments |
|
33 |
Section 8.2 Elective Upgrade Status; No Regional Rates |
|
34 |
Article IX RIGHTS UPON EXPIRATION OF TERM |
|
34 |
Section 9.1 Rollover and Other Rights |
|
34 |
|
|
|
Article X TRANSFER AND RESALE OF TRANSMISSION RIGHTS |
|
34 |
Section 10.1 Transfer of Transmission Rights |
|
34 |
Section 10.2 Resale Rights |
|
35 |
Section 10.3 Capacity Releases for Daily and Hourly Use |
|
35 |
Section 10.4 OASIS |
|
35 |
Section 10.5 Proceeds from Capacity Releases and Transmission Resales |
|
35 |
Section 10.6 Owner’s Rights and Obligations |
|
35 |
|
|
|
Article XI REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS |
|
36 |
Section 11.1 Real Power Losses |
|
36 |
Section 11.2 Other Rights |
|
36 |
|
|
|
Article XII [INTENTIONALLY OMITTED] |
|
37 |
|
|
|
Article XIII BILLING AND PAYMENTS |
|
37 |
Section 13.1 Invoices |
|
37 |
Section 13.2 Procedures for Billing Disputes |
|
37 |
Section 13.3 Interest |
|
37 |
Section 13.4 Obligation to Make Payments |
|
38 |
Section 13.5 Offsets |
|
38 |
|
|
|
Article XIV EVENTS OF DEFAULT AND REMEDIES |
|
38 |
Section 14.1 Distribution Company Defaults |
|
38 |
Section 14.2 Owner Defaults |
|
39 |
Section 14.3 Remedies Upon Distribution Company Default |
|
40 |
Section 14.4 Remedies Upon Owner Default |
|
41 |
Section 14.5 Abandoned Plant Recovery |
|
41 |
Section 14.6 Disputes |
|
43 |
Section 14.7 Limitations on Total Liability |
|
43 |
|
|
|
Article XV FORCE MAJEURE |
|
43 |
Section 15.1 Definition; Conditions |
|
43 |
|
|
|
Article XVI FINANCIAL ASSURANCES |
|
45 |
Section 16.1 Owner Security |
|
45 |
|
|
|
Article XVII DISPUTE RESOLUTION |
|
46 |
Section 17.1 Consultation |
|
46 |
Section 17.2 Disputes to be Resolved by FERC |
|
46 |
ii
|
47 |
|
Section 17.4 WAIVER OF JURY TRIAL |
|
47 |
|
|
|
Article XVIII LIMITATION OF REMEDIES |
|
47 |
|
|
|
Article XIX MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES. |
|
48 |
Section 19.1 Modifications |
|
48 |
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment |
|
48 |
|
|
|
Article XX INDEMNIFICATION |
|
49 |
Section 20.1 Owner Indemnity |
|
49 |
Section 20.2 [Intentionally Omitted] |
|
50 |
Section 20.3 Procedures |
|
50 |
Section 20.4 Defenses |
|
50 |
Section 20.5 Cooperation |
|
50 |
Section 20.6 Recovery |
|
51 |
Section 20.7 Subrogation |
|
51 |
|
|
|
Article XXI REPRESENTATIONS, WARRANTIES AND COVENANTS |
|
51 |
Section 21.1 Mutual Representations and Warranties |
|
51 |
Section 21.2 Additional Representations and Warranties of Owner |
|
52 |
Section 21.3 Additional Representations and Warranties of Distribution Company |
|
53 |
Section 21.4 NO OTHER REPRESENTATIONS OR WARRANTIES |
|
54 |
|
|
|
Article XXII TRANSFER OF INTERESTS |
|
54 |
Section 22.1 No Transfer of Interests |
|
54 |
Section 22.2 Exceptions |
|
55 |
Section 22.3 Collateral Assignment |
|
56 |
|
|
|
Article XXIII MISCELLANEOUS |
|
57 |
Section 23.1 Governing Law |
|
57 |
Section 23.2 Entire Agreement |
|
57 |
Section 23.3 Severability |
|
57 |
Section 23.4 Notices |
|
57 |
Section 23.5 Intentionally Omitted |
|
58 |
Section 23.6 Waiver; Cumulative Remedies |
|
58 |
Section 23.7 Confidential Information |
|
59 |
Section 23.8 No Third-Party Rights |
|
59 |
Section 23.9 Permitted Successors and Assigns |
|
60 |
Section 23.10 Relationship of the Parties |
|
60 |
Section 23.11 Construction |
|
60 |
Section 23.12 Counterparts |
|
60 |
Section 23.13 Survival |
|
60 |
Section 23.14 Headings and Table of Contents |
|
60 |
Section 23.15 Waiver of Immunities |
|
60 |
iii
Attachment A |
|
Description of Transmission Projects |
Attachment B |
|
Critical Milestones |
Attachment C |
|
Owner Approvals |
Attachment D |
|
Canadian Approvals |
Attachment E |
|
Owner’s Preliminary Project Schedule and Construction Schedule |
Attachment F |
|
Required Insurance |
Attachment G |
|
Rate Adjustment Formula |
Attachment H |
|
Refund Calculation |
Attachment I |
|
Real Estate Rights |
Attachment J |
|
Transmission Service Payment Calculation |
iv
TRANSMISSION SERVICE AGREEMENT
This TRANSMISSION SERVICE AGREEMENT (this “ Agreement ”), dated as of June 13, 2018 (the “ Execution Date ”), is made and entered into by and between Central Maine Power Company, a corporation organized and existing under the laws of the State of Maine (“ Owner”) , and NSTAR Electric Company (d/b/a Eversource Energy), a Massachusetts corporation organized and existing under the laws of the Commonwealth of Massachusetts (“ Distribution Company ”). Owner and Distribution Company are hereinafter sometimes also referred to individually as a “ Party ” or collectively as the “ Parties .”
WITNESSETH
WHEREAS, pursuant to “An Act to Promote Energy Diversity” that was signed into law in the Commonwealth of Massachusetts on August 8, 2016 (the “ Energy Diversity Act ”), Fitchburg Gas & Electric Light Company (d/b/a Unitil), Massachusetts Electric Company (d/b/a National Grid), Nantucket Electric Company (d/b/a National Grid), and NSTAR Electric Company (d/b/a Eversource Energy) (collectively, the “ RFP Sponsors ”) have solicited competitive proposals for clean energy generation for an annual amount of electricity equal to approximately 9.45 TWh;
WHEREAS, Owner and an Affiliate of H.Q. Energy Services (U.S.) Inc., a corporation organized and existing under the laws of the State of Delaware (“HQUS”), jointly submitted a proposal pursuant to such solicitation that includes up to 1,090 MW of clean energy generation obtained by HQUS from its affiliate Hydro-Québec Production (a division of Hydro-Québec (as defined below), “ HQP ” and such generation, the “ Hydro Generation ”);
WHEREAS, concurrently with the execution and delivery of this Agreement, HQUS has entered into a power purchase agreement (the “ PPA ”) with Distribution Company and additional power purchase agreements (the “ Additional PPAs ”) with the other RFP Sponsors with respect to an aggregate of 1,090 MW of Hydro Generation (and related renewable energy credits and environmental attributes);
WHEREAS, as part of the delivery of 1,090 MW of Hydro Generation for sale into the U.S. pursuant to the PPA and the Additional PPAs, Hydro-Québec TransÉnergie (“ TransÉnergie ”), a division of Hydro-Québec, intends to develop, construct, own and maintain a 1,200 MW +/-320 kV high-voltage direct current (“ HVDC ”) transmission line from the converter station at the Appalaches substation in Thetford Mines, Québec to the U.S. Border (as defined below) at Beattie Township, Maine (as further delineated in the diagram or described in Attachment A, the “ Québec Line ”);
WHEREAS, HQP has acquired from TransÉnergie firm transmission service over the Québec Line to permit the delivery of at least 1,200 MW of power into the U.S.;
WHEREAS, Owner intends to develop, construct, own and maintain a 1,200 MW +/-320 kV HVDC transmission line extending from the U.S. Border at Beattie Township, Maine to a new direct current to alternating current (“ AC ”) converter station to be located at Merrill Road in the City of Lewiston in the State of Maine (the transmission line and converter station, as more fully described in Attachment A, the “ HVDC Line ”);
1
WHEREAS, in order to interconnect the HVDC Line with the bulk power systems in New England, Owner intends to develop, construct, own and maintain additional 345 kV AC transmission lines, rebuilt 115 kV AC transmission lines and other substation equipment more fully described in Attachment A (together with the Merrill Road substation at its northern terminus and the associated equipment, as more fully described in Attachment A, the “ AC Line ” and, together with the HVDC Line, the “ NECEC Transmission Line ” );
WHEREAS, although Owner has performed studies believed to replicate those utilized by ISO-NE and does not believe that AC Upgrades (as defined below) or CCIS Capacity Upgrades (as defined below) will be required as a consequence of the construction and operation of the NECEC Transmission Line and the consummation of the transactions contemplated by this Agreement, this Agreement, the Additional TSAs (as defined below), the PPA or the Additional PPAs, ISO-NE (as defined below) may require certain AC Upgrades or CCIS Capacity Upgrades to be developed, constructed, owned and maintained by certain transmission owners other than Owner (which may include Affiliates of Owner) within their existing service territories in New England in order to interconnect the NECEC Transmission Line with the New England Transmission System (as defined below) in a safe and reliable manner, which AC Upgrades or CCIS Capacity Upgrades (if any) will be performed at Owner’s sole expense;
WHEREAS, concurrently with the execution and delivery of this Agreement, Owner has entered into (a) certain Additional TSAs with the other RFP Sponsors to sell an aggregate of 510.665 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date (as defined below), (b) certain Additional TSAs with HQUS to sell an aggregate of 1,090 MW of firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date and (c) the Additional HQUS TSA (as defined below) with HQUS; and
WHEREAS, Owner desires to sell Firm Transmission Service (as defined below) to Distribution Company for the first twenty (20) years following the Commercial Operation Date, and Distribution Company desires to acquire such Firm Transmission Service from Owner, at the rates and on the terms and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the foregoing and the respective representations, warranties, covenants, agreements and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound hereby, the Parties hereby agree as follows:
Article I
DEFINITIONS AND RULES OF INTERPRETATION
Section 1.1 Definitions . As used herein, the following terms shall have the following respective meanings:
“ AC ” has the meaning provided in the recitals to this Agreement.
“ AC Line ” has the meaning provided in the recitals to this Agreement.
“ AC Upgrade Approvals ” means, collectively, any Governmental Approvals or Third Party Consents, in each case, that are required to commence construction of the AC Upgrades.
2
“ AC Upgrade Owners ” means, collectively, any Person responsible for constructing one or more AC Upgrades pursuant to a facilities agreement.
“ AC Upgrades ” means any additions, upgrades, reinforcements or other modifications to the New England Transmission System that ISO-NE determines, pursuant to Section I.3.9 of the ISO-NE Tariff, to be required, at a minimum, to interconnect the NECEC Transmission Line at the Delivery Point with the New England Transmission System.
“ Additional HQUS TSA ” means that certain Transmission Service Agreement between HQUS and Owner, dated as of the date hereof, pursuant to which HQUS has acquired transmission service for up to 110 MW of capacity for forty (40) years following the Commercial Operation Date.
“ Additional HQUS TSA Capacity ” means the firm capacity of the NECEC Transmission Line of up to 110 MW that HQUS has committed in the Additional HQUS TSA to purchase in the forty (40) years following the Commercial Operation Date.
“ Additional PPAs ” has the meaning provided in the recitals to this Agreement.
“ Additional TSA ” means (a) any transmission service agreement entered into between an RFP Sponsor and Owner (other than this Agreement), pursuant to which such RFP Sponsor acquires firm transmission service for the first twenty (20) years following the Commercial Operation Date, (b) any transmission service agreement entered into between HQUS and Owner (including the HQUS TSA), pursuant to which HQUS acquires firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date or (c) the Additional HQUS TSA.
“ Adverse Determination ” has the meaning provided in Section 19.2(c) .
“ Advisory Ruling ” has the meaning provided in Section 8.4 of the PPA.
“ Affiliate ” means, with respect to a specified Person, any other Person that directly or indirectly Controls, is Controlled by or is under common Control with the specified Person; provided , however , that, with respect to HQUS, a Person shall not be an “Affiliate” of HQUS unless such Person is Hydro-Québec (including, for the avoidance of doubt, a division of Hydro-Québec) or Controlled by Hydro-Québec.
“ Agreement ” has the meaning provided in the preamble to this Agreement.
“ Applicable Law ” means any duly promulgated federal, national, state, provincial or local law, regulation, rule, ordinance, code, decree, judgment, directive or judicial or administrative order, permit or other duly authorized and valid action of any Governmental Authority, including any binding interpretation of any of the foregoing by any Governmental Authority, which is applicable to a Person, its property or a transaction, and also including without limitation Section 83D of the Energy Diversity Act (“ Section 83D” ), the regulations promulgated under Section 83D, the Regulatory Approval and any other orders of the MDPU with respect to this Agreement.
“ Approval Deadline ” means December 14, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
3
“ Available Transfer Capability ” means the lesser of (a) 1,090 MW or (b) the Total Transfer Capability.
“ Bankruptcy Code ” means the United States Bankruptcy Code, 11 U.S.C. § 101 et seq.
“ Business Day ” means any day except Saturday, Sunday or any other day on which the Federal Reserve member banks are required or authorized to close for business.
“ Canadian Approvals ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the Québec Line in a manner consistent with Attachment A, all as set forth in Attachment D.
“ Canadian Approval Deadline ” means March 11, 2021 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Cash ” shall mean U.S. dollars held by or on behalf of a Party as Credit Support hereunder.
“ CCIS Capacity Upgrade ” means any upgrade determined by ISO-NE as necessary in order for the NECEC Transmission Line Capacity to satisfy the Capacity Capability Interconnection Standard under the ISO-NE Tariff.
“ COD Notice ” has the meaning provided in Section 4.2(c) .
“ Commercial Operation ” means the availability of the NECEC Transmission Line for the provision of Firm Transmission Service in accordance with this Agreement and the HQUS TSA.
“ Commercial Operation Date ” has the meaning provided in Section 4.2(c) .
“ Commissioning ” means (a) with respect to the NECEC Transmission Line, the start-up and testing activities required to demonstrate that the NECEC Transmission Line is ready for Commercial Operation and (b) with respect to the Québec Line, the start-up and testing activities required to demonstrate that the Québec Line is ready for commercial operation, consistent with Section 4.3(f) .
“ Concurrent Delay ” has the meaning provided in Section 4.4.2(a) .
“ Confidential Information ” means (a) this Agreement (including Attachments), (b) any documents, analyses, compilations, studies, or other materials prepared by or information received from a Party or its representatives that contain or reflect written or oral data or information that is privileged, confidential or proprietary and that is marked or otherwise clearly identified as “confidential” or “proprietary” or with words of like meaning, or (c) any subsequently prepared documents, analyses, compilations, studies or other materials or information that are derived from any of the documents, analyses, compilations, studies or other materials or information described in the foregoing clause (b). Without limiting the generality of the foregoing, all information provided to Distribution Company or Owner under Sections 2.4 , 5.2 and 6.3 hereof shall be deemed to be Confidential Information, whether or not such information is marked as “confidential” or “proprietary.”
“ Consent ” means, with respect to a Person, any approval, consent, permit, license, decree, certificate or other authorization of or from such Person.
4
“ Construction Authorizations ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the NECEC Transmission Line, other than the ISO-NE Approval, including the approvals of the Maine Department of Environmental Protection, the U.S. Army Corp of Engineers, the Maine Public Utilities Commission and the U.S. Department of Energy (the Presidential Permit), as more fully set forth in Attachment C.
“ Construction Contract ” means any contract entered into by Owner that provides for the engineering, procurement or construction of the NECEC Transmission Line.
“ Construction Phase ” means the period commencing upon the receipt of the FERC Authorization or such other date to which the Parties shall mutually agree in writing, and ending on the day immediately preceding the Commercial Operation Date or upon the earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Contract Capacity ” means the Proportionate Share multiplied by the NECEC Transmission Line Capacity.
“ Contract Year ” means each twelve-month period during the Term, with the first Contract Year commencing on the Commercial Operation Date and with each Contract Year after the first commencing on the anniversary of the Commerical Operation Date.
“ Control ” (including its correlative meanings “Controlled by” and “under common Control with”) means, with respect to a Person, the possession, directly or indirectly, of the power to direct or cause the direction of the management or policies of the specified Person, whether through ownership of voting securities or partnership or other ownership interests, by contract or Applicable Law or otherwise.
“ Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) , or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Credit Support ” means collateral in the form of (a) Cash or (b) a Letter of Credit issued by a Qualified Bank in a form reasonably satisfactory to the beneficiary.
“ Critical Energy Infrastructure Information ” means any information defined as Critical Energy Infrastructure Information by FERC pursuant to 18 C.F.R. § 388.113, and shall include all Critical Infrastructure Protection (CIP) standards (CIP-002 through CIP-009) established by NERC.
“ Critical Milestone ” has the meaning provided in Section 4.1(a) .
“ Delivery Point ” means the southern terminus of the NECEC Transmission Line at the Larrabee Road substation in Lewiston, Maine, as illustrated in Attachment A.
“ Design Capability ” means the maximum amount of electric power that the materials, equipment and structures comprising the HVDC Transmission Project will be designed to transfer bi-directionally in a safe and reliable manner, which amount shall be sufficient to permit the north-to-south delivery of all amounts scheduled for delivery in an aggregate amount of at least 1,090 MW, but not to exceed 1,200 MW, of electrical energy at the Delivery Point.
5
“ Discount Rate ” means the prime rate specified in the “Money and Investing” section of the Wall Street Journal, determined as of the date of notice of default, plus 300 basis points.
“ Dispute ” means any dispute, controversy or claim of any kind whatsoever arising out of or relating to a Proposal Agreement, including relating to the interpretation of the terms thereof or any Applicable Law that affects such Proposal Agreement, or the transactions contemplated thereunder, or the breach, termination or validity thereof.
“ Distribution Company ” has the meaning provided in the preamble to this Agreement.
“ Distribution Company Default ” has the meaning provided in Section 14.1 .
“ Distribution Company Indemnified Party ” has the meaning provided in Section 20.1 .
“ Distribution Company Termination Payment ” means, if Distribution Company is the defaulting Party, (a) prior to the Commercial Operation Date, an amount equal to the Proportionate Share of all costs prudently incurred by Owner as of the termination date in connection with the development and construction of the NECEC Transmission Line, or (b) on or after the Commercial Operation Date, an amount equal to the Proportionate Share multiplied by the Net Book Value of the NECEC Transmission Line. In either of these cases the Distribution Company Termination Payment will be reduced by the present value, discounted at the Discount Rate, of the Proportionate Share of the revenues (after taxes), if any; (i) received or to be received by Owner from HQUS as successor to Distribution Company under this Agreement pursuant to Sections 8.2 and 14.8 of the HQUS TSA, and (ii) to be received by Owner from long term transmission services provided to other third parties on the NECEC Transmission Line during the remaining Term of the Agreement. For the purpose of these calculations, the revenues will be reduced by the operating costs incurred, or projected by Owner in good faith to be incurred, to provide the corresponding services and by the costs and losses incurred or experienced by Owner as a consequence of the Distribution Company’s default. The reductions determined in accordance with clauses (i) and (ii) above will be limited to the amounts determined in accordance with clauses (a) and (b) above, and the reduction described in clause (ii) above will be determined considering only 90% of the revenues to be received. For purposes of calculating the Distribution Company Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW .
“ Effective Date ” has the meaning provided in Section 3.1 .
“ Excused Outages ” has the meaning provided in Section 7.2(a) .
“ Execution Date ” has the meaning provided in the preamble to this Agreement.
“ Federal Power Act ” means the United States Federal Power Act of 1935, as amended, 16 U.S.C. § 791a et seq.
“ FERC ” means the Federal Energy Regulatory Commission, or any successor regulatory agency that administers the Federal Power Act.
“ FERC Amendment ” has the meaning provided in Section 2.2(b) .
“ FERC Authorization ” means, collectively, any FERC order which is not subject to rehearing or appeal authorizing Owner to provide Firm Transmission Service, including the FERC
6
Order and any authorization from FERC with respect to the Transmission Operating Agreement or Interconnection Agreements.
“ FERC Order ” has the meaning provided in Section 2.2(a) .
“ Financial Transmission Rights ” means Financial Transmission Rights, as defined in the ISO-NE Tariff.
“ Financing Deadline ” means March 7, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing.
“ Firm Transmission Service ” has the meaning provided in Section 7.1.1.
“ Force Majeure ” has the meaning provided in Section 15.1(a) .
“ Good Utility Practice ” means those design, construction, operation, maintenance, repair, removal and disposal practices, methods and acts that are engaged in by a significant portion of the electric transmission industry in the United States during the relevant time period, or any other practices, methods or acts that, in the exercise of reasonable judgment in light of the facts known at the time a decision is made, could have been expected to accomplish a desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Good Utility Practice is not intended to be the optimum practice, method or act to the exclusion of others but rather to be a spectrum of acceptable practices, methods or acts generally accepted in such electric transmission industry for the design, construction, operation, maintenance, repair, removal and disposal of electric transmission facilities in the United States. Good Utility Practice shall not be determined after the fact in light of the results achieved by the practices, methods, or acts undertaken, but rather shall be determined based upon the consistency of (a) the practices, methods, or acts when undertaken with (b) the standard set forth in the first two (2) sentences of this definition at such time.
“ Governmental Approval ” means (a) any authorization, consent, approval, license, lease, ruling, permit, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with or (d) any registration by or with, any Governmental Authority, including any FERC Authorization.
“ Governmental Authority ” means any government or agency or other political subdivision thereof, including any province, state or municipality, or any other governmental, quasi-governmental, judicial, executive, legislative, administrative, regulatory, public or statutory instrumentality, authority, body, agency, commission, department, board, bureau or entity exercising judicial, executive, legislative, administrative or regulatory functions, any court or arbitrator with authority to bind a party at law, and shall include, to the extent exercising powers delegated by any Governmental Authority acting under Applicable Law, NERC and ISO-NE.
“ Hourly Availability ” means, with respect to any hour, the availability of the NECEC Transmission Line for the purposes of this Agreement, which shall equal (a) the Proportionate Share of the Available Transfer Capability for such hour, divided by (b) the Contract Capacity, expressed as a percentage; provided, however, that, for any hour, such availability of the NECEC Transmission Line shall not exceed one hundred percent (100%).
“ HQP ” has the meaning provided in the recitals to this Agreement.
7
“ HQUS ” has the meaning provided in the recitals to this Agreement.
“ HQUS Delay ” means delays in completing the Québec Line, whether due to operational difficulties or any other event that is not an event of Force Majeure.
“ HQUS TSA ” means that certain Transmission Service Agreement between HQUS and Owner, dated as of the date hereof, pursuant to which HQUS has acquired 579.335 MW of firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date.
“ HVDC ” has the meaning provided in the recitals to this Agreement.
“ HVDC Line ” has the meaning provided in the recitals to this Agreement.
“ HVDC Transmission Project ” means, collectively, (a) the Québec Line and (b) the NECEC Transmission Line.
“ Hydro Generation ” has the meaning provided in the recitals to this Agreement.
“ Hydro-Québec ” means Hydro-Québec, a body politic and corporate, duly incorporated and regulated by the Hydro-Québec Act (R.S.Q., Chapter H-5). As of the Execution Date, Hydro-Québec has four divisions: HQP, TransÉnergie, Hydro-Québec Distribution and Hydro-Québec Équipment.
“ Immunities Act ” means the United States Foreign Sovereign Immunities Act of 1976, 28 U.S.C. § 1602 et seq.
“ Indemnification Notice ” has the meaning provided in Section 20.3 .
“ Indemnified Party ” has the meaning provided in Section 20.3 .
“ Insolvency Event ” means, with respect to a Person, such Person (a) becomes “insolvent,” as defined in the Bankruptcy Code, or otherwise becomes bankrupt or insolvent under any Insolvency Laws, (b) has a liquidator, administrator, receiver, custodian, trustee, conservator or similar official appointed with respect to such Person or any material portion of such Person’s assets or such Person consents to such appointment, or a foreclosure action is instituted with respect to any material portion of such Person’s assets and is not dismissed within thirty (30) days of commencement thereof, (c) files a voluntary petition or otherwise authorizes or commences a proceeding or cause of action under the Bankruptcy Code or Insolvency Laws, (d) has an involuntary petition filed against it or acquiesces in the commencement of a proceeding or cause of action as the subject debtor under the Bankruptcy Code or Insolvency Laws, which petition is not dismissed within thirty (30) days after the filing thereof or results in the issuance of an order for relief against such Person, (e) makes or consents to an assignment of its assets in whole or in part, for the benefit of creditors or any general arrangement for the benefit of creditors, or a common law composition of creditors or (f) generally is unable to pay its debts as they fall due, or admits in writing to such inability.
“ Insolvency Laws ” means any bankruptcy, insolvency, reorganization or similar laws of the U.S. or other Governmental Authority, as applicable, other than the Bankruptcy Code.
8
“ Interconnection Agreements ” means, collectively, (a) an agreement by and among Owner, TransÉnergie and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the U.S. Border of the NECEC Transmission Line with the Québec Line and (b) an agreement by and between Owner and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the Delivery Point of the NECEC Transmission Line with certain transmission facilities operated by ISO-NE. The Interconnection Agreements shall address cost responsibilities among entities other than the Distribution Company and the other RFP Sponsors and shall include provisions, both technical and otherwise, for safe and reliable interconnected operations of the HVDC Transmission Project following Commercial Operation (including use of the HVDC Transmission Project for the delivery of electric power in emergency circumstances).
“ Interested Party ” shall mean, collectively, the Parties and, if and as applicable, HQUS and the other RFP Sponsors.
“ Invoice ” means, with respect to a calendar month, an invoice that sets forth the amounts owed to the applicable Party with respect to such month in reasonable detail to evidence the basis for individual billings and charges.
“ ISO-NE ” means ISO New England Inc., or its successor organization.
“ ISO-NE Approval ” means approval by ISO-NE to operate the NECEC Transmission Line up to 1,200 MW.
“ ISO-NE Definitions Manual ” means the ISO New England Manual for Definitions and Abbreviations, Manual M-35, as in effect from time to time.
“ ISO-NE Rules ” means the ISO-NE Tariff and all ISO-NE manuals, rules, procedures, agreements or other documents relating to the reliable operation of the electric system in New England and the purchase and sale of electrical energy, electrical capacity and ancillary services, as such govern market participants with respect thereto in the operating jurisdiction of ISO-NE, as in effect from time to time, including the ISO-NE Definitions Manual; provided that such documents are publicly accessible.
“ ISO-NE Tariff ” means the ISO New England Inc. Transmission, Markets and Services Tariff, FERC Electric Tariff No. 3, as in effect from time to time, on file with FERC, or its successor tariff.
“ kV ” means kilovolt.
“ K W ” means kilowatt.
“ Letter of Credit ” shall mean an irrevocable, non-transferable standby letter of credit issued by a Qualified Bank utilizing a form acceptable to the Party in whose favor such letter of credit is issued. All costs relating to any Letter of Credit shall be for the account of the Party providing that Letter of Credit.
“ Maintenance Plan ” means an annual plan for the management, operation and ordinary maintenance of the NECEC Transmission Line, which plan shall include a description of the scope and nature of the planned operating and maintenance programs and planned and preventive
9
maintenance procedures for the NECEC Transmission Line, and the scheduled maintenance and other planned outages of the NECEC Transmission Line, in each case, in accordance with Section 6.3 hereof and the requirements of the PPA.
“ Market Products ” means, collectively, all products (however entitled and whether existing now or in the future) that (a) are recognized under ISO-NE Rules, (b) derive from the acquisition of transmission service over the NECEC Transmission Line under this Agreement and (c) can be sold for consideration or otherwise have economic value, including electrical energy, electrical capacity and ancillary services, including reserve products (including spinning and non-spinning reserves).
“ Material Adverse Effect ” means, with respect to a Party, a material adverse effect on the ability of such Party to perform any of its obligations under this Agreement.
“ MDPU ” means the Massachusetts Department of Public Utilities.
“ Minimum Average Availability ” means ninety percent (90%) of the Contract Capacity, provided that, during the Remediation Period, if applicable, for every ten (10) MW that the maximum operating capacity is below 1090 MW, the Minimum Average Availability shall be increased by one percent (1%), and provided further that if, at the earlier of the Remediation Date or the end of the Remediation Period, the operating capacity is below 1,090 MW, the Minimum Average Availability shall be increased by one-half of one percent (0.5%) for each 5 MW by which the operating capacity is below 1,090 MW.
“ Municipal Owner Approvals ” means the Owner Approvals identified in paragraph 10 of Attachment C that Owner reasonably determines are necessary to construct, own, and operate the NECEC Transmission Line.
“ Municipal Owner Approval Deadline ” means March 31, 2022 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ MW ” means megawatt.
“ MWh ” means megawatt-hour.
“ NECEC Facilities ” has the meaning provided in Section 8.2 .
“ NECEC Transmission Line ” has the meaning provided in the recitals to this Agreement.
“ NECEC Transmission Line Capacity ” means (a) 1,090 MW or (b) such lesser amount as may be established by the Commissioning of the NECEC Transmission Line, in each case, as measured at the Delivery Point; provided that the amount under clause (b) shall be increased if the capacity is increased after the Commercial Operation Date pursuant to Section 4.4.1(c).
“ NERC ” means the North American Electric Reliability Corporation, or its successor organization.
“ Net Book Value ” means, at any time, an amount equal to the original cost of construction minus depreciation (using a forty (40)-year depreciation schedule), as calculated in accordance with generally accepted accounting principles.
10
“ New England Transmission System ” means New England Transmission System, as defined in the ISO-NE Tariff.
“ Non-Excused Outage ” means any outage of the NECEC Transmission Line or reduction in the Total Transfer Capability below the NECEC Transmission Line Capacity, except due to an Excused Outage.
“ OASIS ” means the Open Access Same-Time Information System.
“ OASIS Administrator ” has the meaning provided in Section 10.4(a) .
“ Operation Phase ” means the period commencing on the Commercial Operation Date and ending upon the expiration of the Term or earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Other Transmission Rights ” means, collectively, any Financial Transmission Rights (or any similar concept), auction revenue rights or other financial or physical transmission rights, in each case, whether existing now or in the future, associated with the NECEC Transmission Line or AC Upgrades.
“ Owner ” has the meaning provided in the preamble to this Agreement.
“ Owner Approvals ” means, collectively, (a) the Construction Authorizations and (b) the ISO-NE Approval, all as set forth in Attachment C.
“ Owner Default ” has the meaning provided in Section 14.2 .
“ Owner Delay ” has the meaning provided in Section 4.4.1 .
“ Owner Security ” has the meaning provided in Section 16.1 .
“ Owner Termination Payment ” means, if Owner is the defaulting Party (a) prior to the Commercial Operation Date, an amount equal to the Owner Security together with any Credit Support held by Distribution Company pursuant to Section 4.1(c) , and (b) on or after the Commercial Operation Date (i) in the event that HQUS timely exercises its right to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under the Agreement pursuant to Section 14.7 of the HQUS TSA, the amount of any damages (including for the avoidance of doubt any lost profit) incurred by Distribution Company as a result of the Owner Default and (ii) otherwise an amount, if positive, calculated according to the following formula: (x) the present value, discounted at the Discount Rate, for each month remaining in the Services Term (as defined in the PPA), of ( A ) the amount, if, any, by which the forward market price of Energy and Environmental Attributes (both as defined in the PPA), as determined by the average of the quotes of at least two nationally recognized energy consulting firms or brokers chosen by Distribution Company, for Replacement Energy and Replacement Environmental Attributes, (both as defined in the PPA) exceeds the applicable Price (as defined in the PPA) that would have been paid pursuant to Exhibit D of the PPA, multiplied by (B) the amount of Guaranteed Qualified Clean Energy (as defined in the PPA) as provided in Exhibit B of the PPA; provided that, if Distribution Company receives a Termination Payment (as defined in the PPA) pursuant to Section 9.3 of the PPA, (other than any such Termination Payment received pursuant to Section 9.3(b)(iii) of the PPA), the Owner Termination Payment shall equal zero.
11
“ Owner’s Construction Progress Report ” has the meaning provided in Section 5.2.3(a) .
“ Owner’s Construction Schedule ” has the meaning provided in Section 5.2.2 .
“ Owner’s Preliminary Schedule ” has the meaning provided in Section 5.2.1 .
“ Parties ” and “ Party ” have the meanings provided in the preamble to this Agreement.
“ Person ” means any legal person, including any natural person, domestic or foreign corporation, limited liability company, general or limited partnership, joint venture, association, joint stock company, business trust, estate, trust, enterprise, unincorporated organization, any Governmental Authority, or any other legal or commercial entity.
“ Physical Transmission Line Capacity ” means the sum of the NECEC Transmission Line Capacity and the Additional HQUS TSA Capacity.
“ Power Cost Reconciliation Tariff ” shall mean a fully reconciling cost recovery tariff mechanism that authorizes the establishment of a distribution charge that fully recovers Distribution Company’s net costs under this Agreement (including annual remuneration of up to two and three-quarters percent (2.75%)). The rate reconciliation shall be designed in such a way as to limit the build-up of any under or over-recoveries over the course of the year. A reconciliation shall occur at least annually, but may also be reconciled quarterly or monthly, to the extent necessary to eliminate regulatory lag for the recovery of costs or crediting of over-recoveries to customers.
“ PPA ” has the meaning provided in the recitals to this Agreement.
“ PPA Contract Maximum Amount ” means 579.335 MW, as such amount may be adjusted in accordance with the terms of the PPA.
“ Presidential Permit ” means the permit granted by the U.S. Department of Energy, pursuant to Executive Order 10485 as amended by Executive Order 12038, authorizing the construction, operation, maintenance and connection of facilities for the transmission of electric energy at the international border between the United States and Canada.
“ Project Schedule ” means a schedule setting forth the proposed engineering, procurement, construction and testing milestone schedule for (a) the NECEC Transmission Line based upon the Construction Contracts, (b) the Québec Line and (c) the AC Upgrades and the CCIS Capacity Upgrades based upon such information as can reasonably be obtained by Owner from the AC Upgrade Owners, recognizing that one or more Project Schedules will be completed and delivered before the date on which the AC Upgrades and the CCIS Capacity Upgrades are formally identified under this Agreement.
“ Proportionate Share ” means a fraction with the numerator equal to 579.335 MW and the denominator equal to 1,090 MW.
“ Proposal Agreements ” means, collectively, this Agreement, the Additional TSAs, the PPA and the Additional PPAs.
“ Purchased Power Accounting Authorization ” shall mean authorization for Distribution Company, at Distribution Company’s sole discretion, to take appropriate steps to assure avoidance
12
of a material, negative balance sheet impact on Distribution Company or Distribution Company’s direct or indirect parent company, upon appropriate filing with and approval by the MDPU.
“ Qualified Bank ” means a U.S. commercial bank (or the U.S. branch of a foreign bank) having (a) assets on its most recent balance sheet of at least $10 billion and (b) a long-term credit rating of at least “A-” by S&P or “A3” by Moody’s (or its equivalent).
“ Québec Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Québec Line ” has the meaning provided in the recitals to this Agreement.
“ Real Power Losses ” means energy consumed by the electrical impedance characteristics of the NECEC Transmission Line.
“ Recovery ” has the meaning provided in Section 20.6 .
“ Regulatory Approval ” shall mean the MDPU approval of this entire Agreement, which approval shall include without limitation: (1) confirmation that this Agreement has been approved under Section 83D and the regulations promulgated thereunder and that all of the terms of such Section 83D and such regulations apply to this Agreement; (2) definitive regulatory authorization for Distribution Company to recover all of its costs incurred under and in connection with this Agreement for the entire term of this Agreement through the implementation of a Power Cost Reconciliation Tariff and/or other cost recovery or reconciliation mechanisms; (3) definitive regulatory authorization for Distribution Company to recover remuneration of up to two and three-quarters percent (2.75%) of Distribution Company’s annual payments under this Agreement for the term of this Agreement through the Power Cost Reconciliation Tariff; and (4) approval of any Purchased Power Accounting Authorization requested by Distribution Company in connection with the Regulatory Approval. Such approvals shall be acceptable in form and substance to Distribution Company in its sole discretion, shall not include any conditions or modifications that Distribution Company deems, in its sole discretion, to be unacceptable, and shall be final and not subject to appeal or rehearing.
“ Regulatory Approval Delay ” means any delay in the receipt of the Regulatory Approval beyond January 25, 2019.
“ Regulatory Approval Termination Outside Date ” has the meaning provided in Section 3.3.1(a) .
“ Remediation Date ” has the meaning provided in Section 4.4.1(b)(i) .
“ Remediation Period ” has the meaning provided in Section 4.4.1(b)(i) .
“ RFP Sponsors ” has the meaning provided in the recitals to this Agreement.
“ Scheduling Rules ” has the meaning provided in Section 7.1.3 .
“ State Amendment ” has the meaning provided in Section 2.3 .
“ Target Date ” has the meaning provided in Section 4.2(a) .
13
“ Term ” has the meaning provided in Section 3.2 .
“ Termination Payment ” means, as the context requires, the Distribution Company Termination Payment or the Owner Termination Payment.
“ Third Party Claim ” has the meaning provided in Section 20.3 .
“ Third Party Consent ” means any Consent of a Person other than a Governmental Authority.
“ Total Transfer Capability ” means the total transfer capability of the NECEC Transmission Line, as defined in, and established in accordance with, the ISO-NE Tariff and determined by ISO-NE for each hour.
“ TransÉnergie ” has the meaning provided in the recitals to this Agreement.
“ TransÉnergie OATT ” means the Hydro-Québec Open Access Transmission Tariff, as amended or accepted by the Régie de l’énergie from time to time.
“ Transfer ” has the meaning provided in Section 22.1(a) .
“ Transmission Operating Agreement ” means an agreement entered into by and between Owner and ISO-NE for transmission operating services over the NECEC Transmission Line under which operating control (as defined in such agreement) of the NECEC Transmission Line is transferred from Owner to ISO-NE.
“ Transmission Operator ” means ISO-NE acting in its capacity pursuant to the Transmission Operating Agreement.
“ Transmission Service Payment ” has the meaning provided in Section 8.1 .
“ Unfavorable FERC Decision ” has the meaning provided in Section 2.2(a) .
“ United States ” or “ U.S. ” means the United States of America.
“ U.S. Border ” means the location on or near the international border between the State of Maine and the Province of Québec where the HVDC Line and the Québec Line interconnect.
Section 1.2 Interpretation . In this Agreement, unless the context otherwise requires, the following rules shall apply to the usage of terms:
Section 1.2.1 Singular; Plural; Gender; Corollary Meaning . The singular shall include the plural and vice versa, and any pronoun shall include the corresponding masculine, feminine and neuter forms. If a term is defined as one part of speech (such as a noun), then it shall have a corresponding meaning when used as another part of speech (such as a verb).
Section 1.2.2 Coordinating Conjunctions . The word “or” shall have the inclusive meaning represented by the phrase “and/or.”
14
Section 1.2.3 Self-Reference . The words “hereof,” “herein,” “hereto” and “hereunder” and words of similar import when used in this Agreement shall, unless otherwise expressly specified, refer to this Agreement as a whole and not to any particular provision of this Agreement.
Section 1.2.4 Inclusive References . The words “include,” “includes” and “including” when used in this Agreement shall be deemed to be followed by “without limitation” or “but not limited to,” whether or not they are in fact followed by such words or words of like import.
Section 1.2.5 Incorporation by Reference . Any reference in this Agreement to an “Article,” “Section” or other subdivision or to an “Attachment” or other schedule or attachment shall be references to an article, section or other subdivision of, or to a schedule or attachment to, this Agreement, unless otherwise stated, and all such Articles, Sections and Attachments are incorporated into this Agreement by reference (all of which comprise part of one and the same agreement with equal force and effect). In the event of any conflict or other inconsistency between the main body of this Agreement and any attachment or schedule to this Agreement, the provisions of the main body of this Agreement shall prevail.
Section 1.2.6 Subsequent Acts . Any references in this Agreement to any statute shall be deemed to refer to such statute, as amended or replaced from time to time, including by succession of comparable successor statute, and all rules and regulations promulgated thereunder. In the event any index or publication referenced in this Agreement ceases to be published or a concept defined by reference to any such index or publication ceases to exist, each such reference shall be deemed to be a reference to a successor or alternate index, publication or concept reasonably agreed to by the Parties. Unless specified otherwise, a reference to a given agreement or instrument, and all schedules and attachments thereto, shall be a reference to that agreement or instrument as modified, amended, supplemented and restated, and as in effect from time to time.
Section 1.2.7 Inclusive of Permitted Successors . Unless otherwise expressly stated, references to any Person also include its permitted successors and assigns.
Section 1.2.8 Time Computation . In this Agreement, in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each means “to but excluding.”
Section 1.2.9 Business Days . Whenever this Agreement refers to a number of days, such number shall refer to calendar days unless Business Days are specified. Whenever any action must be taken under this Agreement on or by a day that is not a Business Day, such action may be validly taken on or by the next day that is a Business Day, and in the case of payments (including refunds of payments), no interest shall accrue on the amount due; provided that such payment is made in full on the next day that is a Business Day.
Section 1.2.10 Governmental Approvals . Except as otherwise expressly provided in this Agreement, any Governmental Approval shall be deemed to be received upon issuance, even if such Governmental Approval is subject to appeal or rehearing.
15
Section 1.2.11 Currency . All references to prices, values or monetary amounts referred to in this Agreement shall be paid in United States currency, unless expressly provided otherwise.
Article II
REGULATORY FILINGS AND REQUIRED APPROVALS
Section 2.1 MDPU Filing; FERC Filing .
(a) Distribution Company shall file for the Regulatory Approval as soon as practicable following the execution of this Agreement, and in any event shall use commercially reasonable efforts to file within sixty (60) days thereafter.
(b) Owner shall file this Agreement with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing with FERC shall include waiver requests for the Effective Date to occur consistent with Section 3.1 , which Effective Date may be more than one hundred twenty (120) days before the Commercial Operation Date.
(c) The Parties shall respond promptly to any requests for additional information made by FERC or the MDPU in connection with such filings.
(d) Upon the filing of this Agreement pursuant to Section 2.1(a) or 2.1(b) , Owner or Distribution Company shall support the approval or acceptance of this Agreement by the MDPU and FERC without modification or condition.
Section 2.2 Modifications to FERC Order .
(a) In the event (i) FERC issues an order accepting or approving this Agreement for filing (the “ FERC Order ”) and (ii) the FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to a Party, in its sole discretion (an “ Unfavorable FERC Decision ”), such Party shall deliver a written notice to the other Party specifying the issues, to the extent it is able, set for hearing or the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following the issuance of the Unfavorable FERC Decision.
(b) In the event of an Unfavorable FERC Decision, the Parties may agree upon amendments to this Agreement (each, a “ FERC Amendment ”) that achieve, as nearly as practicable, the commercial intent of this Agreement as of the Execution Date in a manner consistent with the Unfavorable FERC Decision. Any such amendment shall be subject to applicable regulatory approvals. As soon as practicable after any FERC Amendment(s) have been executed and delivered by the Parties, Owner shall file such FERC Amendment(s) with FERC.
(c) In the event of an Unfavorable FERC Decision, each Party shall retain the right to request a rehearing or reconsideration of the FERC Order regardless of any negotiations that have occurred or are occurring pursuant to clause (b) above;
16
provided, however, that, in the event the Parties execute a FERC Amendment after any one or both of the Parties has filed for rehearing or reconsideration, any such rehearing or reconsideration request shall be withdrawn no later than five (5) Business Days after FERC issues an order accepting or approving the FERC Amendment for filing, if such rehearing or reconsideration request is inconsistent with the terms and conditions of this Agreement, as amended. Unless otherwise agreed in writing by the Parties, a filing by any Party of a request for rehearing or reconsideration of the FERC Order shall not toll or otherwise modify any date or time period set forth in this Agreement, including, for the avoidance of doubt, the date upon which the Construction Phase shall commence.
Section 2.3 Modifications Pursuant to Unfavorable MDPU Order . In the event the Regulatory Approval contains modifications or conditions that are unacceptable to a Party, in the Party’s sole discretion (an “ Unfavorable MDPU Order ”), such Party shall deliver a written notice to the other Party of such Unfavorable MDPU Order specifying the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following such Unfavorable MDPU Order, and the Parties may agree to amend this Agreement to address such modifications or conditions (any of the foregoing amendments, a “ State Amendment ”). Any such amendment shall be subject to applicable regulatory approvals, and as soon as practicable after any State Amendment has been executed, Distribution Company or Owner (as applicable) shall file such State Amendment with the MDPU and FERC.
(a) In addition to their obligations under Section 2.1 , each Party shall (i) cooperate with each other to prepare, file and effect any applications, notices, petitions, reports or other filings or documentation required under Applicable Law or otherwise necessary, proper or advisable to consummate the transactions contemplated by this Agreement, (ii) provide updates to the other Party on material developments in connection with any such filings or documentation, (iii) provide any non-privileged information reasonably requested by the other Party in connection with any such filings or documentation, and (iv) cooperate with the other Party to use commercially reasonable efforts to obtain all Governmental Approvals and Third Party Consents that are necessary, proper or advisable to consummate the transactions contemplated by this Agreement, including the FERC Authorization (without unacceptable modifications or conditions, except as permitted by this Agreement), the other Owner Approvals, the Municipal Owner Approvals, the Canadian Approvals, and the Regulatory Approval (without unacceptable modifications or conditions, except as permitted by this Agreement). Owner shall provide any support reasonably necessary and requested by the AC Upgrade Owners to obtain the AC Upgrade Approvals.
(b) Each Party shall consult with the other Party with respect to all characterizations of information relating to such other Party or the transactions contemplated by this Agreement that are proposed to appear in any filings or documentation contemplated by Section 2.1 or Section 2.4(a) . Each Party shall promptly provide comments, if any, to the other Party on any such characterizations of information. Each Party shall make a good faith effort to take into account any comments made by the other Party.
17
Section 2.5 No Inconsistent Action . Except as provided in Section 17.2 and Article XIX , from and after the Execution Date, no Party shall undertake any action before FERC, ISO-NE, the MDPU or any other Governmental Authority that is contrary to the Party’s obligations under this Agreement, including, for the avoidance of doubt, Section 2.1(c) and Section 7.1.4 , or support any such contrary action by any Affiliate.
Article III
EFFECTIVE DATE; TERM
Section 3.1 Effective Date . Article I , Article II , this Section 3.1 , Section 3.3.1 , Section 3.3.2 , Article XVII , Article XVIII , Article XIX , Article XXII , and Article XXIII shall become effective and enforceable to the extent permitted by Applicable Law upon the Execution Date. The remaining provisions of this Agreement shall become effective and enforceable to the extent permitted by Applicable Law upon receipt of the Regulatory Approval (the “ Effective Date ”). Notwithstanding the first sentence of this Section 3.1 , this Agreement will become effective as a FERC rate schedule upon the effective date set forth in the FERC Order. Notwithstanding Section 14.5 and any other provision of this Agreement, Distribution Company shall have no obligation to make any payment under this Agreement prior to receipt of the Regulatory Approval and the FERC Authorizations.
Section 3.2 Term . The term of this Agreement shall commence on the Execution Date and shall expire on the twentieth (20 th ) anniversary of the Commercial Operation Date, unless earlier terminated (in whole or in part) or extended in accordance with the terms hereof (the “ Term ”).
Section 3.3 Termination Rights . This Agreement may be terminated in accordance with the ensuing provisions in this Article III , subject to any required regulatory reviews, approvals or acceptances, as applicable. Neither Party shall oppose any termination of this Agreement made in accordance with this Article III before FERC or any other Governmental Authority; provided, however, that the foregoing shall not prohibit any Party from challenging or otherwise Disputing whether or not any such termination is permitted by this Agreement.
Section 3.3.1 Failure to Obtain Regulatory Approval and FERC Authorizations .
(a) This Agreement may be terminated by any Party in the event (i) it determines that the Regulatory Approval or the FERC Authorizations contain terms and conditions that are, in its sole discretion, unacceptable to such Party, (ii) the Regulatory Approval is denied or is not received by January 25, 2020 (such date, the “ Regulatory Approval Termination Outside Date ”), (iii) the Regulatory Approval of the PPA (as defined in the PPA) is not received within the time frame set forth therein and the PPA is terminated, (iv) the FERC Authorization is denied or is not received by January 25, 2020, or (v) any Additional TSA with an RFP Sponsor is terminated pursuant to Section 3.3.1(a) of that Additional TSA, provided that the termination right under this clause (v) is exercised by a Party within thirty (30) days of the effective date of the termination of such Additional TSA.
(b) Upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
18
Section 3.3.2 Mutual Agreement . This Agreement may be terminated at any time upon written agreement of the Parties.
Section 3.3.3 Failure to Obtain Certain Approvals .
(a) Unless otherwise agreed in writing by the Parties, this Agreement shall terminate immediately without further action of the Parties in the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline, any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline, or any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e) ).
(b) In the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline or if any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e) ), and this Agreement has been terminated pursuant to clause (a) above, Distribution Company may draw against the Credit Support provided by Owner to Distribution Company, including the Owner Security and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) hereof.
(c) In the event any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline (as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e)) and this Agreement has been terminated pursuant to clause (a) above, Distribution Company may draw against the Credit Support provided by Owner to Distribution Company, including the Owner Security and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) hereof.
(d) Except as otherwise provided in clause (b) or in clause (c) above, upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.4 Distribution Company Default .
(a) Owner shall have the right to terminate this Agreement in accordance with Section 14.3(a) .
(b) Upon the exercise by Owner of its termination rights pursuant to clause (a) above, Owner shall have the right to recover from Distribution Company, and Distribution Company shall pay to Owner, the Distribution Company Termination Payment in accordance with Section 14.3(c) .
(c) The exercise by Owner of its termination rights pursuant to clause (a) above shall constitute a waiver by Owner of all other remedies or damages that may be available at law or in equity against Distribution Company; provided, however, that Owner shall not waive its right to, and Distribution Company shall remain liable for, the Distribution Company Termination Payment, any unpaid amounts owed by Distribution Company pursuant to Section 8.1 hereof and any amounts owed by Distribution Company to Owner under Section 3.4 , together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover the Distribution Company Termination Payment.
19
(a) Distribution Company shall have the right to terminate this Agreement in accordance with Section 14.4(a) .
(b) Upon the exercise by Distribution Company of its termination rights pursuant to clause (a) above, Distribution Company shall have the right to recover from Owner, and Owner shall pay to Distribution Company, the Owner Termination Payment in accordance with Section 14.4(a) .
(c) The exercise by Distribution Company of its termination rights pursuant to clause (a) above shall constitute a waiver by Distribution Company of all other remedies or damages that may be available at law or in equity against Owner; provided, however, that Distribution Company shall not waive any right to, and Owner shall remain liable for, the Owner Termination Payment, any amounts owed by Owner to Distribution Company under Section 3.4 , any accrued but unpaid amounts under Section 4.4.1 or any express modification of Distribution Company’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Distribution Company under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover such damages or such indemnified or other amounts owed to Distribution Company by Owner.
Section 3.3.6 Force Majeure . This Agreement may be terminated in accordance with Section 15.1(c) .
Section 3.3.7 Extended Excused Outage . This Agreement may be terminated in accordance with Section 7.2(c) .
Section 3.3.8 Termination of the PPA under Certain Circumstances . Upon termination of the PPA, this Agreement may be terminated by either Party upon written notice to the other Party and without further recourse, except where the PPA is terminated: (i) due to an Event of Default by Distribution Company as defined in the PPA, or (ii) by mutual agreement of the parties to the PPA.
Section 3.4 Termination Payments .
(a) Within sixty (60) days following the termination of this Agreement pursuant to Section 3.3 , Owner shall deliver to Distribution Company an invoice that sets forth Owner’s good faith estimate of the amounts owed to Owner by Distribution Company under Section 3.3 , or Distribution Company shall deliver to Owner an invoice that sets forth Distribution Company’s good faith estimate of the amounts owed to Distribution Company by Owner under Section 3.3 . The recipient of such invoice shall pay the amounts set forth in such invoice within thirty (30) days following its receipt of such invoice. Either Party may deduct and setoff payment of such amounts against any accrued but unpaid payment obligation of the payee to such Party hereunder. Upon the other Party’s request, the invoicing Party shall provide documentation describing the basis for the amounts invoiced in reasonable detail.
20
(b) The Parties acknowledge and agree that the payment of amounts by the defaulting Party to the non-defaulting Party pursuant to Section 3.3 or this Section 3.4 is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for the termination of this Agreement are difficult or impossible to determine and that the damages calculated under Section 3.3 or this Section 3.4 (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to the non-defaulting Party as a result thereof.
Section 3.5 Effect of Termination . Except as provided in Section 3.3 and in Section 23.13 for the survival of provisions, upon expiration or other termination of this Agreement pursuant to its terms, each of the Parties shall be released from all of its obligations under this Agreement, other than any accrued but unpaid payment obligation. Notwithstanding the foregoing sentence, upon such expiration or termination of this Agreement, either Party shall have the right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by such Party to recover any amounts owed to such Party by the other Party hereunder or to secure the release of any security or performance assurance provided by or on behalf of such Party after the later to occur of the end of the Term or the date on which any accrued but unpaid payment obligation of such Party to the other Party hereunder shall have been fully, finally and indefeasibly satisfied.
Article IV
COMMERCIAL OPERATION
Section 4.1 Critical Milestones .
(a) Subject to Sections 4.1(c) , 4.1(d) and 4.1(e) , commencing on the Effective Date, Owner shall develop the NECEC Transmission Line in order to achieve the milestones set forth in clauses (i), (iii)-(v), and (vii) below, and use commercially reasonable efforts to cause HQUS to develop the Québec Line in order to achieve the milestones set forth in clauses (ii) and (vi) below (each clause, a “ Critical Milestone ”) on or before the dates set forth in this Section 4.1(a) :
(i) Receipt of all Owner Approvals (other than the Municipal Owner Approvals) and AC Upgrade Approvals in final form by the Approval Deadline;
(ii) Receipt of all Canadian Approvals in final form by the Canadian Approval Deadline;
(iii) Receipt of the Municipal Owner Approvals in final form by the Municipal Owner Approval Deadline;
(iv) Closing of any financing required for the construction and operation of the NECEC Transmission Line or other demonstration to Distribution Company’s reasonable satisfaction of the financial capability of Owner to construct the NECEC Transmission Line, including, as applicable, Owner’s financial obligations with respect to interconnection of the NECEC Transmission Line and construction of the AC Upgrades and the CCIS Capacity Upgrades, by the Financing Deadline; and
21
(v) Execution by Owner and a contractor of an agreement for the engineering, procurement, and construction of the converter station at the southern end of the HVDC Line and payment by Owner to the contractor of an initial payment of at least 5% of the total price of the agreement, both by the Converter Station Contract Deadline;
(vi) Execution by Hydro-Québec Equipment, a division of Hydro-Québec, of a contract that provides for the engineering, procurement, or construction of the converter station associated with the Québec Line by the Québec Converter Station Contract Deadline;
(vii) Achievement of the Commercial Operation Date by the Target Date.
(b) Except for the achievement of the Commercial Operation Date, which shall be governed by the provisions of Section 4.2 , Owner shall provide Distribution Company (or, in the case of clause (ii), use commercially reasonable efforts to cause HQUS to provide Distribution Company) with written notice of the achievement of each Critical Milestone as set forth in Attachment B within seven (7) days after that achievement, which notice shall include information demonstrating with reasonable specificity that such Critical Milestone has been achieved. Owner acknowledges that Distribution Company will receive such notice solely to monitor progress toward the Commercial Operation Date, and Distribution Company shall not have any responsibility or liability for the development, construction, operation and maintenance of the NECEC Transmission Line or the Québec Line.
(c) Subject to Sections 4.1(e) and 4.2 , Owner may extend all of the dates for the Critical Milestones not yet achieved under this Agreement by up to four (4) six-month periods for a maximum combined period of two (2) years from the dates originally established in Section 4.1(a) . Owner shall post Credit Support (in addition to the Owner Security and the Twenty-One Million, Eight Hundred Thousand Dollars ($21,800,000) of security delivered to Distribution Company and the other RFP Sponsors by HQUS pursuant to the PPA and the Additional PPAs) in an amount equal to $5,000 per MW of the PPA Contract Maximum Amount for each such six-month period, with a pro-rata adjustment of the amount of any such additional Credit Support for any partial reduction of the applicable six-month period pursuant to Section 4.1(e) . Any such election shall be made in a written notice to Distribution Company on or prior to the first date for a Critical Milestone that has not yet been achieved (as such date may have previously been extended). Such notice shall include a detailed explanation of the reasons for the delay, why the delay could not be avoided and the impact on Owner’s Construction Schedule and the expected Commercial Operation Date. Distribution Company shall have the right to request and receive information from Owner regarding such explanation. Such additional Credit Support shall be provided by Owner if there is an Owner Delay or an HQUS Delay and Owner wishes (or is required under the HQUS TSA) to extend any Critical Milestone date. Any additional Credit Support provided under this Section 4.1(c) shall be returned to Owner upon the Commercial Operation Date; provided that, in the event the Commercial Operation Date is not achieved by the Target Date, Distribution Company shall have the rights and remedies set forth in Article XIV , which, for the avoidance of doubt, shall include recourse against any Credit Support posted by Owner.
22
(d) To the extent a Force Majeure event pursuant to Section 15.1 has occurred that prevents Owner from achieving the Critical Milestone dates for execution of the contract for the purchase by Owner of the Converter Station ( Section 4.1(a)(v) ) or the Commercial Operation Date ( Section 4.1(a)(vii) ), or prevents the achievement of the Québec Converter Station milestone ( Section 4.1(a)(vi) ), by the applicable Critical Milestone date, the Critical Milestone date(s) impacted by such Force Majeure event shall be extended for the duration of the Force Majeure event, but under no circumstances shall extensions of those Critical Milestone dates exceed twelve (12) months beyond the applicable Critical Milestone date; provided that Owner shall not have the right to declare a Force Majeure event related to the Critical Milestone for Owner Approvals ( Section 4.1(a)(i) ), Canadian Approvals ( Section 4.1(a)(ii) ), Municipal Owner Approvals ( Section 4.1(a)(iii) ), or the financing Critical Milestone ( Section 4.1(a)(iv) ).
(e) In the event of a Regulatory Approval Delay, the date for each Critical Milestone not yet achieved shall be extended for the duration of the delay. The number of days of extension pursuant to the six-month extensions available under Section 4.1(c) shall be reduced by one day for each day of Regulatory Approval Delay pursuant to this subsection (e) up to a maximum reduction of 365 days. For purposes of illustration, Regulatory Approval Delay of two hundred ten (210) days would allow Owner two six-month extensions and one extension of five months .
Section 4.2 Commercial Operation Date .
(a) The “ Target Date ” for Commercial Operation is December 13, 2022 (as the same may be extended in accordance with Sections 4.1(c) , 4.1(d) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing. Absent written agreement by the Parties, the Target Date may not be extended beyond December 13, 2024 unless such extension is due to Regulatory Approval Delay or an event of Force Majeure as set forth in Sections 4.1(d) and 4.1(e) . The provisions of Sections 4.1(c) , 4.1(d) , and 4.1(e) and all other provisions of this Agreement are subordinate to this Section 4.2 (a) and the aforesaid Section 4.1 provisions and such other provisions shall be construed in a manner that is consistent with this Section 4.2(a) . Owner shall provide a written non-binding notice to Distribution Company no later than sixty (60) days before the date Owner reasonably expects the Commercial Operation Date to occur.
(b) At the request of Owner made in writing, Distribution Company shall cooperate with Owner, TransÉnergie and ISO-NE to support the Commissioning of the HVDC Transmission Project.
(c) As soon as practicable after Owner is of the opinion that the conditions to Commercial Operation, as set forth in Section 4.3 , have been satisfied, or such conditions have been waived in writing by the Parties (except in the case of Section 4.3(b) , Section 4.3(e) , Section 4.3(g) and Section 4.3(h) , which conditions may be waived in writing by Distribution Company, in its sole discretion), Owner shall deliver a written notice to Distribution Company specifying the date upon which Commercial Operation shall commence (the “ COD Notice ”), which commencement date shall occur no earlier than ten (10) Business Days after the receipt by Distribution Company of the COD Notice or on such other date as agreed upon by the Parties in writing (such date, the “ Commercial Operation Date ”).
23
(d) Within five (5) Business Days after the receipt by Distribution Company of the COD Notice, Distribution Company shall deliver a certificate to Owner either (i) confirming that the conditions set forth in Section 4.3 have been satisfied or duly waived and that Commercial Operation may commence on the Commercial Operation Date or (ii) objecting with reasonable detail to the COD Notice. Distribution Company’s failure to respond in writing to a COD Notice within such five (5) Business Day period shall be deemed to be a confirmation that the conditions set forth in Section 4.3 have been satisfied or duly waived. Any Dispute over whether or not the conditions set forth in Section 4.3 have been satisfied or duly waived shall be resolved in accordance with Article XVII .
Section 4.3 Conditions Precedent to Commercial Operation . The items set forth in clauses (a) through (i) below shall be conditions precedent to the Commercial Operation of the NECEC Transmission Line:
(a) Completion of the Commissioning of the HVDC Transmission Project by Owner (in coordination with ISO-NE) and TransÉnergie;
(b) The NECEC Transmission Line has been constructed in accordance with Attachment A and Good Utility Practice, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(b) ;
(c) Completion of the AC Upgrades and the CCIS Capacity Upgrades;
(d) The Interconnection Agreements shall be in full force and effect;
(e) The Transmission Operating Agreement shall be in full force and effect and ISO-NE shall have informed Owner that ISO-NE (i) is prepared to assume operational control over the NECEC Transmission Line, as defined in, and in accordance with, the Transmission Operating Agreement and (ii) will assume such operational control as of the Commercial Operation Date;
(f) The Québec Line has been constructed in accordance with Attachment A, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(b) ;
(g) Receipt by Distribution Company of copies of certificates evidencing all outstanding insurance required or otherwise obtained under Section 5.3 ; and
(h) Receipt by Distribution Company of an opinion of legal counsel, reasonably satisfactory to Distribution Company, that all Governmental Approvals and Third Party Consents required to own and operate the NECEC Transmission Line have been obtained.
24
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation .
Section 4.4.1 Owner Delay . If, other than solely as a result of an HQUS Delay, Force Majeure, or Concurrent Delay, any conditions set forth in Section 4.3 shall not have been satisfied or duly waived by the Target Date (such delay, an “ Owner Delay ”):
(a) Distribution Company shall have the right to recover from Owner, and Owner shall pay or reimburse to Distribution Company, for each day (or part thereof) following the Target Date during which the Owner Delay is continuing, an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Distribution Company terminates this Agreement under Section 14.4 hereof, and (z) the date that is twelve (12) months after the Target Date.
(b) Design Capacity Shortfall .
(i) As of the Commercial Operation Date . In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line or the Québec Line is only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line and the Quebec Line are capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service hereunder, or (B) the NECEC Transmission Line and the Quebec Line are capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service hereunder (such consent not to be unreasonably withheld, conditioned, or delayed), then Owner shall have twenty-four (24) months from the Commercial Operation Date to attempt to increase such operating capacity to 1,090 MW (the “ Remediation Period ”), and Owner shall pay to Distribution Company, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period, or such earlier date designated by Owner in writing to Distribution Company (the “ Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and such operating capacity as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Distribution Company to Owner. Distribution Company’s payments shall be based on the actual operating capacity of the NECEC Transmission Line, as is stated in Section 8.1 .
(ii) Following Remediation . If, on the earlier of Remediation Date or the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW, then this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line, the Contract Capacity shall be deemed modified accordingly, and the rate used to calculate the Transmission Service Payment will be reduced pro rata to reflect the capacity shortfall below 1,090 MW. For illustrative purposes, if following the earlier of the Remediation Date or the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line is 1,080 MW, which will be the Contract Capacity from then onwards, the Transmission Service Payment rate for the remainder of the Term shall be reduced to the Transmission Service Payment rate then in effect multiplied by 1,080/1,090, and that rate shall be multiplied by the Contract Capacity of 1,080 MW to determine the Transmission Service Payment.
25
(iii) An Owner Default shall be deemed to have occurred pursuant to Section 14.2(c) if (A) as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are not both capable of operating at or above 1,040 MW, and Distribution Company has not agreed in writing to begin transmission service hereunder notwithstanding such operating capability, or (B) as of the earlier of the Remediation Date or the end of the Remediation Period, the NECEC Transmission Line and the Québec Line are not both capable of operating at or above 1,075 MW.
(c) Without any limitation of Section 4.4.2 , the Parties acknowledge and agree that the payment of amounts by Owner to Distribution Company under clauses (a) and (b) above, respectively, are an appropriate remedy and that any such modification or payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for an Owner Delay or a reduction in operating capacity, as described in clause (b), are difficult or impossible to determine and that the damages calculated hereunder (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
(d) Without any limitation of Section 4.4.2 , the rights provided in Section 3.3.5 and this Section 4.4.1 shall collectively be the sole and exclusive remedies of Distribution Company with respect to an Owner Delay or a reduction in operating capacity, as described in clause (b). The foregoing sentence shall not be construed in any way to limit (i) Distribution Company’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, or (ii) Distribution Company’s rights to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1 .
Section 4.4.2 Concurrent Delays .
(a) In the event of a concurrent HQUS Delay and Owner Delay (a “ Concurrent Delay ”), for each day (or part thereof) during which a Concurrent Delay is continuing, Owner will pay to Distribution Company an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (w) the date on which either the Québec Line or the NECEC Transmission Line is capable of commercial operation but for the other Party’s delay, (x) the Commercial Operation Date, (y) the date on which Distribution Company terminates this Agreement under Section 14.4 hereof, and (z) twelve (12) months after the Target Date.
(b) The Parties acknowledge and agree that the payment of amounts by Owner to Distribution Company under clause (a) above is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Concurrent Delay are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
(c) The rights provided in Section 3.3.3 and this Section 4.4.2 shall collectively be the sole and exclusive remedies of Distribution Company with respect to a Concurrent Delay. The foregoing sentence shall not be construed in any way to limit (i)
26
Distribution Company’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, or (ii) Distribution Company’s rights to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1 .
Article V
GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES
Section 5.1 Responsibilities of the Parties .
Section 5.1.1 Construction Phase .
(a) During the Construction Phase, Owner shall (i) exercise Good Utility Practice to complete, or cause the completion of, all tasks required to construct the NECEC Transmission Line, interconnect at least 1,090 MW of capacity with ISO-NE in compliance with the Capacity Capability Interconnection Standard, and achieve Commercial Operation by the Target Date, in each case, in accordance with the Design Capability and in a manner consistent with Attachment A and (ii) use commercially reasonable efforts to obtain all of the Construction Authorizations (other than the Municipal Owner Approvals) by the Approval Deadline, (B) to obtain, in consultation with Distribution Company, the ISO-NE Approval by the Approval Deadline and (C) to cause Owner’s Affiliates that are AC Upgrade Owners to obtain any AC Upgrade Approvals for which such Affiliates are responsible by the Approval Deadline and to assist other AC Upgrade Owners in obtaining their respective AC Upgrade Approvals by the Approval Deadline.
(b) Owner will use commercially reasonable efforts to enter into, within a commercially reasonable timeframe, one or more Construction Contracts. Owner will make a copy of any such contract available to Distribution Company subject to such redactions as Owner or the contracting party deem necessary to protect confidential information.
Section 5.2 Schedules and Reports .
Section 5.2.1 Owner’s Preliminary Schedule . Attached hereto as Attachment E is Owner’s Project Schedule (the “ Owner’s Preliminary Schedule ”). At the request of Distribution Company, Owner shall make the personnel responsible for preparing the Owner’s Preliminary Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Preliminary Schedule with Distribution Company.
Section 5.2.2 Owner’s Construction Schedule . Within ten (10) days after the end of each calendar quarter and sooner if a material change occurs, commencing at least ninety (90) days prior to the commencement of construction, Owner shall prepare and submit to Distribution Company for review an update of the Owner’s Preliminary Schedule (such updated schedule as established herein, the “ Owner’s Construction Schedule ”). At the request of Distribution Company, Owner shall make the personnel responsible for preparing the Owner’s Construction Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Construction Schedule with Distribution Company.
27
Section 5.2.3 Owner’s Progress Reports .
(a) Promptly following the Execution Date, Owner shall deliver to Distribution Company copies of all applications that have been submitted by Owner with respect to any Owner Approvals, as well as all material correspondence and submittals relating to such Owner Approvals. Within ten (10) days after the end of each calendar quarter, commencing at receipt of the Regulatory Approval, Owner shall prepare and submit to Distribution Company for review a progress report for informational purposes that sets forth in reasonable detail the current status of the milestones set forth in the Owner’s Construction Schedule, including any changes in the expected timelines and the status of all Owner Approvals and including copies of any Owner Approval applications, material correspondence and submittals relating to Owner Approvals, and any issued Owner Approvals (the “ Owner’s Construction Progress Report ”). Without limitation of the foregoing, Owner shall include in such reports relevant information relating to: (i) Owner’s efforts to mitigate the impacts of the NECEC Transmission Line on natural resources, environmentally sensitive areas, habitats, and wildlife species, and cultural and historic resources; (ii) Owner’s efforts to comply with applicable noise ordinances; (iii) and Owner’s communication and community outreach efforts and plans with respect to the construction of the NECEC Transmission Line, including with stakeholders in Massachusetts. At the request of Distribution Company, Owner shall, or shall cause each contractor to, provide Distribution Company with access to, and copies of, all reasonably requested documentation concerning such Owner’s Construction Progress Report.
(b) Owner shall, or shall cause the principal contractor to, notify Distribution Company promptly, but in no event later than ten (10) days, after Owner, or such contractor, becomes aware that the Commercial Operation of the NECEC Transmission Line is not reasonably likely to occur by the Target Date.
Section 5.3 Insurance and Events of Loss . Owner shall obtain and maintain with reputable insurers authorized to operate in the scope of the Agreement insurance of the type set forth in Attachment F. Owner shall provide Distribution Company with copies of certificates of all outstanding insurance obtained hereunder promptly after the receipt thereof by Owner. Owner shall notify Distribution Company as soon as reasonably possible if and whenever an event of loss occurs. Without limitation of any obligations Owner may have under Section 15.1 hereof, in the event of damage to or loss of all or part of the NECEC Transmission Line, Owner shall exercise prompt, diligent commercially reasonable efforts to effectuate, in accordance with Good Utility Practice, such repairs and replacements as are necessary or desirable to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss, including, for the avoidance of doubt, the application to such repairs or replacements of any potential or actual proceeds realized in connection with such damage or loss under any available or applicable insurance policies (subject to insurance contract/policy terms and conditions of coverage) maintained pursuant to this Section 5.3 . Subject to Owner’s compliance, in all material respects, with this Section 5.3 , Section 6.3 and all other material terms and conditions with respect to the operation and maintenance of the NECEC Transmission Line, in the event that the costs to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss exceed the available insurance proceeds by more than the greater of (a) an amount equal to three percent (3%) of the Net Book Value of the NECEC Transmission Line and (b) Thirty Million Dollars ($30,000,000), the Parties will negotiate in good faith an appropriate allocation of financial responsibility for such excess costs. In the event that the Parties do not agree on the allocation of
28
financial responsibility, Distribution Company shall be entitled to terminate this Agreement, upon thirty (30) days’ written notice to Owner, without liability to Owner; provided that, if within the thirty (30) day period following receipt of such notice, Owner agrees to assume that portion of the allocation of financial responsibility to which Distribution Company objected, then the termination notice shall be deemed revoked and this Agreement shall not be terminated.
Section 5.4 Compliance with Laws . At all times during the Term, the Parties shall comply with all Applicable Laws (including ISO-NE Rules to the extent applicable) and relevant Governmental Approvals and Third Party Consents.
Section 5.5 Third Party Contracts .
Section 5.5.1 At all times during the Term, Owner shall, in a commercially reasonable manner, (a) satisfy its obligations under all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades, and (b) administer all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades.
Section 5.5.2 Unless it obtains the prior written consent of Distribution Company (such consent not to be unreasonably withheld, conditioned or delayed) , Owner shall not: (i) agree to any amendment to Sections 3.3.5 , 14.3 , 14.6 , 14.7 , 14.8 , and 14.10 of the HQUS TSA, or (ii) agree to an amendment and restatement, replacement, supplement, or other modification or amendment of the HQUS TSA that adversely and materially affects Distribution Company’s rights under this Agreement or the PPA. Owner shall provide to Distribution Company a copy of any proposed amendment to the HQUS TSA not fewer than ten (10) Business Days prior to the execution thereof.
Section 5.6 Continuity of Rights and Responsibilities . Unless otherwise agreed in writing by the Parties or prohibited by Applicable Law, the Parties shall continue to provide service and honor commitments under this Agreement and continue to make payments in accordance with this Agreement pending resolution of any bona fide Dispute hereunder or relating hereto.
Article VI
PROCEDURES FOR OPERATION AND MAINTENANCE
OF THE NECEC TRANSMISSION LINE
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control .
(a) Prior to entering into the Transmission Operating Agreement, Owner shall consult Distribution Company with respect to the proposed terms and conditions thereof and Owner shall make a good faith effort to take into account any comments made by Distribution Company. Distribution Company shall promptly provide comments, if any, to Owner on such terms and conditions.
(b) As of the Commercial Operation Date, Owner shall transfer operational control over the NECEC Transmission Line, as defined in the Transmission Operating Agreement, to Transmission Operator in accordance with the Transmission Operating Agreement. Owner shall provide, and shall direct its Affiliates to provide, such
29
information as Transmission Operator may require to discharge its obligations under the Transmission Operating Agreement, and Owner shall comply with the instructions of Transmission Operator to the extent provided in the Transmission Operating Agreement and the ISO-NE Tariff. The Parties acknowledge and agree that Owner shall not be in breach of, or be liable to Distribution Company under, this Agreement, and no Owner Default shall occur, as a consequence of Owner’s compliance with such instructions of Transmission Operator; provided that Owner did not initiate or support instructions that would otherwise breach Owner’s obligations under this Agreement.
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements . From and after the Commercial Operation Date, Owner shall (a) provide Firm Transmission Service, (b) operate and maintain the NECEC Transmission Line in accordance with Good Utility Practice and in compliance with all applicable regulatory requirements, including applicable NERC and Northeast Power Coordinating Council reliability standards, and (c) comply with all applicable operating instructions of ISO-NE and manufacturers’ warranties.
Section 6.3 Scheduled Maintenance . With respect to each calendar year (or portion thereof) following the Construction Phase, Owner will prepare and deliver to Distribution Company a Maintenance Plan not later than the Commercial Operation Date and two (2) months prior to the end of each calendar year thereafter during the Operation Phase, and shall be available for consultation with Distribution Company with respect thereto (including for coordination of maintenance schedules). Consistent with Good Utility Practice, Owner shall use commercially reasonable efforts to coordinate with TransÉnergie with respect to scheduled maintenance so as to minimize outages, including by meeting annually (or as otherwise necessary in order to comply with any applicable ISO-NE or Canadian regulatory or system operator requirements) to develop a Maintenance Plan. Throughout the Operation Phase, Owner shall coordinate all planned maintenance with ISO-NE, consistent with ISO-NE Rules, and shall promptly provide applicable information concerning scheduled outages, as determined by ISO-NE, to Distribution Company. To maximize value, to the extent possible and consistent with ISO-NE Rules, Owner shall not schedule maintenance of the NECEC Transmission Line during the months of December, January and February or June through September and shall operate the NECEC Transmission Line so as to maximize energy production during the hours of anticipated peak load and energy prices in New England; provided, however, that planned maintenance may be scheduled during such period to the extent the failure to perform such planned maintenance is contrary to operation of the NECEC Transmission Line in accordance with Good Utility Practice. Owner may modify a Maintenance Plan in accordance with Good Utility Practice; provided, however, that (a) a Maintenance Plan may not be modified for the purpose of reducing the magnitude or duration of a Non-Excused Outage, (b) any modification shall, to the extent commercially reasonable, maximize value in the manner described in this Section 6.3 , and (c) Owner shall provide Distribution Company with reasonable notice of any change in a Maintenance Plan. Any maintenance that is not included in the Maintenance Plan for a year and is not otherwise excused under Section 7.2 shall be a Non-Excused Outage.
30
Article VII
DISTRIBUTION
COMPANY’S TRANSMISSION RIGHTS OVER THE
NECEC TRANSMISSION LINE
Section 7.1 Transmission Service .
Section 7.1.1 Firm Transmission Service . Owner shall make available to Distribution Company, from and after the Commercial Operation Date through the end of the Term, transmission capacity on the NECEC Transmission Line in order to deliver electrical energy, as scheduled by Distribution Company or its designee or assignee under the resale provisions of Article X , in such scheduled amount up to the Contract Capacity, measured at the Delivery Point (“ Firm Transmission Service ”). Firm Transmission Service shall be made available over the NECEC Transmission Line at any time from and after the Commercial Operation Date, in a north-to-south direction, and to the extent available in a south-to-north direction, between the U.S. Border and the Delivery Point. Firm Transmission Service shall be subject to curtailment or interruption only as a result of an Excused Outage or as provided in Section 14.3(b) . Without limiting Owner’s obligations under this Section 7.1.1 , the quantity of Firm Transmission Service that Owner will provide in any hour shall not exceed the Proportionate Share of the Available Transfer Capability for such hour.
Section 7.1.2 Limitation on Transmission Service . Owner shall have no obligation to provide transmission service under this Agreement other than Firm Transmission Service. Distribution Company shall have no right to redirect service to alternate points of delivery or receipt on any portion of the transmission system operated by ISO-NE other than the NECEC Transmission Line.
Section 7.1.3 Scheduling . All Firm Transmission Service shall be scheduled in accordance with the rules relating to the scheduling of electrical energy or capacity transactions over the NECEC Transmission Line, as established under the Transmission Operating Agreement (the “ Scheduling Rules ”).
Section 7.1.4 Owner’s Cooperation . Owner shall provide Distribution Company with notice of any FERC or NERC regulatory proceedings relating to the NECEC Transmission Line or this Agreement to which Owner is a party promptly after Owner becomes aware of any such proceedings. Each Party will act in good faith regarding any such proceedings. Neither Party shall take any position in such proceeding that is contrary to such Party’s obligations under this Agreement.
Section 7.2 Excused Outages or Reductions .
(a) Notwithstanding anything herein to the contrary, Owner shall not be in breach of, or be liable to Distribution Company for any losses or damages under, this Agreement, and no Owner Default shall occur, as a consequence of an Excused Outage. “ Excused Outages ” means any outages of the NECEC Transmission Line, or reductions in the Total Transfer Capability below the NECEC Transmission Line Capacity, whether as a result of a physical condition, legal impediment or otherwise, if and to the extent such outage or reduction is due to:
(i) Events of Force Majeure;
31
(ii) Scheduled maintenance in accordance with the applicable Maintenance Plan;
(iii) Outages or reductions in the availability of the Québec Line for any reason; or
(iv) Decisions of ISO-NE or any other independent system operator to reduce or suspend scheduling rights over the NECEC Transmission Line or the Quebec Line, including as a result of any grid reliability issue, emergency condition as defined in any Interconnection Agreement or the ISO-NE Tariff, or to preserve facilities and equipment from physical damage and including any such decisions that arise from outages or reductions in the use or availability of transmission lines other than the NECEC Transmission Line or the Québec Line, which outage or reduction arises from or is attributable to Force Majeure or scheduled maintenance.
(b) Notwithstanding anything in Section 7.3.1 to the contrary, Distribution Company shall remain obligated, during and to the extent of any Excused Outage to pay the Transmission Service Payment without downward adjustment to reflect any such outage, reduction, or delay. Owner shall seek to avoid, mitigate and remedy any Excused Outage consistent with Good Utility Practice.
(c) Notwithstanding anything herein to the contrary and without regard to whether an Excused Outage is due to Force Majeure, if an Excused Outage prevents Owner’s full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, Distribution Company shall have the right, as provided in Section 15.1(c) herein, to terminate this Agreement upon written notice to Owner and without further recourse.
Section 7.3 Non-Excused Outages or Reductions .
Section 7.3.1 Reduction in Transmission Service Payments . In the event the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 , the Transmission Service Payment for such period shall be reduced in accordance with Section 8.1 . Any Dispute over whether or not or to what extent a Non-Excused Outage has occurred shall be resolved in accordance with Article XVII . Owner shall seek to avoid, mitigate and remedy any Non-Excused Outage consistent with Good Utility Practice.
Section 7.3.2 Liquidated Damages . The Parties acknowledge and agree that the modification of Distribution Company’s payment obligations pursuant to Section 8.1 is an appropriate remedy and that any such modification does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Non-Excused Outage are difficult or impossible to determine and that the damages calculated hereunder (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
32
Section 7.3.3 Sole and Exclusive Remedy . The rights provided in Section 3.3.5 , this Section 7.3 , and Section 14.4 shall collectively be the sole and exclusive remedies of Distribution Company with respect to a Non-Excused Outage, subject to (a) Distribution Company’s right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, (b) Distribution Company’s right to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1 , or (c) Distribution Company’s rights on an Owner Event of Default as described in Section 14.2 .
Section 7.4 Allocation of Outages . The Parties expressly intend and agree that any outages or reductions in Total Transfer Capability shall be borne first by HQUS and by all transmission rights holders served by the NECEC Transmission Line (including Owner, if applicable) other than Distribution Company and the other RFP Sponsors, and that any remaining reduction shall be allocated among Distribution Company and the other RFP Sponsors in accordance with their respective Proportionate Shares. Owner acknowledges and agrees that it will not reduce the Firm Transmission Service available to Distribution Company except in accordance with the foregoing priority and will not reduce the Firm Transmission Service available to Distribution Company in an unduly discriminatory manner as compared with any other transmission rights holder served by the NECEC Transmission Line (including Owner, if applicable). For purposes of clarity, HQUS’s transmission service under the Additional HQUS TSA shall be reduced before any reductions are applied to Distribution Company’s transmission service under this Agreement.
Section 7.5 Metering . Metering and telemetering requirements for the NECEC Transmission Line shall be established by Owner in accordance with Good Utility Practice and as necessary to (a) accomplish the purposes of, and to implement and administer, this Agreement and (b) satisfy the requirements of, and to implement and administer, the PPA, the Interconnection Agreement and the Transmission Operating Agreement.
Section 7.6 Line Availability Information and Reporting . Owner shall make available to Distribution Company on a real time basis information relating to the operation and availability of the NECEC Transmission Line and shall provide such additional information as Distribution Company shall reasonably request.
Article VIII
PAYMENTS FOR TRANSMISSION SERVICE OVER THE
NECEC TRANSMISSION LINE
Section 8.1 Transmission Service Payments . During the Operating Phase, except to the extent such payment is excused or reduced pursuant to the terms of this Agreement, Distribution Company shall pay to Owner a transmission service payment (the “ Transmission Service Payment ”) on a monthly basis in an amount calculated as set forth in Attachment J pursuant to invoices delivered by Owner to Distribution Company; provided, however, that, in the event Regulatory Approval does not occur by January 25, 2019, the Transmission Service Payment shall increase 0.18333% per month for each full month following January 25, 2019 until such Regulatory Approval is received. The Transmission Service Payments shall be reduced in accordance with the formula set forth in Attachment G in the event and to the extent that the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non - Excused Outage is less than the Minimum Average
33
Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 , and the rate ($/MW) shall be adjusted in accordance with Section 4.4.1(b)(ii) . Pursuant to Section 13.2 , to the extent there is a Dispute over whether or not or to what extent a Non-Excused Outage has occurred, the reduction in the Transmission Service Payments shall be implemented upon the resolution of that Dispute and such reduction will be effective as of the date when such Dispute arose . Such adjustments shall be made on a monthly basis pursuant to invoices delivered by Owner to Distribution Company.
Section 8.2 Elective Upgrade Status; No Regional Rates . It is the intent of the Parties that the NECEC Transmission Line has Elective Transmission Upgrade status during the Term and that the AC Upgrades and the CCIS Capacity Upgrades constitute Network Upgrades under the ISO-NE Tariff required to accommodate the interconnection of the NECEC Transmission Line. It is the further intent of the Parties that Owner’s recovery of the investment in and return on the NECEC Facilities and the Distribution Company’s obligation to pay for the NECEC Facilities shall be solely governed by this Agreement. The Parties each shall refrain from taking steps to include all or part of the NECEC Facilities in ISO-NE regional transmission rates during the Term and for a period of twenty (20) years thereafter. Notwithstanding the foregoing, if during the Term all or part of the NECEC Facilities are included in ISO-NE regional rates paid by the Distribution Company, the payment required by Section 8.1 shall be reduced by the Proportionate Share of the revenues received by Owner from such ISO-NE rates with respect to the NECEC Facilities. “ NECEC Facilities ” means the NECEC Transmission Line, the AC Upgrades, and the CCIS Capacity Upgrades.
Article IX
RIGHTS UPON EXPIRATION OF TERM
Section 9.1 Rollover and Other Rights . Distribution Company hereby irrevocably waives any rollover rights it may have at the end of the Term in accordance with Order No. 890 et seq. and the FERC pro forma open access transmission service tariff, as such rights are defined as of the Effective Date.
Article X
TRANSFER AND RESALE OF TRANSMISSION RIGHTS
Section 10.1 Transfer of Transmission Rights . Owner conveys to Distribution Company all rights to and title and interest in the use of the Distribution Company’s Proportionate Share of NECEC Transmission Line Capacity and Distribution Company has entered into the PPA, pursuant to which Distribution Company transfers, assigns and conveys to HQUS during the Term all of Distribution Company’s rights, title and interest in and to the Firm Transmission Service, Other Transmission Rights, and Market Products in respect of HQUS’s delivery obligations under the PPA .
34
Section 10.2 Resale Rights . In the PPA, HQUS has acknowledged that if and to the extent HQUS determines from time to time, and in its sole discretion, that the transmission capacity available to HQUS relevant to the receipt of Firm Transmission Service over the NECEC Transmission Line pursuant to this Agreement exceeds HQUS’s needs, HQUS will then offer to resell such unused capacity to third parties in accordance with Applicable Law as may then be in effect (including the terms and conditions of FERC Order No. 890 et seq. , if applicable).
Section 10.3 Capacity Releases for Daily and Hourly Use . From and after the Commercial Operation Date, if and to the extent the Proportionate Share of the Available Transfer Capability exceeds the amount of electrical energy that is scheduled by Distribution Company (or its assignee) for delivery over the NECEC Transmission Line using Firm Transmission Service by the applicable scheduling deadline (as in effect at such time) established pursuant to the Scheduling Rules, then the transmission capacity that is available for resale to third parties for the following day, and the price at which any such resales are offered, shall be posted on the OASIS site established pursuant to Section 10.4 .
(a) Owner or an Affiliate of Owner (in such capacity, the “ OASIS Administrator ”) shall establish an OASIS site for the NECEC Transmission Line and administer such site in accordance with applicable FERC requirements for the establishment and administration of OASIS sites. None of Owner, the OASIS Administrator or Distribution Company (or its assignee) shall be liable to each other or any third party for any decisions the OASIS Administrator makes regarding the appropriate price for resales of unused transmission capacity or the level of any such resales the OASIS Administrator is able to make. The Parties agree that there shall be no damages as between each other or third parties for actions by the OASIS Administrator with respect to resales of unused transmission capacity.
(b) To the extent resales are made available by Distribution Company (or its assignee) pursuant to Section 10.2 , the OASIS Administrator shall post on the OASIS site information regarding such resales, (i) in accordance with written instructions provided by Distribution Company (or its assignee) from time to time and (ii) at a price established by Distribution Company (or its assignee) from time to time, and in its sole discretion, as permitted under Applicable Law.
Section 10.5 Proceeds from Capacity Releases and Transmission Resales . Except as otherwise provided in Section 14.3(b), Distribution Company’s Proportionate Share of the proceeds received by Owner of any capacity releases and transmission resales of transmission capacity assigned to HQUS under Section 20 of the PPA and the Additional PPAs that are made during the Operation Phase shall be credited, net of reasonable fees (including attorneys’ fees) and other expenses incurred in connection with performance of the functions described in Section 10.3 and Section 10.4 , against any Transmission Service Payment or other amounts owed to Owner by Distribution Company for the calendar month subsequent to the calendar month in which such proceeds were received.
Section 10.6 Owner’s Rights and Obligations . Except as expressly provided in the Proposal Agreements, Owner shall have no right or obligation to offer any transmission service over the NECEC Transmission Line for sale or resale to any Person other than Distribution Company, as provided herein.
35
Article XI
REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS
Section 11.1 Real Power Losses . Distribution Company shall not be responsible for any Real Power Losses associated with Firm Transmission Service. Owner and HQUS shall be responsible for the delivery of the scheduled amounts of energy associated up to the Contract Capacity to the Delivery Point without reduction for Real Power Losses.
(a) Distribution Company shall be entitled during the Term to its Proportionate Share of the following, without duplication and without additional cost to Distribution Company or compensation to Owner: (i) all Other Transmission Rights associated with the NECEC Transmission Line or the AC Upgrades, in each case, that are issued in accordance with the ISO-NE Tariff or otherwise granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, and (ii) all other Market Products that are issued in accordance with the ISO-NE Tariff or granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, that derive from the acquisition of transmission service over the NECEC Transmission Line. For purposes of this clause (a), the denominator of the “Proportionate Share” shall be the Physical Transmission Line Capacity. As Owner’s sole obligation under this clause (a), upon its receipt of any of the entitlements or rights described in the foregoing sentence, Owner shall promptly convey such entitlements or rights to Distribution Company.
(b) In the event tie benefits or interconnection capability credits (or any similar concept) are ever deemed applicable to the NECEC Transmission Line and to the extent allocated to any Party during the Term, Distribution Company shall be entitled to its Proportionate Share of one hundred percent (100%) of the economic benefits associated therewith (however entitled and whether existing now or in the future), without additional cost to Distribution Company or compensation to Owner. For purposes of this clause (b), the denominator of the “Proportionate Share” shall be the Physical Transmission Line Capacity.
(c) Owner shall have no obligation to support the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above, but Owner may not oppose the creation or establishment of any such right, unless otherwise agreed in writing by Distribution Company. Neither Section 2.5 nor the foregoing sentence shall be construed in any way to limit the right of any Affiliate of Owner to oppose the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above.
36
Article XII
[INTENTIONALLY OMITTED]
Article XIII
BILLING AND PAYMENTS
Section 13.1 Invoices . Within seven (7) Business Days after the first day of each calendar month following the commencement of the Operation Phase, Owner shall submit an Invoice to Distribution Company for the Transmission Service Payments owed for the preceding calendar month, and Distribution Company shall pay the amounts set forth in the Invoice to Owner within fourteen (14) Business Days following its receipt of such Invoice. All payments shall be made in immediately available funds payable to Owner by wire transfer to a bank named by Owner, in accordance with wiring instructions provided to Distribution Company by Owner in writing. Owner shall be entitled to change the place or recipient for payment by thirty (30) days’ prior written notice to Distribution Company.
Section 13.2 Procedures for Billing Disputes .
(a) In the event of any Dispute with respect to the amount owed to Owner by Distribution Company under this Agreement, Distribution Company shall have no right to withhold payment of the Disputed amount pending resolution of the Dispute; provided, however, that, in the event such Dispute is resolved in favor of Distribution Company, Owner shall complete the following tasks consistent with the resolution of such Dispute: (i) retroactively adjust all payments previously made by Distribution Company; (ii) promptly refund all overpayments previously made by Distribution Company, together with interest thereon in immediately available funds or by wire transfer, in each case, in accordance with wiring instructions provided to Owner by Distribution Company in writing; and (iii) thereafter conform all future Invoices to reflect the resolution of such Dispute, as applicable. Distribution Company’s payment of any Disputed amounts shall be without prejudice to any right or remedy that Distribution Company may have under this Agreement to contest any such amount.
(b) Distribution Company shall not have the right to challenge any Invoice or to bring any action of any kind challenging the propriety of any Invoice after the second (2nd) anniversary of the receipt of such Invoice. If an Invoice is not rendered within two (2) years after the end of the calendar month during which such Invoice should have been rendered hereunder, then the right to payment of such Invoice is waived.
Section 13.3 Interest . All interest payable under this Section 13.3 shall be calculated pursuant to 18 C.F.R. § 35.19a(a), as such regulation (or any successor thereto) is in effect during the period during which such interest is due. Amounts not paid when due to Owner or Distribution Company under this Agreement shall bear interest from the date such amount was due until the date of payment of such overdue amount. For the avoidance of doubt, as illustrated in Attachment H, if all or a portion of the amount to which such interest relates is later refunded pursuant to this Agreement, then, in calculating that refund, such interest shall not be included in the refund. Refunds of overpayments owed to Distribution Company by Owner under this Agreement shall begin to accrue interest on the amount subject to refund, as originally invoiced, from the earlier to occur of the due date or the date of payment of the monthly Invoices to which the overpayment relates and shall continue to accrue interest until the date of payment of such refund.
37
Section 13.4 Obligation to Make Payments . The Parties acknowledge and agree that, except as set forth in Section 3.3.8 , Section 8.1 , Section 13.5 and Section 14.4(d) , no cause or event whatsoever shall excuse or suspend Distribution Company’s obligation to pay Transmission Service Payments or any other amounts payable by Distribution Company under this Agreement. The Parties also acknowledge and agree that no cause or event whatsoever shall excuse or suspend any amounts payable by Owner under this Agreement.
Section 13.5 Offsets . Except as otherwise provided in Section 3.4(a) and Section 14.4(d) , neither Party shall be entitled to deduct or set-off payment of any amount owed to the other Party under this Agreement against payment of any amount owing under this Agreement.
Article XIV
EVENTS OF DEFAULT AND REMEDIES
Section 14.1 Distribution Company Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Distribution Company under this Agreement (a “ Distribution Company Default ”), provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (c), clause (d), or clause (e) :
(a) Distribution Company’s failure to pay any undisputed amount due to Owner under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Distribution Company of a written demand from Owner that such amount is due and owing and has not been timely paid.
(b) Distribution Company’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clause (a) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Distribution Company of written notice thereof from Owner, unless such cure shall reasonably require a longer period, in which case Distribution Company shall be provided an additional thirty (30) days to complete such cure so long as Distribution Company has promptly commenced such cure and thereafter diligently pursues such cure.
(c) Any representation or warranty made by Distribution Company in this Agreement is false or misleading at the time made in any material respect.
(d) Any Insolvency Event occurs with respect to Distribution Company.
(e) Any termination of the PPA due to an “Event of Default” by Distribution Company under and as defined in the PPA.
38
Section 14.2 Owner Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Owner under this Agreement (an “ Owner Default ” ) , provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (h), or clause (i) :
(a) Owner’s failure to pay any undisputed amount due to Distribution Company under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Owner of a written demand from Distribution Company that such amount is due and owing and has not been timely paid.
(b) Owner’s failure to satisfy (other than solely as a result of an HQUS Delay) any of the Critical Milestones in clauses (i), (iii), (iv), (v), or (vii) of Section 4.1(a) by the dates set forth therefor, as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) .
(c) The failure of the NECEC Transmission Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date, where Distribution Company has also not agreed in writing to begin transmission service hereunder notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Remediation Date or the end of the Remediation Period.
(d) Owner’s failure to comply in any material respect with the provisions of Section 5.1.1(a)(ii) and, if such failure is susceptible to cure, such failure continues for thirty (30) days after receipt by Owner of written notice thereof from Distribution Company, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(e) A Non-Excused Outage pursuant to which the average Hourly Availability of the NECEC Transmission Line over any calendar month is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , occurs and continues for more than ninety (90) consecutive days or more than one hundred twenty (120) days in any twelve (12) month period, provided, however, that if (i) Owner presents to Distribution Company before the end of a Non-Excused Outage that would otherwise constitute an Owner Default under this clause (e), a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company, acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, and (ii) Owner posts Credit Support (in addition to the Owner Security) in an amount equal to $5,000 per MWh/h of the Contract Maximum Amount for each such six-month portion of such period, Distribution Company shall forbear terminating this Agreement under this clause (e) for such period, provided that, during any such period, Distribution Company’s obligation to make Transmission Service Payments shall continue to be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. Any additional Credit Support provided under this Section 14.1(e) shall be returned to Owner if Owner is providing Firm Transmission Service in full at the end of the
39
period of forbearance. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, an Owner Default shall be deemed to have occurred and Distribution Company shall have the rights and remedies set forth in Section 14.4 , which, for the avoidance of doubt, shall include recourse against any Credit Support posted by Owner.
(f) Owner’s failure to comply in any material respect with the provisions of Article XVI .
(g) Owner’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), (c), (d), (e) or (f) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Owner of written notice thereof from Distribution Company, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(h) Any representation or warranty made by Owner in this Agreement is false or misleading at the time made in any material respect.
(i) Any Insolvency Event occurs with respect to Owner.
Section 14.3 Remedies Upon Distribution Company Default . Upon the occurrence of a Distribution Company Default and at any time thereafter so long as the same is continuing, Owner shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Owner shall elect:
(a) Subject to Section 5.6 hereof and Section 14.8 of the HQUS TSA: (i) in the case of Distribution Company Default under any clause of Section 14.1 other than clause (e), Owner may terminate this Agreement by written notice to Distribution Company, or (ii) in the case of a Distribution Company Default under clause (e) of Section 14.1 , Owner shall terminate this Agreement upon receipt of Distribution’s Company written request.
(b) In the case of a Distribution Company Default pursuant to Section 14.1(a) , and subject to Section 5.6 , Owner may suspend all or part of Owner’s obligations or Distribution Company’s rights under this Agreement during the period during which such Distribution Company Default is continuing. During any such period of suspension occurring after the Commercial Operation Date, (i) Distribution Company shall not be entitled to schedule, and shall not schedule, any transactions over the NECEC Transmission Line, and (ii) Owner shall be obligated, in the event HQUS so elects as provided in the HQUS TSA, to allow HQUS to assume the rights and obligations of Distribution Company under this Agreement during such suspension. If HQUS does not exercise the rights described in clause (ii) of the preceding sentence, (x) the OASIS Administrator shall be directed to post any portion of the transmission capacity that would have otherwise been available to Distribution Company over the NECEC Transmission Line pursuant to this Agreement and to attempt to sell such capacity to one or more third parties consistent with Article X , (y) the proceeds of any capacity releases and transmission
40
resales made pursuant to clause (x) of this sentence and received by Owner, net of reasonable fees (including attorneys’ fees) and other expenses incurred by Owner in connection with this Section 14.3(b) , shall be credited against any accrued but unpaid payment obligation of Distribution Company to Owner hereunder and (z) any such proceeds in excess of such accrued but unpaid payment obligation of Distribution Company shall be credited in accordance with Section 10.5 .
(c) Subject to Article XVIII and this Section 14.3 , as applicable, Owner may recover from Distribution Company the Distribution Company Termination Payment and, to the extent applicable, all other amounts not waived in accordance with Section 3.3.4(c) or, in the absence of a termination pursuant to a Distribution Company Default, all damages suffered by Owner that are due to a Distribution Company Default, including, for the avoidance of doubt, any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Distribution Company under this Agreement.
(d) Owner may exercise any and all other rights and remedies that may be available to Owner against Distribution Company at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Owner shall have no right to (i) terminate this Agreement based upon a Distribution Company Default, except as provided in clause (a) above, or (ii) suspend transmission service under this Agreement based on a Distribution Company Default, except as provided in clause (b) above.
Section 14.4 Remedies Upon Owner Default . Upon the occurrence of an Owner Default and at any time thereafter so long as the same is continuing, Distribution Company shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Distribution Company shall elect:
(a) In the case of an Owner Default, and subject to Section 5.6 hereof, Distribution Company may recover any accrued but unpaid amounts under Section 4.4.1 and Section 4.4.2 and the Owner Termination Payment and (i) in the case of an Owner Default under any clause of Section 14.2 other than clause (c), Distribution Company may terminate this Agreement by written notice to Owner, or (ii) in the case of an Owner Default under clause (c) of Section 14.2 , this Agreement shall automatically be terminated; provided, however, in the event that HQUS exercises its right under the HQUS TSA to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under this Agreement prior to the effective date of such termination, no termination of this Agreement shall occur under this Section 14.4(a) . In the event that HQUS timely exercises such rights, (x) upon receipt of HQUS’s notice that it is exercising such rights, Owner shall promptly notify Distribution Company thereof and (y) upon the effectiveness of HQUS’ purchase or assumption of control of the NECEC Transmission Line and assumption of Owner’s obligations under this Agreement, (A) Distribution Company and HQUS shall enter into such amendments to this Agreement as are reasonably necessary in order to give effect to such rights of HQUS and assumptions of obligations by HQUS that are consistent with the terms and conditions of this Agreement and are subject to applicable regulatory approvals and (B) thereafter HQUS shall perform and Distribution Company shall continue to perform their respective obligations under this Agreement.
41
(b) Subject to the limitations provided in Section 4.4.1(d) , Section 4.4.2(c) , Article XVIII or this Section 14.4 , as applicable, Distribution Company may recover from Owner any accrued but unpaid amounts under Section 4.4.1 and Section 4.4.2 (as applicable) and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement.
(c) Distribution Company may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Credit Support (including, for avoidance of doubt, the Owner Security) held by Distribution Company, and (ii) the right to liquidate any and all Credit Support held by Distribution Company and to apply the proceeds of such liquidation to any amounts payable to Distribution Company with respect to Owner’s obligations hereunder in such order as Distribution Company may elect. Distribution Company may draw on the undrawn portion of any Letter of Credit provided as Credit Support up to the amount of Owner’s outstanding obligations hereunder. Owner shall remain liable for amounts due and owed to Distribution Company that remain unpaid after the application of Credit Support.
(d) Pursuant to Section 13.2 , to the extent there is a Dispute over the amount of the damages suffered by Distribution Company as a result of an Owner Default, Distribution Company may deduct and setoff payment of such amount against any Transmission Service Payment upon the resolution of that Dispute.
(e) Distribution Company may exercise any and all other rights and remedies that may be available to Distribution Company at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Distribution Company shall have no right to (i) terminate this Agreement based upon an Owner Default, except as provided in clause (a) above, or (ii) any reduction of or offset against payments under this Agreement based upon an Owner Default, except as contemplated by Section 8.1 , Section 13.5 and Section 14.4(d) , as applicable.
Abandoned Plant Recovery . Owner may request from FERC recovery of abandoned plant costs from Distribution Company in the event of the cancellation, termination and abandonment of the NECEC Transmission Line but (a) only if (i) due to the termination of this Agreement by either Party prior to the Commercial Operation Date, or (ii) due to the termination of this Agreement by Distribution Company following the Commercial Operation Date, or (iii) this Agreement is rendered null and void pursuant to Section 19.2(c), and (b) only if such cancellation, termination, and abandonment results from changes after the Effective Date in Massachusetts laws or regulations (including changes in the manner in which the law is applied by those acting under the color of Massachusetts laws or regulations) or changes in MDPU orders that invalidate this Agreement or the Distribution Company’s obligation to pay for Firm Transmission Service or to pay the Distribution Company Termination Payment under this Agreement. In no event will Owner be entitled to recover abandoned plant costs under any other circumstances or in the event that the cancellation, termination or abandonment was caused directly or indirectly by some act or failure to act on the part of Owner or HQUS or their respective affiliates, agents or contractors, including, without limitation, an Owner Default or a Default (as defined in the PPA) by HQUS under the PPA, and Owner agrees not to seek from FERC or any other agency or authority any treatment of abandonment costs inconsistent with this provision, in accordance with Section
42
2.2.2.6.2 of the request for proposals pursuant to which this Agreement has been executed. In any such case, Owner’s recovery shall be limited to the Proportionate Share of its costs related to the NECEC Transmission Line that were prudently incurred after March 31, 2017, provided that, for purposes of calculating the Proportionate Share, on or after the Commercial Operation Date the denominator of the “Proportionate Share” shall be 1,200 MW. Owner may only request recovery of abandoned plant costs up to the remaining amounts available under the cap on Distribution Company’s liability under Section 14.7.2 . Distribution Company shall have the right to participate in such proceedings and to object to or seek to limit the recovery of any abandoned plant costs not expressly permitted to be recovered by Owner under this Section 14.5 or not consistent with FERC policy or precedent. Owner may not seek recovery under this Section 14.5 if it has been paid the Distribution Company Termination Payment.
Section 14.6 Disputes . Any Dispute over whether or not an Owner Default or Distribution Company Default has occurred shall be resolved in accordance with Article XVII .
Section 14.7 Limitations on Total Liability .
Section 14.7.1 Owner Liability . Notwithstanding anything herein to the contrary, Owner’s liability for any payments made to Distribution Company pursuant to Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.2(a) , or 14.4 shall not exceed, in aggregate, the Proportionate Share multiplied by One Hundred Twenty Million Dollars ($120,000,000).
Section 14.7.2 Distribution Company Liability . Notwithstanding anything herein to the contrary, Distribution Company’s liability for any payments made to Owner pursuant to Sections 3.3.4 , 3.4 , 14.3 , and 14.5 shall not exceed, in aggregate, the Proportionate Share multiplied by One Hundred Twenty Million Dollars ($120,000,000).
Section 14.7.3 Exceptions to Total Liability . The limits on liability set forth in Sections 4.4 and 14.7.1 shall not apply to any liability of Owner arising out of Owner’s gross negligence, willful misconduct (including willful breach of this Agreement), or fraud. The limits on liability set forth in Section 14.7.2 shall not apply to any liability of Distribution Company arising out of Distribution Company’s gross negligence, willful misconduct (including willful breach of this Agreement), or fraud.
Section 15.1 Definition; Conditions .
(a) The term “ Force Majeure ” means an event or circumstance (i) that is not within the reasonable control of the Party claiming its occurrence; (ii) that could not have been prevented or avoided by such Party through the exercise of reasonable diligence and (iii) that prohibits or prevents such Party from performing its obligations under this Agreement. Under no circumstances shall Force Majeure include (w) any full or partial curtailment in the operation of the NECEC Transmission Line that is caused by or arises from a mechanical or equipment breakdown or other mishap or events or conditions attributable to normal wear and tear or flaws of the NECEC Transmission Line, unless such curtailment or mishap is caused by one of the following: acts of God such as floods,
43
hurricanes, tornados, or other significantly unusual and abnormal weather conditions such as severe blizzards and severe ice storms; sabotage; terrorism or war; national or regional general strikes, lockouts or other labor disputes, (x) any occurrence or event that increases the costs or causes an economic hardship to a Party but is not otherwise a Force Majeure, (y) Owner’s ability to sell transmission service involving the NECEC Transmission Line at a price greater than that set out in this Agreement or (z) Distribution Company’s ability to procure transmission service at a price lower than that provided in this Agreement, or Distribution Company’s ability to purchase generation at a price lower than that provided in the PPA. In addition, a delay or inability to perform attributable to a Party’s lack of preparation, a Party’s failure to timely obtain and maintain all necessary permits (excepting the Regulatory Approval other than the obligations to file for Regulatory Approval) or qualifications, any delay or failure to obtain the Owner Approvals, Canadian Approvals, or Municipal Owner Approvals, a failure to satisfy contractual conditions or commitments, or lack or deficiency in funding or other resources shall each not constitute a Force Majeure or be the basis for a claim of Force Majeure. Neither Party may raise a claim of Force Majeure based in whole or in part on the failure of HQUS to fulfill any of its obligations under the PPA (including without limitation related to the availability of the Quebec Line) unless such failure is due to “force majeure” as stated in Section 10.1 of the PPA.
(b) Subject to Section 15.1(a) , if either Party is unable, wholly or in part, by Force Majeure to perform its obligations under this Agreement, such performance shall be excused and suspended so long as the circumstances that give rise to such inability exist or would exist if the Party claiming the Force Majeure used commercially reasonable efforts to cure such circumstances, but for no longer period. The Party whose performance is affected shall give prompt notice thereof to the other Party; such notice may be given orally or in writing but, if given orally, it shall be promptly confirmed in writing, providing details regarding the nature, extent and expected duration of the Force Majeure, its anticipated effect on the ability of such Party to perform its obligations under this Agreement, and the estimated duration of any interruption in service or other adverse effects resulting from such Force Majeure, and shall be updated or supplemented to keep the other Party advised of the effect and remedial measures being undertaken to overcome the Force Majeure. Such inability to perform shall be promptly corrected to the extent it may be corrected through the exercise of due diligence consistent with Good Utility Practice. Neither Party shall be liable for any losses or damages arising out of a suspension of performance that occurs because of Force Majeure. Notwithstanding any such suspension of performance, Distribution Company shall be obligated to make Transmission Service Payments as though Firm Transmission Service was then being provided at or greater than the Minimum Average Availability.
(c) Notwithstanding the foregoing, if the Force Majeure prevents full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, the Party whose performance is not prevented by Force Majeure shall have the right to terminate this Agreement upon written notice to the other Party and without further recourse; provided, however, that if (i) Owner presents a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company, acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, to Distribution Company before the
44
end of a period in which Owner’s provision of Firm Transmission Service has been prevented in whole or in part by an event of Force Majeure, Distribution Company shall forbear terminating this Agreement under this clause (c) for such period, provided that, during any such period, Distribution Company’s obligation to make Transmission Service Payments shall be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, Distribution Company may terminate this Agreement under this clause (c). In no event will any delay or failure of performance caused by any conditions or events of Force Majeure extend this Agreement beyond its stated Term.
(d) A Party shall not be required to settle any strike, walkout, lockout or other labor dispute on terms that, in the sole judgment of such Party, are contrary to its interest. The settlement of strikes, walkouts, lockouts or other labor disputes shall be entirely within the discretion of the Party involved in such dispute.
Article XVI
FINANCIAL ASSURANCES
(a) Owner shall be required to post Credit Support in the amount of $5,793,350.00 (“ Owner Security ”) to secure Owner’s obligations under this Agreement in the period beginning on the Effective Date and continuing through and including the date that all of Owner’s obligations under this Agreement are satisfied. Fifty percent (50%) of the Owner Security shall be provided to Distribution Company within three (3) Business Days following the Execution Date; and the remaining fifty percent (50%) shall be provided to Distribution Company within fifteen (15) Business Days after receipt of the Regulatory Approval.
(b) If at any time during the Term of this Agreement, the amount of Credit Support is reduced as a result of Distribution Company’s draw upon such Credit Support, Owner shall replenish such Credit Support to the total amount required under this Section 16.1 within five (5) Business Days of that draw, provided that any replenishment obligation shall be subject to the limitations on total liability set forth in Section 14.7 .
(c) Any Cash provided by Owner as Credit Support under this Agreement shall be held in an account selected by Distribution Company in its reasonable discretion. Interest shall accrue on that Cash deposit at the daily Federal Funds Rate and shall be remitted to Owner upon written request to Distribution Company, with such request not more often than on a quarterly basis, and Distribution Company shall remit such accrued interest to the Owner within a reasonable time following receipt of such request. Owner agrees to comply with the commercially reasonable requirements of Distribution Company in connection with the receipt and retention of any Cash provided as Credit Support under this Agreement.
45
(d) Any unused Credit Support provided under this Agreement shall be returned to Owner only after any such Credit Support has been used to satisfy any outstanding obligations of Owner in existence at the time of the expiration or termination of this Agreement. Provided such obligations have been satisfied, such Credit Support shall be returned to Owner within thirty (30) days after the expiration or earlier termination of this Agreement.
Article XVII
DISPUTE RESOLUTION
(a) The Parties shall initially attempt to resolve any Dispute through consultations between the Parties. Subject to Section 17.2 and except as expressly provided otherwise in this Agreement, if a Dispute has not been timely resolved pursuant to this clause (a) within fifteen (15) Business Days after written notice of such Dispute has been given, then either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction; provided, however, if the Dispute is subject to Section 17.2 , then either Party may elect to proceed with the mediation through FERC's Dispute Resolution Service. If one Party fails to participate in the consultations provided for in this Section 17.1 , the other Party can initiate mediation prior to the expiration of the fifteen (15) Business Days. Unless otherwise agreed, the Parties will select a mediator from the FERC panel. The Parties may, by written agreement signed by both Parties, alter any time deadline, location(s) for meeting(s), or procedure outlined herein or in FERC’s rules for mediation. The procedure specified herein shall be the sole and exclusive procedure for the resolution of Disputes.
(b) All negotiations, consultations, and mediations pursuant to this Section 17.1 shall be deemed to be confidential and shall be treated as compromise and settlement negotiations, and no evidence with regard to any proposal made during such negotiations, consultations, or mediations shall be admissible in any FERC proceeding or filing under Section 17.2 or in any other judicial or other proceeding.
Section 17.2 Disputes to be Resolved by FERC .
(a) In the event a Dispute over any matter is not resolved in accordance with Section 17.1 , either Party shall have the right to file for relief with FERC to the extent that matter is within the primary or exclusive jurisdiction of the FERC. Nothing contained in this Agreement shall be construed as precluding a Party from filing any answer, protest or other opposition to any FERC filing made by the other Party, unless expressly prohibited under the terms of this Agreement.
(b) In the event any Dispute is submitted to FERC for resolution as provided in Section 17.2(a) , the Party submitting the Dispute to FERC shall be responsible for providing written notice of such filing to the other Interested Parties. Unless both Parties agree that the Dispute does not implicate any of the Proposal Agreements other than this Agreement, each Party consents and agrees that (i) each Interested Party is an interested party in the Dispute and (ii) in order to avoid inconsistent interpretations and adjudications of the Proposal Agreements, any
46
Interested Party may, without objection from any other Interested Party, whether by means of joinder, consolidation or otherwise, submit such matters as it considers sufficiently related to the Dispute to FERC to be jointly determined by FERC with the Dispute. Notwithstanding the foregoing, in the event FERC determines that it does not have the jurisdiction to, or otherwise does not want to, hear or determine any portion of a Dispute or other matter so referred to FERC, either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction.
Section 17.3 Consent to Jurisdiction . Subject to Section 17.2 , each Party agrees that any legal action or proceeding with respect to or arising out of this Agreement or any other Proposal Agreement shall be brought in or removed to the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts that has subject matter jurisdiction and any appellate court from any thereof. By execution and delivery of this Agreement, each Party hereby accepts for itself and in respect of its property, generally and unconditionally, the jurisdiction of the aforesaid courts. The Parties irrevocably consent to the service of process out of any of the aforementioned courts in any such action or proceeding by the mailing of copies thereof by registered or certified airmail, postage prepaid, to the applicable Party at its respective addresses for notices as specified in Section 23.4 . Nothing herein shall affect the right to serve process in any other manner permitted by law. Each Party hereby waives any right to stay or dismiss any action or proceeding under or in connection with this Agreement or any other Proposal Agreement brought before the foregoing courts on the basis of forum non-conveniens.
Section 17.4 WAIVER OF JURY TRIAL . EACH PARTY IRREVOCABLY AND UNCONDITIONALLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY LEGAL ACTION, PROCEEDING, CAUSE OF ACTION, OR COUNTERCLAIM ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.
Article XVIII
LIMITATION OF REMEDIES
NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, NEITHER PARTY NOR ANY OF ITS AGENTS, SUBCONTRACTORS, REPRESENTATIVES OR AFFILIATES SHALL BE LIABLE TO THE OTHER PARTY FOR PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE (EXCEPT AS EXPRESSLY CONTEMPLATED IN THIS AGREEMENT, INCLUDING IN Section 4.4 , OR FOR ANY DIRECT DAMAGES SUFFERED BY DISTRIBUTION COMPANY AS A RESULT OF A BREACH BY OWNER OF ITS OBLIGATIONS UNDER Section 6.2 , Article X OR Section 11.2 ), IN EACH CASE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OF THIS AGREEMENT, AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY).
FOR THE AVOIDANCE OF DOUBT, THE PARTIES ACKNOWLEDGE AND AGREE THAT Section 4.4 OR Section 7.3 PROVIDE THE SOLE AND EXCLUSIVE REMEDIES FOR ANY LOSS OF USE CONTEMPLATED BY Section 4.4 OR Section 7.3 AND NOTHING IN Section 6.2 , Article X OR Section 11.2 SHALL SUPERSEDE, SUPPLEMENT OR AMEND SUCH SOLE AND EXCLUSIVE REMEDIES.
47
THIS ARTICLE XVIII IS IN ADDITION TO THE SPECIFIC LIMITATIONS ON REMEDIES REFERENCED IN ARTICLE XIV , SECTION 4.4.1 , AND SECTION 4.4.2 .
Article XIX
MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES.
Section 19.1 Modifications . The Parties specifically intend and acknowledge and agree that, except as otherwise expressly provided in this Agreement, (a) this Agreement shall not be subject to amendment or other modification, absent the written agreement of both Parties and (b) neither Party shall be permitted to make a filing with FERC under any provision of the Federal Power Act or the regulations promulgated thereunder that seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement at any time during the Term, except to implement an amendment or other modification to this Agreement that has been reduced to writing and signed by both Parties. In addition, to the extent any third party, or FERC acting sua sponte seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement, the standard of review for any proposed amendment or other modification shall be the “public interest” standard of review set forth in United Gas Pipe Line Co. v. Mobile Gas Service Corp., 350 U.S. 332 (1956), and Federal Power Commission v. Sierra Pacific Power Co., 350 U.S. 348 (1956), and as further defined in Morgan Stanley Capital Group, Inc. v. Public Utility District No. 1 of Snohomish County, 128 S. Ct. 2733 (2008) and NRG Power Marketing, LLC v. Maine Public Utilities Commission, 130 S. Ct. 693 (2010).
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment .
(a) This Agreement is subject to the ISO-NE Rules. If, during the Term, any ISO-NE Rule is terminated, modified or amended, or is otherwise no longer applicable, resulting in a material alteration of a material right or obligation of a Party hereunder, the Parties agree to negotiate in good faith in an attempt to amend or clarify this Agreement to embody the Parties’ original intent regarding their respective rights and obligations under this Agreement, provided that neither Party shall have any obligation to agree to any particular amendment or clarification of this Agreement. The intent of the Parties is that any such amendment or clarification reflect, as closely as possible, the intent, substance and effect of the ISO-NE Rule being replaced, modified, amended, or made inapplicable as such ISO-NE Rule was in effect prior to such termination, modification, amendment, or inapplicability; provided that such amendment or clarification shall not in any event alter (i) the purchase and sale obligations of the Parties pursuant to this Agreement or (ii) the Transmission Service Payment. In the event the Parties cannot agree upon such amendments within sixty (60) days after such ISO Rule or ISO-NE Practice change described above, the Dispute shall be resolved in accordance with Article XVII .
(b) If, during the Term, there is a change in Applicable Law (other than tax laws or regulations) or accounting standards or rules or a change in the interpretation or applicability thereof that would result in (i) material adverse balance sheet or creditworthiness impacts on Distribution Company associated with this Agreement or the amounts paid for Firm Transmission Service purchased hereunder, or (ii) an adverse impact on the economic benefits (including those stemming from the fiscal conditions provided for herein) that Owner enjoys under this Agreement or that are provided for herein
48
for Owner during the Term, the Parties shall use commercially reasonable efforts to agree to an amendment to the Agreement to avoid or mitigate such impacts and restore the economic benefits to each affected Party; provided that such amendment mitigates any material adverse effect(s) on each non-affected Party (as identified by each such Party, acting reasonably) that could reasonably be expected to result from such amendment, but only to the extent that such mitigation can be accomplished in a manner that is consistent with the purpose of such amendment. I n the event the Parties cannot agree on an amendment in accordance with this Section 19.2(b) , the dispute shall be resolved in accordance with Article XVII .
(c) Upon a determination by a court or regulatory body having jurisdiction over this Agreement or any of the Parties, or over the establishment and enforcement of any of the statutes or regulations or orders or actions of regulatory agencies (including the MDPU) supporting this Agreement or the rights or obligations of the Parties hereunder that any of the statutes or regulations supporting this Agreement or the rights or obligations of the Parties hereunder, or orders of or actions of regulatory agencies (including the MDPU) implementing such statutes or regulations, or this Agreement on its face or as applied, violates any Applicable Law (including the State or Federal Constitution) (an “ Adverse Determination ”), each Party shall have the right to suspend performance under this Agreement without liability. Owner may provide transmission service to a third party during any period of time for which Distribution Company suspends payments under this Section 19.2(c) . Upon an Adverse Determination becoming final and non-appealable, this Agreement shall be rendered null and void.
(d) For the avoidance of doubt, it is understood that the provisions of Article XVII regarding dispute resolution apply to any Dispute under this Article XIX .
Section 20.1 Owner Indemnity . Owner shall indemnify, defend and hold harmless Distribution Company and Distribution Company’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, a “ Distribution Company Indemnified Party ” ) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Distribution Company Indemnified Party, including any such liabilities incurred by a Distribution Company Indemnified Party under the PPA, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Distribution Company Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Distribution Company Indemnified Party.
49
Section 20.2 [Intentionally Omitted]
Section 20.3 Procedures . Promptly after the receipt by any Person seeking indemnification under this Article XX (the “ Indemnified Party ”) of written notice of the assertion of any claim by a third party with respect to any matter in respect of which indemnification may be sought hereunder (a “ Third Party Claim ”), the Indemnified Party shall give written notice (the “ Indemnification Notice ”) to Owner and shall thereafter keep Owner reasonably informed with respect thereto; provided, however, that the failure of the Indemnified Party to give the Indemnifying Party notice as provided herein shall not relieve Owner of any of its obligations hereunder, except to the extent that Owner is materially prejudiced by such failure. Owner shall be entitled to assume the defense of any Third Party Claim by written notice to the Indemnified Party of such intention given within thirty (30) days after the receipt by Owner of the Indemnification Notice; provided, however, that counsel selected by the Indemnifying Party shall be reasonably satisfactory to Owner. Owner shall be liable for the fees and expenses of counsel employed by the Indemnified Party for any period during which Owner has not assumed the defense of any Third Party Claim (other than during any period during which the Indemnified Party has failed to give notice of such Third Party Claim as provided above). If Owner shall assume the defense of the Third Party Claim, then the Owner shall not compromise or settle such Third Party Claim without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld, delayed or conditioned; provided, however, that the Indemnified Party shall have no obligation to consent to any settlement that (a) does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff of a release of the Indemnified Party from all liability with respect to such Third Party Claim or (b) involves the imposition of equitable remedies or the imposition of any material obligations on such Indemnified Party other than financial obligations for which such Indemnified Party is indemnified hereunder. As long as the Owner is contesting any such Third Party Claim on a timely basis, the Indemnified Party shall not pay, compromise or settle any claims brought under such Third Party Claim. Notwithstanding the assumption by the Owner of the defense of any Third Party Claim as provided in this Section 20.3 , the Indemnified Party shall be permitted to participate in the defense of such Third Party Claim and to employ counsel at its own expense (it being understood that Owner controls such defense); provided, however, that, if the defendants in any Third Party Claim shall include both an Owner and any Indemnified Party, and such Indemnified Party shall have reasonably concluded that counsel selected by Owner has a conflict of interest because of the availability of different or additional defenses to such Indemnified Party, such Indemnified Party shall then have the right to select separate counsel to participate in the defense of such Third Party Claim on its behalf, at the expense of Owner; provided that the Owner shall not be obligated to pay the expenses of more than one separate counsel for all Indemnified Parties, taken together.
Section 20.4 Defenses . If Owner shall fail to notify the Indemnified Party of its desire to assume the defense of any Third Party Claim within the prescribed period of time, or shall notify the Indemnified Party that it will not assume the defense of any such Third Party Claim, then the Indemnified Party may assume the defense of any such Third Party Claim, in which case it may do so acting in good faith and otherwise in such manner as it may deem appropriate, and the Owner shall be bound by any determination made in such Third Party Claim.
Section 20.5 Cooperation . The Indemnified Party and Owner shall each cooperate fully (and shall each cause its Affiliates to cooperate fully) with the other in the defense of any Third Party Claim pursuant to this Article XX . Without limiting the generality of the foregoing, each such Person shall furnish the other such Person (at the expense of the Owner) with such
50
documentary or other evidence as is then in its or any of its Affiliates’ possession, as may reasonably be requested by the other Person for the purpose of defending against any such Third Party Claim.
Section 20.6 Recovery . The amount of any indemnity hereunder shall be reduced by any insurance proceeds actually recovered by the Indemnified Party in connection with the Third Party Claim. If at any time subsequent to the receipt by an Indemnified Party of an indemnity payment hereunder, such Indemnified Party (or any Affiliate thereof) receives any recovery, settlement or other similar payment with respect to the Third Party Claim for which it received such indemnity payment (a “ Recovery ”), such Indemnified Party shall then promptly pay to the Owner the amount of such Recovery, less any expenses incurred by such Indemnified Party (or its Affiliates) in connection with such Recovery, but in no event shall any such payment exceed the amount of such indemnity payment.
Section 20.7 Subrogation . To the extent the Owner makes or is required to make any indemnity payment to the Indemnified Party, the Owner shall be entitled to exercise, and shall be subrogated to, any rights and remedies (including rights of indemnity, rights of contribution and other rights of recovery) that the Indemnified Party or any of its Affiliates may have against any other Person with respect thereto, whether directly or indirectly related. The Indemnified Party shall permit the Owner to use the name of the Indemnified Party and the names of the Indemnified Party’s Affiliates in any transaction or in any proceeding or other matter involving any of such rights or remedies; and the Indemnified Party shall take such actions as the Owner may reasonably request for the purpose of enabling the Owner to perfect or exercise its right of subrogation hereunder.
Article XXI
REPRESENTATIONS, WARRANTIES AND COVENANTS
Section 21.1 Mutual Representations and Warranties . Each Party hereby represents and warrants to the other Party that all of the statements in this Section 21.1 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of (i) the Effective Date and (ii) the Commercial Operation Date , but not as of any other date:
(a) It has knowledge and experience in financial matters and in the electric industry that enable it to evaluate the merits and risks of this Agreement and the transactions contemplated hereby, and is capable of evaluating such merits and risks and assuming such risks. It is acting for its own account, has made its own independent decision to enter into this Agreement as to whether this Agreement is appropriate and proper for it based upon its own judgment, is not relying upon the advice or recommendations of the other Party in doing so, and understands and accepts the terms, conditions, and risks of this Agreement and the transactions contemplated hereby;
(b) It has entered into this Agreement in connection with the conduct of its business;
(c) It is not acting as a fiduciary or an advisor with respect to this Agreement or the transactions contemplated hereby;
51
(d) It is not subject to an Insolvency Event and there are no proceedings pending or being contemplated by it or, to its knowledge, threatened against it that could result in the occurrence of an Insolvency Event with respect to it; and
(e) It is an entity subject to the procedures and substantive provisions of the Bankruptcy Code applicable to U.S. corporations or limited liability companies, as applicable, generally.
Section 21.2 Additional Representations and Warranties of Owner . Owner hereby represents and warrants to Distribution Company that all of the statements in this Section 21.2 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Owner is duly organized, validly existing, and in good standing under the laws of the State of Maine and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Owner, and Owner has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Owner has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Owner;
(c) Assuming due authorization, execution and delivery by Distribution Company, this Agreement constitutes Owner’s legal, valid and binding obligation enforceable against Owner in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Owner or any of its Affiliates that could have a Material Adverse Effect on Owner;
(e) No event with respect to Owner has occurred or is continuing that would constitute an Owner Default, and no Owner Default will occur as a result of Owner entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Owner does not and will not (i) violate any provisions of its articles of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The FERC Authorizations, Owner Approvals, Municipal Owner Approvals, and the AC Upgrade Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary to commence construction of and operate the NECEC Transmission Line;
52
(i) Owner has acquired all required real property rights necessary for construction and operation of the NECEC Transmission Line, and the interconnection of the NECEC Transmission Line with (A) the Québec Line (other than real property rights to be held by TransÉnergie) and (B) the Delivery Point, in full and final form with all options or contingencies having been exercised as set forth in Attachment I; and
(h) Owner is in compliance with all Applicable Laws, except such non-compliance as could not reasonably be expected to have a Material Adverse Effect on Owner. Owner has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Owner.
Section 21.3 Additional Representations and Warranties of Distribution Company . The Distribution Company hereby represents and warrants to Owner that all of the statements in this Section 21.3 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Distribution Company is duly organized, validly existing and in good standing under the laws of the Commonwealth of Massachusetts and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Distribution Company, and Distribution Company has all requisite power and authority to conduct its business, own its properties and to execute, deliver and perform its obligations under this Agreement;
(b) Distribution Company has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Distribution Company;
(c) Assuming due authorization, execution and delivery by Owner, this Agreement constitutes Distribution Company’s legal, valid and binding obligation enforceable against Distribution Company in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Distribution Company or any of its Affiliates that could have a Material Adverse Effect on Distribution Company;
(e) No event with respect to Distribution Company has occurred or is continuing that would constitute a Distribution Company Default, and no Distribution Company Default will occur as a result of Distribution Company entering into or performing its obligations under this Agreement;
53
(f) The execution, delivery and performance of this Agreement by Distribution Company does not and will not (i) violate any provisions of its certificate of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The Regulatory Approval constitutes the only action, Consent, notification, waiver, order or filing that is necessary with respect to the execution, delivery and performance of this Agreement by Distribution Company; and
(h) Distribution Company is in compliance with all Applicable Laws, except such non-compliances as could not reasonably be expected to have a Material Adverse Effect on Distribution Company. Distribution Company has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Distribution Company.
(i) Distribution Company has not taken and will not take any action (including providing support or information to any Affiliate of Distribution Company) to directly or indirectly oppose or prevent the achievement of any Governmental Approval, Third Party Consent, or other milestone or requirement set forth in this Agreement.
Section 21.4 NO OTHER REPRESENTATIONS OR WARRANTIES . THE REPRESENTATIONS AND WARRANTIES OF OWNER SET FORTH IN Section 21.1 AND Section 21.2 ARE OWNER’S SOLE REPRESENTATIONS AND WARRANTIES ASSOCIATED WITH THE NECEC TRANSMISSION LINE AND ARE MADE IN LIEU OF ALL OTHER REPRESENTATIONS, WARRANTIES AND GUARANTEES, EXPRESS OR IMPLIED, ASSOCIATED WITH THE NECEC TRANSMISSION LINE, INCLUDING REPRESENTATIONS OR WARRANTIES AS TO MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE. THE FOREGOING SENTENCE SHALL NOT BE CONSTRUED IN ANY WAY TO LIMIT OWNER’S EXPRESS OBLIGATIONS UNDER THIS AGREEMENT.
Article XXII
TRANSFER OF INTERESTS
Section 22.1 No Transfer of Interests .
(a) Any (i) direct or indirect change of Control of any Party (whether voluntary or by operation of law), (ii) sale, transfer or other disposition of all or substantially all of the assets of any Party or (iii) except as provided in Section 22.2 or Section 22.3 , assignment, transfer or other disposition of, whether to one or more assignees or transferees, all or any portion of any Party’s rights, interests or obligations under this Agreement (each of the foregoing, a “ Transfer ”), shall require the prior written consent of the other Party, which consent shall not be unreasonably withheld, delayed or conditioned when viewed in light of all reasonable considerations, including the security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer); provided that any direct or
54
indirect transfer of securities or other ownership interests in a Party to the Party’s Affiliate shall not be considered a Transfer for the purposes of this Section 22.1 and shall not require consent. Any Transfer in contravention of this Article XXII shall be null and void.
(b) If Owner consents to a Transfer by Distribution Company pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Distribution Company’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Owner of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that a Distribution Company Default shall not have occurred and be continuing, (x) the obligations of Distribution Company shall terminate to the extent of the Transferred portion of this Agreement, and Distribution Company shall be fully, finally and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Distribution Company Owner shall execute and deliver to Distribution Company a full, final, and unconditional release of any Credit Support or guarantees provided by Distribution Company, in such form as Distribution Company may reasonably request, with respect to the Transferred portion of this Agreement.
(c) If Distribution Company consents to a Transfer by Owner pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee of Owner’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Distribution Company of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that an Owner Default shall not have occurred and be continuing (x) the obligations of Owner shall terminate to the extent of the Transferred portion of this Agreement, and Owner shall be fully, finally and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Owner, Distribution Company shall execute and deliver to Owner a full, final and unconditional release of any Credit Support or guarantees provided by Owner hereunder, in such form as Owner may reasonably request, with respect to the Transferred portion of this Agreement .
(d) Nothing herein shall prevent Distribution Company or any assignee thereof from transferring or assigning transmission service rights pursuant to FERC rules and regulations, including pursuant to Section 20 of the PPA.
Section 22.2 Exceptions . Notwithstanding Section 22.1 , consent shall not be required for any of the following:
(a) Distribution Company shall have the right to assign this Agreement without consent of Owner:
(i) to a successor in interest in any merger or consolidation of Distribution Company with or into another Person or any exchange of all of the common stock or other equity interests of Distribution Company or Distribution Company’s parent for cash, securities or other property or any acquisition, reorganization, or other similar corporate transaction involving all or substantially all of the common stock
55
or other equity interests in, or assets of, Distribution Company so long as (1) the proposed assignee’s credit rating is at least either BBB- from S&P or Baa3 from Moody’s, or (2) the proposed assignee’s credit rating is equal to or better than that of Distribution Company at the time of the proposed assignment, or (3) the transaction associated with such assignment, has been approved by the MDPU or the appropriate Government Entity, in each case, with an express assumption of Distribution Company’s obligations hereunder in writing, reasonably acceptable to Owner and Distribution Company, if such assumption does not occur under Applicable Law; or
(ii) to any substitute purchaser of the Products so long as (1) the proposed assignee’s credit rating is at least either BBB- from S&P or Baa3 from Moody’s, and (2) the proposed assignee’s credit rating is equal to or better than that of Distribution Company at the time of the proposed assignment, and, if required, (3) such assignment has been approved by the MDPU or the appropriate Government Entity, in each case, with an express assumption of Distribution Company’s obligations hereunder in writing, reasonably acceptable to Owner and Distribution Company. For purposes of clarification, a disposition of this Agreement pursuant to this clause (ii) includes an assignment to any third party other than the successor in interest in connection with a transaction to which clause (i) applies.
(b) any (i) change of Control of Owner or (ii) transfer or other disposition of all or substantially all of the assets of Owner, in each case, resulting from a collateral assignment in favor of a financing party in accordance with Section 22.3 ;
(c) any change of Control of Owner resulting from any direct or indirect change of Control in Owner’s ultimate parent company (currently, Iberdrola, S.A.), Owner’s ultimate parent company in the United States (currently AVANGRID, Inc.) or in the parent company for the network business in the United States of which Owner is part (currently Avangrid Networks, Inc.); or
(d) the exercise of any of HQUS’s or the Distribution Company’s rights pursuant to Section 14.7, 14.8(a) or 14.8(b) of the HQUS TSA.
Section 22.3 Collateral Assignment . Owner shall be entitled, without restriction, to make one or more assignments of this Agreement for purposes of collateral security or any or all of its rights and benefits hereunder to or for the benefit of any and all secured lenders to Owner, or grant to or for the benefit of any and all secured lenders to Owner a lien on, or security interest in, any right, title or interest in all or any part of Owner’s rights hereunder for the purpose of the financing or successive refinancing of the ownership, development, engineering, construction or operation of the NECEC Transmission Line; provided, however, that such assignment for purposes of collateral security shall recognize Distribution Company’s rights under this Agreement on terms and conditions as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner. To facilitate Owner’s obtaining of financing or successive refinancing for the ownership, development, engineering, construction or operation of the NECEC Transmission Line, Distribution Company shall cooperate with Owner and shall execute and deliver such consents, acknowledgements, direct agreements or similar documents as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner.
56
Section 23.1 Governing Law . This Agreement and each of its provisions shall be governed by, and construed in accordance with, the laws of the Commonwealth of Massachusetts.
Section 23.2 Entire Agreement . This Agreement, together with the Attachments, constitutes the entire Agreement and understanding between the Parties with respect to all subjects covered hereby and thereby and supersedes all prior discussions, agreements and understandings between the Parties with respect to such matters.
Section 23.3 Severability . Except as otherwise provided in Section 2.2 or Section 19.2 , (a) in the event any part of this Agreement is held to be illegal, invalid or unenforceable to any extent, the legality, validity and enforceability of the remainder of this Agreement shall not be affected thereby, and shall remain in full force and effect and shall be enforced to the greatest extent permitted by Applicable Law and (b) with respect to any provision found to be illegal, invalid or unenforceable, the Parties shall endeavor to replace such invalid, illegal or unenforceable provision with the valid, legal and enforceable provision that achieves, as nearly as practicable, the commercial intent of this Agreement (as it may be amended from time to time).
Section 23.4 Notices . All notices, billings, requests, demands, waivers, consents and other communications under this Agreement shall be in writing and shall be effective (a) upon personal delivery thereof, including by overnight mail or courier service, with a record of receipt, (b) in the case of notice by United States mail, certified or registered, postage prepaid, return receipt requested, upon the fourth (4th) day after mailing, (c) in the case of notice by facsimile for any communications other than billings, upon transmission; provided that such facsimile transmission is promptly confirmed by either of the methods set forth in the foregoing clause (a) or (b), in each case, addressed to each Party and copy party hereto at its address set forth below or at such other address as a Party may from time to time designate by written notice to the other Party pursuant to this Section 23.4 , (d) in the case of notice by facsimile for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon receipt of confirmation of successful transmission, but without any further requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b), or (e) in the case of notice by electronic mail for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon transmission, without any requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b); provided that the Party delivering such notice did not receive any notice of unsuccessful or delayed transmission. A notice given in connection with this Section 23.4 but received on a day other than a Business Day, or after business hours at the location of receipt, shall be deemed to be received on the next Business Day.
57
Central Maine Power Company
Attn: Douglas Herling, President & CEO
83 Edison Drive, Augusta ME 04336
207-626-9779
With a copy to:
Central Maine Power Company
Attn: Legal Department
83 Edison Drive, Augusta ME 04336
With a further copy to:
Pierce Atwood LLP
Attn: Jared des Rosiers
254 Commercial St., Portland ME 04101
If to Distribution Company:
James G. Daly, Vice President – Energy Supply
Eversource Energy
247 Station Drive/ SE250
Westwood, MA 02090
With a copy to:
Legal Department
Eversource Energy
800 Boylston Street/ P1701
Section 23.5 Intentionally Omitted .
Section 23.6 Waiver; Cumulative Remedies . Any term or condition of this Agreement may be waived at any time by the Party that is entitled to the benefit thereof, but such waiver shall not be effective unless set forth in a written instrument duly executed by or on behalf of the Party waiving such term or condition. No waiver by any Party of any term or condition of this Agreement, in any one or more instances, shall be deemed to be, or construed as, a subsequent waiver of, or estoppel with respect to, the same or any other term or by Applicable Law. Except as otherwise provided in Section 13.2(b), the failure of or delay on the part of any Party to enforce or insist upon compliance with or strict performance of any term or condition of this Agreement, or to take advantage of any of its rights thereunder, shall not constitute a waiver or relinquishment of any such terms, conditions, or rights, but the same shall be and remain at all times in full force and effect. Except as otherwise provided herein, the remedies provided in this Agreement are cumulative and not exclusive of any remedies provided by law or in equity.
58
Section 23.7 Confidential Information . Each Party hereby agrees that it shall not disclose, or cause to be disclosed, to third parties any Confidential Information with respect to the other Party or any material or information identified as Critical Energy Infrastructure Information (other than to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential). Notwithstanding the foregoing, each Party may disclose information related to this Agreement to another party to a Proposal Agreement or to Trans É nergie only if necessary to comply with its obligations hereunder or thereunder or to coordinate the parties’ obligations under different Proposal Agreements. Each Party shall be responsible for ensuring that any Person to whom it discloses any Confidential Information shall comply with the restrictions in this Section 23.7 . The restrictions in this Section 23.7 shall not apply (w) to the extent disclosure is required by Applicable Law or the requirements of a Governmental Authority (including a court order, oral questions, written interrogatories, request for information or documents, subpoena, or similar process, or the requirements of any stock exchange or other Governmental Authority to which the Parties, or any of their Affiliates are subject), (x) to the extent reasonably deemed by the disclosing Party to be required or desirable in connection with regulatory proceedings (including proceedings relating to FERC or any other national, federal, provincial, state or regulatory agency), (y) to the extent reasonably deemed by the disclosing Party to be required to be disclosed in connection with a Dispute between the Parties, or the defense of any litigation or dispute, or (z) as approved for release or disclosure by the Party whose Confidential Information is at issue. In the event disclosure is made pursuant to this Section 23.7 and except for disclosures pursuant to the requirements of securities laws or any stock exchange, the disclosing Party shall use reasonable efforts to minimize the scope of any disclosure and advise recipients of any applicable confidentiality restrictions provided herein. Notwithstanding the foregoing, this Section 23.7 shall not apply to the following information:
(a) Information that is a matter of public knowledge at the time of its disclosure or is thereafter published in or otherwise ascertainable from a source available to the public without breach of this Section 23.7;
(b) Information that is obtained from a Person other than by or as a result of unauthorized disclosure; or
(c) Information that, prior to the time of disclosure, had been independently developed or obtained by the disclosing Party or its Affiliates independent of information obtained as a result of unauthorized disclosure.
Section 23.8 No Third-Party Rights . Except for any secured lenders contemplated by Section 22.3 and any Distribution Company Indemnified Party contemplated by Article XX , and except for HQUS (which is intended to be a third party beneficiary of this Agreement solely to the extent of its capacity as an assignee of transmission rights as set forth in Section 20 of the PPA and for the purposes of and as contemplated by Article X of this Agreement, in light of its rights to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under this Agreement pursuant to Section 14.7 of the HQUS TSA, and with respect to Sections 1.1 , 3.3.1 - 3.3.7 , 5.3 , 5.5.1 , 11.1 , 23.7 , and Articles II , IV , VII , VIII , XIV , XV , and XVII ), the Parties do not intend for this Agreement to confer a third-party beneficiary status or rights of action upon any Person whatsoever other than the Parties and their permitted successors and assigns, and nothing contained herein, either express or implied, shall be construed to confer upon any Person, other than the Parties and their permitted successors and assigns, any rights of action or remedies under
59
this Agreement or in any manner, or any duty, standard of care, or liability with respect thereto. This Agreement does not create any third-party rights, except as expressly stated above in this Section 23.7 .
Section 23.9 Permitted Successors and Assigns . This Agreement shall be binding upon and inure to the benefit of each of the Parties and their permitted successors, legal representatives and assigns.
Section 23.10 Relationship of the Parties . This Agreement shall not be construed as creating an association, joint venture, trust or partnership between the Parties or as imposing any partnership obligation or liability upon either Party. Except as contemplated by Article X , neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.
Section 23.11 Construction . No presumption shall operate in favor of or against either Party as a result of any responsibility for drafting this Agreement.
Section 23.12 Counterparts . This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument. The Parties acknowledge and agree that any document or signature delivered by facsimile or electronic transmission shall be deemed to be an original executed document for all purposes hereof.
Section 23.13 Survival . The provisions of Section 3.3 , Section 3.4 , Section 8.2 , Article IX , Article XIII , Article XIV , Article XVII , Article XVIII , Article XIX , Article XX and this Article XXIII shall survive the expiration or earlier termination of this Agreement.
Section 23.14 Headings and Table of Contents . The headings of the articles and sections of this Agreement and the Table of Contents are inserted for purposes of convenience only, and shall not be construed to affect the meaning or construction of any of the provisions hereof.
Section 23.15 Waiver of Immunities . The Parties acknowledge and agree that this Agreement and the transactions contemplated hereby constitute a commercial transaction. To the extent a Party (including any assignees of a Party’s rights or obligations under this Agreement) may be entitled, in any jurisdiction, to claim for itself, or any of its assets, revenues or properties, sovereign or other immunity, as the case may be, from service of process, suit, the jurisdiction of any court or arbitral tribunal, attachment (whether in aid of execution or otherwise) or enforcement of a judgment (interlocutory or final) or award or any other legal process in a matter arising out of or relating to this Agreement, each Party agrees not to claim or assert, and hereby waives, such immunity. Without limiting the generality of the foregoing, each Party agrees that the waivers set forth in this Section 23.15 shall have the fullest scope permitted under the Immunities Act and under any other Applicable Law related to sovereign immunity.
[ Signature pages follow ]
60
IN WITNESS WHEREOF , Owner and Distribution Company have executed this Agreement as of the Execution Date.
|
OWNER: |
||
|
|
|
|
|
CENTRAL MAINE POWER COMPANY |
||
|
|
|
|
|
By: |
|
/s/ Douglas Herling |
|
Name: |
|
Douglas Herling |
|
Title: |
|
President & CEO |
|
|
|
|
|
|
|
|
|
By: |
|
/s/ Eric N. Stinneford |
|
Name: |
|
Eric N. Stinneford |
|
Title: |
|
Vice President, Controller, & Treasurer |
|
|
|
|
|
|
|
|
|
DISTRIBUTION COMPANY: |
||
|
|
|
|
|
NSTAR ELECTRIC COMPANY D/B/A EVERSOURCE ENERGY |
||
|
|
|
|
|
By: |
|
/s/ James G. Daly |
|
Name: |
|
James G. Daly |
|
Title: |
|
Vice President – Energy Supply |
Description of Transmission Projects
The Québec Line and the NECEC Transmission Line consist in their entirety of:
|
(1) |
New 207 mile (145.3 miles in Maine) +/- 320 kV overhead HVDC transmission line that will run between the existing Appalaches Substation in Thetford Mines, Québec and a new HVDC converter station approximately 1.6 miles from the existing Larrabee Road Substation in Lewiston, Maine; |
|
(2) |
New HVDC converter stations at both ends of the transmission line; and |
|
(3) |
Certain upgrades to the existing high voltage alternating current (AC) New England transmission system necessary to permit the interconnection and transmission of Hydro Generation to the New England Control Area (as defined in the ISO-NE Tariff) at the existing Larrabee Road substation under the requirements of Section I.3.9 and the CCIS of ISO-NE Tariff. |
|
(4) |
System upgrades to the existing Québec transmission system as determined by the Hydro-Québec TransÉnergie System Impact Study (OASIS #203T), as it may be updated. |
Owner is the developer of the portion of the NECEC Transmission Line from the Québec-Maine border to the Lewiston area and all transmission upgrades on the U.S. side of the border. The NECEC Transmission Line and the Québec Line are expected to connect at the Québec-Maine border in the northwest corner of Maine in Beattie Township.
The Québec Line will be constructed by TransÉnergie, a division of Hydro-Québec and an Affiliate of HQUS.
Owner will construct, own, operate and maintain the NECEC Transmission Line, which will be constructed in existing transmission corridors owned by Owner.
The NECEC Transmission Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 145.3 mile +/-320 kV HVDC transmission line from the Canadian Border to a new converter substation located on Merrill Road in Lewiston |
|
ii. |
New 1.6 mile 345 kV AC transmission line from the new Merrill Road converter substation to the existing Larrabee Road substation |
A-1
|
i. |
New 345 kV AC to +/-320 kV HVDC 1200 MW Merrill Road converter substation |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Larrabee Road substation |
|
(2) |
Network Upgrades (subject to change based on ISO-NE system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
New 26.5 mile 345 kV AC transmission line from the existing Coopers Mills substation in Windsor to the existing Maine Yankee substation in Wiscasset |
|
ii. |
New 0.3 mile 345 kV AC transmission line from the existing Surowiec substation in Pownal to a new substation on Fickett Road in Pownal |
|
iii. |
Rebuild 9.3 mile 115 kV Section 62 AC transmission line from the existing Crowley Road substation in Sabattus to the existing Surowiec substation |
|
iv. |
Rebuild 16.1 mile 115 kV Section 64 AC transmission line from the existing Larrabee Road substation to the existing Surowiec substation |
|
v. |
Partial rebuild of 0.8 mile each of 115 kV section 60/88 outside Coopers Mills substation |
|
vi. |
Partial rebuild of 0.3 miles of 345 kV Section 392 AC transmission line between the Coopers Mills substation and the Maine Yankee substation and approximately 3.5 miles of reconductor work on existing double circuit lattice steel towers outside of the Maine Yankee substation |
|
vii. |
Partial rebuild of 0.3 miles of 345 kV Section 3025 between Coopers Mills substation and Larrabee Road substation |
|
viii. |
Partial rebuild 0.8 miles of 34.5 kV Section 72 AC transmission line outside of the Larrabee Road substation |
|
b. |
Substation Equipment: |
|
i. |
Replace existing Larrabee Road 345/115 kV 448 MVA autotransformer with a 600 MVA autotransformer |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Maine Yankee substation |
A-2
|
iii. |
Add 345 kV AC transmission line terminal and 115 kV switch replacements at the existing Surowiec substation |
|
iv. |
115 kV Switch and bus wire replacements at Crowley substation |
|
v. |
New 345 kV Fickett Road substation with 345 kV +/-200 MVAr Static Compensator (STATCOM) |
|
vi. |
Add 345 kV AC transmission line terminal and additional 345 kV +/-200 MVAr STATCOM (+/-400 MVAr total with the +/-200 MVAr existing) at the existing Coopers Mills substation |
|
vii. |
Add 345/115 kV 448 MVA autotransformer, associated 115 kV buswork and terminate existing 115 kV Sections 164, 164A and 165 into three new breaker-and-a-half bays at the existing Raven Farm substation |
A-3
The NECEC transmission components located in Maine are depicted geographically in relationship to the existing Owner transmission system in Figure 1 below.
Figure 1 – Map Depicting the Components of the NECEC Transmission Line
A-4
The Québec Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 65 mile +/-320 kV HVDC transmission line from the Appalaches substation located in Thetford Mines to the U.S. border |
|
b. |
Substation Equipment : |
|
i. |
New +/-320 kV, 1200 MW HVDC converter connected to the 735 kV AC bus of the Appalaches substation and associated 735 kV bus work |
|
(2) |
Network Upgrades (subject to change based on additional system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
Thermal upgrade of existing 735 kV lines 7005 and 7035 (68 miles from Lévis substation to Nicolet substation) |
|
ii. |
Thermal upgrade of existing 735 kV line 7049 (44 miles from Montérégie substation to Hertel substation) |
|
b. |
Substation Equipment: |
|
i. |
Add two 200 MVAr shunt capacitor banks at the Carignan substation |
|
ii. |
Add one 330 MVAr shunt reactor at the Carignan substation |
A-5
Critical Milestones
Item |
Critical Milestone* |
Due Date** |
1. |
Closing of Any Required Financing |
March 7, 2019 |
2. |
Receipt of all Owner Approvals (other than Municipal Owner Approvals) and AC Upgrade Approvals in Final Form |
December 14, 2019 |
3. |
Receipt of all Canadian Approvals |
March 11, 2021 |
4. |
Receipt of all Municipal Owner Approvals |
March 31, 2022 |
5. |
Execution of Contract with the Manufacturer of the Converter Station at the Southern End of the HVDC Line and associated minimum 5% contract value payment |
July 30, 2019 |
6. |
Execution of Contract for the Engineering, Procurement, or Construction of the Converter Station on the Québec Line |
July 30, 2019 |
7. |
Commercial Operation Date |
December 13, 2022 |
* |
As defined in Section 4.1(a) |
** |
Subject to extension in accordance with the Agreement. |
A-6
Owner Approvals
Set forth below are the Governmental Approvals and Third Party Consents, in each case, required to commence construction of and operate the NECEC Transmission Line:
|
1. |
ISO-NE: Approval pursuant to Section I.3.9 of the ISO-NE Tariff to interconnect and operate the NECEC Transmission Line at no fewer than 1,040 MW |
|
2. |
Maine Public Utilities Commission (MPUC): Certificate of Public Convenience and Necessity (CPCN) |
|
3. |
U.S. Department of Energy (DOE): Presidential Permit |
|
4. |
Maine Department of Environmental Protection (MDEP): |
|
a. |
Site Location of Development Act (SLODA) Permit |
|
b. |
Stormwater Management Permit |
|
c. |
Natural Resources Protection Act (NRPA) Permit |
|
d. |
Clean Water Act (CWA) Section 401 Water Quality Certification |
|
e. |
Maine Construction General Permit |
The SLODA Permit, Stormwater Management Permit, NRPA Permit, and CWA Section 401 Water Quality Certification may be combined into one permit.
|
5. |
Maine Land Use Planning Commission (LUPC): Certificate of Compliance |
|
6. |
Maine Department of Agriculture, Conservation and Forestry: |
|
a. |
Submerged Lands Lease |
|
b. |
Public Reserved Land Lease |
|
7. |
Maine Department of Transportation (DOT): |
|
a. |
Utility Location/Road Opening Permits |
|
b. |
Driveway/Entrance Permits |
|
8. |
U.S. Army Corps of Engineers: |
|
a. |
CWA Section 404 - Individual Permit |
|
b. |
Section 10 Rivers & Harbors Act of 1899 |
|
9. |
Federal Aviation Administration Infrastructure in Vicinity of Airports: Determination of No Hazard to Air Navigation |
|
10. |
Municipal Owner Approvals: |
|
a. |
The Municipal Owner Approvals consist of the following types of permits: |
|
i. |
Shoreland zoning permits |
|
ii. |
Building permits |
|
iii. |
Flood hazard development permits |
A-7
|
v. |
Site plan / subdivision approvals |
|
vi. |
Driveway / entrance permits |
|
vii. |
Street opening, blasting and demolition permits |
|
viii. |
Utility location permits |
|
b. |
Owner shall obtain the Municipal Owner Approvals listed above that are necessary (if any) in the following municipalities for the NECEC Transmission Line, subject to any necessary exemptions issued by the MPUC relating to any Municipal Owner Approvals that are denied in any such municipalities or relating to any conditions contained in any Municipal Owner Approvals that are unacceptable to Owner: |
|
i. |
|
ii. |
Lewiston |
|
iii. |
Anson |
|
iv. |
Livermore Falls |
|
v. |
Auburn |
|
vi. |
Moscow |
|
vii. |
Caratunk |
|
viii. |
New Gloucester |
|
ix. |
Chesterville |
|
x. |
New Sharon |
|
xi. |
Durham |
|
xii. |
Pownal |
|
xiii. |
Embden |
|
xiv. |
Starks |
|
xv. |
Farmington |
|
xvi. |
Whitefield |
|
xvii. |
Greene |
|
xviii. |
Wilton |
|
xix. |
Industry |
|
xx. |
Windsor |
|
xxi. |
Jay |
A-8
Canadian Approvals
Set forth below are, to the best of HQUS’s knowledge, the Governmental Approvals and Third Party Consents, in each case, required to commence construction of the Québec Line:
|
• |
Permit from the National Energy Board to construct, operate, maintain or connect an international power line pursuant to the National Energy Board Act (R.S. C., 1985, c. N-7); |
|
• |
Permit from the International Boundary Commission required to cross the Canada-U.S. border pursuant to Article 5 of the International Boundary Commission Act; |
|
• |
Authorization from the Régie de l’énergie to acquire, construct or dispose of transmission assets pursuant to an Act respecting the Régie de l’énergie (R.S.Q., chapter R-6.01); |
|
• |
Expropriation Order in council, if required, to acquire by expropriation any immovable, servitude or construction required for the transmission of power pursuant to Hydro-Québec Act (R.S.Q., chapter H-5) and the Expropriation act (R.S.Q., chapter E-24); |
|
• |
Certificate of authorization issued by the Government of Québec to construct the transmission line under section 31.5 of the Environmental Quality Act subject to the environmental and social impact assessment and review procedure; |
|
• |
Certificate of authorization issued by the Ministère du Développement durable, de l’Environnement et de la Lutte contre les changements climatiques approving the plans and specifications of the transmission line pursuant to Section 22 of the Environmental Quality Act; |
|
• |
Authorization of the Commission de protection du territoire agricole du Québec , if required, approving the use of land situated in an agricultural zone for purposes other than agriculture under Sections 58 and 62 of the Act respecting the preservation of agricultural land and agricultural activities; |
|
• |
Opinion on project compliance with objectives of the city or regional county municipalities’ land-use and development plan. |
A-9
Owner’s Preliminary Project Schedule
A-10
A-11
A-12
A-13
A-14
A-15
A-16
A-17
A-18
A-19
A-20
A-21
A-22
A-23
A-24
A-25
A-26
A-27
Required Insurance
Owner shall obtain and maintain with qualified insurers authorized to issue insurance of the types described below in the State of Maine.
During construction of the NECEC Transmission Line Owner shall maintain or effect to be maintained the following insurance coverages:
|
• |
Primary and Excess Liability |
|
• |
Construction All Risk / Builders Risk |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
|
• |
Pollution / Environmental Liability |
After the Commercial Operation Date Owner shall provide coverage both in terms of scope and limits of coverage that are in accordance with Good Utility Practice and the long-standing practice of Owner. Operational coverage shall include the following insurance types:
|
• |
Excess Liability |
|
• |
Operational All Risk Property Damage |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
Note : At any time after the Commercial Operation Date Owner may choose, as far as it is consistent with Good Utility Practice, to self-insure on customary terms and conditions any coverage (or coverage part) where it meets any state or regulatory requirements of self-insurers.
A-28
Rate Adjustment Formula
In the event that a Transmission Service Payment is subject to reduction pursuant to Section 8.1 , such reduced payment shall equal the Transmission Service Payment that would otherwise be payable under the Agreement for a particular month multiplied by the lesser of 1 or the following fraction:
|
(Contract Capacity x 0.90) |
1 - |
minus (Contract Capacity x A) |
|
|
|
(Contract Capacity x 0.90) |
Where A = |
∑ Hourly Availability for all hours in such month |
∑ Hours in such month |
For purposes of calculating A, Excused Outages (for which Owner is paid full Transmission Service Payments pursuant to the terms of the Agreement) will be regarded as hours in which one hundred percent (100%) of Contract Capacity was provided.
A-29
Refund Calculation
This example is intended to illustrate the methodology for the calculation of a subsequent refund of a late payment. This example and the numbers used in this example are purely illustrative and are in no way intended to supersede any part of the Agreement, including Section 13.3.
Assumptions
|
• |
Interest Rate = 12 percent per annum (compounded monthly) |
June 2023 Billing
Invoice Amount
|
$1,000 |
Date of Invoice |
June 1, 2023
|
Due Date |
June 15, 2023
|
Payment Date |
July 1, 2023
|
The total amount due on the date of payment is $1,005, which amount is computed by adding $1,000 (the original amount invoiced) and $5 (the ½ month late interest fee).
Subsequent Refund
If later, on July 1, 2024, the aforesaid payment is required to be refunded, the refund will equal the $1,000 payment made on July 1, 2023 (the original amount invoiced), plus the interest accrued on that $1,000 payment from the due date of June 15, 2023 to the date of refund on July 1, 2024. To ensure that the refund does not double recover interest, the following language has been included in Section 13.3 of the Agreement: “[I]f all or a portion of the amount [ here, the $1,000 payment due on June 15, 2023 ] to which such interest relates [ here, the $5 late interest fee ] is later refunded pursuant to this Agreement [ here, on July 1, 2024 ], then, in calculating that refund, such interest [ here, $5 ] shall not be included in the refund.”
A-30
Real Estate Rights
A-31
A-32
A-33
A-34
A-35
A-36
A-37
A-38
A-39
A-40
A-41
A-42
A-43
A-44
A-45
A-46
A-47
A-48
A-49
A-50
A-51
A-52
A-53
A-54
A-55
A-56
A-57
A-58
A-59
A-60
A-61
A-62
A-63
A-64
A-65
Transmission Service Payment Calculation
The Transmission Service Payment for a given calendar month shall be equal to the unit price per kW-month for the then-current Contract Year (the “ Unit Price ”), as set forth in the table below, multiplied by the Contract Capacity expressed in kW.
Contract Year |
Unit Price
|
Contract Year 1 |
$9.16 |
Contract Year 2 |
$9.35 |
Contract Year 3 |
$9.53 |
Contract Year 4 |
$9.73 |
Contract Year 5 |
$9.92 |
Contract Year 6 |
$10.12 |
Contract Year 7 |
$10.32 |
Contract Year 8 |
$10.53 |
Contract Year 9 |
$10.74 |
Contract Year 10 |
$10.95 |
Contract Year 11 |
$11.17 |
Contract Year 12 |
$11.40 |
Contract Year 13 |
$11.62 |
Contract Year 14 |
$11.86 |
Contract Year 15 |
$12.09 |
Contract Year 16 |
$12.33 |
Contract Year 17 |
$12.58 |
Contract Year 18 |
$12.83 |
Contract Year 19 |
$13.09 |
Contract Year 20 |
$13.35 |
In the event the anniversary of the Commercial Operation Date falls within the middle of a calendar month (month M), the Unit Price for each month M shall be equal to: the Unit Price for the Contract Year that is ending (Contract Year Y), multiplied by the proportion of the days of the calendar month M that are part of that Contract Year Y, plus the Unit Price for the Contract Year that is beginning (Contract Year Y+1), multiplied by the proportion of the days of the calendar month M that are part of that Contract Year Y+1, the resulting calculation being rounded to the nearest cent.
A-66
Examples . For all examples, assume the Commercial Operation Date is December 13, 2022, with December being month M.
|
• |
Example 1 . The Unit Price for the month of December 2022 is as follows: (($0 [no Transmission Service Payment prior to Contract Year 1] * 12/31 [proportion of days in December 2022 that are prior to Contract Year 1]) + ($9.16 [Unit Price for Contract Year 1] * 19/31 [proportion of days in December that are part of Contract Year 1])) = $5.61/kW-month. |
|
• |
Example 2 . The Unit Price for the month of December 2023 is as follows: (($9.16 [Unit Price for Contract Year 1] * 12/31 [proportion of days in December that are part of Contract Year 1]) + ($9.35 [Unit Price for Contract Year 2] * 19/31 [proportion of days in December that are part of Contract Year 2])) = $9.28/kW-month. |
|
• |
Example 3 . The Unit Price for the month of December 2041 is as follows: (($13.35 [Unit Price for Contract Year 20] * 12/31 [proportion of days in December that are part of Contract Year 20]) + ($0 [no Transmission Service Payment after Contract Year 20] * 19/31 [proportion of days in December that are after end of Contract Year 20])) = $5.17/kW-month. |
A-67
Exhibit 10.3
TRANSMISSION SERVICE AGREEMENT
by and between
CENTRAL MAINE POWER COMPANY,
as Owner,
and
MASSACHUSETTS ELECTRIC COMPANY and NANTUCKET ELECTRIC COMPANY D/B/A NATIONAL GRID,
collectively as Distribution Company
Dated: as of June 13, 2018
TABLE OF CONTENTS
|
|
Page |
|
|
|
Article I DEFINITIONS AND RULES OF INTERPRETATION |
|
2 |
Section 1.1 Definitions |
|
2 |
Section 1.2 Interpretation |
|
15 |
|
|
|
Article II REGULATORY FILINGS AND REQUIRED APPROVALS |
|
16 |
Section 2.1 MDPU Filing; FERC Filing |
|
16 |
Section 2.2 Modifications to FERC Order |
|
17 |
Section 2.3 Modifications Pursuant to Unfavorable MDPU Order |
|
17 |
Section 2.4 Cooperation |
|
18 |
Section 2.5 No Inconsistent Action |
|
18 |
|
|
|
Article III EFFECTIVE DATE; TERM |
|
18 |
Section 3.1 Effective Date |
|
18 |
Section 3.2 Term |
|
19 |
Section 3.3 Termination Rights |
|
19 |
Section 3.4 Termination Payments |
|
21 |
Section 3.5 Effect of Termination |
|
21 |
|
|
|
Article IV COMMERCIAL OPERATION |
|
22 |
Section 4.1 Critical Milestones. |
|
22 |
Section 4.2 Commercial Operation Date |
|
24 |
Section 4.3 Conditions Precedent to Commercial Operation |
|
24 |
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation |
|
25 |
|
|
|
Article V GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES |
|
27 |
Section 5.1 Responsibilities of the Parties |
|
27 |
Section 5.2 Schedules and Reports |
|
28 |
Section 5.3 Insurance and Events of Loss |
|
29 |
Section 5.4 Compliance with Laws |
|
29 |
Section 5.5 Third Party Contracts |
|
29 |
Section 5.6 Continuity of Rights and Responsibilities |
|
29 |
|
|
|
Article VI PROCEDURES FOR OPERATION AND MAINTENANCE OF THE NECEC TRANSMISSION LINE |
|
30 |
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control |
|
30 |
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements |
|
30 |
Section 6.3 Scheduled Maintenance |
|
31 |
|
|
|
Article VII DISTRIBUTION COMPANY’S TRANSMISSION RIGHTS OVER THE NECEC TRANSMISSION LINE |
|
31 |
Section 7.1 Transmission Service |
|
31 |
Section 7.2 Excused Outages or Reductions |
|
32 |
Section 7.3 Non-Excused Outages or Reductions |
|
32 |
Section 7.4 Allocation of Outages |
|
33 |
i
|
33 |
|
Section 7.6 Line Availability Information and Reporting |
|
33 |
|
|
|
Article VIII PAYMENTS FOR TRANSMISSION SERVICE OVER THE NECEC TRANSMISSION LINE |
|
34 |
Section 8.1 Transmission Service Payments |
|
34 |
Section 8.2 Elective Upgrade Status; No Regional Rates |
|
34 |
|
|
|
Article IX RIGHTS UPON EXPIRATION OF TERM |
|
34 |
Section 9.1 Rollover and Other Rights |
|
34 |
|
|
|
Article X TRANSFER AND RESALE OF TRANSMISSION RIGHTS |
|
35 |
Section 10.1 Transfer of Transmission Rights |
|
35 |
Section 10.2 Resale Rights |
|
35 |
Section 10.3 Capacity Releases for Daily and Hourly Use |
|
35 |
Section 10.4 OASIS |
|
35 |
Section 10.5 Proceeds from Capacity Releases and Transmission Resales |
|
35 |
Section 10.6 Owner’s Rights and Obligations |
|
36 |
|
|
|
Article XI REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS |
|
36 |
Section 11.1 Real Power Losses |
|
36 |
Section 11.2 Other Rights |
|
36 |
|
|
|
Article XII [INTENTIONALLY OMITTED] |
|
37 |
|
|
|
Article XIII BILLING AND PAYMENTS |
|
37 |
Section 13.1 Invoices |
|
37 |
Section 13.2 Procedures for Billing Disputes |
|
37 |
Section 13.3 Interest |
|
37 |
Section 13.4 Obligation to Make Payments |
|
38 |
Section 13.5 Offsets |
|
38 |
|
|
|
Article XIV EVENTS OF DEFAULT AND REMEDIES |
|
38 |
Section 14.1 Distribution Company Defaults |
|
38 |
Section 14.2 Owner Defaults |
|
38 |
Section 14.3 Remedies Upon Distribution Company Default |
|
40 |
Section 14.4 Remedies Upon Owner Default |
|
41 |
Section 14.5 Abandoned Plant Recovery |
|
42 |
Section 14.6 Disputes |
|
43 |
Section 14.7 Limitations on Total Liability |
|
43 |
|
|
|
Article XV FORCE MAJEURE |
|
43 |
Section 15.1 Definition; Conditions |
|
43 |
|
|
|
Article XVI FINANCIAL ASSURANCES |
|
45 |
Section 16.1 Owner Security |
|
45 |
|
|
|
Article XVII DISPUTE RESOLUTION |
|
46 |
Section 17.1 Consultation |
|
46 |
ii
|
46 |
|
Section 17.3 Consent to Jurisdiction |
|
47 |
Section 17.4 WAIVER OF JURY TRIAL |
|
47 |
|
|
|
Article XVIII LIMITATION OF REMEDIES |
|
47 |
|
|
|
Article XIX MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES. |
|
48 |
Section 19.1 Modifications |
|
48 |
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment |
|
48 |
|
|
|
Article XX INDEMNIFICATION |
|
49 |
Section 20.1 Owner Indemnity |
|
49 |
Section 20.2 [Intentionally Omitted] |
|
50 |
Section 20.3 Procedures |
|
50 |
Section 20.4 Defenses |
|
50 |
Section 20.5 Cooperation |
|
50 |
Section 20.6 Recovery |
|
51 |
Section 20.7 Subrogation |
|
51 |
|
|
|
Article XXI REPRESENTATIONS, WARRANTIES AND COVENANTS |
|
51 |
Section 21.1 Mutual Representations and Warranties |
|
51 |
Section 21.2 Additional Representations and Warranties of Owner |
|
52 |
Section 21.3 Additional Representations and Warranties of Distribution Company |
|
53 |
Section 21.4 NO OTHER REPRESENTATIONS OR WARRANTIES |
|
54 |
|
|
|
Article XXII TRANSFER OF INTERESTS |
|
54 |
Section 22.1 No Transfer of Interests |
|
54 |
Section 22.2 Exceptions |
|
55 |
Section 22.3 Collateral Assignment |
|
56 |
|
|
|
Article XXIII MISCELLANEOUS |
|
56 |
Section 23.1 Governing Law |
|
56 |
Section 23.2 Entire Agreement |
|
56 |
Section 23.3 Severability |
|
57 |
Section 23.4 Notices |
|
57 |
Section 23.5 Intentionally Omitted |
|
58 |
Section 23.6 Waiver; Cumulative Remedies |
|
58 |
Section 23.7 Confidential Information |
|
59 |
Section 23.8 No Third-Party Rights |
|
59 |
Section 23.9 Permitted Successors and Assigns |
|
60 |
Section 23.10 Relationship of the Parties |
|
60 |
Section 23.11 Construction |
|
60 |
Section 23.12 Counterparts |
|
60 |
Section 23.13 Survival |
|
60 |
Section 23.14 Headings and Table of Contents |
|
60 |
Section 23.15 Waiver of Immunities |
|
60 |
iii
ATTACHMENTS
Attachment A |
|
Description of Transmission Projects |
Attachment B |
|
Critical Milestones |
Attachment C |
|
Owner Approvals |
Attachment D |
|
Canadian Approvals |
Attachment E |
|
Owner’s Preliminary Project Schedule and Construction Schedule |
Attachment F |
|
Required Insurance |
Attachment G |
|
Rate Adjustment Formula |
Attachment H |
|
Refund Calculation |
Attachment I |
|
Real Estate Rights |
Attachment J |
|
Transmission Service Payment Calculation |
iv
TRANSMISSION SERVICE AGREEMENT
This TRANSMISSION SERVICE AGREEMENT (this “ Agreement ”), dated as of June 13, 2018 (the “ Execution Date ”), is made and entered into by and between Central Maine Power Company, a corporation organized and existing under the laws of the State of Maine (“ Owner”) , and Massachusetts Electric Company and Nantucket Electric Company (d/b/a National Grid), corporations organized and existing under the laws of the Commonwealth of Massachusetts, (collectively “ Distribution Company ”). Owner and Distribution Company are hereinafter sometimes also referred to individually as a “ Party ” or collectively as the “ Parties .”
WITNESSETH
WHEREAS, pursuant to “An Act to Promote Energy Diversity” that was signed into law in the Commonwealth of Massachusetts on August 8, 2016 (the “ Energy Diversity Act ”), Fitchburg Gas & Electric Light Company (d/b/a Unitil), Massachusetts Electric Company (d/b/a National Grid), Nantucket Electric Company (d/b/a National Grid), and NSTAR Electric Company (d/b/a Eversource) (collectively, the “ RFP Sponsors ”) have solicited competitive proposals for clean energy generation for an annual amount of electricity equal to approximately 9.45 TWh;
WHEREAS, Owner and an Affiliate of H.Q. Energy Services (U.S.) Inc., a corporation organized and existing under the laws of the State of Delaware (“HQUS”), jointly submitted a proposal pursuant to such solicitation that includes up to 1,090 MW of clean energy generation obtained by HQUS from its affiliate Hydro-Québec Production (a division of Hydro-Québec (as defined below), “ HQP ” and such generation, the “ Hydro Generation ”);
WHEREAS, concurrently with the execution and delivery of this Agreement, HQUS has entered into a power purchase agreement (the “ PPA ”) with Distribution Company and additional power purchase agreements (the “ Additional PPAs ”) with the other RFP Sponsors with respect to an aggregate of 1,090 MW of Hydro Generation (and related renewable energy credits and environmental attributes);
WHEREAS, as part of the delivery of 1,090 MW of Hydro Generation for sale into the U.S. pursuant to the PPA and the Additional PPAs, Hydro-Québec TransÉnergie (“ TransÉnergie ”), a division of Hydro-Québec, intends to develop, construct, own and maintain a 1,200 MW +/-320 kV high-voltage direct current (“ HVDC ”) transmission line from the converter station at the Appalaches substation in Thetford Mines, Québec to the U.S. Border (as defined below) at Beattie Township, Maine (as further delineated in the diagram or described in Attachment A, the “ Québec Line ”);
WHEREAS, HQP has acquired from TransÉnergie firm transmission service over the Québec Line to permit the delivery of at least 1,200 MW of power into the U.S.;
WHEREAS, Owner intends to develop, construct, own and maintain a 1,200 MW +/-320 kV HVDC transmission line extending from the U.S. Border at Beattie Township, Maine to a new direct current to alternating current (“ AC ”) converter station to be located at Merrill Road in the City of Lewiston in the State of Maine (the transmission line and converter station, as more fully described in Attachment A, the “ HVDC Line ”);
1
WHEREAS, in order to interconnect the HVDC Line with the bulk power systems in New England, Owner intends to develop, construct, own and maintain additional 345 kV AC transmission lines, rebuilt 115 kV AC transmission lines and other substation equipment more fully described in Attachment A (together with the Merrill Road substation at its northern terminus and the associated equipment, as more fully described in Attachment A, the “ AC Line ” and, together with the HVDC Line, the “ NECEC Transmission Line ” );
WHEREAS, although Owner has performed studies believed to replicate those utilized by ISO-NE and does not believe that AC Upgrades (as defined below) or CCIS Capacity Upgrades (as defined below) will be required as a consequence of the construction and operation of the NECEC Transmission Line and the consummation of the transactions contemplated by this Agreement, this Agreement, the Additional TSAs (as defined below), the PPA or the Additional PPAs, ISO-NE (as defined below) may require certain AC Upgrades or CCIS Capacity Upgrades to be developed, constructed, owned and maintained by certain transmission owners other than Owner (which may include Affiliates of Owner) within their existing service territories in New England in order to interconnect the NECEC Transmission Line with the New England Transmission System (as defined below) in a safe and reliable manner, which AC Upgrades or CCIS Capacity Upgrades (if any) will be performed at Owner’s sole expense;
WHEREAS, concurrently with the execution and delivery of this Agreement, Owner has entered into (a) certain Additional TSAs with the other RFP Sponsors to sell an aggregate of 591.652 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date (as defined below), (b) certain Additional TSAs with HQUS to sell an aggregate of 1,090 MW of firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date and (c) the Additional HQUS TSA (as defined below) with HQUS; and
WHEREAS, Owner desires to sell Firm Transmission Service (as defined below) to Distribution Company for the first twenty (20) years following the Commercial Operation Date, and Distribution Company desires to acquire such Firm Transmission Service from Owner, at the rates and on the terms and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the foregoing and the respective representations, warranties, covenants, agreements and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound hereby, the Parties hereby agree as follows:
Article I
DEFINITIONS AND RULES OF INTERPRETATION
Section 1.1 Definitions . As used herein, the following terms shall have the following respective meanings:
“ AC ” has the meaning provided in the recitals to this Agreement.
“ AC Line ” has the meaning provided in the recitals to this Agreement.
“ AC Upgrade Approvals ” means, collectively, any Governmental Approvals or Third Party Consents, in each case, that are required to commence construction of the AC Upgrades.
2
“ AC Upgrade Owners ” means, collectively, any Person responsible for constructing one or more AC Upgrades pursuant to a facilities agreement.
“ AC Upgrades ” means any additions, upgrades, reinforcements or other modifications to the New England Transmission System that ISO-NE determines, pursuant to Section I.3.9 of the ISO-NE Tariff, to be required, at a minimum, to interconnect the NECEC Transmission Line at the Delivery Point with the New England Transmission System.
“ Additional HQUS TSA ” means that certain Transmission Service Agreement between HQUS and Owner, dated as of the date hereof, pursuant to which HQUS has acquired transmission service for up to 110 MW of capacity for forty (40) years following the Commercial Operation Date.
“ Additional HQUS TSA Capacity ” means the firm capacity of the NECEC Transmission Line of up to 110 MW that HQUS has committed in the Additional HQUS TSA to purchase in the forty (40) years following the Commercial Operation Date.
“ Additional PPAs ” has the meaning provided in the recitals to this Agreement.
“ Additional TSA ” means (a) any transmission service agreement entered into between an RFP Sponsor and Owner (other than this Agreement), pursuant to which such RFP Sponsor acquires firm transmission service for the first twenty (20) years following the Commercial Operation Date, (b) any transmission service agreement entered into between HQUS and Owner (including the HQUS TSA), pursuant to which HQUS acquires firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date or (c) the Additional HQUS TSA.
“ Adverse Determination ” has the meaning provided in Section 19.2(c) .
“ Advisory Ruling ” has the meaning provided in Section 8.4 of the PPA.
“ Affiliate ” means, with respect to a specified Person, any other Person that directly or indirectly Controls, is Controlled by or is under common Control with the specified Person; provided , however , that, with respect to HQUS, a Person shall not be an “Affiliate” of HQUS unless such Person is Hydro-Québec (including, for the avoidance of doubt, a division of Hydro-Québec) or Controlled by Hydro-Québec.
“ Agreement ” has the meaning provided in the preamble to this Agreement.
“ Applicable Law ” means any duly promulgated federal, national, state, provincial or local law, regulation, rule, ordinance, code, decree, judgment, directive or judicial or administrative order, permit or other duly authorized and valid action of any Governmental Authority, including any binding interpretation of any of the foregoing by any Governmental Authority, which is applicable to a Person, its property or a transaction, and also including without limitation Section 83D of the Energy Diversity Act (“ Section 83D” ), the regulations promulgated under Section 83D, the Regulatory Approval and any other orders of the MDPU with respect to this Agreement.
“ Approval Deadline ” means December 14, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
3
“ Available Transfer Capability ” means the lesser of (a) 1,090 MW or (b) the Total Transfer Capability.
“ Bankruptcy Code ” means the United States Bankruptcy Code, 11 U.S.C. § 101 et seq.
“ Business Day ” means any day except Saturday, Sunday or any other day on which the Federal Reserve member banks are required or authorized to close for business.
“ Canadian Approvals ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the Québec Line in a manner consistent with Attachment A, all as set forth in Attachment D.
“ Canadian Approval Deadline ” means March 11, 2021 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Cash ” shall mean U.S. dollars held by or on behalf of a Party as Credit Support hereunder.
“ CCIS Capacity Upgrade ” means any upgrade determined by ISO-NE as necessary in order for the NECEC Transmission Line Capacity to satisfy the Capacity Capability Interconnection Standard under the ISO-NE Tariff.
“ COD Notice ” has the meaning provided in Section 4.2(c) .
“ Commercial Operation ” means the availability of the NECEC Transmission Line for the provision of Firm Transmission Service in accordance with this Agreement and the HQUS TSA.
“ Commercial Operation Date ” has the meaning provided in Section 4.2(c) .
“ Commissioning ” means (a) with respect to the NECEC Transmission Line, the start-up and testing activities required to demonstrate that the NECEC Transmission Line is ready for Commercial Operation and (b) with respect to the Québec Line, the start-up and testing activities required to demonstrate that the Québec Line is ready for commercial operation, consistent with Section 4.3(f) .
“ Concurrent Delay ” has the meaning provided in Section 4.4.2(a) .
“ Confidential Information ” means (a) this Agreement (including Attachments), (b) any documents, analyses, compilations, studies, or other materials prepared by or information received from a Party or its representatives that contain or reflect written or oral data or information that is privileged, confidential or proprietary and that is marked or otherwise clearly identified as “confidential” or “proprietary” or with words of like meaning, or (c) any subsequently prepared documents, analyses, compilations, studies or other materials or information that are derived from any of the documents, analyses, compilations, studies or other materials or information described in the foregoing clause (b). Without limiting the generality of the foregoing, all information provided to Distribution Company or Owner under Sections 2.4 , 5.2 and 6.3 hereof shall be deemed to be Confidential Information, whether or not such information is marked as “confidential” or “proprietary.”
“ Consent ” means, with respect to a Person, any approval, consent, permit, license, decree, certificate or other authorization of or from such Person.
4
“ Construction Authorizations ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the NECEC Transmission Line, other than the ISO-NE Approval, including the approvals of the Maine Department of Environmental Protection, the U.S. Army Corp of Engineers, the Maine Public Utilities Commission and the U.S. Department of Energy (the Presidential Permit), as more fully set forth in Attachment C.
“ Construction Contract ” means any contract entered into by Owner that provides for the engineering, procurement or construction of the NECEC Transmission Line.
“ Construction Phase ” means the period commencing upon the receipt of the FERC Authorization or such other date to which the Parties shall mutually agree in writing, and ending on the day immediately preceding the Commercial Operation Date or upon the earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Contract Capacity ” means the Proportionate Share multiplied by the NECEC Transmission Line Capacity.
“ Contract Year ” means each twelve-month period during the Term, with the first Contract Year commencing on the Commercial Operation Date and with each Contract Year after the first commencing on the anniversary of the Commerical Operation Date.
“ Control ” (including its correlative meanings “Controlled by” and “under common Control with”) means, with respect to a Person, the possession, directly or indirectly, of the power to direct or cause the direction of the management or policies of the specified Person, whether through ownership of voting securities or partnership or other ownership interests, by contract or Applicable Law or otherwise.
“ Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) , or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Credit Support ” means collateral in the form of (a) Cash or (b) a Letter of Credit issued by a Qualified Bank in a form reasonably satisfactory to the beneficiary.
“ Critical Energy Infrastructure Information ” means any information defined as Critical Energy Infrastructure Information by FERC pursuant to 18 C.F.R. § 388.113, and shall include all Critical Infrastructure Protection (CIP) standards (CIP-002 through CIP-009) established by NERC.
“ Critical Milestone ” has the meaning provided in Section 4.1(a) .
“ Delivery Point ” means the southern terminus of the NECEC Transmission Line at the Larrabee Road substation in Lewiston, Maine, as illustrated in Attachment A.
“ Design Capability ” means the maximum amount of electric power that the materials, equipment and structures comprising the HVDC Transmission Project will be designed to transfer bi-directionally in a safe and reliable manner, which amount shall be sufficient to permit the north-to-south delivery of all amounts scheduled for delivery in an aggregate amount of at least 1,090 MW, but not to exceed 1,200 MW, of electrical energy at the Delivery Point.
5
“ Discount Rate ” means the prime rate specified in the “Money and Investing” section of the Wall Street Journal, determined as of the date of notice of default, plus 300 basis points.
“ Dispute ” means any dispute, controversy or claim of any kind whatsoever arising out of or relating to a Proposal Agreement, including relating to the interpretation of the terms thereof or any Applicable Law that affects such Proposal Agreement, or the transactions contemplated thereunder, or the breach, termination or validity thereof.
“ Distribution Company ” has the meaning provided in the preamble to this Agreement.
“ Distribution Company Default ” has the meaning provided in Section 14.1 .
“ Distribution Company Indemnified Party ” has the meaning provided in Section 20.1 .
“ Distribution Company Termination Payment ” means, if Distribution Company is the defaulting Party, (a) prior to the Commercial Operation Date, an amount equal to the Proportionate Share of all costs prudently incurred by Owner as of the termination date in connection with the development and construction of the NECEC Transmission Line, or (b) on or after the Commercial Operation Date, an amount equal to the Proportionate Share multiplied by the Net Book Value of the NECEC Transmission Line. In either of these cases the Distribution Company Termination Payment will be reduced by the present value, discounted at the Discount Rate, of the Proportionate Share of the revenues (after taxes), if any; (i) received or to be received by Owner from HQUS as successor to Distribution Company under this Agreement pursuant to Sections 8.2 and 14.8 of the HQUS TSA, and (ii) to be received by Owner from long term transmission services provided to other third parties on the NECEC Transmission Line during the remaining Term of the Agreement. For the purpose of these calculations, the revenues will be reduced by the operating costs incurred, or projected by Owner in good faith to be incurred, to provide the corresponding services and by the costs and losses incurred or experienced by Owner as a consequence of the Distribution Company’s default. The reductions determined in accordance with clauses (i) and (ii) above will be limited to the amounts determined in accordance with clauses (a) and (b) above, and the reduction described in clause (ii) above will be determined considering only 90% of the revenues to be received. For purposes of calculating the Distribution Company Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW .
“ Effective Date ” has the meaning provided in Section 3.1 .
“ Excused Outages ” has the meaning provided in Section 7.2(a) .
“ Execution Date ” has the meaning provided in the preamble to this Agreement.
“ Federal Power Act ” means the United States Federal Power Act of 1935, as amended, 16 U.S.C. § 791a et seq.
“ FERC ” means the Federal Energy Regulatory Commission, or any successor regulatory agency that administers the Federal Power Act.
“ FERC Amendment ” has the meaning provided in Section 2.2(b) .
“ FERC Authorization ” means, collectively, any FERC order which is not subject to rehearing or appeal authorizing Owner to provide Firm Transmission Service, including the FERC Order and any authorization from FERC with respect to the Transmission Operating Agreement or Interconnection Agreements.
6
“ FERC Order ” has the meaning provided in Section 2.2(a) .
“ Financial Transmission Rights ” means Financial Transmission Rights, as defined in the ISO-NE Tariff.
“ Financing Deadline ” means March 7, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing.
“ Firm Transmission Service ” has the meaning provided in Section 7.1.1.
“ Force Majeure ” has the meaning provided in Section 15.1(a) .
“ Good Utility Practice ” means those design, construction, operation, maintenance, repair, removal and disposal practices, methods and acts that are engaged in by a significant portion of the electric transmission industry in the United States during the relevant time period, or any other practices, methods or acts that, in the exercise of reasonable judgment in light of the facts known at the time a decision is made, could have been expected to accomplish a desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Good Utility Practice is not intended to be the optimum practice, method or act to the exclusion of others but rather to be a spectrum of acceptable practices, methods or acts generally accepted in such electric transmission industry for the design, construction, operation, maintenance, repair, removal and disposal of electric transmission facilities in the United States. Good Utility Practice shall not be determined after the fact in light of the results achieved by the practices, methods, or acts undertaken, but rather shall be determined based upon the consistency of (a) the practices, methods, or acts when undertaken with (b) the standard set forth in the first two (2) sentences of this definition at such time.
“ Governmental Approval ” means (a) any authorization, consent, approval, license, lease, ruling, permit, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with or (d) any registration by or with, any Governmental Authority, including any FERC Authorization.
“ Governmental Authority ” means any government or agency or other political subdivision thereof, including any province, state or municipality, or any other governmental, quasi-governmental, judicial, executive, legislative, administrative, regulatory, public or statutory instrumentality, authority, body, agency, commission, department, board, bureau or entity exercising judicial, executive, legislative, administrative or regulatory functions, any court or arbitrator with authority to bind a party at law, and shall include, to the extent exercising powers delegated by any Governmental Authority acting under Applicable Law, NERC and ISO-NE.
“ Hourly Availability ” means, with respect to any hour, the availability of the NECEC Transmission Line for the purposes of this Agreement, which shall equal (a) the Proportionate Share of the Available Transfer Capability for such hour, divided by (b) the Contract Capacity, expressed as a percentage; provided, however, that, for any hour, such availability of the NECEC Transmission Line shall not exceed one hundred percent (100%).
“ HQP ” has the meaning provided in the recitals to this Agreement.
“ HQUS ” has the meaning provided in the recitals to this Agreement.
7
“ HQUS Delay ” means delays in completing the Québec Line, whether due to operational difficulties or any other event that is not an event of Force Majeure.
“ HQUS TSA ” means that certain Transmission Service Agreement between HQUS and Owner, dated as of the date hereof, pursuant to which HQUS has acquired 498.348 MW of firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date.
“ HVDC ” has the meaning provided in the recitals to this Agreement.
“ HVDC Line ” has the meaning provided in the recitals to this Agreement.
“ HVDC Transmission Project ” means, collectively, (a) the Québec Line and (b) the NECEC Transmission Line.
“ Hydro Generation ” has the meaning provided in the recitals to this Agreement.
“ Hydro-Québec ” means Hydro-Québec, a body politic and corporate, duly incorporated and regulated by the Hydro-Québec Act (R.S.Q., Chapter H-5). As of the Execution Date, Hydro-Québec has four divisions: HQP, TransÉnergie, Hydro-Québec Distribution and Hydro-Québec Équipment.
“ Immunities Act ” means the United States Foreign Sovereign Immunities Act of 1976, 28 U.S.C. § 1602 et seq.
“ Indemnification Notice ” has the meaning provided in Section 20.3 .
“ Indemnified Party ” has the meaning provided in Section 20.3 .
“ Insolvency Event ” means, with respect to a Person, such Person (a) becomes “insolvent,” as defined in the Bankruptcy Code, or otherwise becomes bankrupt or insolvent under any Insolvency Laws, (b) has a liquidator, administrator, receiver, custodian, trustee, conservator or similar official appointed with respect to such Person or any material portion of such Person’s assets or such Person consents to such appointment, or a foreclosure action is instituted with respect to any material portion of such Person’s assets and is not dismissed within thirty (30) days of commencement thereof, (c) files a voluntary petition or otherwise authorizes or commences a proceeding or cause of action under the Bankruptcy Code or Insolvency Laws, (d) has an involuntary petition filed against it or acquiesces in the commencement of a proceeding or cause of action as the subject debtor under the Bankruptcy Code or Insolvency Laws, which petition is not dismissed within thirty (30) days after the filing thereof or results in the issuance of an order for relief against such Person, (e) makes or consents to an assignment of its assets in whole or in part, for the benefit of creditors or any general arrangement for the benefit of creditors, or a common law composition of creditors or (f) generally is unable to pay its debts as they fall due, or admits in writing to such inability.
“ Insolvency Laws ” means any bankruptcy, insolvency, reorganization or similar laws of the U.S. or other Governmental Authority, as applicable, other than the Bankruptcy Code.
8
“ Interconnection Agreements ” means, collectively, (a) an agreement by and among Owner, TransÉnergie and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the U.S. Border of the NECEC Transmission Line with the Québec Line and (b) an agreement by and between Owner and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the Delivery Point of the NECEC Transmission Line with certain transmission facilities operated by ISO-NE. The Interconnection Agreements shall address cost responsibilities among entities other than the Distribution Company and the other RFP Sponsors and shall include provisions, both technical and otherwise, for safe and reliable interconnected operations of the HVDC Transmission Project following Commercial Operation (including use of the HVDC Transmission Project for the delivery of electric power in emergency circumstances).
“ Interested Party ” shall mean, collectively, the Parties and, if and as applicable, HQUS and the other RFP Sponsors.
“ Invoice ” means, with respect to a calendar month, an invoice that sets forth the amounts owed to the applicable Party with respect to such month in reasonable detail to evidence the basis for individual billings and charges.
“ ISO-NE ” means ISO New England Inc., or its successor organization.
“ ISO-NE Approval ” means approval by ISO-NE to operate the NECEC Transmission Line up to 1,200 MW.
“ ISO-NE Definitions Manual ” means the ISO New England Manual for Definitions and Abbreviations, Manual M-35, as in effect from time to time.
“ ISO-NE Rules ” means the ISO-NE Tariff and all ISO-NE manuals, rules, procedures, agreements or other documents relating to the reliable operation of the electric system in New England and the purchase and sale of electrical energy, electrical capacity and ancillary services, as such govern market participants with respect thereto in the operating jurisdiction of ISO-NE, as in effect from time to time, including the ISO-NE Definitions Manual; provided that such documents are publicly accessible.
“ ISO-NE Tariff ” means the ISO New England Inc. Transmission, Markets and Services Tariff, FERC Electric Tariff No. 3, as in effect from time to time, on file with FERC, or its successor tariff.
“ kV ” means kilovolt.
“ K W ” means kilowatt.
“ Letter of Credit ” shall mean an irrevocable, non-transferable standby letter of credit issued by a Qualified Bank utilizing a form acceptable to the Party in whose favor such letter of credit is issued. All costs relating to any Letter of Credit shall be for the account of the Party providing that Letter of Credit.
9
“ Maintenance Plan ” means an annual plan for the management, operation and ordinary maintenance of the NECEC Transmission Line, which plan shall include a description of the scope and nature of the planned operating and maintenance programs and planned and preventive maintenance procedures for the NECEC Transmission Line, and the scheduled maintenance and other planned outages of the NECEC Transmission Line, in each case, in accordance with Section 6.3 hereof and the requirements of the PPA.
“ Market Products ” means, collectively, all products (however entitled and whether existing now or in the future) that (a) are recognized under ISO-NE Rules, (b) derive from the acquisition of transmission service over the NECEC Transmission Line under this Agreement and (c) can be sold for consideration or otherwise have economic value, including electrical energy, electrical capacity and ancillary services, including reserve products (including spinning and non-spinning reserves).
“ Material Adverse Effect ” means, with respect to a Party, a material adverse effect on the ability of such Party to perform any of its obligations under this Agreement.
“ MDPU ” means the Massachusetts Department of Public Utilities.
“ Minimum Average Availability ” means ninety percent (90%) of the Contract Capacity, provided that, during the Remediation Period, if applicable, for every ten (10) MW that the maximum operating capacity is below 1090 MW, the Minimum Average Availability shall be increased by one percent (1%), and provided further that if, at the earlier of the Remediation Date or the end of the Remediation Period, the operating capacity is below 1,090 MW, the Minimum Average Availability shall be increased by one-half of one percent (0.5%) for each 5 MW by which the operating capacity is below 1,090 MW.
“ Municipal Owner Approvals ” means the Owner Approvals identified in paragraph 10 of Attachment C that Owner reasonably determines are necessary to construct, own, and operate the NECEC Transmission Line.
“ Municipal Owner Approval Deadline ” means March 31, 2022 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ MW ” means megawatt.
“ MWh ” means megawatt-hour.
“ NECEC Facilities ” has the meaning provided in Section 8.2 .
“ NECEC Transmission Line ” has the meaning provided in the recitals to this Agreement.
“ NECEC Transmission Line Capacity ” means (a) 1,090 MW or (b) such lesser amount as may be established by the Commissioning of the NECEC Transmission Line, in each case, as measured at the Delivery Point; provided that the amount under clause (b) shall be increased if the capacity is increased after the Commercial Operation Date pursuant to Section 4.4.1(c).
“ NERC ” means the North American Electric Reliability Corporation, or its successor organization.
10
“ Net Book Value ” means, at any time, an amount equal to the original cost of construction minus depreciation (using a forty (40)-year depreciation schedule), as calculated in accordance with generally accepted accounting principles.
“ New England Transmission System ” means New England Transmission System, as defined in the ISO-NE Tariff.
“ Non-Excused Outage ” means any outage of the NECEC Transmission Line or reduction in the Total Transfer Capability below the NECEC Transmission Line Capacity, except due to an Excused Outage.
“ OASIS ” means the Open Access Same-Time Information System.
“ OASIS Administrator ” has the meaning provided in Section 10.4(a) .
“ Operation Phase ” means the period commencing on the Commercial Operation Date and ending upon the expiration of the Term or earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Other Transmission Rights ” means, collectively, any Financial Transmission Rights (or any similar concept), auction revenue rights or other financial or physical transmission rights, in each case, whether existing now or in the future, associated with the NECEC Transmission Line or AC Upgrades.
“ Owner ” has the meaning provided in the preamble to this Agreement.
“ Owner Approvals ” means, collectively, (a) the Construction Authorizations and (b) the ISO-NE Approval, all as set forth in Attachment C.
“ Owner Default ” has the meaning provided in Section 14.2 .
“ Owner Delay ” has the meaning provided in Section 4.4.1 .
“ Owner Security ” has the meaning provided in Section 16.1 .
11
“ Owner Termination Payment ” means, if Owner is the defaulting Party (a) prior to the Commercial Operation Date, an amount equal to the Owner Security together with any Credit Support held by Distribution Company pursuant to Section 4.1(c) , and (b) on or after the Commercial Operation Date (i) in the event that HQUS timely exercises its right to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under the Agreement pursuant to Section 14.7 of the HQUS TSA, the amount of any damages (including for the avoidance of doubt any lost profit) incurred by Distribution Company as a result of the Owner Default and (ii) otherwise an amount, if positive, calculated according to the following formula: (x) the present value, discounted at the Discount Rate, for each month remaining in the Services Term (as defined in the PPA), of ( A ) the amount, if, any, by which the forward market price of Energy and Environmental Attributes (both as defined in the PPA), as determined by the average of the quotes of at least two nationally recognized energy consulting firms or brokers chosen by Distribution Company, for Replacement Energy and Replacement Environmental Attributes, (both as defined in the PPA) exceeds the applicable Price (as defined in the PPA) that would have been paid pursuant to Exhibit D of the PPA, multiplied by (B) the amount of Guaranteed Qualified Clean Energy (as defined in the PPA) as provided in Exhibit B of the PPA; provided that, if Distribution Company receives a Termination Payment (as defined in the PPA) pursuant to Section 9.3 of the PPA (other than a Termination Payment received pursuant to Section 9.3(b)(iii) or Section 9.3(b)(iv)(B) of the PPA), the Owner Termination Payment shall equal zero.
“ Owner’s Construction Progress Report ” has the meaning provided in Section 5.2.3(a) .
“ Owner’s Construction Schedule ” has the meaning provided in Section 5.2.2 .
“ Owner’s Prelimi nary Schedule ” has the meaning provided in Section 5.2.1 .
“ Parties ” and “ Party ” have the meanings provided in the preamble to this Agreement.
“ Person ” means any legal person, including any natural person, domestic or foreign corporation, limited liability company, general or limited partnership, joint venture, association, joint stock company, business trust, estate, trust, enterprise, unincorporated organization, any Governmental Authority, or any other legal or commercial entity.
“ Physical Transmission Line Capacity ” means the sum of the NECEC Transmission Line Capacity and the Additional HQUS TSA Capacity.
“ Power Cost Reconciliation Tariff ” shall mean a fully reconciling cost recovery tariff mechanism that authorizes the establishment of a distribution charge that fully recovers Distribution Company’s net costs under this Agreement (including annual remuneration of up to two and three-quarters percent (2.75%)). The rate reconciliation shall be designed in such a way as to limit the build-up of any under or over-recoveries over the course of the year. A reconciliation shall occur at least annually, but may also be reconciled quarterly or monthly, to the extent necessary to eliminate regulatory lag for the recovery of costs or crediting of over-recoveries to customers.
“ PPA ” has the meaning provided in the recitals to this Agreement.
“ PPA Contract Maximum Amount ” means 498.348 MW, as such amount may be adjusted in accordance with the terms of the PPA.
12
“ Presidential Permit ” means the permit granted by the U.S. Department of Energy, pursuant to Executive Order 10485 as amended by Executive Order 12038, authorizing the construction, operation, maintenance and connection of facilities for the transmission of electric energy at the international border between the United States and Canada.
“ Project Schedule ” means a schedule setting forth the proposed engineering, procurement, construction and testing milestone schedule for (a) the NECEC Transmission Line based upon the Construction Contracts, (b) the Québec Line and (c) the AC Upgrades and the CCIS Capacity Upgrades based upon such information as can reasonably be obtained by Owner from the AC Upgrade Owners, recognizing that one or more Project Schedules will be completed and delivered before the date on which the AC Upgrades and the CCIS Capacity Upgrades are formally identified under this Agreement.
“ Proportionate Share ” means a fraction with the numerator equal to 498.348 MW and the denominator equal to 1,090 MW.
“ Proposal Agreements ” means, collectively, this Agreement, the Additional TSAs, the PPA and the Additional PPAs.
“ Purchased Power Accounting Authorization ” shall mean authorization for Distribution Company, at Distribution Company’s sole discretion, to take appropriate steps to assure avoidance of a material, negative balance sheet impact on Distribution Company or Distribution Company’s direct or indirect parent company, upon appropriate filing with and approval by the MDPU.
“ Qualified Bank ” means a U.S. commercial bank (or the U.S. branch of a foreign bank) having (a) assets on its most recent balance sheet of at least $10 billion and (b) a long-term credit rating of at least “A-” by S&P or “A3” by Moody’s (or its equivalent).
“ Québec Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Québec Line ” has the meaning provided in the recitals to this Agreement.
“ Real Power Losses ” means energy consumed by the electrical impedance characteristics of the NECEC Transmission Line.
“ Recovery ” has the meaning provided in Section 20.6 .
13
“ Regulatory Approval ” shall mean the MDPU approval of this entire Agreement, which approval shall include without limitation: (1) confirmation that this Agreement has been approved under Section 83D and the regulations promulgated thereunder and that all of the terms of such Section 83D and such regulations apply to this Agreement; (2) definitive regulatory authorization for Distribution Company to recover all of its costs incurred under and in connection with this Agreement for the entire term of this Agreement through the implementation of a Power Cost Reconciliation Tariff and/or other cost recovery or reconciliation mechanisms; (3) definitive regulatory authorization for Distribution Company to recover remuneration of up to two and three-quarters percent (2.75%) of Distribution Company’s annual payments under this Agreement for the term of this Agreement through the Power Cost Reconciliation Tariff; and (4) approval of any Purchased Power Accounting Authorization requested by Distribution Company in connection with the Regulatory Approval. Such approvals shall be acceptable in form and substance to Distribution Company in its sole discretion, shall not include any conditions or modifications that Distribution Company deems, in its sole discretion, to be unacceptable, and shall be final and not subject to appeal or rehearing.
“ Regulatory Approval Delay ” means any delay in the receipt of the Regulatory Approval beyond January 25, 2019.
“ Regulatory Approval Termination Outside Date ” has the meaning provided in Section 3.3.1(a) .
“ Remediation Date ” has the meaning provided in Section 4.4.1(b)(i) .
“ Remediation Period ” has the meaning provided in Section 4.4.1(b)(i) .
“ RFP Sponsors ” has the meaning provided in the recitals to this Agreement.
“ Scheduling Rules ” has the meaning provided in Section 7.1.3 .
“ State Amendment ” has the meaning provided in Section 2.3 .
“ Target Date ” has the meaning provided in Section 4.2(a) .
“ Term ” has the meaning provided in Section 3.2 .
“ Termination Payment ” means, as the context requires, the Distribution Company Termination Payment or the Owner Termination Payment.
“ Third Party Claim ” has the meaning provided in Section 20.3 .
“ Third Party Consent ” means any Consent of a Person other than a Governmental Authority.
“ Total Transfer Capability ” means the total transfer capability of the NECEC Transmission Line, as defined in, and established in accordance with, the ISO-NE Tariff and determined by ISO-NE for each hour.
“ TransÉnergie ” has the meaning provided in the recitals to this Agreement.
14
“ TransÉnergie OATT ” means the Hydro-Québec Open Access Transmission Tariff, as amended or accepted by the Régie de l’énergie from time to time.
“ Transfer ” has the meaning provided in Section 22.1(a) .
“ Transmission Operating Agreement ” means an agreement entered into by and between Owner and ISO-NE for transmission operating services over the NECEC Transmission Line under which operating control (as defined in such agreement) of the NECEC Transmission Line is transferred from Owner to ISO-NE.
“ Transmission Operator ” means ISO-NE acting in its capacity pursuant to the Transmission Operating Agreement.
“ Transmission Service Payment ” has the meaning provided in Section 8.1 .
“ Unfavorable FERC Decision ” has the meaning provided in Section 2.2(a) .
“ United States ” or “ U.S. ” means the United States of America.
“ U.S. Border ” means the location on or near the international border between the State of Maine and the Province of Québec where the HVDC Line and the Québec Line interconnect.
Section 1.2 Interpretation . In this Agreement, unless the context otherwise requires, the following rules shall apply to the usage of terms:
Section 1.2.1 Singular; Plural; Gender; Corollary Meaning . The singular shall include the plural and vice versa, and any pronoun shall include the corresponding masculine, feminine and neuter forms. If a term is defined as one part of speech (such as a noun), then it shall have a corresponding meaning when used as another part of speech (such as a verb).
Section 1.2.2 Coordinating Conjunctions . The word “or” shall have the inclusive meaning represented by the phrase “and/or.”
Section 1.2.3 Self-Reference . The words “hereof,” “herein,” “hereto” and “hereunder” and words of similar import when used in this Agreement shall, unless otherwise expressly specified, refer to this Agreement as a whole and not to any particular provision of this Agreement.
Section 1.2.4 Inclusive References . The words “include,” “includes” and “including” when used in this Agreement shall be deemed to be followed by “without limitation” or “but not limited to,” whether or not they are in fact followed by such words or words of like import.
Section 1.2.5 Incorporation by Reference . Any reference in this Agreement to an “Article,” “Section” or other subdivision or to an “Attachment” or other schedule or attachment shall be references to an article, section or other subdivision of, or to a schedule or attachment to, this Agreement, unless otherwise stated, and all such Articles, Sections and Attachments are incorporated into this Agreement by reference (all of which comprise part of one and the same agreement with equal force and effect). In the event of any conflict or other inconsistency between the main body of this Agreement and any attachment or schedule to this Agreement, the provisions of the main body of this Agreement shall prevail.
15
Section 1.2.6 Subsequent Acts . Any references in this Agreement to any statute shall be deemed to refer to such statute, as amended or replaced from time to time, including by succession of comparable successor statute, and all rules and regulations promulgated thereunder. In the event any index or publication referenced in this Agreement ceases to be published or a concept defined by reference to any such index or publication ceases to exist, each such reference shall be deemed to be a reference to a successor or alternate index, publication or concept reasonably agreed to by the Parties. Unless specified otherwise, a reference to a given agreement or instrument, and all schedules and attachments thereto, shall be a reference to that agreement or instrument as modified, amended, supplemented and restated, and as in effect from time to time.
Section 1.2.7 Inclusive of Permitted Successors . Unless otherwise expressly stated, references to any Person also include its permitted successors and assigns.
Section 1.2.8 Time Computation . In this Agreement, in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each means “to but excluding.”
Section 1.2.9 Business Days . Whenever this Agreement refers to a number of days, such number shall refer to calendar days unless Business Days are specified. Whenever any action must be taken under this Agreement on or by a day that is not a Business Day, such action may be validly taken on or by the next day that is a Business Day, and in the case of payments (including refunds of payments), no interest shall accrue on the amount due; provided that such payment is made in full on the next day that is a Business Day.
Section 1.2.10 Governmental Approvals . Except as otherwise expressly provided in this Agreement, any Governmental Approval shall be deemed to be received upon issuance, even if such Governmental Approval is subject to appeal or rehearing.
Section 1.2.11 Currency . All references to prices, values or monetary amounts referred to in this Agreement shall be paid in United States currency, unless expressly provided otherwise.
Article II
REGULATORY FILINGS AND REQUIRED APPROVALS
Section 2.1 MDPU Filing; FERC Filing.
(a) Distribution Company shall file for the Regulatory Approval as soon as practicable following the execution of this Agreement, and in any event shall use commercially reasonable efforts to file within sixty (60) days thereafter.
(b) Owner shall file this Agreement with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing with FERC shall include waiver requests for the Effective Date to occur consistent with Section 3.1 , which Effective Date may be more than one hundred twenty (120) days before the Commercial Operation Date.
16
(c) The Parties shall respond promptly to any requests for additional information made by FERC or the MDPU in connection with such filings.
(d) Upon the filing of this Agreement pursuant to Section 2.1(a) or 2.1(b) , Owner or Distribution Company shall support the approval or acceptance of this Agreement by the MDPU and FERC without modification or condition.
Section 2.2 Modifications to FERC Order .
(a) In the event (i) FERC issues an order accepting or approving this Agreement for filing (the “ FERC Order ”) and (ii) the FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to a Party, in its sole discretion (an “ Unfavorable FERC Decision ”), such Party shall deliver a written notice to the other Party specifying the issues, to the extent it is able, set for hearing or the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following the issuance of the Unfavorable FERC Decision.
(b) In the event of an Unfavorable FERC Decision, the Parties may agree upon amendments to this Agreement (each, a “ FERC Amendment ”) that achieve, as nearly as practicable, the commercial intent of this Agreement as of the Execution Date in a manner consistent with the Unfavorable FERC Decision. Any such amendment shall be subject to applicable regulatory approvals. As soon as practicable after any FERC Amendment(s) have been executed and delivered by the Parties, Owner shall file such FERC Amendment(s) with FERC.
(c) In the event of an Unfavorable FERC Decision, each Party shall retain the right to request a rehearing or reconsideration of the FERC Order regardless of any negotiations that have occurred or are occurring pursuant to clause (b) above; provided, however, that, in the event the Parties execute a FERC Amendment after any one or both of the Parties has filed for rehearing or reconsideration, any such rehearing or reconsideration request shall be withdrawn no later than five (5) Business Days after FERC issues an order accepting or approving the FERC Amendment for filing, if such rehearing or reconsideration request is inconsistent with the terms and conditions of this Agreement, as amended. Unless otherwise agreed in writing by the Parties, a filing by any Party of a request for rehearing or reconsideration of the FERC Order shall not toll or otherwise modify any date or time period set forth in this Agreement, including, for the avoidance of doubt, the date upon which the Construction Phase shall commence.
Section 2.3 Modifications Pursuant to Unfavorable MDPU Order. In the event the Regulatory Approval contains modifications or conditions that are unacceptable to a Party, in the Party’s sole discretion (an “Unfavorable MDPU Order”), such Party shall deliver a written notice to the other Party of such Unfavorable MDPU Order specifying the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following such Unfavorable MDPU Order, and the Parties may agree to amend this Agreement to address such modifications or conditions (any of the foregoing amendments, a “State Amendment”). Any such amendment shall be subject to applicable regulatory approvals, and as soon as practicable after any State Amendment has been executed, Distribution Company or Owner (as applicable) shall file such State Amendment with the MDPU and FERC.
17
(a) In addition to their obligations under Section 2.1 , each Party shall (i) cooperate with each other to prepare, file and effect any applications, notices, petitions, reports or other filings or documentation required under Applicable Law or otherwise necessary, proper or advisable to consummate the transactions contemplated by this Agreement, (ii) provide updates to the other Party on material developments in connection with any such filings or documentation, (iii) provide any non-privileged information reasonably requested by the other Party in connection with any such filings or documentation, and (iv) cooperate with the other Party to use commercially reasonable efforts to obtain all Governmental Approvals and Third Party Consents that are necessary, proper or advisable to consummate the transactions contemplated by this Agreement, including the FERC Authorization (without unacceptable modifications or conditions, except as permitted by this Agreement), the other Owner Approvals, the Municipal Owner Approvals, the Canadian Approvals, and the Regulatory Approval (without unacceptable modifications or conditions, except as permitted by this Agreement). Owner shall provide any support reasonably necessary and requested by the AC Upgrade Owners to obtain the AC Upgrade Approvals.
(b) Each Party shall consult with the other Party with respect to all characterizations of information relating to such other Party or the transactions contemplated by this Agreement that are proposed to appear in any filings or documentation contemplated by Section 2.1 or Section 2.4(a) . Each Party shall promptly provide comments, if any, to the other Party on any such characterizations of information. Each Party shall make a good faith effort to take into account any comments made by the other Party.
Section 2.5 No Inconsistent Action . Except as provided in Section 17.2 and Article XIX, from and after the Execution Date, no Party shall undertake any action before FERC, ISO-NE, the MDPU or any other Governmental Authority that is contrary to the Party’s obligations under this Agreement, including, for the avoidance of doubt, Section 2.1(c) and Section 7.1.4, or support any such contrary action by any Affiliate.
Article III
EFFECTIVE DATE; TERM
Section 3.1 Effective Date . Article I , Article II , this Section 3.1 , Section 3.3.1 , Section 3.3.2 , Article XVII , Article XVIII , Article XIX , Article XXII , and Article XXIII shall become effective and enforceable to the extent permitted by Applicable Law upon the Execution Date. The remaining provisions of this Agreement shall become effective and enforceable to the extent permitted by Applicable Law upon receipt of the Regulatory Approval (the “ Effective Date ” ). Notwithstanding the first sentence of this Section 3.1 , this Agreement will become effective as a FERC rate schedule upon the effective date set forth in the FERC Order. Notwithstanding Section 14.5 and any other provision of this Agreement, Distribution Company shall have no obligation to make any payment under this Agreement prior to receipt of the Regulatory Approval and the FERC Authorizations.
18
Section 3.2 Term . The term of this Agreement shall commence on the Execution Date and shall expire on the twentieth (20 th ) anniversary of the Commercial Operation Date, unless earlier terminated (in whole or in part) or extended in accordance with the terms hereof (the “ Term ” ).
Section 3.3 Termination Rights . This Agreement may be terminated in accordance with the ensuing provisions in this Article III , subject to any required regulatory reviews, approvals or acceptances, as applicable. Neither Party shall oppose any termination of this Agreement made in accordance with this Article III before FERC or any other Governmental Authority; provided, however, that the foregoing shall not prohibit any Party from challenging or otherwise Disputing whether or not any such termination is permitted by this Agreement.
Section 3.3.1 Failure to Obtain Regulatory Approval and FERC Authorizations .
(a) This Agreement may be terminated by any Party in the event (i) it determines that the Regulatory Approval or the FERC Authorizations contain terms and conditions that are, in its sole discretion, unacceptable to such Party, (ii) the Regulatory Approval is denied or is not received by January 25, 2020 (such date, the “ Regulatory Approval Termination Outside Date ”), (iii) the Regulatory Approval of the PPA (as defined in the PPA) is not received within the time frame set forth therein and the PPA is terminated, (iv) the FERC Authorization is denied or is not received by January 25, 2020, or (v) any Additional TSA with an RFP Sponsor is terminated pursuant to Section 3.3.1(a) of that Additional TSA, provided that the termination right under this clause (v) is exercised by a Party within thirty (30) days of the effective date of the termination of such Additional TSA.
(b) Upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.2 Mutual Agreement . This Agreement may be terminated at any time upon written agreement of the Parties.
Section 3.3.3 Failure to Obtain Certain Approvals .
(a) Unless otherwise agreed in writing by the Parties, this Agreement shall terminate immediately without further action of the Parties in the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline, any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline, or any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e) ).
(b) In the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline or if any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e) ), and this Agreement has been terminated pursuant to clause (a) above, Distribution Company may draw against the Credit Support provided by Owner to Distribution Company, including the Owner Security and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) hereof.
19
(c) In the event any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline (as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e)) and this Agreement has been terminated pursuant to clause (a) above, Distribution Company may draw against the Credit Support provided by Owner to Distribution Company, including the Owner Security and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) hereof.
(d) Except as otherwise provided in clause (b) or in clause (c) above, upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.4 Distribution Company Default .
(a) Owner shall have the right to terminate this Agreement in accordance with Section 14.3(a) .
(b) Upon the exercise by Owner of its termination rights pursuant to clause (a) above, Owner shall have the right to recover from Distribution Company, and Distribution Company shall pay to Owner, the Distribution Company Termination Payment in accordance with Section 14.3(c) .
(c) The exercise by Owner of its termination rights pursuant to clause (a) above shall constitute a waiver by Owner of all other remedies or damages that may be available at law or in equity against Distribution Company; provided, however, that Owner shall not waive its right to, and Distribution Company shall remain liable for, the Distribution Company Termination Payment, any unpaid amounts owed by Distribution Company pursuant to Section 8.1 hereof and any amounts owed by Distribution Company to Owner under Section 3.4 , together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover the Distribution Company Termination Payment.
Section 3.3.5 Owner Default .
(a) Distribution Company shall have the right to terminate this Agreement in accordance with Section 14.4(a) .
(b) Upon the exercise by Distribution Company of its termination rights pursuant to clause (a) above, Distribution Company shall have the right to recover from Owner, and Owner shall pay to Distribution Company, the Owner Termination Payment in accordance with Section 14.4(a) .
(c) The exercise by Distribution Company of its termination rights pursuant to clause (a) above shall constitute a waiver by Distribution Company of all other remedies or damages that may be available at law or in equity against Owner; provided, however, that Distribution Company shall not waive any right to, and Owner shall remain liable for, the Owner Termination Payment, any amounts owed by Owner to Distribution Company under Section 3.4 , any accrued but unpaid amounts under Section 4.4.1 or any express modification of Distribution Company’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Distribution Company under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover such damages or such indemnified or other amounts owed to Distribution Company by Owner.
20
Section 3.3.6 Force Majeure . This Agreement may be terminated in accordance with Section 15.1(c) .
Section 3.3.7 Extended Excused Outage . This Agreement may be terminated in accordance with Section 7.2(c) .
Section 3.3.8 Termination of the PPA under Certain Circumstances . Upon termination of the PPA, this Agreement may be terminated by either Party upon written notice to the other Party and without further recourse, except where the PPA is terminated: (i) due to an Event of Default by Distribution Company as defined in the PPA, or (ii) by mutual agreement of the parties to the PPA.
Section 3.4 Termination Payments .
(a) Within sixty (60) days following the termination of this Agreement pursuant to Section 3.3 , Owner shall deliver to Distribution Company an invoice that sets forth Owner’s good faith estimate of the amounts owed to Owner by Distribution Company under Section 3.3 , or Distribution Company shall deliver to Owner an invoice that sets forth Distribution Company’s good faith estimate of the amounts owed to Distribution Company by Owner under Section 3.3 . The recipient of such invoice shall pay the amounts set forth in such invoice within thirty (30) days following its receipt of such invoice. Either Party may deduct and setoff payment of such amounts against any accrued but unpaid payment obligation of the payee to such Party hereunder. Upon the other Party’s request, the invoicing Party shall provide documentation describing the basis for the amounts invoiced in reasonable detail.
(b) The Parties acknowledge and agree that the payment of amounts by the defaulting Party to the non-defaulting Party pursuant to Section 3.3 or this Section 3.4 is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for the termination of this Agreement are difficult or impossible to determine and that the damages calculated under Section 3.3 or this Section 3.4 (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to the non-defaulting Party as a result thereof.
Section 3.5 Effect of Termination . Except as provided in Section 3.3 and in Section 23.13 for the survival of provisions, upon expiration or other termination of this Agreement pursuant to its terms, each of the Parties shall be released from all of its obligations under this Agreement, other than any accrued but unpaid payment obligation. Notwithstanding the foregoing sentence, upon such expiration or termination of this Agreement, either Party shall have the right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by such Party to recover any amounts owed to such Party by the other Party hereunder or to secure the release of any security or performance assurance provided by or on behalf of such Party after the later to occur of the end of the Term or the date on which any accrued but unpaid payment obligation of such Party to the other Party hereunder shall have been fully, finally and indefeasibly satisfied.
21
COMMERCIAL OPERATION
Section 4.1 Critical Milestones .
(a) Subject to Sections 4.1(c) , 4.1(d) and 4.1(e) , commencing on the Effective Date, Owner shall develop the NECEC Transmission Line in order to achieve the milestones set forth in clauses (i), (iii)-(v), and (vii) below, and use commercially reasonable efforts to cause HQUS to develop the Québec Line in order to achieve the milestones set forth in clauses (ii) and (vi) below (each clause, a “ Critical Milestone ”) on or before the dates set forth in this Section 4.1(a) :
(i) Receipt of all Owner Approvals (other than the Municipal Owner Approvals) and AC Upgrade Approvals in final form by the Approval Deadline;
(ii) Receipt of all Canadian Approvals in final form by the Canadian Approval Deadline;
(iii) Receipt of the Municipal Owner Approvals in final form by the Municipal Owner Approval Deadline;
(iv) Closing of any financing required for the construction and operation of the NECEC Transmission Line or other demonstration to Distribution Company’s reasonable satisfaction of the financial capability of Owner to construct the NECEC Transmission Line, including, as applicable, Owner’s financial obligations with respect to interconnection of the NECEC Transmission Line and construction of the AC Upgrades and the CCIS Capacity Upgrades, by the Financing Deadline; and
(v) Execution by Owner and a contractor of an agreement for the engineering, procurement, and construction of the converter station at the southern end of the HVDC Line and payment by Owner to the contractor of an initial payment of at least 5% of the total price of the agreement, both by the Converter Station Contract Deadline;
(vi) Execution by Hydro-Québec Equipment, a division of Hydro-Québec, of a contract that provides for the engineering, procurement, or construction of the converter station associated with the Québec Line by the Québec Converter Station Contract Deadline;
(vii) Achievement of the Commercial Operation Date by the Target Date.
(b) Except for the achievement of the Commercial Operation Date, which shall be governed by the provisions of Section 4.2 , Owner shall provide Distribution Company (or, in the case of clause (ii), use commercially reasonable efforts to cause HQUS to provide Distribution Company) with written notice of the achievement of each Critical Milestone as set forth in Attachment B within seven (7) days after that achievement, which notice shall include information demonstrating with reasonable specificity that such Critical Milestone has been achieved. Owner acknowledges that Distribution Company will receive such notice solely to monitor progress toward the Commercial Operation Date, and Distribution Company shall not have any responsibility or liability for the development, construction, operation and maintenance of the NECEC Transmission Line or the Québec Line.
22
(c) Subject to Sections 4.1(e) and 4.2 , Owner may extend all of the dates for the Critical Milestones not yet achieved under this Agreement by up to four (4) six-month periods for a maximum combined period of two (2) years from the dates originally established in Section 4.1(a) . Owner shall post Credit Support (in addition to the Owner Security and the Twenty -One Million, Eight Hundred Thousand Dollars ($21, 8 00,000) of security delivered to Distribution Company and the other RFP Sponsors by HQUS pursuant to the PPA and the Additional PPAs) in an amount equal to $5,000 per MW of the PPA Contract Maximum Amount for each such six-month period, with a pro-rata adjustment of the amount of any such additional Credit Support for any partial reduction of the applicable six-month period pursuant to Section 4.1(e) . Any such election shall be made in a written notice to Distribution Company on or prior to the first date for a Critical Milestone that has not yet been achieved (as such date may have previously been extended). Such notice shall include a detailed explanation of the reasons for the delay, why the delay could not be avoided and the impact on Owner’s Construction Schedule and the expected Commercial Operation Date. Distribution Company shall have the right to request and receive information from Owner regarding such explanation. Such additional Credit Support shall be provided by Owner if there is an Owner Delay or an HQUS Delay and Owner wishes (or is required under the HQUS TSA) to extend any Critical Milestone date. Any additional Credit Support provided under this Section 4.1(c) shall be returned to Owner upon the Commercial Operation Date; provided that, in the event the Commercial Operation Date is not achieved by the Target Date, Distribution Company shall have the rights and remedies set forth in Article XIV , which, for the avoidance of doubt, shall include recourse against any Credit Support posted by Owner.
(d) To the extent a Force Majeure event pursuant to Section 15.1 has occurred that prevents Owner from achieving the Critical Milestone dates for execution of the contract for the purchase by Owner of the Converter Station ( Section 4.1(a)(v) ) or the Commercial Operation Date ( Section 4.1(a)(vii) ), or prevents the achievement of the Québec Converter Station milestone ( Section 4.1(a)(vi) ), by the applicable Critical Milestone date, the Critical Milestone date(s) impacted by such Force Majeure event shall be extended for the duration of the Force Majeure event, but under no circumstances shall extensions of those Critical Milestone dates exceed twelve (12) months beyond the applicable Critical Milestone date; provided that Owner shall not have the right to declare a Force Majeure event related to the Critical Milestone for Owner Approvals ( Section 4.1(a)(i) ), Canadian Approvals ( Section 4.1(a)(ii) ), Municipal Owner Approvals ( Section 4.1(a)(iii) ), or the financing Critical Milestone ( Section 4.1(a)(iv) ).
(e) In the event of a Regulatory Approval Delay, the date for each Critical Milestone not yet achieved shall be extended for the duration of the delay. The number of days of extension pursuant to the six-month extensions available under Section 4.1(c) shall be reduced by one day for each day of Regulatory Approval Delay pursuant to this subsection (e) up to a maximum reduction of 365 days. For purposes of illustration, Regulatory Approval Delay of two hundred ten (210) days would allow Owner two six-month extensions and one extension of five months .
23
Section 4.2 Commercial Operation Date .
(a) The “ Target Date ” for Commercial Operation is December 13, 2022 (as the same may be extended in accordance with Sections 4.1(c) , 4.1(d) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing. Absent written agreement by the Parties, the Target Date may not be extended beyond December 13, 2024 unless such extension is due to Regulatory Approval Delay or an event of Force Majeure as set forth in Sections 4.1(d) and 4.1(e) . The provisions of Sections 4.1(c) , 4.1(d) , and 4.1(e) and all other provisions of this Agreement are subordinate to this Section 4.2 (a) and the aforesaid Section 4.1 provisions and such other provisions shall be construed in a manner that is consistent with this Section 4.2(a) . Owner shall provide a written non-binding notice to Distribution Company no later than sixty (60) days before the date Owner reasonably expects the Commercial Operation Date to occur.
(b) At the request of Owner made in writing, Distribution Company shall cooperate with Owner, TransÉnergie and ISO-NE to support the Commissioning of the HVDC Transmission Project.
(c) As soon as practicable after Owner is of the opinion that the conditions to Commercial Operation, as set forth in Section 4.3 , have been satisfied, or such conditions have been waived in writing by the Parties (except in the case of Section 4.3(b) , Section 4.3(e) , Section 4.3(g) and Section 4.3(h) , which conditions may be waived in writing by Distribution Company, in its sole discretion), Owner shall deliver a written notice to Distribution Company specifying the date upon which Commercial Operation shall commence (the “ COD Notice ”), which commencement date shall occur no earlier than ten (10) Business Days after the receipt by Distribution Company of the COD Notice or on such other date as agreed upon by the Parties in writing (such date, the “ Commercial Operation Date ”).
(d) Within five (5) Business Days after the receipt by Distribution Company of the COD Notice, Distribution Company shall deliver a certificate to Owner either (i) confirming that the conditions set forth in Section 4.3 have been satisfied or duly waived and that Commercial Operation may commence on the Commercial Operation Date or (ii) objecting with reasonable detail to the COD Notice. Distribution Company’s failure to respond in writing to a COD Notice within such five (5) Business Day period shall be deemed to be a confirmation that the conditions set forth in Section 4.3 have been satisfied or duly waived. Any Dispute over whether or not the conditions set forth in Section 4.3 have been satisfied or duly waived shall be resolved in accordance with Article XVII .
Section 4.3 Conditions Precedent to Commercial Operation . The items set forth in clauses (a) through (i) below shall be conditions precedent to the Commercial Operation of the NECEC Transmission Line:
(a) Completion of the Commissioning of the HVDC Transmission Project by Owner (in coordination with ISO-NE) and TransÉnergie;
(b) The NECEC Transmission Line has been constructed in accordance with Attachment A and Good Utility Practice, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(b) ;
24
(c) Completion of the AC Upgrades and the CCIS Capacity Upgrades;
(d) The Interconnection Agreements shall be in full force and effect;
(e) The Transmission Operating Agreement shall be in full force and effect and ISO-NE shall have informed Owner that ISO-NE (i) is prepared to assume operational control over the NECEC Transmission Line, as defined in, and in accordance with, the Transmission Operating Agreement and (ii) will assume such operational control as of the Commercial Operation Date;
(f) The Québec Line has been constructed in accordance with Attachment A, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(b) ;
(g) Receipt by Distribution Company of copies of certificates evidencing all outstanding insurance required or otherwise obtained under Section 5.3 ; and
(h) Receipt by Distribution Company of an opinion of legal counsel, reasonably satisfactory to Distribution Company, that all Governmental Approvals and Third Party Consents required to own and operate the NECEC Transmission Line have been obtained.
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation .
Section 4.4.1 Owner Delay . If, other than solely as a result of an HQUS Delay, Force Majeure, or Concurrent Delay, any conditions set forth in Section 4.3 shall not have been satisfied or duly waived by the Target Date (such delay, an “ Owner Delay ”):
(a) Distribution Company shall have the right to recover from Owner, and Owner shall pay or reimburse to Distribution Company, for each day (or part thereof) following the Target Date during which the Owner Delay is continuing, an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Distribution Company terminates this Agreement under Section 14.4 hereof, and (z) the date that is twelve (12) months after the Target Date.
(b) Design Capacity Shortfall .
(i) As of the Commercial Operation Date . In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line or the Québec Line is only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line and the Quebec Line are capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service hereunder, or (B) the NECEC Transmission Line and the Quebec Line are capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service hereunder (such consent not to be unreasonably withheld, conditioned, or delayed), then Owner shall have twenty-four (24) months from the Commercial Operation Date to attempt to increase such operating capacity to 1,090 MW (the “ Remediation Period ”), and Owner shall pay to Distribution Company, for each day (or part thereof) following the Commercial Operation Date and until the end of
25
the Remediation Period, or such earlier date designated by Owner in writing to Distribution Company (the “ Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and such operating capacity as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Distribution Company to Owner. Distribution Company’s payments shall be based on the actual operating capacity of the NECEC Transmission Line, as is stated in Section 8.1 .
(ii) Following Remediation . If, on the earlier of Remediation Date or the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW, then this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line, the Contract Capacity shall be deemed modified accordingly, and the rate used to calculate the Transmission Service Payment will be reduced pro rata to reflect the capacity shortfall below 1,090 MW. For illustrative purposes, if following the earlier of the Remediation Date or the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line is 1,080 MW, which will be the Contract Capacity from then onwards, the Transmission Service Payment rate for the remainder of the Term shall be reduced to the Transmission Service Payment rate then in effect multiplied by 1,080/1,090, and that rate shall be multiplied by the Contract Capacity of 1,080 MW to determine the Transmission Service Payment.
(iii) An Owner Default shall be deemed to have occurred pursuant to Section 14.2(c) if (A) as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are not both capable of operating at or above 1,040 MW, and Distribution Company has not agreed in writing to begin transmission service hereunder notwithstanding such operating capability, or (B) as of the earlier of the Remediation Date or the end of the Remediation Period, the NECEC Transmission Line and the Québec Line are not both capable of operating at or above 1,075 MW.
(c) Without any limitation of Section 4.4.2 , the Parties acknowledge and agree that the payment of amounts by Owner to Distribution Company under clauses (a) and (b) above, respectively, are an appropriate remedy and that any such modification or payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for an Owner Delay or a reduction in operating capacity, as described in clause (b), are difficult or impossible to determine and that the damages calculated hereunder (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
(d) Without any limitation of Section 4.4.2 , the rights provided in Section 3.3.5 and this Section 4.4.1 shall collectively be the sole and exclusive remedies of Distribution Company with respect to an Owner Delay or a reduction in operating capacity, as described in clause (b). The foregoing sentence shall not be construed in any way to limit (i) Distribution Company’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, or (ii) Distribution Company’s rights to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1 .
26
Section 4.4.2 Concurrent Delays .
(a) In the event of a concurrent HQUS Delay and Owner Delay (a “ Concurrent Delay ”), for each day (or part thereof) during which a Concurrent Delay is continuing, Owner will pay to Distribution Company an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (w) the date on which either the Québec Line or the NECEC Transmission Line is capable of commercial operation but for the other Party’s delay, (x) the Commercial Operation Date, (y) the date on which Distribution Company terminates this Agreement under Section 14.4 hereof, and (z) twelve (12) months after the Target Date.
(b) The Parties acknowledge and agree that the payment of amounts by Owner to Distribution Company under clause (a) above is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Concurrent Delay are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
(c) The rights provided in Section 3.3.3 and this Section 4.4.2 shall collectively be the sole and exclusive remedies of Distribution Company with respect to a Concurrent Delay. The foregoing sentence shall not be construed in any way to limit (i) Distribution Company’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, or (ii) Distribution Company’s rights to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1 .
Article V
GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES
Section 5.1 Responsibilities of the Parties .
Section 5.1.1 Construction Phase .
(a) During the Construction Phase, Owner shall (i) exercise Good Utility Practice to complete, or cause the completion of, all tasks required to construct the NECEC Transmission Line, interconnect at least 1,090 MW of capacity with ISO-NE in compliance with the Capacity Capability Interconnection Standard, and achieve Commercial Operation by the Target Date, in each case, in accordance with the Design Capability and in a manner consistent with Attachment A and (ii) use commercially reasonable efforts to obtain all of the Construction Authorizations (other than the Municipal Owner Approvals) by the Approval Deadline, (B) to obtain, in consultation with Distribution Company, the ISO-NE Approval by the Approval Deadline and (C) to cause Owner’s Affiliates that are AC Upgrade Owners to obtain any AC Upgrade Approvals for which such Affiliates are responsible by the Approval Deadline and to assist other AC Upgrade Owners in obtaining their respective AC Upgrade Approvals by the Approval Deadline.
27
(b) Owner will use commercially reasonable efforts to enter into, within a commercially reasonable timeframe, one or more Construction Contracts. Owner will make a copy of any such contract available to Distribution Company subject to such redactions as Owner or the contracting party deem necessary to protect confidential information.
Section 5.2 Schedules and Reports .
Section 5.2.1 Owner’s Preliminary Schedule . Attached hereto as Attachment E is Owner’s Project Schedule (the “ Owner’s Preliminary Schedule ”). At the request of Distribution Company, Owner shall make the personnel responsible for preparing the Owner’s Preliminary Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Preliminary Schedule with Distribution Company.
Section 5.2.2 Owner’s Construction Schedule . Within ten (10) days after the end of each calendar quarter and sooner if a material change occurs, commencing at least ninety (90) days prior to the commencement of construction, Owner shall prepare and submit to Distribution Company for review an update of the Owner’s Preliminary Schedule (such updated schedule as established herein, the “ Owner’s Construction Schedule ”). At the request of Distribution Company, Owner shall make the personnel responsible for preparing the Owner’s Construction Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Construction Schedule with Distribution Company.
Section 5.2.3 Owner’s Progress Reports .
(a) Promptly following the Execution Date, Owner shall deliver to Distribution Company copies of all applications that have been submitted by Owner with respect to any Owner Approvals, as well as all material correspondence and submittals relating to such Owner Approvals. Within ten (10) days after the end of each calendar quarter, commencing at receipt of the Regulatory Approval, Owner shall prepare and submit to Distribution Company for review a progress report for informational purposes that sets forth in reasonable detail the current status of the milestones set forth in the Owner’s Construction Schedule, including any changes in the expected timelines and the status of all Owner Approvals and including copies of any Owner Approval applications, material correspondence and submittals relating to Owner Approvals, and any issued Owner Approvals (the “ Owner’s Construction Progress Report ”). Without limitation of the foregoing, Owner shall include in such reports relevant information relating to: (i) Owner’s efforts to mitigate the impacts of the NECEC Transmission Line on natural resources, environmentally sensitive areas, habitats, and wildlife species, and cultural and historic resources; (ii) Owner’s efforts to comply with applicable noise ordinances; (iii) and Owner’s communication and community outreach efforts and plans with respect to the construction of the NECEC Transmission Line, including with stakeholders in Massachusetts. At the request of Distribution Company, Owner shall, or shall cause each contractor to, provide Distribution Company with access to, and copies of, all reasonably requested documentation concerning such Owner’s Construction Progress Report.
(b) Owner shall, or shall cause the principal contractor to, notify Distribution Company promptly, but in no event later than ten (10) days, after Owner, or such contractor, becomes aware that the Commercial Operation of the NECEC Transmission Line is not reasonably likely to occur by the Target Date.
28
Section 5.3 Insurance and Events of Loss . Owner shall obtain and maintain with reputable insurers authorized to operate in the scope of the Agreement insurance of the type set forth in Attachment F. Owner shall provide Distribution Company with copies of certificates of all outstanding insurance obtained hereunder promptly after the receipt thereof by Owner. Owner shall notify Distribution Company as soon as reasonably possible if and whenever an event of loss occurs. Without limitation of any obligations Owner may have under Section 15.1 hereof, in the event of damage to or loss of all or part of the NECEC Transmission Line, Owner shall exercise prompt, diligent commercially reasonable efforts to effectuate, in accordance with Good Utility Practice, such repairs and replacements as are necessary or desirable to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss, including, for the avoidance of doubt, the application to such repairs or replacements of any potential or actual proceeds realized in connection with such damage or loss under any available or applicable insurance policies (subject to insurance contract/policy terms and conditions of coverage) maintained pursuant to this Section 5.3 . Subject to Owner’s compliance, in all material respects, with this Section 5.3 , Section 6.3 and all other material terms and conditions with respect to the operation and maintenance of the NECEC Transmission Line, in the event that the costs to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss exceed the available insurance proceeds by more than the greater of (a) an amount equal to three percent (3%) of the Net Book Value of the NECEC Transmission Line and (b) Thirty Million Dollars ($30,000,000), the Parties will negotiate in good faith an appropriate allocation of financial responsibility for such excess costs. In the event that the Parties do not agree on the allocation of financial responsibility, Distribution Company shall be entitled to terminate this Agreement, upon thirty (30) days’ written notice to Owner, without liability to Owner; provided that, if within the thirty (30) day period following receipt of such notice, Owner agrees to assume that portion of the allocation of financial responsibility to which Distribution Company objected, then the termination notice shall be deemed revoked and this Agreement shall not be terminated.
Section 5.4 Compliance with Laws . At all times during the Term, the Parties shall comply with all Applicable Laws (including ISO-NE Rules to the extent applicable) and relevant Governmental Approvals and Third Party Consents.
Section 5.5 Third Party Contracts .
Section 5.5.1 At all times during the Term, Owner shall, in a commercially reasonable manner, (a) satisfy its obligations under all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades, and (b) administer all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades.
Section 5.5.2 Unless it obtains the prior written consent of Distribution Company (such consent not to be unreasonably withheld, conditioned or delayed) , Owner shall not: (i) agree to any amendment to Sections 3.3.5 , 14.3 , 14.6 , 14.7 , 14.8 , and 14.10 of the HQUS TSA, or (ii) agree to an amendment and restatement, replacement, supplement, or other modification or amendment of the HQUS TSA that adversely and materially affects Distribution Company’s rights under this Agreement or the PPA. Owner shall provide to Distribution Company a copy of any proposed amendment to the HQUS TSA not fewer than ten (10) Business Days prior to the execution thereof.
Section 5.6 Continuity of Rights and Responsibilities . Unless otherwise agreed in writing by the Parties or prohibited by Applicable Law, the Parties shall continue to provide service and honor commitments under this Agreement and continue to make payments in accordance with this Agreement pending resolution of any bona fide Dispute hereunder or relating hereto.
29
PROCEDURES FOR OPERATION AND MAINTENANCE
OF THE NECEC TRANSMISSION LINE
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control .
(a) Prior to entering into the Transmission Operating Agreement, Owner shall consult Distribution Company with respect to the proposed terms and conditions thereof and Owner shall make a good faith effort to take into account any comments made by Distribution Company. Distribution Company shall promptly provide comments, if any, to Owner on such terms and conditions.
(b) As of the Commercial Operation Date, Owner shall transfer operational control over the NECEC Transmission Line, as defined in the Transmission Operating Agreement, to Transmission Operator in accordance with the Transmission Operating Agreement. Owner shall provide, and shall direct its Affiliates to provide, such information as Transmission Operator may require to discharge its obligations under the Transmission Operating Agreement, and Owner shall comply with the instructions of Transmission Operator to the extent provided in the Transmission Operating Agreement and the ISO-NE Tariff. The Parties acknowledge and agree that Owner shall not be in breach of, or be liable to Distribution Company under, this Agreement, and no Owner Default shall occur, as a consequence of Owner’s compliance with such instructions of Transmission Operator; provided that Owner did not initiate or support instructions that would otherwise breach Owner’s obligations under this Agreement.
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements . From and after the Commercial Operation Date, Owner shall (a) provide Firm Transmission Service, (b) operate and maintain the NECEC Transmission Line in accordance with Good Utility Practice and in compliance with all applicable regulatory requirements, including applicable NERC and Northeast Power Coordinating Council reliability standards, and (c) comply with all applicable operating instructions of ISO-NE and manufacturers’ warranties.
Section 6.3 Scheduled Maintenance . With respect to each calendar year (or portion thereof) following the Construction Phase, Owner will prepare and deliver to Distribution Company a Maintenance Plan not later than the Commercial Operation Date and two (2) months prior to the end of each calendar year thereafter during the Operation Phase, and shall be available for consultation with Distribution Company with respect thereto (including for coordination of maintenance schedules). Consistent with Good Utility Practice, Owner shall use commercially reasonable efforts to coordinate with TransÉnergie with respect to scheduled maintenance so as to minimize outages, including by meeting annually (or as otherwise necessary in order to comply with any applicable ISO-NE or Canadian regulatory or system operator requirements) to develop a Maintenance Plan. Throughout the Operation Phase, Owner shall coordinate all planned maintenance with ISO-NE, consistent with ISO-NE Rules, and shall promptly provide applicable information concerning scheduled outages, as determined by ISO-NE, to Distribution Company. To maximize value, to the extent possible and consistent with ISO-NE Rules, Owner shall not schedule maintenance of the NECEC Transmission Line during the months of December, January and February or June through September and shall operate the NECEC Transmission Line so as to maximize energy production during the hours of anticipated peak load and energy prices in New England; provided, however, that planned maintenance may be scheduled during such period to the
30
extent the failure to perform such planned maintenance is contrary to operation of the NECEC Transmission Line in accordance with Good Utility Practice. Owner may modify a Maintenance Plan in accordance with Good Utility Practice; provided, however, that (a) a Maintenance Plan may not be modified for the purpose of reducing the magnitude or duration of a Non-Excused Outage, (b) any modification shall, to the extent commercially reasonable, maximize value in the manner described in this Section 6.3 , and (c) Owner shall provide Distribution Company with reasonable notice of any change in a Maintenance Plan. Any maintenance that is not included in the Maintenance Plan for a year and is not otherwise excused under Section 7.2 shall be a Non-Excused Outage.
Article VII
DISTRIBUTION
COMPANY’S TRANSMISSION RIGHTS OVER THE
NECEC TRANSMISSION LINE
Section 7.1 Transmission Service .
Section 7.1.1 Firm Transmission Service . Owner shall make available to Distribution Company, from and after the Commercial Operation Date through the end of the Term, transmission capacity on the NECEC Transmission Line in order to deliver electrical energy, as scheduled by Distribution Company or its designee or assignee under the resale provisions of Article X , in such scheduled amount up to the Contract Capacity, measured at the Delivery Point (“ Firm Transmission Service ”). Firm Transmission Service shall be made available over the NECEC Transmission Line at any time from and after the Commercial Operation Date, in a north-to-south direction, and to the extent available in a south-to-north direction, between the U.S. Border and the Delivery Point. Firm Transmission Service shall be subject to curtailment or interruption only as a result of an Excused Outage or as provided in Section 14.3(b) . Without limiting Owner’s obligations under this Section 7.1.1 , the quantity of Firm Transmission Service that Owner will provide in any hour shall not exceed the Proportionate Share of the Available Transfer Capability for such hour.
Section 7.1.2 Limitation on Transmission Service . Owner shall have no obligation to provide transmission service under this Agreement other than Firm Transmission Service. Distribution Company shall have no right to redirect service to alternate points of delivery or receipt on any portion of the transmission system operated by ISO-NE other than the NECEC Transmission Line.
Section 7.1.3 Scheduling . All Firm Transmission Service shall be scheduled in accordance with the rules relating to the scheduling of electrical energy or capacity transactions over the NECEC Transmission Line, as established under the Transmission Operating Agreement (the “ Scheduling Rules ”).
Section 7.1.4 Owner’s Cooperation . Owner shall provide Distribution Company with notice of any FERC or NERC regulatory proceedings relating to the NECEC Transmission Line or this Agreement to which Owner is a party promptly after Owner becomes aware of any such proceedings. Each Party will act in good faith regarding any such proceedings. Neither Party shall take any position in such proceeding that is contrary to such Party’s obligations under this Agreement.
31
Section 7.2 Excused Outages or Reductions .
(a) Notwithstanding anything herein to the contrary, Owner shall not be in breach of, or be liable to Distribution Company for any losses or damages under, this Agreement, and no Owner Default shall occur, as a consequence of an Excused Outage. “ Excused Outages ” means any outages of the NECEC Transmission Line, or reductions in the Total Transfer Capability below the NECEC Transmission Line Capacity, whether as a result of a physical condition, legal impediment or otherwise, if and to the extent such outage or reduction is due to:
(i) Events of Force Majeure;
(ii) Scheduled maintenance in accordance with the applicable Maintenance Plan;
(iii) Outages or reductions in the availability of the Québec Line for any reason; or
(iv) Decisions of ISO-NE or any other independent system operator to reduce or suspend scheduling rights over the NECEC Transmission Line or the Quebec Line, including as a result of any grid reliability issue, emergency condition as defined in any Interconnection Agreement or the ISO-NE Tariff, or to preserve facilities and equipment from physical damage and including any such decisions that arise from outages or reductions in the use or availability of transmission lines other than the NECEC Transmission Line or the Québec Line, which outage or reduction arises from or is attributable to Force Majeure or scheduled maintenance.
(b) Notwithstanding anything in Section 7.3.1 to the contrary, Distribution Company shall remain obligated, during and to the extent of any Excused Outage to pay the Transmission Service Payment without downward adjustment to reflect any such outage, reduction, or delay. Owner shall seek to avoid, mitigate and remedy any Excused Outage consistent with Good Utility Practice.
(c) Notwithstanding anything herein to the contrary and without regard to whether an Excused Outage is due to Force Majeure, if an Excused Outage prevents Owner’s full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, Distribution Company shall have the right, as provided in Section 15.1(c) herein, to terminate this Agreement upon written notice to Owner and without further recourse.
Section 7.3 Non-Excused Outages or Reductions.
Section 7.3.1 Reduction in Transmission Service Payments . In the event the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 , the Transmission Service Payment for such period shall be reduced in accordance with Section 8.1 . Any Dispute over whether or not or to what extent a Non-Excused Outage has occurred shall be resolved in accordance with Article XVII . Owner shall seek to avoid, mitigate and remedy any Non-Excused Outage consistent with Good Utility Practice.
32
Section 7.3.2 Liquidated Damages . The Parties acknowledge and agree that the modification of Distribution Company’s payment obligations pursuant to Section 8.1 is an appropriate remedy and that any such modification does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Non-Excused Outage are difficult or impossible to determine and that the damages calculated hereunder (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
Section 7.3.3 Sole and Exclusive Remedy . The rights provided in Section 3.3.5 , this Section 7.3 , and Section 14.4 shall collectively be the sole and exclusive remedies of Distribution Company with respect to a Non-Excused Outage, subject to (a) Distribution Company’s right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, (b) Distribution Company’s right to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1, or (c) Distribution Company’s rights on an Owner Event of Default as described in Section 14.2 .
Section 7.4 Allocation of Outages . The Parties expressly intend and agree that any outages or reductions in Total Transfer Capability shall be borne first by HQUS and by all transmission rights holders served by the NECEC Transmission Line (including Owner, if applicable) other than Distribution Company and the other RFP Sponsors, and that any remaining reduction shall be allocated among Distribution Company and the other RFP Sponsors in accordance with their respective Proportionate Shares. Owner acknowledges and agrees that it will not reduce the Firm Transmission Service available to Distribution Company except in accordance with the foregoing priority and will not reduce the Firm Transmission Service available to Distribution Company in an unduly discriminatory manner as compared with any other transmission rights holder served by the NECEC Transmission Line (including Owner, if applicable). For purposes of clarity, HQUS’s transmission service under the Additional HQUS TSA shall be reduced before any reductions are applied to Distribution Company’s transmission service under this Agreement.
Section 7.5 Metering . Metering and telemetering requirements for the NECEC Transmission Line shall be established by Owner in accordance with Good Utility Practice and as necessary to (a) accomplish the purposes of, and to implement and administer, this Agreement and (b) satisfy the requirements of, and to implement and administer, the PPA, the Interconnection Agreement and the Transmission Operating Agreement.
Section 7.6 Line Availability Information and Reporting . Owner shall make available to Distribution Company on a real time basis information relating to the operation and availability of the NECEC Transmission Line and shall provide such additional information as Distribution Company shall reasonably request.
33
PAYMENTS FOR TRANSMISSION SERVICE OVER THE
NECEC TRANSMISSION LINE
Section 8.1 Transmission Service Payments . During the Operating Phase, except to the extent such payment is excused or reduced pursuant to the terms of this Agreement, Distribution Company shall pay to Owner a transmission service payment (the “ Transmission Service Payment ” ) on a monthly basis in an amount calculated as set forth in Attachment J pursuant to invoices delivered by Owner to Distribution Company; provided, however, that, in the event Regulatory Approval does not occur by January 25, 2019, the Transmission Service Payment shall increase 0.18333% per month for each full month following January 25, 2019 until such Regulatory Approval is received. The Transmission Service Payments shall be reduced in accordance with the formula set forth in Attachment G in the event and to the extent that the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non - Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 , and the rate ($/MW) shall be adjusted in accordance with Section 4.4.1(b)(ii) . Pursuant to Section 13.2 , to the extent there is a Dispute over whether or not or to what extent a Non-Excused Outage has occurred, the reduction in the Transmission Service Payments shall be implemented upon the resolution of that Dispute and such reduction will be effective as of the date when such Dispute arose . Such adjustments shall be made on a monthly basis pursuant to invoices delivered by Owner to Distribution Company.
Section 8.2 Elective Upgrade Status; No Regional Rates . It is the intent of the Parties that the NECEC Transmission Line has Elective Transmission Upgrade status during the Term and that the AC Upgrades and the CCIS Capacity Upgrades constitute Network Upgrades under the ISO-NE Tariff required to accommodate the interconnection of the NECEC Transmission Line. It is the further intent of the Parties that Owner’s recovery of the investment in and return on the NECEC Facilities and the Distribution Company’s obligation to pay for the NECEC Facilities shall be solely governed by this Agreement. The Parties each shall refrain from taking steps to include all or part of the NECEC Facilities in ISO-NE regional transmission rates during the Term and for a period of twenty (20) years thereafter. Notwithstanding the foregoing, if during the Term all or part of the NECEC Facilities are included in ISO-NE regional rates paid by the Distribution Company, the payment required by Section 8.1 shall be reduced by the Proportionate Share of the revenues received by Owner from such ISO-NE rates with respect to the NECEC Facilities. “ NECEC Facilities ” means the NECEC Transmission Line, the AC Upgrades, and the CCIS Capacity Upgrades.
Article IX
RIGHTS UPON EXPIRATION OF TERM
Section 9.1 Rollover and Other Rights . Distribution Company hereby irrevocably waives any rollover rights it may have at the end of the Term in accordance with Order No. 890 et seq. and the FERC pro forma open access transmission service tariff, as such rights are defined as of the Effective Date.
34
TRANSFER AND RESALE OF TRANSMISSION RIGHTS
Section 10.1 Transfer of Transmission Rights . Owner conveys to Distribution Company all rights to and title and interest in the use of the Distribution Company’s Proportionate Share of NECEC Transmission Line Capacity and Distribution Company has entered into the PPA, pursuant to which Distribution Company transfers, assigns and conveys to HQUS during the Term all of Distribution Company’s rights, title and interest in and to the Firm Transmission Service, Other Transmission Rights, and Market Products in respect of HQUS’s delivery obligations under the PPA .
Section 10.2 Resale Rights . In the PPA, HQUS has acknowledged that if and to the extent HQUS determines from time to time, and in its sole discretion, that the transmission capacity available to HQUS relevant to the receipt of Firm Transmission Service over the NECEC Transmission Line pursuant to this Agreement exceeds HQUS’s needs, HQUS will then offer to resell such unused capacity to third parties in accordance with Applicable Law as may then be in effect (including the terms and conditions of FERC Order No. 890 et seq., if applicable).
Section 10.3 Capacity Releases for Daily and Hourly Use . From and after the Commercial Operation Date, if and to the extent the Proportionate Share of the Available Transfer Capability exceeds the amount of electrical energy that is scheduled by Distribution Company (or its assignee) for delivery over the NECEC Transmission Line using Firm Transmission Service by the applicable scheduling deadline (as in effect at such time) established pursuant to the Scheduling Rules, then the transmission capacity that is available for resale to third parties for the following day, and the price at which any such resales are offered, shall be posted on the OASIS site established pursuant to Section 10.4 .
(a) Owner or an Affiliate of Owner (in such capacity, the “ OASIS Administrator ”) shall establish an OASIS site for the NECEC Transmission Line and administer such site in accordance with applicable FERC requirements for the establishment and administration of OASIS sites. None of Owner, the OASIS Administrator or Distribution Company (or its assignee) shall be liable to each other or any third party for any decisions the OASIS Administrator makes regarding the appropriate price for resales of unused transmission capacity or the level of any such resales the OASIS Administrator is able to make. The Parties agree that there shall be no damages as between each other or third parties for actions by the OASIS Administrator with respect to resales of unused transmission capacity.
(b) To the extent resales are made available by Distribution Company (or its assignee) pursuant to Section 10.2 , the OASIS Administrator shall post on the OASIS site information regarding such resales, (i) in accordance with written instructions provided by Distribution Company (or its assignee) from time to time and (ii) at a price established by Distribution Company (or its assignee) from time to time, and in its sole discretion, as permitted under Applicable Law.
Section 10.5 Proceeds from Capacity Releases and Transmission Resales . Except as otherwise provided in Section 14.3(b) , Distribution Company’s Proportionate Share of the proceeds received by Owner of any capacity releases and transmission resales of transmission capacity assigned to HQUS under Section 20 of the PPA and the Additional PPAs that are made during the Operation Phase shall be credited, net of reasonable fees (including attorneys’ fees) and
35
other expenses incurred in connection with performance of the functions described in Section 10.3 and Section 10.4 , against any Transmission Service Payment or other amounts owed to Owner by Distribution Company for the calendar month subsequent to the calendar month in which such proceeds were received.
Section 10.6 Owner’s Rights and Obligations . Except as expressly provided in the Proposal Agreements, Owner shall have no right or obligation to offer any transmission service over the NECEC Transmission Line for sale or resale to any Person other than Distribution Company, as provided herein.
Article XI
REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS
Section 11.1 Real Power Losses . Distribution Company shall not be responsible for any Real Power Losses associated with Firm Transmission Service. Owner and HQUS shall be responsible for the delivery of the scheduled amounts of energy associated up to the Contract Capacity to the Delivery Point without reduction for Real Power Losses.
(a) Distribution Company shall be entitled during the Term to its Proportionate Share of the following, without duplication and without additional cost to Distribution Company or compensation to Owner: (i) all Other Transmission Rights associated with the NECEC Transmission Line or the AC Upgrades, in each case, that are issued in accordance with the ISO-NE Tariff or otherwise granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, and (ii) all other Market Products that are issued in accordance with the ISO-NE Tariff or granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, that derive from the acquisition of transmission service over the NECEC Transmission Line. For purposes of this clause (a), the denominator of the “Proportionate Share” shall be the Physical Transmission Line Capacity. As Owner’s sole obligation under this clause (a), upon its receipt of any of the entitlements or rights described in the foregoing sentence, Owner shall promptly convey such entitlements or rights to Distribution Company.
(b) In the event tie benefits or interconnection capability credits (or any similar concept) are ever deemed applicable to the NECEC Transmission Line and to the extent allocated to any Party during the Term, Distribution Company shall be entitled to its Proportionate Share of one hundred percent (100%) of the economic benefits associated therewith (however entitled and whether existing now or in the future), without additional cost to Distribution Company or compensation to Owner. For purposes of this clause (b), the denominator of the “Proportionate Share” shall be the Physical Transmission Line Capacity.
(c) Owner shall have no obligation to support the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above, but Owner may not oppose the creation or establishment of any such right, unless otherwise agreed in writing by Distribution Company. Neither Section 2.5 nor the foregoing sentence shall be construed in any way to limit the right of any Affiliate of Owner to oppose the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above.
36
[INTENTIONALLY OMITTED]
Article XIII
BILLING AND PAYMENTS
Section 13.1 Invoices . Within seven (7) Business Days after the first day of each calendar month following the commencement of the Operation Phase, Owner shall submit an Invoice to Distribution Company for the Transmission Service Payments owed for the preceding calendar month, and Distribution Company shall pay the amounts set forth in the Invoice to Owner within fourteen (14) Business Days following its receipt of such Invoice. All payments shall be made in immediately available funds payable to Owner by wire transfer to a bank named by Owner, in accordance with wiring instructions provided to Distribution Company by Owner in writing. Owner shall be entitled to change the place or recipient for payment by thirty (30) days’ prior written notice to Distribution Company.
Section 13.2 Procedures for Billing Disputes .
(a) In the event of any Dispute with respect to the amount owed to Owner by Distribution Company under this Agreement, Distribution Company shall have no right to withhold payment of the Disputed amount pending resolution of the Dispute; provided, however, that, in the event such Dispute is resolved in favor of Distribution Company, Owner shall complete the following tasks consistent with the resolution of such Dispute: (i) retroactively adjust all payments previously made by Distribution Company; (ii) promptly refund all overpayments previously made by Distribution Company, together with interest thereon in immediately available funds or by wire transfer, in each case, in accordance with wiring instructions provided to Owner by Distribution Company in writing; and (iii) thereafter conform all future Invoices to reflect the resolution of such Dispute, as applicable. Distribution Company’s payment of any Disputed amounts shall be without prejudice to any right or remedy that Distribution Company may have under this Agreement to contest any such amount.
(b) Distribution Company shall not have the right to challenge any Invoice or to bring any action of any kind challenging the propriety of any Invoice after the second (2nd) anniversary of the receipt of such Invoice. If an Invoice is not rendered within two (2) years after the end of the calendar month during which such Invoice should have been rendered hereunder, then the right to payment of such Invoice is waived.
Section 13.3 Interest . All interest payable under this Section 13.3 shall be calculated pursuant to 18 C.F.R. § 35.19a(a), as such regulation (or any successor thereto) is in effect during the period during which such interest is due. Amounts not paid when due to Owner or Distribution Company under this Agreement shall bear interest from the date such amount was due until the date of payment of such overdue amount. For the avoidance of doubt, as illustrated in Attachment H, if all or a portion of the amount to which such interest relates is later refunded pursuant to this Agreement, then, in calculating that refund, such interest shall not be included in the refund. Refunds of overpayments owed to Distribution Company by Owner under this Agreement shall begin to accrue interest on the amount subject to refund, as originally invoiced, from the earlier to occur of the due date or the date of payment of the monthly Invoices to which the overpayment relates and shall continue to accrue interest until the date of payment of such refund.
37
Section 13.4 Obligation to Make Payments . The Parties acknowledge and agree that, except as set forth in Section 3.3.8 , Section 8.1 , Section 13.5 and Section 14.4(d) , no cause or event whatsoever shall excuse or suspend Distribution Company’s obligation to pay Transmission Service Payments or any other amounts payable by Distribution Company under this Agreement. The Parties also acknowledge and agree that no cause or event whatsoever shall excuse or suspend any amounts payable by Owner under this Agreement.
Section 13.5 Offsets . Except as otherwise provided in Section 3.4(a) and Section 14.4(d) , neither Party shall be entitled to deduct or set-off payment of any amount owed to the other Party under this Agreement against payment of any amount owing under this Agreement.
Article XIV
EVENTS OF DEFAULT AND REMEDIES
Section 14.1 Distribution Company Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Distribution Company under this Agreement (a “ Distribution Company Default ”), provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (c), clause (d), or clause (e) :
(a) Distribution Company’s failure to pay any undisputed amount due to Owner under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Distribution Company of a written demand from Owner that such amount is due and owing and has not been timely paid.
(b) Distribution Company’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clause (a) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Distribution Company of written notice thereof from Owner, unless such cure shall reasonably require a longer period, in which case Distribution Company shall be provided an additional thirty (30) days to complete such cure so long as Distribution Company has promptly commenced such cure and thereafter diligently pursues such cure.
(c) Any representation or warranty made by Distribution Company in this Agreement is false or misleading at the time made in any material respect.
(d) Any Insolvency Event occurs with respect to Distribution Company.
(e) Any termination of the PPA due to an “Event of Default” by Distribution Company under and as defined in the PPA.
Section 14.2 Owner Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Owner under this Agreement (an “ Owner Default ”) , provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (h), or clause (i) :
38
(a) Owner’s failure to pay any undisputed amount due to Distribution Company under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Owner of a written demand from Distribution Company that such amount is due and owing and has not been timely paid.
(b) Owner’s failure to satisfy (other than solely as a result of an HQUS Delay) any of the Critical Milestones in clauses (i), (iii), (iv), (v), or (vii) of Section 4.1(a) by the dates set forth therefor, as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) .
(c) The failure of the NECEC Transmission Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date, where Distribution Company has also not agreed in writing to begin transmission service hereunder notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Remediation Date or the end of the Remediation Period.
(d) Owner’s failure to comply in any material respect with the provisions of Section 5.1.1(a)(ii) and, if such failure is susceptible to cure, such failure continues for thirty (30) days after receipt by Owner of written notice thereof from Distribution Company, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(e) A Non-Excused Outage pursuant to which the average Hourly Availability of the NECEC Transmission Line over any calendar month is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , occurs and continues for more than ninety (90) consecutive days or more than one hundred twenty (120) days in any twelve (12) month period, provided, however, that if (i) Owner presents to Distribution Company before the end of a Non-Excused Outage that would otherwise constitute an Owner Default under this clause (e), a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company, acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, and (ii) Owner posts Credit Support (in addition to the Owner Security) in an amount equal to $5,000 per MWh/h of the Contract Maximum Amount for each such six-month portion of such period, Distribution Company shall forbear terminating this Agreement under this clause (e) for such period, provided that, during any such period, Distribution Company’s obligation to make Transmission Service Payments shall continue to be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. Any additional Credit Support provided under this Section 14.1(e) shall be returned to Owner if Owner is providing Firm Transmission Service in full at the end of the period of forbearance. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, an Owner Default shall be deemed to have occurred and Distribution Company shall have the rights and remedies set forth in Section 14.4 , which, for the avoidance of doubt, shall include recourse against any Credit Support posted by Owner.
39
(f) Owner’s failure to comply in any material respect with the provisions of Article XVI .
(g) Owner’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), (c), (d), (e) or (f) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Owner of written notice thereof from Distribution Company, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(h) Any representation or warranty made by Owner in this Agreement is false or misleading at the time made in any material respect.
(i) Any Insolvency Event occurs with respect to Owner.
Section 14.3 Remedies Upon Distribution Company Default . Upon the occurrence of a Distribution Company Default and at any time thereafter so long as the same is continuing, Owner shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Owner shall elect:
(a) Subject to Section 5.6 hereof and Section 14.8 of the HQUS TSA: (i) in the case of Distribution Company Default under any clause of Section 14.1 other than clause (e), Owner may terminate this Agreement by written notice to Distribution Company, or (ii) in the case of a Distribution Company Default under clause (e) of Section 14.1 , Owner shall terminate this Agreement upon receipt of Distribution’s Company written request.
(b) In the case of a Distribution Company Default pursuant to Section 14.1(a) , and subject to Section 5.6 , Owner may suspend all or part of Owner’s obligations or Distribution Company’s rights under this Agreement during the period during which such Distribution Company Default is continuing. During any such period of suspension occurring after the Commercial Operation Date, (i) Distribution Company shall not be entitled to schedule, and shall not schedule, any transactions over the NECEC Transmission Line, and (ii) Owner shall be obligated, in the event HQUS so elects as provided in the HQUS TSA, to allow HQUS to assume the rights and obligations of Distribution Company under this Agreement during such suspension. If HQUS does not exercise the rights described in clause (ii) of the preceding sentence, (x) the OASIS Administrator shall be directed to post any portion of the transmission capacity that would have otherwise been available to Distribution Company over the NECEC Transmission Line pursuant to this Agreement and to attempt to sell such capacity to one or more third parties consistent with Article X , (y) the proceeds of any capacity releases and transmission resales made pursuant to clause (x) of this sentence and received by Owner, net of reasonable fees (including attorneys’ fees) and other expenses incurred by Owner in connection with this Section 14.3(b) , shall be credited against any accrued but unpaid payment obligation of Distribution Company to Owner hereunder and (z) any such proceeds in excess of such accrued but unpaid payment obligation of Distribution Company shall be credited in accordance with Section 10.5 .
40
(c) Subject to Article XVIII and this Section 14.3 , as applicable, Owner may recover from Distribution Company the Distribution Company Termination Payment and, to the extent applicable, all other amounts not waived in accordance with Section 3.3.4(c) or, in the absence of a termination pursuant to a Distribution Company Default, all damages suffered by Owner that are due to a Distribution Company Default, including, for the avoidance of doubt, any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Distribution Company under this Agreement.
(d) Owner may exercise any and all other rights and remedies that may be available to Owner against Distribution Company at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Owner shall have no right to (i) terminate this Agreement based upon a Distribution Company Default, except as provided in clause (a) above, or (ii) suspend transmission service under this Agreement based on a Distribution Company Default, except as provided in clause (b) above.
Section 14.4 Remedies Upon Owner Default . Upon the occurrence of an Owner Default and at any time thereafter so long as the same is continuing, Distribution Company shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Distribution Company shall elect:
(a) In the case of an Owner Default, and subject to Section 5.6 hereof, Distribution Company may recover any accrued but unpaid amounts under Section 4.4.1 and Section 4.4.2 and the Owner Termination Payment and (i) in the case of an Owner Default under any clause of Section 14.2 other than clause (c), Distribution Company may terminate this Agreement by written notice to Owner, or (ii) in the case of an Owner Default under clause (c) of Section 14.2 , this Agreement shall automatically be terminated; provided, however, in the event that HQUS exercises its right under the HQUS TSA to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under this Agreement prior to the effective date of such termination, no termination of this Agreement shall occur under this Section 14.4(a) . In the event that HQUS timely exercises such rights, (x) upon receipt of HQUS’s notice that it is exercising such rights, Owner shall promptly notify Distribution Company thereof and (y) upon the effectiveness of HQUS’ purchase or assumption of control of the NECEC Transmission Line and assumption of Owner’s obligations under this Agreement, (A) Distribution Company and HQUS shall enter into such amendments to this Agreement as are reasonably necessary in order to give effect to such rights of HQUS and assumptions of obligations by HQUS that are consistent with the terms and conditions of this Agreement and are subject to applicable regulatory approvals and (B) thereafter HQUS shall perform and Distribution Company shall continue to perform their respective obligations under this Agreement.
(b) Subject to the limitations provided in Section 4.4.1(d) , Section 4.4.2(c) , Article XVIII or this Section 14.4 , as applicable, Distribution Company may recover from Owner any accrued but unpaid amounts under Section 4.4.1 and Section 4.4.2 (as applicable) and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement.
41
(c) Distribution Company may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Credit Support (including, for avoidance of doubt, the Owner Security) held by Distribution Company, and (ii) the right to liquidate any and all Credit Support held by Distribution Company and to apply the proceeds of such liquidation to any amounts payable to Distribution Company with respect to Owner’s obligations hereunder in such order as Distribution Company may elect. Distribution Company may draw on the undrawn portion of any Letter of Credit provided as Credit Support up to the amount of Owner’s outstanding obligations hereunder. Owner shall remain liable for amounts due and owed to Distribution Company that remain unpaid after the application of Credit Support.
(d) Pursuant to Section 13.2 , to the extent there is a Dispute over the amount of the damages suffered by Distribution Company as a result of an Owner Default, Distribution Company may deduct and setoff payment of such amount against any Transmission Service Payment upon the resolution of that Dispute.
(e) Distribution Company may exercise any and all other rights and remedies that may be available to Distribution Company at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Distribution Company shall have no right to (i) terminate this Agreement based upon an Owner Default, except as provided in clause (a) above, or (ii) any reduction of or offset against payments under this Agreement based upon an Owner Default, except as contemplated by Section 8.1 , Section 13.5 and Section 14.4(d) , as applicable.
Section 14.5 Abandoned Plant Recovery . Owner may request from FERC recovery of abandoned plant costs from Distribution Company in the event of the cancellation, termination and abandonment of the NECEC Transmission Line but (a) only if (i) due to the termination of this Agreement by either Party prior to the Commercial Operation Date, or (ii) due to the termination of this Agreement by Distribution Company following the Commercial Operation Date, or (iii) this Agreement is rendered null and void pursuant to Section 19.2(c), and (b) only if such cancellation, termination, and abandonment results from changes after the Effective Date in Massachusetts laws or regulations (including changes in the manner in which the law is applied by those acting under the color of Massachusetts laws or regulations) or changes in MDPU orders that invalidate this Agreement or the Distribution Company’s obligation to pay for Firm Transmission Service or to pay the Distribution Company Termination Payment under this Agreement. In no event will Owner be entitled to recover abandoned plant costs under any other circumstances or in the event that the cancellation, termination or abandonment was caused directly or indirectly by some act or failure to act on the part of Owner or HQUS or their respective affiliates, agents or contractors, including, without limitation, an Owner Default or a Default (as defined in the PPA) by HQUS under the PPA, and Owner agrees not to seek from FERC or any other agency or authority any treatment of abandonment costs inconsistent with this provision, in accordance with Section 2.2.2.6.2 of the request for proposals pursuant to which this Agreement has been executed. In any such case, Owner’s recovery shall be limited to the Proportionate Share of its costs related to the NECEC Transmission Line that were prudently incurred after March 31, 2017, provided that, for purposes of calculating the Proportionate Share, on or after the Commercial Operation Date the denominator of the “Proportionate Share” shall be 1,200 MW. Owner may only request recovery of abandoned plant costs up to the remaining amounts available under the cap on Distribution Company’s liability under Section 14.7.2 . Distribution Company
42
shall have the right to participate in such proceedings and to object to or seek to limit the recovery of any abandoned plant costs not expressly permitted to be recovered by Owner under this Section 14.5 or not consistent with FERC policy or precedent. Owner may not seek recovery under this Section 14.5 if it has been paid the Distribution Company Termination Payment.
Section 14.6 Disputes . Any Dispute over whether or not an Owner Default or Distribution Company Default has occurred shall be resolved in accordance with Article XVII .
Section 14.7 Limitations on Total Liability .
Section 14.7.1 Owner Liability . Notwithstanding anything herein to the contrary, Owner’s liability for any payments made to Distribution Company pursuant to Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.2(a) , or 14.4 shall not exceed, in aggregate, the Proportionate Share multiplied by One Hundred Twenty Million Dollars ($120,000,000).
Section 14.7.2 Distribution Company Liability . Notwithstanding anything herein to the contrary, Distribution Company’s liability for any payments made to Owner pursuant to Sections 3.3.4 , 3.4 , 14.3 , and 14.5 shall not exceed, in aggregate, the Proportionate Share multiplied by One Hundred Twenty Million Dollars ($120,000,000).
Section 14.7.3 Exceptions to Total Liability . The limits on liability set forth in Sections 4.4 and 14.7.1 shall not apply to any liability of Owner arising out of Owner’s gross negligence, willful misconduct (including willful breach of this Agreement), or fraud. The limits on liability set forth in Section 14.7.2 shall not apply to any liability of Distribution Company arising out of Distribution Company’s gross negligence, willful misconduct (including willful breach of this Agreement), or fraud.
Article XV
FORCE MAJEURE
Section 15.1 Definition; Conditions .
(a) The term “ Force Majeure ” means an event or circumstance (i) that is not within the reasonable control of the Party claiming its occurrence; (ii) that could not have been prevented or avoided by such Party through the exercise of reasonable diligence and (iii) that prohibits or prevents such Party from performing its obligations under this Agreement. Under no circumstances shall Force Majeure include (w) any full or partial curtailment in the operation of the NECEC Transmission Line that is caused by or arises from a mechanical or equipment breakdown or other mishap or events or conditions attributable to normal wear and tear or flaws of the NECEC Transmission Line, unless such curtailment or mishap is caused by one of the following: acts of God such as floods, hurricanes, tornados, or other significantly unusual and abnormal weather conditions such as severe blizzards and severe ice storms; sabotage; terrorism or war; national or regional general strikes, lockouts or other labor disputes, (x) any occurrence or event that increases the costs or causes an economic hardship to a Party but is not otherwise a Force Majeure, (y) Owner’s ability to sell transmission service involving the NECEC Transmission Line at a price greater than that set out in this Agreement or (z) Distribution Company’s ability to procure transmission service at a price lower than that provided in this Agreement, or Distribution Company’s ability to purchase generation at a price lower than that provided in the PPA. In addition, a delay or inability to perform attributable to a Party’s lack of
43
preparation, a Party’s failure to timely obtain and maintain all necessary permits (excepting the Regulatory Approval other than the obligations to file for Regulatory Approval) or qualifications, any delay or failure to obtain the Owner Approvals, Canadian Approvals, or Municipal Owner Approvals, a failure to satisfy contractual conditions or commitments, or lack or deficiency in funding or other resources shall each not constitute a Force Majeure or be the basis for a claim of Force Majeure. Neither Party may raise a claim of Force Majeure based in whole or in part on the failure of HQUS to fulfill any of its obligations under the PPA (including without limitation related to the availability of the Quebec Line) unless such failure is due to “force majeure” as stated in Section 10.1 of the PPA.
(b) Subject to Section 15.1(a) , if either Party is unable, wholly or in part, by Force Majeure to perform its obligations under this Agreement, such performance shall be excused and suspended so long as the circumstances that give rise to such inability exist or would exist if the Party claiming the Force Majeure used commercially reasonable efforts to cure such circumstances, but for no longer period. The Party whose performance is affected shall give prompt notice thereof to the other Party; such notice may be given orally or in writing but, if given orally, it shall be promptly confirmed in writing, providing details regarding the nature, extent and expected duration of the Force Majeure, its anticipated effect on the ability of such Party to perform its obligations under this Agreement, and the estimated duration of any interruption in service or other adverse effects resulting from such Force Majeure, and shall be updated or supplemented to keep the other Party advised of the effect and remedial measures being undertaken to overcome the Force Majeure. Such inability to perform shall be promptly corrected to the extent it may be corrected through the exercise of due diligence consistent with Good Utility Practice. Neither Party shall be liable for any losses or damages arising out of a suspension of performance that occurs because of Force Majeure. Notwithstanding any such suspension of performance, Distribution Company shall be obligated to make Transmission Service Payments as though Firm Transmission Service was then being provided at or greater than the Minimum Average Availability.
(c) Notwithstanding the foregoing, if the Force Majeure prevents full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, the Party whose performance is not prevented by Force Majeure shall have the right to terminate this Agreement upon written notice to the other Party and without further recourse; provided, however, that if (i) Owner presents a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company, acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, to Distribution Company before the end of a period in which Owner’s provision of Firm Transmission Service has been prevented in whole or in part by an event of Force Majeure, Distribution Company shall forbear terminating this Agreement under this clause (c) for such period, provided that, during any such period, Distribution Company’s obligation to make Transmission Service Payments shall be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, Distribution Company may terminate this Agreement under this clause (c). In no event will any delay or failure of performance caused by any conditions or events of Force Majeure extend this Agreement beyond its stated Term.
44
(d) A Party shall not be required to settle any strike, walkout, lockout or other labor dispute on terms that, in the sole judgment of such Party, are contrary to its interest. The settlement of strikes, walkouts, lockouts or other labor disputes shall be entirely within the discretion of the Party involved in such dispute.
Article XVI
FINANCIAL ASSURANCES
(a) Owner shall be required to post Credit Support in the amount of $4,983,480.00 (“ Owner Security ”) to secure Owner’s obligations under this Agreement in the period beginning on the Effective Date and continuing through and including the date that all of Owner’s obligations under this Agreement are satisfied. Fifty percent (50%) of the Owner Security shall be provided to Distribution Company within three (3) Business Days following the Execution Date; and the remaining fifty percent (50%) shall be provided to Distribution Company within fifteen (15) Business Days after receipt of the Regulatory Approval.
(b) If at any time during the Term of this Agreement, the amount of Credit Support is reduced as a result of Distribution Company’s draw upon such Credit Support, Owner shall replenish such Credit Support to the total amount required under this Section 16.1 within five (5) Business Days of that draw, provided that any replenishment obligation shall be subject to the limitations on total liability set forth in Section 14.7 .
(c) Any Cash provided by Owner as Credit Support under this Agreement shall be held in an account selected by Distribution Company in its reasonable discretion. Interest shall accrue on that Cash deposit at the daily Federal Funds Rate and shall be remitted to Owner upon written request to Distribution Company, with such request not more often than on a quarterly basis, and Distribution Company shall remit such accrued interest to the Owner within a reasonable time following receipt of such request. Owner agrees to comply with the commercially reasonable requirements of Distribution Company in connection with the receipt and retention of any Cash provided as Credit Support under this Agreement.
(d) Any unused Credit Support provided under this Agreement shall be returned to Owner only after any such Credit Support has been used to satisfy any outstanding obligations of Owner in existence at the time of the expiration or termination of this Agreement. Provided such obligations have been satisfied, such Credit Support shall be returned to Owner within thirty (30) days after the expiration or earlier termination of this Agreement.
45
DISPUTE RESOLUTION
(a) The Parties shall initially attempt to resolve any Dispute through consultations between the Parties. Subject to Section 17.2 and except as expressly provided otherwise in this Agreement, if a Dispute has not been timely resolved pursuant to this clause (a) within fifteen (15) Business Days after written notice of such Dispute has been given, then either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction; provided, however, if the Dispute is subject to Section 17.2 , then either Party may elect to proceed with the mediation through FERC's Dispute Resolution Service. If one Party fails to participate in the consultations provided for in this Section 17.1 , the other Party can initiate mediation prior to the expiration of the fifteen (15) Business Days. Unless otherwise agreed, the Parties will select a mediator from the FERC panel. The Parties may, by written agreement signed by both Parties, alter any time deadline, location(s) for meeting(s), or procedure outlined herein or in FERC’s rules for mediation. The procedure specified herein shall be the sole and exclusive procedure for the resolution of Disputes.
(b) All negotiations, consultations, and mediations pursuant to this Section 17.1 shall be deemed to be confidential and shall be treated as compromise and settlement negotiations, and no evidence with regard to any proposal made during such negotiations, consultations, or mediations shall be admissible in any FERC proceeding or filing under Section 17.2 or in any other judicial or other proceeding.
Section 17.2 Disputes to be Resolved by FERC .
(a) In the event a Dispute over any matter is not resolved in accordance with Section 17.1 , either Party shall have the right to file for relief with FERC to the extent that matter is within the primary or exclusive jurisdiction of the FERC. Nothing contained in this Agreement shall be construed as precluding a Party from filing any answer, protest or other opposition to any FERC filing made by the other Party, unless expressly prohibited under the terms of this Agreement.
(b) In the event any Dispute is submitted to FERC for resolution as provided in Section 17.2(a) , the Party submitting the Dispute to FERC shall be responsible for providing written notice of such filing to the other Interested Parties. Unless both Parties agree that the Dispute does not implicate any of the Proposal Agreements other than this Agreement, each Party consents and agrees that (i) each Interested Party is an interested party in the Dispute and (ii) in order to avoid inconsistent interpretations and adjudications of the Proposal Agreements, any Interested Party may, without objection from any other Interested Party, whether by means of joinder, consolidation or otherwise, submit such matters as it considers sufficiently related to the Dispute to FERC to be jointly determined by FERC with the Dispute. Notwithstanding the foregoing, in the event FERC determines that it does not have the jurisdiction to, or otherwise does not want to, hear or determine any portion of a Dispute or other matter so referred to FERC, either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction.
46
Section 17.3 Consent to Jurisdiction . Subject to Section 17.2 , each Party agrees that any legal action or proceeding with respect to or arising out of this Agreement or any other Proposal Agreement shall be brought in or removed to the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts that has subject matter jurisdiction and any appellate court from any thereof. By execution and delivery of this Agreement, each Party hereby accepts for itself and in respect of its property, generally and unconditionally, the jurisdiction of the aforesaid courts. The Parties irrevocably consent to the service of process out of any of the aforementioned courts in any such action or proceeding by the mailing of copies thereof by registered or certified airmail, postage prepaid, to the applicable Party at its respective addresses for notices as specified in Section 23.4 . Nothing herein shall affect the right to serve process in any other manner permitted by law. Each Party hereby waives any right to stay or dismiss any action or proceeding under or in connection with this Agreement or any other Proposal Agreement brought before the foregoing courts on the basis of forum non-conveniens.
Section 17.4 WAIVER OF JURY TRIAL . EACH PARTY IRREVOCABLY AND UNCONDITIONALLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY LEGAL ACTION, PROCEEDING, CAUSE OF ACTION, OR COUNTERCLAIM ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.
Article XVIII
LIMITATION OF REMEDIES
NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, NEITHER PARTY NOR ANY OF ITS AGENTS, SUBCONTRACTORS, REPRESENTATIVES OR AFFILIATES SHALL BE LIABLE TO THE OTHER PARTY FOR PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE (EXCEPT AS EXPRESSLY CONTEMPLATED IN THIS AGREEMENT, INCLUDING IN Section 4.4 , OR FOR ANY DIRECT DAMAGES SUFFERED BY DISTRIBUTION COMPANY AS A RESULT OF A BREACH BY OWNER OF ITS OBLIGATIONS UNDER Section 6.2 , Article X OR Section 11.2 ), IN EACH CASE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OF THIS AGREEMENT, AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY).
FOR THE AVOIDANCE OF DOUBT, THE PARTIES ACKNOWLEDGE AND AGREE THAT Section 4.4 OR Section 7.3 PROVIDE THE SOLE AND EXCLUSIVE REMEDIES FOR ANY LOSS OF USE CONTEMPLATED BY Section 4.4 OR Section 7.3 AND NOTHING IN Section 6.2 , Article X OR Section 11.2 SHALL SUPERSEDE, SUPPLEMENT OR AMEND SUCH SOLE AND EXCLUSIVE REMEDIES.
THIS ARTICLE XVIII IS IN ADDITION TO THE SPECIFIC LIMITATIONS ON REMEDIES REFERENCED IN ARTICLE XIV , SECTION 4.4.1 , AND SECTION 4.4.2 .
47
MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES.
Section 19.1 Modifications . The Parties specifically intend and acknowledge and agree that, except as otherwise expressly provided in this Agreement, (a) this Agreement shall not be subject to amendment or other modification, absent the written agreement of both Parties and (b) neither Party shall be permitted to make a filing with FERC under any provision of the Federal Power Act or the regulations promulgated thereunder that seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement at any time during the Term, except to implement an amendment or other modification to this Agreement that has been reduced to writing and signed by both Parties. In addition, to the extent any third party, or FERC acting sua sponte seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement, the standard of review for any proposed amendment or other modification shall be the “public interest” standard of review set forth in United Gas Pipe Line Co. v. Mobile Gas Service Corp., 350 U.S. 332 (1956), and Federal Power Commission v. Sierra Pacific Power Co., 350 U.S. 348 (1956), and as further defined in Morgan Stanley Capital Group, Inc. v. Public Utility District No. 1 of Snohomish County, 128 S. Ct. 2733 (2008) and NRG Power Marketing, LLC v. Maine Public Utilities Commission, 130 S. Ct. 693 (2010).
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment .
(a) This Agreement is subject to the ISO-NE Rules. If, during the Term, any ISO-NE Rule is terminated, modified or amended, or is otherwise no longer applicable, resulting in a material alteration of a material right or obligation of a Party hereunder, the Parties agree to negotiate in good faith in an attempt to amend or clarify this Agreement to embody the Parties’ original intent regarding their respective rights and obligations under this Agreement, provided that neither Party shall have any obligation to agree to any particular amendment or clarification of this Agreement. The intent of the Parties is that any such amendment or clarification reflect, as closely as possible, the intent, substance and effect of the ISO-NE Rule being replaced, modified, amended, or made inapplicable as such ISO-NE Rule was in effect prior to such termination, modification, amendment, or inapplicability; provided that such amendment or clarification shall not in any event alter (i) the purchase and sale obligations of the Parties pursuant to this Agreement or (ii) the Transmission Service Payment. In the event the Parties cannot agree upon such amendments within sixty (60) days after such ISO Rule or ISO-NE Practice change described above, the Dispute shall be resolved in accordance with Article XVII .
(b) If, during the Term, there is a change in Applicable Law (other than tax laws or regulations) or accounting standards or rules or a change in the interpretation or applicability thereof that would result in (i) material adverse balance sheet or creditworthiness impacts on Distribution Company associated with this Agreement or the amounts paid for Firm Transmission Service purchased hereunder, or (ii) an adverse impact on the economic benefits (including those stemming from the fiscal conditions provided for herein) that Owner enjoys under this Agreement or that are provided for herein for Owner during the Term, the Parties shall use commercially reasonable efforts to agree to an amendment to the Agreement to avoid or mitigate such impacts and restore the economic benefits to each affected Party; provided that such amendment mitigates any
48
material adverse effect(s) on each non-affected Party (as identified by each such Party, acting reasonably) that could reasonably be expected to result from such amendment, but only to the extent that such mitigation can be accomplished in a manner that is consistent with the purpose of such amendment. I n the event the Parties cannot agree on an amendment in accordance with this Section 19.2(b) , the dispute shall be resolved in accordance with Article XVII .
(c) Upon a determination by a court or regulatory body having jurisdiction over this Agreement or any of the Parties, or over the establishment and enforcement of any of the statutes or regulations or orders or actions of regulatory agencies (including the MDPU) supporting this Agreement or the rights or obligations of the Parties hereunder that any of the statutes or regulations supporting this Agreement or the rights or obligations of the Parties hereunder, or orders of or actions of regulatory agencies (including the MDPU) implementing such statutes or regulations, or this Agreement on its face or as applied, violates any Applicable Law (including the State or Federal Constitution) (an “ Adverse Determination ”), each Party shall have the right to suspend performance under this Agreement without liability. Owner may provide transmission service to a third party during any period of time for which Distribution Company suspends payments under this Section 19.2(c) . Upon an Adverse Determination becoming final and non-appealable, this Agreement shall be rendered null and void.
(d) For the avoidance of doubt, it is understood that the provisions of Article XVII regarding dispute resolution apply to any Dispute under this Article XIX .
Article XX
INDEMNIFICATION
Section 20.1 Owner Indemnity . Owner shall indemnify, defend and hold harmless Distribution Company and Distribution Company’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, a “ Distribution Company Indemnified Party ” ) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Distribution Company Indemnified Party, including any such liabilities incurred by a Distribution Company Indemnified Party under the PPA, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Distribution Company Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Distribution Company Indemnified Party.
49
Section 20.2 [Intentionally Omitted]
Section 20.3 Procedures . Promptly after the receipt by any Person seeking indemnification under this Article XX (the “ Indemnified Party ”) of written notice of the assertion of any claim by a third party with respect to any matter in respect of which indemnification may be sought hereunder (a “ Third Party Claim ”), the Indemnified Party shall give written notice (the “ Indemnification Notice ”) to Owner and shall thereafter keep Owner reasonably informed with respect thereto; provided, however, that the failure of the Indemnified Party to give the Indemnifying Party notice as provided herein shall not relieve Owner of any of its obligations hereunder, except to the extent that Owner is materially prejudiced by such failure. Owner shall be entitled to assume the defense of any Third Party Claim by written notice to the Indemnified Party of such intention given within thirty (30) days after the receipt by Owner of the Indemnification Notice; provided, however, that counsel selected by the Indemnifying Party shall be reasonably satisfactory to Owner. Owner shall be liable for the fees and expenses of counsel employed by the Indemnified Party for any period during which Owner has not assumed the defense of any Third Party Claim (other than during any period during which the Indemnified Party has failed to give notice of such Third Party Claim as provided above). If Owner shall assume the defense of the Third Party Claim, then the Owner shall not compromise or settle such Third Party Claim without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld, delayed or conditioned; provided, however, that the Indemnified Party shall have no obligation to consent to any settlement that (a) does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff of a release of the Indemnified Party from all liability with respect to such Third Party Claim or (b) involves the imposition of equitable remedies or the imposition of any material obligations on such Indemnified Party other than financial obligations for which such Indemnified Party is indemnified hereunder. As long as the Owner is contesting any such Third Party Claim on a timely basis, the Indemnified Party shall not pay, compromise or settle any claims brought under such Third Party Claim. Notwithstanding the assumption by the Owner of the defense of any Third Party Claim as provided in this Section 20.3 , the Indemnified Party shall be permitted to participate in the defense of such Third Party Claim and to employ counsel at its own expense (it being understood that Owner controls such defense); provided, however, that, if the defendants in any Third Party Claim shall include both an Owner and any Indemnified Party, and such Indemnified Party shall have reasonably concluded that counsel selected by Owner has a conflict of interest because of the availability of different or additional defenses to such Indemnified Party, such Indemnified Party shall then have the right to select separate counsel to participate in the defense of such Third Party Claim on its behalf, at the expense of Owner; provided that the Owner shall not be obligated to pay the expenses of more than one separate counsel for all Indemnified Parties, taken together.
Section 20.4 Defenses . If Owner shall fail to notify the Indemnified Party of its desire to assume the defense of any Third Party Claim within the prescribed period of time, or shall notify the Indemnified Party that it will not assume the defense of any such Third Party Claim, then the Indemnified Party may assume the defense of any such Third Party Claim, in which case it may do so acting in good faith and otherwise in such manner as it may deem appropriate, and the Owner shall be bound by any determination made in such Third Party Claim.
Section 20.5 Cooperation . The Indemnified Party and Owner shall each cooperate fully (and shall each cause its Affiliates to cooperate fully) with the other in the defense of any Third Party Claim pursuant to this Article XX . Without limiting the generality of the foregoing, each such Person shall furnish the other such Person (at the expense of the Owner) with such documentary or other evidence as is then in its or any of its Affiliates’ possession, as may reasonably be requested by the other Person for the purpose of defending against any such Third Party Claim.
50
Section 20.6 Recovery . The amount of any indemnity hereunder shall be reduced by any insurance proceeds actually recovered by the Indemnified Party in connection with the Third Party Claim. If at any time subsequent to the receipt by an Indemnified Party of an indemnity payment hereunder, such Indemnified Party (or any Affiliate thereof) receives any recovery, settlement or other similar payment with respect to the Third Party Claim for which it received such indemnity payment (a “ Recovery ” ), such Indemnified Party shall then promptly pay to the Owner the amount of such Recovery, less any expenses incurred by such Indemnified Party (or its Affiliates) in connection with such Recovery, but in no event shall any such payment exceed the amount of such indemnity payment.
Section 20.7 Subrogation . To the extent the Owner makes or is required to make any indemnity payment to the Indemnified Party, the Owner shall be entitled to exercise, and shall be subrogated to, any rights and remedies (including rights of indemnity, rights of contribution and other rights of recovery) that the Indemnified Party or any of its Affiliates may have against any other Person with respect thereto, whether directly or indirectly related. The Indemnified Party shall permit the Owner to use the name of the Indemnified Party and the names of the Indemnified Party’s Affiliates in any transaction or in any proceeding or other matter involving any of such rights or remedies; and the Indemnified Party shall take such actions as the Owner may reasonably request for the purpose of enabling the Owner to perfect or exercise its right of subrogation hereunder.
Article XXI
REPRESENTATIONS, WARRANTIES AND COVENANTS
Section 21.1 Mutual Representations and Warranties . Each Party hereby represents and warrants to the other Party that all of the statements in this Section 21.1 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of (i) the Effective Date and (ii) the Commercial Operation Date , but not as of any other date:
(a) It has knowledge and experience in financial matters and in the electric industry that enable it to evaluate the merits and risks of this Agreement and the transactions contemplated hereby, and is capable of evaluating such merits and risks and assuming such risks. It is acting for its own account, has made its own independent decision to enter into this Agreement as to whether this Agreement is appropriate and proper for it based upon its own judgment, is not relying upon the advice or recommendations of the other Party in doing so, and understands and accepts the terms, conditions, and risks of this Agreement and the transactions contemplated hereby;
(b) It has entered into this Agreement in connection with the conduct of its business;
(c) It is not acting as a fiduciary or an advisor with respect to this Agreement or the transactions contemplated hereby;
(d) It is not subject to an Insolvency Event and there are no proceedings pending or being contemplated by it or, to its knowledge, threatened against it that could result in the occurrence of an Insolvency Event with respect to it; and
51
(e) It is an entity subject to the procedures and substantive provisions of the Bankruptcy Code applicable to U.S. corporations or limited liability companies, as applicable, generally.
Section 21.2 Additional Representations and Warranties of Owner . Owner hereby represents and warrants to Distribution Company that all of the statements in this Section 21.2 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Owner is duly organized, validly existing, and in good standing under the laws of the State of Maine and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Owner, and Owner has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Owner has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Owner;
(c) Assuming due authorization, execution and delivery by Distribution Company, this Agreement constitutes Owner’s legal, valid and binding obligation enforceable against Owner in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Owner or any of its Affiliates that could have a Material Adverse Effect on Owner;
(e) No event with respect to Owner has occurred or is continuing that would constitute an Owner Default, and no Owner Default will occur as a result of Owner entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Owner does not and will not (i) violate any provisions of its articles of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The FERC Authorizations, Owner Approvals, Municipal Owner Approvals, and the AC Upgrade Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary to commence construction of and operate the NECEC Transmission Line;
(i) Owner has acquired all required real property rights necessary for construction and operation of the NECEC Transmission Line, and the interconnection of the NECEC Transmission Line with (A) the Québec Line (other than real property rights to be held by TransÉnergie) and (B) the Delivery Point, in full and final form with all options or contingencies having been exercised as set forth in Attachment I; and
52
(h) Owner is in compliance with all Applicable Laws, except such non-compliance as could not reasonably be expected to have a Material Adverse Effect on Owner. Owner has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Owner.
Section 21.3 Additional Representations and Warranties of Distribution Company . The Distribution Company hereby represents and warrants to Owner that all of the statements in this Section 21.3 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Distribution Company is duly organized, validly existing and in good standing under the laws of the Commonwealth of Massachusetts and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Distribution Company, and Distribution Company has all requisite power and authority to conduct its business, own its properties and to execute, deliver and perform its obligations under this Agreement;
(b) Distribution Company has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Distribution Company;
(c) Assuming due authorization, execution and delivery by Owner, this Agreement constitutes Distribution Company’s legal, valid and binding obligation enforceable against Distribution Company in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Distribution Company or any of its Affiliates that could have a Material Adverse Effect on Distribution Company;
(e) No event with respect to Distribution Company has occurred or is continuing that would constitute a Distribution Company Default, and no Distribution Company Default will occur as a result of Distribution Company entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Distribution Company does not and will not (i) violate any provisions of its certificate of incorporation or other governing documents, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The Regulatory Approval constitutes the only action, Consent, notification, waiver, order or filing that is necessary with respect to the execution, delivery and performance of this Agreement by Distribution Company; and
53
(h) Distribution Company is in compliance with all Applicable Laws, except such non-compliances as could not reasonably be expected to have a Material Adverse Effect on Distribution Company. Distribution Company has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Distribution Company.
(i) Distribution Company has not taken and will not take any action (including providing support or information to any Affiliate of Distribution Company) to directly or indirectly oppose or prevent the achievement of any Governmental Approval, Third Party Consent, or other milestone or requirement set forth in this Agreement.
Section 21.4 NO OTHER REPRESENTATIONS OR WARRANTIES . THE REPRESENTATIONS AND WARRANTIES OF OWNER SET FORTH IN Section 21.1 AND Section 21.2 ARE OWNER’S SOLE REPRESENTATIONS AND WARRANTIES ASSOCIATED WITH THE NECEC TRANSMISSION LINE AND ARE MADE IN LIEU OF ALL OTHER REPRESENTATIONS, WARRANTIES AND GUARANTEES, EXPRESS OR IMPLIED, ASSOCIATED WITH THE NECEC TRANSMISSION LINE, INCLUDING REPRESENTATIONS OR WARRANTIES AS TO MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE. THE FOREGOING SENTENCE SHALL NOT BE CONSTRUED IN ANY WAY TO LIMIT OWNER’S EXPRESS OBLIGATIONS UNDER THIS AGREEMENT.
Article XXII
TRANSFER OF INTERESTS
Section 22.1 No Transfer of Interests .
(a) Any (i) direct or indirect change of Control of any Party (whether voluntary or by operation of law), (ii) sale, transfer or other disposition of all or substantially all of the assets of any Party or (iii) except as provided in Section 22.2 or Section 22.3 , assignment, transfer or other disposition of, whether to one or more assignees or transferees, all or any portion of any Party’s rights, interests or obligations under this Agreement (each of the foregoing, a “ Transfer ”), shall require the prior written consent of the other Party, which consent shall not be unreasonably withheld, delayed or conditioned when viewed in light of all reasonable considerations, including the security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer); provided that any direct or indirect transfer of securities or other ownership interests in a Party to the Party’s Affiliate shall not be considered a Transfer for the purposes of this Section 22.1 and shall not require consent. Any Transfer in contravention of this Article XXII shall be null and void.
(b) If Owner consents to a Transfer by Distribution Company pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Distribution Company’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Owner of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that a Distribution Company Default shall not have occurred and be continuing, (x) the obligations of Distribution Company shall terminate to the extent of
54
the Transferred portion of this Agreement, and Distribution Company shall be fully, finally and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Distribution Company Owner shall execute and deliver to Distribution Company a full, final, and unconditional release of any Credit Support or guarantees provided by Distribution Company, in such form as Distribution Company may reasonably request, with respect to the Transferred portion of this Agreement.
(c) If Distribution Company consents to a Transfer by Owner pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee of Owner’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Distribution Company of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that an Owner Default shall not have occurred and be continuing (x) the obligations of Owner shall terminate to the extent of the Transferred portion of this Agreement, and Owner shall be fully, finally and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Owner, Distribution Company shall execute and deliver to Owner a full, final and unconditional release of any Credit Support or guarantees provided by Owner hereunder, in such form as Owner may reasonably request, with respect to the Transferred portion of this Agreement .
(d) Nothing herein shall prevent Distribution Company or any assignee thereof from transferring or assigning transmission service rights pursuant to FERC rules and regulations, including pursuant to Section 20 of the PPA.
Section 22.2 Exceptions . Notwithstanding Section 22.1 , consent shall not be required for any of the following:
(a) Distribution Company shall have the right to assign this Agreement without consent of Owner:
(i) to a successor in interest in any merger or consolidation of Distribution Company with or into another Person or any exchange of all of the common stock or other equity interests of Distribution Company or Distribution Company’s parent for cash, securities or other property or any acquisition, reorganization, or other similar corporate transaction involving all or substantially all of the common stock or other equity interests in, or assets of, Distribution Company so long as (1) the proposed assignee’s credit rating is at least either BBB- from S&P or Baa3 from Moody’s, or (2) the proposed assignee’s credit rating is equal to or better than that of Distribution Company at the time of the proposed assignment, or (3) the transaction associated with such assignment, has been approved by the MDPU or the appropriate Government Entity, in each case, with an express assumption of Distribution Company’s obligations hereunder in writing, reasonably acceptable to Owner and Distribution Company, if such assumption does not occur under Applicable Law; or
55
(ii) to any substitute purchaser of the Products so long as (1) the proposed assignee’s credit rating is at least either BBB- from S&P or Baa3 from Moody’s, and (2) the proposed assignee’s credit rating is equal to or better than that of Distribution Company at the time of the proposed assignment, and, if required, (3) such assignment has been approved by the MDPU or the appropriate Government Entity, in each case, with an express assumption of Distribution Company’s obligations hereunder in writing, reasonably acceptable to Owner and Distribution Company. For purposes of clarification, a disposition of this Agreement pursuant to this clause (ii) includes an assignment to any third party other than the successor in interest in connection with a transaction to which clause (i) applies.
(b) any (i) change of Control of Owner or (ii) transfer or other disposition of all or substantially all of the assets of Owner, in each case, resulting from a collateral assignment in favor of a financing party in accordance with Section 22.3 ;
(c) any change of Control of Owner resulting from any direct or indirect change of Control in Owner’s ultimate parent company (currently, Iberdrola, S.A.), Owner’s ultimate parent company in the United States (currently AVANGRID, Inc.) or in the parent company for the network business in the United States of which Owner is part (currently Avangrid Networks, Inc.); or
(d) the exercise of any of HQUS’s or the Distribution Company’s rights pursuant to Section 14.7, 14.8(a) or 14.8(b) of the HQUS TSA.
Section 22.3 Collateral Assignment . Owner shall be entitled, without restriction, to make one or more assignments of this Agreement for purposes of collateral security or any or all of its rights and benefits hereunder to or for the benefit of any and all secured lenders to Owner, or grant to or for the benefit of any and all secured lenders to Owner a lien on, or security interest in, any right, title or interest in all or any part of Owner’s rights hereunder for the purpose of the financing or successive refinancing of the ownership, development, engineering, construction or operation of the NECEC Transmission Line; provided, however, that such assignment for purposes of collateral security shall recognize Distribution Company’s rights under this Agreement on terms and conditions as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner. To facilitate Owner’s obtaining of financing or successive refinancing for the ownership, development, engineering, construction or operation of the NECEC Transmission Line, Distribution Company shall cooperate with Owner and shall execute and deliver such consents, acknowledgements, direct agreements or similar documents as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner.
Article XXIII
MISCELLANEOUS
Section 23.1 Governing Law . This Agreement and each of its provisions shall be governed by, and construed in accordance with, the laws of the Commonwealth of Massachusetts.
Section 23.2 Entire Agreement . This Agreement, together with the Attachments, constitutes the entire Agreement and understanding between the Parties with respect to all subjects covered hereby and thereby and supersedes all prior discussions, agreements and understandings between the Parties with respect to such matters.
56
Section 23.3 Severability . Except as otherwise provided in Section 2.2 or Section 19.2 , (a) in the event any part of this Agreement is held to be illegal, invalid or unenforceable to any extent, the legality, validity and enforceability of the remainder of this Agreement shall not be affected thereby, and shall remain in full force and effect and shall be enforced to the greatest extent permitted by Applicable Law and (b) with respect to any provision found to be illegal, invalid or unenforceable, the Parties shall endeavor to replace such invalid, illegal or unenforceable provision with the valid, legal and enforceable provision that achieves, as nearly as practicable, the commercial intent of this Agreement (as it may be amended from time to time).
Section 23.4 Notices . All notices, billings, requests, demands, waivers, consents and other communications under this Agreement shall be in writing and shall be effective (a) upon personal delivery thereof, including by overnight mail or courier service, with a record of receipt, (b) in the case of notice by United States mail, certified or registered, postage prepaid, return receipt requested, upon the fourth (4th) day after mailing, (c) in the case of notice by facsimile for any communications other than billings, upon transmission; provided that such facsimile transmission is promptly confirmed by either of the methods set forth in the foregoing clause (a) or (b), in each case, addressed to each Party and copy party hereto at its address set forth below or at such other address as a Party may from time to time designate by written notice to the other Party pursuant to this Section 23.4 , (d) in the case of notice by facsimile for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon receipt of confirmation of successful transmission, but without any further requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b), or (e) in the case of notice by electronic mail for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon transmission, without any requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b); provided that the Party delivering such notice did not receive any notice of unsuccessful or delayed transmission. A notice given in connection with this Section 23.4 but received on a day other than a Business Day, or after business hours at the location of receipt, shall be deemed to be received on the next Business Day.
|
If to Owner: |
|
|
|
|
|
|
Central Maine Power Company |
|
|
|
|
|
Attn: Douglas Herling, President & CEO |
|
|
|
|
|
83 Edison Drive, Augusta ME 04336 |
|
|
|
|
|
207-626-9779 |
|
|
|
|
With a copy to: |
|
|
|
|
|
|
Central Maine Power Company |
|
|
|
|
|
Attn: Legal Department |
|
|
|
|
|
83 Edison Drive, Augusta ME 04336 |
|
|
|
|
With a further copy to: |
|
|
|
|
57
|
|
Pierce Atwood LLP |
|
|
|
|
|
Attn: Jared des Rosiers |
|
|
|
|
|
254 Commercial St., Portland ME 04101 |
|
|
|
|
If to Distribution Company: |
|
|
|
|
|
|
Attn: Renewable Contract Manager, Environmental Transactions |
|
|
|
|
|
National Grid |
|
|
|
|
|
100 East Old Country Road, Second Floor |
|
|
|
|
|
Hicksville, NY 11801-4218 |
|
|
|
|
|
Email: RenewableContracts@nationalgrid.com , with a copy to |
|
|
ElectricSupply@nationalgrid.com |
|
|
|
|
With a copy to: |
|
|
|
|
|
|
Legal Department |
|
|
|
|
|
Attn: Cynthia R. Clark, Esq. |
|
|
|
|
|
Assistant General Counsel |
|
|
|
|
|
National Grid |
|
|
|
|
|
175 East Old Country Road |
|
|
|
|
|
Hicksville, NY 11801 |
|
|
|
|
|
Email: cynthia.clark@nationalgrid.com |
Section 23.5 Intentionally Omitted.
Section 23.6 Waiver; Cumulative Remedies . Any term or condition of this Agreement may be waived at any time by the Party that is entitled to the benefit thereof, but such waiver shall not be effective unless set forth in a written instrument duly executed by or on behalf of the Party waiving such term or condition. No waiver by any Party of any term or condition of this Agreement, in any one or more instances, shall be deemed to be, or construed as, a subsequent waiver of, or estoppel with respect to, the same or any other term or by Applicable Law. Except as otherwise provided in Section 13.2(b) , the failure of or delay on the part of any Party to enforce or insist upon compliance with or strict performance of any term or condition of this Agreement, or to take advantage of any of its rights thereunder, shall not constitute a waiver or relinquishment of any such terms, conditions, or rights, but the same shall be and remain at all times in full force and effect. Except as otherwise provided herein, the remedies provided in this Agreement are cumulative and not exclusive of any remedies provided by law or in equity.
58
Section 23.7 Confidential Information . Each Party hereby agrees that it shall not disclose, or cause to be disclosed, to third parties any Confidential Information with respect to the other Party or any material or information identified as Critical Energy Infrastructure Information (other than to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential). Notwithstanding the foregoing, each Party may disclose information related to this Agreement to another party to a Proposal Agreement or to Trans É nergie only if necessary to comply with its obligations hereunder or thereunder or to coordinate the parties’ obligations under different Proposal Agreements. Each Party shall be responsible for ensuring that any Person to whom it discloses any Confidential Information shall comply with the restrictions in this Section 23.7 . The restrictions in this Section 23.7 shall not apply (w) to the extent disclosure is required by Applicable Law or the requirements of a Governmental Authority (including a court order, oral questions, written interrogatories, request for information or documents, subpoena, or similar process, or the requirements of any stock exchange or other Governmental Authority to which the Parties, or any of their Affiliates are subject), (x) to the extent reasonably deemed by the disclosing Party to be required or desirable in connection with regulatory proceedings (including proceedings relating to FERC or any other national, federal, provincial, state or regulatory agency), (y) to the extent reasonably deemed by the disclosing Party to be required to be disclosed in connection with a Dispute between the Parties, or the defense of any litigation or dispute, or (z) as approved for release or disclosure by the Party whose Confidential Information is at issue. In the event disclosure is made pursuant to this Section 23.7 and except for disclosures pursuant to the requirements of securities laws or any stock exchange, the disclosing Party shall use reasonable efforts to minimize the scope of any disclosure and advise recipients of any applicable confidentiality restrictions provided herein. Notwithstanding the foregoing, this Section 23.7 shall not apply to the following information:
(a) Information that is a matter of public knowledge at the time of its disclosure or is thereafter published in or otherwise ascertainable from a source available to the public without breach of this Section 23.7 ;
(b) Information that is obtained from a Person other than by or as a result of unauthorized disclosure; or
(c) Information that, prior to the time of disclosure, had been independently developed or obtained by the disclosing Party or its Affiliates independent of information obtained as a result of unauthorized disclosure.
Section 23.8 No Third-Party Rights . Except for any secured lenders contemplated by Section 22.3 and any Distribution Company Indemnified Party contemplated by Article XX , and except for HQUS (which is intended to be a third party beneficiary of this Agreement solely to the extent of its capacity as an assignee of transmission rights as set forth in Section 20 of the PPA and for the purposes of and as contemplated by Article X of this Agreement, in light of its rights to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under this Agreement pursuant to Section 14.7 of the HQUS TSA, and with respect to Sections 1.1 , 3.3.1 - 3.3.7 , 5.3 , 5.5.1 , 11.1 , 23.7 , and Articles II , IV , VII , VIII , XIV , XV , and XVII ), the Parties do not intend for this Agreement to confer a third-party beneficiary status or rights of action upon any Person whatsoever other than the Parties and their permitted successors and assigns, and nothing contained herein, either express or implied, shall be construed to confer upon any Person, other than the Parties and their permitted successors and assigns, any rights of action or remedies under
59
this Agreement or in any manner, or any duty, standard of care, or liability with respect thereto. This Agreement does not create any third-party rights, except as expressly stated above in this Section 23.7 .
Section 23.9 Permitted Successors and Assigns . This Agreement shall be binding upon and inure to the benefit of each of the Parties and their permitted successors, legal representatives and assigns.
Section 23.10 Relationship of the Parties . This Agreement shall not be construed as creating an association, joint venture, trust or partnership between the Parties or as imposing any partnership obligation or liability upon either Party. Except as contemplated by Article X , neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.
Section 23.11 Construction . No presumption shall operate in favor of or against either Party as a result of any responsibility for drafting this Agreement.
Section 23.12 Counterparts . This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument. The Parties acknowledge and agree that any document or signature delivered by facsimile or electronic transmission shall be deemed to be an original executed document for all purposes hereof.
Section 23.13 Survival . The provisions of Section 3.3 , Section 3.4 , Section 8.2 , Article IX , Article XIII , Article XIV , Article XVII , Article XVIII , Article XIX , Article XX and this Article XXIII shall survive the expiration or earlier termination of this Agreement.
Section 23.14 Headings and Table of Contents . The headings of the articles and sections of this Agreement and the Table of Contents are inserted for purposes of convenience only, and shall not be construed to affect the meaning or construction of any of the provisions hereof.
Section 23.15 Waiver of Immunities . The Parties acknowledge and agree that this Agreement and the transactions contemplated hereby constitute a commercial transaction. To the extent a Party (including any assignees of a Party’s rights or obligations under this Agreement) may be entitled, in any jurisdiction, to claim for itself, or any of its assets, revenues or properties, sovereign or other immunity, as the case may be, from service of process, suit, the jurisdiction of any court or arbitral tribunal, attachment (whether in aid of execution or otherwise) or enforcement of a judgment (interlocutory or final) or award or any other legal process in a matter arising out of or relating to this Agreement, each Party agrees not to claim or assert, and hereby waives, such immunity. Without limiting the generality of the foregoing, each Party agrees that the waivers set forth in this Section 23.15 shall have the fullest scope permitted under the Immunities Act and under any other Applicable Law related to sovereign immunity.
[ Signature pages follow ]
60
IN WITNESS WHEREOF , Owner and Distribution Company have executed this Agreement as of the Execution Date.
|
OWNER: |
||
|
|
|
|
|
|
|
|
|
CENTRAL MAINE POWER COMPANY |
||
|
|
|
|
|
By: |
|
/s/ Douglas Herling |
|
Name: |
|
Douglas Herling |
|
Title: |
|
President & CEO |
|
|
|
|
|
|
|
|
|
By: |
|
/s/ Eric N. Stinneford |
|
Name: |
|
Eric N. Stinneford |
|
Title: |
|
Vice President, Controller, & Treasurer |
|
|
|
|
|
|
|
|
|
DISTRIBUTION COMPANY: |
||
|
|
|
|
|
|
||
|
MASSACHUSETTS ELECTRIC COMPANY AND NANTUCKET ELECTRIC COMPANY D/B/A NATIONAL GRID |
||
|
|
||
|
|
|
|
|
|
|
|
|
By: |
|
/s/ Marcy L. Reed |
|
Name: |
|
Marcy L. Reed |
|
Title: |
|
President |
Description of Transmission Projects
The Québec Line and the NECEC Transmission Line consist in their entirety of:
|
(1) |
New 207 mile (145.3 miles in Maine) +/- 320 kV overhead HVDC transmission line that will run between the existing Appalaches Substation in Thetford Mines, Québec and a new HVDC converter station approximately 1.6 miles from the existing Larrabee Road Substation in Lewiston, Maine; |
|
(2) |
New HVDC converter stations at both ends of the transmission line; and |
|
(3) |
Certain upgrades to the existing high voltage alternating current (AC) New England transmission system necessary to permit the interconnection and transmission of Hydro Generation to the New England Control Area (as defined in the ISO-NE Tariff) at the existing Larrabee Road substation under the requirements of Section I.3.9 and the CCIS of ISO-NE Tariff. |
|
(4) |
System upgrades to the existing Québec transmission system as determined by the Hydro-Québec TransÉnergie System Impact Study (OASIS #203T), as it may be updated. |
Owner is the developer of the portion of the NECEC Transmission Line from the Québec-Maine border to the Lewiston area and all transmission upgrades on the U.S. side of the border. The NECEC Transmission Line and the Québec Line are expected to connect at the Québec-Maine border in the northwest corner of Maine in Beattie Township.
The Québec Line will be constructed by TransÉnergie, a division of Hydro-Québec and an Affiliate of HQUS.
Owner will construct, own, operate and maintain the NECEC Transmission Line, which will be constructed in existing transmission corridors owned by Owner.
The NECEC Transmission Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 145.3 mile +/-320 kV HVDC transmission line from the Canadian Border to a new converter substation located on Merrill Road in Lewiston |
|
ii. |
New 1.6 mile 345 kV AC transmission line from the new Merrill Road converter substation to the existing Larrabee Road substation |
A-1
|
i. |
New 345 kV AC to +/-320 kV HVDC 1200 MW Merrill Road converter substation |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Larrabee Road substation |
|
(2) |
Network Upgrades (subject to change based on ISO-NE system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
New 26.5 mile 345 kV AC transmission line from the existing Coopers Mills substation in Windsor to the existing Maine Yankee substation in Wiscasset |
|
ii. |
New 0.3 mile 345 kV AC transmission line from the existing Surowiec substation in Pownal to a new substation on Fickett Road in Pownal |
|
iii. |
Rebuild 9.3 mile 115 kV Section 62 AC transmission line from the existing Crowley Road substation in Sabattus to the existing Surowiec substation |
|
iv. |
Rebuild 16.1 mile 115 kV Section 64 AC transmission line from the existing Larrabee Road substation to the existing Surowiec substation |
|
v. |
Partial rebuild of 0.8 mile each of 115 kV section 60/88 outside Coopers Mills substation |
|
vi. |
Partial rebuild of 0.3 miles of 345 kV Section 392 AC transmission line between the Coopers Mills substation and the Maine Yankee substation and approximately 3.5 miles of reconductor work on existing double circuit lattice steel towers outside of the Maine Yankee substation |
|
vii. |
Partial rebuild of 0.3 miles of 345 kV Section 3025 between Coopers Mills substation and Larrabee Road substation |
|
viii. |
Partial rebuild 0.8 miles of 34.5 kV Section 72 AC transmission line outside of the Larrabee Road substation |
|
b. |
Substation Equipment: |
|
i. |
Replace existing Larrabee Road 345/115 kV 448 MVA autotransformer with a 600 MVA autotransformer |
A-2
|
ii. |
Add 345 kV AC transmission line terminal at the existing Maine Yankee substation |
|
iii. |
Add 345 kV AC transmission line terminal and 115 kV switch replacements at the existing Surowiec substation |
|
iv. |
115 kV Switch and bus wire replacements at Crowley substation |
|
v. |
New 345 kV Fickett Road substation with 345 kV +/-200 MVAr Static Compensator (STATCOM) |
|
vi. |
Add 345 kV AC transmission line terminal and additional 345 kV +/-200 MVAr STATCOM (+/-400 MVAr total with the +/-200 MVAr existing) at the existing Coopers Mills substation |
|
vii. |
Add 345/115 kV 448 MVA autotransformer, associated 115 kV buswork and terminate existing 115 kV Sections 164, 164A and 165 into three new breaker-and-a-half bays at the existing Raven Farm substation |
The NECEC transmission components located in Maine are depicted geographically in relationship to the existing Owner transmission system in Figure 1 below.
A-3
Figure 1 – Map Depicting the Components of the NECEC Transmission Line
A-4
The Québec Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 65 mile +/-320 kV HVDC transmission line from the Appalaches substation located in Thetford Mines to the U.S. border |
|
b. |
Substation Equipment : |
|
i. |
New +/-320 kV, 1200 MW HVDC converter connected to the 735 kV AC bus of the Appalaches substation and associated 735 kV bus work |
|
(2) |
Network Upgrades (subject to change based on additional system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
Thermal upgrade of existing 735 kV lines 7005 and 7035 (68 miles from Lévis substation to Nicolet substation) |
|
ii. |
Thermal upgrade of existing 735 kV line 7049 (44 miles from Montérégie substation to Hertel substation) |
|
b. |
Substation Equipment: |
|
i. |
Add two 200 MVAr shunt capacitor banks at the Carignan substation |
|
ii. |
Add one 330 MVAr shunt reactor at the Carignan substation |
A-5
Critical Milestones
Item |
Critical Milestone* |
Due Date** |
1. |
Closing of Any Required Financing |
March 7, 2019 |
2. |
Receipt of all Owner Approvals (other than Municipal Owner Approvals) and AC Upgrade Approvals in Final Form |
December 14, 2019 |
3. |
Receipt of all Canadian Approvals |
March 11, 2021 |
4. |
Receipt of all Municipal Owner Approvals |
March 31, 2022 |
5. |
Execution of Contract with the Manufacturer of the Converter Station at the Southern End of the HVDC Line and associated minimum 5% contract value payment |
July 30, 2019 |
6. |
Execution of Contract for the Engineering, Procurement, or Construction of the Converter Station on the Québec Line |
July 30, 2019 |
7. |
Commercial Operation Date |
December 13, 2022 |
* As defined in Section 4.1(a)
** Subject to extension in accordance with the Agreement.
A-6
Attachment C
Owner Approvals
Set forth below are the Governmental Approvals and Third Party Consents, in each case, required to commence construction of and operate the NECEC Transmission Line:
|
1. |
ISO-NE: Approval pursuant to Section I.3.9 of the ISO-NE Tariff to interconnect and operate the NECEC Transmission Line at no fewer than 1,040 MW |
|
2. |
Maine Public Utilities Commission (MPUC): Certificate of Public Convenience and Necessity (CPCN) |
|
3. |
U.S. Department of Energy (DOE): Presidential Permit |
|
4. |
Maine Department of Environmental Protection (MDEP): |
|
a. |
Site Location of Development Act (SLODA) Permit |
|
b. |
Stormwater Management Permit |
|
c. |
Natural Resources Protection Act (NRPA) Permit |
|
d. |
Clean Water Act (CWA) Section 401 Water Quality Certification |
|
e. |
Maine Construction General Permit |
The SLODA Permit, Stormwater Management Permit, NRPA Permit, and CWA Section 401 Water Quality Certification may be combined into one permit.
|
5. |
Maine Land Use Planning Commission (LUPC): Certificate of Compliance |
|
6. |
Maine Department of Agriculture, Conservation and Forestry: |
|
a. |
Submerged Lands Lease |
|
b. |
Public Reserved Land Lease |
|
7. |
Maine Department of Transportation (DOT): |
|
a. |
Utility Location/Road Opening Permits |
|
b. |
Driveway/Entrance Permits |
|
8. |
U.S. Army Corps of Engineers: |
|
a. |
CWA Section 404 - Individual Permit |
|
b. |
Section 10 Rivers & Harbors Act of 1899 |
|
9. |
Federal Aviation Administration Infrastructure in Vicinity of Airports: Determination of No Hazard to Air Navigation |
|
10. |
Municipal Owner Approvals: |
A-7
|
i. |
Shoreland zoning permits |
|
ii. |
Building permits |
|
iii. |
Flood hazard development permits |
|
iv. |
Conditional use / rezoning approvals |
|
v. |
Site plan / subdivision approvals |
|
vi. |
Driveway / entrance permits |
|
vii. |
Street opening, blasting and demolition permits |
|
viii. |
Utility location permits |
|
b. |
Owner shall obtain the Municipal Owner Approvals listed above that are necessary (if any) in the following municipalities for the NECEC Transmission Line, subject to any necessary exemptions issued by the MPUC relating to any Municipal Owner Approvals that are denied in any such municipalities or relating to any conditions contained in any Municipal Owner Approvals that are unacceptable to Owner: |
A-8
Canadian Approvals
Set forth below are, to the best of HQUS’s knowledge, the Governmental Approvals and Third Party Consents, in each case, required to commence construction of the Québec Line:
|
• |
Permit from the National Energy Board to construct, operate, maintain or connect an international power line pursuant to the National Energy Board Act (R.S. C., 1985, c. N-7); |
|
• |
Permit from the International Boundary Commission required to cross the Canada-U.S. border pursuant to Article 5 of the International Boundary Commission Act; |
|
• |
Authorization from the Régie de l’énergie to acquire, construct or dispose of transmission assets pursuant to an Act respecting the Régie de l’énergie (R.S.Q., chapter R-6.01); |
|
• |
Expropriation Order in council, if required, to acquire by expropriation any immovable, servitude or construction required for the transmission of power pursuant to Hydro-Québec Act (R.S.Q., chapter H-5) and the Expropriation act (R.S.Q., chapter E-24); |
|
• |
Certificate of authorization issued by the Government of Québec to construct the transmission line under section 31.5 of the Environmental Quality Act subject to the environmental and social impact assessment and review procedure; |
|
• |
Certificate of authorization issued by the Ministère du Développement durable, de l’Environnement et de la Lutte contre les changements climatiques approving the plans and specifications of the transmission line pursuant to Section 22 of the Environmental Quality Act; |
|
• |
Authorization of the Commission de protection du territoire agricole du Québec , if required, approving the use of land situated in an agricultural zone for purposes other than agriculture under Sections 58 and 62 of the Act respecting the preservation of agricultural land and agricultural activities; |
|
• |
Opinion on project compliance with objectives of the city or regional county municipalities’ land-use and development plan. |
A-9
Owner’s Preliminary Project Schedule
A-10
A-11
Required Insurance
Owner shall obtain and maintain with qualified insurers authorized to issue insurance of the types described below in the State of Maine.
During construction of the NECEC Transmission Line Owner shall maintain or effect to be maintained the following insurance coverages:
|
• |
Primary and Excess Liability |
|
• |
Construction All Risk / Builders Risk |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
|
• |
Pollution / Environmental Liability |
After the Commercial Operation Date Owner shall provide coverage both in terms of scope and limits of coverage that are in accordance with Good Utility Practice and the long-standing practice of Owner. Operational coverage shall include the following insurance types:
|
• |
Excess Liability |
|
• |
Operational All Risk Property Damage |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
Note : At any time after the Commercial Operation Date Owner may choose, as far as it is consistent with Good Utility Practice, to self-insure on customary terms and conditions any coverage (or coverage part) where it meets any state or regulatory requirements of self-insurers.
A-12
Rate Adjustment Formula
In the event that a Transmission Service Payment is subject to reduction pursuant to Section 8.1 , such reduced payment shall equal the Transmission Service Payment that would otherwise be payable under the Agreement for a particular month multiplied by the lesser of 1 or the following fraction:
|
|
|
|||||
|
|
(Contract Capacity x 0.90) |
|||||
|
1 - |
minus (Contract Capacity x A) |
|||||
|
|
|
|
|
|
||
|
|
(Contract Capacity x 0.90) |
|||||
|
|
|
|||||
|
Where A = |
∑ Hourly Availability for all hours in such month |
|||||
|
|
|
|
|
|||
|
|
∑ Hours in such month |
For purposes of calculating A, Excused Outages (for which Owner is paid full Transmission Service Payments pursuant to the terms of the Agreement) will be regarded as hours in which one hundred percent (100%) of Contract Capacity was provided.
A-13
Refund Calculation
This example is intended to illustrate the methodology for the calculation of a subsequent refund of a late payment. This example and the numbers used in this example are purely illustrative and are in no way intended to supersede any part of the Agreement, including Section 13.3.
Assumptions
|
• |
Interest Rate = 12 percent per annum (compounded monthly) |
June 2023 Billing
Invoice Amount
|
$1,000 |
Date of Invoice |
June 1, 2023
|
Due Date |
June 15, 2023
|
Payment Date |
July 1, 2023
|
The total amount due on the date of payment is $1,005, which amount is computed by adding $1,000 (the original amount invoiced) and $5 (the ½ month late interest fee).
Subsequent Refund
If later, on July 1, 2024, the aforesaid payment is required to be refunded, the refund will equal the $1,000 payment made on July 1, 2023 (the original amount invoiced), plus the interest accrued on that $1,000 payment from the due date of June 15, 2023 to the date of refund on July 1, 2024. To ensure that the refund does not double recover interest, the following language has been included in Section 13.3 of the Agreement: “[I]f all or a portion of the amount [ here, the $1,000 payment due on June 15, 2023 ] to which such interest relates [ here, the $5 late interest fee ] is later refunded pursuant to this Agreement [ here, on July 1, 2024 ], then, in calculating that refund, such interest [ here, $5 ] shall not be included in the refund.”
A-14
A-15
A-16
Attachment J
Transmission Service Payment Calculation
The Transmission Service Payment for a given calendar month shall be equal to the unit price per kW-month for the then-current Contract Year (the “ Unit Price ”), as set forth in the table below, multiplied by the Contract Capacity expressed in kW.
In the event the anniversary of the Commercial Operation Date falls within the middle of a calendar month (month M), the Unit Price for each month M shall be equal to: the Unit Price for the Contract Year that is ending (Contract Year Y), multiplied by the proportion of the days of the calendar month M that are part of that Contract Year Y, plus the Unit Price for the Contract Year that is beginning (Contract Year Y+1), multiplied by the proportion of the days of the calendar month M that are part of that Contract Year Y+1, the resulting calculation being rounded to the nearest cent.
A-17
Examples . For all examples, assume the Commercial Operation Date is December 13, 2022, with December being month M.
|
• |
Example 1 . The Unit Price for the month of December 2022 is as follows: (($0 [no Transmission Service Payment prior to Contract Year 1] * 12/31 [proportion of days in December 2022 that are prior to Contract Year 1]) + ($9.16 [Unit Price for Contract Year 1] * 19/31 [proportion of days in December that are part of Contract Year 1])) = $5.61/kW-month. |
|
• |
Example 2 . The Unit Price for the month of December 2023 is as follows: (($9.16 [Unit Price for Contract Year 1] * 12/31 [proportion of days in December that are part of Contract Year 1]) + ($9.35 [Unit Price for Contract Year 2] * 19/31 [proportion of days in December that are part of Contract Year 2])) = $9.28/kW-month. |
|
• |
Example 3 . The Unit Price for the month of December 2041 is as follows: (($13.35 [Unit Price for Contract Year 20] * 12/31 [proportion of days in December that are part of Contract Year 20]) + ($0 [no Transmission Service Payment after Contract Year 20] * 19/31 [proportion of days in December that are after end of Contract Year 20])) = $5.17/kW-month. |
A-18
Exhibit 10.4
TRANSMISSION SERVICE AGREEMENT
by and between
CENTRAL MAINE POWER COMPANY,
as Owner,
and
FITCHBURG GAS AND ELECTRIC LIGHT COMPANY D/B/A UNITIL,
as Distribution Company
Dated: as of June 13, 2018
|
|
|
|
Page |
Article I DEFINITIONS AND RULES OF INTERPRETATION |
|
2 |
||
Section 1.1 |
|
Definitions |
|
2 |
Section 1.2 |
|
Interpretation |
|
15 |
|
|
|
|
|
Article II REGULATORY FILINGS AND REQUIRED APPROVALS |
|
16 |
||
Section 2.1 |
|
MDPU Filing; FERC Filing |
|
16 |
Section 2.2 |
|
Modifications to FERC Order |
|
16 |
Section 2.3 |
|
Modifications Pursuant to Unfavorable MDPU Order |
|
17 |
Section 2.4 |
|
Cooperation |
|
17 |
Section 2.5 |
|
No Inconsistent Action |
|
18 |
|
|
|
|
|
Article III EFFECTIVE DATE; TERM |
|
18 |
||
Section 3.1 |
|
Effective Date |
|
18 |
Section 3.2 |
|
Term |
|
18 |
Section 3.3 |
|
Termination Rights |
|
18 |
Section 3.4 |
|
Termination Payments |
|
20 |
Section 3.5 |
|
Effect of Termination |
|
21 |
|
|
|
|
|
Article IV COMMERCIAL OPERATION |
|
21 |
||
Section 4.1 |
|
Critical Milestones. |
|
21 |
Section 4.2 |
|
Commercial Operation Date |
|
23 |
Section 4.3 |
|
Conditions Precedent to Commercial Operation |
|
24 |
Section 4.4 |
|
Delay in Commercial Operation; Reduced Level of Operation |
|
25 |
|
|
|
|
|
Article V GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES |
|
27 |
||
Section 5.1 |
|
Responsibilities of the Parties |
|
27 |
Section 5.2 |
|
Schedules and Reports |
|
27 |
Section 5.3 |
|
Insurance and Events of Loss |
|
28 |
Section 5.4 |
|
Compliance with Laws |
|
29 |
Section 5.5 |
|
Third Party Contracts |
|
29 |
Section 5.6 |
|
Continuity of Rights and Responsibilities |
|
29 |
|
|
|
|
|
Article VI PROCEDURES FOR OPERATION AND MAINTENANCE OF THE NECEC TRANSMISSION LINE |
|
29 |
||
Section 6.1 |
|
Transmission Operating Agreement; ISO-NE Operational Control |
|
29 |
Section 6.2 |
|
Good Utility Practice; Regulatory and Reliability Requirements |
|
30 |
Section 6.3 |
|
Scheduled Maintenance |
|
30 |
|
|
|
|
|
Article VII DISTRIBUTION COMPANY’S TRANSMISSION RIGHTS OVER THE NECEC TRANSMISSION LINE |
|
31 |
||
Section 7.1 |
|
Transmission Service |
|
31 |
Section 7.2 |
|
Excused Outages or Reductions |
|
31 |
Section 7.3 |
|
Non-Excused Outages or Reductions |
|
32 |
i
|
Allocation of Outages |
|
33 |
|
Section 7.5 |
|
Metering |
|
33 |
Section 7.6 |
|
Line Availability Information and Reporting |
|
33 |
|
|
|
|
|
Article VIII PAYMENTS FOR TRANSMISSION SERVICE OVER THE NECEC TRANSMISSION LINE |
|
33 |
||
Section 8.1 |
|
Transmission Service Payments |
|
33 |
Section 8.2 |
|
Elective Upgrade Status; No Regional Rates |
|
34 |
|
|
|
|
|
Article IX RIGHTS UPON EXPIRATION OF TERM |
|
34 |
||
Section 9.1 |
|
Rollover and Other Rights |
|
34 |
|
|
|
|
|
Article X TRANSFER AND RESALE OF TRANSMISSION RIGHTS |
|
34 |
||
Section 10.1 |
|
Transfer of Transmission Rights |
|
34 |
Section 10.2 |
|
Resale Rights |
|
34 |
Section 10.3 |
|
Capacity Releases for Daily and Hourly Use |
|
35 |
Section 10.4 |
|
OASIS |
|
35 |
Section 10.5 |
|
Proceeds from Capacity Releases and Transmission Resales |
|
35 |
Section 10.6 |
|
Owner’s Rights and Obligations |
|
35 |
|
|
|
|
|
Article XI REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS |
|
36 |
||
Section 11.1 |
|
Real Power Losses |
|
36 |
Section 11.2 |
|
Other Rights |
|
36 |
|
|
|
|
|
Article XII [INTENTIONALLY OMITTED] |
|
37 |
||
|
|
|
|
|
Article XIII BILLING AND PAYMENTS |
|
37 |
||
Section 13.1 |
|
Invoices |
|
37 |
Section 13.2 |
|
Procedures for Billing Disputes |
|
37 |
Section 13.3 |
|
Interest |
|
37 |
Section 13.4 |
|
Obligation to Make Payments |
|
38 |
Section 13.5 |
|
Offsets |
|
38 |
|
|
|
|
|
Article XIV EVENTS OF DEFAULT AND REMEDIES |
|
38 |
||
Section 14.1 |
|
Distribution Company Defaults |
|
38 |
Section 14.2 |
|
Owner Defaults |
|
38 |
Section 14.3 |
|
Remedies Upon Distribution Company Default |
|
40 |
Section 14.4 |
|
Remedies Upon Owner Default |
|
41 |
Section 14.5 |
|
Abandoned Plant Recovery |
|
42 |
Section 14.6 |
|
Disputes |
|
43 |
Section 14.7 |
|
Limitations on Total Liability |
|
43 |
|
|
|
|
|
Article XV FORCE MAJEURE |
|
43 |
||
Section 15.1 |
|
Definition; Conditions |
|
43 |
|
|
|
|
|
Article XVI FINANCIAL ASSURANCES |
|
45 |
||
Section 16.1 |
|
Owner Security |
|
45 |
ii
|
|
|
|
|
Article XVII DISPUTE RESOLUTION |
|
46 |
||
Section 17.1 |
|
Consultation |
|
46 |
Section 17.2 |
|
Disputes to be Resolved by FERC |
|
46 |
Section 17.3 |
|
Consent to Jurisdiction |
|
47 |
Section 17.4 |
|
WAIVER OF JURY TRIAL |
|
47 |
|
|
|
|
|
Article XVIII LIMITATION OF REMEDIES |
|
47 |
||
|
|
|
|
|
Article XIX MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES. |
|
48 |
||
Section 19.1 |
|
Modifications |
|
48 |
Section 19.2 |
|
Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment |
|
48 |
|
|
|
|
|
Article XX INDEMNIFICATION |
|
49 |
||
Section 20.1 |
|
Owner Indemnity |
|
49 |
Section 20.2 |
|
[Intentionally Omitted] |
|
49 |
Section 20.3 |
|
Procedures |
|
50 |
Section 20.4 |
|
Defenses |
|
50 |
Section 20.5 |
|
Cooperation |
|
50 |
Section 20.6 |
|
Recovery |
|
51 |
Section 20.7 |
|
Subrogation |
|
51 |
|
|
|
|
|
Article XXI REPRESENTATIONS, WARRANTIES AND COVENANTS |
|
51 |
||
Section 21.1 |
|
Mutual Representations and Warranties |
|
51 |
Section 21.2 |
|
Additional Representations and Warranties of Owner |
|
52 |
Section 21.3 |
|
Additional Representations and Warranties of Distribution Company |
|
53 |
Section 21.4 |
|
NO OTHER REPRESENTATIONS OR WARRANTIES |
|
54 |
|
|
|
|
|
Article XXII TRANSFER OF INTERESTS |
|
54 |
||
Section 22.1 |
|
No Transfer of Interests |
|
54 |
Section 22.2 |
|
Exceptions |
|
55 |
Section 22.3 |
|
Collateral Assignment |
|
56 |
|
|
|
|
|
Article XXIII MISCELLANEOUS |
|
56 |
||
Section 23.1 |
|
Governing Law |
|
56 |
Section 23.2 |
|
Entire Agreement |
|
57 |
Section 23.3 |
|
Severability |
|
57 |
Section 23.4 |
|
Notices |
|
57 |
Section 23.5 |
|
Intentionally Omitted. |
|
58 |
Section 23.6 |
|
Waivers; Cumulative Remedies. |
|
58 |
Section 23.7 |
|
Confidential Information |
|
59 |
Section 23.8 |
|
No Third-Party Rights |
|
59 |
Section 23.9 |
|
Permitted Successors and Assigns |
|
60 |
Section 23.10 |
|
Relationship of the Parties |
|
60 |
Section 23.11 |
|
Construction |
|
60 |
iii
|
Counterparts |
|
60 |
|
Section 23.13 |
|
Survival |
|
60 |
Section 23.14 |
|
Headings and Table of Contents |
|
60 |
Section 23.15 |
|
Waiver of Immunities |
|
60 |
iv
Attachment A |
|
Description of Transmission Projects |
Attachment B |
|
Critical Milestones |
Attachment C |
|
Owner Approvals |
Attachment D |
|
Canadian Approvals |
Attachment E |
|
Owner’s Preliminary Project Schedule and Construction Schedule |
Attachment F |
|
Required Insurance |
Attachment G |
|
Rate Adjustment Formula |
Attachment H |
|
Refund Calculation |
Attachment I |
|
Real Estate Rights |
Attachment J |
|
Transmission Service Payment Calculation |
v
TRANSMISSION SERVICE AGREEMENT
This TRANSMISSION SERVICE AGREEMENT (this “ Agreement ”), dated as of June 13, 2018 (the “ Execution Date ”), is made and entered into by and between Central Maine Power Company, a corporation organized and existing under the laws of the State of Maine (“ Owner”) , and Fitchburg Gas and Electric Light Company (d/b/a Unitil), a corporation organized and existing under the laws of the Commonwealth of Massachusetts (“ Distribution Company ”). Owner and Distribution Company are hereinafter sometimes also referred to individually as a “ Party ” or collectively as the “ Parties .”
WITNESSETH
WHEREAS, pursuant to “An Act to Promote Energy Diversity” that was signed into law in the Commonwealth of Massachusetts on August 8, 2016 (the “ Energy Diversity Act ”), Fitchburg Gas and Electric Light Company (d/b/a Unitil), Massachusetts Electric Company (d/b/a National Grid), Nantucket Electric Company (d/b/a National Grid), and NSTAR Electric Company (d/b/a Eversource) (collectively, the “ RFP Sponsors ”) have solicited competitive proposals for clean energy generation for an annual amount of electricity equal to approximately 9.45 TWh;
WHEREAS, Owner and an Affiliate of H.Q. Energy Services (U.S.) Inc., a corporation organized and existing under the laws of the State of Delaware (“HQUS”), jointly submitted a proposal pursuant to such solicitation that includes up to 1,090 MW of clean energy generation obtained by HQUS from its affiliate Hydro-Québec Production (a division of Hydro-Québec (as defined below), “ HQP ” and such generation, the “ Hydro Generation ”);
WHEREAS, concurrently with the execution and delivery of this Agreement, HQUS has entered into a power purchase agreement (the “ PPA ”) with Distribution Company and additional power purchase agreements (the “ Additional PPAs ”) with the other RFP Sponsors with respect to an aggregate of 1,090 MW of Hydro Generation (and related renewable energy credits and environmental attributes);
WHEREAS, as part of the delivery of 1,090 MW of Hydro Generation for sale into the U.S. pursuant to the PPA and the Additional PPAs, Hydro-Québec TransÉnergie (“ TransÉnergie ”), a division of Hydro-Québec, intends to develop, construct, own and maintain a 1,200 MW +/-320 kV high-voltage direct current (“ HVDC ”) transmission line from the converter station at the Appalaches substation in Thetford Mines, Québec to the U.S. Border (as defined below) at Beattie Township, Maine (as further delineated in the diagram or described in Attachment A, the “ Québec Line ”);
WHEREAS, HQP has acquired from TransÉnergie firm transmission service over the Québec Line to permit the delivery of at least 1,200 MW of power into the U.S.;
WHEREAS, Owner intends to develop, construct, own and maintain a 1,200 MW +/-320 kV HVDC transmission line extending from the U.S. Border at Beattie Township, Maine to a new direct current to alternating current (“ AC ”) converter station to be located at Merrill Road in the City of Lewiston in the State of Maine (the transmission line and converter station, as more fully described in Attachment A, the “ HVDC Line ”);
1
WHEREAS, in order to interconnect the HVDC Line with the bulk power systems in New England, Owner intends to develop, construct, own and maintain additional 345 kV AC transmission lines, rebuilt 115 kV AC transmission lines and other substation equipment more fully described in Attachment A (together with the Merrill Road substation at its northern terminus and the associated equipment, as more fully described in Attachment A, the “ AC Line ” and, together with the HVDC Line, the “ NECEC Transmission Line ” );
WHEREAS, although Owner has performed studies believed to replicate those utilized by ISO-NE and does not believe that AC Upgrades (as defined below) or CCIS Capacity Upgrades (as defined below) will be required as a consequence of the construction and operation of the NECEC Transmission Line and the consummation of the transactions contemplated by this Agreement, this Agreement, the Additional TSAs (as defined below), the PPA or the Additional PPAs, ISO-NE (as defined below) may require certain AC Upgrades or CCIS Capacity Upgrades to be developed, constructed, owned and maintained by certain transmission owners other than Owner (which may include Affiliates of Owner) within their existing service territories in New England in order to interconnect the NECEC Transmission Line with the New England Transmission System (as defined below) in a safe and reliable manner, which AC Upgrades or CCIS Capacity Upgrades (if any) will be performed at Owner’s sole expense;
WHEREAS, concurrently with the execution and delivery of this Agreement, Owner has entered into (a) certain Additional TSAs with the other RFP Sponsors to sell an aggregate of 1077.683 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date (as defined below), (b) certain Additional TSAs with HQUS to sell an aggregate of 1,090 MW of firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date and (c) the Additional HQUS TSA (as defined below) with HQUS; and
WHEREAS, Owner desires to sell Firm Transmission Service (as defined below) to Distribution Company for the first twenty (20) years following the Commercial Operation Date, and Distribution Company desires to acquire such Firm Transmission Service from Owner, at the rates and on the terms and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the foregoing and the respective representations, warranties, covenants, agreements and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound hereby, the Parties hereby agree as follows:
Article I
DEFINITIONS AND RULES OF INTERPRETATION
Section 1.1 Definitions . As used herein, the following terms shall have the following respective meanings:
“ AC ” has the meaning provided in the recitals to this Agreement.
“ AC Line ” has the meaning provided in the recitals to this Agreement.
“ AC Upgrade Approvals ” means, collectively, any Governmental Approvals or Third Party Consents, in each case, that are required to commence construction of the AC Upgrades.
2
“ AC Upgrade Owners ” means, collectively, any Person responsible for constructing one or more AC Upgrades pursuant to a facilities agreement.
“ AC Upgrades ” means any additions, upgrades, reinforcements or other modifications to the New England Transmission System that ISO-NE determines, pursuant to Section I.3.9 of the ISO-NE Tariff, to be required, at a minimum, to interconnect the NECEC Transmission Line at the Delivery Point with the New England Transmission System.
“ Additional HQUS TSA ” means that certain Transmission Service Agreement between HQUS and Owner, dated as of the date hereof, pursuant to which HQUS has acquired transmission service for up to 110 MW of capacity for forty (40) years following the Commercial Operation Date.
“ Additional HQUS TSA Capacity ” means the firm capacity of the NECEC Transmission Line of up to 110 MW that HQUS has committed in the Additional HQUS TSA to purchase in the forty (40) years following the Commercial Operation Date.
“ Additional PPAs ” has the meaning provided in the recitals to this Agreement.
“ Additional TSA ” means (a) any transmission service agreement entered into between an RFP Sponsor and Owner (other than this Agreement), pursuant to which such RFP Sponsor acquires firm transmission service for the first twenty (20) years following the Commercial Operation Date, (b) any transmission service agreement entered into between HQUS and Owner (including the HQUS TSA), pursuant to which HQUS acquires firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date or (c) the Additional HQUS TSA.
“ Adverse Determination ” has the meaning provided in Section 19.2(c) .
“ Advisory Ruling ” has the meaning provided in Section 8.4 of the PPA.
“ Affiliate ” means, with respect to a specified Person, any other Person that directly or indirectly Controls, is Controlled by or is under common Control with the specified Person; provided , however , that, with respect to HQUS, a Person shall not be an “Affiliate” of HQUS unless such Person is Hydro-Québec (including, for the avoidance of doubt, a division of Hydro-Québec) or Controlled by Hydro-Québec.
“ Agreement ” has the meaning provided in the preamble to this Agreement.
“ Applicable Law ” means any duly promulgated federal, national, state, provincial or local law, regulation, rule, ordinance, code, decree, judgment, directive or judicial or administrative order, permit or other duly authorized and valid action of any Governmental Authority, including any binding interpretation of any of the foregoing by any Governmental Authority, which is applicable to a Person, its property or a transaction, and also including without limitation Section 83D of the Energy Diversity Act (“ Section 83D” ), the regulations promulgated under Section 83D, the Regulatory Approval and any other orders of the MDPU with respect to this Agreement.
“ Approval Deadline ” means December 14, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
3
“ Available Transfer Capability ” means the lesser of (a) 1,090 MW or (b) the Total Transfer Capability.
“ Bankruptcy Code ” means the United States Bankruptcy Code, 11 U.S.C. § 101 et seq.
“ Business Day ” means any day except Saturday, Sunday or any other day on which the Federal Reserve member banks are required or authorized to close for business.
“ Canadian Approvals ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the Québec Line in a manner consistent with Attachment A, all as set forth in Attachment D.
“ Canadian Approval Deadline ” means March 11, 2021 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Cash ” shall mean U.S. dollars held by or on behalf of a Party as Credit Support hereunder.
“ CCIS Capacity Upgrade ” means any upgrade determined by ISO-NE as necessary in order for the NECEC Transmission Line Capacity to satisfy the Capacity Capability Interconnection Standard under the ISO-NE Tariff.
“ COD Notice ” has the meaning provided in Section 4.2(c) .
“ Commercial Operation ” means the availability of the NECEC Transmission Line for the provision of Firm Transmission Service in accordance with this Agreement and the HQUS TSA.
“ Commercial Operation Date ” has the meaning provided in Section 4.2(c) .
“ Commissioning ” means (a) with respect to the NECEC Transmission Line, the start-up and testing activities required to demonstrate that the NECEC Transmission Line is ready for Commercial Operation and (b) with respect to the Québec Line, the start-up and testing activities required to demonstrate that the Québec Line is ready for commercial operation, consistent with Section 4.3(f) .
“ Concurrent Delay ” has the meaning provided in Section 4.4.2(a) .
“ Confidential Information ” means (a) this Agreement (including Attachments), (b) any documents, analyses, compilations, studies, or other materials prepared by or information received from a Party or its representatives that contain or reflect written or oral data or information that is privileged, confidential or proprietary and that is marked or otherwise clearly identified as “confidential” or “proprietary” or with words of like meaning, or (c) any subsequently prepared documents, analyses, compilations, studies or other materials or information that are derived from any of the documents, analyses, compilations, studies or other materials or information described in the foregoing clause (b). Without limiting the generality of the foregoing, all information provided to Distribution Company or Owner under Sections 2.4 , 5.2 and 6.3 hereof shall be deemed to be Confidential Information, whether or not such information is marked as “confidential” or “proprietary.”
“ Consent ” means, with respect to a Person, any approval, consent, permit, license, decree, certificate or other authorization of or from such Person.
4
“ Construction Authorizations ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the NECEC Transmission Line, other than the ISO-NE Approval, including the approvals of the Maine Department of Environmental Protection, the U.S. Army Corp of Engineers, the Maine Public Utilities Commission and the U.S. Department of Energy (the Presidential Permit), as more fully set forth in Attachment C.
“ Construction Contract ” means any contract entered into by Owner that provides for the engineering, procurement or construction of the NECEC Transmission Line.
“ Construction Phase ” means the period commencing upon the receipt of the FERC Authorization or such other date to which the Parties shall mutually agree in writing, and ending on the day immediately preceding the Commercial Operation Date or upon the earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Contract Capacity ” means the Proportionate Share multiplied by the NECEC Transmission Line Capacity.
“ Contract Year ” means each twelve-month period during the Term, with the first Contract Year commencing on the Commercial Operation Date and with each Contract Year after the first commencing on the anniversary of the Commerical Operation Date.
“ Control ” (including its correlative meanings “Controlled by” and “under common Control with”) means, with respect to a Person, the possession, directly or indirectly, of the power to direct or cause the direction of the management or policies of the specified Person, whether through ownership of voting securities or partnership or other ownership interests, by contract or Applicable Law or otherwise.
“ Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) , or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Credit Support ” means collateral in the form of (a) Cash or (b) a Letter of Credit issued by a Qualified Bank in a form reasonably satisfactory to the beneficiary.
“ Critical Energy Infrastructure Information ” means any information defined as Critical Energy Infrastructure Information by FERC pursuant to 18 C.F.R. § 388.113, and shall include all Critical Infrastructure Protection (CIP) standards (CIP-002 through CIP-009) established by NERC.
“ Critical Milestone ” has the meaning provided in Section 4.1(a) .
“ Delivery Point ” means the southern terminus of the NECEC Transmission Line at the Larrabee Road substation in Lewiston, Maine, as illustrated in Attachment A.
“ Design Capability ” means the maximum amount of electric power that the materials, equipment and structures comprising the HVDC Transmission Project will be designed to transfer bi-directionally in a safe and reliable manner, which amount shall be sufficient to permit the north-to-south delivery of all amounts scheduled for delivery in an aggregate amount of at least 1,090 MW, but not to exceed 1,200 MW, of electrical energy at the Delivery Point.
5
“ Discount Rate ” means the prime rate specified in the “Money and Investing” section of the Wall Street Journal, determined as of the date of notice of default, plus 300 basis points.
“ Dispute ” means any dispute, controversy or claim of any kind whatsoever arising out of or relating to a Proposal Agreement, including relating to the interpretation of the terms thereof or any Applicable Law that affects such Proposal Agreement, or the transactions contemplated thereunder, or the breach, termination or validity thereof.
“ Distribution Company ” has the meaning provided in the preamble to this Agreement.
“ Distribution Company Default ” has the meaning provided in Section 14.1 .
“ Distribution Company Indemnified Party ” has the meaning provided in Section 20.1 .
“ Distribution Company Termination Payment ” means, if Distribution Company is the defaulting Party, (a) prior to the Commercial Operation Date, an amount equal to the Proportionate Share of all costs prudently incurred by Owner as of the termination date in connection with the development and construction of the NECEC Transmission Line, or (b) on or after the Commercial Operation Date, an amount equal to the Proportionate Share multiplied by the Net Book Value of the NECEC Transmission Line. In either of these cases the Distribution Company Termination Payment will be reduced by the present value, discounted at the Discount Rate, of the Proportionate Share of the revenues (after taxes), if any; (i) received or to be received by Owner from HQUS as successor to Distribution Company under this Agreement pursuant to Sections 8.2 and 14.8 of the HQUS TSA, and (ii) to be received by Owner from long term transmission services provided to other third parties on the NECEC Transmission Line during the remaining Term of the Agreement. For the purpose of these calculations, the revenues will be reduced by the operating costs incurred, or projected by Owner in good faith to be incurred, to provide the corresponding services and by the costs and losses incurred or experienced by Owner as a consequence of the Distribution Company’s default. The reductions determined in accordance with clauses (i) and (ii) above will be limited to the amounts determined in accordance with clauses (a) and (b) above, and the reduction described in clause (ii) above will be determined considering only 90% of the revenues to be received. For purposes of calculating the Distribution Company Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW .
“ Effective Date ” has the meaning provided in Section 3.1 .
“ Excused Outages ” has the meaning provided in Section 7.2(a) .
“ Execution Date ” has the meaning provided in the preamble to this Agreement.
“ Federal Power Act ” means the United States Federal Power Act of 1935, as amended, 16 U.S.C. § 791a et seq.
“ FERC ” means the Federal Energy Regulatory Commission, or any successor regulatory agency that administers the Federal Power Act.
“ FERC Amendment ” has the meaning provided in Section 2.2(b) .
6
“ FERC Authorization ” means, collectively, any FERC order which is not subject to rehearing or appeal authorizing Owner to provide Firm Transmission Service, including the FERC Order and any authorization from FERC with respect to the Transmission Operating Agreement or Interconnection Agreements.
“ FERC Order ” has the meaning provided in Section 2.2(a) .
“ Financial Transmission Rights ” means Financial Transmission Rights, as defined in the ISO-NE Tariff.
“ Financing Deadline ” means March 7, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing.
“ Firm Transmission Service ” has the meaning provided in Section 7.1.1.
“ Force Majeure ” has the meaning provided in Section 15.1(a) .
“ Good Utility Practice ” means those design, construction, operation, maintenance, repair, removal and disposal practices, methods and acts that are engaged in by a significant portion of the electric transmission industry in the United States during the relevant time period, or any other practices, methods or acts that, in the exercise of reasonable judgment in light of the facts known at the time a decision is made, could have been expected to accomplish a desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Good Utility Practice is not intended to be the optimum practice, method or act to the exclusion of others but rather to be a spectrum of acceptable practices, methods or acts generally accepted in such electric transmission industry for the design, construction, operation, maintenance, repair, removal and disposal of electric transmission facilities in the United States. Good Utility Practice shall not be determined after the fact in light of the results achieved by the practices, methods, or acts undertaken, but rather shall be determined based upon the consistency of (a) the practices, methods, or acts when undertaken with (b) the standard set forth in the first two (2) sentences of this definition at such time.
“ Governmental Approval ” means (a) any authorization, consent, approval, license, lease, ruling, permit, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with or (d) any registration by or with, any Governmental Authority, including any FERC Authorization.
“ Governmental Authority ” means any government or agency or other political subdivision thereof, including any province, state or municipality, or any other governmental, quasi-governmental, judicial, executive, legislative, administrative, regulatory, public or statutory instrumentality, authority, body, agency, commission, department, board, bureau or entity exercising judicial, executive, legislative, administrative or regulatory functions, any court or arbitrator with authority to bind a party at law, and shall include, to the extent exercising powers delegated by any Governmental Authority acting under Applicable Law, NERC and ISO-NE.
“ Hourly Availability ” means, with respect to any hour, the availability of the NECEC Transmission Line for the purposes of this Agreement, which shall equal (a) the Proportionate Share of the Available Transfer Capability for such hour, divided by (b) the Contract Capacity, expressed as a percentage; provided, however, that, for any hour, such availability of the NECEC Transmission Line shall not exceed one hundred percent (100%).
7
“ HQP ” has the meaning provided in the recitals to this Agreement.
“ HQUS ” has the meaning provided in the recitals to this Agreement.
“ HQUS Delay ” means delays in completing the Québec Line, whether due to operational difficulties or any other event that is not an event of Force Majeure.
“ HQUS TSA ” means that certain Transmission Service Agreement between HQUS and Owner, dated as of the date hereof, pursuant to which HQUS has acquired 12.317 MW of firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date.
“ HVDC ” has the meaning provided in the recitals to this Agreement.
“ HVDC Line ” has the meaning provided in the recitals to this Agreement.
“ HVDC Transmission Project ” means, collectively, (a) the Québec Line and (b) the NECEC Transmission Line.
“ Hydro Generation ” has the meaning provided in the recitals to this Agreement.
“ Hydro-Québec ” means Hydro-Québec, a body politic and corporate, duly incorporated and regulated by the Hydro-Québec Act (R.S.Q., Chapter H-5). As of the Execution Date, Hydro-Québec has four divisions: HQP, TransÉnergie, Hydro-Québec Distribution and Hydro-Québec Équipment.
“ Immunities Act ” means the United States Foreign Sovereign Immunities Act of 1976, 28 U.S.C. § 1602 et seq.
“ Indemnification Notice ” has the meaning provided in Section 20.3 .
“ Indemnified Party ” has the meaning provided in Section 20.3 .
“ Insolvency Event ” means, with respect to a Person, such Person (a) becomes “insolvent,” as defined in the Bankruptcy Code, or otherwise becomes bankrupt or insolvent under any Insolvency Laws, (b) has a liquidator, administrator, receiver, custodian, trustee, conservator or similar official appointed with respect to such Person or any material portion of such Person’s assets or such Person consents to such appointment, or a foreclosure action is instituted with respect to any material portion of such Person’s assets and is not dismissed within thirty (30) days of commencement thereof, (c) files a voluntary petition or otherwise authorizes or commences a proceeding or cause of action under the Bankruptcy Code or Insolvency Laws, (d) has an involuntary petition filed against it or acquiesces in the commencement of a proceeding or cause of action as the subject debtor under the Bankruptcy Code or Insolvency Laws, which petition is not dismissed within thirty (30) days after the filing thereof or results in the issuance of an order for relief against such Person, (e) makes or consents to an assignment of its assets in whole or in part, for the benefit of creditors or any general arrangement for the benefit of creditors, or a common law composition of creditors or (f) generally is unable to pay its debts as they fall due, or admits in writing to such inability.
“ Insolvency Laws ” means any bankruptcy, insolvency, reorganization or similar laws of the U.S. or other Governmental Authority, as applicable, other than the Bankruptcy Code.
8
“ Interconnection Agreements ” means, collectively, (a) an agreement by and among Owner, TransÉnergie and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the U.S. Border of the NECEC Transmission Line with the Québec Line and (b) an agreement by and between Owner and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the Delivery Point of the NECEC Transmission Line with certain transmission facilities operated by ISO-NE. The Interconnection Agreements shall address cost responsibilities among entities other than the Distribution Company and the other RFP Sponsors and shall include provisions, both technical and otherwise, for safe and reliable interconnected operations of the HVDC Transmission Project following Commercial Operation (including use of the HVDC Transmission Project for the delivery of electric power in emergency circumstances).
“ Interested Party ” shall mean, collectively, the Parties and, if and as applicable, HQUS and the other RFP Sponsors.
“ Invoice ” means, with respect to a calendar month, an invoice that sets forth the amounts owed to the applicable Party with respect to such month in reasonable detail to evidence the basis for individual billings and charges.
“ ISO-NE ” means ISO New England Inc., or its successor organization.
“ ISO-NE Approval ” means approval by ISO-NE to operate the NECEC Transmission Line up to 1,200 MW.
“ ISO-NE Definitions Manual ” means the ISO New England Manual for Definitions and Abbreviations, Manual M-35, as in effect from time to time.
“ ISO-NE Rules ” means the ISO-NE Tariff and all ISO-NE manuals, rules, procedures, agreements or other documents relating to the reliable operation of the electric system in New England and the purchase and sale of electrical energy, electrical capacity and ancillary services, as such govern market participants with respect thereto in the operating jurisdiction of ISO-NE, as in effect from time to time, including the ISO-NE Definitions Manual; provided that such documents are publicly accessible.
“ ISO-NE Tariff ” means the ISO New England Inc. Transmission, Markets and Services Tariff, FERC Electric Tariff No. 3, as in effect from time to time, on file with FERC, or its successor tariff.
“ kV ” means kilovolt.
“ K W ” means kilowatt.
“ Letter of Credit ” shall mean an irrevocable, non-transferable standby letter of credit issued by a Qualified Bank utilizing a form acceptable to the Party in whose favor such letter of credit is issued. All costs relating to any Letter of Credit shall be for the account of the Party providing that Letter of Credit.
9
“ Maintenance Plan ” means an annual plan for the management, operation and ordinary maintenance of the NECEC Transmission Line, which plan shall include a description of the scope and nature of the planned operating and maintenance programs and planned and preventive maintenance procedures for the NECEC Transmission Line, and the scheduled maintenance and other planned outages of the NECEC Transmission Line, in each case, in accordance with Section 6.3 hereof and the requirements of the PPA.
“ Market Products ” means, collectively, all products (however entitled and whether existing now or in the future) that (a) are recognized under ISO-NE Rules, (b) derive from the acquisition of transmission service over the NECEC Transmission Line under this Agreement and (c) can be sold for consideration or otherwise have economic value, including electrical energy, electrical capacity and ancillary services, including reserve products (including spinning and non-spinning reserves).
“ Material Adverse Effect ” means, with respect to a Party, a material adverse effect on the ability of such Party to perform any of its obligations under this Agreement.
“ MDPU ” means the Massachusetts Department of Public Utilities.
“ Minimum Average Availability ” means ninety percent (90%) of the Contract Capacity, provided that, during the Remediation Period, if applicable, for every ten (10) MW that the maximum operating capacity is below 1090 MW, the Minimum Average Availability shall be increased by one percent (1%), and provided further that if, at the earlier of the Remediation Date or the end of the Remediation Period, the operating capacity is below 1,090 MW, the Minimum Average Availability shall be increased by one-half of one percent (0.5%) for each 5 MW by which the operating capacity is below 1,090 MW.
“ Municipal Owner Approvals ” means the Owner Approvals identified in paragraph 10 of Attachment C that Owner reasonably determines are necessary to construct, own, and operate the NECEC Transmission Line.
“ Municipal Owner Approval Deadline ” means March 31, 2022 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ MW ” means megawatt.
“ MWh ” means megawatt-hour.
“ NECEC Facilities ” has the meaning provided in Section 8.2 .
“ NECEC Transmission Line ” has the meaning provided in the recitals to this Agreement.
“ NECEC Transmission Line Capacity ” means (a) 1,090 MW or (b) such lesser amount as may be established by the Commissioning of the NECEC Transmission Line, in each case, as measured at the Delivery Point; provided that the amount under clause (b) shall be increased if the capacity is increased after the Commercial Operation Date pursuant to Section 4.4.1(c).
“ NERC ” means the North American Electric Reliability Corporation, or its successor organization.
10
“ Net Book Value ” means, at any time, an amount equal to the original cost of construction minus depreciation (using a forty (40)-year depreciation schedule), as calculated in accordance with generally accepted accounting principles.
“ New England Transmission System ” means New England Transmission System, as defined in the ISO-NE Tariff.
“ Non-Excused Outage ” means any outage of the NECEC Transmission Line or reduction in the Total Transfer Capability below the NECEC Transmission Line Capacity, except due to an Excused Outage.
“ OASIS ” means the Open Access Same-Time Information System.
“ OASIS Administrator ” has the meaning provided in Section 10.4(a) .
“ Operation Phase ” means the period commencing on the Commercial Operation Date and ending upon the expiration of the Term or earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Other Transmission Rights ” means, collectively, any Financial Transmission Rights (or any similar concept), auction revenue rights or other financial or physical transmission rights, in each case, whether existing now or in the future, associated with the NECEC Transmission Line or AC Upgrades.
“ Owner ” has the meaning provided in the preamble to this Agreement.
“ Owner Approvals ” means, collectively, (a) the Construction Authorizations and (b) the ISO-NE Approval, all as set forth in Attachment C.
“ Owner Default ” has the meaning provided in Section 14.2 .
“ Owner Delay ” has the meaning provided in Section 4.4.1 .
“ Owner Security ” has the meaning provided in Section 16.1 .
“ Owner Termination Payment ” means, if Owner is the defaulting Party (a) prior to the Commercial Operation Date, an amount equal to the Owner Security together with any Credit Support held by Distribution Company pursuant to Section 4.1(c) , and (b) on or after the Commercial Operation Date (i) in the event that HQUS timely exercises its right to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under the Agreement pursuant to Section 14.7 of the HQUS TSA, the amount of any damages (including for the avoidance of doubt any lost profit) incurred by Distribution Company as a result of the Owner Default and (ii) otherwise an amount, if positive, calculated according to the following formula: (x) the present value, discounted at the Discount Rate, for each month remaining in the Services Term (as defined in the PPA), of ( A ) the amount, if, any, by which the forward market price of Energy and Environmental Attributes (both as defined in the PPA), as determined by the average of the quotes of at least two nationally recognized energy consulting firms or brokers chosen by Distribution Company, for Replacement Energy and Replacement Environmental Attributes, (both as defined in the PPA) exceeds the applicable Price (as defined in the PPA) that would have been
11
paid pursuant to Exhibit D of the PPA, multiplied by (B) the amount of Guaranteed Qualified Clean Energy (as defined in the PPA) as provided in Exhibit B of the PPA; provided that, if Distribution Company receives a Termination Payment (as defined in the PPA) pursuant to Section 9.3 of the PPA, (other than any such Termination Payment received pursuant to Section 9.3(b)(iii) of the PPA), the Owner Termination Payment shall equal zero.
“ Owner’s Construction Progress Report ” has the meaning provided in Section 5.2.3(a) .
“ Owner’s Construction Schedule ” has the meaning provided in Section 5.2.2 .
“ Owner’s Preliminary Schedule ” has the meaning provided in Section 5.2.1 .
“ Parties ” and “ Party ” have the meanings provided in the preamble to this Agreement.
“ Person ” means any legal person, including any natural person, domestic or foreign corporation, limited liability company, general or limited partnership, joint venture, association, joint stock company, business trust, estate, trust, enterprise, unincorporated organization, any Governmental Authority, or any other legal or commercial entity.
“ Physical Transmission Line Capacity ” means the sum of the NECEC Transmission Line Capacity and the Additional HQUS TSA Capacity.
“ Power Cost Reconciliation Tariff ” shall mean a fully reconciling cost recovery tariff mechanism that authorizes the establishment of a distribution charge that fully recovers Distribution Company’s net costs under this Agreement (including annual remuneration of up to two and three-quarters percent (2.75%)). The rate reconciliation shall be designed in such a way as to limit the build-up of any under or over-recoveries over the course of the year. A reconciliation shall occur at least annually, but may also be reconciled quarterly or monthly, to the extent necessary to eliminate regulatory lag for the recovery of costs or crediting of over-recoveries to customers.
“ PPA ” has the meaning provided in the recitals to this Agreement.
“ PPA Contract Maximum Amount ” means 12.317 MW, as such amount may be adjusted in accordance with the terms of the PPA.
“ Presidential Permit ” means the permit granted by the U.S. Department of Energy, pursuant to Executive Order 10485 as amended by Executive Order 12038, authorizing the construction, operation, maintenance and connection of facilities for the transmission of electric energy at the international border between the United States and Canada.
“ Project Schedule ” means a schedule setting forth the proposed engineering, procurement, construction and testing milestone schedule for (a) the NECEC Transmission Line based upon the Construction Contracts, (b) the Québec Line and (c) the AC Upgrades and the CCIS Capacity Upgrades based upon such information as can reasonably be obtained by Owner from the AC Upgrade Owners, recognizing that one or more Project Schedules will be completed and delivered before the date on which the AC Upgrades and the CCIS Capacity Upgrades are formally identified under this Agreement.
12
“ Proportionate Share ” means a fraction with the numerator equal to 12.317 MW and the denominator equal to 1,090 MW.
“ Proposal Agreements ” means, collectively, this Agreement, the Additional TSAs, the PPA and the Additional PPAs.
“ Purchased Power Accounting Authorization ” shall mean authorization for Distribution Company, at Distribution Company’s sole discretion, to take appropriate steps to assure avoidance of a material, negative balance sheet impact on Distribution Company or Distribution Company’s direct or indirect parent company, upon appropriate filing with and approval by the MDPU.
“ Qualified Bank ” means a U.S. commercial bank (or the U.S. branch of a foreign bank) having (a) assets on its most recent balance sheet of at least $10 billion and (b) a long-term credit rating of at least “A-” by S&P or “A3” by Moody’s (or its equivalent).
“ Québec Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Québec Line ” has the meaning provided in the recitals to this Agreement.
“ Real Power Losses ” means energy consumed by the electrical impedance characteristics of the NECEC Transmission Line.
“ Recovery ” has the meaning provided in Section 20.6 .
“ Regulatory Approval ” shall mean the MDPU approval of this entire Agreement, which approval shall include without limitation: (1) confirmation that this Agreement has been approved under Section 83D and the regulations promulgated thereunder and that all of the terms of such Section 83D and such regulations apply to this Agreement; (2) definitive regulatory authorization for Distribution Company to recover all of its costs incurred under and in connection with this Agreement for the entire term of this Agreement through the implementation of a Power Cost Reconciliation Tariff and/or other cost recovery or reconciliation mechanisms; (3) definitive regulatory authorization for Distribution Company to recover remuneration of up to two and three-quarters percent (2.75%) of Distribution Company’s annual payments under this Agreement for the term of this Agreement through the Power Cost Reconciliation Tariff; and (4) approval of any Purchased Power Accounting Authorization requested by Distribution Company in connection with the Regulatory Approval. Such approvals shall be acceptable in form and substance to Distribution Company in its sole discretion, shall not include any conditions or modifications that Distribution Company deems, in its sole discretion, to be unacceptable, and shall be final and not subject to appeal or rehearing.
“ Regulatory Approval Delay ” means any delay in the receipt of the Regulatory Approval beyond January 25, 2019.
“ Regulatory Approval Termination Outside Date ” has the meaning provided in Section 3.3.1(a) .
“ Remediation Date ” has the meaning provided in Section 4.4.1(b)(i) .
“ Remediation Period ” has the meaning provided in Section 4.4.1(b)(i) .
13
“ RFP Sponsors ” has the meaning provided in the recitals to this Agreement.
“ Scheduling Rules ” has the meaning provided in Section 7.1.3 .
“ State Amendment ” has the meaning provided in Section 2.3 .
“ Target Date ” has the meaning provided in Section 4.2(a) .
“ Term ” has the meaning provided in Section 3.2 .
“ Termination Payment ” means, as the context requires, the Distribution Company Termination Payment or the Owner Termination Payment.
“ Third Party Claim ” has the meaning provided in Section 20.3 .
“ Third Party Consent ” means any Consent of a Person other than a Governmental Authority.
“ Total Transfer Capability ” means the total transfer capability of the NECEC Transmission Line, as defined in, and established in accordance with, the ISO-NE Tariff and determined by ISO-NE for each hour.
“ TransÉnergie ” has the meaning provided in the recitals to this Agreement.
“ TransÉnergie OATT ” means the Hydro-Québec Open Access Transmission Tariff, as amended or accepted by the Régie de l’énergie from time to time.
“ Transfer ” has the meaning provided in Section 22.1(a) .
“ Transmission Operating Agreement ” means an agreement entered into by and between Owner and ISO-NE for transmission operating services over the NECEC Transmission Line under which operating control (as defined in such agreement) of the NECEC Transmission Line is transferred from Owner to ISO-NE.
“ Transmission Operator ” means ISO-NE acting in its capacity pursuant to the Transmission Operating Agreement.
“ Transmission Service Payment ” has the meaning provided in Section 8.1 .
“ Unfavorable FERC Decision ” has the meaning provided in Section 2.2(a) .
“ United States ” or “ U.S. ” means the United States of America.
“ U.S. Border ” means the location on or near the international border between the State of Maine and the Province of Québec where the HVDC Line and the Québec Line interconnect.
14
Section 1.2 Interpretation . In this Agreement, unless the context otherwise requires, the following rules shall apply to the usage of terms:
Section 1.2.1 Singular; Plural; Gender; Corollary Meaning . The singular shall include the plural and vice versa, and any pronoun shall include the corresponding masculine, feminine and neuter forms. If a term is defined as one part of speech (such as a noun), then it shall have a corresponding meaning when used as another part of speech (such as a verb).
Section 1.2.2 Coordinating Conjunctions . The word “or” shall have the inclusive meaning represented by the phrase “and/or.”
Section 1.2.3 Self-Reference . The words “hereof,” “herein,” “hereto” and “hereunder” and words of similar import when used in this Agreement shall, unless otherwise expressly specified, refer to this Agreement as a whole and not to any particular provision of this Agreement.
Section 1.2.4 Inclusive References . The words “include,” “includes” and “including” when used in this Agreement shall be deemed to be followed by “without limitation” or “but not limited to,” whether or not they are in fact followed by such words or words of like import.
Section 1.2.5 Incorporation by Reference . Any reference in this Agreement to an “Article,” “Section” or other subdivision or to an “Attachment” or other schedule or attachment shall be references to an article, section or other subdivision of, or to a schedule or attachment to, this Agreement, unless otherwise stated, and all such Articles, Sections and Attachments are incorporated into this Agreement by reference (all of which comprise part of one and the same agreement with equal force and effect). In the event of any conflict or other inconsistency between the main body of this Agreement and any attachment or schedule to this Agreement, the provisions of the main body of this Agreement shall prevail.
Section 1.2.6 Subsequent Acts . Any references in this Agreement to any statute shall be deemed to refer to such statute, as amended or replaced from time to time, including by succession of comparable successor statute, and all rules and regulations promulgated thereunder. In the event any index or publication referenced in this Agreement ceases to be published or a concept defined by reference to any such index or publication ceases to exist, each such reference shall be deemed to be a reference to a successor or alternate index, publication or concept reasonably agreed to by the Parties. Unless specified otherwise, a reference to a given agreement or instrument, and all schedules and attachments thereto, shall be a reference to that agreement or instrument as modified, amended, supplemented and restated, and as in effect from time to time.
Section 1.2.7 Inclusive of Permitted Successors . Unless otherwise expressly stated, references to any Person also include its permitted successors and assigns.
Section 1.2.8 Time Computation . In this Agreement, in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each means “to but excluding.”
Section 1.2.9 Business Days . Whenever this Agreement refers to a number of days, such number shall refer to calendar days unless Business Days are specified. Whenever any action must be taken under this Agreement on or by a day that is not a Business Day, such action may be validly taken on or by the next day that is a Business Day, and in the case of
15
payments (including refunds of payments), no interest shall accrue on the amount due; provided that such payment is made in full on the next day that is a Business Day.
Section 1.2.10 Governmental Approvals . Except as otherwise expressly provided in this Agreement, any Governmental Approval shall be deemed to be received upon issuance, even if such Governmental Approval is subject to appeal or rehearing.
Section 1.2.11 Currency . All references to prices, values or monetary amounts referred to in this Agreement shall be paid in United States currency, unless expressly provided otherwise.
Article II
REGULATORY FILINGS AND REQUIRED APPROVALS
Section 2.1 MDPU Filing; FERC Filing .
(a) Distribution Company shall file for the Regulatory Approval as soon as practicable following the execution of this Agreement, and in any event shall use commercially reasonable efforts to file within sixty (60) days thereafter.
(b) Owner shall file this Agreement with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing with FERC shall include waiver requests for the Effective Date to occur consistent with Section 3.1 , which Effective Date may be more than one hundred twenty (120) days before the Commercial Operation Date.
(c) The Parties shall respond promptly to any requests for additional information made by FERC or the MDPU in connection with such filings.
(d) Upon the filing of this Agreement pursuant to Section 2.1(a) or 2.1(b) , Owner or Distribution Company shall support the approval or acceptance of this Agreement by the MDPU and FERC without modification or condition.
Section 2.2 Modifications to FERC Order .
(a) In the event (i) FERC issues an order accepting or approving this Agreement for filing (the “ FERC Order ”) and (ii) the FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to a Party, in its sole discretion (an “ Unfavorable FERC Decision ”), such Party shall deliver a written notice to the other Party specifying the issues, to the extent it is able, set for hearing or the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following the issuance of the Unfavorable FERC Decision.
(b) In the event of an Unfavorable FERC Decision, the Parties may agree upon amendments to this Agreement (each, a “ FERC Amendment ”) that achieve, as nearly as practicable, the commercial intent of this Agreement as of the Execution Date in a manner consistent with the Unfavorable FERC Decision. Any such amendment shall be subject to applicable regulatory approvals. As soon as practicable after any FERC Amendment(s) have been executed and delivered by the Parties, Owner shall file such FERC Amendment(s) with FERC.
16
(c) In the event of an Unfavorable FERC Decision, each Party shall retain the right to request a rehearing or reconsideration of the FERC Order regardless of any negotiations that have occurred or are occurring pursuant to clause (b) above; provided, however, that, in the event the Parties execute a FERC Amendment after any one or both of the Parties has filed for rehearing or reconsideration, any such rehearing or reconsideration request shall be withdrawn no later than five (5) Business Days after FERC issues an order accepting or approving the FERC Amendment for filing, if such rehearing or reconsideration request is inconsistent with the terms and conditions of this Agreement, as amended. Unless otherwise agreed in writing by the Parties, a filing by any Party of a request for rehearing or reconsideration of the FERC Order shall not toll or otherwise modify any date or time period set forth in this Agreement, including, for the avoidance of doubt, the date upon which the Construction Phase shall commence.
Section 2.3 Modifications Pursuant to Unfavorable MDPU Order . In the event the Regulatory Approval contains modifications or conditions that are unacceptable to a Party, in the Party’s sole discretion (an “ Unfavorable MDPU Order ”), such Party shall deliver a written notice to the other Party of such Unfavorable MDPU Order specifying the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following such Unfavorable MDPU Order, and the Parties may agree to amend this Agreement to address such modifications or conditions (any of the foregoing amendments, a “ State Amendment ”). Any such amendment shall be subject to applicable regulatory approvals, and as soon as practicable after any State Amendment has been executed, Distribution Company or Owner (as applicable) shall file such State Amendment with the MDPU and FERC.
(a) In addition to their obligations under Section 2.1 , each Party shall (i) cooperate with each other to prepare, file and effect any applications, notices, petitions, reports or other filings or documentation required under Applicable Law or otherwise necessary, proper or advisable to consummate the transactions contemplated by this Agreement, (ii) provide updates to the other Party on material developments in connection with any such filings or documentation, (iii) provide any non-privileged information reasonably requested by the other Party in connection with any such filings or documentation, and (iv) cooperate with the other Party to use commercially reasonable efforts to obtain all Governmental Approvals and Third Party Consents that are necessary, proper or advisable to consummate the transactions contemplated by this Agreement, including the FERC Authorization (without unacceptable modifications or conditions, except as permitted by this Agreement), the other Owner Approvals, the Municipal Owner Approvals, the Canadian Approvals, and the Regulatory Approval (without unacceptable modifications or conditions, except as permitted by this Agreement). Owner shall provide any support reasonably necessary and requested by the AC Upgrade Owners to obtain the AC Upgrade Approvals.
(b) Each Party shall consult with the other Party with respect to all characterizations of information relating to such other Party or the transactions contemplated by this Agreement that are proposed to appear in any filings or documentation contemplated by Section 2.1 or Section 2.4(a) . Each Party shall promptly provide comments, if any, to the other Party on any such characterizations of information. Each Party shall make a good faith effort to take into account any comments made by the other Party.
17
Section 2.5 No Inconsistent Action . Except as provided in Section 17.2 and Article XIX , from and after the Execution Date, no Party shall undertake any action before FERC, ISO-NE, the MDPU or any other Governmental Authority that is contrary to the Party’s obligations under this Agreement, including, for the avoidance of doubt, Section 2.1(c) and Section 7.1.4 , or support any such contrary action by any Affiliate.
Article III
Section 3.1 Effective Date . Article I , Article II , this Section 3.1 , Section 3.3.1 , Section 3.3.2 , Article XVII , Article XVIII , Article XIX , Article XXII , and Article XXIII shall become effective and enforceable to the extent permitted by Applicable Law upon the Execution Date. The remaining provisions of this Agreement shall become effective and enforceable to the extent permitted by Applicable Law upon receipt of the Regulatory Approval (the “ Effective Date ”). Notwithstanding the first sentence of this Section 3.1 , this Agreement will become effective as a FERC rate schedule upon the effective date set forth in the FERC Order. Notwithstanding Section 14.5 and any other provision of this Agreement, Distribution Company shall have no obligation to make any payment under this Agreement prior to receipt of the Regulatory Approval and the FERC Authorizations.
Section 3.2 Term . The term of this Agreement shall commence on the Execution Date and shall expire on the twentieth (20 th ) anniversary of the Commercial Operation Date, unless earlier terminated (in whole or in part) or extended in accordance with the terms hereof (the “ Term ”).
Section 3.3 Termination Rights . This Agreement may be terminated in accordance with the ensuing provisions in this Article III , subject to any required regulatory reviews, approvals or acceptances, as applicable. Neither Party shall oppose any termination of this Agreement made in accordance with this Article III before FERC or any other Governmental Authority; provided, however, that the foregoing shall not prohibit any Party from challenging or otherwise Disputing whether or not any such termination is permitted by this Agreement.
Section 3.3.1 Failure to Obtain Regulatory Approval and FERC Authorizations .
(a) This Agreement may be terminated by any Party in the event (i) it determines that the Regulatory Approval or the FERC Authorizations contain terms and conditions that are, in its sole discretion, unacceptable to such Party, (ii) the Regulatory Approval is denied or is not received by January 25, 2020 (such date, the “ Regulatory Approval Termination Outside Date ”), (iii) the Regulatory Approval of the PPA (as defined in the PPA) is not received within the time frame set forth therein and the PPA is terminated, (iv) the FERC Authorization is denied or is not received by January 25, 2020, or (v) any Additional TSA with an RFP Sponsor is terminated pursuant to Section 3.3.1(a) of that Additional TSA, provided that the termination right under this clause (v) is exercised by a Party within thirty (30) days of the effective date of the termination of such Additional TSA.
(b) Upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
18
Section 3.3.2 Mutual Agreement . This Agreement may be terminated at any time upon written agreement of the Parties.
Section 3.3.3 Failure to Obtain Certain Approvals .
(a) Unless otherwise agreed in writing by the Parties, this Agreement shall terminate immediately without further action of the Parties in the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline, any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline, or any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e) ).
(b) In the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline or if any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e) ), and this Agreement has been terminated pursuant to clause (a) above, Distribution Company may draw against the Credit Support provided by Owner to Distribution Company, including the Owner Security and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) hereof.
(c) In the event any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline (as extended, if applicable, pursuant to Section 4.1(c) or 4.1(e)) and this Agreement has been terminated pursuant to clause (a) above, Distribution Company may draw against the Credit Support provided by Owner to Distribution Company, including the Owner Security and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) hereof.
(d) Except as otherwise provided in clause (b) or in clause (c) above, upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.4 Distribution Company Default .
(a) Owner shall have the right to terminate this Agreement in accordance with Section 14.3(a) .
(b) Upon the exercise by Owner of its termination rights pursuant to clause (a) above, Owner shall have the right to recover from Distribution Company, and Distribution Company shall pay to Owner, the Distribution Company Termination Payment in accordance with Section 14.3(c) .
(c) The exercise by Owner of its termination rights pursuant to clause (a) above shall constitute a waiver by Owner of all other remedies or damages that may be available at law or in equity against Distribution Company; provided, however, that Owner shall not waive its right to, and Distribution Company shall remain liable for, the Distribution Company Termination Payment, any unpaid amounts owed by Distribution Company pursuant to Section 8.1 hereof and any amounts owed by Distribution Company to Owner under Section 3.4 , together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover the Distribution Company Termination Payment.
19
(a) Distribution Company shall have the right to terminate this Agreement in accordance with Section 14.4(a) .
(b) Upon the exercise by Distribution Company of its termination rights pursuant to clause (a) above, Distribution Company shall have the right to recover from Owner, and Owner shall pay to Distribution Company, the Owner Termination Payment in accordance with Section 14.4(a) .
(c) The exercise by Distribution Company of its termination rights pursuant to clause (a) above shall constitute a waiver by Distribution Company of all other remedies or damages that may be available at law or in equity against Owner; provided, however, that Distribution Company shall not waive any right to, and Owner shall remain liable for, the Owner Termination Payment, any amounts owed by Owner to Distribution Company under Section 3.4 , any accrued but unpaid amounts under Section 4.4.1 or any express modification of Distribution Company’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Distribution Company under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover such damages or such indemnified or other amounts owed to Distribution Company by Owner.
Section 3.3.6 Force Majeure . This Agreement may be terminated in accordance with Section 15.1(c) .
Section 3.3.7 Extended Excused Outage . This Agreement may be terminated in accordance with Section 7.2(c) .
Section 3.3.8 Termination of the PPA under Certain Circumstances . Upon termination of the PPA, this Agreement may be terminated by either Party upon written notice to the other Party and without further recourse, except where the PPA is terminated: (i) due to an Event of Default by Distribution Company as defined in the PPA, or (ii) by mutual agreement of the parties to the PPA.
Section 3.4 Termination Payments .
(a) Within sixty (60) days following the termination of this Agreement pursuant to Section 3.3 , Owner shall deliver to Distribution Company an invoice that sets forth Owner’s good faith estimate of the amounts owed to Owner by Distribution Company under Section 3.3 , or Distribution Company shall deliver to Owner an invoice that sets forth Distribution Company’s good faith estimate of the amounts owed to Distribution Company by Owner under Section 3.3 . The recipient of such invoice shall pay the amounts set forth in such invoice within thirty (30) days following its receipt of such invoice. Either Party may deduct and setoff payment of such amounts against any accrued but unpaid payment obligation of the payee to such Party hereunder. Upon the other Party’s request, the invoicing Party shall provide documentation describing the basis for the amounts invoiced in reasonable detail.
20
(b) The Parties acknowledge and agree that the payment of amounts by the defaulting Party to the non-defaulting Party pursuant to Section 3.3 or this Section 3.4 is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for the termination of this Agreement are difficult or impossible to determine and that the damages calculated under Section 3.3 or this Section 3.4 (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to the non-defaulting Party as a result thereof.
Section 3.5 Effect of Termination . Except as provided in Section 3.3 and in Section 23.13 for the survival of provisions, upon expiration or other termination of this Agreement pursuant to its terms, each of the Parties shall be released from all of its obligations under this Agreement, other than any accrued but unpaid payment obligation. Notwithstanding the foregoing sentence, upon such expiration or termination of this Agreement, either Party shall have the right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by such Party to recover any amounts owed to such Party by the other Party hereunder or to secure the release of any security or performance assurance provided by or on behalf of such Party after the later to occur of the end of the Term or the date on which any accrued but unpaid payment obligation of such Party to the other Party hereunder shall have been fully, finally and indefeasibly satisfied.
Article IV
Section 4.1 Critical Milestones .
(a) Subject to Sections 4.1(c) , 4.1(d) and 4.1(e) , commencing on the Effective Date, Owner shall develop the NECEC Transmission Line in order to achieve the milestones set forth in clauses (i), (iii)-(v), and (vii) below, and use commercially reasonable efforts to cause HQUS to develop the Québec Line in order to achieve the milestones set forth in clauses (ii) and (vi) below (each clause, a “ Critical Milestone ”) on or before the dates set forth in this Section 4.1(a) :
(i) Receipt of all Owner Approvals (other than the Municipal Owner Approvals) and AC Upgrade Approvals in final form by the Approval Deadline;
(ii) Receipt of all Canadian Approvals in final form by the Canadian Approval Deadline;
(iii) Receipt of the Municipal Owner Approvals in final form by the Municipal Owner Approval Deadline;
(iv) Closing of any financing required for the construction and operation of the NECEC Transmission Line or other demonstration to Distribution Company’s reasonable satisfaction of the financial capability of Owner to construct the NECEC Transmission Line, including, as applicable, Owner’s financial obligations with respect to interconnection of the NECEC Transmission Line and construction of the AC Upgrades and the CCIS Capacity Upgrades, by the Financing Deadline; and
21
(v) Execution by Owner and a contractor of an agreement for the engineering, procurement, and construction of the converter station at the southern end of the HVDC Line and payment by Owner to the contractor of an initial payment of at least 5% of the total price of the agreement, both by the Converter Station Contract Deadline;
(vi) Execution by Hydro-Québec Equipment, a division of Hydro-Québec, of a contract that provides for the engineering, procurement, or construction of the converter station associated with the Québec Line by the Québec Converter Station Contract Deadline;
(vii) Achievement of the Commercial Operation Date by the Target Date.
(b) Except for the achievement of the Commercial Operation Date, which shall be governed by the provisions of Section 4.2 , Owner shall provide Distribution Company (or, in the case of clause (ii), use commercially reasonable efforts to cause HQUS to provide Distribution Company) with written notice of the achievement of each Critical Milestone as set forth in Attachment B within seven (7) days after that achievement, which notice shall include information demonstrating with reasonable specificity that such Critical Milestone has been achieved. Owner acknowledges that Distribution Company will receive such notice solely to monitor progress toward the Commercial Operation Date, and Distribution Company shall not have any responsibility or liability for the development, construction, operation and maintenance of the NECEC Transmission Line or the Québec Line.
(c) Subject to Sections 4.1(e) and 4.2 , Owner may extend all of the dates for the Critical Milestones not yet achieved under this Agreement by up to four (4) six-month periods for a maximum combined period of two (2) years from the dates originally established in Section 4.1(a) . Owner shall post Credit Support (in addition to the Owner Security and the Twenty-One Million, Eight Hundred Thousand Dollars ($21,800,000) of security delivered to Distribution Company and the other RFP Sponsors by HQUS pursuant to the PPA and the Additional PPAs) in an amount equal to $5,000 per MW of the PPA Contract Maximum Amount for each such six-month period, with a pro-rata adjustment of the amount of any such additional Credit Support for any partial reduction of the applicable six-month period pursuant to Section 4.1(e) . Any such election shall be made in a written notice to Distribution Company on or prior to the first date for a Critical Milestone that has not yet been achieved (as such date may have previously been extended). Such notice shall include a detailed explanation of the reasons for the delay, why the delay could not be avoided and the impact on Owner’s Construction Schedule and the expected Commercial Operation Date. Distribution Company shall have the right to request and receive information from Owner regarding such explanation. Such additional Credit Support shall be provided by Owner if there is an Owner Delay or an HQUS Delay and Owner wishes (or is required under the HQUS TSA) to extend any Critical Milestone date. Any additional Credit Support provided under this Section 4.1(c) shall be returned to Owner upon the Commercial Operation Date; provided that, in the event the Commercial Operation Date is not achieved by the Target Date, Distribution Company shall have the rights and remedies set forth in Article XIV , which, for the avoidance of doubt, shall include recourse against any Credit Support posted by Owner.
22
(d) To the extent a Force Majeure event pursuant to Section 15.1 has occurred that prevents Owner from achieving the Critical Milestone dates for execution of the contract for the purchase by Owner of the Converter Station ( Section 4.1(a)(v) ) or the Commercial Operation Date ( Section 4.1(a)(vii) ), or prevents the achievement of the Québec Converter Station milestone ( Section 4.1(a)(vi) ), by the applicable Critical Milestone date, the Critical Milestone date(s) impacted by such Force Majeure event shall be extended for the duration of the Force Majeure event, but under no circumstances shall extensions of those Critical Milestone dates exceed twelve (12) months beyond the applicable Critical Milestone date; provided that Owner shall not have the right to declare a Force Majeure event related to the Critical Milestone for Owner Approvals ( Section 4.1(a)(i) ), Canadian Approvals ( Section 4.1(a)(ii) ), Municipal Owner Approvals ( Section 4.1(a)(iii) ), or the financing Critical Milestone ( Section 4.1(a)(iv) ).
(e) In the event of a Regulatory Approval Delay, the date for each Critical Milestone not yet achieved shall be extended for the duration of the delay. The number of days of extension pursuant to the six-month extensions available under Section 4.1(c) shall be reduced by one day for each day of Regulatory Approval Delay pursuant to this subsection (e) up to a maximum reduction of 365 days. For purposes of illustration, Regulatory Approval Delay of two hundred ten (210) days would allow Owner two six-month extensions and one extension of five months .
Section 4.2 Commercial Operation Date .
(a) The “ Target Date ” for Commercial Operation is December 13, 2022 (as the same may be extended in accordance with Sections 4.1(c) , 4.1(d) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing. Absent written agreement by the Parties, the Target Date may not be extended beyond December 13, 2024 unless such extension is due to Regulatory Approval Delay or an event of Force Majeure as set forth in Sections 4.1(d) and 4.1(e) . The provisions of Sections 4.1(c) , 4.1(d) , and 4.1(e) and all other provisions of this Agreement are subordinate to this Section 4.2 (a) and the aforesaid Section 4.1 provisions and such other provisions shall be construed in a manner that is consistent with this Section 4.2(a) . Owner shall provide a written non-binding notice to Distribution Company no later than sixty (60) days before the date Owner reasonably expects the Commercial Operation Date to occur.
(b) At the request of Owner made in writing, Distribution Company shall cooperate with Owner, TransÉnergie and ISO-NE to support the Commissioning of the HVDC Transmission Project.
(c) As soon as practicable after Owner is of the opinion that the conditions to Commercial Operation, as set forth in Section 4.3 , have been satisfied, or such conditions have been waived in writing by the Parties (except in the case of Section 4.3(b) , Section 4.3(e) , Section 4.3(g) and Section 4.3(h) , which conditions may be waived in writing by Distribution Company, in its sole discretion), Owner shall deliver a written notice to Distribution Company specifying the date upon which Commercial Operation shall commence (the “ COD Notice ”), which commencement date shall occur no earlier than ten (10) Business Days after the receipt by Distribution Company of the COD Notice or on such other date as agreed upon by the Parties in writing (such date, the “ Commercial Operation Date ”).
23
(d) Within five (5) Business Days after the receipt by Distribution Company of the COD Notice, Distribution Company shall deliver a certificate to Owner either (i) confirming that the conditions set forth in Section 4.3 have been satisfied or duly waived and that Commercial Operation may commence on the Commercial Operation Date or (ii) objecting with reasonable detail to the COD Notice. Distribution Company’s failure to respond in writing to a COD Notice within such five (5) Business Day period shall be deemed to be a confirmation that the conditions set forth in Section 4.3 have been satisfied or duly waived. Any Dispute over whether or not the conditions set forth in Section 4.3 have been satisfied or duly waived shall be resolved in accordance with Article XVII .
Section 4.3 Conditions Precedent to Commercial Operation . The items set forth in clauses (a) through (i) below shall be conditions precedent to the Commercial Operation of the NECEC Transmission Line:
(a) Completion of the Commissioning of the HVDC Transmission Project by Owner (in coordination with ISO-NE) and TransÉnergie;
(b) The NECEC Transmission Line has been constructed in accordance with Attachment A and Good Utility Practice, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(b) ;
(c) Completion of the AC Upgrades and the CCIS Capacity Upgrades;
(d) The Interconnection Agreements shall be in full force and effect;
(e) The Transmission Operating Agreement shall be in full force and effect and ISO-NE shall have informed Owner that ISO-NE (i) is prepared to assume operational control over the NECEC Transmission Line, as defined in, and in accordance with, the Transmission Operating Agreement and (ii) will assume such operational control as of the Commercial Operation Date;
(f) The Québec Line has been constructed in accordance with Attachment A, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(b) ;
(g) Receipt by Distribution Company of copies of certificates evidencing all outstanding insurance required or otherwise obtained under Section 5.3 ; and
(h) Receipt by Distribution Company of an opinion of legal counsel, reasonably satisfactory to Distribution Company, that all Governmental Approvals and Third Party Consents required to own and operate the NECEC Transmission Line have been obtained.
24
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation .
Section 4.4.1 Owner Delay . If, other than solely as a result of an HQUS Delay, Force Majeure, or Concurrent Delay, any conditions set forth in Section 4.3 shall not have been satisfied or duly waived by the Target Date (such delay, an “ Owner Delay ”):
(a) Distribution Company shall have the right to recover from Owner, and Owner shall pay or reimburse to Distribution Company, for each day (or part thereof) following the Target Date during which the Owner Delay is continuing, an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Distribution Company terminates this Agreement under Section 14.4 hereof, and (z) the date that is twelve (12) months after the Target Date.
(b) Design Capacity Shortfall .
(i) As of the Commercial Operation Date . In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line or the Québec Line is only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line and the Quebec Line are capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service hereunder, or (B) the NECEC Transmission Line and the Quebec Line are capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service hereunder (such consent not to be unreasonably withheld, conditioned, or delayed), then Owner shall have twenty-four (24) months from the Commercial Operation Date to attempt to increase such operating capacity to 1,090 MW (the “ Remediation Period ”), and Owner shall pay to Distribution Company, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period, or such earlier date designated by Owner in writing to Distribution Company (the “ Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and such operating capacity as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Distribution Company to Owner. Distribution Company’s payments shall be based on the actual operating capacity of the NECEC Transmission Line, as is stated in Section 8.1 .
(ii) Following Remediation . If, on the earlier of Remediation Date or the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW, then this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line, the Contract Capacity shall be deemed modified accordingly, and the rate used to calculate the Transmission Service Payment will be reduced pro rata to reflect the capacity shortfall below 1,090 MW. For illustrative purposes, if following the earlier of the Remediation Date or the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line is 1,080 MW, which will be the Contract Capacity from then onwards, the Transmission Service Payment rate for the remainder of the Term shall be reduced to the Transmission Service Payment rate then in effect multiplied by 1,080/1,090, and that rate shall be multiplied by the Contract Capacity of 1,080 MW to determine the Transmission Service Payment.
25
(iii) An Owner Default shall be deemed to have occurred pursuant to Section 14.2(c) if (A) as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are not both capable of operating at or above 1,040 MW, and Distribution Company has not agreed in writing to begin transmission service hereunder notwithstanding such operating capability, or (B) as of the earlier of the Remediation Date or the end of the Remediation Period, the NECEC Transmission Line and the Québec Line are not both capable of operating at or above 1,075 MW.
(c) Without any limitation of Section 4.4.2 , the Parties acknowledge and agree that the payment of amounts by Owner to Distribution Company under clauses (a) and (b) above, respectively, are an appropriate remedy and that any such modification or payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for an Owner Delay or a reduction in operating capacity, as described in clause (b), are difficult or impossible to determine and that the damages calculated hereunder (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
(d) Without any limitation of Section 4.4.2 , the rights provided in Section 3.3.5 and this Section 4.4.1 shall collectively be the sole and exclusive remedies of Distribution Company with respect to an Owner Delay or a reduction in operating capacity, as described in clause (b). The foregoing sentence shall not be construed in any way to limit (i) Distribution Company’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, or (ii) Distribution Company’s rights to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1 .
Section 4.4.2 Concurrent Delays .
(a) In the event of a concurrent HQUS Delay and Owner Delay (a “ Concurrent Delay ”), for each day (or part thereof) during which a Concurrent Delay is continuing, Owner will pay to Distribution Company an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (w) the date on which either the Québec Line or the NECEC Transmission Line is capable of commercial operation but for the other Party’s delay, (x) the Commercial Operation Date, (y) the date on which Distribution Company terminates this Agreement under Section 14.4 hereof, and (z) twelve (12) months after the Target Date.
(b) The Parties acknowledge and agree that the payment of amounts by Owner to Distribution Company under clause (a) above is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Concurrent Delay are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
26
(c) The rights provided in Section 3.3.3 and this Section 4.4.2 shall collectively be the sole and exclusive remedies of Distribution Company with respect to a Concurrent Delay. The foregoing sentence shall not be construed in any way to limit (i) Distribution Company’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, or (ii) Distribution Company’s rights to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1 .
Article V
GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES
Section 5.1 Responsibilities of the Parties .
Section 5.1.1 Construction Phase .
(a) During the Construction Phase, Owner shall (i) exercise Good Utility Practice to complete, or cause the completion of, all tasks required to construct the NECEC Transmission Line, interconnect at least 1,090 MW of capacity with ISO-NE in compliance with the Capacity Capability Interconnection Standard, and achieve Commercial Operation by the Target Date, in each case, in accordance with the Design Capability and in a manner consistent with Attachment A and (ii) use commercially reasonable efforts to obtain all of the Construction Authorizations (other than the Municipal Owner Approvals) by the Approval Deadline, (B) to obtain, in consultation with Distribution Company, the ISO-NE Approval by the Approval Deadline and (C) to cause Owner’s Affiliates that are AC Upgrade Owners to obtain any AC Upgrade Approvals for which such Affiliates are responsible by the Approval Deadline and to assist other AC Upgrade Owners in obtaining their respective AC Upgrade Approvals by the Approval Deadline.
(b) Owner will use commercially reasonable efforts to enter into, within a commercially reasonable timeframe, one or more Construction Contracts. Owner will make a copy of any such contract available to Distribution Company subject to such redactions as Owner or the contracting party deem necessary to protect confidential information.
Section 5.2 Schedules and Reports .
Section 5.2.1 Owner’s Preliminary Schedule . Attached hereto as Attachment E is Owner’s Project Schedule (the “ Owner’s Preliminary Schedule ”). At the request of Distribution Company, Owner shall make the personnel responsible for preparing the Owner’s Preliminary Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Preliminary Schedule with Distribution Company.
Section 5.2.2 Owner’s Construction Schedule . Within ten (10) days after the end of each calendar quarter and sooner if a material change occurs, commencing at least ninety (90) days prior to the commencement of construction, Owner shall prepare and submit to Distribution Company for review an update of the Owner’s Preliminary Schedule (such updated schedule as established herein, the “ Owner’s Construction Schedule ”). At the request of Distribution Company, Owner shall make the personnel responsible for preparing the Owner’s
27
Construction Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Construction Schedule with Distribution Company.
Section 5.2.3 Owner’s Progress Reports .
(a) Promptly following the Execution Date, Owner shall deliver to Distribution Company copies of all applications that have been submitted by Owner with respect to any Owner Approvals, as well as all material correspondence and submittals relating to such Owner Approvals. Within ten (10) days after the end of each calendar quarter, commencing at receipt of the Regulatory Approval, Owner shall prepare and submit to Distribution Company for review a progress report for informational purposes that sets forth in reasonable detail the current status of the milestones set forth in the Owner’s Construction Schedule, including any changes in the expected timelines and the status of all Owner Approvals and including copies of any Owner Approval applications, material correspondence and submittals relating to Owner Approvals, and any issued Owner Approvals (the “ Owner’s Construction Progress Report ”). Without limitation of the foregoing, Owner shall include in such reports relevant information relating to: (i) Owner’s efforts to mitigate the impacts of the NECEC Transmission Line on natural resources, environmentally sensitive areas, habitats, and wildlife species, and cultural and historic resources; (ii) Owner’s efforts to comply with applicable noise ordinances; (iii) and Owner’s communication and community outreach efforts and plans with respect to the construction of the NECEC Transmission Line, including with stakeholders in Massachusetts. At the request of Distribution Company, Owner shall, or shall cause each contractor to, provide Distribution Company with access to, and copies of, all reasonably requested documentation concerning such Owner’s Construction Progress Report.
(b) Owner shall, or shall cause the principal contractor to, notify Distribution Company promptly, but in no event later than ten (10) days, after Owner, or such contractor, becomes aware that the Commercial Operation of the NECEC Transmission Line is not reasonably likely to occur by the Target Date.
Section 5.3 Insurance and Events of Loss . Owner shall obtain and maintain with reputable insurers authorized to operate in the scope of the Agreement insurance of the type set forth in Attachment F. Owner shall provide Distribution Company with copies of certificates of all outstanding insurance obtained hereunder promptly after the receipt thereof by Owner. Owner shall notify Distribution Company as soon as reasonably possible if and whenever an event of loss occurs. Without limitation of any obligations Owner may have under Section 15.1 hereof, in the event of damage to or loss of all or part of the NECEC Transmission Line, Owner shall exercise prompt, diligent commercially reasonable efforts to effectuate, in accordance with Good Utility Practice, such repairs and replacements as are necessary or desirable to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss, including, for the avoidance of doubt, the application to such repairs or replacements of any potential or actual proceeds realized in connection with such damage or loss under any available or applicable insurance policies (subject to insurance contract/policy terms and conditions of coverage) maintained pursuant to this Section 5.3 . Subject to Owner’s compliance, in all material respects, with this Section 5.3 , Section 6.3 and all other material terms and conditions with respect to the operation and maintenance of the NECEC Transmission Line, in the event that the costs to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss exceed the available insurance proceeds by more than the greater of (a) an amount equal to three percent (3%) of the Net Book Value of the NECEC Transmission Line and (b) Thirty Million
28
Dollars ($30,000,000), the Parties will negotiate in good faith an appropriate allocation of financial responsibility for such excess costs. In the event that the Parties do not agree on the allocation of financial responsibility, Distribution Company shall be entitled to terminate this Agreement, upon thirty (30) days’ written notice to Owner, without liability to Owner; provided that, if within the thirty (30) day period following receipt of such notice, Owner agrees to assume that portion of the allocation of financial responsibility to which Distribution Company objected, then the termination notice shall be deemed revoked and this Agreement shall not be terminated.
Section 5.4 Compliance with Laws . At all times during the Term, the Parties shall comply with all Applicable Laws (including ISO-NE Rules to the extent applicable) and relevant Governmental Approvals and Third Party Consents.
Section 5.5 Third Party Contracts .
Section 5.5.1 At all times during the Term, Owner shall, in a commercially reasonable manner, (a) satisfy its obligations under all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades, and (b) administer all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades.
Section 5.5.2 Unless it obtains the prior written consent of Distribution Company (such consent not to be unreasonably withheld, conditioned or delayed) , Owner shall not: (i) agree to any amendment to Sections 3.3.5 , 14.3 , 14.6 , 14.7 , 14.8 , and 14.10 of the HQUS TSA, or (ii) agree to an amendment and restatement, replacement, supplement, or other modification or amendment of the HQUS TSA that adversely and materially affects Distribution Company’s rights under this Agreement or the PPA. Owner shall provide to Distribution Company a copy of any proposed amendment to the HQUS TSA not fewer than ten (10) Business Days prior to the execution thereof.
Section 5.6 Continuity of Rights and Responsibilities . Unless otherwise agreed in writing by the Parties or prohibited by Applicable Law, the Parties shall continue to provide service and honor commitments under this Agreement and continue to make payments in accordance with this Agreement pending resolution of any bona fide Dispute hereunder or relating hereto.
Article VI
PROCEDURES FOR OPERATION AND MAINTENANCE
OF THE NECEC TRANSMISSION LINE
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control .
(a) Prior to entering into the Transmission Operating Agreement, Owner shall consult Distribution Company with respect to the proposed terms and conditions thereof and Owner shall make a good faith effort to take into account any comments made by Distribution Company. Distribution Company shall promptly provide comments, if any, to Owner on such terms and conditions.
29
(b) As of the Commercial Operation Date, Owner shall transfer operational control over the NECEC Transmission Line, as defined in the Transmission Operating Agreement, to Transmission Operator in accordance with the Transmission Operating Agreement. Owner shall provide, and shall direct its Affiliates to provide, such information as Transmission Operator may require to discharge its obligations under the Transmission Operating Agreement, and Owner shall comply with the instructions of Transmission Operator to the extent provided in the Transmission Operating Agreement and the ISO-NE Tariff. The Parties acknowledge and agree that Owner shall not be in breach of, or be liable to Distribution Company under, this Agreement, and no Owner Default shall occur, as a consequence of Owner’s compliance with such instructions of Transmission Operator; provided that Owner did not initiate or support instructions that would otherwise breach Owner’s obligations under this Agreement.
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements . From and after the Commercial Operation Date, Owner shall (a) provide Firm Transmission Service, (b) operate and maintain the NECEC Transmission Line in accordance with Good Utility Practice and in compliance with all applicable regulatory requirements, including applicable NERC and Northeast Power Coordinating Council reliability standards, and (c) comply with all applicable operating instructions of ISO-NE and manufacturers’ warranties.
Section 6.3 Scheduled Maintenance . With respect to each calendar year (or portion thereof) following the Construction Phase, Owner will prepare and deliver to Distribution Company a Maintenance Plan not later than the Commercial Operation Date and two (2) months prior to the end of each calendar year thereafter during the Operation Phase, and shall be available for consultation with Distribution Company with respect thereto (including for coordination of maintenance schedules). Consistent with Good Utility Practice, Owner shall use commercially reasonable efforts to coordinate with TransÉnergie with respect to scheduled maintenance so as to minimize outages, including by meeting annually (or as otherwise necessary in order to comply with any applicable ISO-NE or Canadian regulatory or system operator requirements) to develop a Maintenance Plan. Throughout the Operation Phase, Owner shall coordinate all planned maintenance with ISO-NE, consistent with ISO-NE Rules, and shall promptly provide applicable information concerning scheduled outages, as determined by ISO-NE, to Distribution Company. To maximize value, to the extent possible and consistent with ISO-NE Rules, Owner shall not schedule maintenance of the NECEC Transmission Line during the months of December, January and February or June through September and shall operate the NECEC Transmission Line so as to maximize energy production during the hours of anticipated peak load and energy prices in New England; provided, however, that planned maintenance may be scheduled during such period to the extent the failure to perform such planned maintenance is contrary to operation of the NECEC Transmission Line in accordance with Good Utility Practice. Owner may modify a Maintenance Plan in accordance with Good Utility Practice; provided, however, that (a) a Maintenance Plan may not be modified for the purpose of reducing the magnitude or duration of a Non-Excused Outage, (b) any modification shall, to the extent commercially reasonable, maximize value in the manner described in this Section 6.3, and (c) Owner shall provide Distribution Company with reasonable notice of any change in a Maintenance Plan. Any maintenance that is not included in the Maintenance Plan for a year and is not otherwise excused under Section 7.2 shall be a Non-Excused Outage.
30
DISTRIBUTION
COMPANY’S TRANSMISSION RIGHTS OVER THE
NECEC TRANSMISSION LINE
Section 7.1 Transmission Service .
Section 7.1.1 Firm Transmission Service . Owner shall make available to Distribution Company, from and after the Commercial Operation Date through the end of the Term, transmission capacity on the NECEC Transmission Line in order to deliver electrical energy, as scheduled by Distribution Company or its designee or assignee under the resale provisions of Article X , in such scheduled amount up to the Contract Capacity, measured at the Delivery Point (“ Firm Transmission Service ”). Firm Transmission Service shall be made available over the NECEC Transmission Line at any time from and after the Commercial Operation Date, in a north-to-south direction, and to the extent available in a south-to-north direction, between the U.S. Border and the Delivery Point. Firm Transmission Service shall be subject to curtailment or interruption only as a result of an Excused Outage or as provided in Section 14.3(b) . Without limiting Owner’s obligations under this Section 7.1.1 , the quantity of Firm Transmission Service that Owner will provide in any hour shall not exceed the Proportionate Share of the Available Transfer Capability for such hour.
Section 7.1.2 Limitation on Transmission Service . Owner shall have no obligation to provide transmission service under this Agreement other than Firm Transmission Service. Distribution Company shall have no right to redirect service to alternate points of delivery or receipt on any portion of the transmission system operated by ISO-NE other than the NECEC Transmission Line.
Section 7.1.3 Scheduling . All Firm Transmission Service shall be scheduled in accordance with the rules relating to the scheduling of electrical energy or capacity transactions over the NECEC Transmission Line, as established under the Transmission Operating Agreement (the “ Scheduling Rules ”).
Section 7.1.4 Owner’s Cooperation . Owner shall provide Distribution Company with notice of any FERC or NERC regulatory proceedings relating to the NECEC Transmission Line or this Agreement to which Owner is a party promptly after Owner becomes aware of any such proceedings. Each Party will act in good faith regarding any such proceedings. Neither Party shall take any position in such proceeding that is contrary to such Party’s obligations under this Agreement.
Section 7.2 Excused Outages or Reductions.
(a) Notwithstanding anything herein to the contrary, Owner shall not be in breach of, or be liable to Distribution Company for any losses or damages under, this Agreement, and no Owner Default shall occur, as a consequence of an Excused Outage. “ Excused Outages ” means any outages of the NECEC Transmission Line, or reductions in the Total Transfer Capability below the NECEC Transmission Line Capacity, whether as a result of a physical condition, legal impediment or otherwise, if and to the extent such outage or reduction is due to:
(i) Events of Force Majeure;
(ii) Scheduled maintenance in accordance with the applicable Maintenance Plan;
31
(iii) Outages or reductions in the availability of the Québec Line for any reason; or
(iv) Decisions of ISO-NE or any other independent system operator to reduce or suspend scheduling rights over the NECEC Transmission Line or the Quebec Line, including as a result of any grid reliability issue, emergency condition as defined in any Interconnection Agreement or the ISO-NE Tariff, or to preserve facilities and equipment from physical damage and including any such decisions that arise from outages or reductions in the use or availability of transmission lines other than the NECEC Transmission Line or the Québec Line, which outage or reduction arises from or is attributable to Force Majeure or scheduled maintenance.
(b) Notwithstanding anything in Section 7.3.1 to the contrary, Distribution Company shall remain obligated, during and to the extent of any Excused Outage to pay the Transmission Service Payment without downward adjustment to reflect any such outage, reduction, or delay. Owner shall seek to avoid, mitigate and remedy any Excused Outage consistent with Good Utility Practice.
(c) Notwithstanding anything herein to the contrary and without regard to whether an Excused Outage is due to Force Majeure, if an Excused Outage prevents Owner’s full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, Distribution Company shall have the right, as provided in Section 15.1(c) herein, to terminate this Agreement upon written notice to Owner and without further recourse.
Section 7.3 Non-Excused Outages or Reductions .
Section 7.3.1 Reduction in Transmission Service Payments . In the event the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 , the Transmission Service Payment for such period shall be reduced in accordance with Section 8.1 . Any Dispute over whether or not or to what extent a Non-Excused Outage has occurred shall be resolved in accordance with Article XVII . Owner shall seek to avoid, mitigate and remedy any Non-Excused Outage consistent with Good Utility Practice.
Section 7.3.2 Liquidated Damages . The Parties acknowledge and agree that the modification of Distribution Company’s payment obligations pursuant to Section 8.1 is an appropriate remedy and that any such modification does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Non-Excused Outage are difficult or impossible to determine and that the damages calculated hereunder (together with any remedies available to Distribution Company under the PPA) constitute a reasonable approximation of the harm or loss to Distribution Company as a result thereof.
Section 7.3.3 Sole and Exclusive Remedy . The rights provided in Section 3.3.5 , this Section 7.3 , and Section 14.4 shall collectively be the sole and exclusive remedies of Distribution Company with respect to a Non-Excused Outage, subject to (a) Distribution Company’s right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably
32
incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement, (b) Distribution Company’s right to recover payment of any indemnification obligations of Owner to Distribution Company pursuant to Section 20.1, or (c) Distribution Company’s rights on an Owner Event of Default as described in Section 14.2 .
Section 7.4 Allocation of Outages . The Parties expressly intend and agree that any outages or reductions in Total Transfer Capability shall be borne first by HQUS and by all transmission rights holders served by the NECEC Transmission Line (including Owner, if applicable) other than Distribution Company and the other RFP Sponsors, and that any remaining reduction shall be allocated among Distribution Company and the other RFP Sponsors in accordance with their respective Proportionate Shares. Owner acknowledges and agrees that it will not reduce the Firm Transmission Service available to Distribution Company except in accordance with the foregoing priority and will not reduce the Firm Transmission Service available to Distribution Company in an unduly discriminatory manner as compared with any other transmission rights holder served by the NECEC Transmission Line (including Owner, if applicable). For purposes of clarity, HQUS’s transmission service under the Additional HQUS TSA shall be reduced before any reductions are applied to Distribution Company’s transmission service under this Agreement.
Section 7.5 Metering . Metering and telemetering requirements for the NECEC Transmission Line shall be established by Owner in accordance with Good Utility Practice and as necessary to (a) accomplish the purposes of, and to implement and administer, this Agreement and (b) satisfy the requirements of, and to implement and administer, the PPA, the Interconnection Agreement and the Transmission Operating Agreement.
Section 7.6 Line Availability Information and Reporting . Owner shall make available to Distribution Company on a real time basis information relating to the operation and availability of the NECEC Transmission Line and shall provide such additional information as Distribution Company shall reasonably request.
PAYMENTS FOR TRANSMISSION SERVICE OVER THE
NECEC TRANSMISSION LINE
Section 8.1 Transmission Service Payments . During the Operating Phase, except to the extent such payment is excused or reduced pursuant to the terms of this Agreement, Distribution Company shall pay to Owner a transmission service payment (the “ Transmission Service Payment ”) on a monthly basis in an amount calculated as set forth in Attachment J pursuant to invoices delivered by Owner to Distribution Company; provided, however, that, in the event Regulatory Approval does not occur by January 25, 2019, the Transmission Service Payment shall increase 0.18333% per month for each full month following January 25, 2019 until such Regulatory Approval is received. The Transmission Service Payments shall be reduced in accordance with the formula set forth in Attachment G in the event and to the extent that the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 , and the rate ($/MW) shall be adjusted in accordance with Section
33
4.4.1(b)(ii) . Pursuant to Section 13.2 , to the extent there is a Dispute over whether or not or to what extent a Non-Excused Outage has occurred, the reduction in the Transmission Service Payments shall be implemented upon the resolution of that Dispute and such reduction will be effective as of the date when such Dispute arose . Such adjustments shall be made on a monthly basis pursuant to invoices delivered by Owner to Distribution Company.
Section 8.2 Elective Upgrade Status; No Regional Rates . It is the intent of the Parties that the NECEC Transmission Line has Elective Transmission Upgrade status during the Term and that the AC Upgrades and the CCIS Capacity Upgrades constitute Network Upgrades under the ISO-NE Tariff required to accommodate the interconnection of the NECEC Transmission Line. It is the further intent of the Parties that Owner’s recovery of the investment in and return on the NECEC Facilities and the Distribution Company’s obligation to pay for the NECEC Facilities shall be solely governed by this Agreement. The Parties each shall refrain from taking steps to include all or part of the NECEC Facilities in ISO-NE regional transmission rates during the Term and for a period of twenty (20) years thereafter. Notwithstanding the foregoing, if during the Term all or part of the NECEC Facilities are included in ISO-NE regional rates paid by the Distribution Company, the payment required by Section 8.1 shall be reduced by the Proportionate Share of the revenues received by Owner from such ISO-NE rates with respect to the NECEC Facilities. “ NECEC Facilities ” means the NECEC Transmission Line, the AC Upgrades, and the CCIS Capacity Upgrades.
Article IX
RIGHTS UPON EXPIRATION OF TERM
Section 9.1 Rollover and Other Rights . Distribution Company hereby irrevocably waives any rollover rights it may have at the end of the Term in accordance with Order No. 890 et seq. and the FERC pro forma open access transmission service tariff, as such rights are defined as of the Effective Date.
Article X
TRANSFER AND RESALE OF TRANSMISSION RIGHTS
Section 10.1 Transfer of Transmission Rights . Owner conveys to Distribution Company all rights to and title and interest in the use of the Distribution Company’s Proportionate Share of NECEC Transmission Line Capacity and Distribution Company has entered into the PPA, pursuant to which Distribution Company transfers, assigns and conveys to HQUS during the Term all of Distribution Company’s rights, title and interest in and to the Firm Transmission Service, Other Transmission Rights, and Market Products in respect of HQUS’s delivery obligations under the PPA .
Section 10.2 Resale Rights . In the PPA, HQUS has acknowledged that if and to the extent HQUS determines from time to time, and in its sole discretion, that the transmission capacity available to HQUS relevant to the receipt of Firm Transmission Service over the NECEC Transmission Line pursuant to this Agreement exceeds HQUS’s needs, HQUS will then offer to resell such unused capacity to third parties in accordance with Applicable Law as may then be in effect (including the terms and conditions of FERC Order No. 890 et seq., if applicable).
34
Section 10.3 Capacity Releases for Daily and Hourly Use . From and after the Commercial Operation Date, if and to the extent the Proportionate Share of the Available Transfer Capability exceeds the amount of electrical energy that is scheduled by Distribution Company (or its assignee) for delivery over the NECEC Transmission Line using Firm Transmission Service by the applicable scheduling deadline (as in effect at such time) established pursuant to the Scheduling Rules, then the transmission capacity that is available for resale to third parties for the following day, and the price at which any such resales are offered, shall be posted on the OASIS site established pursuant to Section 10.4 .
(a) Owner or an Affiliate of Owner (in such capacity, the “ OASIS Administrator ”) shall establish an OASIS site for the NECEC Transmission Line and administer such site in accordance with applicable FERC requirements for the establishment and administration of OASIS sites. None of Owner, the OASIS Administrator or Distribution Company (or its assignee) shall be liable to each other or any third party for any decisions the OASIS Administrator makes regarding the appropriate price for resales of unused transmission capacity or the level of any such resales the OASIS Administrator is able to make. The Parties agree that there shall be no damages as between each other or third parties for actions by the OASIS Administrator with respect to resales of unused transmission capacity.
(b) To the extent resales are made available by Distribution Company (or its assignee) pursuant to Section 10.2 , the OASIS Administrator shall post on the OASIS site information regarding such resales, (i) in accordance with written instructions provided by Distribution Company (or its assignee) from time to time and (ii) at a price established by Distribution Company (or its assignee) from time to time, and in its sole discretion, as permitted under Applicable Law.
Section 10.5 Proceeds from Capacity Releases and Transmission Resales . Except as otherwise provided in Section 14.3(b) , Distribution Company’s Proportionate Share of the proceeds received by Owner of any capacity releases and transmission resales of transmission capacity assigned to HQUS under Section 20 of the PPA and the Additional PPAs that are made during the Operation Phase shall be credited, net of reasonable fees (including attorneys’ fees) and other expenses incurred in connection with performance of the functions described in Section 10.3 and Section 10.4 , against any Transmission Service Payment or other amounts owed to Owner by Distribution Company for the calendar month subsequent to the calendar month in which such proceeds were received.
Section 10.6 Owner’s Rights and Obligations . Except as expressly provided in the Proposal Agreements, Owner shall have no right or obligation to offer any transmission service over the NECEC Transmission Line for sale or resale to any Person other than Distribution Company, as provided herein.
35
REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS
Section 11.1 Real Power Losses . Distribution Company shall not be responsible for any Real Power Losses associated with Firm Transmission Service. Owner and HQUS shall be responsible for the delivery of the scheduled amounts of energy associated up to the Contract Capacity to the Delivery Point without reduction for Real Power Losses.
(a) Distribution Company shall be entitled during the Term to its Proportionate Share of the following, without duplication and without additional cost to Distribution Company or compensation to Owner: (i) all Other Transmission Rights associated with the NECEC Transmission Line or the AC Upgrades, in each case, that are issued in accordance with the ISO-NE Tariff or otherwise granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, and (ii) all other Market Products that are issued in accordance with the ISO-NE Tariff or granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, that derive from the acquisition of transmission service over the NECEC Transmission Line. For purposes of this clause (a), the denominator of the “Proportionate Share” shall be the Physical Transmission Line Capacity. As Owner’s sole obligation under this clause (a), upon its receipt of any of the entitlements or rights described in the foregoing sentence, Owner shall promptly convey such entitlements or rights to Distribution Company.
(b) In the event tie benefits or interconnection capability credits (or any similar concept) are ever deemed applicable to the NECEC Transmission Line and to the extent allocated to any Party during the Term, Distribution Company shall be entitled to its Proportionate Share of one hundred percent (100%) of the economic benefits associated therewith (however entitled and whether existing now or in the future), without additional cost to Distribution Company or compensation to Owner. For purposes of this clause (b), the denominator of the “Proportionate Share” shall be the Physical Transmission Line Capacity.
(c) Owner shall have no obligation to support the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above, but Owner may not oppose the creation or establishment of any such right, unless otherwise agreed in writing by Distribution Company. Neither Section 2.5 nor the foregoing sentence shall be construed in any way to limit the right of any Affiliate of Owner to oppose the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above.
36
Article XIII
Section 13.1 Invoices . Within seven (7) Business Days after the first day of each calendar month following the commencement of the Operation Phase, Owner shall submit an Invoice to Distribution Company for the Transmission Service Payments owed for the preceding calendar month, and Distribution Company shall pay the amounts set forth in the Invoice to Owner within fourteen (14) Business Days following its receipt of such Invoice. All payments shall be made in immediately available funds payable to Owner by wire transfer to a bank named by Owner, in accordance with wiring instructions provided to Distribution Company by Owner in writing. Owner shall be entitled to change the place or recipient for payment by thirty (30) days’ prior written notice to Distribution Company.
Section 13.2 Procedures for Billing Disputes .
(a) In the event of any Dispute with respect to the amount owed to Owner by Distribution Company under this Agreement, Distribution Company shall have no right to withhold payment of the Disputed amount pending resolution of the Dispute; provided, however, that, in the event such Dispute is resolved in favor of Distribution Company, Owner shall complete the following tasks consistent with the resolution of such Dispute: (i) retroactively adjust all payments previously made by Distribution Company; (ii) promptly refund all overpayments previously made by Distribution Company, together with interest thereon in immediately available funds or by wire transfer, in each case, in accordance with wiring instructions provided to Owner by Distribution Company in writing; and (iii) thereafter conform all future Invoices to reflect the resolution of such Dispute, as applicable. Distribution Company’s payment of any Disputed amounts shall be without prejudice to any right or remedy that Distribution Company may have under this Agreement to contest any such amount.
(b) Distribution Company shall not have the right to challenge any Invoice or to bring any action of any kind challenging the propriety of any Invoice after the second (2nd) anniversary of the receipt of such Invoice. If an Invoice is not rendered within two (2) years after the end of the calendar month during which such Invoice should have been rendered hereunder, then the right to payment of such Invoice is waived.
Section 13.3 Interest . All interest payable under this Section 13.3 shall be calculated pursuant to 18 C.F.R. § 35.19a(a), as such regulation (or any successor thereto) is in effect during the period during which such interest is due. Amounts not paid when due to Owner or Distribution Company under this Agreement shall bear interest from the date such amount was due until the date of payment of such overdue amount. For the avoidance of doubt, as illustrated in Attachment H, if all or a portion of the amount to which such interest relates is later refunded pursuant to this Agreement, then, in calculating that refund, such interest shall not be included in the refund. Refunds of overpayments owed to Distribution Company by Owner under this Agreement shall begin to accrue interest on the amount subject to refund, as originally invoiced, from the earlier to occur of the due date or the date of payment of the monthly Invoices to which the overpayment relates and shall continue to accrue interest until the date of payment of such refund.
37
Section 13.4 Obligation to Make Payments . The Parties acknowledge and agree that, except as set forth in Section 3.3.8 , Section 8.1 , Section 13.5 and Section 14.4(d) , no cause or event whatsoever shall excuse or suspend Distribution Company’s obligation to pay Transmission Service Payments or any other amounts payable by Distribution Company under this Agreement. The Parties also acknowledge and agree that no cause or event whatsoever shall excuse or suspend any amounts payable by Owner under this Agreement.
Section 13.5 Offsets . Except as otherwise provided in Section 3.4(a) and Section 14.4(d) , neither Party shall be entitled to deduct or set-off payment of any amount owed to the other Party under this Agreement against payment of any amount owing under this Agreement.
EVENTS OF DEFAULT AND REMEDIES
Section 14.1 Distribution Company Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Distribution Company under this Agreement (a “ Distribution Company Default ”), provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (c), clause (d), or clause (e) :
(a) Distribution Company’s failure to pay any undisputed amount due to Owner under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Distribution Company of a written demand from Owner that such amount is due and owing and has not been timely paid.
(b) Distribution Company’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clause (a) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Distribution Company of written notice thereof from Owner, unless such cure shall reasonably require a longer period, in which case Distribution Company shall be provided an additional thirty (30) days to complete such cure so long as Distribution Company has promptly commenced such cure and thereafter diligently pursues such cure.
(c) Any representation or warranty made by Distribution Company in this Agreement is false or misleading at the time made in any material respect.
(d) Any Insolvency Event occurs with respect to Distribution Company.
(e) Any termination of the PPA due to an “Event of Default” by Distribution Company under and as defined in the PPA.
Section 14.2 Owner Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Owner under this Agreement (an “ Owner Default ” ) , provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (h), or clause (i) :
38
(a) Owner’s failure to pay any undisputed amount due to Distribution Company under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Owner of a written demand from Distribution Company that such amount is due and owing and has not been timely paid.
(b) Owner’s failure to satisfy (other than solely as a result of an HQUS Delay) any of the Critical Milestones in clauses (i), (iii), (iv), (v), or (vii) of Section 4.1(a) by the dates set forth therefor, as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) .
(c) The failure of the NECEC Transmission Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date, where Distribution Company has also not agreed in writing to begin transmission service hereunder notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Remediation Date or the end of the Remediation Period.
(d) Owner’s failure to comply in any material respect with the provisions of Section 5.1.1(a)(ii) and, if such failure is susceptible to cure, such failure continues for thirty (30) days after receipt by Owner of written notice thereof from Distribution Company, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(e) A Non-Excused Outage pursuant to which the average Hourly Availability of the NECEC Transmission Line over any calendar month is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , occurs and continues for more than ninety (90) consecutive days or more than one hundred twenty (120) days in any twelve (12) month period, provided, however, that if (i) Owner presents to Distribution Company before the end of a Non-Excused Outage that would otherwise constitute an Owner Default under this clause (e), a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company, acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, and (ii) Owner posts Credit Support (in addition to the Owner Security) in an amount equal to $5,000 per MWh/h of the Contract Maximum Amount for each such six-month portion of such period, Distribution Company shall forbear terminating this Agreement under this clause (e) for such period, provided that, during any such period, Distribution Company’s obligation to make Transmission Service Payments shall continue to be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. Any additional Credit Support provided under this Section 14.1(e) shall be returned to Owner if Owner is providing Firm Transmission Service in full at the end of the period of forbearance. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, an Owner Default shall be deemed to have occurred and Distribution Company shall have the rights and remedies set forth in Section 14.4 , which, for the avoidance of doubt, shall include recourse against any Credit Support posted by Owner.
39
(f) Owner’s failure to comply in any material respect with the provisions of Article XVI .
(g) Owner’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), (c), (d), (e) or (f) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Owner of written notice thereof from Distribution Company, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(h) Any representation or warranty made by Owner in this Agreement is false or misleading at the time made in any material respect.
(i) Any Insolvency Event occurs with respect to Owner.
Section 14.3 Remedies Upon Distribution Company Default . Upon the occurrence of a Distribution Company Default and at any time thereafter so long as the same is continuing, Owner shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Owner shall elect:
(a) Subject to Section 5.6 hereof and Section 14.8 of the HQUS TSA: (i) in the case of Distribution Company Default under any clause of Section 14.1 other than clause (e), Owner may terminate this Agreement by written notice to Distribution Company, or (ii) in the case of a Distribution Company Default under clause (e) of Section 14.1 , Owner shall terminate this Agreement upon receipt of Distribution’s Company written request.
(b) In the case of a Distribution Company Default pursuant to Section 14.1(a) , and subject to Section 5.6 , Owner may suspend all or part of Owner’s obligations or Distribution Company’s rights under this Agreement during the period during which such Distribution Company Default is continuing. During any such period of suspension occurring after the Commercial Operation Date, (i) Distribution Company shall not be entitled to schedule, and shall not schedule, any transactions over the NECEC Transmission Line, and (ii) Owner shall be obligated, in the event HQUS so elects as provided in the HQUS TSA, to allow HQUS to assume the rights and obligations of Distribution Company under this Agreement during such suspension. If HQUS does not exercise the rights described in clause (ii) of the preceding sentence, (x) the OASIS Administrator shall be directed to post any portion of the transmission capacity that would have otherwise been available to Distribution Company over the NECEC Transmission Line pursuant to this Agreement and to attempt to sell such capacity to one or more third parties consistent with Article X , (y) the proceeds of any capacity releases and transmission resales made pursuant to clause (x) of this sentence and received by Owner, net of reasonable fees (including attorneys’ fees) and other expenses incurred by Owner in connection with this Section 14.3(b) , shall be credited against any accrued but unpaid payment obligation of Distribution Company to Owner hereunder and (z) any such proceeds in excess of such accrued but unpaid payment obligation of Distribution Company shall be credited in accordance with Section 10.5 .
40
(c) Subject to Article XVIII and this Section 14.3 , as applicable, Owner may recover from Distribution Company the Distribution Company Termination Payment and, to the extent applicable, all other amounts not waived in accordance with Section 3.3.4(c) or, in the absence of a termination pursuant to a Distribution Company Default, all damages suffered by Owner that are due to a Distribution Company Default, including, for the avoidance of doubt, any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Distribution Company under this Agreement.
(d) Owner may exercise any and all other rights and remedies that may be available to Owner against Distribution Company at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Owner shall have no right to (i) terminate this Agreement based upon a Distribution Company Default, except as provided in clause (a) above, or (ii) suspend transmission service under this Agreement based on a Distribution Company Default, except as provided in clause (b) above.
Section 14.4 Remedies Upon Owner Default . Upon the occurrence of an Owner Default and at any time thereafter so long as the same is continuing, Distribution Company shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Distribution Company shall elect:
(a) In the case of an Owner Default, and subject to Section 5.6 hereof, Distribution Company may recover any accrued but unpaid amounts under Section 4.4.1 and Section 4.4.2 and the Owner Termination Payment and (i) in the case of an Owner Default under any clause of Section 14.2 other than clause (c), Distribution Company may terminate this Agreement by written notice to Owner, or (ii) in the case of an Owner Default under clause (c) of Section 14.2 , this Agreement shall automatically be terminated; provided, however, in the event that HQUS exercises its right under the HQUS TSA to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under this Agreement prior to the effective date of such termination, no termination of this Agreement shall occur under this Section 14.4(a) . In the event that HQUS timely exercises such rights, (x) upon receipt of HQUS’s notice that it is exercising such rights, Owner shall promptly notify Distribution Company thereof and (y) upon the effectiveness of HQUS’ purchase or assumption of control of the NECEC Transmission Line and assumption of Owner’s obligations under this Agreement, (A) Distribution Company and HQUS shall enter into such amendments to this Agreement as are reasonably necessary in order to give effect to such rights of HQUS and assumptions of obligations by HQUS that are consistent with the terms and conditions of this Agreement and are subject to applicable regulatory approvals and (B) thereafter HQUS shall perform and Distribution Company shall continue to perform their respective obligations under this Agreement.
(b) Subject to the limitations provided in Section 4.4.1(d) , Section 4.4.2(c) , Article XVIII or this Section 14.4 , as applicable, Distribution Company may recover from Owner any accrued but unpaid amounts under Section 4.4.1 and Section 4.4.2 (as applicable) and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Distribution Company to recover any amounts owed to Distribution Company by Owner under this Agreement.
41
(c) Distribution Company may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Credit Support (including, for avoidance of doubt, the Owner Security) held by Distribution Company, and (ii) the right to liquidate any and all Credit Support held by Distribution Company and to apply the proceeds of such liquidation to any amounts payable to Distribution Company with respect to Owner’s obligations hereunder in such order as Distribution Company may elect. Distribution Company may draw on the undrawn portion of any Letter of Credit provided as Credit Support up to the amount of Owner’s outstanding obligations hereunder. Owner shall remain liable for amounts due and owed to Distribution Company that remain unpaid after the application of Credit Support.
(d) Pursuant to Section 13.2 , to the extent there is a Dispute over the amount of the damages suffered by Distribution Company as a result of an Owner Default, Distribution Company may deduct and setoff payment of such amount against any Transmission Service Payment upon the resolution of that Dispute.
(e) Distribution Company may exercise any and all other rights and remedies that may be available to Distribution Company at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Distribution Company shall have no right to (i) terminate this Agreement based upon an Owner Default, except as provided in clause (a) above, or (ii) any reduction of or offset against payments under this Agreement based upon an Owner Default, except as contemplated by Section 8.1 , Section 13.5 and Section 14.4(d) , as applicable.
Section 14.5 Abandoned Plant Recovery . Owner may request from FERC recovery of abandoned plant costs from Distribution Company in the event of the cancellation, termination and abandonment of the NECEC Transmission Line but (a) only if (i) due to the termination of this Agreement by either Party prior to the Commercial Operation Date, or (ii) due to the termination of this Agreement by Distribution Company following the Commercial Operation Date, or (iii) this Agreement is rendered null and void pursuant to Section 19.2(c), and (b) only if such cancellation, termination, and abandonment results from changes after the Effective Date in Massachusetts laws or regulations (including changes in the manner in which the law is applied by those acting under the color of Massachusetts laws or regulations) or changes in MDPU orders that invalidate this Agreement or the Distribution Company’s obligation to pay for Firm Transmission Service or to pay the Distribution Company Termination Payment under this Agreement. In no event will Owner be entitled to recover abandoned plant costs under any other circumstances or in the event that the cancellation, termination or abandonment was caused directly or indirectly by some act or failure to act on the part of Owner or HQUS or their respective affiliates, agents or contractors, including, without limitation, an Owner Default or a Default (as defined in the PPA) by HQUS under the PPA, and Owner agrees not to seek from FERC or any other agency or authority any treatment of abandonment costs inconsistent with this provision, in accordance with Section 2.2.2.6.2 of the request for proposals pursuant to which this Agreement has been executed. In any such case, Owner’s recovery shall be limited to the Proportionate Share of its costs related to the NECEC Transmission Line that were prudently incurred after March 31, 2017, provided that, for purposes of calculating the Proportionate Share, on or after the Commercial Operation Date the denominator of the “Proportionate Share” shall be 1,200 MW. Owner may only request recovery of abandoned plant costs up to the remaining amounts available under the cap on Distribution Company’s liability under Section 14.7.2 . Distribution Company
42
shall have the right to participate in such proceedings and to object to or seek to limit the recovery of any abandoned plant costs not expressly permitted to be recovered by Owner under this Section 14.5 or not consistent with FERC policy or precedent. Owner may not seek recovery under this Section 14.5 if it has been paid the Distribution Company Termination Payment.
Section 14.6 Disputes . Any Dispute over whether or not an Owner Default or Distribution Company Default has occurred shall be resolved in accordance with Article XVII .
Section 14.7 Limitations on Total Liability .
Section 14.7.1 Owner Liability . Notwithstanding anything herein to the contrary, Owner’s liability for any payments made to Distribution Company pursuant to Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.2(a) , or 14.4 shall not exceed, in aggregate, the Proportionate Share multiplied by One Hundred Twenty Million Dollars ($120,000,000).
Section 14.7.2 Distribution Company Liability . Notwithstanding anything herein to the contrary, Distribution Company’s liability for any payments made to Owner pursuant to Sections 3.3.4 , 3.4 , 14.3 , and 14.5 shall not exceed, in aggregate, the Proportionate Share multiplied by One Hundred Twenty Million Dollars ($120,000,000).
Section 14.7.3 Exceptions to Total Liability . The limits on liability set forth in Sections 4.4 and 14.7.1 shall not apply to any liability of Owner arising out of Owner’s gross negligence, willful misconduct (including willful breach of this Agreement), or fraud. The limits on liability set forth in Section 14.7.2 shall not apply to any liability of Distribution Company arising out of Distribution Company’s gross negligence, willful misconduct (including willful breach of this Agreement), or fraud.
Article XV
Section 15.1 Definition; Conditions .
(a) The term “ Force Majeure ” means an event or circumstance (i) that is not within the reasonable control of the Party claiming its occurrence; (ii) that could not have been prevented or avoided by such Party through the exercise of reasonable diligence and (iii) that prohibits or prevents such Party from performing its obligations under this Agreement. Under no circumstances shall Force Majeure include (w) any full or partial curtailment in the operation of the NECEC Transmission Line that is caused by or arises from a mechanical or equipment breakdown or other mishap or events or conditions attributable to normal wear and tear or flaws of the NECEC Transmission Line, unless such curtailment or mishap is caused by one of the following: acts of God such as floods, hurricanes, tornados, or other significantly unusual and abnormal weather conditions such as severe blizzards and severe ice storms; sabotage; terrorism or war; national or regional general strikes, lockouts or other labor disputes, (x) any occurrence or event that increases the costs or causes an economic hardship to a Party but is not otherwise a Force Majeure, (y) Owner’s ability to sell transmission service involving the NECEC Transmission Line at a price greater than that set out in this Agreement or (z) Distribution Company’s ability to procure transmission service at a price lower than that provided in this Agreement, or Distribution Company’s ability to purchase generation at a price lower than that provided in the PPA. In addition, a delay or inability to perform attributable to a Party’s lack of
43
preparation, a Party’s failure to timely obtain and maintain all necessary permits (excepting the Regulatory Approval other than the obligations to file for Regulatory Approval) or qualifications, any delay or failure to obtain the Owner Approvals, Canadian Approvals, or Municipal Owner Approvals, a failure to satisfy contractual conditions or commitments, or lack or deficiency in funding or other resources shall each not constitute a Force Majeure or be the basis for a claim of Force Majeure. Neither Party may raise a claim of Force Majeure based in whole or in part on the failure of HQUS to fulfill any of its obligations under the PPA (including without limitation related to the availability of the Quebec Line) unless such failure is due to “force majeure” as stated in Section 10.1 of the PPA.
(b) Subject to Section 15.1(a) , if either Party is unable, wholly or in part, by Force Majeure to perform its obligations under this Agreement, such performance shall be excused and suspended so long as the circumstances that give rise to such inability exist or would exist if the Party claiming the Force Majeure used commercially reasonable efforts to cure such circumstances, but for no longer period. The Party whose performance is affected shall give prompt notice thereof to the other Party; such notice may be given orally or in writing but, if given orally, it shall be promptly confirmed in writing, providing details regarding the nature, extent and expected duration of the Force Majeure, its anticipated effect on the ability of such Party to perform its obligations under this Agreement, and the estimated duration of any interruption in service or other adverse effects resulting from such Force Majeure, and shall be updated or supplemented to keep the other Party advised of the effect and remedial measures being undertaken to overcome the Force Majeure. Such inability to perform shall be promptly corrected to the extent it may be corrected through the exercise of due diligence consistent with Good Utility Practice. Neither Party shall be liable for any losses or damages arising out of a suspension of performance that occurs because of Force Majeure. Notwithstanding any such suspension of performance, Distribution Company shall be obligated to make Transmission Service Payments as though Firm Transmission Service was then being provided at or greater than the Minimum Average Availability.
(c) Notwithstanding the foregoing, if the Force Majeure prevents full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, the Party whose performance is not prevented by Force Majeure shall have the right to terminate this Agreement upon written notice to the other Party and without further recourse; provided, however, that if (i) Owner presents a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company, acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, to Distribution Company before the end of a period in which Owner’s provision of Firm Transmission Service has been prevented in whole or in part by an event of Force Majeure, Distribution Company shall forbear terminating this Agreement under this clause (c) for such period, provided that, during any such period, Distribution Company’s obligation to make Transmission Service Payments shall be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, Distribution Company may terminate this Agreement under
44
this clause (c). In no event will any delay or failure of performance caused by any conditions or events of Force Majeure extend this Agreement beyond its stated Term.
(d) A Party shall not be required to settle any strike, walkout, lockout or other labor dispute on terms that, in the sole judgment of such Party, are contrary to its interest. The settlement of strikes, walkouts, lockouts or other labor disputes shall be entirely within the discretion of the Party involved in such dispute.
FINANCIAL ASSURANCES
(a) Owner shall be required to post Credit Support in the amount of $123,170.00 (“ Owner Security ”) to secure Owner’s obligations under this Agreement in the period beginning on the Effective Date and continuing through and including the date that all of Owner’s obligations under this Agreement are satisfied. Fifty percent (50%) of the Owner Security shall be provided to Distribution Company within three (3) Business Days following the Execution Date; and the remaining fifty percent (50%) shall be provided to Distribution Company within fifteen (15) Business Days after receipt of the Regulatory Approval.
(b) If at any time during the Term of this Agreement, the amount of Credit Support is reduced as a result of Distribution Company’s draw upon such Credit Support, Owner shall replenish such Credit Support to the total amount required under this Section 16.1 within five (5) Business Days of that draw, provided that any replenishment obligation shall be subject to the limitations on total liability set forth in Section 14.7 .
(c) Any Cash provided by Owner as Credit Support under this Agreement shall be held in an account selected by Distribution Company in its reasonable discretion. Interest shall accrue on that Cash deposit at the daily Federal Funds Rate and shall be remitted to Owner upon written request to Distribution Company, with such request not more often than on a quarterly basis, and Distribution Company shall remit such accrued interest to the Owner within a reasonable time following receipt of such request. Owner agrees to comply with the commercially reasonable requirements of Distribution Company in connection with the receipt and retention of any Cash provided as Credit Support under this Agreement.
(d) Any unused Credit Support provided under this Agreement shall be returned to Owner only after any such Credit Support has been used to satisfy any outstanding obligations of Owner in existence at the time of the expiration or termination of this Agreement. Provided such obligations have been satisfied, such Credit Support shall be returned to Owner within thirty (30) days after the expiration or earlier termination of this Agreement.
45
(a) The Parties shall initially attempt to resolve any Dispute through consultations between the Parties. Subject to Section 17.2 and except as expressly provided otherwise in this Agreement, if a Dispute has not been timely resolved pursuant to this clause (a) within fifteen (15) Business Days after written notice of such Dispute has been given, then either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction; provided, however, if the Dispute is subject to Section 17.2 , then either Party may elect to proceed with the mediation through FERC's Dispute Resolution Service. If one Party fails to participate in the consultations provided for in this Section 17.1 , the other Party can initiate mediation prior to the expiration of the fifteen (15) Business Days. Unless otherwise agreed, the Parties will select a mediator from the FERC panel. The Parties may, by written agreement signed by both Parties, alter any time deadline, location(s) for meeting(s), or procedure outlined herein or in FERC’s rules for mediation. The procedure specified herein shall be the sole and exclusive procedure for the resolution of Disputes.
(b) All negotiations, consultations, and mediations pursuant to this Section 17.1 shall be deemed to be confidential and shall be treated as compromise and settlement negotiations, and no evidence with regard to any proposal made during such negotiations, consultations, or mediations shall be admissible in any FERC proceeding or filing under Section 17.2 or in any other judicial or other proceeding.
Section 17.2 Disputes to be Resolved by FERC .
(a) In the event a Dispute over any matter is not resolved in accordance with Section 17.1 , either Party shall have the right to file for relief with FERC to the extent that matter is within the primary or exclusive jurisdiction of the FERC. Nothing contained in this Agreement shall be construed as precluding a Party from filing any answer, protest or other opposition to any FERC filing made by the other Party, unless expressly prohibited under the terms of this Agreement.
(b) In the event any Dispute is submitted to FERC for resolution as provided in Section 17.2(a) , the Party submitting the Dispute to FERC shall be responsible for providing written notice of such filing to the other Interested Parties. Unless both Parties agree that the Dispute does not implicate any of the Proposal Agreements other than this Agreement, each Party consents and agrees that (i) each Interested Party is an interested party in the Dispute and (ii) in order to avoid inconsistent interpretations and adjudications of the Proposal Agreements, any Interested Party may, without objection from any other Interested Party, whether by means of joinder, consolidation or otherwise, submit such matters as it considers sufficiently related to the Dispute to FERC to be jointly determined by FERC with the Dispute. Notwithstanding the foregoing, in the event FERC determines that it does not have the jurisdiction to, or otherwise does not want to, hear or determine any portion of a Dispute or other matter so referred to FERC, either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction.
46
Section 17.3 Consent to Jurisdiction . Subject to Section 17.2 , each Party agrees that any legal action or proceeding with respect to or arising out of this Agreement or any other Proposal Agreement shall be brought in or removed to the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts that has subject matter jurisdiction and any appellate court from any thereof. By execution and delivery of this Agreement, each Party hereby accepts for itself and in respect of its property, generally and unconditionally, the jurisdiction of the aforesaid courts. The Parties irrevocably consent to the service of process out of any of the aforementioned courts in any such action or proceeding by the mailing of copies thereof by registered or certified airmail, postage prepaid, to the applicable Party at its respective addresses for notices as specified in Section 23.4 . Nothing herein shall affect the right to serve process in any other manner permitted by law. Each Party hereby waives any right to stay or dismiss any action or proceeding under or in connection with this Agreement or any other Proposal Agreement brought before the foregoing courts on the basis of forum non-conveniens.
Section 17.4 WAIVER OF JURY TRIAL . EACH PARTY IRREVOCABLY AND UNCONDITIONALLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY LEGAL ACTION, PROCEEDING, CAUSE OF ACTION, OR COUNTERCLAIM ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.
Article XVIII
NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, NEITHER PARTY NOR ANY OF ITS AGENTS, SUBCONTRACTORS, REPRESENTATIVES OR AFFILIATES SHALL BE LIABLE TO THE OTHER PARTY FOR PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE (EXCEPT AS EXPRESSLY CONTEMPLATED IN THIS AGREEMENT, INCLUDING IN Section 4.4 , OR FOR ANY DIRECT DAMAGES SUFFERED BY DISTRIBUTION COMPANY AS A RESULT OF A BREACH BY OWNER OF ITS OBLIGATIONS UNDER Section 6.2 , Article X OR Section 11.2 ), IN EACH CASE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OF THIS AGREEMENT, AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY).
FOR THE AVOIDANCE OF DOUBT, THE PARTIES ACKNOWLEDGE AND AGREE THAT Section 4.4 OR Section 7.3 PROVIDE THE SOLE AND EXCLUSIVE REMEDIES FOR ANY LOSS OF USE CONTEMPLATED BY Section 4.4 OR Section 7.3 AND NOTHING IN Section 6.2 , Article X OR Section 11.2 SHALL SUPERSEDE, SUPPLEMENT OR AMEND SUCH SOLE AND EXCLUSIVE REMEDIES.
THIS ARTICLE XVIII IS IN ADDITION TO THE SPECIFIC LIMITATIONS ON REMEDIES REFERENCED IN ARTICLE XIV , SECTION 4.4.1 , AND SECTION 4.4.2 .
47
MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES.
Section 19.1 Modifications . The Parties specifically intend and acknowledge and agree that, except as otherwise expressly provided in this Agreement, (a) this Agreement shall not be subject to amendment or other modification, absent the written agreement of both Parties and (b) neither Party shall be permitted to make a filing with FERC under any provision of the Federal Power Act or the regulations promulgated thereunder that seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement at any time during the Term, except to implement an amendment or other modification to this Agreement that has been reduced to writing and signed by both Parties. In addition, to the extent any third party, or FERC acting sua sponte seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement, the standard of review for any proposed amendment or other modification shall be the “public interest” standard of review set forth in United Gas Pipe Line Co. v. Mobile Gas Service Corp., 350 U.S. 332 (1956), and Federal Power Commission v. Sierra Pacific Power Co., 350 U.S. 348 (1956), and as further defined in Morgan Stanley Capital Group, Inc. v. Public Utility District No. 1 of Snohomish County, 128 S. Ct. 2733 (2008) and NRG Power Marketing, LLC v. Maine Public Utilities Commission, 130 S. Ct. 693 (2010).
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment .
(a) This Agreement is subject to the ISO-NE Rules. If, during the Term, any ISO-NE Rule is terminated, modified or amended, or is otherwise no longer applicable, resulting in a material alteration of a material right or obligation of a Party hereunder, the Parties agree to negotiate in good faith in an attempt to amend or clarify this Agreement to embody the Parties’ original intent regarding their respective rights and obligations under this Agreement, provided that neither Party shall have any obligation to agree to any particular amendment or clarification of this Agreement. The intent of the Parties is that any such amendment or clarification reflect, as closely as possible, the intent, substance and effect of the ISO-NE Rule being replaced, modified, amended, or made inapplicable as such ISO-NE Rule was in effect prior to such termination, modification, amendment, or inapplicability; provided that such amendment or clarification shall not in any event alter (i) the purchase and sale obligations of the Parties pursuant to this Agreement or (ii) the Transmission Service Payment. In the event the Parties cannot agree upon such amendments within sixty (60) days after such ISO Rule or ISO-NE Practice change described above, the Dispute shall be resolved in accordance with Article XVII .
(b) If, during the Term, there is a change in Applicable Law (other than tax laws or regulations) or accounting standards or rules or a change in the interpretation or applicability thereof that would result in (i) material adverse balance sheet or creditworthiness impacts on Distribution Company associated with this Agreement or the amounts paid for Firm Transmission Service purchased hereunder, or (ii) an adverse impact on the economic benefits (including those stemming from the fiscal conditions provided for herein) that Owner enjoys under this Agreement or that are provided for herein for Owner during the Term, the Parties shall use commercially reasonable efforts to agree to an amendment to the Agreement to avoid or mitigate such impacts and restore the economic benefits to each affected Party; provided that such amendment mitigates any
48
material adverse effect(s) on each non-affected Party (as identified by each such Party, acting reasonably) that could reasonably be expected to result from such amendment, but only to the extent that such mitigation can be accomplished in a manner that is consistent with the purpose of such amendment. I n the event the Parties cannot agree on an amendment in accordance with this Section 19.2(b) , the dispute shall be resolved in accordance with Article XVII .
(c) Upon a determination by a court or regulatory body having jurisdiction over this Agreement or any of the Parties, or over the establishment and enforcement of any of the statutes or regulations or orders or actions of regulatory agencies (including the MDPU) supporting this Agreement or the rights or obligations of the Parties hereunder that any of the statutes or regulations supporting this Agreement or the rights or obligations of the Parties hereunder, or orders of or actions of regulatory agencies (including the MDPU) implementing such statutes or regulations, or this Agreement on its face or as applied, violates any Applicable Law (including the State or Federal Constitution) (an “ Adverse Determination ”), each Party shall have the right to suspend performance under this Agreement without liability. Owner may provide transmission service to a third party during any period of time for which Distribution Company suspends payments under this Section 19.2(c) . Upon an Adverse Determination becoming final and non-appealable, this Agreement shall be rendered null and void.
(d) For the avoidance of doubt, it is understood that the provisions of Article XVII regarding dispute resolution apply to any Dispute under this Article XIX .
Article XX
Section 20.1 Owner Indemnity . Owner shall indemnify, defend and hold harmless Distribution Company and Distribution Company’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, a “ Distribution Company Indemnified Party ” ) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Distribution Company Indemnified Party, including any such liabilities incurred by a Distribution Company Indemnified Party under the PPA, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Distribution Company Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Distribution Company Indemnified Party.
Section 20.2 [Intentionally Omitted]
49
Section 20.3 Procedures . Promptly after the receipt by any Person seeking indemnification under this Article XX (the “ Indemnified Party ” ) of written notice of the assertion of any claim by a third party with respect to any matter in respect of which indemnification may be sought hereunder (a “ Third Party Claim ” ), the Indemnified Party shall give written notice (the “ Indemnification Notice ” ) to Owner and shall thereafter keep Owner reasonably informed with respect thereto; provided, however, that the failure of the Indemnified Party to give the Indemnifying Party notice as provided herein shall not relieve Owner of any of its obligations hereunder, except to the extent that Owner is materially prejudiced by such failure. Owner shall be entitled to assume the defense of any Third Party Claim by written notice to the Indemnified Party of such intention given within thirty (30) days after the receipt by Owner of the Indemnification Notice; provided, however, that counsel selected by the Indemnifying Party shall be reasonably satisfactory to Owner. Owner shall be liable for the fees and expenses of counsel employed by the Indemnified Party for any period during which Owner has not assumed the defense of any Third Party Claim (other than during any period during which the Indemnified Party has failed to give notice of such Third Party Claim as provided above). If Owner shall assume the defense of the Third Party Claim, then the Owner shall not compromise or settle such Third Party Claim without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld, delayed or conditioned; provided, however, that the Indemnified Party shall have no obligation to consent to any settlement that (a) does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff of a release of the Indemnified Party from all liability with respect to such Third Party Claim or (b) involves the imposition of equitable remedies or the imposition of any material obligations on such Indemnified Party other than financial obligations for which such Indemnified Party is indemnified hereunder. As long as the Owner is contesting any such Third Party Claim on a timely basis, the Indemnified Party shall not pay, compromise or settle any claims brought under such Third Party Claim. Notwithstanding the assumption by the Owner of the defense of any Third Party Claim as provided in this Section 20.3 , the Indemnified Party shall be permitted to participate in the defense of such Third Party Claim and to employ counsel at its own expense (it being understood that Owner controls such defense); provided, however, that, if the defendants in any Third Party Claim shall include both an Owner and any Indemnified Party, and such Indemnified Party shall have reasonably concluded that counsel selected by Owner has a conflict of interest because of the availability of different or additional defenses to such Indemnified Party, such Indemnified Party shall then have the right to select separate counsel to participate in the defense of such Third Party Claim on its behalf, at the expense of Owner; provided that the Owner shall not be obligated to pay the expenses of more than one separate counsel for all Indemnified Parties, taken together.
Section 20.4 Defenses . If Owner shall fail to notify the Indemnified Party of its desire to assume the defense of any Third Party Claim within the prescribed period of time, or shall notify the Indemnified Party that it will not assume the defense of any such Third Party Claim, then the Indemnified Party may assume the defense of any such Third Party Claim, in which case it may do so acting in good faith and otherwise in such manner as it may deem appropriate, and the Owner shall be bound by any determination made in such Third Party Claim.
Section 20.5 Cooperation . The Indemnified Party and Owner shall each cooperate fully (and shall each cause its Affiliates to cooperate fully) with the other in the defense of any Third Party Claim pursuant to this Article XX. Without limiting the generality of the foregoing, each such Person shall furnish the other such Person (at the expense of the Owner) with such documentary or other evidence as is then in its or any of its Affiliates’ possession, as may reasonably be requested by the other Person for the purpose of defending against any such Third Party Claim.
50
Section 20.6 Recovery . The amount of any indemnity hereunder shall be reduced by any insurance proceeds actually recovered by the Indemnified Party in connection with the Third Party Claim. If at any time subsequent to the receipt by an Indemnified Party of an indemnity payment hereunder, such Indemnified Party (or any Affiliate thereof) receives any recovery, settlement or other similar payment with respect to the Third Party Claim for which it received such indemnity payment (a “ Recovery ” ), such Indemnified Party shall then promptly pay to the Owner the amount of such Recovery, less any expenses incurred by such Indemnified Party (or its Affiliates) in connection with such Recovery, but in no event shall any such payment exceed the amount of such indemnity payment.
Section 20.7 Subrogation . To the extent the Owner makes or is required to make any indemnity payment to the Indemnified Party, the Owner shall be entitled to exercise, and shall be subrogated to, any rights and remedies (including rights of indemnity, rights of contribution and other rights of recovery) that the Indemnified Party or any of its Affiliates may have against any other Person with respect thereto, whether directly or indirectly related. The Indemnified Party shall permit the Owner to use the name of the Indemnified Party and the names of the Indemnified Party’s Affiliates in any transaction or in any proceeding or other matter involving any of such rights or remedies; and the Indemnified Party shall take such actions as the Owner may reasonably request for the purpose of enabling the Owner to perfect or exercise its right of subrogation hereunder.
Article XXI
REPRESENTATIONS, WARRANTIES AND COVENANTS
Section 21.1 Mutual Representations and Warranties . Each Party hereby represents and warrants to the other Party that all of the statements in this Section 21.1 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of (i) the Effective Date and (ii) the Commercial Operation Date , but not as of any other date:
(a) It has knowledge and experience in financial matters and in the electric industry that enable it to evaluate the merits and risks of this Agreement and the transactions contemplated hereby, and is capable of evaluating such merits and risks and assuming such risks. It is acting for its own account, has made its own independent decision to enter into this Agreement as to whether this Agreement is appropriate and proper for it based upon its own judgment, is not relying upon the advice or recommendations of the other Party in doing so, and understands and accepts the terms, conditions, and risks of this Agreement and the transactions contemplated hereby;
(b) It has entered into this Agreement in connection with the conduct of its business;
(c) It is not acting as a fiduciary or an advisor with respect to this Agreement or the transactions contemplated hereby;
(d) It is not subject to an Insolvency Event and there are no proceedings pending or being contemplated by it or, to its knowledge, threatened against it that could result in the occurrence of an Insolvency Event with respect to it; and
51
(e) It is an entity subject to the procedures and substantive provisions of the Bankruptcy Code applicable to U.S. corporations or limited liability companies, as applicable, generally.
Section 21.2 Additional Representations and Warranties of Owner . Owner hereby represents and warrants to Distribution Company that all of the statements in this Section 21.2 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Owner is duly organized, validly existing, and in good standing under the laws of the State of Maine and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Owner, and Owner has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Owner has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Owner;
(c) Assuming due authorization, execution and delivery by Distribution Company, this Agreement constitutes Owner’s legal, valid and binding obligation enforceable against Owner in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Owner or any of its Affiliates that could have a Material Adverse Effect on Owner;
(e) No event with respect to Owner has occurred or is continuing that would constitute an Owner Default, and no Owner Default will occur as a result of Owner entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Owner does not and will not (i) violate any provisions of its articles of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The FERC Authorizations, Owner Approvals, Municipal Owner Approvals, and the AC Upgrade Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary to commence construction of and operate the NECEC Transmission Line;
(i) Owner has acquired all required real property rights necessary for construction and operation of the NECEC Transmission Line, and the interconnection of the NECEC Transmission Line with (A) the Québec Line (other than real property rights to be held by TransÉnergie) and (B) the Delivery Point, in full and final form with all options or contingencies having been exercised as set forth in Attachment I; and
52
(h) Owner is in compliance with all Applicable Laws, except such non-compliance as could not reasonably be expected to have a Material Adverse Effect on Owner. Owner has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Owner.
Section 21.3 Additional Representations and Warranties of Distribution Company . The Distribution Company hereby represents and warrants to Owner that all of the statements in this Section 21.3 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Distribution Company is duly organized, validly existing and in good standing under the laws of the Commonwealth of Massachusetts and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Distribution Company, and Distribution Company has all requisite power and authority to conduct its business, own its properties and to execute, deliver and perform its obligations under this Agreement;
(b) Distribution Company has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Distribution Company;
(c) Assuming due authorization, execution and delivery by Owner, this Agreement constitutes Distribution Company’s legal, valid and binding obligation enforceable against Distribution Company in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Distribution Company or any of its Affiliates that could have a Material Adverse Effect on Distribution Company;
(e) No event with respect to Distribution Company has occurred or is continuing that would constitute a Distribution Company Default, and no Distribution Company Default will occur as a result of Distribution Company entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Distribution Company does not and will not (i) violate any provisions of its certificate of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The Regulatory Approval constitutes the only action, Consent, notification, waiver, order or filing that is necessary with respect to the execution, delivery and performance of this Agreement by Distribution Company; and
53
(h) Distribution Company is in compliance with all Applicable Laws, except such non-compliances as could not reasonably be expected to have a Material Adverse Effect on Distribution Company. Distribution Company has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Distribution Company.
(i) Distribution Company has not taken and will not take any action (including providing support or information to any Affiliate of Distribution Company) to directly or indirectly oppose or prevent the achievement of any Governmental Approval, Third Party Consent, or other milestone or requirement set forth in this Agreement.
Section 21.4 NO OTHER REPRESENTATIONS OR WARRANTIES . THE REPRESENTATIONS AND WARRANTIES OF OWNER SET FORTH IN Section 21.1 AND Section 21.2 ARE OWNER’S SOLE REPRESENTATIONS AND WARRANTIES ASSOCIATED WITH THE NECEC TRANSMISSION LINE AND ARE MADE IN LIEU OF ALL OTHER REPRESENTATIONS, WARRANTIES AND GUARANTEES, EXPRESS OR IMPLIED, ASSOCIATED WITH THE NECEC TRANSMISSION LINE, INCLUDING REPRESENTATIONS OR WARRANTIES AS TO MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE. THE FOREGOING SENTENCE SHALL NOT BE CONSTRUED IN ANY WAY TO LIMIT OWNER’S EXPRESS OBLIGATIONS UNDER THIS AGREEMENT.
Article XXII
Section 22.1 No Transfer of Interests .
(a) Any (i) direct or indirect change of Control of any Party (whether voluntary or by operation of law), (ii) sale, transfer or other disposition of all or substantially all of the assets of any Party or (iii) except as provided in Section 22.2 or Section 22.3 , assignment, transfer or other disposition of, whether to one or more assignees or transferees, all or any portion of any Party’s rights, interests or obligations under this Agreement (each of the foregoing, a “ Transfer ”), shall require the prior written consent of the other Party, which consent shall not be unreasonably withheld, delayed or conditioned when viewed in light of all reasonable considerations, including the security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer); provided that any direct or indirect transfer of securities or other ownership interests in a Party to the Party’s Affiliate shall not be considered a Transfer for the purposes of this Section 22.1 and shall not require consent. Any Transfer in contravention of this Article XXII shall be null and void.
(b) If Owner consents to a Transfer by Distribution Company pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Distribution Company’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Owner of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that a Distribution Company Default shall not have occurred and be continuing, (x) the obligations of Distribution Company shall terminate to the extent of
54
the Transferred portion of this Agreement, and Distribution Company shall be fully, finally and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Distribution Company Owner shall execute and deliver to Distribution Company a full, final, and unconditional release of any Credit Support or guarantees provided by Distribution Company, in such form as Distribution Company may reasonably request, with respect to the Transferred portion of this Agreement.
(c) If Distribution Company consents to a Transfer by Owner pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee of Owner’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Distribution Company of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that an Owner Default shall not have occurred and be continuing (x) the obligations of Owner shall terminate to the extent of the Transferred portion of this Agreement, and Owner shall be fully, finally and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Owner, Distribution Company shall execute and deliver to Owner a full, final and unconditional release of any Credit Support or guarantees provided by Owner hereunder, in such form as Owner may reasonably request, with respect to the Transferred portion of this Agreement .
(d) Nothing herein shall prevent Distribution Company or any assignee thereof from transferring or assigning transmission service rights pursuant to FERC rules and regulations, including pursuant to Section 20 of the PPA.
Section 22.2 Exceptions . Notwithstanding Section 22.1 , consent shall not be required for any of the following:
(a) Distribution Company shall have the right to assign this Agreement without consent of Owner:
(i) to a successor in interest in any merger or consolidation of Distribution Company with or into another Person or any exchange of all of the common stock or other equity interests of Distribution Company or Distribution Company’s parent for cash, securities or other property or any acquisition, reorganization, or other similar corporate transaction involving all or substantially all of the common stock or other equity interests in, or assets of, Distribution Company so long as (1) the proposed assignee’s credit rating is at least either BBB- from S&P or Baa3 from Moody’s, or (2) the proposed assignee’s credit rating is equal to or better than that of Distribution Company at the time of the proposed assignment, or (3) the transaction associated with such assignment, has been approved by the MDPU or the appropriate Government Entity, in each case, with an express assumption of Distribution Company’s obligations hereunder in writing, reasonably acceptable to Owner and Distribution Company, if such assumption does not occur under Applicable Law; or
55
(ii) to any substitute purchaser of the Products so long as (1) the proposed assignee’s credit rating is at least either BBB- from S&P or Baa3 from Moody’s, and (2) the proposed assignee’s credit rating is equal to or better than that of Distribution Company at the time of the proposed assignment, and, if required, (3) such assignment has been approved by the MDPU or the appropriate Government Entity, in each case, with an express assumption of Distribution Company’s obligations hereunder in writing, reasonably acceptable to Owner and Distribution Company. For purposes of clarification, a disposition of this Agreement pursuant to this clause (ii) includes an assignment to any third party other than the successor in interest in connection with a transaction to which clause (i) applies.
(b) any (i) change of Control of Owner or (ii) transfer or other disposition of all or substantially all of the assets of Owner, in each case, resulting from a collateral assignment in favor of a financing party in accordance with Section 22.3 ;
(c) any change of Control of Owner resulting from any direct or indirect change of Control in Owner’s ultimate parent company (currently, Iberdrola, S.A.), Owner’s ultimate parent company in the United States (currently AVANGRID, Inc.) or in the parent company for the network business in the United States of which Owner is part (currently Avangrid Networks, Inc.); or
(d) the exercise of any of HQUS’s or the Distribution Company’s rights pursuant to Section 14.7, 14.8(a) or 14.8(b) of the HQUS TSA.
Section 22.3 Collateral Assignment . Owner shall be entitled, without restriction, to make one or more assignments of this Agreement for purposes of collateral security or any or all of its rights and benefits hereunder to or for the benefit of any and all secured lenders to Owner, or grant to or for the benefit of any and all secured lenders to Owner a lien on, or security interest in, any right, title or interest in all or any part of Owner’s rights hereunder for the purpose of the financing or successive refinancing of the ownership, development, engineering, construction or operation of the NECEC Transmission Line; provided, however, that such assignment for purposes of collateral security shall recognize Distribution Company’s rights under this Agreement on terms and conditions as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner. To facilitate Owner’s obtaining of financing or successive refinancing for the ownership, development, engineering, construction or operation of the NECEC Transmission Line, Distribution Company shall cooperate with Owner and shall execute and deliver such consents, acknowledgements, direct agreements or similar documents as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner.
MISCELLANEOUS
Section 23.1 Governing Law . This Agreement and each of its provisions shall be governed by, and construed in accordance with, the laws of the Commonwealth of Massachusetts.
56
Section 23.2 Entire Agreement . This Agreement, together with the Attachments, constitutes the entire Agreement and understanding between the Parties with respect to all subjects covered hereby and thereby and supersedes all prior discussions, agreements and understandings between the Parties with respect to such matters.
Section 23.3 Severability . Except as otherwise provided in Section 2.2 or Section 19.2 , (a) in the event any part of this Agreement is held to be illegal, invalid or unenforceable to any extent, the legality, validity and enforceability of the remainder of this Agreement shall not be affected thereby, and shall remain in full force and effect and shall be enforced to the greatest extent permitted by Applicable Law and (b) with respect to any provision found to be illegal, invalid or unenforceable, the Parties shall endeavor to replace such invalid, illegal or unenforceable provision with the valid, legal and enforceable provision that achieves, as nearly as practicable, the commercial intent of this Agreement (as it may be amended from time to time).
Section 23.4 Notices . All notices, billings, requests, demands, waivers, consents and other communications under this Agreement shall be in writing and shall be effective (a) upon personal delivery thereof, including by overnight mail or courier service, with a record of receipt, (b) in the case of notice by United States mail, certified or registered, postage prepaid, return receipt requested, upon the fourth (4th) day after mailing, (c) in the case of notice by facsimile for any communications other than billings, upon transmission; provided that such facsimile transmission is promptly confirmed by either of the methods set forth in the foregoing clause (a) or (b), in each case, addressed to each Party and copy party hereto at its address set forth below or at such other address as a Party may from time to time designate by written notice to the other Party pursuant to this Section 23.4 , (d) in the case of notice by facsimile for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon receipt of confirmation of successful transmission, but without any further requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b), or (e) in the case of notice by electronic mail for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon transmission, without any requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b); provided that the Party delivering such notice did not receive any notice of unsuccessful or delayed transmission. A notice given in connection with this Section 23.4 but received on a day other than a Business Day, or after business hours at the location of receipt, shall be deemed to be received on the next Business Day.
If to Owner:
Central Maine Power Company
Attn: Douglas Herling, President & CEO
83 Edison Drive, Augusta ME 04336
207-626-9779
With a copy to:
Central Maine Power Company
Attn: Legal Department
83 Edison Drive, Augusta ME 04336
57
Pierce Atwood LLP
Attn: Jared des Rosiers
254 Commercial St., Portland ME 04101
If to Distribution Company:
Robert S. Furino
Director, Energy Contracts
Unitil Service Corp.
Six Liberty Lane West
Hampton, NH 03842
Tel (603) 773-6452
Fax (603) 773-6652
Email: furino@unitil.com
With a copy to:
Gary Epler, Esq.
Chief Regulatory Counsel
Unitil Service Corp.
Six Liberty Lane West
Hampton, NH 03842
Tel (603) 773-6440
Fax (603) 773-6605
Email: epler@unitil.com
Section 23.5 Intentionally Omitted .
Section 23.6 Waivers; Cumulative Remedies .
Any term or condition of this Agreement may be waived at any time by the Party that is entitled to the benefit thereof, but such waiver shall not be effective unless set forth in a written instrument duly executed by or on behalf of the Party waiving such term or condition. No waiver by any Party of any term or condition of this Agreement, in any one or more instances, shall be deemed to be, or construed as, a subsequent waiver of, or estoppel with respect to, the same or any other term or by Applicable Law. Except as otherwise provided in Section 13.2(b) , the failure of or delay on the part of any Party to enforce or insist upon compliance with or strict performance of any term or condition of this Agreement, or to take advantage of any of its rights thereunder, shall not constitute a waiver or relinquishment of any such terms, conditions, or rights, but the same shall be and remain at all times in full force and effect. Except as otherwise provided herein, the remedies provided in this Agreement are cumulative and not exclusive of any remedies provided by law or in equity.
58
Section 23.7 Confidential Information . Each Party hereby agrees that it shall not disclose, or cause to be disclosed, to third parties any Confidential Information with respect to the other Party or any material or information identified as Critical Energy Infrastructure Information (other than to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential). Notwithstanding the foregoing, each Party may disclose information related to this Agreement to another party to a Proposal Agreement or to Trans É nergie only if necessary to comply with its obligations hereunder or thereunder or to coordinate the parties’ obligations under different Proposal Agreements. Each Party shall be responsible for ensuring that any Person to whom it discloses any Confidential Information shall comply with the restrictions in this Section 23.7 . The restrictions in this Section 23.7 shall not apply (w) to the extent disclosure is required by Applicable Law or the requirements of a Governmental Authority (including a court order, oral questions, written interrogatories, request for information or documents, subpoena, or similar process, or the requirements of any stock exchange or other Governmental Authority to which the Parties, or any of their Affiliates are subject), (x) to the extent reasonably deemed by the disclosing Party to be required or desirable in connection with regulatory proceedings (including proceedings relating to FERC or any other national, federal, provincial, state or regulatory agency), (y) to the extent reasonably deemed by the disclosing Party to be required to be disclosed in connection with a Dispute between the Parties, or the defense of any litigation or dispute, or (z) as approved for release or disclosure by the Party whose Confidential Information is at issue. In the event disclosure is made pursuant to this Section 23.7 and except for disclosures pursuant to the requirements of securities laws or any stock exchange, the disclosing Party shall use reasonable efforts to minimize the scope of any disclosure and advise recipients of any applicable confidentiality restrictions provided herein. Notwithstanding the foregoing, this Section 23.7 shall not apply to the following information:
(a) Information that is a matter of public knowledge at the time of its disclosure or is thereafter published in or otherwise ascertainable from a source available to the public without breach of this Section 23.7 ;
(b) Information that is obtained from a Person other than by or as a result of unauthorized disclosure; or
(c) Information that, prior to the time of disclosure, had been independently developed or obtained by the disclosing Party or its Affiliates independent of information obtained as a result of unauthorized disclosure.
Section 23.8 No Third-Party Rights . Except for any secured lenders contemplated by Section 22.3 and any Distribution Company Indemnified Party contemplated by Article XX , and except for HQUS (which is intended to be a third party beneficiary of this Agreement solely to the extent of its capacity as an assignee of transmission rights as set forth in Section 20 of the PPA and for the purposes of and as contemplated by Article X of this Agreement, in light of its rights to purchase or assume control of the NECEC Transmission Line and assume Owner’s obligations under this Agreement pursuant to Section 14.7 of the HQUS TSA, and with respect to Sections 1.1 , 3.3.1 - 3.3.7 , 5.3 , 5.5.1 , 11.1 , 23.7 , and Articles II , IV , VII , VIII , XIV , XV , and XVII ), the Parties do not intend for this Agreement to confer a third-party beneficiary status or rights of action upon any Person whatsoever other than the Parties and their permitted successors and assigns, and nothing contained herein, either express or implied, shall be construed to confer upon any Person, other
59
than the Parties and their permitted successors and assigns, any rights of action or remedies under this Agreement or in any manner, or any duty, standard of care, or liability with respect thereto. This Agreement does not create any third-party rights, except as expressly stated above in this Section 23.7 .
Section 23.9 Permitted Successors and Assigns . This Agreement shall be binding upon and inure to the benefit of each of the Parties and their permitted successors, legal representatives and assigns.
Section 23.10 Relationship of the Parties . This Agreement shall not be construed as creating an association, joint venture, trust or partnership between the Parties or as imposing any partnership obligation or liability upon either Party. Except as contemplated by Article X , neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.
Section 23.11 Construction . No presumption shall operate in favor of or against either Party as a result of any responsibility for drafting this Agreement.
Section 23.12 Counterparts . This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument. The Parties acknowledge and agree that any document or signature delivered by facsimile or electronic transmission shall be deemed to be an original executed document for all purposes hereof.
Section 23.13 Survival . The provisions of Section 3.3 , Section 3.4 , Section 8.2 , Article IX , Article XIII , Article XIV , Article XVII , Article XVIII , Article XIX , Article XX and this Article XXIII shall survive the expiration or earlier termination of this Agreement.
Section 23.14 Headings and Table of Contents . The headings of the articles and sections of this Agreement and the Table of Contents are inserted for purposes of convenience only, and shall not be construed to affect the meaning or construction of any of the provisions hereof.
Section 23.15 Waiver of Immunities . The Parties acknowledge and agree that this Agreement and the transactions contemplated hereby constitute a commercial transaction. To the extent a Party (including any assignees of a Party’s rights or obligations under this Agreement) may be entitled, in any jurisdiction, to claim for itself, or any of its assets, revenues or properties, sovereign or other immunity, as the case may be, from service of process, suit, the jurisdiction of any court or arbitral tribunal, attachment (whether in aid of execution or otherwise) or enforcement of a judgment (interlocutory or final) or award or any other legal process in a matter arising out of or relating to this Agreement, each Party agrees not to claim or assert, and hereby waives, such immunity. Without limiting the generality of the foregoing, each Party agrees that the waivers set forth in this Section 23.15 shall have the fullest scope permitted under the Immunities Act and under any other Applicable Law related to sovereign immunity.
[ Signature pages follow ]
60
IN WITNESS WHEREOF, Owner and Distribution Company have executed this Agreement as of the Execution Date.
|
OWNER: |
|
|
|
|
|
CENTRAL MAINE POWER COMPANY |
|
|
|
|
|
By: |
/s/ Douglas Herling |
|
Name: |
Douglas Herling |
|
Title: |
President & CEO |
|
|
|
|
By: |
/s/ Eric Stinneford |
|
Name: |
Eric N. Stinneford |
|
Title: |
Vice President, Controller, & Treasurer |
|
|
|
|
DISTRIBUTION COMPANY: |
|
|
|
|
|
FITCHBURG GAS AND ELECTRIC LIGHT COMPANY D/B/A UNITIL |
|
|
|
|
|
By: |
/s/ Mark H. Collin |
|
Name: |
Mark H. Collin |
|
Title: |
Senior Vice President |
1
Description of Transmission Projects
The Québec Line and the NECEC Transmission Line consist in their entirety of:
|
(1) |
New 207 mile (145.3 miles in Maine) +/- 320 kV overhead HVDC transmission line that will run between the existing Appalaches Substation in Thetford Mines, Québec and a new HVDC converter station approximately 1.6 miles from the existing Larrabee Road Substation in Lewiston, Maine; |
|
(2) |
New HVDC converter stations at both ends of the transmission line; and |
|
(3) |
Certain upgrades to the existing high voltage alternating current (AC) New England transmission system necessary to permit the interconnection and transmission of Hydro Generation to the New England Control Area (as defined in the ISO-NE Tariff) at the existing Larrabee Road substation under the requirements of Section I.3.9 and the CCIS of ISO-NE Tariff. |
|
(4) |
System upgrades to the existing Québec transmission system as determined by the Hydro-Québec TransÉnergie System Impact Study (OASIS #203T), as it may be updated. |
Owner is the developer of the portion of the NECEC Transmission Line from the Québec-Maine border to the Lewiston area and all transmission upgrades on the U.S. side of the border. The NECEC Transmission Line and the Québec Line are expected to connect at the Québec-Maine border in the northwest corner of Maine in Beattie Township.
The Québec Line will be constructed by TransÉnergie, a division of Hydro-Québec and an Affiliate of HQUS.
Owner will construct, own, operate and maintain the NECEC Transmission Line, which will be constructed in existing transmission corridors owned by Owner.
The NECEC Transmission Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 145.3 mile +/-320 kV HVDC transmission line from the Canadian Border to a new converter substation located on Merrill Road in Lewiston |
|
ii. |
New 1.6 mile 345 kV AC transmission line from the new Merrill Road converter substation to the existing Larrabee Road substation |
A-1
|
i. |
New 345 kV AC to +/-320 kV HVDC 1200 MW Merrill Road converter substation |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Larrabee Road substation |
|
(2) |
Network Upgrades (subject to change based on ISO-NE system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
New 26.5 mile 345 kV AC transmission line from the existing Coopers Mills substation in Windsor to the existing Maine Yankee substation in Wiscasset |
|
ii. |
New 0.3 mile 345 kV AC transmission line from the existing Surowiec substation in Pownal to a new substation on Fickett Road in Pownal |
|
iii. |
Rebuild 9.3 mile 115 kV Section 62 AC transmission line from the existing Crowley Road substation in Sabattus to the existing Surowiec substation |
|
iv. |
Rebuild 16.1 mile 115 kV Section 64 AC transmission line from the existing Larrabee Road substation to the existing Surowiec substation |
|
v. |
Partial rebuild of 0.8 mile each of 115 kV section 60/88 outside Coopers Mills substation |
|
vi. |
Partial rebuild of 0.3 miles of 345 kV Section 392 AC transmission line between the Coopers Mills substation and the Maine Yankee substation and approximately 3.5 miles of reconductor work on existing double circuit lattice steel towers outside of the Maine Yankee substation |
|
vii. |
Partial rebuild of 0.3 miles of 345 kV Section 3025 between Coopers Mills substation and Larrabee Road substation |
|
viii. |
Partial rebuild 0.8 miles of 34.5 kV Section 72 AC transmission line outside of the Larrabee Road substation |
|
b. |
Substation Equipment: |
|
i. |
Replace existing Larrabee Road 345/115 kV 448 MVA autotransformer with a 600 MVA autotransformer |
A-2
|
iii. |
Add 345 kV AC transmission line terminal and 115 kV switch replacements at the existing Surowiec substation |
|
iv. |
115 kV Switch and bus wire replacements at Crowley substation |
|
v. |
New 345 kV Fickett Road substation with 345 kV +/-200 MVAr Static Compensator (STATCOM) |
|
vi. |
Add 345 kV AC transmission line terminal and additional 345 kV +/-200 MVAr STATCOM (+/-400 MVAr total with the +/-200 MVAr existing) at the existing Coopers Mills substation |
|
vii. |
Add 345/115 kV 448 MVA autotransformer, associated 115 kV buswork and terminate existing 115 kV Sections 164, 164A and 165 into three new breaker-and-a-half bays at the existing Raven Farm substation |
The NECEC transmission components located in Maine are depicted geographically in relationship to the existing Owner transmission system in Figure 1 below.
A-3
Figure 1 – Map Depicting the Components of the NECEC Transmission Line
A-4
The Québec Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 65 mile +/-320 kV HVDC transmission line from the Appalaches substation located in Thetford Mines to the U.S. border |
|
b. |
Substation Equipment : |
|
i. |
New +/-320 kV, 1200 MW HVDC converter connected to the 735 kV AC bus of the Appalaches substation and associated 735 kV bus work |
|
(2) |
Network Upgrades (subject to change based on additional system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
Thermal upgrade of existing 735 kV lines 7005 and 7035 (68 miles from Lévis substation to Nicolet substation) |
|
ii. |
Thermal upgrade of existing 735 kV line 7049 (44 miles from Montérégie substation to Hertel substation) |
|
b. |
Substation Equipment: |
|
i. |
Add two 200 MVAr shunt capacitor banks at the Carignan substation |
|
ii. |
Add one 330 MVAr shunt reactor at the Carignan substation |
A-5
Critical Milestones
Item |
Critical Milestone* |
Due Date** |
1. |
Closing of Any Required Financing |
March 7, 2019 |
2. |
Receipt of all Owner Approvals (other than Municipal Owner Approvals) and AC Upgrade Approvals in Final Form |
December 14, 2019 |
3. |
Receipt of all Canadian Approvals |
March 11, 2021 |
4. |
Receipt of all Municipal Owner Approvals |
March 31, 2022 |
5. |
Execution of Contract with the Manufacturer of the Converter Station at the Southern End of the HVDC Line and associated minimum 5% contract value payment |
July 30, 2019 |
6. |
Execution of Contract for the Engineering, Procurement, or Construction of the Converter Station on the Québec Line |
July 30, 2019 |
7. |
Commercial Operation Date |
December 13, 2022 |
* As defined in Section 4.1(a)
** Subject to extension in accordance with the Agreement.
A-6
Owner Approvals
Set forth below are the Governmental Approvals and Third Party Consents, in each case, required to commence construction of and operate the NECEC Transmission Line:
|
1. |
ISO-NE: Approval pursuant to Section I.3.9 of the ISO-NE Tariff to interconnect and operate the NECEC Transmission Line at no fewer than 1,040 MW |
|
2. |
Maine Public Utilities Commission (MPUC): Certificate of Public Convenience and Necessity (CPCN) |
|
3. |
U.S. Department of Energy (DOE): Presidential Permit |
|
4. |
Maine Department of Environmental Protection (MDEP): |
|
a. |
Site Location of Development Act (SLODA) Permit |
|
b. |
Stormwater Management Permit |
|
c. |
Natural Resources Protection Act (NRPA) Permit |
|
d. |
Clean Water Act (CWA) Section 401 Water Quality Certification |
|
e. |
Maine Construction General Permit |
The SLODA Permit, Stormwater Management Permit, NRPA Permit, and CWA Section 401 Water Quality Certification may be combined into one permit.
|
5. |
Maine Land Use Planning Commission (LUPC): Certificate of Compliance |
|
6. |
Maine Department of Agriculture, Conservation and Forestry: |
|
a. |
Submerged Lands Lease |
|
b. |
Public Reserved Land Lease |
|
7. |
Maine Department of Transportation (DOT): |
|
a. |
Utility Location/Road Opening Permits |
|
b. |
Driveway/Entrance Permits |
|
8. |
U.S. Army Corps of Engineers: |
|
a. |
CWA Section 404 - Individual Permit |
|
b. |
Section 10 Rivers & Harbors Act of 1899 |
|
9. |
Federal Aviation Administration Infrastructure in Vicinity of Airports: Determination of No Hazard to Air Navigation |
|
10. |
Municipal Owner Approvals: |
|
a. |
The Municipal Owner Approvals consist of the following types of permits: |
|
i. |
Shoreland zoning permits |
|
ii. |
Building permits |
|
iii. |
Flood hazard development permits |
A-7
|
v. |
Site plan / subdivision approvals |
|
vi. |
Driveway / entrance permits |
|
vii. |
Street opening, blasting and demolition permits |
|
viii. |
Utility location permits |
|
b. |
Owner shall obtain the Municipal Owner Approvals listed above that are necessary (if any) in the following municipalities for the NECEC Transmission Line, subject to any necessary exemptions issued by the MPUC relating to any Municipal Owner Approvals that are denied in any such municipalities or relating to any conditions contained in any Municipal Owner Approvals that are unacceptable to Owner: |
|
i. |
Alna |
|
xvi. |
Whitefield |
|
ii. |
Lewiston |
|
xvii. |
Greene |
|
iii. |
Anson |
|
xviii. |
Wilton |
|
iv. |
Livermore Falls |
|
xix. |
Industry |
|
v. |
Auburn |
|
xx. |
Windsor |
|
vi. |
Moscow |
|
xxi. |
Jay |
|
vii. |
Caratunk |
|
xxii. |
Wiscasset |
|
viii. |
New Gloucester |
|
xxiii. |
Leeds |
|
ix. |
Chesterville |
|
xxiv. |
Woolwich |
|
x. |
New Sharon |
|
|
|
|
xi. |
Durham |
|
|
|
|
xii. |
Pownal |
|
|
|
|
xiii. |
Embden |
|
|
|
|
xiv. |
Starks |
|
|
|
|
xv. |
Farmington |
|
|
|
A-8
Canadian Approvals
Set forth below are, to the best of HQUS’s knowledge, the Governmental Approvals and Third Party Consents, in each case, required to commence construction of the Québec Line:
|
• |
Permit from the National Energy Board to construct, operate, maintain or connect an international power line pursuant to the National Energy Board Act (R.S. C., 1985, c. N-7); |
|
• |
Permit from the International Boundary Commission required to cross the Canada-U.S. border pursuant to Article 5 of the International Boundary Commission Act; |
|
• |
Authorization from the Régie de l’énergie to acquire, construct or dispose of transmission assets pursuant to an Act respecting the Régie de l’énergie (R.S.Q., chapter R-6.01); |
|
• |
Expropriation Order in council, if required, to acquire by expropriation any immovable, servitude or construction required for the transmission of power pursuant to Hydro-Québec Act (R.S.Q., chapter H-5) and the Expropriation act (R.S.Q., chapter E-24); |
|
• |
Certificate of authorization issued by the Government of Québec to construct the transmission line under section 31.5 of the Environmental Quality Act subject to the environmental and social impact assessment and review procedure; |
|
• |
Certificate of authorization issued by the Ministère du Développement durable, de l’Environnement et de la Lutte contre les changements climatiques approving the plans and specifications of the transmission line pursuant to Section 22 of the Environmental Quality Act; |
|
• |
Authorization of the Commission de protection du territoire agricole du Québec , if required, approving the use of land situated in an agricultural zone for purposes other than agriculture under Sections 58 and 62 of the Act respecting the preservation of agricultural land and agricultural activities; |
|
• |
Opinion on project compliance with objectives of the city or regional county municipalities’ land-use and development plan. |
A-9
Owner’s Preliminary Project Schedule
A-10
A-11
A-12
A-13
Required Insurance
Owner shall obtain and maintain with qualified insurers authorized to issue insurance of the types described below in the State of Maine.
During construction of the NECEC Transmission Line Owner shall maintain or effect to be maintained the following insurance coverages:
|
• |
Primary and Excess Liability |
|
• |
Construction All Risk / Builders Risk |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
|
• |
Pollution / Environmental Liability |
After the Commercial Operation Date Owner shall provide coverage both in terms of scope and limits of coverage that are in accordance with Good Utility Practice and the long-standing practice of Owner. Operational coverage shall include the following insurance types:
|
• |
Excess Liability |
|
• |
Operational All Risk Property Damage |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
Note : At any time after the Commercial Operation Date Owner may choose, as far as it is consistent with Good Utility Practice, to self-insure on customary terms and conditions any coverage (or coverage part) where it meets any state or regulatory requirements of self-insurers.
A-14
Attachment G
Rate Adjustment Formula
In the event that a Transmission Service Payment is subject to reduction pursuant to Section 8.1 , such reduced payment shall equal the Transmission Service Payment that would otherwise be payable under the Agreement for a particular month multiplied by the lesser of 1 or the following fraction:
1 - |
(Contract Capacity x 0.90) |
|
minus (Contract Capacity x A) |
||
|
|
|
(Contract Capacity x 0.90) |
Where A = |
∑ Hourly Availability for all hours in such month |
∑ Hours in such month |
For purposes of calculating A, Excused Outages (for which Owner is paid full Transmission Service Payments pursuant to the terms of the Agreement) will be regarded as hours in which one hundred percent (100%) of Contract Capacity was provided.
A-15
Attachment H
Refund Calculation
This example is intended to illustrate the methodology for the calculation of a subsequent refund of a late payment. This example and the numbers used in this example are purely illustrative and are in no way intended to supersede any part of the Agreement, including Section 13.3.
Assumptions
|
• |
Interest Rate = 12 percent per annum (compounded monthly) |
June 2023 Billing
Invoice Amount
|
$1,000 |
Date of Invoice |
June 1, 2023
|
Due Date |
June 15, 2023
|
Payment Date |
July 1, 2023
|
The total amount due on the date of payment is $1,005, which amount is computed by adding $1,000 (the original amount invoiced) and $5 (the ½ month late interest fee).
Subsequent Refund
If later, on July 1, 2024, the aforesaid payment is required to be refunded, the refund will equal the $1,000 payment made on July 1, 2023 (the original amount invoiced), plus the interest accrued on that $1,000 payment from the due date of June 15, 2023 to the date of refund on July 1, 2024. To ensure that the refund does not double recover interest, the following language has been included in Section 13.3 of the Agreement: “[I]f all or a portion of the amount [ here, the $1,000 payment due on June 15, 2023 ] to which such interest relates [ here, the $5 late interest fee ] is later refunded pursuant to this Agreement [ here, on July 1, 2024 ], then, in calculating that refund, such interest [ here, $5 ] shall not be included in the refund.”
A-16
Real Estate Rights
A-17
A-18
A-19
A-20
A-21
A-22
A-23
Transmission Service Payment Calculation
The Transmission Service Payment for a given calendar month shall be equal to the unit price per kW-month for the then-current Contract Year (the “ Unit Price ”), as set forth in the table below, multiplied by the Contract Capacity expressed in kW.
In the event the anniversary of the Commercial Operation Date falls within the middle of a calendar month (month M), the Unit Price for each month M shall be equal to: the Unit Price for the Contract Year that is ending (Contract Year Y), multiplied by the proportion of the days of the calendar month M that are part of that Contract Year Y, plus the Unit Price for the Contract Year that is beginning (Contract Year Y+1), multiplied by the proportion of the days of the calendar month M that are part of that Contract Year Y+1, the resulting calculation being rounded to the nearest cent.
Examples . For all examples, assume the Commercial Operation Date is December 13, 2022, with December being month M.
A-24
|
* 19/31 [proportion of days in December that are part of Contract Year 1])) = $5.61/kW-month. |
|
• |
Example 2 . The Unit Price for the month of December 2023 is as follows: (($9.16 [Unit Price for Contract Year 1] * 12/31 [proportion of days in December that are part of Contract Year 1]) + ($9.35 [Unit Price for Contract Year 2] * 19/31 [proportion of days in December that are part of Contract Year 2])) = $9.28/kW-month. |
|
• |
Example 3 . The Unit Price for the month of December 2041 is as follows: (($13.35 [Unit Price for Contract Year 20] * 12/31 [proportion of days in December that are part of Contract Year 20]) + ($0 [no Transmission Service Payment after Contract Year 20] * 19/31 [proportion of days in December that are after end of Contract Year 20])) = $5.17/kW-month. |
A-25
Exhibit 10.5
TRANSMISSION SERVICE AGREEMENT (National Grid - 498.348 MW)
by and between
CENTRAL MAINE POWER COMPANY,
as Owner,
and
H.Q. ENERGY SERVICES (U.S.) INC.,
as Purchaser
Dated: as of June 13, 2018
|
|
Page |
|||
Article I DEFINITIONS AND RULES OF INTERPRETATION |
|
3 |
|||
|
|
|
|
|
|
|
Section 1.1 |
|
Definitions |
|
3 |
|
Section 1.2 |
|
Interpretation |
|
17 |
|
|
|
|||
Article II REGULATORY FILINGS AND REQUIRED APPROVALS |
|
19 |
|||
|
|
|
|
|
|
|
Section 2.1 |
|
MDPU Filing; FERC Filings |
|
19 |
|
Section 2.2 |
|
Modifications to FERC Order |
|
19 |
|
Section 2.3 |
|
Modifications Pursuant to Unfavorable MDPU Order or FERC
|
|
20 |
|
Section 2.4 |
|
Cooperation |
|
20 |
|
Section 2.5 |
|
No Inconsistent Action |
|
21 |
|
|
|
|||
Article III EFFECTIVE DATE; TERM |
|
21 |
|||
|
|
|
|
|
|
|
Section 3.1 |
|
Effective Date |
|
21 |
|
Section 3.2 |
|
Term |
|
21 |
|
Section 3.3 |
|
Termination Rights |
|
22 |
|
Section 3.4 |
|
Termination Payments |
|
24 |
|
Section 3.5 |
|
Effect of Termination |
|
24 |
|
|
|
|||
Article IV COMMERCIAL OPERATION |
|
25 |
|||
|
|
|
|
|
|
|
Section 4.1 |
|
Critical Milestones |
|
25 |
|
Section 4.2 |
|
Commercial Operation Date |
|
28 |
|
Section 4.3 |
|
Conditions Precedent to Commercial Operation |
|
28 |
|
Section 4.4 |
|
Delay in Commercial Operation; Reduced Level of Operation |
|
29 |
|
|
|
|||
Article V GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES |
|
34 |
|||
|
|
|
|
|
|
|
Section 5.1 |
|
Responsibilities of the Parties |
|
34 |
|
Section 5.2 |
|
Schedules and Reports |
|
34 |
|
Section 5.3 |
|
Québec Line Reports; Joint Development Agreement |
|
36 |
|
Section 5.4 |
|
Insurance and Events of Loss |
|
36 |
|
Section 5.5 |
|
Compliance with Laws |
|
36 |
|
Section 5.6 |
|
Third Party Contracts |
|
36 |
|
Section 5.7 |
|
Purchaser’s Losses. |
|
37 |
|
Section 5.8 |
|
Continuity of Rights and Responsibilities |
|
37 |
|
Section 5.9 |
|
Right of First Offer to Purchase NECEC Transmission Line |
|
37 |
|
Section 5.10 |
|
Amendment to the PPA |
|
37 |
|
Section 5.11 |
|
Amendment to the Distribution Company TSA |
|
38 |
|
|
|
i
ii
|
47 |
||||
|
|
|
|
|
|
|
Section 14.1 |
|
Purchaser Defaults |
|
47 |
|
Section 14.2 |
|
[Intentionally Omitted] |
|
48 |
|
Section 14.3 |
|
Owner Defaults |
|
48 |
|
Section 14.4 |
|
Remedies Upon Purchaser Default |
|
50 |
|
Section 14.5 |
|
[Intentionally Omitted] |
|
51 |
|
Section 14.6 |
|
Remedies Upon Owner Default |
|
51 |
|
Section 14.7 |
|
Purchaser Step-in Rights |
|
52 |
|
Section 14.8 |
|
Early Termination of Distribution Company TSA |
|
56 |
|
Section 14.9 |
|
Disputes |
|
56 |
|
Section 14.10 |
|
Limitations on Total Liability |
|
56 |
|
Section 14.11 |
|
Modified Terms Applicable During Forbearance Period. |
|
57 |
|
|
|
|||
Article XV FORCE MAJEURE |
|
58 |
|||
|
|
|
|
|
|
|
Section 15.1 |
|
Definition; Conditions |
|
58 |
|
|
|
|||
Article XVI FINANCIAL ASSURANCES |
|
59 |
|||
|
|
|
|
|
|
|
Section 16.1 |
|
[Purchaser’s Guaranty |
|
59 |
|
Section 16.2 |
|
[Intentionally Omitted] |
|
59 |
|
Section 16.3 |
|
Credit Downgrade Event |
|
60 |
|
|
|
|||
Article XVII DISPUTE RESOLUTION |
|
60 |
|||
|
|
|
|
|
|
|
Section 17.1 |
|
Consultation |
|
60 |
|
Section 17.2 |
|
Disputes to be Resolved by FERC |
|
61 |
|
Section 17.3 |
|
Consent to Jurisdiction |
|
61 |
|
Section 17.4 |
|
WAIVER OF JURY TRIAL |
|
61 |
|
|
|
|||
Article XVIII LIMITATION OF REMEDIES |
|
62 |
|||
|
|
|
|||
Article XIX MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE
|
|
63 |
|||
|
|
|
|
|
|
|
Section 19.1 |
|
Modifications |
|
63 |
|
Section 19.2 |
|
Change in ISO-NE Rules; Change in Applicable Law or
|
|
63 |
|
|
|
|||
Article XX INDEMNIFICATION |
|
65 |
|||
|
|
|
|
|
|
|
Section 20.1 |
|
Purchaser Indemnity |
|
65 |
|
Section 20.2 |
|
Owner Indemnity |
|
65 |
|
Section 20.3 |
|
[Intentionally Omitted] |
|
65 |
|
Section 20.4 |
|
Procedures |
|
66 |
|
Section 20.5 |
|
Defenses |
|
66 |
|
Section 20.6 |
|
Cooperation |
|
67 |
|
Section 20.7 |
|
Recovery |
|
67 |
|
Section 20.8 |
|
Subrogation |
|
67 |
iii
|
|
|
|||
Article XXI REPRESENTATIONS, WARRANTIES AND COVENANTS |
|
67 |
|||
|
|
|
|
|
|
|
Section 21.1 |
|
Mutual Representations and Warranties |
|
67 |
|
Section 21.2 |
|
Additional Representations and Warranties of Purchaser |
|
68 |
|
Section 21.3 |
|
Additional Representations and Warranties of Owner |
|
69 |
|
Section 21.4 |
|
[Intentionally Omitted] |
|
70 |
|
Section 21.5 |
|
NO OTHER REPRESENTATIONS OR WARRANTIES |
|
70 |
|
|
|
|||
Article XXII TRANSFER OF INTERESTS |
|
71 |
|||
|
|
|
|
|
|
|
Section 22.1 |
|
No Transfer of Interests |
|
71 |
|
Section 22.2 |
|
Exceptions |
|
72 |
|
Section 22.3 |
|
Collateral Assignment |
|
73 |
|
|
|
|||
Article XXIII MISCELLANEOUS |
|
73 |
|||
|
|
|
|
|
|
|
Section 23.1 |
|
Governing Law |
|
73 |
|
Section 23.2 |
|
Entire Agreement |
|
73 |
|
Section 23.3 |
|
Severability |
|
73 |
|
Section 23.4 |
|
Notices |
|
73 |
|
Section 23.5 |
|
Waiver; Cumulative Remedies |
|
74 |
|
Section 23.6 |
|
Confidential Information |
|
75 |
|
Section 23.7 |
|
No Third-Party Rights |
|
75 |
|
Section 23.8 |
|
Permitted Successors and Assigns |
|
76 |
|
Section 23.9 |
|
Relationship of the Parties |
|
76 |
|
Section 23.10 |
|
Construction |
|
76 |
|
Section 23.11 |
|
Counterparts |
|
76 |
|
Section 23.12 |
|
Survival |
|
76 |
|
Section 23.13 |
|
Language |
|
76 |
|
Section 23.14 |
|
Headings and Table of Contents |
|
76 |
|
Section 23.15 |
|
Waiver of Immunities |
|
76 |
iv
ATTACHMENTS
Attachment A |
|
Description of Transmission Projects |
Attachment B |
|
Critical Milestones |
Attachment C |
|
Owner Approvals |
Attachment D |
|
Canadian Approvals |
Attachment E |
|
Owner’s Preliminary Project Schedule and Construction Schedule |
Attachment F |
|
Required Insurance |
Attachment G |
|
Rate Adjustment Formula |
Attachment H |
|
Refund Calculation |
Attachment I |
|
Real Estate Rights |
Attachment J |
|
Form of Purchaser Guaranty |
v
TRANSMISSION SERVICE AGREEMENT
This TRANSMISSION SERVICE AGREEMENT (this “ Agreement ”), dated as of June 13, 2018 (the “ Execution Date ”), is made and entered into by and between Central Maine Power Company, a corporation organized and existing under the laws of the State of Maine (“ Owner ”), and H.Q. Energy Services (U.S.) Inc. , a corporation organized and existing under the laws of the State of Delaware (“ HQ-US ” or “ Purchaser ”). Owner and Purchaser are hereinafter sometimes also referred to individually as a “ Party ” or collectively as the “ Parties.”
WITNESSETH
WHEREAS, Purchaser is an indirect, wholly-owned subsidiary of Hydro-Québec (as defined below);
WHEREAS, pursuant to “An Act to Promote Energy Diversity” that was signed into law in the Commonwealth of Massachusetts on August 8, 2016 (the “ Energy Diversity Act ”), Fitchburg Gas and Electric Light Company (d/b/a Unitil), Massachusetts Electric Company and Nantucket Electric Company (d/b/a National Grid), and NSTAR Electric Company (d/b/a Eversource Energy) (collectively, the “ RFP Sponsors ”) have solicited competitive proposals for clean energy generation for an annual amount of electricity equal to approximately 9.45 TWh;
WHEREAS, Owner and an Affiliate of HQ-US jointly submitted a proposal pursuant to such solicitation that includes up to 1,090 MW of clean energy generation obtained by HQ-US from its affiliate Hydro-Québec Production (a division of Hydro-Québec (as defined below), “ HQP ” and such generation, the “ Hydro Generation ”);
WHEREAS, concurrently with the execution and delivery of this Agreement, HQ-US has entered into a power purchase agreement (the “ PPA ”) with National Grid (“ Distribution Company ”) and additional power purchase agreements (the “ Additional PPAs ”) with the other RFP Sponsors with respect to an aggregate of 1,090 MW of Hydro Generation (and related renewable energy credits and environmental attributes);
WHEREAS, as part of the delivery of 1,090 MW of Hydro Generation for sale into the U.S. pursuant to the PPA and the Additional PPAs, Hydro-Québec TransÉnergie (“ TransÉnergie ”), a division of Hydro-Québec, intends to develop, construct, own and maintain a 1,200 MW +/-320 kV high-voltage direct current (“ HVDC ”) transmission line from the converter station at the Appalaches substation in Thetford Mines, Québec to the U.S. Border (as defined below) at Beattie Township, Maine (as further delineated in the diagram or described in Attachment A , the “ Québec Line ”);
WHEREAS, HQP has acquired from TransÉnergie firm transmission service over the Québec Line to permit the delivery of at least 1,200 MW of power into the U.S.;
WHEREAS, Owner intends to develop, construct, own and maintain a 1,200 MW +/-320 kV HVDC transmission line extending from the U.S. Border at Beattie Township, Maine to a new direct current to alternating current (“ AC ”) converter station to be located at Merrill Road in the City of Lewiston in the State of Maine (the transmission line and converter station, as more fully described in Attachment A , the “ HVDC Line ”);
1
WHEREAS, in order to interconnect the HVDC Line with the bulk power systems in New England, Owner intends to develop, construct, own and maintain additional 345 kV AC transmission lines, rebuilt 115 kV AC transmission lines and other substation equipment more fully described in Attachment A (together with the Merrill Road substation at its northern terminus and the associated equipment, as more fully described in Attachment A , the “ AC Line ” and, together with the HVDC Line, the “ NECEC Transmission Line ” );
WHEREAS, although Owner has performed studies believed to replicate those utilized by ISO-NE and does not believe that AC Upgrades (as defined below) or CCIS Capacity Upgrades (as defined below) will be required as a consequence of the construction and operation of the NECEC Transmission Line and the consummation of the transactions contemplated by this Agreement, this Agreement, the Distribution Company TSA (as defined below), the Additional RFP Sponsor TSAs (as defined below), the Purchaser TSAs, the 110 MW TSA, the PPA or the Additional PPAs, ISO-NE (as defined below) may require certain AC Upgrades or CCIS Capacity Upgrades to be developed, constructed, owned and maintained by certain transmission owners other than Owner (which may include Affiliates of Owner) within their existing service territories in New England in order to interconnect the NECEC Transmission Line with the New England Transmission System (as defined below) in a safe and reliable manner, which AC Upgrades or CCIS Capacity Upgrades (if any) will be performed at Owner’s sole expense;
WHEREAS, concurrently with the execution and delivery of this Agreement, Owner has entered into a transmission service agreement (the “ Distribution Company TSA ”) with Distribution Company to sell 498.348 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date (as defined below) and additional transmission service agreements (the “ Additional RFP Sponsor TSAs ”) with the other RFP Sponsors to sell an aggregate of 591.652 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date; and
WHEREAS, Owner desires to sell Firm Transmission Service (as defined below) to Purchaser for years twenty-one (21) through forty (40) following the Commercial Operation Date, and Purchaser desires to acquire such Firm Transmission Service from Owner, at the rates and on the terms and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the foregoing and the respective representations, warranties, covenants, agreements and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound hereby, the Parties hereby agree as follows:
2
Article I
DEFINITIONS AND RULES OF INTERPRETATION
Section 1.1 Definitions. As used herein, the following terms shall have the following respective meanings:
“ 110 MW TSA ” means that certain Transmission Service Agreement between Purchaser and Owner, dated as of the date hereof, pursuant to which Purchaser has acquired transmission service for up to 110 MW of capacity for forty (40) years following the Commercial Operation Date.
“ 110 MW TSA Capacity ” means the firm capacity of the NECEC Transmission Line of up to 110 MW that Purchaser has committed in the 110 MW TSA to purchase in the forty (40) years following the Commercial Operation Date.
“ 110 MW TSA FERC Order ” means an order accepting or approving the 110 MW TSA for filing.
“ AC ” has the meaning provided in the recitals to this Agreement.
“ AC Line ” has the meaning provided in the recitals to this Agreement.
“ AC Upgrade Approvals ” means, collectively, any Governmental Approvals or Third Party Consents, in each case, that are required to commence construction of the AC Upgrades.
“ AC Upgrade Owners ” means, collectively, any Person responsible for constructing one or more AC Upgrades pursuant to a facilities agreement.
“ AC Upgrades ” means any additions, upgrades, reinforcements or other modifications to the New England Transmission System that ISO-NE determines, pursuant to Section I.3.9 of the ISO-NE Tariff, to be required, at a minimum, to interconnect the NECEC Transmission Line at the Delivery Point with the New England Transmission System.
“ Acquisition Notice ” has the meaning provided in Section 14.7(b) .
“ Additional Bids ” has the meaning provided in Article XVIII .
“ Additional Credit Support ” means one or more of the following, issued in favor of or otherwise held by or for the benefit of Owner or Purchaser, as applicable:
(a) a guaranty, in form and substance reasonably satisfactory to Purchaser or Owner (as applicable), issued by an Affiliate of Owner or Purchaser (as applicable) that meets the Credit Rating Requirements;
(b) a Letter of Credit, in form and substance reasonably satisfactory to Purchaser or Owner (as applicable); or
(c) Cash.
3
“ Additional RFP Sponsor TSAs ” has the meaning provided in the recitals to this Agreement.
“ Additional RFP Sponsor TSA FERC Order ” means an order accepting or approving one or more Additional RFP Sponsor TSAs for filing.
“ Additional PPAs ” has the meaning provided in the recitals to this Agreement.
“ Adverse Determination ” has the meaning provided in Section 19.2(c) .
“ Affiliate ” means, with respect to a specified Person, any other Person that directly or indirectly Controls, is Controlled by or is under common Control with the specified Person; provided , however , that, with respect to Purchaser, a Person shall not be an “Affiliate” of Purchaser unless such Person is Hydro-Québec (including, for the avoidance of doubt, a division of Hydro-Québec) or Controlled by Hydro-Québec.
“ Agreement ” has the meaning provided in the preamble to this Agreement.
“ Applicable Law ” means any duly promulgated federal, national, state, provincial or local law, regulation, rule, ordinance, code, decree, judgment, directive or judicial or administrative order, permit or other duly authorized and valid action of any Governmental Authority, including any binding interpretation of any of the foregoing by any Governmental Authority, which is applicable to a Person, its property or a transaction, and also including Section 83D, the regulations promulgated under Section 83D, the Regulatory Approval and any other orders of the MDPU with respect to this Agreement.
“ Approval Deadline ” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Available Transfer Capability ” means the lesser of (a) 1,090 MW or (b) the Total Transfer Capability.
“ Bankruptcy Code ” means the United States Bankruptcy Code, 11 U.S.C. § 101 et seq.
“ Business Day ” means any day except Saturday, Sunday or any other day on which the Federal Reserve member banks are required or authorized to close for business.
“ Canadian Approval Deadline ” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Canadian Approvals ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the Québec Line in a manner consistent with Attachment A , all as set forth in Attachment D .
“ Cash ” means U.S. dollars held by or on behalf of a Party as Credit Support hereunder.
4
“ CCIS Capacity Upgrade ” means any upgrade determined by ISO-NE as necessary in order for the NECEC Transmission Line Capacity to satisfy the Capacity Capability Interconnection Standard under and as defined in the ISO-NE Tariff.
“ COD Notice ” has the meaning provided in Section 4.2(c) .
“ Commercial Operation ” means the availability of the NECEC Transmission Line for the provision of Firm Transmission Service in accordance with this Agreement and the Distribution Company TSA.
“ Commercial Operation Date ” has the meaning provided in Section 4.2(c) .
“ Commissioning ” means (a) with respect to the NECEC Transmission Line, the start-up and testing activities required to demonstrate that the NECEC Transmission Line is ready for Commercial Operation and (b) with respect to the Québec Line, the start-up and testing activities required to demonstrate that the Québec Line is ready for commercial operation, consistent with Section 4.3(f) .
“ Concurrent Delay ” has the meaning provided in Section 4.4.3 .
“ Confidential Information ” means (a) this Agreement, (b) any documents, analyses, compilations, studies, or other materials prepared by or information received from a Party or its representatives that contain or reflect written or oral data or information that is privileged, confidential or proprietary and that is marked or otherwise clearly identified as “confidential” or “proprietary” or with words of like meaning, or (c) any subsequently prepared documents, analyses, compilations, studies or other materials or information that are derived from any of the documents, analyses, compilations, studies or other materials or information described in the foregoing clause (b). Without limiting the generality of the foregoing, all information provided to Purchaser or Owner under Sections 2.4 , 5.2 and 6.3 hereof shall be deemed to be Confidential Information, whether or not such information is marked as “confidential” or “proprietary.”
“ Consent ” means, with respect to a Person, any approval, consent, permit, license, decree, certificate or other authorization of or from such Person.
“ Construction Authorizations ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the NECEC Transmission Line, other than the ISO-NE Approval, including the approvals of the Maine Department of Environmental Protection, the U.S. Army Corp of Engineers, the Maine Public Utilities Commission and the U.S. Department of Energy (the Presidential Permit), as more fully set forth in Attachment C .
“ Construction Contract ” means any contract entered into by Owner that provides for the engineering, procurement or construction of the NECEC Transmission Line.
5
“ Construction Phase ” means the period commencing upon the receipt of the FERC Authorization or such other date to which the Parties shall mutually agree in writing, and ending on the day immediately preceding the Commercial Operation Date or upon the earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Contract Capacity ” means the Proportionate Share multiplied by the NECEC Transmission Line Capacity.
“ Contract Year ” means each twelve-month period during the Term, with the first Contract Year commencing on the Commercial Operation Date and with each Contract Year after the first commencing on the anniversary of the Commercial Operation Date.
“ Control ” (including its correlative meanings “Controlled by” and “under common Control with”) means, with respect to a Person, the possession, directly or indirectly, of the power to direct or cause the direction of the management or policies of the specified Person, whether through ownership of voting securities or partnership or other ownership interests, by contract or Applicable Law or otherwise.
“ Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , Section 4.1(d) or Section 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“Credit Rating Requirements” means a long-term credit rating of at least “BBB-” by S&P or “Baa3” by Moody’s.
“Credit Support” means collateral in the form of (a) Cash or (b) a Letter of Credit issued by a Qualified Bank in a form reasonably satisfactory to the beneficiary.
“ Critical Energy Infrastructure Information ” means any information defined as Critical Energy Infrastructure Information by FERC pursuant to 18 C.F.R. § 388.113, and shall include all Critical Infrastructure Protection (CIP) standards (CIP-002 through CIP-009) established by NERC.
“ Critical Milestone ” has the meaning provided in Section 4.1(a) .
“ Delivery Point ” means the southern terminus of the NECEC Transmission Line at the Larrabee Road substation in Lewiston, Maine, as illustrated in Attachment A .
“ Design Capability ” means the maximum amount of electric power that the materials, equipment and structures comprising the HVDC Transmission Project will be designed to transfer bi-directionally in a safe and reliable manner, which amount shall be sufficient to permit the north-to-south delivery of all amounts scheduled for delivery in an aggregate amount of at least 1,090 MW, but not to exceed 1,200 MW, of electrical energy at the Delivery Point.
“ Discount Rate ” means the prime rate specified in the “Money and Investing” section of the Wall Street Journal plus 300 basis points.
6
“ Dispute ” means any dispute, controversy or claim of any kind whatsoever arising out of or relating to a Proposal Agreement, including relating to the interpretation of the terms thereof or any Applicable Law that affects such Proposal Agreement, or the transactions contemplated thereunder, or the breach, termination or validity thereof.
“ Distribution Company ” has the meaning provided in the recitals to this Agreement.
“ Distribution Company TSA ” has the meaning provided in the recitals to this Agreement.
“ Distribution Company TSA Amendment ” has the meaning provided in Section 2.3 .
“ Distribution Company TSA Critical Milestones ” means the “Critical Milestones” as defined in the Distribution Company TSA.
“ Distribution Company TSA FERC Order ” has the meaning provided in Section 2.3 .
“ Effective Date ” has the meaning provided in Section 3.1 .
“ Energy Diversity Act ” has the meaning provided in the recitals to this Agreement.
“ Excused Outages ” has the meaning provided in Section 7.2(a) .
“ Execution Date ” has the meaning provided in the preamble to this Agreement.
“ Federal Power Act ” means the United States Federal Power Act of 1935, as amended, 16 U.S.C. § 791a et seq.
“ FERC ” means the Federal Energy Regulatory Commission, or any successor regulatory agency that administers the Federal Power Act.
“ FERC Amendment ” has the meaning provided in Section 2.2(b) .
“ FERC Authorization ” means, collectively, any FERC order that is not subject to rehearing or appeal authorizing Owner to provide Firm Transmission Service, including the FERC Order, the Distribution Company TSA FERC Order, any Additional RFP Sponsor TSA FERC Order, any Purchaser TSA FERC Order and the 110 MW TSA FERC Order , and any authorization from FERC with respect to the Transmission Operating Agreement or Interconnection Agreements.
“ FERC Order ” has the meaning provided in Section 2.2(a) .
“ Financial Transmission Rights ” means Financial Transmission Rights, as defined in the ISO-NE Tariff.
“ Financing Deadline ” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Firm Transmission Service ” has the meaning provided in Section 7.1.1 .
7
“ Fixed Credit Support ” has the meaning provided in the PPA.
“ Force Majeure ” has the meaning provided in Section 15.1(a) .
“ Good Utility Practice ” means those design, construction, operation, maintenance, repair, removal and disposal practices, methods and acts that are engaged in by a significant portion of the electric transmission industry in the United States during the relevant time period, or any other practices, methods or acts that, in the exercise of reasonable judgment in light of the facts known at the time a decision is made, could have been expected to accomplish a desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Good Utility Practice is not intended to be the optimum practice, method or act to the exclusion of others but rather to be a spectrum of acceptable practices, methods or acts generally accepted in such electric transmission industry for the design, construction, operation, maintenance, repair, removal and disposal of electric transmission facilities in the United States. Good Utility Practice shall not be determined after the fact in light of the results achieved by the practices, methods, or acts undertaken, but rather shall be determined based upon the consistency of (a) the practices, methods, or acts when undertaken with (b) the standard set forth in the first two (2) sentences of this definition at such time.
“ Governmental Approval ” means (a) any authorization, consent, approval, license, lease, ruling, permit, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with or (d) any registration by or with, any Governmental Authority, including any FERC Authorization.
“ Governmental Authority ” means any government or agency or other political subdivision thereof, including any province, state or municipality, or any other governmental, quasi-governmental, judicial, executive, legislative, administrative, regulatory, public or statutory instrumentality, authority, body, agency, commission, department, board, bureau or entity exercising judicial, executive, legislative, administrative or regulatory functions, any court or arbitrator with authority to bind a party at law, and shall include, to the extent exercising powers delegated by any Governmental Authority acting under Applicable Law, NERC and ISO-NE.
“ Hourly Availability ” means, with respect to any hour, the availability of the NECEC Transmission Line for the purposes of this Agreement, which shall equal (a) the Proportionate Share of the Available Transfer Capability for such hour, divided by (b) the Contract Capacity, expressed as a percentage; provided , however , that, for any hour, such availability of the NECEC Transmission Line shall not exceed one hundred percent (100%).
“ HQ-US ” has the meaning provided in the preamble to this Agreement.
“ HQE ” means Hydro-Québec Équipment, a division of Hydro-Québec .
“ HQP ” has the meaning provided in the recitals to this Agreement.
“ HVDC ” has the meaning provided in the recitals to this Agreement.
“ HVDC Line ” has the meaning provided in the recitals to this Agreement.
8
“ HVDC Transmission Project ” means, collectively, (a) the Québec Line and (b) the NECEC Transmission Line.
“ Hydro Generation ” has the meaning provided in the recitals to this Agreement.
“ Hydro-Québec ” means Hydro-Québec, a body politic and corporate, duly incorporated and regulated by the Hydro-Québec Act (R.S.Q., Chapter H-5). As of the Execution Date, Hydro-Québec has four divisions: HQP, TransÉnergie, Hydro-Québec Distribution and HQE.
“ Hydro-Quebec Guaranty ” has the meaning provided in Section 16.1 .
“ Immunities Act ” means the United States Foreign Sovereign Immunities Act of 1976, 28 U.S.C. § 1602 et seq.
“ Indemnification Notice ” has the meaning provided in Section 20.4 .
“ Indemnified Party ” has the meaning provided in Section 20.4 .
“ Indemnifying Party ” has the meaning provided in Section 20.4 .
“ Insolvency Event ” means, with respect to a Person, such Person (a) becomes “insolvent,” as defined in the Bankruptcy Code, or otherwise becomes bankrupt or insolvent under any Insolvency Laws, (b) has a liquidator, administrator, receiver, custodian, trustee, conservator or similar official appointed with respect to such Person or any material portion of such Person’s assets or such Person consents to such appointment, or a foreclosure action is instituted with respect to any material portion of such Person’s assets and is not dismissed within thirty (30) days of commencement thereof, (c) files a voluntary petition or otherwise authorizes or commences a proceeding or cause of action under the Bankruptcy Code or Insolvency Laws, (d) has an involuntary petition filed against it or acquiesces in the commencement of a proceeding or cause of action as the subject debtor under the Bankruptcy Code or Insolvency Laws, which petition is not dismissed within thirty (30) days after the filing thereof or results in the issuance of an order for relief against such Person, (e) makes or consents to an assignment of its assets in whole or in part, for the benefit of creditors or any general arrangement for the benefit of creditors, or a common law composition of creditors or (f) generally is unable to pay its debts as they fall due, or admits in writing to such inability.
“ Insolvency Laws ” means any bankruptcy, insolvency, reorganization or similar laws of the U.S., Canada, or other Governmental Authority, as applicable, other than the Bankruptcy Code.
9
“ Interconnection Agreements ” means, collectively, (a) an agreement by and among Owner, TransÉnergie and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the U.S. Border of the NECEC Transmission Line with the Québec Line and (b) an agreement by and between Owner and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the Delivery Point of the NECEC Transmission Line with certain transmission facilities operated by ISO-NE. The Interconnection Agreements shall address cost responsibilities among entities other than the Distribution Company and the other RFP Sponsors and shall include provisions, both technical and otherwise, for safe and reliable interconnected operations of the HVDC Transmission Project following Commercial Operation (including use of the HVDC Transmission Project for the delivery of electric power in emergency circumstances).
“ Interested Party ” means, collectively, the Parties and, if and as applicable, the RFP Sponsors.
“ Invoice ” means, with respect to a calendar month, an invoice that sets forth the amounts owed to the applicable Party with respect to such month in reasonable detail to evidence the basis for individual billings and charges.
“ ISO-NE ” means ISO New England Inc., or its successor organization.
“ ISO-NE Approval ” means approval by ISO-NE to operate the NECEC Transmission Line up to 1,200 MW.
“ ISO-NE Definitions Manual ” means the ISO New England Manual for Definitions and Abbreviations, Manual M-35, as in effect from time to time.
“ ISO-NE Rules ” means the ISO-NE Tariff and all ISO-NE manuals, rules, procedures, agreements or other documents relating to the reliable operation of the electric system in New England and the purchase and sale of electrical energy, electrical capacity and ancillary services, as such govern market participants with respect thereto in the operating jurisdiction of ISO-NE, as in effect from time to time, including the ISO-NE Definitions Manual; provided that such documents are publicly accessible.
“ ISO-NE Tariff ” means the ISO New England Inc. Transmission, Markets and Services Tariff, FERC Electric Tariff No. 3, as in effect from time to time, on file with FERC, or its successor tariff.
“ Joint Development Agreement ” has the meaning provided in Section 5.3 .
“ kV ” means kilovolt.
“ K W ” means kilowatt.
“ Letter of Credit ” means an irrevocable, non-transferable standby letter of credit issued by a Qualified Bank utilizing a form acceptable to the Party in whose favor such letter of credit is issued. All costs relating to any Letter of Credit shall be for the account of the Party providing that Letter of Credit.
10
“ Maintenance Plan ” means an annual plan for the management, operation and ordinary maintenance of the NECEC Transmission Line, which plan shall include a description of the scope and nature of the planned operating and maintenance programs and planned and preventive maintenance procedures for the NECEC Transmission Line, and the scheduled maintenance and other planned outages of the NECEC Transmission Line, in each case, in accordance with Section 6.3 hereof and the requirements of the PPA.
“ Market Products ” means, collectively, all products (however entitled and whether existing now or in the future) that (a) are recognized under ISO-NE Rules, (b) derive from the acquisition of transmission service over the NECEC Transmission Line under this Agreement and (c) can be sold for consideration or otherwise have economic value, including electrical energy, electrical capacity and ancillary services, including reserve products (including spinning and non-spinning reserves).
“ Marketing Activities ” means a specific offering by Owner of the NECEC Transmission Line (without any other material assets) for purchase by one or more third parties (other than an Affiliate of Owner).
“ Marketing Notice ” has the meaning provided in Section 5.9(a) .
“ Material Adverse Effect ” means, with respect to a Party, a material adverse effect on the ability of such Party to perform any of its obligations under this Agreement.
“ MDPU ” means the Massachusetts Department of Public Utilities.
“ Minimum Average Availability ” means ninety percent (90%) of the Contract Capacity, provided that, during the Remediation Period, if applicable, for every ten (10) MW that the maximum operating agreement of the NECEC Transmission Line is below 1,090 MW, the Minimum Average Availability shall be increased by one percent (1%), and provided further that, if, at the earlier of the Owner Remediation Date or the end of the Remediation Period, the NECEC Transmission Line is operating at an operating capacity below 1090 MW in any of the circumstances described in Section 4.4.1(c)(ii), the Minimum Average Availability shall be increased by one-half of one percent (0.5%) for each 5 MW by which the operating capacity of the NECEC Transmission Line is below 1,090 MW.
“ Municipal Owner Approval Deadline ” means March 31, 2022 (as the same may be extended in accordance with Section 4.1(c) or Section 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Municipal Owner Approvals ” means the Owner Approvals identified in paragraph 10 of Attachment C that are required to construct, own, and operate the NECEC Transmission Line.
“ MW ” means megawatt.
“ NECEC Facilities ” has the meaning provided in Section 8.3 .
“ NECEC Transmission Line ” has the meaning provided in the recitals to this Agreement.
11
“ NECEC Transmission Line Capacity ” means (a) 1,090 MW or (b) such lesser amount as may be established by the Commissioning of the NECEC Transmission Line, in each case as measured at the Delivery Point; provided that the amount under clause (b) shall be increased if the capacity is increased after the Commercial Operation Date pursuant to Section 4.4.1(c) , Section 4.4.2(b) or Section 4.4.3(b) .
“ NERC ” means the North American Electric Reliability Corporation, or its successor organization.
“ Net Book Value ” means, at any time, an amount equal to the original cost of construction minus depreciation (using a forty (40)-year depreciation schedule), as calculated in accordance with generally accepted accounting principles.
“ New England Transmission System ” means New England Transmission System, as defined in the ISO-NE Tariff.
“ Non-Excused Outage ” means any outage of the NECEC Transmission Line or reduction in the Total Transfer Capability below the NECEC Transmission Line Capacity, except due to an Excused Outage.
“ Non-Excused Outage Payment ” means, with respect to any month during which a Non-Excused Outage occurs, an amount equal to:
(a) the excess, in MW, if any, of (i) the Contract Capacity multiplied by the Minimum Average Availability over (ii) the Contract Capacity multiplied by the average Hourly Availability of the NECEC Transmission Line for such month, multiplied by
(b) $6, multiplied by
(c) the number of hours in such month.
“ OASIS ” means the Open Access Same-Time Information System.
“ OASIS Administrator ” has the meaning provided in Section 10.3(a) .
“ Offer Price ” has the meaning provided in Section 5.9(a) .
“ Other Transmission Rights ” means, collectively, any Financial Transmission Rights (or any similar concept), auction revenue rights or other financial or physical transmission rights, in each case, whether existing now or in the future, associated with the NECEC Transmission Line or AC Upgrades.
“ Owner ” has the meaning provided in the preamble to this Agreement.
“ Owner Approvals ” means, collectively, (a) the Construction Authorizations and (b) the ISO-NE Approval, all as set forth in Attachment C .
“ Owner Default ” has the meaning provided in Section 14.3 .
12
“ Owner Delay ” has the meaning provided in Section 4.4.1 .
“ Owner Indemnified Party ” has the meaning provided in Section 20.1 .
“ Owner Remediation Date ” has the meaning provided in Section 4.4.1(c)(i) .
“ Owner Security ” has the meaning provided in the Distribution Company TSA.
“ Owner Termination Payment ” means (a) if prior to the Commercial Operation Date, (i) liquidated damages in an amount equal to the Proportionate Share multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the termination date in connection with the development and construction of the Québec Line, and (ii) if the PPA has also been terminated pursuant to Section 9.2(b) thereof or, if due to a default by Owner under the Distribution Company TSA, Section 9.2(c) of the PPA, an amount equal to any Fixed Credit Support or (b) if on or after the Commercial Operation Date, an amount equal to the amounts paid by Purchaser to Distribution Company under the PPA (including any amounts drawn on any Credit Support provided by Purchaser under the PPA), arising out of or in connection with the Owner Default and termination of this Agreement. For the avoidance of doubt, the amounts described in the foregoing clause (b) shall be without duplication of any amounts paid by Owner to Distribution Company under the Distribution Company TSA in satisfaction of any liabilities to Distribution Company under the PPA. For purposes of calculating the Owner Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW.
“ Owner’s Construction Progress Report ” has the meaning provided in Section 5.2.3(a) .
“ Owner’s Construction Schedule ” has the meaning provided in Section 5.2.2 .
“ Owner’s Preliminary Schedule ” has the meaning provided in Section 5.2.1 .
“ Parties ” and “ Party ” have the meanings provided in the preamble to this Agreement.
“ Person ” means any legal person, including any natural person, domestic or foreign corporation, limited liability company, general or limited partnership, joint venture, association, joint stock company, business trust, estate, trust, enterprise, unincorporated organization, any Governmental Authority, or any other legal or commercial entity.
“ Physical Transmission Line Capacity ” means the sum of the NECEC Transmission Line Capacity and the 110 MW TSA Capacity.
“ Power Cost Reconciliation Tariff ” means a fully reconciling cost recovery tariff mechanism that authorizes the establishment of a distribution charge that fully recovers Distribution Company’s net costs under the Distribution Company TSA (including annual remuneration of up to two and three-quarters percent (2.75%)). The rate reconciliation shall be designed in such a way as to limit the build-up of any under or over-recoveries over the course of the year. A reconciliation shall occur at least annually, but may also be reconciled quarterly or monthly, to the extent necessary to eliminate regulatory lag for the recovery of costs or crediting of over-recoveries to customers.
13
“ PPA ” has the meaning provided in the recitals to this Agreement .
“ PPA Contract Maximum Amount ” means 498.348 MW, as such amount may be adjusted in accordance with the terms of the PPA.
“ Presidential Permit ” means the permit granted by the U.S. Department of Energy, pursuant to Executive Order 10485 as amended by Executive Order 12038, authorizing the construction, operation, maintenance and connection of facilities for the transmission of electric energy at the international border between the United States and Canada.
“ Project Schedule ” means a schedule setting forth the proposed engineering, procurement, construction and testing milestone schedule for (a) the NECEC Transmission Line based upon the Construction Contracts, (b) the Québec Line and (c) the AC Upgrades and the CCIS Capacity Upgrades based upon such information as can reasonably be obtained by Owner from the AC Upgrade Owners, recognizing that one or more Project Schedules will be completed and delivered before the date on which the AC Upgrades and the CCIS Capacity Upgrades are formally identified under this Agreement.
“ Proportionate Share ” means a fraction with the numerator equal to 498.348 MW and the denominator equal to 1,090 MW.
“ Proposal Agreements ” means, collectively, this Agreement, the 110 MW TSA, the Distribution Company TSA, the Additional RFP Sponsor TSAs, the Purchaser TSAs, the PPA and the Additional PPAs.
“ Purchased Power Accounting Authorization ” means authorization for Distribution Company, at Distribution Company’s sole discretion, to take appropriate steps to assure avoidance of a material, negative balance sheet impact on Distribution Company or Distribution Company’s direct or indirect parent company, upon appropriate filing with and approval by the MDPU.
“ Purchaser ” has the meaning provided in the preamble to this Agreement.
“ Purchaser Default ” has the meaning provided in Section 14.1 .
“ Purchaser Delay ” has the meaning provided in Section 4.4.2(a) .
“ Purchaser Guarantor ” means Hydro-Québec.
“ Purchaser Indemnified Party ” has the meaning provided in Section 20.2 .
“ Purchaser Term ” has the meaning provided in Section 8.1 .
14
“ Purchaser Termination Payment ” means (a) if prior to the Commercial Operation Date, an amount equal to the Proportionate Share of all costs prudently incurred by Owner as of the termination date in connection with the development and construction of the NECEC Transmission Line or (b) if on or after the Commercial Operation Date, an amount equal to the Proportionate Share multiplied by the Net Book Value of the NECEC Transmission Line minus the present value, discounted at the Discount Rate, of the Proportionate Share of revenues (if any) to be received by Owner, acting in a commercially reasonable manner, pursuant to contracts (if any) entered into by Owner during the sixty (60) day period immediately following the delivery of the termination notice, from one or more other purchasers or payors over the remainder of the Term for transmission service utilizing the NECEC Transmission Line up to an amount of generation at the Contract Capacity (net of operating costs in respect of such revenues), provided that, for purposes of calculating the Purchaser Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW.
“ Purchaser TSA ” means any transmission service agreement entered into between Purchaser and Owner (other than this Agreement), pursuant to which Purchaser acquires firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date.
“ Purchaser TSA FERC Order ” means an order issued by FERC accepting or approving one or more Purchaser TSAs for filing.
“ Qualified Bank ” means a U.S. commercial bank (or the U.S. branch of a foreign bank) having (a) assets on its most recent balance sheet of at least $10 billion and (b) a long-term credit rating of at least “A-” by S&P or “A3” by Moody’s (or its equivalent).
“ Québec Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Québec Line ” has the meaning provided in the recitals to this Agreement.
“ Québec Line Capacity Deficiency Payment ” means the Proportionate Share of (i) all costs prudently incurred by Owner as of the Commercial Operation Date in connection with the development and construction of the NECEC Transmission Line, multiplied by (ii) a fraction, the numerator of which is (A) the difference between the lesser of (x) the operating capacity of the NECEC Transmission Line and (y) 1,090 MW, and the operating capacity of the Québec Line, and the denominator of which is (B) the lesser of (x) the operating capacity of the NECEC Transmission Line or (y) 1,090 MW.
“ Real Power Losses ” means energy consumed by the electrical impedance characteristics of the NECEC Transmission Line.
“ Recovery ” has the meaning provided in Section 20.7 .
15
“ Regulatory Approval ” means the MDPU approval of the Distribution Company TSA , which approval shall include: (1) confirmation that the Distribution Company TSA has been approved under Section 83D and the regulations promulgated thereunder and that all of the terms of such Section 83D and such regulations apply to the Distribution Company TSA; (2) definitive regulatory authorization for Distribution Company to recover all of its costs incurred under and in connection with the Distribution Company TSA for the entire term of the Distribution Company TSA through the implementation of a Power Cost Reconciliation Tariff or other cost recovery or reconciliation mechanisms; (3) definitive regulatory authorization for Distribution Company to recover remuneration of up to two and three-quarters percent (2.75%) of Distribution Company’s annual payments under the Distribution Company TSA for the term of the Distribution Company TSA through the Power Cost Reconciliation Tariff; and (4) approval of any Purchased Power Accounting Authorization requested by Distribution Company in connection with the Regulatory Approval. Such approvals shall be acceptable in form and substance to Distribution Company in its sole discretion and shall not include any conditions or modifications that Distribution Company deems, in its sole discretion, to be unacceptable, and shall be final and not subject to appear or rehearing.
“ Regulatory Approval Delay ” means any delay in the receipt of the Regulatory Approval beyond January 25, 2019.
“ Regulatory Approval Termination Outside Date ” has the meaning provided in Section 3.3.1(a).
“ RFP Sponsors ” has the meaning provided in the recitals to this Agreement.
“ Section 83D ” means Section 83D of the Energy Diversity Act.
“ Scheduling Rules ” has the meaning provided in Section 7.1.3 .
“ Step-In Trigger Event ” has the meaning provided in Section 14.7(f) .
“ Target Date ” has the meaning provided in Section 4.2(a) .
“ Term ” has the meaning provided in Section 3.2 .
“ Third Party Claim ” has the meaning provided in Section 20.4 .
“ Third Party Consent ” means any Consent of a Person other than a Governmental Authority.
“ Total Transfer Capability ” means the Total Transfer Capability of the NECEC Transmission Line, as defined in, and established in accordance with, the ISO-NE Tariff and determined by ISO-NE for each hour.
“ TransÉnergie ” has the meaning provided in the recitals to this Agreement.
“ TransÉnergie OATT ” means the Hydro-Québec Open Access Transmission Tariff, as amended or accepted by the Régie de l’énergie from time to time.
16
“ Transfer ” has the meaning provided in Section 22.1(a) .
“ Transmission Operating Agreement ” means an agreement entered into by and between Owner and ISO-NE for transmission operating services over the NECEC Transmission Line under which operating control (as defined in such agreement) of the NECEC Transmission Line is transferred from Owner to ISO-NE.
“ Transmission Operator ” means ISO-NE acting in its capacity pursuant to the Transmission Operating Agreement.
“ Transmission Percentage ” means a fraction with the numerator equal to the Contract Capacity and the denominator equal to the Physical Transmission Line Capacity.
“ Transmission Service Payment ” has the meaning provided in Section 8.1 .
“ Unfavorable FERC Decision ” has the meaning provided in Section 2.2(a) .
“ Unfavorable MDPU Order ” has the meaning provided in Section 2.3 .
“ United States ” or “ U.S. ” means the United States of America.
“ U.S. Border ” means the location on or near the international border between the State of Maine and the Province of Québec where the HVDC Line and the Québec Line interconnect.
Section 1.2 Interpretation . In this Agreement, unless the context otherwise requires, the following rules shall apply to the usage of terms:
Section 1.2.1 Singular; Plural; Gender; Corollary Meaning . The singular shall include the plural and vice versa, and any pronoun shall include the corresponding masculine, feminine and neuter forms. If a term is defined as one part of speech (such as a noun), then it shall have a corresponding meaning when used as another part of speech (such as a verb).
Section 1.2.2 Coordinating Conjunctions . The word “or” shall have the inclusive meaning represented by the phrase “and/or.”
Section 1.2.3 Self-Reference . The words “hereof,” “herein,” “hereto” and “hereunder” and words of similar import when used in this Agreement shall, unless otherwise expressly specified, refer to this Agreement as a whole and not to any particular provision of this Agreement.
Section 1.2.4 Inclusive References . The words “include,” “includes” and “including” when used in this Agreement shall be deemed to be followed by “without limitation” or “but not limited to,” whether or not they are in fact followed by such words or words of like import.
17
Section 1.2.5 Incorporation by Reference . Any reference in this Agreement to an “Article,” “Section” or other subdivision or to an “Attachment” or other schedule or attachment shall be references to an article, section or other subdivision of, or to a schedule or attachment to, this Agreement, unless otherwise stated, and all such Articles, Sections and Attachments are incorporated into this Agreement by reference (all of which comprise part of one and the same agreement with equal force and effect). In the event of any conflict or other inconsistency between the main body of this Agreement and any attachment or schedule to this Agreement, the provisions of the main body of this Agreement shall prevail.
Section 1.2.6 Subsequent Acts . Any references in this Agreement to any statute shall be deemed to refer to such statute, as amended or replaced from time to time, including by succession of comparable successor statute, and all rules and regulations promulgated thereunder. In the event any index or publication referenced in this Agreement ceases to be published or a concept defined by reference to any such index or publication ceases to exist, each such reference shall be deemed to be a reference to a successor or alternate index, publication or concept reasonably agreed to by the Parties. Unless specified otherwise, a reference to a given agreement or instrument, and all schedules and attachments thereto, shall be a reference to that agreement or instrument as modified, amended, supplemented and restated, and as in effect from time to time.
Section 1.2.7 Inclusive of Permitted Successors . Unless otherwise expressly stated, references to any Person also include its permitted successors and assigns.
Section 1.2.8 Time Computation . In this Agreement, in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each means “to but excluding.”
Section 1.2.9 Business Days . Whenever this Agreement refers to a number of days, such number shall refer to calendar days unless Business Days are specified. Whenever any action must be taken under this Agreement on or by a day that is not a Business Day, such action may be validly taken on or by the next day that is a Business Day, and in the case of payments (including refunds of payments), no interest shall accrue on the amount due; provided that such payment is made in full on the next day that is a Business Day.
Section 1.2.10 Governmental Approvals . Except as otherwise expressly provided in this Agreement, any Governmental Approval shall be deemed to be received upon issuance, even if such Governmental Approval is subject to appeal or rehearing.
Section 1.2.11 Currency . All references to prices, values or monetary amounts referred to in this Agreement shall be paid in United States currency, unless expressly provided otherwise.
18
Article II
REGULATORY FILINGS AND REQUIRED APPROVALS
Section 2.1 MDPU Filing; FERC Filings.
(a) Owner shall use commercially reasonable efforts to cause Distribution Company to: (i) file for the Regulatory Approval as soon as practicable following the execution of the Distribution Company TSA, and (ii) use commercially reasonable efforts to file within sixty (60) days thereafter.
(b) Owner shall file the Distribution Company TSA with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing with FERC shall include waiver requests for the effective date of the Distribution Company TSA to occur consistent with Section 3.1 thereof, which effective date may be more than one hundred twenty (120) days before the Commercial Operation Date. Owner shall file this Agreement with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when the Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing shall include waiver requests for the Effective Date to occur consistent with Section 3.1 , which Effective Date may be more than one hundred twenty (120) days before the Commercial Operation Date.
(c) The Parties shall respond promptly to any requests for additional information made by FERC in connection with any such filings.
(d) Upon the filing of this Agreement pursuant to Section 2.1(b) , Purchaser and Owner shall support the approval or acceptance of this Agreement by FERC without modification or condition.
Section 2.2 Modifications to FERC Order.
(a) In the event (i) FERC issues an order accepting or approving this Agreement for filing (the “ FERC Order ”) and (ii) the FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to a Party, in its sole discretion (an “ Unfavorable FERC Decision ”), such Party shall deliver a written notice to the other Party specifying the issues, to the extent it is able, set for hearing or the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following the issuance of the Unfavorable FERC Decision.
(b) In the event of an Unfavorable FERC Decision, the Parties may agree upon amendments to this Agreement (each, a “ FERC Amendment ”) that achieve, as nearly as practicable, the commercial intent of this Agreement as of the Execution Date in a manner consistent with the Unfavorable FERC Decision. Any such amendment shall be subject to applicable regulatory approvals. As soon as practicable after any FERC Amendment(s) have been executed and delivered by the Parties, Owner shall file such FERC Amendment(s) with FERC.
19
(c) In the event of an Unfavorable FERC Decision, each Party shall retain the right to request a rehearing or reconsideration of the FERC Order regardless of any negotiations that have occurred or are occurring pursuant to clause (b) above; provided , however , that, in the event the Parties execute a FERC Amendment after any one or both of the Parties has filed for rehearing or reconsideration, any such rehearing or reconsideration request shall be withdrawn no later than five (5) Business Days after FERC issues an order accepting or approving the FERC Amendment for filing, if such rehearing or reconsideration request is inconsistent with the terms and conditions of this Agreement, as amended. Unless otherwise agreed in writing by the Parties, a filing by any Party of a request for rehearing or reconsideration of the FERC Order shall not toll or otherwise modify any date or time period set forth in this Agreement, including, for the avoidance of doubt, the date upon which the Construction Phase shall commence.
Section 2.3 Modifications Pursuant to Unfavorable MDPU Order or FERC Order . In the event the Regulatory Approval contains modifications or conditions that are unacceptable to Owner or Distribution Company, or in the event the MDPU issues an order setting for hearing Distribution Company’s submission (an order setting a hearing or containing unacceptable modifications or conditions is hereinafter referred to as “Unfavorable MDPU Order ”), Owner shall promptly deliver a written notice to Purchaser of such occurrence. In the event (i) FERC issues an order accepting or approving the Distribution Company TSA for filing (the “ Distribution Company TSA FERC Order ”) and (ii) the Distribution Company TSA FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to Owner or Distribution Company, Owner shall promptly deliver a written notice to Purchaser of such occurrence. Owner and Distribution Company may agree to amend the Distribution Company TSA to address such modifications or conditions or to eliminate the issues raised in any such order or hearing, as applicable (any of the foregoing amendments, a “ Distribution Company TSA Amendment ”); provided that any Distribution Company TSA Amendment shall be subject to the prior written approval of Purchaser, which approval shall not be unreasonably withheld, delayed or conditioned. As soon as practicable after any Distribution Company TSA Amendment has been executed, Owner shall file such Distribution Company TSA Amendment with FERC and, if required, Owner shall use commercially reasonable efforts to cause Distribution Company to file such Distribution Company TSA Amendment with the MDPU, and the Parties shall execute and deliver an amendment to this Agreement as necessary to correspond with such Distribution Company TSA Amendment.
Section 2.4 Cooperation.
(a) In addition to their obligations under Section 2.1 , each Party shall, and each Party shall use commercially reasonable efforts to cause its Affiliates to, (i) cooperate with each other to prepare, file and effect any applications, notices, petitions, reports or other filings or documentation required under Applicable Law or otherwise necessary, proper or advisable to consummate the transactions contemplated by this Agreement, (ii) provide updates to the other Party on material developments in connection with any such filings or documentation, (iii) provide any non-privileged information reasonably requested by the other Party in connection with any such filings or documentation, (iv) cooperate with the other Party to use commercially reasonable efforts to obtain all Governmental Approvals and Third Party Consents that are necessary, proper or advisable to consummate the transactions contemplated by this Agreement, including the FERC Authorization (without unacceptable modifications or conditions, except as permitted by this Agreement), the Municipal Owner Approvals, the other Owner Approvals and the Canadian Approvals and (v) provide any support reasonably necessary and requested by the AC Upgrade Owners to obtain the AC Upgrade Approvals.
20
(b) Each Party shall consult with the other Party with respect to all characterizations of information relating to such other Party, its Affiliates or the transactions contemplated by this Agreement that are proposed to appear in any filings or documentation contemplated by Section 2.1 or Section 2.4(a) . Each Party shall promptly provide comments, if any, to the other Party on any such characterizations of information. Each Party shall make a good faith effort to take into account any comments made by the other Party.
(c) Owner shall, and shall use commercially reasonable efforts to cause its Affiliates to, cooperate with Purchaser, as reasonably requested by Purchaser, to satisfy the conditions precedent in Section 3.4 of PPA and any related reporting requirements in the PPA in order for Purchaser to deliver and track unit specific accounting of environmental attributes, enabling the Massachusetts Department of Environmental Protection to accurately account for qualified clean energy in the state greenhouse gas emissions inventory, and transmit real time meter data and measurements to ISO-NE.
(d) Each Party shall use reasonable efforts to implement the provisions of, and to administer, this Agreement in accordance with the intent of the Parties to minimize all taxes, including delivery of the United States Internal Revenue Service Form W-9 and sales tax exemptions (if applicable), so long as neither Party is materially adversely affected by such efforts.
Section 2.5 No Inconsistent Action . Except as provided in Section 17.2 and Article XIX , from and after the Execution Date, the Parties shall not undertake, and shall use commercially reasonable efforts to cause their Affiliates not to undertake, any action before FERC, ISO-NE, or any other Governmental Authority that is contrary to the Party’s obligations under this Agreement, including, for the avoidance of doubt, Section 2.1(c) and Section 7.1.4 , or support any such contrary action by any Affiliate.
Article III
EFFECTIVE DATE; TERM
Section 3.1 Effective Date . Article I , Article II , this Section 3.1 , Section 3.3.1 , Section 3.3.2 , Article XVII , Article XVIII , Article XIX , Article XXII , and Article XXIII shall become effective and enforceable to the extent permitted by Applicable Law upon the Execution Date. The remaining provisions of this Agreement shall become effective and enforceable to the extent permitted by Applicable Law upon the effective date set forth in the FERC Order (the “ Effective Date ”). Notwithstanding the first sentence of this Section 3.1 , this Agreement will become effective as a FERC rate schedule upon the effective date set forth in the FERC Order. Notwithstanding any other provision of this Agreement, Purchaser shall have no obligation to make any payment under this Agreement prior to receipt of the Regulatory Approval and the FERC Authorization.
Section 3.2 Term . The term of this Agreement shall commence on the Execution Date and shall expire on the fortieth (40th) anniversary of the Commercial Operation Date, unless earlier terminated (in whole or in part) or extended in accordance with the terms hereof (the “ Term ”).
21
Section 3.3 Termination Rights . This Agreement may be terminated in accordance with the ensuing provisions in this Article III , subject to any required regulatory reviews, approvals or acceptances, as applicable. Neither Party shall oppose any termination of this Agreement made in accordance with this Article III before FERC or any other Governmental Authority; provided, however , that the foregoing shall not prohibit any Party from challenging or otherwise Disputing whether or not any such termination is permitted by this Agreement.
Section 3.3.1 Failure to Obtain Satisfactory Regulatory Approval and FERC Authorization .
(a) This Agreement may be terminated by any Party in the event (i) it determines that the Regulatory Approval or the FERC Authorization contain terms and conditions that are, in its sole discretion, unacceptable to such Party, (ii) the Regulatory Approval is denied or is not received by January 25, 2020 (such date, the “ Regulatory Approval Termination Outside Date ”), (iii) the Regulatory Approval of the PPA (as defined in the PPA) is not received within the time frame set forth therein and the PPA is terminated, (iv) the FERC Authorization is denied or is not received by January 25, 2020, or (v) the Distribution Company TSA is terminated pursuant to Section 3.3.1(a) of the Distribution Company TSA; provided that the termination right under this clause (a) is exercised by a Party within thirty (30) days after the effective date of the termination of the Distribution Company TSA.
(b) Upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.2 Mutual Agreement . This Agreement may be terminated at any time upon written agreement of the Parties.
Section 3.3.3 Failure to Obtain Certain Approvals .
(a) Unless otherwise agreed in writing by the Parties, this Agreement shall terminate immediately without further action of the Parties in the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline, any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline, or any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof).
(b) In the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline or if any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof), and the Distribution Company TSA has been terminated pursuant to Section 3.3.3(a) of the Distribution Company TSA, Owner shall pay to Distribution Company the amounts contemplated by Section 3.3.3(b) of the Distribution Company TSA, and Owner shall pay to Purchaser (i) an amount equal to the Credit Support provided by Purchaser under this Agreement, including any Credit Support provided by Purchaser pursuant to Section 4.1(c) and (ii) in the event the PPA is terminated pursuant to Section 9.2(b) thereof, an amount equal to the Fixed Credit Support.
22
(c) In the event any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline (as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof), and the Distribution Company TSA has been terminated pursuant to Section 3.3.3(a) of the Distribution Company TSA, Purchaser shall pay to Owner an amount equal to the Credit Support provided by Owner to Distribution Company under the Distribution Company TSA, including the Owner Security (as defined in the Distribution Company TSA) and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) of the Distribution Company TSA; provided that such amount shall exclude the Credit Support provided by Purchaser under this Agreement including any Credit Support provided by Purchaser pursuant to Section 4.1(c) .
(d) Except as otherwise provided in clause (b) or (c) above, upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.4 Purchaser Default .
(a) Owner shall have the right to terminate this Agreement in accordance with Section 14.4(a) .
(b) [Intentionally Omitted].
(c) Upon the exercise by Owner of its termination rights pursuant to clause (a) above, Owner shall have the right to recover from Purchaser, and Purchaser shall pay to Owner, the Purchaser Termination Payment in accordance with Section 14.4(a) .
(d) The exercise by Owner of its termination rights pursuant to clause (a) above shall constitute a waiver by Owner of all other remedies or damages that may be available at law or in equity against Purchaser; provided , however , that, except as provided in Section 14.7 , Owner shall not waive its right to, and Purchaser shall remain liable for, the Purchaser Termination Payment, any unpaid amounts owed by Purchaser pursuant to Section 8.1 , any amounts owed by Purchaser to Owner under Section 3.4 , Section 4.4.2 , or Section 4.4.3 and any indemnification obligations of Purchaser to Owner under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover the Purchaser Termination Payment or such indemnified or other amounts.
Section 3.3.5 Owner Default .
(a) Purchaser shall have the right to terminate this Agreement in accordance with Section 14.6(a) or Section 14.7(e)(i) .
(b) Upon the exercise by Purchaser of its termination rights pursuant to clause (a) above, subject to Section 14.7 , Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, the Owner Termination Payment in accordance with Section 14.6(a) .
23
(c) Subject to Section 14.7 , the exercise by Purchaser of its termination rights pursuant to clause (a) above shall constitute a waiver by Purchaser of all other remedies or damages that may be available at law or in equity against Owner; provided , however , that Purchaser shall not waive any right to, and Owner shall remain liable for, the Owner Termination Payment, any amounts owed by Owner to Purchaser under Section 3.4 or Section 14.7(f) hereof, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 hereof or any express modification of Purchaser’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Purchaser under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover such damages or such indemnified or other amounts owed to Purchaser by Owner.
Section 3.3.6 Force Majeure . This Agreement may be terminated in accordance with Section 15.1(c) .
Section 3.3.7 Extended Excused Outage . This Agreement may be terminated in accordance with Section 7.2(c) .
Section 3.4 Termination Payments.
(a) Within sixty (60) days following the termination of this Agreement pursuant to Section 3.3 , Owner shall deliver to Purchaser an invoice that sets forth Owner’s good faith estimate of the amounts owed to Owner by Purchaser under Section 3.3 , or Purchaser shall deliver to Owner an invoice that sets forth Purchaser’s good faith estimate of the amounts owed to Purchaser by Owner under Section 3.3 . The recipient of such invoice shall pay the amounts set forth in such invoice within thirty (30) days following its receipt of such invoice. Either Party may deduct and setoff payment of such amounts against any accrued but unpaid payment obligation of the payee to such Party hereunder. Upon the other Party’s request, the invoicing Party shall provide documentation describing the basis for the amounts invoiced in reasonable detail.
(b) The Parties acknowledge and agree that the payment of amounts by the defaulting Party to the non-defaulting Party pursuant to Section 3.3 or this Section 3.4 is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for the termination of this Agreement are difficult or impossible to determine and that the damages calculated under Section 3.3 or this Section 3.4 constitute a reasonable approximation of the harm or loss to the non-defaulting Party as a result thereof.
Section 3.5 Effect of Termination . Except as provided in Section 3.3 and in Section 23.12 for the survival of provisions, upon expiration or other termination of this Agreement pursuant to its terms, each of the Parties shall be released from all of its obligations under this Agreement, other than any accrued but unpaid payment obligation. Notwithstanding the foregoing sentence, upon such expiration or termination of this Agreement, either Party shall have the right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by such Party to recover any amounts owed to such Party by the other Party hereunder or to secure the release of any security or performance assurance provided by or on behalf of such Party after the later to occur of the end of the Term or the date on which any accrued but unpaid payment obligation of such Party to the other Party hereunder shall have been fully, finally and indefeasibly satisfied.
24
Article IV
COMMERCIAL OPERATION
Section 4.1 Critical Milestones.
(a) Subject to Section 4.1(c) , Section 4.1(d) and Section 4.1(e) , commencing on the Effective Date, Owner shall develop the NECEC Transmission Line in order to achieve the milestones set forth in clauses (i), (iii)-(v) and (vii) below, and Purchaser shall cause its Affiliates to develop the Québec Line in order to achieve the milestones set forth in clauses (ii), (vi) and (vii) below (each clause, a “ Critical Milestone ”) on or before the dates set forth in this Section 4.1(a) :
(i) Receipt of all Owner Approvals (other than the Municipal Owner Approvals) and AC Upgrade Approvals in final form by the Approval Deadline;
(ii) Receipt of all Canadian Approvals in final form by the Canadian Approval Deadline;
(iii) Receipt of the Municipal Owner Approvals in final form by the Municipal Owner Approval Deadline;
(iv) Closing of any financing required for the construction and operation of the NECEC Transmission Line or other demonstration to Purchaser’s reasonable satisfaction of the financial capability of Owner to construct the NECEC Transmission Line, including, as applicable, Owner’s financial obligations with respect to interconnection of the NECEC Transmission Line and construction of the AC Upgrades and the CCIS Capacity Upgrades by the Financing Deadline;
(v) Execution by Owner and a contractor of an agreement for the engineering, procurement, and construction of the converter station at the southern end of the HVDC Line and payment by Owner to the contractor of an initial payment of at least 5% of the total price of the agreement, both by the Converter Station Contract Deadline;
(vi) Execution by HQE of a contract that provides for the engineering, procurement, or construction of the converter station associated with the Québec Line by the Québec Converter Station Contract Deadline; and
(vii) Achievement of the Commercial Operation Date by the Target Date.
25
(b) Except for the achievement of the Commercial Operation Date, which shall be governed by the provisions of Section 4.2 , the Party responsible for achieving a Critical Milestone shall provide the other Party with written notice of the achievement of such Critical Milestone as set forth in Attachment B within seven (7) days after that achievement, which notice shall include information demonstrating with reasonable specificity that such Critical Milestone has been achieved. Each Party acknowledges that: (i) the Party receiving such notice does so solely to monitor progress toward the Commercial Operation Date; (ii) Purchaser shall not have any responsibility or liability for the development, construction, operation, and maintenance of the NECEC Transmission Line; and (iii) Owner shall not have any responsibility or liability for the development, construction, operation, and maintenance of the Québec Line.
(c) The following provisions shall govern the rights and obligations of the Parties to extend any of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA and the Critical Milestones not yet achieved under this Agreement:
(i) Purchaser may elect to require Owner to extend all of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA by up to four (4) six-month periods for a maximum combined period of two (2) years from the applicable dates set forth in Section 4.1(a) thereof by delivering Credit Support to Owner for the benefit of Distribution Company (in addition to the Twenty-One Million, Eight Hundred Thousand Dollars ($21,800,000) of security delivered to Distribution Company and the other RFP Sponsors by Purchaser pursuant to the PPA and the Additional PPAs) in an amount equal to $5,000 per MW of PPA Contract Maximum Amount for each such six-month period, with a pro rata adjustment of the amount of any such additional Credit Support for any partial reduction of the applicable six-month period pursuant to Section 4.1(e) . Any such election shall be made in a written notice to Owner on or prior to the first date for a Distribution Company TSA Critical Milestone that has not yet been achieved (as such date may have previously been extended). Such additional Credit Support shall be provided by Purchaser if there is a Purchaser Delay and Purchaser wishes to extend any Distribution Company TSA Critical Milestone date. In the event that there is both an Owner Delay and a Purchaser Delay and either Party wishes to extend any Distribution Company TSA Critical Milestone date by delivering additional Credit Support to Distribution Company, the additional Credit Support shall be provided in equal parts by Owner and Purchaser. Owner shall cause any additional Credit Support provided by Purchaser pursuant to this Section 4.1(c) to be returned to Purchaser upon the Commercial Operation Date; provided that, in the event the Commercial Operation Date is not achieved by the Target Date, Distribution Company shall have the rights and remedies set forth in Article XIV of the Distribution Company TSA, which, for the avoidance of doubt, shall include recourse against any Credit Support provided to Distribution Company.
26
(ii) Owner may elect to extend all of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA in accordance with Section 4.1(c) of the Distribution Company TSA. Such additional Credit Support shall be provided by Owner if there is an Owner Delay and Owner wishes to extend any Distribution Company TSA Critical Milestone date. In the event that there is both an Owner Delay and a Purchaser Delay and either Party wishes to extend any Distribution Company TSA Critical Milestone date by delivering additional Credit Support to Distribution Company, the additional Credit Support shall be provided in equal parts by Owner and Purchaser.
(iii) Upon any extension of any of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA, the corresponding dates for the Critical Milestones not yet achieved hereunder shall be extended accordingly; provided that Owner shall not agree to any extension of the Distribution Company TSA Critical Milestones beyond what is permitted under the Distribution Company TSA or this Agreement without the prior written consent of Purchaser, such consent not to be unreasonably withheld, conditioned or delayed.
(d) To the extent a Force Majeure event pursuant to Section 15.1 has occurred that prevents Owner or Purchaser from achieving the Critical Milestone dates for execution of the contract to purchase the converter station for the NECEC Transmission Line ( Section 4.1(a)(v) ), execution of the contract to purchase the converter station for the Québec Line ( Section 4.1(a)(vi) ) or the Commercial Operation Date ( Section 4.1(a)(vii) ) by the applicable Critical Milestone date, the Critical Milestone date(s) impacted by such Force Majeure event shall be extended for the duration of the Force Majeure event, but under no circumstances shall extensions of those Critical Milestone dates exceed twelve (12) months beyond the applicable Critical Milestone date provided that (i) Owner shall not have the right to declare a Force Majeure event related to the Critical Milestone for Owner Approvals ( Section 4.1(a)(i) ), Municipal Owner Approvals ( Section 4.1(a)(iii) ), or the financing Critical Milestones ( Section 4.1(a)(iv) ); and (ii) Purchaser shall not have the right to declare a Force Majeure event related to the Critical Milestone for Canadian Approvals ( Section 4.1(a)(ii) ).
(e) In the event of a Regulatory Approval Delay, the date for each Critical Milestone not yet achieved shall be extended for the duration of the delay. The number of days of extension pursuant to the six-month extensions available under Section 4.1(c) shall be reduced by one day for each day of Regulatory Approval Delay pursuant to this subsection (e) up to a maximum reduction of 365 days. For purposes of illustration, Regulatory Approval Delay of two hundred ten (210) days would allow the Parties two six-month extensions and one extension of five months .
27
Section 4.2 Commercial Operation Date.
(a) The “ Target Date ” for Commercial Operation is December 13, 2022 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing. Absent written agreement by the Parties, the Target Date may not be extended beyond December 13, 2024 unless such extension is due to Regulatory Approval Delay or an event of Force Majeure as set forth in Sections 4.1(d) and 4.1(e) . The provisions of Sections 4.1(c) , 4.1(d) and 4.1(e) and all other provisions of this Agreement are subordinate to this Section 4.2(a) and the aforesaid Section 4.1 provisions and such other provisions shall be construed in a manner that is consistent with this Section 4.2(a) . Owner shall provide a written non-binding notice to Purchaser no later than sixty (60) days before the date Owner reasonably expects the Commercial Operation Date to occur.
(b) At the request of Owner made in writing, Purchaser shall, and shall use commercially reasonable efforts to cause its Affiliates to, cooperate with Owner, TransÉnergie and ISO-NE to support the Commissioning of the HVDC Transmission Project.
(c) As soon as practicable after Owner is of the opinion that the conditions to Commercial Operation, as set forth in Section 4.3 , have been satisfied, or such conditions have been waived in writing by the Parties (except in the case of Section 4.3(b) , Section 4.3(e) , Section 4.3(g) , Section 4.3(h) and Section 4.3(i) , which conditions may be waived in writing by Purchaser in its sole discretion), Owner shall deliver a written notice to Purchaser specifying the date upon which Commercial Operation shall commence (the “ COD Notice ”), which commencement date shall occur no earlier than ten (10) Business Days after the receipt by Purchaser of the COD Notice or on such other date as agreed upon by the Parties in writing (such date, the “ Commercial Operation Date ”).
(d) Within five (5) Business Days after the receipt by Purchaser of the COD Notice, Purchaser shall deliver a certificate to Owner either (i) confirming that the conditions set forth in Section 4.3 have been satisfied or duly waived and that Commercial Operation may commence on the Commercial Operation Date or (ii) objecting with reasonable detail to the COD Notice. Purchaser’s failure to respond in writing to a COD Notice within such five (5) Business Day period shall be deemed to be a confirmation that the conditions set forth in Section 4.3 have been satisfied or duly waived. Any Dispute over whether or not the conditions set forth in Section 4.3 have been satisfied or duly waived shall be resolved in accordance with Article XVII .
Section 4.3 Conditions Precedent to Commercial Operation . The items set forth in clauses (a) through (i) below shall be conditions precedent to the Commercial Operation of the NECEC Transmission Line:
(a) Completion of the Commissioning of the HVDC Transmission Project by Owner (in coordination with ISO-NE) and TransÉnergie;
28
(b) The NECEC Transmission Line has been constructed in accordance with Attachment A and Good Utility Practice, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(c) and Section 4.4.3(b) ;
(c) Completion of the AC Upgrades and the CCIS Capacity Upgrades;
(d) The Interconnection Agreements shall be in full force and effect;
(e) The Transmission Operating Agreement shall be in full force and effect and ISO-NE shall have informed Owner that ISO-NE (i) is prepared to assume operational control over the NECEC Transmission Line, as defined in, and in accordance with, the Transmission Operating Agreement and (ii) will assume such operational control as of the Commercial Operation Date;
(f) The Québec Line has been constructed in accordance with Attachment A , and is capable of operating at, the Design Capability, except as otherwise permitted pursuant to Section 4.4.2(b) and Section 4.4.3(b) ;
(g) Receipt by Purchaser of copies of certificates evidencing all outstanding insurance required or otherwise obtained under Section 5.4 ;
(h) Receipt by Purchaser of an opinion of legal counsel, reasonably satisfactory to Purchaser, that all Governmental Approvals and Third Party Consents required to own and operate the NECEC Transmission Line have been obtained;
(i) Distribution Company has confirmed (or has been deemed to have confirmed) that the conditions set forth in Section 4.3 of the Distribution Company TSA have been satisfied or duly waived; and
(j) The PPA is in full force and effect and binding against the parties thereto (except where the PPA has been terminated by mutual agreement of the parties to the PPA).
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation .
Section 4.4.1 Owner Delay . If, other than solely as a result of a Purchaser Delay, Force Majeure, or Concurrent Delay, any conditions set forth in Section 4.3 shall not have been satisfied or duly waived by the Target Date (such delay, an “ Owner Delay ”):
(a) Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, for each day (or part thereof) following the Target Date during which the Owner Delay is continuing and, but for such Owner Delay, Purchaser would then be capable of delivering the energy and providing the environmental attributes to Distribution Company as provided in the PPA, an amount equal to Fifty Dollars ($50) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Purchaser terminates this Agreement pursuant to Section 14.6 or Distribution Company terminates the Distribution Company TSA pursuant to Section 14.4 thereof and (z) the date that is twelve (12) months after the Target Date.
29
(c) Owner’s Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the Québec Line is capable of operating at or above 1,090 MW and the NECEC Transmission Line is only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line is capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the NECEC Transmission Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then Owner shall have twenty-four (24) months from the Commercial Operation Date to attempt to increase such operating capacity to 1,090 MW (the “ Remediation Period ”); provided that upon any extension of the Remediation Period (as defined in the Distribution Company TSA) under the Distribution Company TSA, the Remediation Period hereunder shall be extended accordingly. Owner shall pay to Purchaser, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period, or such earlier date designated by Owner in writing to Distribution Company (the “ Owner Remediation Date ”), an amount equal to Fifty Dollars ($50) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and the operating capacity of the NECEC Transmission Line as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Purchaser to Owner. Owner’s payments shall be based on the actual operating capacity of the NECEC Transmission Line, as is stated in Section 8.1 .
(ii) If, on the earlier of the Owner Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line has been increased to at or above 1,075 MW but less than 1,090 MW, then Owner shall be liable to Purchaser for an amount equal to the Proportionate Share multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the Commercial Operation Date in connection with the development and construction of the Québec Line multiplied by the percentage equal to (A) the difference between (x) the 1,090 MW and (y) the operating capacity of the NECEC Transmission Line divided by (B) the 1,090 MW. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(d) The Parties acknowledge and agree that the payment of amounts by Owner to Purchaser under clauses (a) and (c) above are an appropriate remedy and that any such modification or payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for an Owner Delay or a reduction in operating capacity, as described in clause (c), are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Purchaser as a result thereof.
30
(e) The rights provided in Section 3.3.5 , this Section 4.4.1 , and Section 4.4.3 shall collectively be the sole and exclusive remedies of Purchaser with respect to an Owner Delay or a reduction in operating capacity, as described in clause (c). The foregoing sentence shall not be construed in any way to limit (i) Purchaser’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement, or (ii) Purchaser’s rights to recover payment of any indemnification obligations of Owner to Purchaser pursuant to Section 20.2 .
Section 4.4.2 Purchaser Delays .
(a) Subject to any extension of any Critical Milestone date pursuant to the Distribution Company TSA or Section 4.1(c) , Section 4.1(d) , or Section 4.1(e) hereof, if, except in the event of Force Majeure, on the Target Date, solely as a result of delays in completing the Québec Line or operational difficulties with the Québec Line (a “ Purchaser Delay ”), the Commercial Operation Date is delayed, for each day (or part thereof) during which the Purchaser Delay is continuing, Purchaser will pay to Owner an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Owner terminates this Agreement pursuant to Section 14.4 or Distribution Company terminates the Distribution Company TSA pursuant to Section 3.3.8 thereof and (z) twelve (12) months after the Target Date.
(b) Purchaser’s Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line is capable of operating at or above 1,090 MW and the Québec Line is only capable of operating below 1,090 MW, and (A) the Québec Line is capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the Québec Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then Purchaser shall have the Remediation Period to attempt to increase the operating capacity of the Québec Line to 1,090 MW; provided that upon any extension of the Remediation Period (as defined in the Distribution Company TSA) under the Distribution Company TSA, the Remediation Period hereunder shall be extended accordingly. Purchaser shall pay to Owner, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period, or such earlier date designated by Owner pursuant to the Distribution Company TSA (the “ Purchaser Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and the operating capacity of the Québec Line.
31
(ii) If, on the earlier of the Purchaser Remediation Date and the end of the Remediation Period, the operating capacity of the Québec Line has been increased to at or above 1,075 MW but less than 1,090 MW, then Purchaser shall be liable to Owner for the Québec Line Capacity Deficiency Payment. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the Québec Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(c) The Parties acknowledge and agree that the payment of amounts by Purchaser to Owner under clauses (a) and (b) above, respectively, are an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Purchaser Delay or a reduction in operating capacity, as described in clause (b) , are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Owner as a result thereof.
(d) The rights provided in Section 3.3.4 , this Section 4.4.2 and Section 4.4.3 shall collectively be the sole and exclusive remedies of Owner with respect to a Purchaser Delay or a reduction in operating capacity, as described in clause (b) . The foregoing sentence shall not be construed in any way to limit (i) Owner’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Purchaser under this Agreement, or (ii) Owner’s rights to recover payment of any indemnification obligations of Purchaser to Owner pursuant to Section 20.1 .
Section 4.4.3 Concurrent Delays .
(a) In the event of a concurrent Purchaser Delay and Owner Delay (a “ Concurrent Delay ”), for each day (or part thereof) during which a Concurrent Delay is continuing, Owner shall pay to Distribution Company the amounts required under Section 4.4.2(a) of the Distribution Company TSA; provided , however , that Purchaser shall be liable to Owner for such portion of the amounts paid by Owner to Distribution Company under Section 4.4.2(a) of the Distribution Company TSA that is in proportion to Purchaser’s share of liability for the Concurrent Delay.
(b) Concurrent Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are both only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line and the Québec Line are both capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the NECEC Transmission Line or the Québec Line, or both, are capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then the Parties shall have the Remediation Period to attempt to increase the operating capacity of their respective lines to 1,090 MW. If the actual capacity of the Québec Line is less than the actual capacity of the NECEC Transmission Line as of the Commercial
32
Operation Date, Purchaser shall pay to Owner, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period or such earlier date designated by Owner pursuant to the Distribution Company TSA (the “ Concurrent Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between the lesser of (x) the actual capacity of the NECEC Transmission Line and (y) 1,090 MW and the actual capacity of the Québec Line as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Owner to Purchaser.
(ii) Québec Line Capacity is Lower . If, on the earlier of the Concurrent Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW (and Distribution Company has waived any deficiency in capacity of the Québec Line or the NECEC Transmission Line), and the actual capacity of the Québec Line is less than the actual capacity of the NECEC Transmission Line, then Purchaser shall be liable to Owner for the Québec Line Capacity Deficiency Payment. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the Québec Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(iii) NECEC Transmission Line Capacity is Lower . If, on the earlier of the Concurrent Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW, and the actual capacity of the NECEC Transmission Line is less than the actual capacity of the Québec Line, then Owner shall be liable to Purchaser for an amount equal to the Proportionate Share of the difference between the actual capacity of the Québec Line and the actual capacity of the NECEC Transmission Line as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period, divided by an amount equal to 1,090 MW minus the actual capacity of the NECEC Transmission Line, multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period in connection with the development and construction of the Québec Line. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(iv) Both Lines Have Capacity Shortfall . If: (1) as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are both not capable of operating at or above 1,040 MW, and Distribution Company has not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability, or (2) as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period, the NECEC Transmission Line and the Québec Line are both not capable of operating at or above 1,075 MW and Distribution Company has not waived such deficiency under the Distribution Company TSA, then Purchaser shall pay to Owner one-half (1/2) of the Owner Termination Payment (as defined in the Distribution Company TSA) payable to Distribution Company under the Distribution Company TSA as a consequence thereof.
33
Article V
GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES
Section 5.1 Responsibilities of the Parties .
Section 5.1.1 Construction Phase .
(a) During the Construction Phase, Owner shall (i) exercise Good Utility Practice to complete, or cause the completion of, all tasks required to construct the NECEC Transmission Line, interconnect at least 1,090 MW of capacity with ISO-NE in compliance with the Capacity Capability Interconnection Standard, and achieve Commercial Operation by the Target Date, in each case, in accordance with the Design Capability and in a manner consistent with Attachment A and (ii) use commercially reasonable efforts (A) to obtain all of the Construction Authorizations (other than the Municipal Owner Approvals) by the Approval Deadline and to obtain the Municipal Owner Approvals by the Municipal Owner Approval Deadline, (B) to obtain, in consultation with Purchaser, the ISO-NE Approval by the Approval Deadline and (C) to cause Owner’s Affiliates that are AC Upgrade Owners to obtain any AC Upgrade Approvals for which such Affiliates are responsible by the Approval Deadline and to assist other AC Upgrade Owners in obtaining their respective AC Upgrade Approvals by the Approval Deadline.
(b) Owner will use commercially reasonable efforts to enter into, within a commercially reasonable timeframe, one or more Construction Contracts. Owner will make a copy of any such contract available to Purchaser subject to such redactions as Owner or the contracting party deem necessary to protect confidential information.
(c) [Intentionally Omitted.]
(d) During the Construction Phase, Purchaser shall take commercially reasonable steps to cause its Affiliate, TransÉnergie, to exercise Good Utility Practice to complete, or cause the completion, of all tasks required to construct the Québec Line in accordance with the applicable design, as set forth in Attachment A , prior to the Target Date and to cooperate with Owner to enable the achievement of Commercial Operation by the Target Date, and Purchaser shall cause TransÉnergie to use commercially reasonable efforts to obtain the Canadian Approvals by the Canadian Approval Deadline.
Section 5.2 Schedules and Reports .
Section 5.2.1 Owner’s Preliminary Schedule . Attached hereto as Attachment E is Owner’s Project Schedule (the “ Owner’s Preliminary Schedule ”). At the request of Purchaser, Owner shall make the personnel responsible for preparing the Owner’s Preliminary Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Preliminary Schedule with Purchaser.
34
Section 5.2.2 Owner’s Construction Schedule . Within ten (10) days after the end of each calendar quarter and sooner if a material change occurs, commencing at least ninety (90) days prior to the commencement of construction , Owner shall prepare and submit to Purchaser for review an update of the Owner’s Preliminary Schedule (such updated schedule as established herein, the “ Owner’s Construction Schedule ”). At the request of Purchaser, Owner shall make the personnel responsible for preparing the Owner’s Construction Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Construction Schedule with Purchaser.
Section 5.2.3 Owner’s Progress Reports .
(a) Promptly following the Execution Date, Owner shall deliver to Purchaser copies of all applications that have been submitted by Owner with respect to any Owner Approvals, as well as all material correspondence and submittals relating to such Owner Approvals. Within ten (10) days after the end of each calendar quarter, commencing at receipt of the Regulatory Approval, Owner shall prepare and submit to Purchaser for review a progress report for informational purposes that sets forth in reasonable detail the current status of the milestones set forth in the Owner’s Construction Schedule, including any changes in the expected timelines and the status of all Owner Approvals and including copies of any Owner Approval applications, material correspondence and submittals relating to Owner Approvals, and any issued Owner Approvals (the “ Owner’s Construction Progress Report ”). Without limitation of the foregoing, Owner shall include in such reports relevant information relating to: (i) Owner’s efforts to mitigate the impacts of the NECEC Transmission Line on natural resources, environmentally sensitive areas, habitats, and wildlife species, and cultural and historic resources; (ii) Owner’s efforts to comply with applicable noise ordinances; (iii) Owner’s communication and community outreach efforts and plans with respect to the construction of the NECEC Transmission Line, including with stakeholders in Massachusetts; and (iv) Owner’s analysis of, and any material developments related to, the Municipal Owner Approvals (or any applications to the Maine Public Utilities Commission to exempt Owner from the requirement to obtain any Municipal Owner Approval). In delivering the Owner’s Construction Progress Report, Owner shall be deemed to certify that the list of required Municipal Owner Approvals identified in paragraph 10 of Attachment C is accurate and complete as of the date of delivery of the Owner’s Construction Progress Report except as supplemented in such report. At the request of Purchaser, Owner shall, or shall cause each contractor to, provide Purchaser with access to, and copies of, all reasonably requested documentation concerning such Owner’s Construction Progress Report.
(b) Owner shall, or shall cause the principal contractor to, notify Purchaser promptly, but in no event later than ten (10) days, after Owner, or such contractor, becomes aware that the Commercial Operation of the NECEC Transmission Line is not reasonably likely to occur by the Target Date.
35
Section 5.3 Québec Line Reports; Joint Development Agreement . Purchaser agrees to cooperate with and support Owner in connection with the negotiation and execution of a joint development agreement between TransÉnergie and Owner relating to the Owner Approvals, the Canadian Approvals and construction and design matters relating to the Québec Line and the NECEC Transmission Line (such agreement, the “ Joint Development Agreement ”). Until the execution of the Joint Development Agreement, Purchaser shall promptly provide to Owner all material information received from TransÉnergie with respect to progress on the construction of the Québec Line, including information related to the Canadian Approvals.
Section 5.4 Insurance and Events of Loss . Owner shall obtain and maintain with reputable insurers authorized to operate in the scope of the Agreement insurance of the type as set forth in Attachment F . Owner shall provide Purchaser with copies of certificates of all outstanding insurance obtained hereunder promptly after the receipt thereof by Owner. Owner shall notify Purchaser as soon as reasonably possible if and whenever an event of loss occurs. Without limitation of any obligations Owner may have under Section 15.1 hereof, in the event of damage to or loss of all or part of the NECEC Transmission Line, Owner shall exercise prompt, diligent commercially reasonable efforts to effectuate, in accordance with Good Utility Practice, such repairs and replacements as are necessary or desirable to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss, including, for the avoidance of doubt, the application to such repairs or replacements of any potential or actual proceeds realized in connection with such damage or loss under any available or applicable insurance policies (subject to insurance contract/policy terms and conditions of coverage) maintained pursuant to this Section 5.4 . Subject to Owner’s compliance, in all material respects, with this Section 5.4 , Section 6.3 and all other material terms and conditions with respect to the operation and maintenance of the NECEC Transmission Line, in the event that the costs to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss exceed the available insurance proceeds by more than the greater of (a) an amount equal to three percent (3%) of the Net Book Value of the NECEC Transmission Line and (b) Thirty Million Dollars ($30,000,000), the Parties will negotiate in good faith an appropriate allocation of financial responsibility for such excess costs. In the event that the Parties do not agree on the allocation of financial responsibility, Purchaser shall be entitled to terminate this Agreement, upon thirty (30) days’ written notice to Owner, without liability to Owner; provided that, if within the thirty (30) day period following receipt of such notice, Owner agrees to assume that portion of the allocation of financial responsibility to which Purchaser objected, then the termination notice shall be deemed revoked and this Agreement shall not be terminated.
Section 5.5 Compliance with Laws . At all times during the Term, the Parties shall comply with all Applicable Laws (including ISO-NE Rules to the extent applicable) and relevant Governmental Approvals and Third Party Consents.
Section 5.6 Third Party Contracts . At all times during the Term, Owner shall, in a commercially reasonable manner, (a) satisfy its obligations under all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades, and (b) administer all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades.
36
Section 5.7 Purchaser’s Losses . Neither Purchaser nor its Affiliates shall be entitled to recover from Owner any losses, damages, costs or expenses related to the Québec Line or arising under the TransÉnergie OATT, except to the extent included in (a) an Owner Termination Payment, or (b) any damages paid pursuant to Section 4.4.1(a), Section 4.4.1(c), or Section 4.4.3.
Section 5.8 Continuity of Rights and Responsibilities . Unless otherwise agreed in writing by the Parties or prohibited by Applicable Law, the Parties shall continue to provide service and honor commitments under this Agreement and continue to make payments in accordance with this Agreement pending resolution of any bona fide Dispute hereunder or relating hereto.
Section 5.9 Right of First Offer to Purchase NECEC Transmission Line .
(a) Subject to the receipt of any required regulatory approvals and Third Party Consents, prior to conducting any Marketing Activities, Owner shall provide Purchaser with the right to offer to buy, directly or through an Affiliate, the NECEC Transmission Line in accordance with this Section 5.9 , by providing Purchaser with written notice of Owner’s intent to sell the NECEC Transmission Line (to the extent that such sale relates only to the NECEC Transmission Line without any other material assets) (such notice, a “ Marketing Notice ”). Upon receipt of the Marketing Notice, Purchaser shall then have forty five (45) days to make an offer to purchase the NECEC Transmission Line, which offer shall contain reasonably detailed information relating to the price (such price, the “ Offer Price ”) and all material economic terms of the transaction upon which Purchaser is willing to purchase the NECEC Transmission Line. If Purchaser elects to make such an offer, Owner shall, within thirty (30) days following the receipt of such offer, either (i) accept such offer, in which case the parties will proceed to close the purchase of the NECEC Transmission Line within the next sixty (60) days (or such longer period as is reasonably necessary to obtain all required approvals and consents) on the terms contained in such offer, or (ii) reject such offer.
(b) If Owner rejects the offer made by Purchaser, then Owner shall be free to thereafter sell the NECEC Transmission Line to third parties (subject to the provisions of this Agreement) within the twelve (12) months following the date of Owner’s rejection of Purchaser’s offer for a price higher than one hundred percent (100%) of the Offer Price, with economic terms not materially less favorable to Owner (taken in the aggregate) than those contained in Purchaser’s offer (or, if materially less favorable, then with such adjustments to the price to account for any such material differences in the economic terms of the sale).
Section 5.10 Amendment to the PPA . Purchaser shall not amend or otherwise modify the PPA, or seek or provide any waiver of any term or condition of the PPA, in a manner that adversely and materially affects Purchaser’s rights under this Agreement or that would result in an increase in Owner’s liability pursuant to clause (b) of “Owner Termination Payment,” clause (b)(ii) of “Owner Termination Payment” (as defined in the Distribution Company TSA) or Section 3.3.3 or that would affect Owner’s rights under Section 7.2(b) without the consent of Owner, which consent shall not be unreasonably withheld, conditioned or delayed. Purchaser shall provide Owner with notice of any amendment or other modification to Section 8.3 of the PPA prior to the effective date of such amendment.
37
Section 5.11 Amendment to the Distribution Company TSA . Owner shall not (a) terminate the Distribution Company TSA pursuant to Section 3.3.2 thereof or (b) agree to any amendment or other modification of the Distribution Company TSA, or seek or provide any waiver of any term or condition of the Distribution Company TSA, that adversely and materially affects Purchaser’s rights under this Agreement (including in a manner that would result in an increase in the credit support provided by Owner under the Distribution Company TSA), in each case without the consent of Purchaser, which consent shall not be unreasonably withheld, conditioned or delayed.
Article VI
PROCEDURES FOR OPERATION AND MAINTENANCE
OF THE NECEC TRANSMISSION LINE
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control .
(a) Prior to entering into the Transmission Operating Agreement, Owner shall consult Purchaser with respect to the proposed terms and conditions thereof and Owner shall make a good faith effort to take into account any comments made by Purchaser. Purchaser shall promptly provide comments, if any, to Owner on such terms and conditions.
(b) As of the Commercial Operation Date, Owner shall transfer operational control over the NECEC Transmission Line, as defined in the Transmission Operating Agreement, to Transmission Operator in accordance with the Transmission Operating Agreement. Owner shall provide, and shall direct its Affiliates to provide, such information as Transmission Operator may require to discharge its obligations under the Transmission Operating Agreement, and Owner shall comply with the instructions of Transmission Operator to the extent provided in the Transmission Operating Agreement and the ISO-NE Tariff. The Parties acknowledge and agree that Owner shall not be in breach of, or be liable to Purchaser under, this Agreement, and no Owner Default shall occur, as a consequence of Owner’s compliance with such instructions of Transmission Operator; provided that Owner did not initiate or support instructions that would otherwise breach Owner’s obligations under this Agreement.
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements . From and after the Commercial Operation Date, Owner shall (a) provide Firm Transmission Service, (b) operate and maintain the NECEC Transmission Line in accordance with Good Utility Practice and in compliance with all applicable regulatory requirements, including applicable NERC and Northeast Power Coordinating Council reliability standards, and (c) comply with all applicable operating instructions of ISO-NE and manufacturers’ warranties.
Section 6.3 Scheduled Maintenance . With respect to each calendar year (or portion thereof) following the Construction Phase, Owner will prepare and deliver to Purchaser a Maintenance Plan not later than the Commercial Operation Date and two (2) months prior to the end of each calendar year thereafter, and shall be available for consultation with Purchaser with respect thereto (including for coordination of maintenance schedules). Consistent with Good
38
Utility Practice, Owner shall use commercially reasonable efforts to coordinate with TransÉnergie with respect to scheduled maintenance so as to minimize outages, including by meeting annually (or as otherwise necessary in order to comply with any applicable ISO-NE or Canadian regulatory or system operator requirements) to develop a Maintenance Plan. From and after the Commercial Operation Date, Owner shall coordinate all planned maintenance with ISO-NE, consistent with ISO-NE Rules, and shall promptly provide applicable information concerning scheduled outages, as determined by ISO-NE, to Purchaser. To maximize value, to the extent possible and consistent with ISO-NE Rules, Owner shall not schedule maintenance of the NECEC Transmission Line during the months of December, January and February or June through September and shall operate the NECEC Transmission Line so as to maximize energy production during the hours of anticipated peak load and energy prices in New England; provided, however, that planned maintenance may be scheduled during such period to the extent the failure to perform such planned maintenance is contrary to operation of the NECEC Transmission Line in accordance with Good Utility Practice. Owner may modify a Maintenance Plan in accordance with Good Utility Practice; provided , however , that (a) a Maintenance Plan may not be modified for the purpose of reducing the magnitude or duration of a Non-Excused Outage, (b) any modification shall, to the extent commercially reasonable, maximize value in the manner described in this Section 6.3 and (c) Owner shall provide Purchaser with reasonable notice of any change in a Maintenance Plan. Any maintenance that is not included in the Maintenance Plan for a year and is not otherwise excused under Section 7.2 shall be a Non-Excused Outage.
Article VII
PURCHASER’S TRANSMISSION RIGHTS OVER THE
NECEC TRANSMISSION LINE
Section 7.1 Transmission Service .
Section 7.1.1 Firm Transmission Service. Owner shall make available to Purchaser throughout the Purchaser Term transmission capacity on the NECEC Transmission Line in order to deliver electrical energy, as scheduled by Purchaser or its designee or assignee under the resale provisions of Article X, in such scheduled amount up to the Contract Capacity, measured at the Delivery Point (“ Firm Transmission Service ”). Firm Transmission Service shall be made available over the NECEC Transmission Line during the Purchaser Term, in a north-to-south direction, and to the extent available in a south-to-north direction, between the U.S. Border and the Delivery Point. Firm Transmission Service shall be subject to curtailment or interruption only as a result of an Excused Outage or as provided in Section 14.4(b). Without limiting Owner’s obligations under this Section 7.1.1, the quantity of Firm Transmission Service that Owner will provide in any hour shall not exceed the Proportionate Share of the Available Transfer Capability for such hour.
Section 7.1.2 Limitation on Transmission Service . Owner shall have no obligation to provide transmission service under this Agreement other than Firm Transmission Service. Purchaser shall have no right to redirect service to alternate points of delivery or receipt on any portion of the transmission system operated by ISO-NE other than the NECEC Transmission Line.
39
Section 7.1.3 Scheduling . All Firm Transmission Service shall be scheduled in accordance with the rules relating to the scheduling of electrical energy or capacity transactions over the NECEC Transmission Line, as established under the Transmission Operating Agreement (the “ Scheduling Rules ” ).
Section 7.1.4 Owner’s Cooperation . Owner shall provide Purchaser with notice of any FERC or NERC regulatory proceedings relating to the NECEC Transmission Line or this Agreement to which Owner is a party promptly after Owner becomes aware of any such proceedings. Each Party will act in good faith regarding any such proceedings. Neither Party shall take any position in such proceeding that is contrary to such Party’s obligations under this Agreement.
Section 7.2 Excused Outages or Reductions .
(a) Notwithstanding anything herein to the contrary, Owner shall not be in breach of, or be liable to Purchaser for any losses or damages under, this Agreement, and no Owner Default shall occur, as a consequence of an Excused Outage. “ Excused Outages ” means any outages of the NECEC Transmission Line or reductions in the Total Transfer Capability below the NECEC Transmission Line Capacity, whether as a result of a physical condition, legal impediment or otherwise, if and to the extent such outage or reduction is due to:
(i) Events of Force Majeure;
(ii) Scheduled maintenance in accordance with the applicable Maintenance Plan;
(iii) Outages or reductions in the availability of the Québec Line for any reason; or
(iv) Decisions of ISO-NE or any other independent system operator to reduce or suspend scheduling rights over the NECEC Transmission Line or the Québec Line, including as a result of any grid reliability issue, emergency condition as defined in any Interconnection Agreement or the ISO-NE Tariff, or to preserve facilities and equipment from physical damage and including any such decisions that arise from outages or reductions in the use or availability of transmission lines other than the NECEC Transmission Line or the Québec Line, which outage or reduction arises from or is attributable to Force Majeure or scheduled maintenance.
(b) Notwithstanding anything in Section 7.3.1 to the contrary, Purchaser shall remain obligated, during and to the extent of any Excused Outage, to pay the Transmission Service Payment without downward adjustment to reflect any such outage, reduction or delay. Owner shall seek to avoid and mitigate or remedy any Excused Outage consistent with Good Utility Practice.
40
(c) Notwithstanding anything herein to the contrary and without regard to whether an Excused Outage is due to Force Majeure, if an Excused Outage prevents Owner’s full or partial performance under this Agreement during the Purchaser Term for a period of twelve (12) consecutive months or more, Purchaser shall have the right, as provided in Section 15.1(c) herein, to terminate this Agreement upon written notice to Owner and without further recourse.
Section 7.3 Non-Excused Outages or Reductions .
Section 7.3.1 Reduction in Transmission Service Payments . In the event the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), u nless otherwise excused under Section 7.2 or Section 11.1 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 during the Term or firm transmission service contemplated by Section 7.1.1 of the Distribution Company TSA during the term of the Distribution Company TSA, Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, for each such month during which a Non-Excused Outage occurs, the Non-Excused Outage Payment; provided that, in no event, shall the total amount of (a) all Non-Excused Outage Payments made in any Contract Year under this Agreement plus (b) all Non-Excused Outage Payments (as defined in the Purchaser TSAs) made in any Contract Year plus (c) all Non-Excused Outage Payments (as defined in the 110 MW TSA) made in any Contract Year exceed Twenty Million Dollars ($20,000,000); provided further that such cap shall be proportionately reduced in any Contract Year that is less than a full calendar year. Any Dispute over whether or not or to what extent a Non-Excused Outage has occurred shall be resolved in accordance with Article XVII. Such amounts shall be payable on a monthly basis pursuant to invoices delivered by Purchaser to Owner. Owner shall seek to avoid, mitigate and remedy any Non-Excused Outage consistent with Good Utility Practice.
Section 7.3.2 [Intentionally Omitted] .
Section 7.3.3 Liquidated Damages . The Parties acknowledge and agree that the payment of amounts by Owner to Purchaser under Section 7.3.1 and the modification of Purchaser’s payment obligations pursuant to Section 8.1 are an appropriate remedy and that any such payment or modification does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Non-Excused Outage are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Purchaser as a result thereof.
Section 7.3.4 Sole and Exclusive Remedy . The rights provided in Section 3.3.5 , this Section 7.3 and Section 8.1 shall collectively be the sole and exclusive remedies of Purchaser with respect to a Non-Excused Outage, subject to (a) Purchaser’s right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement, (b) Purchaser’s right to recover payment of any indemnification obligations of Owner to Purchaser pursuant to Section 20.1 , (c) Purchaser’s rights upon the occurrence of an Owner Default as described in Section 14.3 or (d) Purchaser’s rights in the event of Real Power Losses pursuant to Section 11.1 .
41
Section 7.4 Allocation of Outages . Except as set forth in this Section 7.4 with respect to the 110 MW TSA, the Parties expressly intend and agree that any outages or reductions in Total Transfer Capability shall be borne equitably by all transmission rights holders served by the NECEC Transmission Line (including Owner, if applicable), and Owner acknowledges and agrees that it will not reduce the Firm Transmission Service available to Purchaser in an unduly discriminatory manner as compared with any other transmission rights holder served by the NECEC Transmission Line (including Owner, if applicable). Purchaser’s transmission service under the 110 MW TSA shall be reduced before any reductions are applied to Distribution Company’s transmission service under the Distribution Company TSA or the Additional RFP Sponsor TSAs.
Section 7.5 Metering . Metering and telemetering requirements for the NECEC Transmission Line shall be established by Owner in accordance with Good Utility Practice and as necessary to (a) accomplish the purposes of, and to implement and administer, this Agreement and (b) satisfy the requirements of, and to implement and administer, the PPA, the Interconnection Agreement and the Transmission Operating Agreement.
Section 7.6 Line Availability Information and Reporting . Owner shall make available to Purchaser on a real time basis information relating to the operation and availability of the NECEC Transmission Line and shall provide such additional information as Purchaser shall reasonably request.
Article VIII
PAYMENTS FOR TRANSMISSION SERVICE OVER THE
NECEC TRANSMISSION LINE
Section 8.1 Transmission Service Payments . During the period beginning on the twentieth (20th) anniversary of the Commercial Operation Date and ending on the fortieth (40th) anniversary of the Commercial Operation Date (unless earlier terminated) (the “ Purchaser Term ”), except to the extent such payment is excused or reduced pursuant to the terms of this Agreement, Purchaser shall pay to Owner a transmission service payment (the “ Transmission Service Payment ”) on a monthly basis pursuant to invoices delivered by Owner to Purchaser equal to Seven Dollars Thirty Eight Cents ($7.38) per KW of Contract Capacity per month. The Transmission Service Payment shall be reduced in accordance with the formula set forth in Attachment G in the event and to the extent that the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 . To the extent there is a Dispute over whether or not or to what extent a Non-Excused Outage has occurred , Purchaser’s right, pursuant to this Section 8.1, to any reduction in the Transmission Service Payment shall be implemented upon the resolution of such Dispute and such reduction will be effective as of the date when such Dispute arose . Such adjustments shall be made on a monthly basis pursuant to invoices delivered by Owner to Purchaser.
42
Section 8.2 Adjustment to Rate Upon Purchaser Step-in . Notwithstanding anything in the Distribution Company TSA to the contrary, in the event Purchaser elects to assume the rights and obligations of Distribution Company under the Distribution Company TSA, as provided in Section 14.8(a) or 14.8(b) , the transmission service payment payable under the Distribution Company TSA by Purchaser for the remainder of the term thereunder shall be equal to that portion of the transmission service payment payable under the Distribution Company TSA comprising Owner’s non-capital expenses related to the NECEC Transmission Line, and Purchaser shall not be required to compensate Owner for any depreciation, equity return or cost of capital during the remainder of the term under the Distribution Company TSA. In the event of such assumption and upon request of Purchaser, the Parties shall amend the Distribution Company TSA to give effect to this Section 8.2 .
Section 8.3 Elective Upgrade Status; No Regional Rates . It is the intent of the Parties that the NECEC Transmission Line has Elective Transmission Upgrade status during the Term and that the AC Upgrades and the CCIS Capacity Upgrades constitute Network Upgrades under the ISO-NE Tariff required to accommodate the interconnection of the NECEC Transmission Line. The Parties acknowledge and agree that (a) as contemplated by the PPA, Purchaser shall participate in such Forward Capacity Auction (as defined in the ISO-NE Rules) qualification process as required to allow Purchaser to qualify a Seasonal Claimed Capability (as defined in the ISO-NE Rules) of not less than 1,200 MW over the NECEC Transmission Line no later than the Guaranteed Delivery Term Start Date (as defined in the PPA), as it may be extended pursuant to Sections 3.1(c) through 3.1(f) of the PPA and (b) such Network Upgrades, if any, shall be at Owner’s sole expense. It is the further intent of the Parties that Owner’s recovery of the investment in and return on the NECEC Facilities and Purchaser’s obligation to pay for the NECEC Facilities, shall be solely governed by this Agreement. The Parties each shall refrain from taking steps to include all or part of the NECEC Facilities in ISO-NE regional transmission rates during the Term. Notwithstanding the foregoing, if during the Term all or part of the NECEC Facilities are included in ISO-NE regional rates paid by Purchaser, the payment required by Section 8.1 shall be reduced by the Proportionate Share of the revenues received by Owner from such ISO-NE rates with respect to the NECEC Facilities. “NECEC Facilities” means the NECEC Transmission Line, the AC Upgrades, and the CCIS Capacity Upgrades.
Article IX
RIGHTS UPON EXPIRATION OF TERM
Section 9.1 Rollover Rights.
(a) Unless this Agreement is terminated early under Section 3.3 , Section 14.4 or Section 14.6 , Purchaser shall have rollover rights at the end of the Purchaser Term in accordance with FERC Order No. 890 et seq. and the FERC pro forma open access transmission service tariff, as such rights are defined as of the Effective Date.
(b) Owner shall not enter into any contract or other arrangement for use of the NECEC Transmission Line that is inconsistent with Purchaser’s rollover rights, as provided herein.
43
Article X
RESALE OF TRANSMISSION SERVICE
Section 10.1 Resale Rights of Purchaser . If and to the extent Purchaser (including, prior to the Purchaser Term, in its capacity as assignee of transmission rights under Section 20 of the PPA) determines from time to time, and in its sole discretion, that the transmission capacity available to Purchaser relevant to the receipt of Firm Transmission Service over the NECEC Transmission Line pursuant to this Agreement exceeds Purchaser’s needs, Purchaser shall then offer to resell such unused capacity to third parties in accordance with Applicable Law as may then be in effect (including the terms and conditions of FERC Order No. 890 et seq., if applicable).
Section 10.2 Capacity Releases for Daily and Hourly Use . From and after the Commercial Operation Date, if and to the extent the Proportionate Share of the Available Transfer Capability exceeds the amount of electrical energy that is scheduled by Purchaser for delivery over the NECEC Transmission Line using Firm Transmission Service by the applicable scheduling deadline (as in effect at such time) established pursuant to the Scheduling Rules, then the transmission capacity that is available for resale to third parties for the following day, and the price at which any such resales are offered, shall be posted on the OASIS site established pursuant to Section 10.3 .
Section 10.3 OASIS.
(a) Owner or an Affiliate of Owner (in such capacity, the “ OASIS Administrator ”) shall establish an OASIS site for the NECEC Transmission Line and administer such site in accordance with applicable FERC requirements for the establishment and administration of OASIS sites. None of Owner, the OASIS Administrator or Purchaser shall be liable to each other or any third party for any decisions the OASIS Administrator makes regarding the appropriate price for resales of unused transmission capacity or the level of any such resales the OASIS Administrator is able to make. The Parties agree that there shall be no damages as between each other or third parties for actions by the OASIS Administrator with respect to resales of unused transmission capacity.
(b) To the extent resales are made available by Purchaser pursuant to Section 10.1 , the OASIS Administrator shall post on the OASIS site information regarding such resales, (i) in accordance with written instructions provided by Purchaser from time to time and (ii) at a price established by Purchaser from time to time, and in its sole discretion, as permitted under Applicable Law.
Section 10.4 Proceeds from Capacity Releases and Transmission Resales . Except as otherwise provided in Section 14.4(b) , Purchaser’s proceeds received by Owner of any capacity releases and transmission resales that are made during the Purchaser Term pursuant to this Article X shall be credited, net of reasonable fees (including attorneys’ fees) and other expenses incurred in connection with performance of the functions described in Section 10.2 and Section 10.3 , against any Transmission Service Payment or other amounts owed to Owner by Purchaser for the calendar month subsequent to the calendar month in which such proceeds were received.
44
Section 10.5 Owner’s Rights and Obligations . Except as expressly provided in the Proposal Agreements, Owner shall have no right or obligation to offer any transmission service over the NECEC Transmission Line for sale or resale to any Person other than Purchaser, as provided herein.
Article XI
REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS
Section 11.1 Real Power Losses . Purchaser shall be responsible for all Real Power Losses associated with Firm Transmission Service; provided, however , that, if and to the extent any Real Power Losses associated with Firm Transmission Service between the U.S. Border and the Delivery Point are due to Owner’s failure to exercise Good Utility Practice or otherwise discharge its obligations under this Agreement, (a) such incremental Real Power Losses shall be treated as Non-Excused Outages for which Owner shall be liable in accordance with Section 7.3 and (b) the Transmission Service Payments owed by Purchaser shall be reduced pursuant to Section 8.1 ; and provided, further , that during the Term Owner shall (x) exercise diligent, commercially reasonable efforts to maximize the warranty or similar obligations of its vendors and suppliers for the NECEC Transmission Line with respect to such Real Power Losses under any Construction Contract or otherwise and (y) credit, assign or pay over to Purchaser any amounts receivable by or paid to Owner under such warranties or similar obligations, including liquidated damages under any Construction Contract, related to such Real Power Losses, and the rights and remedies contemplated by Section 3.3.5 , Section 7.3 , Section 8.1 and this Section 11.1 , shall collectively be the sole and exclusive remedy of Purchaser with respect to any such incremental Real Power Losses.
Section 11.2 Other Rights.
(a) Purchaser shall be entitled during the Purchaser Term to its Transmission Percentage of the following, without duplication and without additional cost to Purchaser or compensation to Owner: (i) all Other Transmission Rights associated with the NECEC Transmission Line or the AC Upgrades, in each case, that are issued in accordance with the ISO-NE Tariff or otherwise granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE and (ii) all other Market Products that are issued in accordance with the ISO-NE Tariff or granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, that derive from the acquisition of transmission service over the NECEC Transmission Line. As Owner’s sole obligation under this clause (a), upon its receipt of any of the entitlements or rights described in the foregoing sentence, Owner shall promptly convey such entitlements or rights to Purchaser.
(b) In the event tie benefits or interconnection capability credits (or any similar concept) are ever deemed applicable to the NECEC Transmission Line and to the extent allocated to any Party during the Purchaser Term, Purchaser shall be entitled to its Transmission Percentage of one hundred percent (100%) of the economic benefits associated therewith (however entitled and whether existing now or in the future), without additional cost to Purchaser or compensation to Owner.
45
(c) Owner shall have no obligation to support the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above, but Owner may not oppose the creation or establishment of any such right, unless otherwise agreed in writing by Purchaser. Neither Section 2.5 nor the foregoing sentence shall be construed in any way to limit the right of any Affiliate of Owner to oppose the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above.
Article XII
[INTENTIONALLY OMITTED]
Article XIII
BILLING AND PAYMENTS
Section 13.1 Invoices . Within seven (7) Business Days after the first day of each calendar month following the commencement of the Purchaser Term, Owner shall submit an Invoice to Purchaser for the Transmission Service Payments owed for the preceding calendar month, and Purchaser shall pay the amounts set forth in the Invoice to Owner within fourteen (14) Business Days following its receipt of such Invoice. All payments shall be made in immediately available funds payable to Owner by wire transfer to a bank named by Owner, in accordance with wiring instructions provided to Purchaser by Owner in writing. Owner shall be entitled to change the place or recipient for payment by thirty (30) days’ prior written notice to Purchaser.
Section 13.2 Procedures for Billing Disputes.
(a) In the event of any Dispute with respect to the amount owed to Owner by Purchaser under this Agreement, Purchaser shall have no right to withhold payment of the Disputed amount pending resolution of the Dispute; provided , however , that, in the event such Dispute is resolved in favor of Purchaser, Owner shall complete the following tasks consistent with the resolution of such Dispute: (i) retroactively adjust all payments previously made by Purchaser; (ii) promptly refund all overpayments previously made by Purchaser, together with interest thereon in immediately available funds or by wire transfer, in each case, in accordance with wiring instructions provided to Owner by Purchaser in writing; and (iii) thereafter conform all future Invoices to reflect the resolution of such Dispute, as applicable. Purchaser’s payment of any Disputed amounts shall be without prejudice to any right or remedy that Purchaser may have under this Agreement to contest any such amount.
(b) Purchaser shall not have the right to challenge any Invoice or to bring any action of any kind challenging the propriety of any Invoice after the second (2nd) anniversary of the receipt of such Invoice. If an Invoice is not rendered within two (2) years after the end of the calendar month during which such Invoice should have been rendered hereunder, then the right to payment of such Invoice is waived.
46
Section 13.3 Interest. All interest payable under this Section 13.3 shall be calculated pursuant to 18 C.F.R. § 35.19a(a), as such regulation (or any successor thereto) is in effect during the period during which such interest is due. Amounts not paid when due to Owner or Purchaser under this Agreement shall bear interest from the date such amount was due until the date of payment of such overdue amount. For the avoidance of doubt, as illustrated in Attachment H , if all or a portion of the amount to which such interest relates is later refunded pursuant to this Agreement, then, in calculating that refund, such interest shall not be included in the refund. Refunds of overpayments owed to Purchaser by Owner under this Agreement shall begin to accrue interest on the amount subject to refund, as originally invoiced, from the earlier to occur of the due date or the date of payment of the monthly Invoices to which the overpayment relates and shall continue to accrue interest until the date of payment of such refund.
Section 13.4 Obligation to Make Payments . The Parties acknowledge and agree that, except as set forth in Section 8.1 , Section 13.5 and Section 14.6(d) , no cause or event whatsoever shall excuse or suspend Purchaser’s obligation to pay Transmission Service Payments or any other amounts payable by Purchaser under this Agreement. The Parties also acknowledge and agree that no cause or event whatsoever shall excuse or suspend any amounts payable by Owner under this Agreement.
Section 13.5 Offsets . Except as otherwise provided in Section 3.4(a) and Section 14.6(d) , neither Party shall be entitled to deduct or set-off payment of any amount owed to the other Party under this Agreement against payment of any amount owing under this Agreement. The Parties shall have the right to deduct or set-off payments of amounts owed hereunder against payments of amounts owing under the 110 MW TSA or the Purchaser TSAs.
Article XIV
EVENTS OF DEFAULT AND REMEDIES
Section 14.1 Purchaser Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Purchaser under this Agreement (a “ Purchaser Default ”); provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (e), clause (f) or clause (g):
(a) Purchaser’s failure to pay any undisputed amount due to Owner under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Purchaser of a written demand from Owner that such amount is due and owing and has not been timely paid.
(b) Purchaser’s failure to comply in any material respect with the provisions of Article XVI .
47
(c) The failure of the Québec Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date (where the NECEC Transmission Line is capable of operating at or above 1,040 MW as of the Commercial Operation Date), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Purchaser Remediation Date or the end of the Remediation Period (where the NECEC Transmission Line is capable of operating at or above 1,075 MW as of the earlier of the Purchaser Remediation Date or the end of the Remediation Period), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability.
(d) Purchaser’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), and (c) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Purchaser of written notice thereof from Owner, unless such cure shall reasonably require a longer period, in which case Purchaser shall be provided an additional thirty (30) days to complete such cure so long as Purchaser has promptly commenced such cure and thereafter diligently pursues such cure.
(e) Any representation or warranty made by Purchaser in this Agreement is false or misleading at the time made in any material respect.
(f) Any Insolvency Event occurs with respect to Purchaser.
(g) An Event of Default (as defined in the PPA) by Purchaser under the PPA that does not result from a TSA Delivery Shortfall (as defined in the PPA) or a Transmission Delay (as defined in the PPA), or a Purchaser Default (as defined in the 110 MW TSA), occurs and is continuing.
Section 14.2 [Intentionally Omitted].
Section 14.3 Owner Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Owner under this Agreement (an “ Owner Default ”); provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (h) or clause (i):
(a) Owner’s failure to pay any undisputed amount due to Purchaser under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Owner of a written demand from Purchaser that such amount is due and owing and has not been timely paid.
(b) Owner’s failure to satisfy (other than as a result of a Purchaser Delay) any of the Critical Milestones in clauses (i), (iii), (iv), (v), or (vii) of Section 4.1(a) by the dates set forth therefor, as the same may be extended in accordance with Section 4.1(c) , Section 4.1(d) , or Section 4.1(e) .
48
(c) The failure of the NECEC Transmission Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date (where the Québec Line is capable of operating at or above 1,040 MW as of the Commercial Operation Date), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Owner Remediation Date or the end of the Remediation Period (where the Québec Line is capable of operating at or above 1,075 MW as of the earlier of the Owner Remediation Date or the end of the Remediation Period), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability.
(d) Owner’s failure to comply in any material respect with the provisions of Section 5.1.1(a)(ii) and, if such failure is susceptible to cure, such failure continues for thirty (30) days after receipt by Owner of written notice thereof from Purchaser, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(e) A Non-Excused Outage pursuant to which (A) the Hourly Availability of the NECEC Transmission Line is less than one hundred percent (100%) for more than ninety (90) consecutive days and the average Hourly Availability of the NECEC Transmission Line over each calendar month in which the ninety (90) consecutive days occur is less than the Minimum Average Availability for each such month (whether as a result of a physical condition, legal impediment or otherwise), or (B) the Hourly Availability of the NECEC Transmission Line is less than one hundred percent (100%) for more than hundred twenty (120) days in any twelve (12) month period and the average Hourly Availability of the NECEC Transmission Line over each calendar month in which any such day occurs is less than the Minimum Average Availability for each such month (whether as a result of a physical condition, legal impediment or otherwise) in each case, unless otherwise excused under Section 7.2 , provided , however , that if (i) Owner presents to Purchaser and Distribution Company (before the Purchaser Term) or Purchaser (during the Purchaser Term) before the end of a Non-Excused Outage that would otherwise constitute an Owner Default under this clause (e) , a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company and Purchaser (before the Purchaser Term) or Purchaser (during the Purchaser Term), each acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, and (ii) prior to the start of the Purchaser Term, Owner posts Credit Support with Distribution Company as set forth in Section 14.2(e) of the Distribution Company TSA, Purchaser shall forbear terminating this Agreement under this clause (e) for such period, provided that, during any such period, Purchaser’s obligation to make Transmission Service Payments shall continue to be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, an Owner Default shall be deemed to have occurred and Purchaser shall have the rights and remedies set forth in Section 14.6 and Section 14.7 .
49
(f) Owner’s failure to comply in any material respect with the provisions of Article XVI .
(g) Owner’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), (c), (d), or (e) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Owner of written notice thereof from Purchaser, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(h) Any representation or warranty made by Owner in this Agreement is false or misleading at the time made in any material respect.
(i) Any Insolvency Event occurs with respect to Owner.
(j) An Owner Default (as defined in the Distribution Company TSA) that is not attributable to the operating capability of the Québec Line, or an Owner Default (as defined in the 110 MW TSA), occurs and is continuing.
Section 14.4 Remedies Upon Purchaser Default . Upon the occurrence of a Purchaser Default and at any time thereafter so long as the same is continuing, Owner shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Owner shall elect:
(a) In the case of a Purchaser Default, and subject to Section 5.8 , Owner may terminate this Agreement by written notice to Purchaser.
(b) In the case of a Purchaser Default pursuant to Section 14.1(a) , and subject to Section 5.8 , Owner may suspend all or part of Owner’s obligations or Purchaser’s rights under this Agreement during the period during which such Purchaser Default is continuing. During any such period of suspension occurring after the Commercial Operation Date, (i) Purchaser shall not be entitled to schedule, and shall not schedule, any transactions over the NECEC Transmission Line and (ii) the OASIS Administrator shall be directed to post any portion of the transmission capacity that would have otherwise been available to Purchaser over the NECEC Transmission Line pursuant to this Agreement and to attempt to sell such capacity to one or more third parties consistent with Article X . The proceeds of any capacity releases and transmission resales made pursuant to the foregoing sentence and received by Owner, net of reasonable fees (including attorneys’ fees) and other expenses incurred by Owner in connection with this Section 14.4(b) , shall be credited against any accrued but unpaid payment obligation of Purchaser to Owner hereunder. Any such proceeds in excess of such accrued but unpaid payment obligation of Purchaser shall be credited in accordance with Section 10.4 .
50
(c) Subject to Article XVIII and this Section 14.4 , as applicable, Owner may recover from Purchaser the Purchaser Termination Payment and, to the extent applicable, all other amounts not waived in accordance with Section 3.3.4(d) or, in the absence of a termination pursuant to a Purchaser Default, all damages suffered by Owner that are due to a Purchaser Default, including, for the avoidance of doubt, any amounts payable under Section 4.4.2 and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Purchaser under this Agreement.
(d) Owner may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Additional Credit Support held by Owner and (ii) the right to liquidate any and all Additional Credit Support held by Owner and to apply the proceeds of such liquidation to any amounts payable to Owner with respect to Purchaser’s obligations hereunder in such order as Owner may elect. Owner may draw on the undrawn portion of any Letter of Credit provided as Additional Credit Support up to the amount of Purchaser’s outstanding obligations hereunder. Purchaser shall remain liable for amounts due and owed to Owner that remain unpaid after the application of Additional Credit Support.
(e) Owner may exercise and enforce any and all of its rights and remedies under the Hydro-Québec Guaranty.
(f) Owner may exercise any and all other rights and remedies that may be available to Owner against Purchaser at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Owner shall have no right to (i) terminate this Agreement based upon a Purchaser Default, except as provided in clause (a) above, or (ii) suspend transmission service under this Agreement based upon a Purchaser Default, except as provided in clause (b) above.
Section 14.5 [Intentionally Omitted].
Section 14.6 Remedies Upon Owner Default . Upon the occurrence of an Owner Default and at any time thereafter so long as the same is continuing, Purchaser shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Purchaser shall elect:
(a) In the case of an Owner Default, and subject to Section 5.8 and Section 14.7 , Purchaser may terminate this Agreement by written notice to Owner and may recover, as applicable, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 and the Owner Termination Payment.
(b) Subject to the limitations provided in Section 4.4.1(e) , Section 7.3.4 , Article XVIII or this Section 14.6 , as applicable, Purchaser may recover from Owner any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement.
51
(c) Purchaser may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Additional Credit Support held by Purchaser and (ii) the right to liquidate any and all Additional Credit Support held by Purchaser and to apply the proceeds of such liquidation to any amounts payable to Purchaser with respect to Owner’s obligations hereunder in such order as Purchaser may elect. Purchaser may draw on the undrawn portion of any Letter of Credit or apply Cash, in each case that has been provided as Additional Credit Support up to the amount of Owner’s outstanding obligations hereunder. Owner shall remain liable for amounts due and owed to Purchaser that remain unpaid after the application of Additional Credit Support.
(d) Pursuant to Section 13.2 , to the extent there is a Dispute over the amount of the damages suffered by Purchaser as a result of an Owner Default, Purchaser may deduct and setoff payment of such amount against any Transmission Service Payment upon resolution of that Dispute.
(e) Purchaser may exercise any and all other rights and remedies that may be available to Purchaser at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Purchaser shall have no right to (i) terminate this Agreement based upon an Owner Default, except as provided in clause (a) above or Section 14.7(e)(i) , or (ii) any reduction of or offset against payments under this Agreement based upon an Owner Default, except as contemplated by Section 8.1 , Section 13.5 and Section 14.6(d) , as applicable.
Section 14.7 Purchaser Step-in Rights.
(a) In the event that (i) an Owner Default or an Owner Default (as defined in the Distribution Company TSA) occurs or (ii)(A) Owner exercises its rights pursuant to Section 14.2(e) of the Distribution Company TSA or Section 14.3(e) of this Agreement and (B) at the end of the first six (6) months of the period of forbearance by Purchaser of its rights as contemplated by Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA, Owner is not providing Firm Transmission Service in full, then Purchaser shall have the right, but not the obligation, to (x) assume control of and possess and operate the NECEC Transmission Line as agent for Owner (in accordance with Owner’s rights, obligations and interest under this Agreement, the Distribution Company TSA and the Additional RFP Sponsor TSAs, as applicable) during the period provided for herein, pursuant to an agreement to be negotiated in good faith between Owner and Purchaser or (y) assume ownership, control of, possession and operation of the NECEC Transmission Line, in each case, which right shall be exercisable by written notice to Owner and subject to the receipt of any required regulatory approvals and Third Party Consents.
52
(b) Upon receipt of such written notice to assume ownership of the NECEC Transmission Line (the “ Acquisition Notice ”), Owner shall (i) provide such documents and information as is reasonably necessary for Purchaser to determine any amount owed pursuant to Section 14.7(c) and (ii) take all necessary action to effect the transfer of the NECEC Transmission Line to Purchaser (or its designated Affiliate), including causing all permits, title to land and property, and interests in all contracts (including Owner’s rights under this Agreement, the 110 MW TSA, the Purchaser TSAs, the Distribution Company TSA and the Additional RFP Sponsor TSAs, as applicable) applicable to the NECEC Transmission Line to be transferred to Purchaser or such designated Affiliate. Each Party shall, and each Party shall use commercially reasonable efforts to cause its Affiliates to, cooperate to obtain any required regulatory approvals and Third Party Consents necessary to effect the transfer of the NECEC Transmission Line to Purchaser.
(c) In consideration for acquiring the NECEC Transmission Line, on the closing date, as reasonably determined by Purchaser and specified in the Acquisition Notice, Purchaser shall pay to Owner an amount equal to (i) if such Owner Default occurs prior to the Commercial Operation Date, all costs prudently incurred by Owner as of the date of the Acquisition Notice in connection with the development and construction of the NECEC Transmission Line or (ii) if such Owner Default occurs on or after the Commercial Operation Date, the lesser of (A) one hundred percent (100%) of Owner’s investment in the NECEC Transmission Line as of the notice date and (B) the fair market value of the NECEC Transmission Line, as reasonably determined by a third party appraiser selected by Purchaser and reasonably acceptable to Owner (which amount shall be net of the costs of any such appraisal). The amount to be paid pursuant to this clause (c) shall be in satisfaction of any consideration required to be paid pursuant to Section 14.7 of all Purchaser TSAs and shall be determined within fifteen (15) days after the delivery of the Acquisition Notice or such other time period as is reasonably practicable.
(d) Upon receipt of all required regulatory approvals and Third Party Consents and the payment set forth in clause (c) above, Owner shall transfer to Purchaser (or its designated Affiliate), without recourse or warranty (except as to title and the absence of any liens other than liens arising in the ordinary course), all of Owner’s right, title and interest in and to the NECEC Transmission Line free and clear of all liens other than liens arising in the ordinary course and Purchaser (or such designated Affiliate) shall be assigned all rights of Owner under all contracts required for the ownership and operation of the NECEC Transmission Line and shall assume all liabilities and obligations of Owner arising under such contracts after the transfer (other than applicable contracts between Owner and its lenders, the liabilities and obligations of Owner thereunder to be completely satisfied and discharged by Owner as of closing) and Owner shall cease to be a Party.
53
(e) Upon Purchaser (or its designated Affiliate) assuming ownership and control of the NECEC Transmission Line:
(i) (A) Purchaser (or its designated Affiliate) shall have the right to terminate this Agreement and Purchaser may recover, as applicable, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 or (B) Purchaser (or its designated Affiliate) shall assume Owner’s obligations under this Agreement pursuant to this Section 14.7 and Purchaser shall enter into such amendments to this Agreement as are reasonably necessary in order to give effect to such rights and that are consistent with the terms and conditions of this Agreement and are subject to applicable regulatory approvals;
(ii) Purchaser (or its designated Affiliate) shall assume the rights and obligations of Owner under the Distribution Company TSA, the Additional RFP Sponsor TSAs, the 110 MW TSA and the Purchaser TSAs for the remainder of the term thereof (excluding any rights and obligations accrued prior to such assumption).
(f) In connection with an event occurring that gives rise to Purchaser’s step-in rights pursuant to Section 14.7(a) (a “ Step-In Trigger Event ”) and the exercise by Purchaser of its rights under this Section 14.7 , Owner shall pay liquidated damages to Purchaser (without duplication of any amounts paid under Section 14.7 of any other Purchaser TSA) in an amount equal to:
(i) if such Step-In Trigger Event occurs on or before December 31, 2019, Twelve Million Dollars ($12,000,000);
(ii) if such Step-In Trigger Event occurs after December 31, 2019, but on or before December 31, 2020, Thirty Million Dollars ($30,000,000);
(iii) if such Step-In Trigger Event occurs after December 31, 2020, but on or before December 31,2021, Seventy-Three Million Dollars ($73,000,000);
(iv) if such Step-In Trigger Event occurs after December 31, 2021 but before the Commercial Operation Date, Ninety Million Dollars ($90,000,000); or
(v) if such Step-In Trigger Event occurs on or after the Commercial Operation Date, One Hundred Million Dollars ($100,000,000).
54
The assumption by Purchaser (or its designated Affiliate) of ownership and control of the NECEC Transmission Line under this Section 14.7 shall constitute a waiver by Purchaser of all other remedies or damages that may be available at law or in equity against Owner; provided , however , that Purchaser shall not waive any right to, and Owner shall remain liable for, the liquidated damages set forth in this Section 14.7(f) , any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.2 , or Section 7.3.1 hereof or any express modification of Purchaser’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Purchaser under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover such damages or such indemnified or other amounts owed to Purchaser by Owner.
(g) Notwithstanding this Section 14.7 , in the event that an Owner Default occurs and at any time prior to Purchaser (or its designated Affiliate) assuming ownership and control of the NECEC Transmission Line, (i) Purchaser may exercise its termination rights pursuant to Section 14.6(a) and the exercise of such termination rights shall result in a revocation of Purchaser’s step-in rights under Section 14.7(a) or (ii) Purchaser may revoke the exercise of its step-in rights under Section 14.7(a) .
(h) Owner shall not grant any Person, other than a secured party in accordance with Section 22.3 , a right to assume control of, possess and operate the NECEC Transmission Line that is equal to or superior to Purchaser’s right under this Section 14.7 .
(i) As requested by Purchaser following its purchase of the NECEC Transmission Line pursuant to this Section 14.7 , Owner agrees to grant to Purchaser (or its designated Affiliate) any such other rights of way, and assign to Purchaser or such designated Affiliate such other contracts to which it is then a party, as shall be necessary for the ownership, operation, and maintenance of the NECEC Transmission Line.
(j) Owner shall deliver true, correct and complete copies of all applicable contracts and books and records to Purchaser for its review no later than ten (10) days after receipt of the Acquisition Notice. Following the timely delivery by Owner to Purchaser of all such contracts and books and records, Purchaser shall be required to notify Owner at least twenty (20) days prior to the expected closing date if the terms and conditions of the assignment and assumption of any such contracts will not be satisfactory to Purchaser (or its designated Affiliate) and, if Purchaser does so notify Owner, such notice shall result in the revocation of the Acquisition Notice, and the Parties shall be deemed to be in the same position as if Purchaser had not delivered such Acquisition Notice. As a condition of closing, Owner shall completely satisfy and discharge its liabilities and obligations under all applicable contracts between Owner and its lenders and Owner shall obtain written releases, in recordable form reasonably acceptable to Purchaser, of all liens (whether for the benefit of its lenders or otherwise) on the NECEC Transmission Line and the applicable contracts other than liens arising in the ordinary course, and Owner obligates itself to satisfy such liabilities and obligations and to obtain such releases as of closing.
55
Section 14.8 Early Termination of Distribution Company TSA.
(a) Upon any termination of the Distribution Company TSA as a result of a Distribution Company default thereunder, Purchaser shall have the right, exercisable in its sole discretion, to assume the rights and obligations (subject to the adjustment set forth in Section 8.2 ) of Distribution Company under the Distribution Company TSA for the remainder of the term thereunder by written notice to Owner; provided that Purchaser shall have no obligations for amounts owed by Distribution Company to Owner prior to Purchaser’s assumption in accordance with this Section 14.8(a) , including any amounts owed as a result of a Distribution Company default thereunder, and provided that Hydro-Québec shall execute and deliver an amendment to the Hydro-Québec Guaranty, in form and substance reasonably satisfactory to Owner, to guarantee such assumed obligations.
(b) During any suspension of all or part of Owner’s obligations or Distribution Company’s rights under the Distribution Company TSA, Purchaser shall have the right, exercisable in its sole discretion, to assume the rights and obligations (subject to the adjustment set forth in Section 8.2 ) of Distribution Company under the Distribution Company TSA by written notice to Owner, and, in the event Purchaser elects to assume such Distribution Company’s obligations, Owner shall thereafter resume performance of its obligations thereunder. For the avoidance of doubt, the exercise by Purchaser of any rights hereunder shall be without prejudice to the rights of Purchaser under the PPA.
Section 14.9 Disputes . Any Dispute over whether or not an Owner Default or Purchaser Default has occurred shall be resolved in accordance with Article XVII .
Section 14.10 Limitations on Total Liability.
Section 14.10.1 Purchaser Liability . Notwithstanding anything herein to the contrary, Purchaser’s liability for any payments made to Owner pursuant (x) to Sections 3.3.3 , 3.3.4 , 3.4 , 4.4.2 , 4.4.3 and 14.4 , (y) Sections 3.3.3 , 3.3.4 , 3.4 , 4.4.2 , 4.4.3 and 14.4 of the Purchaser TSAs and (z) Sections 3.3.4 , 3.4 , 4.4.2 and 14.4 of the 110 MW TSA shall not exceed, in aggregate, an amount equal to Two Hundred Million Dollars ($200,000,000), which $200,000,000 shall be adjusted in accordance with the following:
(a) increased by the total amount of Credit Support provided by Owner pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs;
(b) reduced by the amount drawn on any Credit Support provided by Owner pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs as a result of an Owner Default hereunder and thereunder;
(c) reduced by any amount of Credit Support that has been returned to Owner pursuant to Section 4.1(c) of the Distribution Company TSA and Section 4.1(c) of the Additional TSAs with the RFP Sponsors; and
(d) reduced by any Delay Damages (as defined in the PPA) paid by Purchaser to Distribution Company under the PPA.
56
Section 14.10.2 Owner Liability . Notwithstanding anything herein to the contrary, Owner’s liability for any payments made to Purchaser pursuant to (x) Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.3(b)(iii) , 7.3 , 14.11 and 14.6 , (y) Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.3(b)(iii) , 7.3 , 14.11 and 14.6 of the Purchaser TSAs and (z) Sections 3.3.5 , 3.4 , 4.4.1 , 7.3 , 14.11 and 14.6 of the 110 MW TSA shall not exceed, in aggregate, an amount equal to Sixty Million Dollars ($60,000,000), which $60,000,000 shall be adjusted in accordance with the following:
(a) increased by the total amount of Credit Support provided by Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs;
(b) reduced by the amount drawn on any Credit Support provided by Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs as a result of a Purchaser Default hereunder and thereunder;
(c) reduced by any amount of Credit Support that has been returned to Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs; and
(d) reduced by any amounts paid by Owner pursuant to Section 14.7(f) of this Agreement and Section 14.7(f) of the Purchaser TSAs.
Section 14.10.3 Exceptions to Total Liability . The limits on liability set forth in Sections 4.4 , 14.10.1 and 14.10.2 shall not apply to any liability of a Party arising out of such Party’s gross negligence, willful misconduct (including willful breach of this Agreement) or fraud.
Section 14.11 Modified Terms Applicable During Forbearance Period . In the event that Owner exercises its rights pursuant to Section 14.2(e) of the Distribution Company TSA or Section 14.3(e) of this Agreement, during the continuation of the period of forbearance by Purchaser of its rights as contemplated by Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA, an additional $3 shall be available in clause (b) of the definition of Non-Excused Outage Payment for the calculation of such payment by Owner, and an additional Ten Million Dollars ($10,000,000) per Contract Year shall be available with respect to the limitation of liability contained in Section 7.3.1 . If Owner is successful in providing Firm Transmission Service under this Agreement or Firm Transmission Service (as defined in the Distribution Company TSA), as applicable, in full at or prior to the end of such period of forbearance, all such amounts shall revert at the time Firm Transmission Service or Firm Transmission Service (as defined in the Distribution Company TSA), as applicable, is provided in full to the amounts applicable under this Agreement prior to Owner’s exercise of its rights under Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA.
57
Section 15.1 Definition; Conditions.
(a) The term “ Force Majeure ” means an event or circumstance (i) that is not within the reasonable control of the Party claiming its occurrence; (ii) that could not have been prevented or avoided by such Party through the exercise of reasonable diligence and (iii) that prohibits or prevents such Party from performing its obligations under this Agreement. Under no circumstances shall Force Majeure include (w) any full or partial curtailment in the operation of the NECEC Transmission Line that is caused by or arises from a mechanical or equipment breakdown or other mishap or events or conditions attributable to normal wear and tear or flaws of the NECEC Transmission Line, unless such curtailment or mishap is caused by one of the following: acts of God such as floods, hurricanes, tornados, or other significantly unusual and abnormal weather conditions, such as severe blizzards and severe ice storms; sabotage; terrorism or war; national or regional general strikes, lockouts or other labor disputes, (x) any occurrence or event that increases the costs or causes an economic hardship to a Party but is not otherwise a Force Majeure, (y) Owner’s ability to sell transmission service involving the NECEC Transmission Line at a price greater than that set out in this Agreement or (z) Purchaser’s ability to procure transmission service at a price lower than that provided in this Agreement or Purchaser’s ability to sell generation at a price higher than that provided in the PPA. In addition, a delay or inability to perform attributable to a Party’s lack of preparation, a Party’s failure to timely obtain and maintain all necessary permits (excepting the Regulatory Approval other than the obligations to file for Regulatory Approval) or qualifications, any delay or failure of Owner to obtain the Owner Approvals or of Purchaser to obtain the Canadian Approvals, a failure to satisfy contractual conditions or commitments, or lack or deficiency in funding or other resources shall each not constitute a Force Majeure or be the basis for a claim of Force Majeure. Neither Party may raise a claim of Force Majeure based in whole or in part on the failure of Purchaser to fulfill any of its obligations under the PPA (including related to the availability of the Québec Line) unless such failure is due to “force majeure” or “uncontrollable force” or a similar term as defined under the PPA.
(b) Subject to Section 15.1(a) , if a Party is unable, wholly or in part, by Force Majeure to perform its obligations under this Agreement, such performance shall be excused and suspended so long as the circumstances that give rise to such inability exist or would exist if the Party claiming the Force Majeure used commercially reasonable efforts to cure such circumstances, but for no longer period. The Party whose performance is affected shall give prompt notice thereof to the other Party; such notice may be given orally or in writing but, if given orally, it shall be promptly confirmed in writing, providing details regarding the nature, extent and expected duration of the Force Majeure, its anticipated effect on the ability of such Party to perform its obligations under this Agreement, and the estimated duration of any interruption in service or other adverse effects resulting from such Force Majeure, and shall be updated or supplemented to keep the other Party advised of the effect and remedial measures being undertaken to overcome
58
the Force Majeure. Such inability to perform shall be promptly corrected to the extent it may be corrected through the exercise of due diligence consistent with Good Utility Practice. Neither Party shall be liable for any losses or damages arising out of a suspension of performance that occurs because of Force Majeure. Notwithstanding any such suspension of performance, Purchaser shall be obligated to make Transmission Service Payments as though Firm Transmission Service was then being provided at or greater than the Minimum Average Availability.
(c) Notwithstanding the foregoing, if the Force Majeure prevents full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, the Party whose performance is not prevented by Force Majeure shall have the right to terminate this Agreement upon written notice to the other Party and without further recourse, provided , however , that if (i) Owner presents a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan reasonably acceptable to Purchaser and Distribution Company (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, to Purchaser and Distribution Company before the end of a period in which Owner’s provision of Firm Transmission Service has been prevented in whole or in part by an event of Force Majeure, Purchaser shall forbear terminating this Agreement under this clause (c) for such period, provided that, during any such period, Purchaser’s obligation to make Transmission Service Payments shall be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, Purchaser may terminate this Agreement under this clause (c) . In no event will any delay or failure of performance caused by any conditions or events of Force Majeure extend this Agreement beyond its stated Term.
(d) A Party shall not be required to settle any strike, walkout, lockout or other labor dispute on terms that, in the sole judgment of such Party, are contrary to its interest. The settlement of strikes, walkouts, lockouts or other labor disputes shall be entirely within the discretion of the Party involved in such dispute.
Article XVI
FINANCIAL ASSURANCES
Section 16.1 Purchaser’s Guaranty . Concurrently with the execution of this Agreement, Purchaser shall cause Purchaser Guarantor to deliver to Owner a guaranty by Purchaser Guarantor of Purchaser’s payment obligations under this Agreement substantially in the form of Attachment J (the “ Hydro-Québec Guaranty ”).
Section 16.2 [Intentionally Omitted].
59
Section 16.3 Credit Downgrade Event . Purchaser Guarantor and Owner shall at all times meet the Credit Rating Requirements.
(a) In the event Owner fails to meet the Credit Rating Requirements, Owner shall promptly furnish to Purchaser, in an amount equal to the Proportionate Share multiplied by Two Hundred Fifty Million Dollars ($250,000,000), Additional Credit Support.
(b) In the event Purchaser Guarantor fails to meet the Credit Rating Requirements, Purchaser shall promptly furnish to Owner, in an amount equal to the Proportionate Share multiplied by Two Hundred Fifty Million Dollars ($250,000,000), Additional Credit Support.
For the purposes of this Section 16.3 , the denominator in “Proportionate Share” shall be 1,200 MW.
Article XVII
DISPUTE RESOLUTION
Section 17.1 Consultation.
(a) The Parties shall initially attempt to resolve any Dispute through consultations between the Parties. Subject to Section 17.2 and except as expressly provided otherwise in this Agreement, if a Dispute has not been timely resolved pursuant to this clause (a) within fifteen (15) Business Days after written notice of such Dispute has been given, then either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction; provided, however, if the Dispute is subject to Section 17.2 , then either Party may elect to proceed with the mediation through FERC's Dispute Resolution Service. If one Party fails to participate in the consultations provided for in this Section 17.1 , the other Party can initiate mediation prior to the expiration of the fifteen (15) Business Days. Unless otherwise agreed, the Parties will select a mediator from the FERC panel. The Parties may, by written agreement signed by both Parties, alter any time deadline, location(s) for meeting(s) or procedure outlined herein or in FERC’s rules for mediation. The procedure specified herein shall be the sole and exclusive procedure for the resolution of Disputes.
(b) All negotiations, consultations, and mediations pursuant to this Section 17.1 shall be deemed to be confidential and shall be treated as compromise and settlement negotiations, and no evidence with regard to any proposal made during such negotiations, consultations or mediations shall be admissible in any FERC proceeding or filing under Section 17.2 or in any other judicial or other proceeding.
60
Section 17.2 Disputes to be Resolved by FERC.
(a) In the event a Dispute over any matter is not resolved in accordance with Section 17.1 , either Party shall have the right to file for relief with FERC to the extent that matter is within the primary or exclusive jurisdiction of the FERC. Nothing contained in this Agreement shall be construed as precluding a Party from filing any answer, protest or other opposition to any FERC filing made by the other Party, unless expressly prohibited under the terms of this Agreement.
(b) In the event any Dispute is submitted to FERC for resolution as provided in Section 17.2(a) , the Party submitting the Dispute to FERC shall be responsible for providing written notice of such filing to the other Interested Parties. Unless both Parties agree that the Dispute does not implicate any of the Proposal Agreements other than this Agreement, each Party consents and agrees that (i) each Interested Party is an interested party in the Dispute and (ii) in order to avoid inconsistent interpretations and adjudications of the Proposal Agreements, any Interested Party may, without objection from any other Interested Party, whether by means of joinder, consolidation or otherwise, submit such matters as it considers sufficiently related to the Dispute to FERC to be jointly determined by FERC with the Dispute. Notwithstanding the foregoing, in the event FERC determines that it does not have the jurisdiction to, or otherwise does not want to, hear or determine any portion of a Dispute or other matter so referred to FERC, either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction.
Section 17.3 Consent to Jurisdiction . Subject to Section 17.2 , each Party agrees that any legal action or proceeding with respect to or arising out of this Agreement or any other Proposal Agreement shall be brought in or removed to the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts that has subject matter jurisdiction and any appellate court from any thereof. By execution and delivery of this Agreement, each Party hereby accepts for itself and in respect of its property, generally and unconditionally, the jurisdiction of the aforesaid courts. The Parties irrevocably consent to the service of process out of any of the aforementioned courts in any such action or proceeding by the mailing of copies thereof by registered or certified airmail, postage prepaid, to the applicable Party at its respective addresses for notices as specified in Section 23.4. Nothing herein shall affect the right to serve process in any other manner permitted by law. Each Party hereby waives any right to stay or dismiss any action or proceeding under or in connection with this Agreement or any other Proposal Agreement brought before the foregoing courts on the basis of forum non-conveniens.
Section 17.4 WAIVER OF JURY TRIAL . EACH PARTY IRREVOCABLY AND UNCONDITIONALLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY LEGAL ACTION, PROCEEDING, CAUSE OF ACTION , OR COUNTERCLAIM ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.
61
Article XVIII
LIMITATION OF REMEDIES
NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, NEITHER PARTY NOR ANY OF ITS AGENTS, SUBCONTRACTORS, REPRESENTATIVES OR AFFILIATES SHALL BE LIABLE TO THE OTHER PARTY FOR PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE (EXCEPT AS EXPRESSLY CONTEMPLATED IN THIS AGREEMENT, INCLUDING IN Section 4.4 OR Section 7.3 , OR FOR ANY DIRECT DAMAGES SUFFERED BY PURCHASER AS A RESULT OF A BREACH BY OWNER OF ITS OBLIGATIONS UNDER Section 6.2 , Article X OR Section 11.2 ), IN EACH CASE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OF THIS AGREEMENT, AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY).
FOR THE AVOIDANCE OF DOUBT, THE PARTIES ACKNOWLEDGE AND AGREE THAT Section 4.4 OR Section 7.3 PROVIDE THE SOLE AND EXCLUSIVE REMEDIES FOR ANY LOSS OF USE CONTEMPLATED BY Section 4.4 OR Section 7.3 AND NOTHING IN Section 6.2 , Article X OR Section 11.2 SHALL SUPERSEDE, SUPPLEMENT OR AMEND SUCH SOLE AND EXCLUSIVE REMEDIES.
THIS Article XVIII IS IN ADDITION TO THE SPECIFIC LIMITATIONS ON REMEDIES REFERENCED IN Article XIV , Section 4.4.1 AND Section 4.4.2 .
OWNER ACKNOWLEDGES THAT (A) PURCHASER (OR ITS AFFILIATES) MAY BE A PROPONENT OF OR PARTICIPATE IN OTHER BIDS WITH OTHER TRANSMISSION DEVELOPERS IN RESPONSE TO THE RFP (“ ADDITIONAL BIDS ”), EITHER ON ITS OWN OR WITH ONE OR MORE THIRD PARTIES AND (B) PURCHASER SHALL NOT BE LIABLE TO OWNER FOR ANY PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE, INCLUDING LOST PROFITS, IN EACH CASE, ARISING FROM OR RELATING TO ANY ADDITIONAL BIDS (INCLUDING IF ANY ADDITIONAL BIDS ARE SELECTED PURSUANT TO THE RFP), AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY). OWNER ACKNOWLEDGES AND AGREES THAT AS PART OF PURCHASER’S PARTICIPATION IN ADDITIONAL BIDS, PURCHASER SHALL EMPLOY MATERIALLY SIMILAR LANGUAGE IN DOCUMENTS PREPARED PURSUANT TO ADDITIONAL BIDS, FOR WHICH NO LIABILITY OR OBLIGATION OF ANY KIND, INCLUDING FOR COMPENSATION, SHALL BE IMPOSED UPON PURCHASER.
62
PURCHASER ACKNOWLEDGES THAT (A) OWNER (OR ITS AFFILIATES) MAY BE A PROPONENT OF OR PARTICIPATE IN OTHER BIDS WITH OTHER GENERATION DEVELOPERS IN RESPONSE TO THE RFP, EITHER ON ITS OWN OR WITH ONE OR MORE THIRD PARTIES AND (B) OWNER SHALL NOT BE LIABLE TO PURCHASER FOR ANY PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE, INCLUDING LOST PROFITS, IN EACH CASE ARISING FROM OR RELATING TO ANY SUCH OTHER BIDS (INCLUDING IF ANY SUCH OTHER BID IS SELECTED PURSUANT TO THE RFP) AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY). PURCHASER ACKNOWLEDGES AND AGREES THAT AS PART OF OWNER’S PARTICIPATION IN OTHER BIDS, OWNER MAY EMPLOY MATERIALLY SIMILAR LANGUAGE IN DOCUMENTS PREPARED PURSUANT TO OTHER BIDS, FOR WHICH NO LIABILITY OR OBLIGATION OF ANY KIND, INCLUDING FOR COMPENSATION, SHALL BE IMPOSED UPON OWNER.
Article XIX
MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES.
Section 19.1 Modifications . The Parties specifically intend and acknowledge and agree that, except as otherwise expressly provided in this Agreement, (a) this Agreement shall not be subject to amendment or other modification, absent the written agreement of both Parties and (b) neither Party shall be permitted to make a filing with FERC under any provision of the Federal Power Act or the regulations promulgated thereunder that seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement at any time during the Term, except to implement an amendment or other modification to this Agreement that has been reduced to writing and signed by both Parties. In addition, to the extent any third party, or FERC acting sua sponte , seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement, the standard of review for any proposed amendment or other modification shall be the “public interest” standard of review set forth in United Gas Pipe Line Co. v. Mobile Gas Service Corp ., 350 U.S. 332 (1956), and Federal Power Commission v. Sierra Pacific Power Co ., 350 U.S. 348 (1956), and as further defined in Morgan Stanley Capital Group, Inc. v. Public Utility District No. 1 of Snohomish County , 128 S. Ct. 2733 (2008) and NRG Power Marketing, LLC v. Maine Public Utilities Commission , 130 S. Ct. 693 (2010).
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment.
(a) This Agreement is subject to the ISO-NE Rules. If, during the Term, any ISO-NE Rule is terminated, modified or amended, or is otherwise no longer applicable, resulting in a material alteration of a material right or obligation of a Party hereunder, the Parties agree to negotiate in good faith in an attempt to amend or clarify this Agreement to embody the Parties’ original intent regarding their respective rights and obligations under this Agreement; provided that neither Party shall have any obligation to
63
agree to any particular amendment or clarification of this Agreement. The intent of the Parties is that any such amendment or clarification reflect, as closely as possible, the intent, substance and effect of the ISO-NE Rule being replaced, modified, amended or made inapplicable as such ISO-NE Rule was in effect prior to such termination, modification, amendment or inapplicability; provided that such amendment or clarification shall not in any event alter (i) the purchase and sale obligations of the Parties pursuant to this Agreement or (ii) the Transmission Service Payment. In the event the Parties cannot agree upon such amendments within sixty (60) days after such ISO-NE Rule or ISO-NE Practice change described above, the Dispute shall be resolved in accordance with Article XVII .
(b) If, during the Term, there is a change in Applicable Law (other than tax laws or regulations) or accounting standards or rules or a change in the interpretation or applicability thereof that would result in a (A) material adverse balance sheet or creditworthiness impacts on Purchaser associated with this Agreement or the amounts paid for Firm Transmission Service purchased hereunder, or (B) an adverse impact on the economic benefits (including those stemming from the fiscal conditions provided for herein) that any Party enjoys under this Agreement or that are provided for herein for any Party during the Term, the Parties shall use commercially reasonable efforts to agree to an amendment to the Agreement to avoid or mitigate such impacts and restore the economic benefits to each affected Party; provided that such amendment mitigates any material adverse effect(s) on each non-affected Party (as identified by each such Party, acting reasonably) that could reasonably be expected to result from such amendment, but only to the extent that such mitigation can be accomplished in a manner that is consistent with the purpose of such amendment. In the event the Parties cannot agree on an amendment in accordance with this Section 19.2(b) , the Dispute shall be resolved in accordance with Article XVII .
(c) Upon a determination by a court or regulatory body having jurisdiction over this Agreement or any of the Parties, or over the establishment and enforcement of any of the statutes or regulations or orders or actions of regulatory agencies (including the MDPU) supporting this Agreement or the rights or obligations of the Parties hereunder that any of the statutes or regulations supporting this Agreement or the rights or obligations of the Parties hereunder, or orders of or actions of regulatory agencies (including the MDPU) implementing such statutes or regulations, or this Agreement on its face or as applied, violates any Applicable Law (including the State or Federal Constitution) (an “ Adverse Determination ”), each Party shall have the right to suspend performance under this Agreement without liability. Owner may provide transmission service to a third party during any period of time for which Purchaser suspends payments under this Section 19.2(c) . Upon an Adverse Determination becoming final and non-appealable, this Agreement shall be rendered null and void.
(d) For the avoidance of doubt, it is understood that the provisions of Article XVII regarding dispute resolution apply to any Dispute under this Article XIX .
64
Section 20.1 Purchaser Indemnity . Purchaser shall indemnify, defend and hold harmless Owner and Owner’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, an “ Owner Indemnified Party ”) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Owner Indemnified Party, and arising out of the negligence, willful misconduct or criminal misconduct of Purchaser or its agents. Purchaser shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Owner Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, an Owner Indemnified Party. This Section 20.1 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPA, the Additional PPAs, the Distribution Company TSA or the Additional RFP Sponsor TSAs.
Section 20.2 Owner Indemnity . Owner shall indemnify, defend and hold harmless Purchaser and Purchaser’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives and permitted successors and assigns (each, a “ Purchaser Indemnified Party ”) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party, including any such liabilities incurred by a Purchaser Indemnified Party under the PPA, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents, including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Purchaser Indemnified Party. This Section 20.2 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPA, the Additional PPAs, the Distribution Company TSA or the Additional RFP Sponsor TSAs.
Section 20.3 [Intentionally Omitted].
65
Section 20.4 Procedures . Promptly after the receipt by any Person seeking indemnification under this Article XX (the “ Indemnified Party ” ) of written notice of the assertion of any claim by a third party with respect to any matter in respect of which indemnification may be sought hereunder (a “ Third Party Claim ” ), the Indemnified Party shall give written notice (the “ Indemnification Notice ” ) to the Party from which indemnification is sought (the “ Indemnifying Party ” ), and shall thereafter keep the Indemnifying Party reasonably informed with respect thereto; provided, however , that the failure of the Indemnified Party to give the Indemnifying Party notice as provided herein shall not relieve the Indemnifying Party of any of its obligations hereunder, except to the extent that the Indemnifying Party is materially prejudiced by such failure. The Indemnifying Party shall be entitled to assume the defense of any Third Party Claim by written notice to the Indemnified Party of such intention given within thirty (30) days after the receipt by the Indemnifying Party of the Indemnification Notice; provided, however , that counsel selected by the Indemnifying Party shall be reasonably satisfactory to the Indemnified Party. The Indemnifying Party shall be liable for the fees and expenses of counsel employed by the Indemnified Party for any period during which the Indemnifying Party has not assumed the defense of any Third Party Claim (other than during any period during which the Indemnified Party has failed to give notice of such Third Party Claim as provided above). If the Indemnifying Party shall assume the defense of the Third Party Claim, then the Indemnifying Party shall not compromise or settle such Third Party Claim without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld, delayed or conditioned; provided, however , that the Indemnified Party shall have no obligation to consent to any settlement that (a) does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff of a release of the Indemnified Party from all liability with respect to such Third Party Claim or (b) involves the imposition of equitable remedies or the imposition of any material obligations on such Indemnified Party other than financial obligations for which such Indemnified Party is indemnified hereunder. As long as the Indemnifying Party is contesting any such Third Party Claim on a timely basis, the Indemnified Party shall not pay, compromise or settle any claims brought under such Third Party Claim. Notwithstanding the assumption by the Indemnifying Party of the defense of any Third Party Claim as provided in this Section 20.4 , the Indemnified Party shall be permitted to participate in the defense of such Third Party Claim and to employ counsel at its own expense (it being understood that the Indemnifying Party controls such defense); provided, however , that, if the defendants in any Third Party Claim shall include both an Indemnifying Party and any Indemnified Party, and such Indemnified Party shall have reasonably concluded that counsel selected by the Indemnifying Party has a conflict of interest because of the availability of different or additional defenses to such Indemnified Party, such Indemnified Party shall then have the right to select separate counsel to participate in the defense of such Third Party Claim on its behalf, at the expense of the Indemnifying Party; provided that the Indemnifying Party shall not be obligated to pay the expenses of more than one separate counsel for all Indemnified Parties, taken together.
Section 20.5 Defenses . If the Indemnifying Party shall fail to notify the Indemnified Party of its desire to assume the defense of any Third Party Claim within the prescribed period of time, or shall notify the Indemnified Party that it will not assume the defense of any such Third Party Claim, then the Indemnified Party may assume the defense of any such Third Party Claim, in which case it may do so acting in good faith and otherwise in such manner as it may deem appropriate, and the Indemnifying Party shall be bound by any determination made in such Third Party Claim.
66
Section 20.6 Cooperation . The Indemnified Party and the Indemnifying Party shall each cooperate fully (and shall each cause its Affiliates to cooperate fully) with the other in the defense of any Third Party Claim pursuant to this Article XX . Without limiting the generality of the foregoing, each such Person shall furnish the other such Person (at the expense of the Indemnifying Party) with such documentary or other evidence as is then in its or any of its Affiliates’ possession, as may reasonably be requested by the other Person for the purpose of defending against any such Third Party Claim.
Section 20.7 Recovery . The amount of any indemnity hereunder shall be reduced by any insurance proceeds actually recovered by the Indemnified Party in connection with the Third Party Claim. If at any time subsequent to the receipt by an Indemnified Party of an indemnity payment hereunder, such Indemnified Party (or any Affiliate thereof) receives any recovery, settlement or other similar payment with respect to the Third Party Claim for which it received such indemnity payment (a “ Recovery ”), such Indemnified Party shall then promptly pay to the Indemnifying Party the amount of such Recovery, less any expenses incurred by such Indemnified Party (or its Affiliates) in connection with such Recovery, but in no event shall any such payment exceed the amount of such indemnity payment.
Section 20.8 Subrogation . To the extent the Indemnifying Party makes or is required to make any indemnity payment to the Indemnified Party, the Indemnifying Party shall be entitled to exercise, and shall be subrogated to, any rights and remedies (including rights of indemnity, rights of contribution and other rights of recovery) that the Indemnified Party or any of its Affiliates may have against any other Person with respect thereto, whether directly or indirectly related. The Indemnified Party shall permit the Indemnifying Party to use the name of the Indemnified Party and the names of the Indemnified Party’s Affiliates in any transaction or in any proceeding or other matter involving any of such rights or remedies; and the Indemnified Party shall take such actions as the Indemnifying Party may reasonably request for the purpose of enabling the Indemnifying Party to perfect or exercise its right of subrogation hereunder.
Article XXI
REPRESENTATIONS, WARRANTIES AND COVENANTS
Section 21.1 Mutual Representations and Warranties . Each Party hereby represents and warrants to the other Party that all of the statements in this Section 21.1 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of (i) the Effective Date, (ii) the Commercial Operation Date and (iii) the start of the Purchaser Term , but not as of any other date:
(a) It has knowledge and experience in financial matters and in the electric industry that enable it to evaluate the merits and risks of this Agreement and the transactions contemplated hereby, and is capable of evaluating such merits and risks and assuming such risks. It is acting for its own account, has made its own independent decision to enter into this Agreement as to whether this Agreement is appropriate and proper for it based upon its own judgment, is not relying upon the advice or recommendations of the other Party in doing so, and understands and accepts the terms, conditions, and risks of this Agreement and the transactions contemplated hereby;
67
(b) It has entered into this Agreement in connection with the conduct of its business;
(c) It is not acting as a fiduciary or an advisor with respect to this Agreement or the transactions contemplated hereby;
(d) It is not subject to an Insolvency Event and there are no proceedings pending or being contemplated by it or, to its knowledge, threatened against it that could result in the occurrence of an Insolvency Event with respect to it; and
(e) It is an entity subject to the procedures and substantive provisions of the Bankruptcy Code applicable to U.S. corporations or limited liability companies, as applicable, generally.
Section 21.2 Additional Representations and Warranties of Purchaser . Purchaser hereby represents and warrants to Owner that all of the statements in this Section 21.2 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Purchaser is duly organized, validly existing, and in good standing under the laws of the State of Delaware and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Purchaser, and Purchaser has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Purchaser has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Purchaser;
(c) Assuming due authorization, execution and delivery by Owner, this Agreement constitutes Purchaser’s legal, valid and binding obligation enforceable against Purchaser in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Purchaser or any of its Affiliates that could have a Material Adverse Effect on Purchaser;
(e) No event with respect to Purchaser has occurred or is continuing that would constitute a Purchaser Default, and no Purchaser Default will occur as a result of Purchaser entering into or performing its obligations under this Agreement;
68
(f) The execution, delivery and performance of this Agreement by Purchaser does not and will not (i) violate any provisions of its certificate of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) To the best of Purchaser’s knowledge, the Canadian Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary for TransÉnergie to commence construction of and to own and operate the Québec Line in a manner consistent with Attachment A and this Agreement; and
(h) Purchaser is in compliance with all Applicable Laws, except such noncompliance as could not reasonably be expected to have a Material Adverse Effect on Purchaser. Purchaser has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Purchaser.
Section 21.3 Additional Representations and Warranties of Owner . Owner hereby represents and warrants to Purchaser that all of the statements in this Section 21.3 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Owner is duly organized, validly existing, and in good standing under the laws of the State of Maine and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Owner, and Owner has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Owner has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Owner;
(c) Assuming due authorization, execution and delivery by Purchaser, this Agreement constitutes Owner’s legal, valid and binding obligation enforceable against Owner in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Owner or any of its Affiliates that could have a Material Adverse Effect on Owner;
(e) No event with respect to Owner has occurred or is continuing that would constitute an Owner Default, and no Owner Default will occur as a result of Owner entering into or performing its obligations under this Agreement;
69
(f) The execution, delivery and performance of this Agreement by Owner does not and will not (i) violate any provisions of its articles of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The FERC Authorization, the Owner Approvals (other than the Municipal Owner Approvals) and the AC Upgrade Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary to commence construction of and operate the NECEC Transmission Line (other than the Municipal Owner Approvals);
(h) To the best of Owner’s knowledge, the Municipal Owner Approvals identified in paragraph 10 of Attachment C constitute all of the Municipal Owner Approvals that are necessary to commence construction of and operate the NECEC Transmission Line;
(i) Owner is in compliance with all Applicable Laws, except such noncompliance as could not reasonably be expected to have a Material Adverse Effect on Owner. Owner has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Owner; and
(j) Owner has acquired all required real property rights necessary for construction and operation of the NECEC Transmission Line, and the interconnection of the NECEC Transmission Line with (A) the Québec Line (other than real property rights to be held by TransÉnergie) and (B) the Delivery Point, in full and final form with all options or contingencies having been exercised as set forth in Attachment I .
Section 21.4 [Intentionally Omitted].
Section 21.5 NO OTHER REPRESENTATIONS OR WARRANTIES . THE REPRESENTATIONS AND WARRANTIES OF OWNER SET FORTH IN Section 21.1 AND Section 21.3 ARE OWNER’S SOLE REPRESENTATIONS AND WARRANTIES ASSOCIATED WITH THE NECEC TRANSMISSION LINE AND ARE MADE IN LIEU OF ALL OTHER REPRESENTATIONS, WARRANTIES AND GUARANTEES, EXPRESS OR IMPLIED, ASSOCIATED WITH THE NECEC TRANSMISSION LINE, INCLUDING REPRESENTATIONS OR WARRANTIES AS TO MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE. THE FOREGOING SENTENCE SHALL NOT BE CONSTRUED IN ANY WAY TO LIMIT OWNER’S EXPRESS OBLIGATIONS UNDER THIS AGREEMENT.
70
Article XXII
TRANSFER OF INTERESTS
Section 22.1 No Transfer of Interests.
(a) Any (i) direct or indirect change of Control of any Party (whether voluntary or by operation of law), (ii) sale, transfer or other disposition of all or substantially all of the assets of any Party or (iii) except as provided in Section 22.2 or Section 22.3 , assignment, transfer or other disposition of, whether to one or more assignees or transferees, all or any portion of any Party’s rights, interests or obligations under this Agreement (each of the foregoing, a “ Transfer ”), shall require the prior written consent of the other Party, which consent shall not be unreasonably withheld, delayed or conditioned when viewed in light of all reasonable considerations, including the security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer); provided that any direct or indirect transfer of securities or other ownership interests in a Party to a Person Controlled by a Party’s ultimate parent company (for Purchaser, currently Hydro-Québec, and for Owner, currently Iberdrola, S.A.), as applicable, shall not be considered a Transfer for the purposes of this Section 22.1(a) and shall not require consent. Any Transfer in contravention of this Article XXII shall be null and void. The Parties agree that the provision by or for the account of an assignee or transferee of any Party of Additional Credit Support in an amount equal to the Maximum Amount provided under, and as defined in, the Hydro-Québec Guaranty, as such Maximum Amount may vary from time to time, shall be deemed to satisfy the criterion set forth herein with respect to security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer).
(b) If Owner consents to a Transfer by Purchaser pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Purchaser’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Owner of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that a Purchaser Default shall not have occurred and be continuing, (x) the obligations of Purchaser shall terminate to the extent of the Transferred portion of this Agreement, and Purchaser shall be fully, finally, and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Purchaser, Owner shall execute and deliver to Purchaser a full, final, and unconditional release of any credit support or guarantees provided by Purchaser, in such form as Purchaser may reasonably request, with respect to the Transferred portion of this Agreement.
71
(c) If Purchaser consents to a Transfer by Owner pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Owner’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Purchaser of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that an Owner Default shall not have occurred and be continuing, (x) the obligations of Owner shall terminate to the extent of the Transferred portion of this Agreement, and Owner shall be fully, finally, and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Owner, Purchaser shall execute and deliver to Owner a full, final, and unconditional release of any credit support or guarantees provided by Owner hereunder, in such form as Owner may reasonably request, with respect to the Transferred portion of this Agreement.
(d) [Intentionally Omitted].
(e) Nothing herein shall prevent Purchaser or any assignee thereof from transferring or assigning transmission service rights pursuant to FERC rules and regulations.
Section 22.2 Exceptions . Notwithstanding Section 22.1 , consent shall not be required for any of the following:
(a) an assignment by Purchaser to any of its Affiliates; provided that Hydro-Québec confirms in a writing satisfactory to Owner that the Hydro-Québec Guaranty applies with respect to the assignee’s obligations under this Agreement;
(b) [intentionally omitted];
(c) any (i) change of Control of Owner or (ii) transfer or other disposition of all or substantially all of the assets of Owner, in each case, resulting from a collateral assignment in favor of a financing party in accordance with Section 22.3 ;
(d) any change of Control of Owner resulting from any direct or indirect change of Control in Owner’s ultimate parent company (currently Iberdrola, S.A.), Owner’s ultimate parent company in the United States (currently AVANGRID, Inc.) or in the parent company for the network business in the United States of which Owner is part (currently Avangrid Networks, Inc.);
(e) any change of Control of Purchaser resulting from the direct or indirect transfer of interests in Hydro-Québec; or
(f) the exercise of any of Purchaser’s rights pursuant to Section 14.7 , 14.8(a) or 14.8(b) .
72
Section 22.3 Collateral Assignment . Owner shall be entitled, without restriction, to make one or more assignments of this Agreement for purposes of collateral security or any or all of its rights and benefits hereunder to or for the benefit of any and all secured lenders to Owner, or grant to or for the benefit of any and all secured lenders to Owner a lien on, or security interest in, any right, title or interest in all or any part of Owner’s rights hereunder for the purpose of the financing or successive refinancing of the ownership, development, engineering, construction or operation of the NECEC Transmission Line; provided , however , that such assignment for purposes of collateral security shall recognize Purchaser’s rights under this Agreement on terms and conditions as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner. To facilitate Owner’s obtaining of financing or successive refinancing for the ownership, development, engineering, construction or operation of the NECEC Transmission Line, Purchaser shall cooperate with Owner and shall execute and deliver such consents, acknowledgements, direct agreements or similar documents as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner.
Article XXIII
MISCELLANEOUS
Section 23.1 Governing Law . This Agreement and each of its provisions shall be governed by, and construed in accordance with, the laws of the Commonwealth of Massachusetts.
Section 23.2 Entire Agreement . This Agreement, together with the Attachments, constitutes the entire Agreement and understanding between the Parties with respect to all subjects covered hereby and thereby and supersedes all prior discussions, agreements and understandings between the Parties with respect to such matters. Notwithstanding the foregoing, each Party is subject to obligations under different Proposal Agreements.
Section 23.3 Severability . Except as otherwise provided in Section 2.2 or Section 19.2 , (a) in the event any part of this Agreement is held to be illegal, invalid or unenforceable to any extent, the legality, validity and enforceability of the remainder of this Agreement shall not be affected thereby, and shall remain in full force and effect and shall be enforced to the greatest extent permitted by Applicable Law and (b) with respect to any provision found to be illegal, invalid or unenforceable, the Parties shall endeavor to replace such invalid, illegal or unenforceable provision with the valid, legal and enforceable provision that achieves, as nearly as practicable, the commercial intent of this Agreement (as it may be amended from time to time).
Section 23.4 Notices . All notices, billings, requests, demands, waivers, consents and other communications under this Agreement shall be in writing and shall be effective (a) upon personal delivery thereof, including by overnight mail or courier service, with a record of receipt, (b) in the case of notice by United States mail, certified or registered, postage prepaid, return receipt requested, upon the fourth (4th) day after mailing, (c) in the case of notice by facsimile for any communications other than billings, upon transmission; provided that such facsimile transmission is promptly confirmed by either of the methods set forth in the foregoing clause (a) or (b), in each case, addressed to each Party and copy party hereto at its address set forth below or at such other address as a Party may from time to time designate by written notice to the other Party pursuant to this Section 23.4 , (d) in the case of notice by facsimile for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts),
73
upon receipt of confirmation of successful transmission, but without any further requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b), or (e) in the case of notice by electronic mail for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon transmission, without any requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b); provided that the Party delivering such notice did not receive any notice of unsuccessful or delayed transmission. A notice given in connection with this Section 23.4 but received on a day other than a Business Day, or after business hours at the location of receipt, shall be deemed to be received on the next Business Day.
If to Owner:
Central Maine Power Company
Attn: Douglas Herling, President & CEO
83 Edison Drive, Augusta ME 04336
207-626-9779
With a copy to:
Central Maine Power Company
Attn: Legal Department
83 Edison Drive, Augusta ME 04336
With a further copy to:
Pierce Atwood LLP
Attn: Jared des Rosiers
254 Commercial St., Portland ME 04101
If to Purchaser:
H.Q. Energy Services (U.S.) Inc.
75, René-Lévesque Boulevard West, 18th Floor
Montréal (Québec) Canada
H2Z 1A4
Attention: President
Facsimile: (514) 289-6723
Section 23.5 Waiver; Cumulative Remedies . Any term or condition of this Agreement may be waived at any time by the Party that is entitled to the benefit thereof, but such waiver shall not be effective unless set forth in a written instrument duly executed by or on behalf of the Party waiving such term or condition. No waiver by any Party of any term or condition of this Agreement, in any one or more instances, shall be deemed to be, or construed as, a subsequent waiver of, or estoppel with respect to, the same or any other term or by Applicable Law. Except as otherwise provided in Section 13.2(b) , the failure of or delay on the part of any Party to enforce or insist upon compliance with or strict performance of any term or condition of this Agreement, or to take advantage of any of its rights thereunder, shall not constitute a waiver or relinquishment of any such terms, conditions, or rights, but the same shall be and remain at all times in full force and effect. Except as otherwise provided herein, the remedies provided in this Agreement are cumulative and not exclusive of any remedies provided by law or in equity.
74
Section 23.6 Confidential Information . Each Party hereby agrees that it shall not disclose, or cause to be disclosed, to third parties any Confidential Information with respect to the other Party or any material or information identified as Critical Energy Infrastructure Information (other than to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential). Notwithstanding the foregoing, each Party may disclose information related to this Agreement to another party to a Proposal Agreement or to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential, only if necessary to comply with its obligations hereunder or thereunder or to coordinate the parties’ obligations under different Proposal Agreements. Each Party shall be responsible for ensuring that any Person to whom it discloses any Confidential Information shall comply with the restrictions in this Section 23.6 . The restrictions in this Section 23.6 shall not apply (w) to the extent disclosure is required by Applicable Law or the requirements of a Governmental Authority (including a court order, oral questions, written interrogatories, request for information or documents, subpoena or similar process, or the requirements of any stock exchange or other Governmental Authority to which the Parties, or any of their Affiliates are subject), (x) to the extent reasonably deemed by the disclosing Party to be required or desirable in connection with regulatory proceedings (including proceedings relating to FERC or any other national, federal, provincial, state or regulatory agency), (y) to the extent reasonably deemed by the disclosing Party to be required to be disclosed in connection with a Dispute between the Parties, or the defense of any litigation or dispute, or (z) as approved for release or disclosure by the Party whose Confidential Information is at issue. In the event disclosure is made pursuant to this Section 23.6 , and except for disclosures pursuant to the requirements of securities laws or any stock exchange, the disclosing Party shall use reasonable efforts to minimize the scope of any disclosure and advise recipients of any applicable confidentiality restrictions provided herein. Notwithstanding the foregoing, this Section 23.6 shall not apply to the following information:
(a) Information that is a matter of public knowledge at the time of its disclosure or is thereafter published in or otherwise ascertainable from a source available to the public without breach of this Section 23.6 ;
(b) Information that is obtained from a Person other than by or as a result of unauthorized disclosure; or
(c) Information that, prior to the time of disclosure, had been independently developed or obtained by the disclosing Party or its Affiliates independent of information obtained as a result of unauthorized disclosure.
Section 23.7 No Third-Party Rights . Except for any secured lenders contemplated by Section 22.3 and any Owner Indemnified Party or Purchaser Indemnified Party contemplated by Article XX , the Parties do not intend for this Agreement to confer a third-party beneficiary status or rights of action upon any Person whatsoever other than the Parties and their permitted successors and assigns, and nothing contained herein, either express or implied, shall be construed to confer upon any Person, other than the Parties and their permitted successors and assigns, any rights of action or remedies under this Agreement or in any manner, or any duty, standard of care, or liability with respect thereto. This Agreement does not create any third-party rights, except as expressly stated above in this Section 23.7 .
75
Section 23.8 Permitted Successors and Assigns . This Agreement shall be binding upon and inure to the benefit of each of the Parties and their permitted successors, legal representatives and assigns.
Section 23.9 Relationship of the Parties . This Agreement shall not be construed as creating an association, joint venture, trust or partnership between the Parties or as imposing any partnership obligation or liability upon either Party. Except as contemplated by Article X or Section 14.7 , neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.
Section 23.10 Construction . No presumption shall operate in favor of or against either Party as a result of any responsibility for drafting this Agreement.
Section 23.11 Counterparts . This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument. The Parties acknowledge and agree that any document or signature delivered by facsimile or electronic transmission shall be deemed to be an original executed document for all purposes hereof.
Section 23.12 Survival . The provisions of Section 3.3 , Section 3.4 , Article IX , Article XIII , Article XIV , Article XVII , Article XVIII , Article XIX , Article XX and this Article XXIII shall survive the expiration or earlier termination of this Agreement.
Section 23.13 Language . All notices, requests, demands, waivers, consents and other communications between Owner and Purchaser under this Agreement shall be conducted in English.
Section 23.14 Headings and Table of Contents . The headings of the articles and sections of this Agreement and the Table of Contents are inserted for purposes of convenience only, and shall not be construed to affect the meaning or construction of any of the provisions hereof.
Section 23.15 Waiver of Immunities . The Parties acknowledge and agree that this Agreement and the transactions contemplated hereby constitute a commercial transaction. To the extent a Party (including any assignees of a Party’s rights or obligations under this Agreement) may be entitled, in any jurisdiction, to claim for itself, or any of its assets, revenues or properties, sovereign or other immunity, as the case may be, from service of process, suit, the jurisdiction of any court or arbitral tribunal, attachment (whether in aid of execution or otherwise) or enforcement of a judgment (interlocutory or final) or award or any other legal process in a matter arising out of or relating to this Agreement, each Party agrees not to claim or assert, and hereby waives, such immunity. Without limiting the generality of the foregoing, each Party agrees that the waivers set forth in this Section 23.15 shall have the fullest scope permitted under the Immunities Act and under any other Applicable Law related to sovereign immunity.
[Signature pages follow]
76
IN WITNESS WHEREOF , Owner and Purchaser have executed this Agreement as of the Execution Date.
OWNER: |
||
|
||
CENTRAL MAINE POWER COMPANY |
||
|
|
|
By: |
|
/s/ Douglas Herling |
Name: |
|
Douglas Herling |
Title: |
|
President & CEO |
|
|
|
By: |
|
/s/ Eric N. Stinneford |
Name: |
|
Eric N. Stinneford |
Title: |
|
Vice President, Controller, Treasurer & Clerk |
|
|
|
PURCHASER: |
||
|
|
|
H.Q. ENERGY SERVICES (U.S.) INC. |
||
|
|
|
By: |
|
/s/ David Murray |
Name: |
|
David Murray |
Title: |
|
Chairman of the Board and President |
Attachment A
Description of Transmission Projects
The Québec Line and the NECEC Transmission Line consist in their entirety of:
|
(1) |
New 207 mile (145.3 miles in Maine) +/- 320 kV overhead HVDC transmission line that will run between the existing Appalaches Substation in Thetford Mines, Québec and a new HVDC converter station approximately 1.6 miles from the existing Larrabee Road Substation in Lewiston, Maine; |
|
(2) |
New HVDC converter stations at both ends of the transmission line; and |
|
(3) |
Certain upgrades to the existing high voltage alternating current (AC) New England transmission system necessary to permit the interconnection and transmission of Hydro Generation to the New England Control Area (as defined in the ISO-NE Tariff) at the existing Larrabee Road substation under the requirements of Section I.3.9 and the CCIS of ISO-NE Tariff. |
|
(4) |
System upgrades to the existing Québec transmission system as determined by the Hydro-Québec TransÉnergie System Impact Study (OASIS #203T), as it may be updated. |
Owner is the developer of the portion of the NECEC Transmission Line from the Québec-Maine border to the Lewiston area and all transmission upgrades on the U.S. side of the border. The NECEC Transmission Line and the Québec Line are expected to connect at the Québec-Maine border in the northwest corner of Maine in Beattie Township.
The Québec Line will be constructed by TransÉnergie, a division of Hydro-Québec and an Affiliate of Purchaser.
Owner will construct, own, operate and maintain the NECEC Transmission Line, which will be constructed in existing transmission corridors owned by Owner.
The NECEC Transmission Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 145.3 mile +/-320 kV HVDC transmission line from the Canadian Border to a new converter substation located on Merrill Road in Lewiston |
|
ii. |
New 1.6 mile 345 kV AC transmission line from the new Merrill Road converter substation to the existing Larrabee Road substation |
|
b. |
Substation Equipment : |
|
i. |
New 345 kV AC to +/-320 kV HVDC 1200 MW Merrill Road converter substation |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Larrabee Road substation |
|
(2) |
Network Upgrades (subject to change based on ISO-NE system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
New 26.5 mile 345 kV AC transmission line from the existing Coopers Mills substation in Windsor to the existing Maine Yankee substation in Wiscasset |
|
ii. |
New 0.3 mile 345 kV AC transmission line from the existing Surowiec substation in Pownal to a new substation on Fickett Road in Pownal |
|
iii. |
Rebuild 9.3 mile 115 kV Section 62 AC transmission line from the existing Crowley Road substation in Sabattus to the existing Surowiec substation |
|
iv. |
Rebuild 16.1 mile 115 kV Section 64 AC transmission line from the existing Larrabee Road substation to the existing Surowiec substation |
|
v. |
Partial rebuild of 0.8 mile each of 115 kV Section 60/88 outside Coopers Mills substation |
|
vi. |
Partial rebuild of 0.3 miles of 345 kV Section 392 AC transmission line between the Coopers Mills substation and the Maine Yankee substation and approximately 3.5 miles of reconductor work on existing double circuit lattice steel towers outside of the Maine Yankee substation |
|
vii. |
Partial rebuild of 0.3 miles of 345 kV Section 3025 between Coopers Mills substation and Larrabee Road substation |
|
viii. |
Partial rebuild 0.8 miles of 34.5 kV Section 72 AC transmission line outside of the Larrabee Road substation |
|
b. |
Substation Equipment: |
|
i. |
Replace existing Larrabee Road 345/115 kV 448 MVA autotransformer with a 600 MVA autotransformer |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Maine Yankee substation |
|
iii. |
Add 345 kV AC transmission line terminal and 115 kV switch replacements at the existing Surowiec substation |
|
iv. |
115 kV Switch and bus wire replacements at Crowley substation |
|
v. |
New 345 kV Fickett Road substation with 345 kV +/-200 MVAr Static Compensator (STATCOM) |
|
vi. |
Add 345 kV AC transmission line terminal and additional 345 kV +/-200 MVAr STATCOM (+/-400 MVAr total with the +/-200 MVAr existing) at the existing Coopers Mills substation |
|
vii. |
Add 345/115 kV 448 MVA autotransformer, associated 115 kV buswork and terminate existing 115 kV Sections 164, 164A and 165 into three new breaker-and-a-half bays at the existing Raven Farm substation |
The NECEC transmission components located in Maine are depicted geographically in relationship to the existing Owner transmission system in Figure 1 below.
Figure 1 – Map Depicting the Components of the NECEC Transmission Line
The Québec Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 65 mile +/-320 kV HVDC transmission line from the Appalaches substation located in Thetford Mines to the U.S. border |
|
b. |
Substation Equipment : |
|
i. |
New +/-320 kV, 1200 MW HVDC converter connected to the 735 kV AC bus of the Appalaches substation and associated 735 kV bus work |
|
(2) |
Network Upgrades (subject to change based on additional system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
Thermal upgrade of existing 735 kV lines 7005 and 7035 (68 miles from Lévis substation to Nicolet substation) |
|
ii. |
Thermal upgrade of existing 735 kV line 7049 (44 miles from Montérégie substation to Hertel substation) |
|
b. |
Substation Equipment: |
|
i. |
Add two 200 MVAr shunt capacitor banks at the Carignan substation |
|
ii. |
Add one 330 MVAr shunt reactor at the Carignan substation |
Critical Milestones
Item |
Critical Milestone* |
Due Date** |
1. |
Closing of Any Required Financing |
March 7, 2019 |
2. |
Receipt of all Owner Approvals (other than Municipal Owner Approvals) and AC Upgrade Approvals in Final Form |
December 14, 2019 |
3. |
Receipt of all Canadian Approvals |
March 11, 2021 |
4. |
Receipt of all Municipal Owner Approvals |
March 31, 2022 |
5. |
Execution of Contract with the Manufacturer of the Converter Station at the Southern End of the HVDC Line and associated minimum 5% contract value payment |
July 30, 2019 |
6. |
Execution of Contract for the Engineering, Procurement, or Construction of the Converter Station on the Québec Line |
July 30, 2019 |
7. |
Commercial Operation Date |
December 13, 2022 |
* |
As defined in Section 4.1(a) |
** |
Subject to extension in accordance with the Agreement |
Owner Approvals
Set forth below are the Governmental Approvals and Third Party Consents, in each case, required to commence construction of and operate the NECEC Transmission Line:
|
1. |
ISO-NE: Approval pursuant to Section I.3.9 of the ISO-NE Tariff to interconnect and operate the NECEC Transmission Line at no fewer than 1,040 MW |
|
2. |
Maine Public Utilities Commission (MPUC): Certificate of Public Convenience and Necessity (CPCN) |
|
3. |
U.S. Department of Energy (DOE): Presidential Permit |
|
4. |
Maine Department of Environmental Protection (MDEP): |
|
a. |
Site Location of Development Act (SLODA) Permit |
|
b. |
Stormwater Management Permit |
|
c. |
Natural Resources Protection Act (NRPA) Permit |
|
d. |
Clean Water Act (CWA) Section 401 Water Quality Certification |
|
e. |
Maine Construction General Permit |
The SLODA Permit, Stormwater Management Permit, NRPA Permit, and CWA Section 401 Water Quality Certification may be combined into one permit.
|
5. |
Maine Land Use Planning Commission (LUPC): Certificate of Compliance |
|
6. |
Maine Department of Agriculture, Conservation and Forestry: |
|
a. |
Submerged Lands Lease |
|
b. |
Public Reserved Land Lease |
|
7. |
Maine Department of Transportation (DOT): |
|
a. |
Utility Location/Road Opening Permits |
|
b. |
Driveway/Entrance Permits |
|
8. |
U.S. Army Corps of Engineers: |
|
a. |
CWA Section 404 - Individual Permit |
|
b. |
Section 10 Rivers & Harbors Act of 1899 |
|
9. |
Federal Aviation Administration Infrastructure in Vicinity of Airports: Determination of No Hazard to Air Navigation |
|
10. |
Municipal Owner Approvals: |
|
a. |
The Municipal Owner Approvals consist of the following types of permits: |
|
i. |
Shoreland zoning permits |
|
ii. |
Building permits |
|
iii. |
Flood hazard development permits |
|
iv. |
Conditional use / rezoning approvals |
|
v. |
Site plan / subdivision approvals |
|
vii. |
Street opening, blasting and demolition permits |
|
viii. |
Utility location permits |
|
b. |
Owner shall obtain the Municipal Owner Approvals listed above that are necessary (if any) in the following municipalities for the NECEC Transmission Line, subject to any necessary exemptions issued by the MPUC relating to any Municipal Owner Approvals that are denied in any such municipalities or relating to any conditions contained in any Municipal Owner Approvals that are unacceptable to Owner: |
i. |
Alna |
xiii. |
Embden |
ii. |
Lewiston |
xiv. |
Starks |
iii. |
Anson |
xv. |
Farmington |
iv. |
Livermore Falls |
xvi. |
Whitefield |
v. |
Auburn |
xvii. |
Greene |
vi. |
Moscow |
xviii. |
Wilton |
vii. |
Caratunk |
xix. |
Industry |
viii. |
New Gloucester |
xx. |
Windsor |
ix. |
Chesterville |
xxi. |
Jay |
x. |
New Sharon |
xxii. |
Wiscasset |
xi. |
Durham |
xxiii. |
Leeds |
xii. |
Pownal |
xxiv. |
Woolwich |
Canadian Approvals
Set forth below are, to the best of Purchaser’s knowledge, the Governmental Approvals and Third Party Consents, in each case, required to commence construction of the Québec Line:
|
• |
Permit from the National Energy Board to construct, operate, maintain or connect an international power line pursuant to the National Energy Board Act (R.S. C., 1985, c. N-7); |
|
• |
Permit from the International Boundary Commission required to cross the Canada-U.S. border pursuant to Article 5 of the International Boundary Commission Act; |
|
• |
Authorization from the Régie de l’énergie to acquire, construct or dispose of transmission assets pursuant to an Act respecting the Régie de l’énergie (R.S.Q., chapter R-6.01); |
|
• |
Expropriation Order in council, if required, to acquire by expropriation any immovable, servitude or construction required for the transmission of power pursuant to Hydro-Québec Act (R.S.Q., chapter H-5) and the Expropriation act (R.S.Q., chapter E-24); |
|
• |
Certificate of authorization issued by the Government of Québec to construct the transmission line under Section 31.5 of the Environmental Quality Act subject to the environmental and social impact assessment and review procedure; |
|
• |
Certificate of authorization issued by the Ministère du Développement durable, de l’Environnement et de la Lutte contre les changements climatiques approving the plans and specifications of the transmission line pursuant to Section 22 of the Environmental Quality Act; |
|
• |
Authorization of the Commission de protection du territoire agricole du Québec , if required, approving the use of land situated in an agricultural zone for purposes other than agriculture under Sections 58 and 62 of the Act respecting the preservation of agricultural land and agricultural activities; |
|
• |
Opinion on project compliance with objectives of the city or regional county municipalities’ land-use and development plan. |
Attachment E
Owner’s Preliminary Project Schedule and Construction Schedule
Required Insurance
Owner shall obtain and maintain with qualified insurers authorized to issue insurance of the types described below in the State of Maine.
During construction of the NECEC Transmission Line Owner shall maintain or effect to be maintained the following insurance coverages:
|
• |
Primary and Excess Liability |
|
• |
Construction All Risk / Builders Risk |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
|
• |
Pollution / Environmental Liability |
After the Commercial Operation Date Owner shall provide coverage both in terms of scope and limits of coverage that are in accordance with Good Utility Practice and the long-standing practice of Owner. Operational coverage shall include the following insurance types:
|
• |
Excess Liability |
|
• |
Operational All Risk Property Damage |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
Note : At any time after the Commercial Operation Date Owner may choose, as far as it is consistent with Good Utility Practice, to self-insure on customary terms and conditions any coverage (or coverage part) where it meets any state or regulatory requirements of self-insurers.
Rate Adjustment Formula
In the event that a Transmission Service Payment is subject to reduction pursuant to Section 8.1 , such reduced payment shall equal the Transmission Service Payment that would otherwise be payable under the Agreement for a particular month multiplied by the lesser of 1 or the following fraction:
1 - |
(Contract Capacity x 0.90) |
minus (Contract Capacity x A) |
|
|
|
(Contract Capacity x 0.90) |
Where A = |
∑ Hourly Availability for all hours in such month |
∑ Hours in such month |
For purposes of calculating A, Excused Outages (for which Owner is paid full Transmission Service Payments pursuant to the terms of the Agreement) will be regarded as hours in which one hundred percent (100%) of Contract Capacity was provided.
Refund Calculation
This example is intended to illustrate the methodology for the calculation of a subsequent refund of a late payment. This example and the numbers used in this example are purely illustrative and are in no way intended to supersede any part of the Agreement, including Section 13.3 .
Assumptions
|
• |
Interest Rate = 12 percent per annum (compounded monthly) |
June 2043 Billing
Invoice Amount |
$1,000 |
Date of Invoice |
June 1, 2043 |
Due Date |
June 15, 2043 |
Payment Date |
July 1, 2043 |
The total amount due on the date of payment is $1,005, which amount is computed by adding $1,000 (the original amount invoiced) and $5 (the ½ month late interest fee).
Subsequent Refund
If later, on July 1, 2044, the aforesaid payment is required to be refunded, the refund will equal the $1,000 payment made on July 1, 2043 (the original amount invoiced), plus the interest accrued on that $1,000 payment from the due date of June 15, 2043 to the date of refund on July 1, 2044. To ensure that the refund does not double recover interest, the following language has been included in Section 13.3 of the Agreement: “[I]f all or a portion of the amount [ here, the $1,000 payment due on June 15, 2043 ] to which such interest relates [ here, the $5 late interest fee ] is later refunded pursuant to this Agreement [ here, on July 1, 2044 ], then, in calculating that refund, such interest [ here, $5 ] shall not be included in the refund.”
Attachment I
Real Estate Rights
Form of Purchaser Guaranty
See attached.
CONVENTION DE CAUTIONNEMENT La présente convention de cautionnement (« Cautionnement »), portant la date du juin 2018, est conclue entre Hydro-Québec , société dûment constituée et régie par la Loi sur Hydro-Québec (L.R.Q., chapitre H-5) ayant son siège social et son principal lieu d’affaires au 75, boulevard René-Lévesque Ouest, Montréal, Québec, Canada, H2Z 1A4 (ci-après appelée « Caution »), et Central Maine Power Company, société dûment constituée en vertu des lois de l’État du Maine, ayant son principal lieu d'affaires au 83 Edison Drive, Augusta ME 04336, États-Unis d'Amérique (ci-après appelée « Bénéficiaire »). |
|
GUARANTY AGREEMENT This Guaranty Agreement («Guaranty»), dated as of June 2018, is made and entered into between Hydro-Québec , a body politic and corporate, duly incorporated and regulated by Hydro-Québec Act (R.S.Q., chapter H-5) and having its head office and principal place of business at 75, René-Lévesque Boulevard West, Montréal, Québec, Canada, H2Z 1A4, hereinafter referred to as the «Guarantor» and Central Maine Power Company, a corporation duly organized under the laws of the State of Maine, having its principal place of business at 83 Edison Drive, Augusta ME 04336, United States of America, (hereinafter referred to as the «Beneficiary»). |
ATTENDU QUE le Bénéficiaire et H.Q. ENERGY SERVICES (U.S.) INC. , société créée en vertu des lois de l’état du Delaware, ayant son lieu d’affaires au 225 Asylum Street, 27 th étage, Hartford, CT 06103 (ci-après appelée « HQUS »), filiale en propriété indirecte de la Caution, ont signé les ententes suivantes: (a) une entente de service de transport pour l’achat de 579.335 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (b) une entente de service de transport pour l’achat de 498.348 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (c) une entente de service de transport pour l’achat de 12.317 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (d) une entente de service de transport pour l’achat de 110 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018 (ci-après appelées collectivement les « Conventions »); |
|
WHEREAS the Beneficiary and H.Q. ENERGY SERVICES (U.S.) INC., a corporation created under the laws of the State of Delaware, having its place of business at 225 Asylum Street, 27 th Floor, Hartford, CT 06103, (hereinafter referred to as «HQUS»), an indirectly owned subsidiary of the Guarantor, have executed the following agreements: (a) a Transmission Service Agreement for the purchase of 579.335 MW of firm transmission service from the Beneficiary dated as of June 13, 2018; (b) a Transmission Service Agreement for the purchase of 498.348 MW of firm transmission service from the Beneficiary dated as of June 13, 2018; (c) a Transmission Service Agreement for the purchase of 12.317 MW of firm transmission service from the Beneficiary dated as of June 13, 2018, and (d) a Transmission Service Agreement for the purchase of 110 MW of firm transmission service from the Beneficiary dated as of June 13, 2018 (hereinafter collectively referred to as the «Agreements»); |
ATTENDU QUE la Caution bénéficiera directement ou indirectement des Conventions ; |
|
WHEREAS the Guarantor will directly or indirectly benefit from the Agreements; |
|
|
|
|
|
S’ils sont destinés à la Caution : HYDRO-QUÉBEC À l’attention du vice‑président Financement, trésorerie et caisse de retraite 75, boulevard René-Lévesque Ouest 5 e étage Montréal (Québec) Canada H2Z 1A4 Télécopieur : 514 289-5409 |
S’ils sont destinés au Bénéficiaire :
Douglas Herling President & CEO Central Maine Power Company 83 Edison Drive Augusta, Maine 04336 Télécopieur : 207-626-9779 |
|
If to the Guarantor : HYDRO-QUÉBEC Attention : Vice-President Financing, Treasury and Pension Fund 75, René-Lévesque Boulevard West 5 th floor Montréal (Québec) Canada H2Z 1A4 Facsimile: 514 289-5409 |
If to the Beneficiary :
Douglas Herling President & CEO Central Maine Power Company 83 Edison Drive Augusta, Maine 04336 fax 207-626-9779 |
ou à l’adresse dont la Caution ou le Bénéficiaire peut notifier l’autre partie de temps à autre. |
|
or such address as the Guarantor or the Beneficiary may give notice to the other party, from time to time. |
Article 12. Ayants droit; lois applicables. Le présent Cautionnement lie la Caution, ses ayants droit et ses cessionnaires, et est régie par et doit être interprétée conformément aux lois de l'État de New York. |
|
Section 12. Successors; Governing Law . This Guarantee shall be binding upon the Guarantor, its successors and assignees, and shall be governed by and construed in accordance with the laws of the State of New York. |
Article 13. Convention intégrale . Le présent Cautionnement constitue la convention intégrale intervenue entre la Caution et le Bénéficiaire quant à son objet et remplace toutes les conventions et ententes antérieures, écrites ou verbales, entre la Caution et le Bénéficiaire quant à l’objet des présentes. |
|
Section 13. Entire agreement . This Guaranty constitutes the entire agreement of the Guarantor and the Beneficiary pertaining to the subject matter hereof and supersedes all prior written or oral agreements and understandings between the Guarantor and the Beneficiary with respect to the subject matter hereof. |
Article 14. Modifications . Aucune modification apportée aux dispositions du présent Cautionnement ne lie les parties à moins d’avoir été faite par écrit et signée par chaque partie. Article 15. Cautionnement unique . Nonobstant l’existence de plusieurs copies originales du présent Cautionnement, le présent Cautionnement constitue un acte unique en faveur du Bénéficiaire et le Bénéficiaire ne peut tirer un montant qui excède globalement la limite établie à l’article 1 des présentes. |
|
Section 14. Amendments . No amendments or modifications of or to any provision of this Guaranty shall be binding until in writing and executed by the Guarantor and the Beneficiary. Section 15. Single Guaranty . Notwithstanding the existence of original copies of this Guaranty, this Guaranty constitutes a single instrument in favor of the Beneficiary and cannot be drawn upon in the aggregate by the Beneficiary in excess of the limitation set forth in Section 1. |
EN FOI DE QUOI , la Caution partie aux présentes a signé le présent cautionnement à la date mentionnée ci-dessus. |
|
IN WITNESS WHEREOF , the Guarantor hereto has executed this Guaranty, as of the date set forth above. |
Exhibit 10.6
TRANSMISSION SERVICE AGREEMENT (Unitil - 12.317 MW)
by and between
CENTRAL MAINE POWER COMPANY,
as Owner,
and
H.Q. ENERGY SERVICES (U.S.) INC.,
as Purchaser
Dated: as of June 13, 2018
TABLE OF CONTENTS |
|
|
|
|
Page |
|
|
|
Article I DEFINITIONS AND RULES OF INTERPRETATION |
2 |
|
|
|
|
Section 1.1 |
Definitions |
2 |
Section 1.2 |
Interpretation |
16 |
|
|
|
Article II REGULATORY FILINGS AND REQUIRED APPROVALS |
18 |
|
|
|
|
Section 2.1 |
MDPU Filing; FERC Filings |
18 |
Section 2.2 |
Modifications to FERC Order |
18 |
Section 2.3 |
Modifications Pursuant to Unfavorable MDPU Order or FERC Order |
19 |
Section 2.4 |
Cooperation |
20 |
Section 2.5 |
No Inconsistent Action |
20 |
|
|
|
Article III EFFECTIVE DATE; TERM |
21 |
|
|
|
|
Section 3.1 |
Effective Date |
21 |
Section 3.2 |
Term |
21 |
Section 3.3 |
Termination Rights |
21 |
Section 3.4 |
Termination Payments |
24 |
Section 3.5 |
Effect of Termination |
24 |
|
|
|
Article IV COMMERCIAL OPERATION |
24 |
|
|
|
|
Section 4.1 |
Critical Milestones |
24 |
Section 4.2 |
Commercial Operation Date |
27 |
Section 4.3 |
Conditions Precedent to Commercial Operation |
28 |
Section 4.4 |
Delay in Commercial Operation; Reduced Level of Operation |
29 |
|
|
|
Article V GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES |
33 |
|
|
|
|
Section 5.1 |
Responsibilities of the Parties |
33 |
Section 5.2 |
Schedules and Reports |
34 |
Section 5.3 |
Québec Line Reports; Joint Development Agreement |
35 |
Section 5.4 |
Insurance and Events of Loss |
35 |
Section 5.5 |
Compliance with Laws |
36 |
Section 5.6 |
Third Party Contracts |
36 |
Section 5.7 |
Purchaser’s Losses. |
36 |
Section 5.8 |
Continuity of Rights and Responsibilities |
36 |
Section 5.9 |
Right of First Offer to Purchase NECEC Transmission Line |
36 |
Section 5.10 |
Amendment to the PPA |
37 |
Section 5.11 |
Amendment to the Distribution Company TSA |
37 |
|
|
i
ii
45 |
||
|
|
|
Section 13.1 |
Invoices |
45 |
Section 13.2 |
Procedures for Billing Disputes |
46 |
Section 13.3 |
Interest |
46 |
Section 13.4 |
Obligation to Make Payments |
46 |
Section 13.5 |
Offsets |
46 |
|
|
|
Article XIV EVENTS OF DEFAULT AND REMEDIES |
47 |
|
|
|
|
Section 14.1 |
Purchaser Defaults |
47 |
Section 14.2 |
[Intentionally Omitted] |
47 |
Section 14.3 |
Owner Defaults |
48 |
Section 14.4 |
Remedies Upon Purchaser Default |
49 |
Section 14.5 |
[Intentionally Omitted] |
50 |
Section 14.6 |
Remedies Upon Owner Default |
51 |
Section 14.7 |
Purchaser Step-in Rights |
52 |
Section 14.8 |
Early Termination of Distribution Company TSA |
55 |
Section 14.9 |
Disputes |
55 |
Section 14.10 |
Limitations on Total Liability |
55 |
Section 14.11 |
Modified Terms Applicable During Forbearance Period. |
56 |
|
|
|
Article XV FORCE MAJEURE |
57 |
|
|
|
|
Section 15.1 |
Definition; Conditions |
57 |
|
|
|
Article XVI FINANCIAL ASSURANCES |
58 |
|
|
|
|
Section 16.1 |
[Purchaser’s Guaranty |
58 |
Section 16.2 |
[Intentionally Omitted] |
58 |
Section 16.3 |
Credit Downgrade Event |
59 |
Article XVII DISPUTE RESOLUTION |
59 |
|
Section 17.1 |
Consultation |
59 |
Section 17.2 |
Disputes to be Resolved by FERC |
60 |
Section 17.3 |
Consent to Jurisdiction |
60 |
Section 17.4 |
WAIVER OF JURY TRIAL |
60 |
|
|
|
Article XVIII LIMITATION OF REMEDIES |
61 |
|
|
|
|
Article XIX MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES. |
62 |
|
|
|
|
Section 19.1 |
Modifications |
62 |
Section 19.2 |
Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment |
62 |
|
|
iii
64 |
||
|
|
|
Section 20.1 |
Purchaser Indemnity |
64 |
Section 20.2 |
Owner Indemnity |
64 |
Section 20.3 |
[Intentionally Omitted] |
65 |
Section 20.4 |
Procedures |
65 |
Section 20.5 |
Defenses |
65 |
Section 20.6 |
Cooperation |
66 |
Section 20.7 |
Recovery |
66 |
Section 20.8 |
Subrogation |
66 |
|
|
|
Article XXI REPRESENTATIONS, WARRANTIES AND COVENANTS |
66 |
|
|
|
|
Section 21.1 |
Mutual Representations and Warranties |
66 |
Section 21.2 |
Additional Representations and Warranties of Purchaser |
67 |
Section 21.3 |
Additional Representations and Warranties of Owner |
68 |
Section 21.4 |
[Intentionally Omitted] |
69 |
Section 21.5 |
NO OTHER REPRESENTATIONS OR WARRANTIES |
69 |
|
|
|
Article XXII TRANSFER OF INTERESTS |
70 |
|
|
|
|
Section 22.1 |
No Transfer of Interests |
70 |
Section 22.2 |
Exceptions |
71 |
Section 22.3 |
Collateral Assignment |
72 |
|
|
|
Article XXIII MISCELLANEOUS |
72 |
|
|
|
|
Section 23.1 |
Governing Law |
72 |
Section 23.2 |
Entire Agreement |
72 |
Section 23.3 |
Severability |
72 |
Section 23.4 |
Notices |
72 |
Section 23.5 |
Waiver; Cumulative Remedies |
73 |
Section 23.6 |
Confidential Information |
74 |
Section 23.7 |
No Third-Party Rights |
74 |
Section 23.8 |
Permitted Successors and Assigns |
75 |
Section 23.9 |
Relationship of the Parties |
75 |
Section 23.10 |
Construction |
75 |
Section 23.11 |
Counterparts |
75 |
Section 23.12 |
Survival |
75 |
Section 23.13 |
Language |
75 |
Section 23.14 |
Headings and Table of Contents |
75 |
Section 23.15 |
Waiver of Immunities |
75 |
iv
Attachment A |
Description of Transmission Projects |
Attachment B |
Critical Milestones |
Attachment C |
Owner Approvals |
Attachment D |
Canadian Approvals |
Attachment E |
Owner’s Preliminary Project Schedule and Construction Schedule |
Attachment F |
Required Insurance |
Attachment G |
Rate Adjustment Formula |
Attachment H |
Refund Calculation |
Attachment I |
Real Estate Rights |
Attachment J |
Form of Purchaser Guaranty |
v
TRANSMISSION SERVICE AGREEMENT
This TRANSMISSION SERVICE AGREEMENT (this “ Agreement ”), dated as of June 13, 2018 (the “ Execution Date ”), is made and entered into by and between Central Maine Power Company, a corporation organized and existing under the laws of the State of Maine (“ Owner ”), and H.Q. Energy Services (U.S.) Inc. , a corporation organized and existing under the laws of the State of Delaware (“ HQ-US ” or “ Purchaser ”). Owner and Purchaser are hereinafter sometimes also referred to individually as a “ Party ” or collectively as the “ Parties.”
WITNESSETH
WHEREAS, Purchaser is an indirect, wholly-owned subsidiary of Hydro-Québec (as defined below);
WHEREAS, pursuant to “An Act to Promote Energy Diversity” that was signed into law in the Commonwealth of Massachusetts on August 8, 2016 (the “ Energy Diversity Act ”), Fitchburg Gas and Electric Light Company (d/b/a Unitil), Massachusetts Electric Company and Nantucket Electric Company (d/b/a National Grid), and NSTAR Electric Company (d/b/a Eversource Energy) (collectively, the “ RFP Sponsors ”) have solicited competitive proposals for clean energy generation for an annual amount of electricity equal to approximately 9.45 TWh;
WHEREAS, Owner and an Affiliate of HQ-US jointly submitted a proposal pursuant to such solicitation that includes up to 1,090 MW of clean energy generation obtained by HQ-US from its affiliate Hydro-Québec Production (a division of Hydro-Québec (as defined below), “ HQP ” and such generation, the “ Hydro Generation ”);
WHEREAS, concurrently with the execution and delivery of this Agreement, HQ-US has entered into a power purchase agreement (the “ PPA ”) with Unitil (“ Distribution Company ”) and additional power purchase agreements (the “ Additional PPAs ”) with the other RFP Sponsors with respect to an aggregate of 1,090 MW of Hydro Generation (and related renewable energy credits and environmental attributes);
WHEREAS, as part of the delivery of 1,090 MW of Hydro Generation for sale into the U.S. pursuant to the PPA and the Additional PPAs, Hydro-Québec TransÉnergie (“ TransÉnergie ”), a division of Hydro-Québec, intends to develop, construct, own and maintain a 1,200 MW +/-320 kV high-voltage direct current (“ HVDC ”) transmission line from the converter station at the Appalaches substation in Thetford Mines, Québec to the U.S. Border (as defined below) at Beattie Township, Maine (as further delineated in the diagram or described in Attachment A , the “ Québec Line ”);
WHEREAS, HQP has acquired from TransÉnergie firm transmission service over the Québec Line to permit the delivery of at least 1,200 MW of power into the U.S.;
WHEREAS, Owner intends to develop, construct, own and maintain a 1,200 MW +/-320 kV HVDC transmission line extending from the U.S. Border at Beattie Township, Maine to a new direct current to alternating current (“ AC ”) converter station to be located at Merrill Road in the City of Lewiston in the State of Maine (the transmission line and converter station, as more fully described in Attachment A , the “ HVDC Line ”);
1
WHEREAS, in order to interconnect the HVDC Line with the bulk power systems in New England, Owner intends to develop, construct, own and maintain additional 345 kV AC transmission lines, rebuilt 115 kV AC transmission lines and other substation equipment more fully described in Attachment A (together with the Merrill Road substation at its northern terminus and the associated equipment, as more fully described in Attachment A , the “ AC Line ” and, together with the HVDC Line, the “ NECEC Transmission Line ” );
WHEREAS, although Owner has performed studies believed to replicate those utilized by ISO-NE and does not believe that AC Upgrades (as defined below) or CCIS Capacity Upgrades (as defined below) will be required as a consequence of the construction and operation of the NECEC Transmission Line and the consummation of the transactions contemplated by this Agreement, this Agreement, the Distribution Company TSA (as defined below), the Additional RFP Sponsor TSAs (as defined below), the Purchaser TSAs, the 110 MW TSA, the PPA or the Additional PPAs, ISO-NE (as defined below) may require certain AC Upgrades or CCIS Capacity Upgrades to be developed, constructed, owned and maintained by certain transmission owners other than Owner (which may include Affiliates of Owner) within their existing service territories in New England in order to interconnect the NECEC Transmission Line with the New England Transmission System (as defined below) in a safe and reliable manner, which AC Upgrades or CCIS Capacity Upgrades (if any) will be performed at Owner’s sole expense;
WHEREAS, concurrently with the execution and delivery of this Agreement, Owner has entered into a transmission service agreement (the “ Distribution Company TSA ”) with Distribution Company to sell 12.317 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date (as defined below) and additional transmission service agreements (the “ Additional RFP Sponsor TSAs ”) with the other RFP Sponsors to sell an aggregate of 1,077.683 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date; and
WHEREAS, Owner desires to sell Firm Transmission Service (as defined below) to Purchaser for years twenty-one (21) through forty (40) following the Commercial Operation Date, and Purchaser desires to acquire such Firm Transmission Service from Owner, at the rates and on the terms and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the foregoing and the respective representations, warranties, covenants, agreements and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound hereby, the Parties hereby agree as follows:
Article I
DEFINITIONS AND RULES OF INTERPRETATION
Section 1.1 Definitions . As used herein, the following terms shall have the following respective meanings:
“ 110 MW TSA ” means that certain Transmission Service Agreement between Purchaser and Owner, dated as of the date hereof, pursuant to which Purchaser has acquired transmission service for up to 110 MW of capacity for forty (40) years following the Commercial Operation Date.
2
“ 110 MW TSA Capacity ” means the firm capacity of the NECEC Transmission Line of up to 110 MW that Purchaser has committed in the 110 MW TSA to purchase in the forty (40) years following the Commercial Operation Date.
“ 110 MW TSA FERC Order ” means an order accepting or approving the 110 MW TSA for filing.
“ AC ” has the meaning provided in the recitals to this Agreement.
“AC Line” has the meaning provided in the recitals to this Agreement.
“ AC Upgrade Approvals ” means, collectively, any Governmental Approvals or Third Party Consents, in each case, that are required to commence construction of the AC Upgrades.
“ AC Upgrade Owners ” means, collectively, any Person responsible for constructing one or more AC Upgrades pursuant to a facilities agreement.
“ AC Upgrades ” means any additions, upgrades, reinforcements or other modifications to the New England Transmission System that ISO-NE determines, pursuant to Section I.3.9 of the ISO-NE Tariff, to be required, at a minimum, to interconnect the NECEC Transmission Line at the Delivery Point with the New England Transmission System.
“ Acquisition Notice ” has the meaning provided in Section 14.7(b) .
“ Additional Bids ” has the meaning provided in Article XVIII.
“ Additional Credit Support ” means one or more of the following, issued in favor of or otherwise held by or for the benefit of Owner or Purchaser, as applicable:
(a) a guaranty, in form and substance reasonably satisfactory to Purchaser or Owner (as applicable), issued by an Affiliate of Owner or Purchaser (as applicable) that meets the Credit Rating Requirements;
(b) a Letter of Credit, in form and substance reasonably satisfactory to Purchaser or Owner (as applicable); or
(c) Cash.
“ Additional RFP Sponsor TSAs ” has the meaning provided in the recitals to this Agreement.
“ Additional RFP Sponsor TSA FERC Order ” means an order accepting or approving one or more Additional RFP Sponsor TSAs for filing.
“ Additional PPAs ” has the meaning provided in the recitals to this Agreement.
“ Adverse Determination ” has the meaning provided in Section 19.2(c) .
3
“ Affiliate ” means, with respect to a specified Person, any other Person that directly or indirectly Controls, is Controlled by or is under common Control with the specified Person; provided , however , that, with respect to Purchaser, a Person shall not be an “Affiliate” of Purchaser unless such Person is Hydro-Québec (including, for the avoidance of doubt, a division of Hydro-Québec) or Controlled by Hydro-Québec.
“ Agreement ” has the meaning provided in the preamble to this Agreement.
“ Applicable Law ” means any duly promulgated federal, national, state, provincial or local law, regulation, rule, ordinance, code, decree, judgment, directive or judicial or administrative order, permit or other duly authorized and valid action of any Governmental Authority, including any binding interpretation of any of the foregoing by any Governmental Authority, which is applicable to a Person, its property or a transaction, and also including Section 83D, the regulations promulgated under Section 83D, the Regulatory Approval and any other orders of the MDPU with respect to this Agreement.
“ Approval Deadline ” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Available Transfer Capability ” means the lesser of (a) 1,090 MW or (b) the Total Transfer Capability.
“ Bankruptcy Code ” means the United States Bankruptcy Code, 11 U.S.C. § 101 et seq.
“ Business Day ” means any day except Saturday, Sunday or any other day on which the Federal Reserve member banks are required or authorized to close for business.
“Canadian Approval Deadline” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Canadian Approvals ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the Québec Line in a manner consistent with Attachment A , all as set forth in Attachment D .
“ Cash ” means U.S. dollars held by or on behalf of a Party as Credit Support hereunder.
“ CCIS Capacity Upgrade ” means any upgrade determined by ISO-NE as necessary in order for the NECEC Transmission Line Capacity to satisfy the Capacity Capability Interconnection Standard under and as defined in the ISO-NE Tariff.
“ COD Notice ” has the meaning provided in Section 4.2(c) .
“ Commercial Operation ” means the availability of the NECEC Transmission Line for the provision of Firm Transmission Service in accordance with this Agreement and the Distribution Company TSA.
“ Commercial Operation Date ” has the meaning provided in Section 4.2(c) .
4
“ Commissioning ” means (a) with respect to the NECEC Transmission Line, the start-up and testing activities required to demonstrate that the NECEC Transmission Line is ready for Commercial Operation and (b) with respect to the Québec Line, the start-up and testing activities required to demonstrate that the Québec Line is ready for commercial operation, consistent with Section 4.3(f) .
“ Concurrent Delay ” has the meaning provided in Section 4.4.3 .
“ Confidential Information ” means (a) this Agreement, (b) any documents, analyses, compilations, studies, or other materials prepared by or information received from a Party or its representatives that contain or reflect written or oral data or information that is privileged, confidential or proprietary and that is marked or otherwise clearly identified as “confidential” or “proprietary” or with words of like meaning, or (c) any subsequently prepared documents, analyses, compilations, studies or other materials or information that are derived from any of the documents, analyses, compilations, studies or other materials or information described in the foregoing clause (b). Without limiting the generality of the foregoing, all information provided to Purchaser or Owner under Sections 2.4 , 5.2 and 6.3 hereof shall be deemed to be Confidential Information, whether or not such information is marked as “confidential” or “proprietary.”
“ Consent ” means, with respect to a Person, any approval, consent, permit, license, decree, certificate or other authorization of or from such Person.
“ Construction Authorizations ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the NECEC Transmission Line, other than the ISO-NE Approval, including the approvals of the Maine Department of Environmental Protection, the U.S. Army Corp of Engineers, the Maine Public Utilities Commission and the U.S. Department of Energy (the Presidential Permit), as more fully set forth in Attachment C .
“ Construction Contract ” means any contract entered into by Owner that provides for the engineering, procurement or construction of the NECEC Transmission Line.
“ Construction Phase ” means the period commencing upon the receipt of the FERC Authorization or such other date to which the Parties shall mutually agree in writing, and ending on the day immediately preceding the Commercial Operation Date or upon the earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Contract Capacity ” means the Proportionate Share multiplied by the NECEC Transmission Line Capacity.
“ Contract Year ” means each twelve-month period during the Term, with the first Contract Year commencing on the Commercial Operation Date and with each Contract Year after the first commencing on the anniversary of the Commercial Operation Date.
“ Control ” (including its correlative meanings “Controlled by” and “under common Control with”) means, with respect to a Person, the possession, directly or indirectly, of the power to direct or cause the direction of the management or policies of the specified Person, whether through ownership of voting securities or partnership or other ownership interests, by contract or Applicable Law or otherwise.
5
“ Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , Section 4.1(d) or Section 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Credit Rating Requirements ” means a long-term credit rating of at least “BBB-” by S&P or “Baa3” by Moody’s.
“ Credit Support ” means collateral in the form of (a) Cash or (b) a Letter of Credit issued by a Qualified Bank in a form reasonably satisfactory to the beneficiary.
“ Critical Energy Infrastructure Information ” means any information defined as Critical Energy Infrastructure Information by FERC pursuant to 18 C.F.R. § 388.113, and shall include all Critical Infrastructure Protection (CIP) standards (CIP-002 through CIP-009) established by NERC.
“ Critical Milestone ” has the meaning provided in Section 4.1(a) .
“ Delivery Point ” means the southern terminus of the NECEC Transmission Line at the Larrabee Road substation in Lewiston, Maine, as illustrated in Attachment A .
“ Design Capability ” means the maximum amount of electric power that the materials, equipment and structures comprising the HVDC Transmission Project will be designed to transfer bi-directionally in a safe and reliable manner, which amount shall be sufficient to permit the north-to-south delivery of all amounts scheduled for delivery in an aggregate amount of at least 1,090 MW, but not to exceed 1,200 MW, of electrical energy at the Delivery Point.
“ Discount Rate ” means the prime rate specified in the “Money and Investing” section of the Wall Street Journal, determined as of the date of the notice of default, plus 300 basis points.
“ Dispute ” means any dispute, controversy or claim of any kind whatsoever arising out of or relating to a Proposal Agreement, including relating to the interpretation of the terms thereof or any Applicable Law that affects such Proposal Agreement, or the transactions contemplated thereunder, or the breach, termination or validity thereof.
“ Distribution Company ” has the meaning provided in the recitals to this Agreement.
“ Distribution Company TSA ” has the meaning provided in the recitals to this Agreement.
“ Distribution Company TSA Amendment ” has the meaning provided in Section 2.3 .
“ Distribution Company TSA Critical Milestones ” means the “Critical Milestones” as defined in the Distribution Company TSA.
“ Distribution Company TSA FERC Order ” has the meaning provided in Section 2.3 .
“ Effective Date ” has the meaning provided in Section 3.1 .
“ Energy Diversity Act ” has the meaning provided in the recitals to this Agreement.
6
“ Excused Outages ” has the meaning provided in Section 7.2(a) .
“ Execution Date ” has the meaning provided in the preamble to this Agreement.
“ Federal Power Act ” means the United States Federal Power Act of 1935, as amended, 16 U.S.C. § 791a et seq.
“ FERC ” means the Federal Energy Regulatory Commission, or any successor regulatory agency that administers the Federal Power Act.
“ FERC Amendment ” has the meaning provided in Section 2.2(b) .
“ FERC Authorization ” means, collectively, any FERC order that is not subject to rehearing or appeal authorizing Owner to provide Firm Transmission Service, including the FERC Order, the Distribution Company TSA FERC Order, any Additional RFP Sponsor TSA FERC Order, any Purchaser TSA FERC Order and the 110 MW TSA FERC Order , and any authorization from FERC with respect to the Transmission Operating Agreement or Interconnection Agreements.
“ FERC Order ” has the meaning provided in Section 2.2(a) .
“ Financial Transmission Rights ” means Financial Transmission Rights, as defined in the ISO-NE Tariff.
“ Financing Deadline ” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Firm Transmission Service ” has the meaning provided in Section 7.1.1 .
“ Fixed Credit Support ” has the meaning provided in the PPA.
“ Force Majeure ” has the meaning provided in Section 15.1(a) .
“ Good Utility Practice ” means those design, construction, operation, maintenance, repair, removal and disposal practices, methods and acts that are engaged in by a significant portion of the electric transmission industry in the United States during the relevant time period, or any other practices, methods or acts that, in the exercise of reasonable judgment in light of the facts known at the time a decision is made, could have been expected to accomplish a desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Good Utility Practice is not intended to be the optimum practice, method or act to the exclusion of others but rather to be a spectrum of acceptable practices, methods or acts generally accepted in such electric transmission industry for the design, construction, operation, maintenance, repair, removal and disposal of electric transmission facilities in the United States. Good Utility Practice shall not be determined after the fact in light of the results achieved by the practices, methods, or acts undertaken, but rather shall be determined based upon the consistency of (a) the practices, methods, or acts when undertaken with (b) the standard set forth in the first two (2) sentences of this definition at such time.
7
“ Governmental Approval ” means (a) any authorization, consent, approval, license, lease, ruling, permit, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with or (d) any registration by or with, any Governmental Authority, including any FERC Authorization.
“ Governmental Authority ” means any government or agency or other political subdivision thereof, including any province, state or municipality, or any other governmental, quasi-governmental, judicial, executive, legislative, administrative, regulatory, public or statutory instrumentality, authority, body, agency, commission, department, board, bureau or entity exercising judicial, executive, legislative, administrative or regulatory functions, any court or arbitrator with authority to bind a party at law, and shall include, to the extent exercising powers delegated by any Governmental Authority acting under Applicable Law, NERC and ISO-NE.
“ Hourly Availability ” means, with respect to any hour, the availability of the NECEC Transmission Line for the purposes of this Agreement, which shall equal (a) the Proportionate Share of the Available Transfer Capability for such hour, divided by (b) the Contract Capacity, expressed as a percentage; provided , however , that, for any hour, such availability of the NECEC Transmission Line shall not exceed one hundred percent (100%).
“ HQ-US ” has the meaning provided in the preamble to this Agreement.
“ HQE ” means Hydro-Québec Équipment, a division of Hydro-Québec .
“ HQP ” has the meaning provided in the recitals to this Agreement.
“ HVDC ” has the meaning provided in the recitals to this Agreement.
“ HVDC Line ” has the meaning provided in the recitals to this Agreement.
“ HVDC Transmission Project ” means, collectively, (a) the Québec Line and (b) the NECEC Transmission Line.
“ Hydro Generation ” has the meaning provided in the recitals to this Agreement.
“ Hydro-Québec ” means Hydro-Québec, a body politic and corporate, duly incorporated and regulated by the Hydro-Québec Act (R.S.Q., Chapter H-5). As of the Execution Date, Hydro-Québec has four divisions: HQP, TransÉnergie, Hydro-Québec Distribution and HQE.
“ Hydro-Quebec Guaranty ” has the meaning provided in Section 16.1 .
“ Immunities Act ” means the United States Foreign Sovereign Immunities Act of 1976, 28 U.S.C. § 1602 et seq.
“ Indemnification Notice ” has the meaning provided in Section 20.4 .
“ Indemnified Party ” has the meaning provided in Section 20.4 .
“ Indemnifying Party ” has the meaning provided in Section 20.4 .
8
“ Insolvency Event ” means, with respect to a Person, such Person (a) becomes “insolvent,” as defined in the Bankruptcy Code, or otherwise becomes bankrupt or insolvent under any Insolvency Laws, (b) has a liquidator, administrator, receiver, custodian, trustee, conservator or similar official appointed with respect to such Person or any material portion of such Person’s assets or such Person consents to such appointment, or a foreclosure action is instituted with respect to any material portion of such Person’s assets and is not dismissed within thirty (30) days of commencement thereof, (c) files a voluntary petition or otherwise authorizes or commences a proceeding or cause of action under the Bankruptcy Code or Insolvency Laws, (d) has an involuntary petition filed against it or acquiesces in the commencement of a proceeding or cause of action as the subject debtor under the Bankruptcy Code or Insolvency Laws, which petition is not dismissed within thirty (30) days after the filing thereof or results in the issuance of an order for relief against such Person, (e) makes or consents to an assignment of its assets in whole or in part, for the benefit of creditors or any general arrangement for the benefit of creditors, or a common law composition of creditors or (f) generally is unable to pay its debts as they fall due, or admits in writing to such inability.
“ Insolvency Laws ” means any bankruptcy, insolvency, reorganization or similar laws of the U.S., Canada, or other Governmental Authority, as applicable, other than the Bankruptcy Code.
“ Interconnection Agreements ” means, collectively, (a) an agreement by and among Owner, TransÉnergie and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the U.S. Border of the NECEC Transmission Line with the Québec Line and (b) an agreement by and between Owner and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the Delivery Point of the NECEC Transmission Line with certain transmission facilities operated by ISO-NE. The Interconnection Agreements shall address cost responsibilities among entities other than the Distribution Company and the other RFP Sponsors and shall include provisions, both technical and otherwise, for safe and reliable interconnected operations of the HVDC Transmission Project following Commercial Operation (including use of the HVDC Transmission Project for the delivery of electric power in emergency circumstances).
“ Interested Party ” means, collectively, the Parties and, if and as applicable, the RFP Sponsors.
“ Invoice ” means, with respect to a calendar month, an invoice that sets forth the amounts owed to the applicable Party with respect to such month in reasonable detail to evidence the basis for individual billings and charges.
“ ISO-NE ” means ISO New England Inc., or its successor organization.
“ ISO-NE Approval ” means approval by ISO-NE to operate the NECEC Transmission Line up to 1,200 MW.
“ ISO-NE Definitions Manual ” means the ISO New England Manual for Definitions and Abbreviations, Manual M-35, as in effect from time to time.
9
“ ISO-NE Rules ” means the ISO-NE Tariff and all ISO-NE manuals, rules, procedures, agreements or other documents relating to the reliable operation of the electric system in New England and the purchase and sale of electrical energy, electrical capacity and ancillary services, as such govern market participants with respect thereto in the operating jurisdiction of ISO-NE, as in effect from time to time, including the ISO-NE Definitions Manual; provided that such documents are publicly accessible.
“ ISO-NE Tariff ” means the ISO New England Inc. Transmission, Markets and Services Tariff, FERC Electric Tariff No. 3, as in effect from time to time, on file with FERC, or its successor tariff.
“Joint Development Agreement” has the meaning provided in Section 5.3 .
“ kV ” means kilovolt.
“ K W ” means kilowatt.
“ Letter of Credit ” means an irrevocable, non-transferable standby letter of credit issued by a Qualified Bank utilizing a form acceptable to the Party in whose favor such letter of credit is issued. All costs relating to any Letter of Credit shall be for the account of the Party providing that Letter of Credit.
“ Maintenance Plan ” means an annual plan for the management, operation and ordinary maintenance of the NECEC Transmission Line, which plan shall include a description of the scope and nature of the planned operating and maintenance programs and planned and preventive maintenance procedures for the NECEC Transmission Line, and the scheduled maintenance and other planned outages of the NECEC Transmission Line, in each case, in accordance with Section 6.3 hereof and the requirements of the PPA.
“ Market Products ” means, collectively, all products (however entitled and whether existing now or in the future) that (a) are recognized under ISO-NE Rules, (b) derive from the acquisition of transmission service over the NECEC Transmission Line under this Agreement and (c) can be sold for consideration or otherwise have economic value, including electrical energy, electrical capacity and ancillary services, including reserve products (including spinning and non-spinning reserves).
“ Marketing Activities ” means a specific offering by Owner of the NECEC Transmission Line (without any other material assets) for purchase by one or more third parties (other than an Affiliate of Owner).
“ Marketing Notice ” has the meaning provided in Section 5.9(a) .
“ Material Adverse Effect ” means, with respect to a Party, a material adverse effect on the ability of such Party to perform any of its obligations under this Agreement.
“ MDPU ” means the Massachusetts Department of Public Utilities.
10
“ Minimum Average Availability ” means ninety percent (90%) of the Contract Capacity, provided that, during the Remediation Period, if applicable, for every ten (10) MW that the maximum operating agreement of the NECEC Transmission Line is below 1,090 MW, the Minimum Average Availability shall be increased by one percent (1%), and provided further that, if, at the earlier of the Owner Remediation Date or the end of the Remediation Period, the NECEC Transmission Line is operating at an operating capacity below 1090 MW in any of the circumstances described in Section 4.4.1(c)(ii), the Minimum Average Availability shall be increased by one-half of one percent (0.5%) for each 5 MW by which the operating capacity of the NECEC Transmission Line is below 1,090 MW.
“ Municipal Owner Approval Deadline ” means March 31, 2022 (as the same may be extended in accordance with Section 4.1(c) or Section 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Municipal Owner Approvals ” means the Owner Approvals identified in paragraph 10 of Attachment C that are required to construct, own, and operate the NECEC Transmission Line.
“ MW ” means megawatt.
“ NECEC Facilities ” has the meaning provided in Section 8.3 .
“ NECEC Transmission Line ” has the meaning provided in the recitals to this Agreement.
“ NECEC Transmission Line Capacity ” means (a) 1,090 MW or (b) such lesser amount as may be established by the Commissioning of the NECEC Transmission Line, in each case as measured at the Delivery Point; provided that the amount under clause (b) shall be increased if the capacity is increased after the Commercial Operation Date pursuant to Section 4.4.1(c) , Section 4.4.2(b) or Section 4.4.3(b) .
“ NERC ” means the North American Electric Reliability Corporation, or its successor organization.
“ Net Book Value ” means, at any time, an amount equal to the original cost of construction minus depreciation (using a forty (40)-year depreciation schedule), as calculated in accordance with generally accepted accounting principles.
“ New England Transmission System ” means New England Transmission System, as defined in the ISO-NE Tariff.
“ Non-Excused Outage ” means any outage of the NECEC Transmission Line or reduction in the Total Transfer Capability below the NECEC Transmission Line Capacity, except due to an Excused Outage.
11
“ Non-Excused Outage Payment ” means, with respect to any month during which a Non-Excused Outage occurs, an amount equal to:
(a) the excess, in MW, if any, of (i) the Contract Capacity multiplied by the Minimum Average Availability over (ii) the Contract Capacity multiplied by the average Hourly Availability of the NECEC Transmission Line for such month, multiplied by
(b) $6, multiplied by
(c) the number of hours in such month.
“ OASIS ” means the Open Access Same-Time Information System.
“ OASIS Administrator ” has the meaning provided in Section 10.3(a) .
“ Offer Price ” has the meaning provided in Section 5.9(a) .
“ Other Transmission Rights ” means, collectively, any Financial Transmission Rights (or any similar concept), auction revenue rights or other financial or physical transmission rights, in each case, whether existing now or in the future, associated with the NECEC Transmission Line or AC Upgrades.
“ Owner ” has the meaning provided in the preamble to this Agreement.
“ Owner Approvals ” means, collectively, (a) the Construction Authorizations and (b) the ISO-NE Approval, all as set forth in Attachment C .
“ Owner Default ” has the meaning provided in Section 14.3 .
“ Owner Delay ” has the meaning provided in Section 4.4.1 .
“ Owner Indemnified Party ” has the meaning provided in Section 20.1 .
“ Owner Remediation Date ” has the meaning provided in Section 4.4.1(c)(i) .
“ Owner Security ” has the meaning provided in the Distribution Company TSA.
“ Owner Termination Payment ” means (a) if prior to the Commercial Operation Date, (i) liquidated damages in an amount equal to the Proportionate Share multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the termination date in connection with the development and construction of the Québec Line, and (ii) if the PPA has also been terminated pursuant to Section 9.2(b) thereof or, if due to a default by Owner under the Distribution Company TSA, Section 9.2(c) of the PPA, an amount equal to any Fixed Credit Support or (b) if on or after the Commercial Operation Date, an amount equal to the amounts paid by Purchaser to Distribution Company under the PPA (including any amounts drawn on any Credit Support provided by Purchaser under the PPA), arising out of or in connection with the Owner Default and termination of this Agreement. For the avoidance of doubt, the amounts described in the foregoing clause (b) shall be without duplication of any amounts paid by Owner to Distribution Company under the Distribution Company TSA in satisfaction of any liabilities to Distribution Company under the PPA. For purposes of calculating the Owner Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW.
12
“ Owner’s Construction Progress Report ” has the meaning provided in Section 5.2.3(a) .
“ Owner’s Construction Schedule ” has the meaning provided in Section 5.2.2 .
“ Owner’s Preliminary Schedule ” has the meaning provided in Section 5.2.1 .
“ Parties ” and “ Party ” have the meanings provided in the preamble to this Agreement.
“ Person ” means any legal person, including any natural person, domestic or foreign corporation, limited liability company, general or limited partnership, joint venture, association, joint stock company, business trust, estate, trust, enterprise, unincorporated organization, any Governmental Authority, or any other legal or commercial entity.
“ Physical Transmission Line Capacity ” means the sum of the NECEC Transmission Line Capacity and the 110 MW TSA Capacity.
“ Power Cost Reconciliation Tariff ” means a fully reconciling cost recovery tariff mechanism that authorizes the establishment of a distribution charge that fully recovers Distribution Company’s net costs under the Distribution Company TSA (including annual remuneration of up to two and three-quarters percent (2.75%)). The rate reconciliation shall be designed in such a way as to limit the build-up of any under or over-recoveries over the course of the year. A reconciliation shall occur at least annually, but may also be reconciled quarterly or monthly, to the extent necessary to eliminate regulatory lag for the recovery of costs or crediting of over-recoveries to customers.
“ PPA ” has the meaning provided in the recitals to this Agreement.
“ PPA Contract Maximum Amount ” means 12.317 MW, as such amount may be adjusted in accordance with the terms of the PPA.
“ Presidential Permit ” means the permit granted by the U.S. Department of Energy, pursuant to Executive Order 10485 as amended by Executive Order 12038, authorizing the construction, operation, maintenance and connection of facilities for the transmission of electric energy at the international border between the United States and Canada.
“ Project Schedule ” means a schedule setting forth the proposed engineering, procurement, construction and testing milestone schedule for (a) the NECEC Transmission Line based upon the Construction Contracts, (b) the Québec Line and (c) the AC Upgrades and the CCIS Capacity Upgrades based upon such information as can reasonably be obtained by Owner from the AC Upgrade Owners, recognizing that one or more Project Schedules will be completed and delivered before the date on which the AC Upgrades and the CCIS Capacity Upgrades are formally identified under this Agreement.
“ Proportionate Share ” means a fraction with the numerator equal to 12.317 MW and the denominator equal to 1,090 MW .
13
“ Proposal Agreements ” means, collectively, this Agreement, the 110 MW TSA, the Distribution Company TSA, the Additional RFP Sponsor TSAs, the Purchaser TSAs, the PPA and the Additional PPAs.
“ Purchased Power Accounting Authorization ” means authorization for Distribution Company, at Distribution Company’s sole discretion, to take appropriate steps to assure avoidance of a material, negative balance sheet impact on Distribution Company or Distribution Company’s direct or indirect parent company, upon appropriate filing with and approval by the MDPU.
“ Purchaser ” has the meaning provided in the preamble to this Agreement.
“ Purchaser Default ” has the meaning provided in Section 14.1 .
“ Purchaser Delay ” has the meaning provided in Section 4.4.2(a) .
“ Purchaser Guarantor ” means Hydro-Québec.
“ Purchaser Indemnified Party ” has the meaning provided in Section 20.2 .
“ Purchaser Term ” has the meaning provided in Section 8.1 .
“ Purchaser Termination Payment ” means (a) if prior to the Commercial Operation Date, an amount equal to the Proportionate Share of all costs prudently incurred by Owner as of the termination date in connection with the development and construction of the NECEC Transmission Line or (b) if on or after the Commercial Operation Date, an amount equal to the Proportionate Share multiplied by the Net Book Value of the NECEC Transmission Line minus the present value, discounted at the Discount Rate, of the Proportionate Share of revenues (if any) to be received by Owner, acting in a commercially reasonable manner, pursuant to contracts (if any) entered into by Owner during the sixty (60) day period immediately following the delivery of the termination notice, from one or more other purchasers or payors over the remainder of the Term for transmission service utilizing the NECEC Transmission Line up to an amount of generation at the Contract Capacity (net of operating costs in respect of such revenues), provided that, for purposes of calculating the Purchaser Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW.
“ Purchaser TSA ” means any transmission service agreement entered into between Purchaser and Owner (other than this Agreement), pursuant to which Purchaser acquires firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date.
“ Purchaser TSA FERC Order ” means an order issued by FERC accepting or approving one or more Purchaser TSAs for filing.
“ Qualified Bank ” means a U.S. commercial bank (or the U.S. branch of a foreign bank) having (a) assets on its most recent balance sheet of at least $10 billion and (b) a long-term credit rating of at least “A-” by S&P or “A3” by Moody’s (or its equivalent).
14
“ Québec Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Québec Line ” has the meaning provided in the recitals to this Agreement.
“ Québec Line Capacity Deficiency Payment ” means the Proportionate Share of (i) all costs prudently incurred by Owner as of the Commercial Operation Date in connection with the development and construction of the NECEC Transmission Line, multiplied by (ii) a fraction, the numerator of which is (A) the difference between the lesser of (x) the operating capacity of the NECEC Transmission Line and (y) 1,090 MW, and the operating capacity of the Québec Line, and the denominator of which is (B) the lesser of (x) the operating capacity of the NECEC Transmission Line or (y) 1,090 MW.
“ Real Power Losses ” means energy consumed by the electrical impedance characteristics of the NECEC Transmission Line.
“ Recovery ” has the meaning provided in Section 20.7 .
“ Regulatory Approval ” means the MDPU approval of the Distribution Company TSA , which approval shall include: (1) confirmation that the Distribution Company TSA has been approved under Section 83D and the regulations promulgated thereunder and that all of the terms of such Section 83D and such regulations apply to the Distribution Company TSA; (2) definitive regulatory authorization for Distribution Company to recover all of its costs incurred under and in connection with the Distribution Company TSA for the entire term of the Distribution Company TSA through the implementation of a Power Cost Reconciliation Tariff or other cost recovery or reconciliation mechanisms; (3) definitive regulatory authorization for Distribution Company to recover remuneration of up to two and three-quarters percent (2.75%) of Distribution Company’s annual payments under the Distribution Company TSA for the term of the Distribution Company TSA through the Power Cost Reconciliation Tariff; and (4) approval of any Purchased Power Accounting Authorization requested by Distribution Company in connection with the Regulatory Approval. Such approvals shall be acceptable in form and substance to Distribution Company in its sole discretion and shall not include any conditions or modifications that Distribution Company deems, in its sole discretion, to be unacceptable, and shall be final and not subject to appear or rehearing.
“ Regulatory Approval Delay ” means any delay in the receipt of the Regulatory Approval beyond January 25, 2019.
“ Regulatory Approval Termination Outside Date ” has the meaning provided in Section 3.3.1(a) .
“ RFP Sponsors ” has the meaning provided in the recitals to this Agreement.
“ Section 83D ” means Section 83D of the Energy Diversity Act.
“ Scheduling Rules ” has the meaning provided in Section 7.1.3 .
15
“ Step-In Trigger Event ” has the meaning provided in Section 14.7(f) .
“ Target Date ” has the meaning provided in Section 4.2(a) .
“ Term ” has the meaning provided in Section 3.2 .
“ Third Party Claim ” has the meaning provided in Section 20.4 .
“ Third Party Consent ” means any Consent of a Person other than a Governmental Authority.
“ Total Transfer Capability ” means the Total Transfer Capability of the NECEC Transmission Line, as defined in, and established in accordance with, the ISO-NE Tariff and determined by ISO-NE for each hour.
“ TransÉnergie ” has the meaning provided in the recitals to this Agreement.
“ TransÉnergie OATT ” means the Hydro-Québec Open Access Transmission Tariff, as amended or accepted by the Régie de l’énergie from time to time.
“ Transfer ” has the meaning provided in Section 22.1(a) .
“ Transmission Operating Agreement ” means an agreement entered into by and between Owner and ISO-NE for transmission operating services over the NECEC Transmission Line under which operating control (as defined in such agreement) of the NECEC Transmission Line is transferred from Owner to ISO-NE.
“ Transmission Operator ” means ISO-NE acting in its capacity pursuant to the Transmission Operating Agreement.
“ Transmission Percentage ” means a fraction with the numerator equal to the Contract Capacity and the denominator equal to the Physical Transmission Line Capacity.
“ Transmission Service Payment ” has the meaning provided in Section 8.1 .
“ Unfavorable FERC Decision ” has the meaning provided in Section 2.2(a) .
“ Unfavorable MDPU Order ” has the meaning provided in Section 2.3 .
“ United States ” or “ U.S. ” means the United States of America.
“ U.S. Border ” means the location on or near the international border between the State of Maine and the Province of Québec where the HVDC Line and the Québec Line interconnect.
Section 1.2 Interpretation . In this Agreement, unless the context otherwise requires, the following rules shall apply to the usage of terms:
Section 1.2.1 Singular; Plural; Gender; Corollary Meaning . The singular shall include the plural and vice versa, and any pronoun shall include the corresponding masculine, feminine and neuter forms. If a term is defined as one part of speech (such as a noun), then it shall have a corresponding meaning when used as another part of speech (such as a verb).
16
Section 1.2.2 Coordinating Conjunctions . The word “or” shall have the inclusive meaning represented by the phrase “and/or.”
Section 1.2.3 Self-Reference . The words “hereof,” “herein,” “hereto” and “hereunder” and words of similar import when used in this Agreement shall, unless otherwise expressly specified, refer to this Agreement as a whole and not to any particular provision of this Agreement.
Section 1.2.4 Inclusive References . The words “include,” “includes” and “including” when used in this Agreement shall be deemed to be followed by “without limitation” or “but not limited to,” whether or not they are in fact followed by such words or words of like import.
Section 1.2.5 Incorporation by Reference . Any reference in this Agreement to an “Article,” “Section” or other subdivision or to an “Attachment” or other schedule or attachment shall be references to an article, section or other subdivision of, or to a schedule or attachment to, this Agreement, unless otherwise stated, and all such Articles, Sections and Attachments are incorporated into this Agreement by reference (all of which comprise part of one and the same agreement with equal force and effect). In the event of any conflict or other inconsistency between the main body of this Agreement and any attachment or schedule to this Agreement, the provisions of the main body of this Agreement shall prevail.
Section 1.2.6 Subsequent Acts . Any references in this Agreement to any statute shall be deemed to refer to such statute, as amended or replaced from time to time, including by succession of comparable successor statute, and all rules and regulations promulgated thereunder. In the event any index or publication referenced in this Agreement ceases to be published or a concept defined by reference to any such index or publication ceases to exist, each such reference shall be deemed to be a reference to a successor or alternate index, publication or concept reasonably agreed to by the Parties. Unless specified otherwise, a reference to a given agreement or instrument, and all schedules and attachments thereto, shall be a reference to that agreement or instrument as modified, amended, supplemented and restated, and as in effect from time to time.
Section 1.2.7 Inclusive of Permitted Successors . Unless otherwise expressly stated, references to any Person also include its permitted successors and assigns.
Section 1.2.8 Time Computation . In this Agreement, in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each means “to but excluding.”
Section 1.2.9 Business Days . Whenever this Agreement refers to a number of days, such number shall refer to calendar days unless Business Days are specified. Whenever any action must be taken under this Agreement on or by a day that is not a Business Day, such action may be validly taken on or by the next day that is a Business Day, and in the case of payments (including refunds of payments), no interest shall accrue on the amount due; provided that such payment is made in full on the next day that is a Business Day.
17
Section 1.2.10 Governmental Approvals . Except as otherwise expressly provided in this Agreement, any Governmental Approval shall be deemed to be received upon issuance, even if such Governmental Approval is subject to appeal or rehearing.
Section 1.2.11 Currency . All references to prices, values or monetary amounts referred to in this Agreement shall be paid in United States currency, unless expressly provided otherwise.
Article II
REGULATORY FILINGS AND REQUIRED APPROVALS
Section 2.1 MDPU Filing; FERC Filings.
(a) Owner shall use commercially reasonable efforts to cause Distribution Company to: (i) file for the Regulatory Approval as soon as practicable following the execution of the Distribution Company TSA, and (ii) use commercially reasonable efforts to file within sixty (60) days thereafter.
(b) Owner shall file the Distribution Company TSA with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing with FERC shall include waiver requests for the effective date of the Distribution Company TSA to occur consistent with Section 3.1 thereof, which effective date may be more than one hundred twenty (120) days before the Commercial Operation Date. Owner shall file this Agreement with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when the Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing shall include waiver requests for the Effective Date to occur consistent with Section 3.1 , which Effective Date may be more than one hundred twenty (120) days before the Commercial Operation Date.
(c) The Parties shall respond promptly to any requests for additional information made by FERC in connection with any such filings.
(d) Upon the filing of this Agreement pursuant to Section 2.1(b) , Purchaser and Owner shall support the approval or acceptance of this Agreement by FERC without modification or condition.
Section 2.2 Modifications to FERC Order.
(a) In the event (i) FERC issues an order accepting or approving this Agreement for filing (the “ FERC Order ”) and (ii) the FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to a Party, in its sole discretion (an “ Unfavorable FERC Decision ”), such Party shall deliver a written notice to the other Party specifying the issues, to the extent it is able, set for hearing or the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following the issuance of the Unfavorable FERC Decision.
18
(b) In the event of an Unfavorable FERC Decision, the Parties may agree upon amendments to this Agreement (each, a “ FERC Amendment ” ) that achieve, as nearly as practicable, the commercial intent of this Agreement as of the Execution Date in a manner consistent with the Unfavorable FERC Decision. Any such amendment shall be subject to applicable regulatory approvals. As soon as practicable after any FERC Amendment(s) have been executed and delivered by the Parties, Owner shall file such FERC Amendment(s) with FERC.
(c) In the event of an Unfavorable FERC Decision, each Party shall retain the right to request a rehearing or reconsideration of the FERC Order regardless of any negotiations that have occurred or are occurring pursuant to clause (b) above; provided , however , that, in the event the Parties execute a FERC Amendment after any one or both of the Parties has filed for rehearing or reconsideration, any such rehearing or reconsideration request shall be withdrawn no later than five (5) Business Days after FERC issues an order accepting or approving the FERC Amendment for filing, if such rehearing or reconsideration request is inconsistent with the terms and conditions of this Agreement, as amended. Unless otherwise agreed in writing by the Parties, a filing by any Party of a request for rehearing or reconsideration of the FERC Order shall not toll or otherwise modify any date or time period set forth in this Agreement, including, for the avoidance of doubt, the date upon which the Construction Phase shall commence.
Section 2.3 Modifications Pursuant to Unfavorable MDPU Order or FERC Order . In the event the Regulatory Approval contains modifications or conditions that are unacceptable to Owner or Distribution Company, or in the event the MDPU issues an order setting for hearing Distribution Company’s submission (an order setting a hearing or containing unacceptable modifications or conditions is hereinafter referred to as “ Unfavorable MDPU Order ”), Owner shall promptly deliver a written notice to Purchaser of such occurrence. In the event (i) FERC issues an order accepting or approving the Distribution Company TSA for filing (the “ Distribution Company TSA FERC Order ”) and (ii) the Distribution Company TSA FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to Owner or Distribution Company, Owner shall promptly deliver a written notice to Purchaser of such occurrence. Owner and Distribution Company may agree to amend the Distribution Company TSA to address such modifications or conditions or to eliminate the issues raised in any such order or hearing, as applicable (any of the foregoing amendments, a “ Distribution Company TSA Amendment ”); provided that any Distribution Company TSA Amendment shall be subject to the prior written approval of Purchaser, which approval shall not be unreasonably withheld, delayed or conditioned. As soon as practicable after any Distribution Company TSA Amendment has been executed, Owner shall file such Distribution Company TSA Amendment with FERC and, if required, Owner shall use commercially reasonable efforts to cause Distribution Company to file such Distribution Company TSA Amendment with the MDPU, and the Parties shall execute and deliver an amendment to this Agreement as necessary to correspond with such Distribution Company TSA Amendment.
19
(a) In addition to their obligations under Section 2.1 , each Party shall, and each Party shall use commercially reasonable efforts to cause its Affiliates to, (i) cooperate with each other to prepare, file and effect any applications, notices, petitions, reports or other filings or documentation required under Applicable Law or otherwise necessary, proper or advisable to consummate the transactions contemplated by this Agreement, (ii) provide updates to the other Party on material developments in connection with any such filings or documentation, (iii) provide any non-privileged information reasonably requested by the other Party in connection with any such filings or documentation, (iv) cooperate with the other Party to use commercially reasonable efforts to obtain all Governmental Approvals and Third Party Consents that are necessary, proper or advisable to consummate the transactions contemplated by this Agreement, including the FERC Authorization (without unacceptable modifications or conditions, except as permitted by this Agreement), the Municipal Owner Approvals, the other Owner Approvals and the Canadian Approvals and (v) provide any support reasonably necessary and requested by the AC Upgrade Owners to obtain the AC Upgrade Approvals.
(b) Each Party shall consult with the other Party with respect to all characterizations of information relating to such other Party, its Affiliates or the transactions contemplated by this Agreement that are proposed to appear in any filings or documentation contemplated by Section 2.1 or Section 2.4(a) . Each Party shall promptly provide comments, if any, to the other Party on any such characterizations of information. Each Party shall make a good faith effort to take into account any comments made by the other Party.
(c) Owner shall, and shall use commercially reasonable efforts to cause its Affiliates to, cooperate with Purchaser, as reasonably requested by Purchaser, to satisfy the conditions precedent in Section 3.4 of PPA and any related reporting requirements in the PPA in order for Purchaser to deliver and track unit specific accounting of environmental attributes, enabling the Massachusetts Department of Environmental Protection to accurately account for qualified clean energy in the state greenhouse gas emissions inventory, and transmit real time meter data and measurements to ISO-NE.
(d) Each Party shall use reasonable efforts to implement the provisions of, and to administer, this Agreement in accordance with the intent of the Parties to minimize all taxes, including delivery of the United States Internal Revenue Service Form W-9 and sales tax exemptions (if applicable), so long as neither Party is materially adversely affected by such efforts.
Section 2.5 No Inconsistent Action . Except as provided in Section 17.2 and Article XIX , from and after the Execution Date, the Parties shall not undertake, and shall use commercially reasonable efforts to cause their Affiliates not to undertake, any action before FERC, ISO-NE, or any other Governmental Authority that is contrary to the Party’s obligations under this Agreement, including, for the avoidance of doubt, Section 2.1(c) and Section 7.1.4 , or support any such contrary action by any Affiliate.
20
Article III
EFFECTIVE DATE; TERM
Section 3.1 Effective Date . Article I , Article II , this Section 3.1 , Section 3.3.1 , Section 3.3.2 , Article XVII , Article XVIII , Article XIX , Article XXII , and Article XXIII shall become effective and enforceable to the extent permitted by Applicable Law upon the Execution Date. The remaining provisions of this Agreement shall become effective and enforceable to the extent permitted by Applicable Law upon the effective date set forth in the FERC Order (the “ Effective Date ”). Notwithstanding the first sentence of this Section 3.1 , this Agreement will become effective as a FERC rate schedule upon the effective date set forth in the FERC Order. Notwithstanding any other provision of this Agreement, Purchaser shall have no obligation to make any payment under this Agreement prior to receipt of the Regulatory Approval and the FERC Authorization.
Section 3.2 Term . The term of this Agreement shall commence on the Execution Date and shall expire on the fortieth (40th) anniversary of the Commercial Operation Date, unless earlier terminated (in whole or in part) or extended in accordance with the terms hereof (the “ Term ”).
Section 3.3 Termination Rights . This Agreement may be terminated in accordance with the ensuing provisions in this Article III , subject to any required regulatory reviews, approvals or acceptances, as applicable. Neither Party shall oppose any termination of this Agreement made in accordance with this Article III before FERC or any other Governmental Authority; provided , however , that the foregoing shall not prohibit any Party from challenging or otherwise Disputing whether or not any such termination is permitted by this Agreement.
Section 3.3.1 Failure to Obtain Satisfactory Regulatory Approval and FERC Authorization .
(a) This Agreement may be terminated by any Party in the event (i) it determines that the Regulatory Approval or the FERC Authorization contain terms and conditions that are, in its sole discretion, unacceptable to such Party, (ii) the Regulatory Approval is denied or is not received by January 25, 2020 (such date, the “ Regulatory Approval Termination Outside Date ”), (iii) the Regulatory Approval of the PPA (as defined in the PPA) is not received within the time frame set forth therein and the PPA is terminated, (iv) the FERC Authorization is denied or is not received by January 25, 2020, or (v) the Distribution Company TSA is terminated pursuant to Section 3.3.1(a) of the Distribution Company TSA; provided that the termination right under this clause (a) is exercised by a Party within thirty (30) days after the effective date of the termination of the Distribution Company TSA.
(b) Upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.2 Mutual Agreement . This Agreement may be terminated at any time upon written agreement of the Parties.
21
Section 3.3.3 Failure to Obtain Certain Approvals .
(a) Unless otherwise agreed in writing by the Parties, this Agreement shall terminate immediately without further action of the Parties in the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline, any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline, or any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof).
(b) In the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline or if any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof), and the Distribution Company TSA has been terminated pursuant to Section 3.3.3(a) of the Distribution Company TSA, Owner shall pay to Distribution Company the amounts contemplated by Section 3.3.3(b) of the Distribution Company TSA, and Owner shall pay to Purchaser (i) an amount equal to the Credit Support provided by Purchaser under this Agreement, including any Credit Support provided by Purchaser pursuant to Section 4.1(c) and (ii) in the event the PPA is terminated pursuant to Section 9.2(b) thereof, an amount equal to the Fixed Credit Support.
(c) In the event any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline (as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof), and the Distribution Company TSA has been terminated pursuant to Section 3.3.3(a) of the Distribution Company TSA, Purchaser shall pay to Owner an amount equal to the Credit Support provided by Owner to Distribution Company under the Distribution Company TSA, including the Owner Security (as defined in the Distribution Company TSA) and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) of the Distribution Company TSA; provided that such amount shall exclude the Credit Support provided by Purchaser under this Agreement including any Credit Support provided by Purchaser pursuant to Section 4.1(c) .
(d) Except as otherwise provided in clause (b) or (c) above, upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.4 Purchaser Default .
(a) Owner shall have the right to terminate this Agreement in accordance with Section 14.4(a) .
(b) [Intentionally Omitted].
(c) Upon the exercise by Owner of its termination rights pursuant to clause (a) above, Owner shall have the right to recover from Purchaser, and Purchaser shall pay to Owner, the Purchaser Termination Payment in accordance with Section 14.4(a) .
22
(d) The exercise by Owner of its termination rights pursuant to clause (a) above shall constitute a waiver by Owner of all other remedies or damages that may be available at law or in equity against Purchaser; provided , however , that, except as provided in Section 14.7 , Owner shall not waive its right to, and Purchaser shall remain liable for, the Purchaser Termination Payment, any unpaid amounts owed by Purchaser pursuant to Section 8.1 , any amounts owed by Purchaser to Owner under Section 3.4 , Section 4.4.2 , or Section 4.4.3 and any indemnification obligations of Purchaser to Owner under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover the Purchaser Termination Payment or such indemnified or other amounts.
Section 3.3.5 Owner Default .
(a) Purchaser shall have the right to terminate this Agreement in accordance with Section 14.6(a) or Section 14.7(e)(i) .
(b) Upon the exercise by Purchaser of its termination rights pursuant to clause (a) above, subject to Section 14.7 , Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, the Owner Termination Payment in accordance with Section 14.6(a) .
(c) Subject to Section 14.7 , the exercise by Purchaser of its termination rights pursuant to clause (a) above shall constitute a waiver by Purchaser of all other remedies or damages that may be available at law or in equity against Owner; provided , however , that Purchaser shall not waive any right to, and Owner shall remain liable for, the Owner Termination Payment, any amounts owed by Owner to Purchaser under Section 3.4 or Section 14.7(f) hereof, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 hereof or any express modification of Purchaser’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Purchaser under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover such damages or such indemnified or other amounts owed to Purchaser by Owner.
Section 3.3.6 Force Majeure . This Agreement may be terminated in accordance with Section 15.1(c) .
Section 3.3.7 Extended Excused Outage . This Agreement may be terminated in accordance with Section 7.2(c) .
23
Section 3.4 Termination Payments.
(a) Within sixty (60) days following the termination of this Agreement pursuant to Section 3.3 , Owner shall deliver to Purchaser an invoice that sets forth Owner’s good faith estimate of the amounts owed to Owner by Purchaser under Section 3.3 , or Purchaser shall deliver to Owner an invoice that sets forth Purchaser’s good faith estimate of the amounts owed to Purchaser by Owner under Section 3.3 . The recipient of such invoice shall pay the amounts set forth in such invoice within thirty (30) days following its receipt of such invoice. Either Party may deduct and setoff payment of such amounts against any accrued but unpaid payment obligation of the payee to such Party hereunder. Upon the other Party’s request, the invoicing Party shall provide documentation describing the basis for the amounts invoiced in reasonable detail.
(b) The Parties acknowledge and agree that the payment of amounts by the defaulting Party to the non-defaulting Party pursuant to Section 3.3 or this Section 3.4 is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for the termination of this Agreement are difficult or impossible to determine and that the damages calculated under Section 3.3 or this Section 3.4 constitute a reasonable approximation of the harm or loss to the non-defaulting Party as a result thereof.
Section 3.5 Effect of Termination . Except as provided in Section 3.3 and in Section 23.12 for the survival of provisions, upon expiration or other termination of this Agreement pursuant to its terms, each of the Parties shall be released from all of its obligations under this Agreement, other than any accrued but unpaid payment obligation. Notwithstanding the foregoing sentence, upon such expiration or termination of this Agreement, either Party shall have the right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by such Party to recover any amounts owed to such Party by the other Party hereunder or to secure the release of any security or performance assurance provided by or on behalf of such Party after the later to occur of the end of the Term or the date on which any accrued but unpaid payment obligation of such Party to the other Party hereunder shall have been fully, finally and indefeasibly satisfied.
Article IV
COMMERCIAL OPERATION
Section 4.1 Critical Milestones .
(a) Subject to Section 4.1(c) , Section 4.1(d) and Section 4.1(e) , commencing on the Effective Date, Owner shall develop the NECEC Transmission Line in order to achieve the milestones set forth in clauses (i), (iii)-(v) and (vii) below, and Purchaser shall cause its Affiliates to develop the Québec Line in order to achieve the milestones set forth in clauses (ii), (vi) and (vii) below (each clause, a “ Critical Milestone ”) on or before the dates set forth in this Section 4.1(a) :
(i) Receipt of all Owner Approvals (other than the Municipal Owner Approvals) and AC Upgrade Approvals in final form by the Approval Deadline;
24
(ii) Receipt of all Canadian Approvals in final form by the Canadian Approval Deadline;
(iii) Receipt of the Municipal Owner Approvals in final form by the Municipal Owner Approval Deadline;
(iv) Closing of any financing required for the construction and operation of the NECEC Transmission Line or other demonstration to Purchaser’s reasonable satisfaction of the financial capability of Owner to construct the NECEC Transmission Line, including, as applicable, Owner’s financial obligations with respect to interconnection of the NECEC Transmission Line and construction of the AC Upgrades and the CCIS Capacity Upgrades by the Financing Deadline;
(v) Execution by Owner and a contractor of an agreement for the engineering, procurement, and construction of the converter station at the southern end of the HVDC Line and payment by Owner to the contractor of an initial payment of at least 5% of the total price of the agreement, both by the Converter Station Contract Deadline;
(vi) Execution by HQE of a contract that provides for the engineering, procurement, or construction of the converter station associated with the Québec Line by the Québec Converter Station Contract Deadline; and
(vii) Achievement of the Commercial Operation Date by the Target Date.
(b) Except for the achievement of the Commercial Operation Date, which shall be governed by the provisions of Section 4.2 , the Party responsible for achieving a Critical Milestone shall provide the other Party with written notice of the achievement of such Critical Milestone as set forth in Attachment B within seven (7) days after that achievement, which notice shall include information demonstrating with reasonable specificity that such Critical Milestone has been achieved. Each Party acknowledges that: (i) the Party receiving such notice does so solely to monitor progress toward the Commercial Operation Date; (ii) Purchaser shall not have any responsibility or liability for the development, construction, operation, and maintenance of the NECEC Transmission Line; and (iii) Owner shall not have any responsibility or liability for the development, construction, operation, and maintenance of the Québec Line.
(c) The following provisions shall govern the rights and obligations of the Parties to extend any of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA and the Critical Milestones not yet achieved under this Agreement:
(i) Purchaser may elect to require Owner to extend all of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA by up to four (4) six-month periods for a maximum combined period of two (2) years from the applicable dates set forth in Section 4.1(a) thereof by delivering Credit Support to Owner for the benefit of
25
Distribution Company (in addition to the Twenty-One Million, Eight Hundred Thousand Dollars ($21,800,000) of security delivered to Distribution Company and the other RFP Sponsors by Purchaser pursuant to the PPA and the Additional PPAs) in an amount equal to $5,000 per MW of PPA Contract Maximum Amount for each such six-month period, with a pro rata adjustment of the amount of any such additional Credit Support for any partial reduction of the applicable six-month period pursuant to Section 4.1(e) . Any such election shall be made in a written notice to Owner on or prior to the first date for a Distribution Company TSA Critical Milestone that has not yet been achieved (as such date may have previously been extended). Such additional Credit Support shall be provided by Purchaser if there is a Purchaser Delay and Purchaser wishes to extend any Distribution Company TSA Critical Milestone date. In the event that there is both an Owner Delay and a Purchaser Delay and either Party wishes to extend any Distribution Company TSA Critical Milestone date by delivering additional Credit Support to Distribution Company, the additional Credit Support shall be provided in equal parts by Owner and Purchaser. Owner shall cause any additional Credit Support provided by Purchaser pursuant to this Section 4.1(c) to be returned to Purchaser upon the Commercial Operation Date; provided that, in the event the Commercial Operation Date is not achieved by the Target Date, Distribution Company shall have the rights and remedies set forth in Article XIV of the Distribution Company TSA, which, for the avoidance of doubt, shall include recourse against any Credit Support provided to Distribution Company.
(ii) Owner may elect to extend all of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA in accordance with Section 4.1(c) of the Distribution Company TSA. Such additional Credit Support shall be provided by Owner if there is an Owner Delay and Owner wishes to extend any Distribution Company TSA Critical Milestone date. In the event that there is both an Owner Delay and a Purchaser Delay and either Party wishes to extend any Distribution Company TSA Critical Milestone date by delivering additional Credit Support to Distribution Company, the additional Credit Support shall be provided in equal parts by Owner and Purchaser.
(iii) Upon any extension of any of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA, the corresponding dates for the Critical Milestones not yet achieved hereunder shall be extended accordingly; provided that Owner shall not agree to any extension of the Distribution Company TSA Critical Milestones beyond what is permitted under the Distribution Company TSA or this Agreement without the prior written consent of Purchaser, such consent not to be unreasonably withheld, conditioned or delayed.
(d) To the extent a Force Majeure event pursuant to Section 15.1 has occurred that prevents Owner or Purchaser from achieving the Critical Milestone dates for execution of the contract to purchase the converter station for the NECEC Transmission Line ( Section 4.1(a)(v) ), execution of the contract to purchase the converter station for the
26
Québec Line ( Section 4.1(a)(vi) ) or the Commercial Operation Date ( Section 4.1(a)(vii) ) by the applicable Critical Milestone date, the Critical Milestone date(s) impacted by such Force Majeure event shall be extended for the duration of the Force Majeure event, but under no circumstances shall extensions of those Critical Milestone dates exceed twelve (12) months beyond the applicable Critical Milestone date provided that (i) Owner shall not have the right to declare a Force Majeure event related to the Critical Milestone for Owner Approvals ( Section 4.1(a)(i) ), Municipal Owner Approvals ( Section 4.1(a)(iii) ), or the financing Critical Milestones ( Section 4.1(a)(iv) ); and (ii) Purchaser shall not have the right to declare a Force Majeure event related to the Critical Milestone for Canadian Approvals ( Section 4.1(a)(ii) ).
(e) In the event of a Regulatory Approval Delay, the date for each Critical Milestone not yet achieved shall be extended for the duration of the delay. The number of days of extension pursuant to the six-month extensions available under Section 4.1(c) shall be reduced by one day for each day of Regulatory Approval Delay pursuant to this subsection (e) up to a maximum reduction of 365 days. For purposes of illustration, Regulatory Approval Delay of two hundred ten (210) days would allow the Parties two six-month extensions and one extension of five months .
Section 4.2 Commercial Operation Date .
(a) The “ Target Date ” for Commercial Operation is December 13, 2022 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing. Absent written agreement by the Parties, the Target Date may not be extended beyond December 13, 2024 unless such extension is due to Regulatory Approval Delay or an event of Force Majeure as set forth in Sections 4.1(d) and 4.1(e) . The provisions of Sections 4.1(c) , 4.1(d) and 4.1(e) and all other provisions of this Agreement are subordinate to this Section 4.2(a) and the aforesaid Section 4.1 provisions and such other provisions shall be construed in a manner that is consistent with this Section 4.2(a) . Owner shall provide a written non-binding notice to Purchaser no later than sixty (60) days before the date Owner reasonably expects the Commercial Operation Date to occur.
(b) At the request of Owner made in writing, Purchaser shall, and shall use commercially reasonable efforts to cause its Affiliates to, cooperate with Owner, TransÉnergie and ISO-NE to support the Commissioning of the HVDC Transmission Project.
(c) As soon as practicable after Owner is of the opinion that the conditions to Commercial Operation, as set forth in Section 4.3 , have been satisfied, or such conditions have been waived in writing by the Parties (except in the case of Section 4.3(b) , Section 4.3(e) , Section 4.3(g) , Section 4.3(h) and Section 4.3(i) , which conditions may be waived in writing by Purchaser in its sole discretion), Owner shall deliver a written notice to Purchaser specifying the date upon which Commercial Operation shall commence (the “ COD Notice ”), which commencement date shall occur no earlier than ten (10) Business Days after the receipt by Purchaser of the COD Notice or on such other date as agreed upon by the Parties in writing (such date, the “ Commercial Operation Date ”).
27
(d) Within five (5) Business Days after the receipt by Purchaser of the COD Notice, Purchaser shall deliver a certificate to Owner either (i) confirming that the conditions set forth in Section 4.3 have been satisfied or duly waived and that Commercial Operation may commence on the Commercial Operation Date or (ii) objecting with reasonable detail to the COD Notice. Purchaser’s failure to respond in writing to a COD Notice within such five (5) Business Day period shall be deemed to be a confirmation that the conditions set forth in Section 4.3 have been satisfied or duly waived. Any Dispute over whether or not the conditions set forth in Section 4.3 have been satisfied or duly waived shall be resolved in accordance with Article XVII .
Section 4.3 Conditions Precedent to Commercial Operation
. The items set forth in clauses (a) through (i) below shall be conditions precedent to the Commercial Operation of the NECEC Transmission Line:
(a) Completion of the Commissioning of the HVDC Transmission Project by Owner (in coordination with ISO-NE) and TransÉnergie;
(b) The NECEC Transmission Line has been constructed in accordance with Attachment A and Good Utility Practice, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(c) and Section 4.4.3(b) ;
(c) Completion of the AC Upgrades and the CCIS Capacity Upgrades;
(d) The Interconnection Agreements shall be in full force and effect;
(e) The Transmission Operating Agreement shall be in full force and effect and ISO-NE shall have informed Owner that ISO-NE (i) is prepared to assume operational control over the NECEC Transmission Line, as defined in, and in accordance with, the Transmission Operating Agreement and (ii) will assume such operational control as of the Commercial Operation Date;
(f) The Québec Line has been constructed in accordance with Attachment A , and is capable of operating at, the Design Capability, except as otherwise permitted pursuant to Section 4.4.2(b) and Section 4.4.3(b) ;
(g) Receipt by Purchaser of copies of certificates evidencing all outstanding insurance required or otherwise obtained under Section 5.4 ;
(h) Receipt by Purchaser of an opinion of legal counsel, reasonably satisfactory to Purchaser, that all Governmental Approvals and Third Party Consents required to own and operate the NECEC Transmission Line have been obtained;
(i) Distribution Company has confirmed (or has been deemed to have confirmed) that the conditions set forth in Section 4.3 of the Distribution Company TSA have been satisfied or duly waived; and
28
(j) The PPA is in full force and effect and binding against the parties thereto (except where the PPA has been terminated by mutual agreement of the parties to the PPA).
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation .
Section 4.4.1 Owner Delay . If, other than solely as a result of a Purchaser Delay, Force Majeure, or Concurrent Delay, any conditions set forth in Section 4.3 shall not have been satisfied or duly waived by the Target Date (such delay, an “ Owner Delay ”):
(a) Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, for each day (or part thereof) following the Target Date during which the Owner Delay is continuing and, but for such Owner Delay, Purchaser would then be capable of delivering the energy and providing the environmental attributes to Distribution Company as provided in the PPA, an amount equal to Fifty Dollars ($50) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Purchaser terminates this Agreement pursuant to Section 14.6 or Distribution Company terminates the Distribution Company TSA pursuant to Section 14.4 thereof and (z) the date that is twelve (12) months after the Target Date.
(b) [Intentionally Omitted].
(c) Owner’s Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the Québec Line is capable of operating at or above 1,090 MW and the NECEC Transmission Line is only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line is capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the NECEC Transmission Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then Owner shall have twenty-four (24) months from the Commercial Operation Date to attempt to increase such operating capacity to 1,090 MW (the “ Remediation Period ”); provided that upon any extension of the Remediation Period (as defined in the Distribution Company TSA) under the Distribution Company TSA, the Remediation Period hereunder shall be extended accordingly. Owner shall pay to Purchaser, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period, or such earlier date designated by Owner in writing to Distribution Company (the “ Owner Remediation Date ”), an amount equal to Fifty Dollars ($50) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and the operating capacity of the NECEC Transmission Line as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Purchaser to Owner. Owner’s payments shall be based on the actual operating capacity of the NECEC Transmission Line, as is stated in Section 8.1 .
29
(ii) If, on the earlier of the Owner Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line has been increased to at or above 1,075 MW but less than 1,090 MW, then Owner shall be liable to Purchaser for an amount equal to the Proportionate Share multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the Commercial Operation Date in connection with the development and construction of the Qu é bec Line multiplied by the percentage equal to (A) the difference between (x) the 1,090 MW and (y) the operating capacity of the NECEC Transmission Line divided by (B) the 1,090 MW. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(d) The Parties acknowledge and agree that the payment of amounts by Owner to Purchaser under clauses (a) and (c) above are an appropriate remedy and that any such modification or payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for an Owner Delay or a reduction in operating capacity, as described in clause (c), are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Purchaser as a result thereof.
(e) The rights provided in Section 3.3.5 , this Section 4.4.1 , and Section 4.4.3 shall collectively be the sole and exclusive remedies of Purchaser with respect to an Owner Delay or a reduction in operating capacity, as described in clause (c). The foregoing sentence shall not be construed in any way to limit (i) Purchaser’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement, or (ii) Purchaser’s rights to recover payment of any indemnification obligations of Owner to Purchaser pursuant to Section 20.2 .
Section 4.4.2 Purchaser Delays .
(a) Subject to any extension of any Critical Milestone date pursuant to the Distribution Company TSA or Section 4.1(c) , Section 4.1(d) , or Section 4.1(e) hereof, if, except in the event of Force Majeure, on the Target Date, solely as a result of delays in completing the Québec Line or operational difficulties with the Québec Line (a “ Purchaser Delay ”), the Commercial Operation Date is delayed, for each day (or part thereof) during which the Purchaser Delay is continuing, Purchaser will pay to Owner an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Owner terminates this Agreement pursuant to Section 14.4 or Distribution Company terminates the Distribution Company TSA pursuant to Section 3.3.8 thereof and (z) twelve (12) months after the Target Date.
30
(b) Purchaser’s Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line is capable of operating at or above 1,090 MW and the Québec Line is only capable of operating below 1,090 MW, and (A) the Québec Line is capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the Québec Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then Purchaser shall have the Remediation Period to attempt to increase the operating capacity of the Québec Line to 1,090 MW; provided that upon any extension of the Remediation Period (as defined in the Distribution Company TSA) under the Distribution Company TSA, the Remediation Period hereunder shall be extended accordingly. Purchaser shall pay to Owner, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period, or such earlier date designated by Owner pursuant to the Distribution Company TSA (the “ Purchaser Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and the operating capacity of the Québec Line.
(ii) If, on the earlier of the Purchaser Remediation Date and the end of the Remediation Period, the operating capacity of the Québec Line has been increased to at or above 1,075 MW but less than 1,090 MW, then Purchaser shall be liable to Owner for the Québec Line Capacity Deficiency Payment. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the Québec Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(c) The Parties acknowledge and agree that the payment of amounts by Purchaser to Owner under clauses (a) and (b) above, respectively, are an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Purchaser Delay or a reduction in operating capacity, as described in clause (b) , are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Owner as a result thereof.
(d) The rights provided in Section 3.3.4 , this Section 4.4.2 and Section 4.4.3 shall collectively be the sole and exclusive remedies of Owner with respect to a Purchaser Delay or a reduction in operating capacity, as described in clause (b) . The foregoing sentence shall not be construed in any way to limit (i) Owner’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Purchaser under this Agreement, or (ii) Owner’s rights to recover payment of any indemnification obligations of Purchaser to Owner pursuant to Section 20.1 .
31
Section 4.4.3 Concurrent Delays .
(a) In the event of a concurrent Purchaser Delay and Owner Delay (a “ Concurrent Delay ”), for each day (or part thereof) during which a Concurrent Delay is continuing, Owner shall pay to Distribution Company the amounts required under Section 4.4.2(a) of the Distribution Company TSA; provided , however , that Purchaser shall be liable to Owner for such portion of the amounts paid by Owner to Distribution Company under Section 4.4.2(a) of the Distribution Company TSA that is in proportion to Purchaser’s share of liability for the Concurrent Delay.
(b) Concurrent Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are both only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line and the Québec Line are both capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the NECEC Transmission Line or the Québec Line, or both, are capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then the Parties shall have the Remediation Period to attempt to increase the operating capacity of their respective lines to 1,090 MW. If the actual capacity of the Québec Line is less than the actual capacity of the NECEC Transmission Line as of the Commercial Operation Date, Purchaser shall pay to Owner, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period or such earlier date designated by Owner pursuant to the Distribution Company TSA (the “ Concurrent Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between the lesser of (x) the actual capacity of the NECEC Transmission Line and (y) 1,090 MW and the actual capacity of the Québec Line as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Owner to Purchaser.
(ii) Québec Line Capacity is Lower . If, on the earlier of the Concurrent Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW (and Distribution Company has waived any deficiency in capacity of the Québec Line or the NECEC Transmission Line), and the actual capacity of the Québec Line is less than the actual capacity of the NECEC Transmission Line, then Purchaser shall be liable to Owner for the Québec Line Capacity Deficiency Payment. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the Québec Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
32
(iii) NECEC Transmission Line Capacity is Lower . If, on the earlier of the Concurrent Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW, and the actual capacity of the NECEC Transmission Line is less than the actual capacity of the Québec Line, then Owner shall be liable to Purchaser for an amount equal to the Proportionate Share of the difference between the actual capacity of the Québec Line and the actual capacity of the NECEC Transmission Line as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period, divided by an amount equal to 1,090 MW minus the actual capacity of the NECEC Transmission Line, multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period in connection with the development and construction of the Québec Line. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(iv) Both Lines Have Capacity Shortfall . If: (1) as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are both not capable of operating at or above 1,040 MW, and Distribution Company has not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability, or (2) as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period, the NECEC Transmission Line and the Québec Line are both not capable of operating at or above 1,075 MW and Distribution Company has not waived such deficiency under the Distribution Company TSA, then Purchaser shall pay to Owner one-half (1/2) of the Owner Termination Payment (as defined in the Distribution Company TSA) payable to Distribution Company under the Distribution Company TSA as a consequence thereof.
Article V
GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES
Section 5.1 Responsibilities of the Parties .
Section 5.1.1 Construction Phase .
(a) During the Construction Phase, Owner shall (i) exercise Good Utility Practice to complete, or cause the completion of, all tasks required to construct the NECEC Transmission Line, interconnect at least 1,090 MW of capacity with ISO-NE in compliance with the Capacity Capability Interconnection Standard, and achieve Commercial Operation by the Target Date, in each case, in accordance with the Design Capability and in a manner consistent with Attachment A and (ii) use commercially reasonable efforts (A) to obtain all of the Construction Authorizations (other than the Municipal Owner Approvals) by the Approval Deadline and to obtain the Municipal
33
Owner Approvals by the Municipal Owner Approval Deadline, (B) to obtain, in consultation with Purchaser, the ISO-NE Approval by the Approval Deadline and (C) to cause Owner’s Affiliates that are AC Upgrade Owners to obtain any AC Upgrade Approvals for which such Affiliates are responsible by the Approval Deadline and to assist other AC Upgrade Owners in obtaining their respective AC Upgrade Approvals by the Approval Deadline.
(b) Owner will use commercially reasonable efforts to enter into, within a commercially reasonable timeframe, one or more Construction Contracts. Owner will make a copy of any such contract available to Purchaser subject to such redactions as Owner or the contracting party deem necessary to protect confidential information.
(c) [Intentionally Omitted.]
(d) During the Construction Phase, Purchaser shall take commercially reasonable steps to cause its Affiliate, TransÉnergie, to exercise Good Utility Practice to complete, or cause the completion, of all tasks required to construct the Québec Line in accordance with the applicable design, as set forth in Attachment A , prior to the Target Date and to cooperate with Owner to enable the achievement of Commercial Operation by the Target Date, and Purchaser shall cause TransÉnergie to use commercially reasonable efforts to obtain the Canadian Approvals by the Canadian Approval Deadline.
Section 5.2 Schedules and Reports .
Section 5.2.1 Owner’s Preliminary Schedule . Attached hereto as Attachment E is Owner’s Project Schedule (the “ Owner’s Preliminary Schedule ”). At the request of Purchaser, Owner shall make the personnel responsible for preparing the Owner’s Preliminary Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Preliminary Schedule with Purchaser.
Section 5.2.2 Owner’s Construction Schedule . Within ten (10) days after the end of each calendar quarter and sooner if a material change occurs, commencing at least ninety (90) days prior to the commencement of construction, Owner shall prepare and submit to Purchaser for review an update of the Owner’s Preliminary Schedule (such updated schedule as established herein, the “ Owner’s Construction Schedule ”). At the request of Purchaser, Owner shall make the personnel responsible for preparing the Owner’s Construction Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Construction Schedule with Purchaser.
Section 5.2.3 Owner’s Progress Reports .
(a) Promptly following the Execution Date, Owner shall deliver to Purchaser copies of all applications that have been submitted by Owner with respect to any Owner Approvals, as well as all material correspondence and submittals relating to such Owner Approvals. Within ten (10) days after the end of each calendar quarter, commencing at receipt of the Regulatory Approval, Owner shall prepare and submit to Purchaser for review a progress report for informational purposes that sets forth in reasonable detail the current status of the milestones set forth in the Owner’s Construction
34
Schedule, including any changes in the expected timelines and the status of all Owner Approvals and including copies of any Owner Approval applications, material correspondence and submittals relating to Owner Approvals, and any issued Owner Approvals (the “ Owner’s Construction Progress Report ”). Without limitation of the foregoing, Owner shall include in such reports relevant information relating to: (i) Owner’s efforts to mitigate the impacts of the NECEC Transmission Line on natural resources, environmentally sensitive areas, habitats, and wildlife species, and cultural and historic resources; (ii) Owner’s efforts to comply with applicable noise ordinances; (iii) Owner’s communication and community outreach efforts and plans with respect to the construction of the NECEC Transmission Line, including with stakeholders in Massachusetts; and (iv) Owner’s analysis of, and any material developments related to, the Municipal Owner Approvals (or any applications to the Maine Public Utilities Commission to exempt Owner from the requirement to obtain any Municipal Owner Approval). In delivering the Owner’s Construction Progress Report, Owner shall be deemed to certify that the list of required Municipal Owner Approvals identified in paragraph 10 of Attachment C is accurate and complete as of the date of delivery of the Owner’s Construction Progress Report except as supplemented in such report. At the request of Purchaser, Owner shall, or shall cause each contractor to, provide Purchaser with access to, and copies of, all reasonably requested documentation concerning such Owner’s Construction Progress Report.
(b) Owner shall, or shall cause the principal contractor to, notify Purchaser promptly, but in no event later than ten (10) days, after Owner, or such contractor, becomes aware that the Commercial Operation of the NECEC Transmission Line is not reasonably likely to occur by the Target Date.
Section 5.3 Québec Line Reports; Joint Development Agreement . Purchaser agrees to cooperate with and support Owner in connection with the negotiation and execution of a joint development agreement between TransÉnergie and Owner relating to the Owner Approvals, the Canadian Approvals and construction and design matters relating to the Québec Line and the NECEC Transmission Line (such agreement, the “ Joint Development Agreement ”). Until the execution of the Joint Development Agreement, Purchaser shall promptly provide to Owner all material information received from TransÉnergie with respect to progress on the construction of the Québec Line, including information related to the Canadian Approvals.
Section 5.4 Insurance and Events of Loss . Owner shall obtain and maintain with reputable insurers authorized to operate in the scope of the Agreement insurance of the type as set forth in Attachment F . Owner shall provide Purchaser with copies of certificates of all outstanding insurance obtained hereunder promptly after the receipt thereof by Owner. Owner shall notify Purchaser as soon as reasonably possible if and whenever an event of loss occurs. Without limitation of any obligations Owner may have under Section 15.1 hereof, in the event of damage to or loss of all or part of the NECEC Transmission Line, Owner shall exercise prompt, diligent commercially reasonable efforts to effectuate, in accordance with Good Utility Practice, such repairs and replacements as are necessary or desirable to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss, including, for the avoidance of doubt, the application to such repairs or replacements of any potential or actual proceeds realized in connection with such damage or loss under any available or applicable
35
insurance policies (subject to insurance contract/policy terms and conditions of coverage) maintained pursuant to this Section 5.4 . Subject to Owner’s compliance, in all material respects, with this Section 5.4 , Section 6.3 and all other material terms and conditions with respect to the operation and maintenance of the NECEC Transmission Line, in the event that the costs to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss exceed the available insurance proceeds by more than the greater of (a) an amount equal to three percent (3%) of the Net Book Value of the NECEC Transmission Line and (b) Thirty Million Dollars ($30,000,000), the Parties will negotiate in good faith an appropriate allocation of financial responsibility for such excess costs. In the event that the Parties do not agree on the allocation of financial responsibility, Purchaser shall be entitled to terminate this Agreement, upon thirty (30) days’ written notice to Owner, without liability to Owner; provided that, if within the thirty (30) day period following receipt of such notice, Owner agrees to assume that portion of the allocation of financial responsibility to which Purchaser objected, then the termination notice shall be deemed revoked and this Agreement shall not be terminated.
Section 5.5 Compliance with Laws . At all times during the Term, the Parties shall comply with all Applicable Laws (including ISO-NE Rules to the extent applicable) and relevant Governmental Approvals and Third Party Consents.
Section 5.6 Third Party Contracts . At all times during the Term, Owner shall, in a commercially reasonable manner, (a) satisfy its obligations under all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades, and (b) administer all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades.
Section 5.7 Purchaser’s Losses . Neither Purchaser nor its Affiliates shall be entitled to recover from Owner any losses, damages, costs or expenses related to the Québec Line or arising under the TransÉnergie OATT, except to the extent included in (a) an Owner Termination Payment, or (b) any damages paid pursuant to Section 4.4.1(a) , Section 4.4.1(c) , or Section 4.4.3 .
Section 5.8 Continuity of Rights and Responsibilities . Unless otherwise agreed in writing by the Parties or prohibited by Applicable Law, the Parties shall continue to provide service and honor commitments under this Agreement and continue to make payments in accordance with this Agreement pending resolution of any bona fide Dispute hereunder or relating hereto.
Section 5.9 Right of First Offer to Purchase NECEC Transmission Line .
(a) Subject to the receipt of any required regulatory approvals and Third Party Consents, prior to conducting any Marketing Activities, Owner shall provide Purchaser with the right to offer to buy, directly or through an Affiliate, the NECEC Transmission Line in accordance with this Section 5.9 , by providing Purchaser with written notice of Owner’s intent to sell the NECEC Transmission Line (to the extent that such sale relates only to the NECEC Transmission Line without any other material assets) (such notice, a “ Marketing Notice ”). Upon receipt of the Marketing Notice, Purchaser shall then have forty five (45) days to make an offer to purchase the NECEC Transmission Line, which offer shall contain reasonably detailed information relating to the price (such
36
price, the “ Offer Price ”) and all material economic terms of the transaction upon which Purchaser is willing to purchase the NECEC Transmission Line. If Purchaser elects to make such an offer, Owner shall, within thirty (30) days following the receipt of such offer, either (i) accept such offer, in which case the parties will proceed to close the purchase of the NECEC Transmission Line within the next sixty (60) days (or such longer period as is reasonably necessary to obtain all required approvals and consents) on the terms contained in such offer, or (ii) reject such offer.
(b) If Owner rejects the offer made by Purchaser, then Owner shall be free to thereafter sell the NECEC Transmission Line to third parties (subject to the provisions of this Agreement) within the twelve (12) months following the date of Owner’s rejection of Purchaser’s offer for a price higher than one hundred percent (100%) of the Offer Price, with economic terms not materially less favorable to Owner (taken in the aggregate) than those contained in Purchaser’s offer (or, if materially less favorable, then with such adjustments to the price to account for any such material differences in the economic terms of the sale).
Section 5.10 Amendment to the PPA . Purchaser shall not amend or otherwise modify the PPA, or seek or provide any waiver of any term or condition of the PPA, in a manner that adversely and materially affects Purchaser’s rights under this Agreement or that would result in an increase in Owner’s liability pursuant to clause (b) of “Owner Termination Payment,” clause (b)(ii) of “Owner Termination Payment” (as defined in the Distribution Company TSA) or Section 3.3.3 or that would affect Owner’s rights under Section 7.2(b) without the consent of Owner, which consent shall not be unreasonably withheld, conditioned or delayed. Purchaser shall provide Owner with notice of any amendment or other modification to Section 8.3 of the PPA prior to the effective date of such amendment.
Section 5.11 Amendment to the Distribution Company TSA . Owner shall not (a) terminate the Distribution Company TSA pursuant to Section 3.3.2 thereof or (b) agree to any amendment or other modification of the Distribution Company TSA, or seek or provide any waiver of any term or condition of the Distribution Company TSA, that adversely and materially affects Purchaser’s rights under this Agreement (including in a manner that would result in an increase in the credit support provided by Owner under the Distribution Company TSA), in each case without the consent of Purchaser, which consent shall not be unreasonably withheld, conditioned or delayed.
Article VI
PROCEDURES FOR OPERATION AND MAINTENANCE
OF THE NECEC TRANSMISSION LINE
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control .
(a) Prior to entering into the Transmission Operating Agreement, Owner shall consult Purchaser with respect to the proposed terms and conditions thereof and Owner shall make a good faith effort to take into account any comments made by Purchaser. Purchaser shall promptly provide comments, if any, to Owner on such terms and conditions.
37
(b) As of the Commercial Operation Date, Owner shall transfer operational control over the NECEC Transmission Line, as defined in the Transmission Operating Agreement, to Transmission Operator in accordance with the Transmission Operating Agreement. Owner shall provide, and shall direct its Affiliates to provide, such information as Transmission Operator may require to discharge its obligations under the Transmission Operating Agreement, and Owner shall comply with the instructions of Transmission Operator to the extent provided in the Transmission Operating Agreement and the ISO-NE Tariff. The Parties acknowledge and agree that Owner shall not be in breach of, or be liable to Purchaser under, this Agreement, and no Owner Default shall occur, as a consequence of Owner’s compliance with such instructions of Transmission Operator; provided that Owner did not initiate or support instructions that would otherwise breach Owner’s obligations under this Agreement.
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements . From and after the Commercial Operation Date, Owner shall (a) provide Firm Transmission Service, (b) operate and maintain the NECEC Transmission Line in accordance with Good Utility Practice and in compliance with all applicable regulatory requirements, including applicable NERC and Northeast Power Coordinating Council reliability standards, and (c) comply with all applicable operating instructions of ISO-NE and manufacturers’ warranties.
Section 6.3 Scheduled Maintenance . With respect to each calendar year (or portion thereof) following the Construction Phase, Owner will prepare and deliver to Purchaser a Maintenance Plan not later than the Commercial Operation Date and two (2) months prior to the end of each calendar year thereafter, and shall be available for consultation with Purchaser with respect thereto (including for coordination of maintenance schedules). Consistent with Good Utility Practice, Owner shall use commercially reasonable efforts to coordinate with TransÉnergie with respect to scheduled maintenance so as to minimize outages, including by meeting annually (or as otherwise necessary in order to comply with any applicable ISO-NE or Canadian regulatory or system operator requirements) to develop a Maintenance Plan. From and after the Commercial Operation Date, Owner shall coordinate all planned maintenance with ISO-NE, consistent with ISO-NE Rules, and shall promptly provide applicable information concerning scheduled outages, as determined by ISO-NE, to Purchaser. To maximize value, to the extent possible and consistent with ISO-NE Rules, Owner shall not schedule maintenance of the NECEC Transmission Line during the months of December, January and February or June through September and shall operate the NECEC Transmission Line so as to maximize energy production during the hours of anticipated peak load and energy prices in New England; provided , however , that planned maintenance may be scheduled during such period to the extent the failure to perform such planned maintenance is contrary to operation of the NECEC Transmission Line in accordance with Good Utility Practice. Owner may modify a Maintenance Plan in accordance with Good Utility Practice; provided, however, that (a) a Maintenance Plan may not be modified for the purpose of reducing the magnitude or duration of a Non-Excused Outage, (b) any modification shall, to the extent commercially reasonable, maximize value in the manner described in this Section 6.3 and (c) Owner shall provide Purchaser with reasonable notice of any change in a Maintenance Plan. Any maintenance that is not included in the Maintenance Plan for a year and is not otherwise excused under Section 7.2 shall be a Non-Excused Outage.
38
PURCHASER’S TRANSMISSION RIGHTS OVER THE
NECEC TRANSMISSION LINE
Section 7.1 Transmission Service .
Section 7.1.1 Firm Transmission Service. Owner shall make available to Purchaser throughout the Purchaser Term transmission capacity on the NECEC Transmission Line in order to deliver electrical energy, as scheduled by Purchaser or its designee or assignee under the resale provisions of Article X, in such scheduled amount up to the Contract Capacity, measured at the Delivery Point (“Firm Transmission Service”). Firm Transmission Service shall be made available over the NECEC Transmission Line during the Purchaser Term, in a north-to-south direction, and to the extent available in a south-to-north direction, between the U.S. Border and the Delivery Point. Firm Transmission Service shall be subject to curtailment or interruption only as a result of an Excused Outage or as provided in Section 14.4(b). Without limiting Owner’s obligations under this Section 7.1.1, the quantity of Firm Transmission Service that Owner will provide in any hour shall not exceed the Proportionate Share of the Available Transfer Capability for such hour.
Section 7.1.2 Limitation on Transmission Service . Owner shall have no obligation to provide transmission service under this Agreement other than Firm Transmission Service. Purchaser shall have no right to redirect service to alternate points of delivery or receipt on any portion of the transmission system operated by ISO-NE other than the NECEC Transmission Line.
Section 7.1.3 Scheduling . All Firm Transmission Service shall be scheduled in accordance with the rules relating to the scheduling of electrical energy or capacity transactions over the NECEC Transmission Line, as established under the Transmission Operating Agreement (the “ Scheduling Rules ”).
Section 7.1.4 Owner’s Cooperation . Owner shall provide Purchaser with notice of any FERC or NERC regulatory proceedings relating to the NECEC Transmission Line or this Agreement to which Owner is a party promptly after Owner becomes aware of any such proceedings. Each Party will act in good faith regarding any such proceedings. Neither Party shall take any position in such proceeding that is contrary to such Party’s obligations under this Agreement.
Section 7.2 Excused Outages or Reductions .
(a) Notwithstanding anything herein to the contrary, Owner shall not be in breach of, or be liable to Purchaser for any losses or damages under, this Agreement, and no Owner Default shall occur, as a consequence of an Excused Outage. “ Excused Outages ” means any outages of the NECEC Transmission Line or reductions in the Total Transfer Capability below the NECEC Transmission Line Capacity, whether as a result of a physical condition, legal impediment or otherwise, if and to the extent such outage or reduction is due to:
(i) Events of Force Majeure;
39
(ii) Scheduled maintenance in accordance with the applicable Maintenance Plan;
(iii) Outages or reductions in the availability of the Québec Line for any reason; or
(iv) Decisions of ISO-NE or any other independent system operator to reduce or suspend scheduling rights over the NECEC Transmission Line or the Québec Line, including as a result of any grid reliability issue, emergency condition as defined in any Interconnection Agreement or the ISO-NE Tariff, or to preserve facilities and equipment from physical damage and including any such decisions that arise from outages or reductions in the use or availability of transmission lines other than the NECEC Transmission Line or the Québec Line, which outage or reduction arises from or is attributable to Force Majeure or scheduled maintenance.
(b) Notwithstanding anything in Section 7.3.1 to the contrary, Purchaser shall remain obligated, during and to the extent of any Excused Outage, to pay the Transmission Service Payment without downward adjustment to reflect any such outage, reduction or delay. Owner shall seek to avoid and mitigate or remedy any Excused Outage consistent with Good Utility Practice.
(c) Notwithstanding anything herein to the contrary and without regard to whether an Excused Outage is due to Force Majeure, if an Excused Outage prevents Owner’s full or partial performance under this Agreement during the Purchaser Term for a period of twelve (12) consecutive months or more, Purchaser shall have the right, as provided in Section 15.1(c) herein, to terminate this Agreement upon written notice to Owner and without further recourse.
Section 7.3 Non-Excused Outages or Reductions .
Section 7.3.1 Reduction in Transmission Service Payments . In the event the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), u nless otherwise excused under Section 7.2 or Section 11.1 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 during the Term or firm transmission service contemplated by Section 7.1.1 of the Distribution Company TSA during the term of the Distribution Company TSA, Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, for each such month during which a Non-Excused Outage occurs, the Non-Excused Outage Payment; provided that, in no event, shall the total amount of (a) all Non-Excused Outage Payments made in any Contract Year under this Agreement plus (b) all Non-Excused Outage Payments (as defined in the Purchaser TSAs) made in any Contract Year plus (c) all Non-Excused Outage Payments (as defined in the 110 MW TSA) made in any Contract Year exceed Twenty Million Dollars ($20,000,000); provided further that such cap shall be proportionately reduced in any Contract Year that is less than a full calendar year. Any Dispute
40
over whether or not or to what extent a Non-Excused Outage has occurred shall be resolved in accordance with Article XVII. Such amounts shall be payable on a monthly basis pursuant to invoices delivered by Purchaser to Owner. Owner shall seek to avoid, mitigate and remedy any Non-Excused Outage consistent with Good Utility Practice.
Section 7.3.2 [Intentionally Omitted] .
Section 7.3.3 Liquidated Damages . The Parties acknowledge and agree that the payment of amounts by Owner to Purchaser under Section 7.3.1 and the modification of Purchaser’s payment obligations pursuant to Section 8.1 are an appropriate remedy and that any such payment or modification does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Non-Excused Outage are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Purchaser as a result thereof.
Section 7.3.4 Sole and Exclusive Remedy . The rights provided in Section 3.3.5 , this Section 7.3 and Section 8.1 shall collectively be the sole and exclusive remedies of Purchaser with respect to a Non-Excused Outage, subject to (a) Purchaser’s right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement, (b) Purchaser’s right to recover payment of any indemnification obligations of Owner to Purchaser pursuant to Section 20.1 , (c) Purchaser’s rights upon the occurrence of an Owner Default as described in Section 14.3 or (d) Purchaser’s rights in the event of Real Power Losses pursuant to Section 11.1 .
Section 7.4 Allocation of Outages . Except as set forth in this Section 7.4 with respect to the 110 MW TSA, the Parties expressly intend and agree that any outages or reductions in Total Transfer Capability shall be borne equitably by all transmission rights holders served by the NECEC Transmission Line (including Owner, if applicable), and Owner acknowledges and agrees that it will not reduce the Firm Transmission Service available to Purchaser in an unduly discriminatory manner as compared with any other transmission rights holder served by the NECEC Transmission Line (including Owner, if applicable). Purchaser’s transmission service under the 110 MW TSA shall be reduced before any reductions are applied to Distribution Company’s transmission service under the Distribution Company TSA or the Additional RFP Sponsor TSAs.
Section 7.5 Metering . Metering and telemetering requirements for the NECEC Transmission Line shall be established by Owner in accordance with Good Utility Practice and as necessary to (a) accomplish the purposes of, and to implement and administer, this Agreement and (b) satisfy the requirements of, and to implement and administer, the PPA, the Interconnection Agreement and the Transmission Operating Agreement.
Section 7.6 Line Availability Information and Reporting . Owner shall make available to Purchaser on a real time basis information relating to the operation and availability of the NECEC Transmission Line and shall provide such additional information as Purchaser shall reasonably request.
41
PAYMENTS FOR TRANSMISSION SERVICE OVER THE
NECEC TRANSMISSION LINE
Section 8.1 Transmission Service Payments . During the period beginning on the twentieth (20th) anniversary of the Commercial Operation Date and ending on the fortieth (40th) anniversary of the Commercial Operation Date (unless earlier terminated) (the “ Purchaser Term ”), except to the extent such payment is excused or reduced pursuant to the terms of this Agreement, Purchaser shall pay to Owner a transmission service payment (the “ Transmission Service Payment ”) on a monthly basis pursuant to invoices delivered by Owner to Purchaser equal to Seven Dollars Thirty Eight Cents ($7.38) per KW of Contract Capacity per month. The Transmission Service Payment shall be reduced in accordance with the formula set forth in Attachment G in the event and to the extent that the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 . To the extent there is a Dispute over whether or not or to what extent a Non-Excused Outage has occurred , Purchaser’s right, pursuant to this Section 8.1, to any reduction in the Transmission Service Payment shall be implemented upon the resolution of such Dispute and such reduction will be effective as of the date when such Dispute arose . Such adjustments shall be made on a monthly basis pursuant to invoices delivered by Owner to Purchaser.
Section 8.2 Adjustment to Rate Upon Purchaser Step-in . Notwithstanding anything in the Distribution Company TSA to the contrary, in the event Purchaser elects to assume the rights and obligations of Distribution Company under the Distribution Company TSA, as provided in Section 14.8(a) or 14.8(b) , the transmission service payment payable under the Distribution Company TSA by Purchaser for the remainder of the term thereunder shall be equal to that portion of the transmission service payment payable under the Distribution Company TSA comprising Owner’s non-capital expenses related to the NECEC Transmission Line, and Purchaser shall not be required to compensate Owner for any depreciation, equity return or cost of capital during the remainder of the term under the Distribution Company TSA. In the event of such assumption and upon request of Purchaser, the Parties shall amend the Distribution Company TSA to give effect to this Section 8.2.
Section 8.3 Elective Upgrade Status; No Regional Rates . It is the intent of the Parties that the NECEC Transmission Line has Elective Transmission Upgrade status during the Term and that the AC Upgrades and the CCIS Capacity Upgrades constitute Network Upgrades under the ISO-NE Tariff required to accommodate the interconnection of the NECEC Transmission Line. The Parties acknowledge and agree that (a) as contemplated by the PPA, Purchaser shall participate in such Forward Capacity Auction (as defined in the ISO-NE Rules) qualification process as required to allow Purchaser to qualify a Seasonal Claimed Capability (as defined in the ISO-NE Rules) of not less than 1,200 MW over the NECEC Transmission Line no later than the Guaranteed Delivery Term Start Date (as defined in the PPA), as it may be extended pursuant to Sections 3.1(c) through 3.1(f) of the PPA and (b) such Network Upgrades, if any, shall be at
42
Owner’s sole expense. It is the further intent of the Parties that Owner’s recovery of the investment in and return on the NECEC Facilities and Purchaser’s obligation to pay for the NECEC Facilities, shall be solely governed by this Agreement. The Parties each shall refrain from taking steps to include all or part of the NECEC Facilities in ISO-NE regional transmission rates during the Term. Notwithstanding the foregoing, if during the Term all or part of the NECEC Facilities are included in ISO-NE regional rates paid by Purchaser, the payment required by Section 8.1 shall be reduced by the Proportionate Share of the revenues received by Owner from such ISO-NE rates with respect to the NECEC Facilities. “NECEC Facilities” means the NECEC Transmission Line, the AC Upgrades, and the CCIS Capacity Upgrades.
Article IX
RIGHTS UPON EXPIRATION OF TERM
Section 9.1 Rollover Rights .
(a) Unless this Agreement is terminated early under Section 3.3 , Section 14.4 or Section 14.6 , Purchaser shall have rollover rights at the end of the Purchaser Term in accordance with FERC Order No. 890 et seq. and the FERC pro forma open access transmission service tariff, as such rights are defined as of the Effective Date.
(b) Owner shall not enter into any contract or other arrangement for use of the NECEC Transmission Line that is inconsistent with Purchaser’s rollover rights, as provided herein.
Article X
RESALE OF TRANSMISSION SERVICE
Section 10.1 Resale Rights of Purchaser . If and to the extent Purchaser (including, prior to the Purchaser Term, in its capacity as assignee of transmission rights under Section 20 of the PPA) determines from time to time, and in its sole discretion, that the transmission capacity available to Purchaser relevant to the receipt of Firm Transmission Service over the NECEC Transmission Line pursuant to this Agreement exceeds Purchaser’s needs, Purchaser shall then offer to resell such unused capacity to third parties in accordance with Applicable Law as may then be in effect (including the terms and conditions of FERC Order No. 890 et seq., if applicable).
Section 10.2 Capacity Releases for Daily and Hourly Use . From and after the Commercial Operation Date, if and to the extent the Proportionate Share of the Available Transfer Capability exceeds the amount of electrical energy that is scheduled by Purchaser for delivery over the NECEC Transmission Line using Firm Transmission Service by the applicable scheduling deadline (as in effect at such time) established pursuant to the Scheduling Rules, then the transmission capacity that is available for resale to third parties for the following day, and the price at which any such resales are offered, shall be posted on the OASIS site established pursuant to Section 10.3 .
43
(a) Owner or an Affiliate of Owner (in such capacity, the “ OASIS Administrator ”) shall establish an OASIS site for the NECEC Transmission Line and administer such site in accordance with applicable FERC requirements for the establishment and administration of OASIS sites. None of Owner, the OASIS Administrator or Purchaser shall be liable to each other or any third party for any decisions the OASIS Administrator makes regarding the appropriate price for resales of unused transmission capacity or the level of any such resales the OASIS Administrator is able to make. The Parties agree that there shall be no damages as between each other or third parties for actions by the OASIS Administrator with respect to resales of unused transmission capacity.
(b) To the extent resales are made available by Purchaser pursuant to Section 10.1 , the OASIS Administrator shall post on the OASIS site information regarding such resales, (i) in accordance with written instructions provided by Purchaser from time to time and (ii) at a price established by Purchaser from time to time, and in its sole discretion, as permitted under Applicable Law.
Section 10.4 Proceeds from Capacity Releases and Transmission Resales . Except as otherwise provided in Section 14.4(b) , Purchaser’s proceeds received by Owner of any capacity releases and transmission resales that are made during the Purchaser Term pursuant to this Article X shall be credited, net of reasonable fees (including attorneys’ fees) and other expenses incurred in connection with performance of the functions described in Section 10.2 and Section 10.3 , against any Transmission Service Payment or other amounts owed to Owner by Purchaser for the calendar month subsequent to the calendar month in which such proceeds were received.
Section 10.5 Owner’s Rights and Obligations . Except as expressly provided in the Proposal Agreements, Owner shall have no right or obligation to offer any transmission service over the NECEC Transmission Line for sale or resale to any Person other than Purchaser, as provided herein.
Article XI
REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS
Section 11.1 Real Power Losses . Purchaser shall be responsible for all Real Power Losses associated with Firm Transmission Service; provided , however , that, if and to the extent any Real Power Losses associated with Firm Transmission Service between the U.S. Border and the Delivery Point are due to Owner’s failure to exercise Good Utility Practice or otherwise discharge its obligations under this Agreement, (a) such incremental Real Power Losses shall be treated as Non-Excused Outages for which Owner shall be liable in accordance with Section 7.3 and (b) the Transmission Service Payments owed by Purchaser shall be reduced pursuant to Section 8.1 ; and provided , further , that during the Term Owner shall (x) exercise diligent, commercially reasonable efforts to maximize the warranty or similar obligations of its vendors and suppliers for the NECEC Transmission Line with respect to such Real Power Losses under any Construction Contract or otherwise and (y) credit, assign or pay over to Purchaser any amounts receivable by or paid to Owner under such warranties or similar obligations, including
44
liquidated damages under any Construction Contract, related to such Real Power Losses, and the rights and remedies contemplated by Section 3.3.5 , Section 7.3 , Section 8.1 and this Section 11.1 , shall collectively be the sole and exclusive remedy of Purchaser with respect to any such incremental Real Power Losses.
Section 11.2 Other Rights .
(a) Purchaser shall be entitled during the Purchaser Term to its Transmission Percentage of the following, without duplication and without additional cost to Purchaser or compensation to Owner: (i) all Other Transmission Rights associated with the NECEC Transmission Line or the AC Upgrades, in each case, that are issued in accordance with the ISO-NE Tariff or otherwise granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE and (ii) all other Market Products that are issued in accordance with the ISO-NE Tariff or granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, that derive from the acquisition of transmission service over the NECEC Transmission Line. As Owner’s sole obligation under this clause (a), upon its receipt of any of the entitlements or rights described in the foregoing sentence, Owner shall promptly convey such entitlements or rights to Purchaser.
(b) In the event tie benefits or interconnection capability credits (or any similar concept) are ever deemed applicable to the NECEC Transmission Line and to the extent allocated to any Party during the Purchaser Term, Purchaser shall be entitled to its Transmission Percentage of one hundred percent (100%) of the economic benefits associated therewith (however entitled and whether existing now or in the future), without additional cost to Purchaser or compensation to Owner.
(c) Owner shall have no obligation to support the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above, but Owner may not oppose the creation or establishment of any such right, unless otherwise agreed in writing by Purchaser. Neither Section 2.5 nor the foregoing sentence shall be construed in any way to limit the right of any Affiliate of Owner to oppose the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above.
Article XII
[INTENTIONALLY OMITTED]
Article XIII
BILLING AND PAYMENTS
Section 13.1 Invoices . Within seven (7) Business Days after the first day of each calendar month following the commencement of the Purchaser Term, Owner shall submit an Invoice to Purchaser for the Transmission Service Payments owed for the preceding calendar month, and Purchaser shall pay the amounts set forth in the Invoice to Owner within fourteen (14) Business Days following its receipt of such Invoice. All payments shall be made in immediately available funds payable to Owner by wire transfer to a bank named by Owner, in accordance with wiring instructions provided to Purchaser by Owner in writing. Owner shall be entitled to change the place or recipient for payment by thirty (30) days’ prior written notice to Purchaser.
45
Section 13.2 Procedures for Billing Disputes .
(a) In the event of any Dispute with respect to the amount owed to Owner by Purchaser under this Agreement, Purchaser shall have no right to withhold payment of the Disputed amount pending resolution of the Dispute; provided , however , that, in the event such Dispute is resolved in favor of Purchaser, Owner shall complete the following tasks consistent with the resolution of such Dispute: (i) retroactively adjust all payments previously made by Purchaser; (ii) promptly refund all overpayments previously made by Purchaser, together with interest thereon in immediately available funds or by wire transfer, in each case, in accordance with wiring instructions provided to Owner by Purchaser in writing; and (iii) thereafter conform all future Invoices to reflect the resolution of such Dispute, as applicable. Purchaser’s payment of any Disputed amounts shall be without prejudice to any right or remedy that Purchaser may have under this Agreement to contest any such amount.
(b) Purchaser shall not have the right to challenge any Invoice or to bring any action of any kind challenging the propriety of any Invoice after the second (2nd) anniversary of the receipt of such Invoice. If an Invoice is not rendered within two (2) years after the end of the calendar month during which such Invoice should have been rendered hereunder, then the right to payment of such Invoice is waived.
Section 13.3 Interest . All interest payable under this Section 13.3 shall be calculated pursuant to 18 C.F.R. § 35.19a(a), as such regulation (or any successor thereto) is in effect during the period during which such interest is due. Amounts not paid when due to Owner or Purchaser under this Agreement shall bear interest from the date such amount was due until the date of payment of such overdue amount. For the avoidance of doubt, as illustrated in Attachment H , if all or a portion of the amount to which such interest relates is later refunded pursuant to this Agreement, then, in calculating that refund, such interest shall not be included in the refund. Refunds of overpayments owed to Purchaser by Owner under this Agreement shall begin to accrue interest on the amount subject to refund, as originally invoiced, from the earlier to occur of the due date or the date of payment of the monthly Invoices to which the overpayment relates and shall continue to accrue interest until the date of payment of such refund.
Section 13.4 Obligation to Make Payments . The Parties acknowledge and agree that, except as set forth in Section 8.1 , Section 13.5 and Section 14.6(d) , no cause or event whatsoever shall excuse or suspend Purchaser’s obligation to pay Transmission Service Payments or any other amounts payable by Purchaser under this Agreement. The Parties also acknowledge and agree that no cause or event whatsoever shall excuse or suspend any amounts payable by Owner under this Agreement.
Section 13.5 Offsets . Except as otherwise provided in Section 3.4(a) and Section 14.6(d) , neither Party shall be entitled to deduct or set-off payment of any amount owed to the other Party under this Agreement against payment of any amount owing under this Agreement. The Parties shall have the right to deduct or set-off payments of amounts owed hereunder against payments of amounts owing under the 110 MW TSA or the Purchaser TSAs.
46
EVENTS OF DEFAULT AND REMEDIES
Section 14.1 Purchaser Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Purchaser under this Agreement (a “ Purchaser Default ”); provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (e), clause (f) or clause (g):
(a) Purchaser’s failure to pay any undisputed amount due to Owner under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Purchaser of a written demand from Owner that such amount is due and owing and has not been timely paid.
(b) Purchaser’s failure to comply in any material respect with the provisions of Article XVI .
(c) The failure of the Québec Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date (where the NECEC Transmission Line is capable of operating at or above 1,040 MW as of the Commercial Operation Date), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Purchaser Remediation Date or the end of the Remediation Period (where the NECEC Transmission Line is capable of operating at or above 1,075 MW as of the earlier of the Purchaser Remediation Date or the end of the Remediation Period), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability.
(d) Purchaser’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), and (c) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Purchaser of written notice thereof from Owner, unless such cure shall reasonably require a longer period, in which case Purchaser shall be provided an additional thirty (30) days to complete such cure so long as Purchaser has promptly commenced such cure and thereafter diligently pursues such cure.
(e) Any representation or warranty made by Purchaser in this Agreement is false or misleading at the time made in any material respect.
(f) Any Insolvency Event occurs with respect to Purchaser.
(g) An Event of Default (as defined in the PPA) by Purchaser under the PPA that does not result from a TSA Delivery Shortfall (as defined in the PPA) or a Transmission Delay (as defined in the PPA), or a Purchaser Default (as defined in the 110 MW TSA), occurs and is continuing.
Section 14.2 [Intentionally Omitted] .
47
Section 14.3 Owner Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Owner under this Agreement (an “ Owner Default ” ); provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (h) or clause (i):
(a) Owner’s failure to pay any undisputed amount due to Purchaser under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Owner of a written demand from Purchaser that such amount is due and owing and has not been timely paid.
(b) Owner’s failure to satisfy (other than as a result of a Purchaser Delay) any of the Critical Milestones in clauses (i) , ( iii ), ( iv ), ( v ), or (vii) of Section 4.1(a) by the dates set forth therefor, as the same may be extended in accordance with Section 4.1(c) , Section 4.1(d) , or Section 4.1(e) .
(c) The failure of the NECEC Transmission Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date (where the Québec Line is capable of operating at or above 1,040 MW as of the Commercial Operation Date), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Owner Remediation Date or the end of the Remediation Period (where the Québec Line is capable of operating at or above 1,075 MW as of the earlier of the Owner Remediation Date or the end of the Remediation Period), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability.
(d) Owner’s failure to comply in any material respect with the provisions of Section 5.1.1(a)(ii) and, if such failure is susceptible to cure, such failure continues for thirty (30) days after receipt by Owner of written notice thereof from Purchaser, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(e) A Non-Excused Outage pursuant to which (A) the Hourly Availability of the NECEC Transmission Line is less than one hundred percent (100%) for more than ninety (90) consecutive days and the average Hourly Availability of the NECEC Transmission Line over each calendar month in which the ninety (90) consecutive days occur is less than the Minimum Average Availability for each such month (whether as a result of a physical condition, legal impediment or otherwise), or (B) the Hourly Availability of the NECEC Transmission Line is less than one hundred percent (100%) for more than hundred twenty (120) days in any twelve (12) month period and the average Hourly Availability of the NECEC Transmission Line over each calendar month in which any such day occurs is less than the Minimum Average Availability for each such month (whether as a result of a physical condition, legal impediment or otherwise) in each case, unless otherwise excused under Section 7.2 , provided , however , that if (i) Owner presents
48
to Purchaser and Distribution Company (before the Purchaser Term) or Purchaser (during the Purchaser Term) before the end of a Non-Excused Outage that would otherwise constitute an Owner Default under this clause (e) , a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company and Purchaser (before the Purchaser Term) or Purchaser (during the Purchaser Term), each acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, and (ii) prior to the start of the Purchaser Term, Owner posts Credit Support with Distribution Company as set forth in Section 14.2(e) of the Distribution Company TSA, Purchaser shall forbear terminating this Agreement under this clause (e) for such period, provided that, during any such period, Purchaser’s obligation to make Transmission Service Payments shall continue to be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, an Owner Default shall be deemed to have occurred and Purchaser shall have the rights and remedies set forth in Section 14.6 and Section 14.7 .
(f) Owner’s failure to comply in any material respect with the provisions of Article XVI .
(g) Owner’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), (c), (d), or (e) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Owner of written notice thereof from Purchaser, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(h) Any representation or warranty made by Owner in this Agreement is false or misleading at the time made in any material respect.
(i) Any Insolvency Event occurs with respect to Owner.
(j) An Owner Default (as defined in the Distribution Company TSA) that is not attributable to the operating capability of the Québec Line, or an Owner Default (as defined in the 110 MW TSA), occurs and is continuing.
Section 14.4 Remedies Upon Purchaser Default . Upon the occurrence of a Purchaser Default and at any time thereafter so long as the same is continuing, Owner shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Owner shall elect:
(a) In the case of a Purchaser Default, and subject to Section 5.8 , Owner may terminate this Agreement by written notice to Purchaser.
49
(b) In the case of a Purchaser Default pursuant to Section 14.1(a) , and subject to Section 5.8 , Owner may suspend all or part of Owner’s obligations or Purchaser’s rights under this Agreement during the period during which such Purchaser Default is continuing. During any such period of suspension occurring after the Commercial Operation Date, (i) Purchaser shall not be entitled to schedule, and shall not schedule, any transactions over the NECEC Transmission Line and (ii) the OASIS Administrator shall be directed to post any portion of the transmission capacity that would have otherwise been available to Purchaser over the NECEC Transmission Line pursuant to this Agreement and to attempt to sell such capacity to one or more third parties consistent with Article X . The proceeds of any capacity releases and transmission resales made pursuant to the foregoing sentence and received by Owner, net of reasonable fees (including attorneys’ fees) and other expenses incurred by Owner in connection with this Section 14.4(b) , shall be credited against any accrued but unpaid payment obligation of Purchaser to Owner hereunder. Any such proceeds in excess of such accrued but unpaid payment obligation of Purchaser shall be credited in accordance with Section 10.4 .
(c) Subject to Article XVIII and this Section 14.4 , as applicable, Owner may recover from Purchaser the Purchaser Termination Payment and, to the extent applicable, all other amounts not waived in accordance with Section 3.3.4(d) or, in the absence of a termination pursuant to a Purchaser Default, all damages suffered by Owner that are due to a Purchaser Default, including, for the avoidance of doubt, any amounts payable under Section 4.4.2 and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Purchaser under this Agreement.
(d) Owner may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Additional Credit Support held by Owner and (ii) the right to liquidate any and all Additional Credit Support held by Owner and to apply the proceeds of such liquidation to any amounts payable to Owner with respect to Purchaser’s obligations hereunder in such order as Owner may elect. Owner may draw on the undrawn portion of any Letter of Credit provided as Additional Credit Support up to the amount of Purchaser’s outstanding obligations hereunder. Purchaser shall remain liable for amounts due and owed to Owner that remain unpaid after the application of Additional Credit Support.
(e) Owner may exercise and enforce any and all of its rights and remedies under the Hydro-Québec Guaranty.
(f) Owner may exercise any and all other rights and remedies that may be available to Owner against Purchaser at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Owner shall have no right to (i) terminate this Agreement based upon a Purchaser Default, except as provided in clause (a) above, or (ii) suspend transmission service under this Agreement based upon a Purchaser Default, except as provided in clause (b) above.
Section 14.5 [Intentionally Omitted] .
50
Section 14.6 Remedies Upon Owner Default . Upon the occurrence of an Owner Default and at any time thereafter so long as the same is continuing, Purchaser shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Purchaser shall elect:
(a) In the case of an Owner Default, and subject to Section 5.8 and Section 14.7 , Purchaser may terminate this Agreement by written notice to Owner and may recover, as applicable, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 and the Owner Termination Payment.
(b) Subject to the limitations provided in Section 4.4.1(e) , Section 7.3.4 , Article XVIII or this Section 14.6 , as applicable, Purchaser may recover from Owner any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement.
(c) Purchaser may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Additional Credit Support held by Purchaser and (ii) the right to liquidate any and all Additional Credit Support held by Purchaser and to apply the proceeds of such liquidation to any amounts payable to Purchaser with respect to Owner’s obligations hereunder in such order as Purchaser may elect. Purchaser may draw on the undrawn portion of any Letter of Credit or apply Cash, in each case that has been provided as Additional Credit Support up to the amount of Owner’s outstanding obligations hereunder. Owner shall remain liable for amounts due and owed to Purchaser that remain unpaid after the application of Additional Credit Support.
(d) Pursuant to Section 13.2 , to the extent there is a Dispute over the amount of the damages suffered by Purchaser as a result of an Owner Default, Purchaser may deduct and setoff payment of such amount against any Transmission Service Payment upon resolution of that Dispute.
(e) Purchaser may exercise any and all other rights and remedies that may be available to Purchaser at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Purchaser shall have no right to (i) terminate this Agreement based upon an Owner Default, except as provided in clause (a) above or Section 14.7(e)(i) , or (ii) any reduction of or offset against payments under this Agreement based upon an Owner Default, except as contemplated by Section 8.1 , Section 13.5 and Section 14.6(d) , as applicable.
51
Section 14.7 Purchaser Step-in Rights .
(a) In the event that (i) an Owner Default or an Owner Default (as defined in the Distribution Company TSA) occurs or (ii)(A) Owner exercises its rights pursuant to Section 14.2(e) of the Distribution Company TSA or Section 14.3(e) of this Agreement and (B) at the end of the first six (6) months of the period of forbearance by Purchaser of its rights as contemplated by Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA, Owner is not providing Firm Transmission Service in full, then Purchaser shall have the right, but not the obligation, to (x) assume control of and possess and operate the NECEC Transmission Line as agent for Owner (in accordance with Owner’s rights, obligations and interest under this Agreement, the Distribution Company TSA and the Additional RFP Sponsor TSAs, as applicable) during the period provided for herein, pursuant to an agreement to be negotiated in good faith between Owner and Purchaser or (y) assume ownership, control of, possession and operation of the NECEC Transmission Line, in each case, which right shall be exercisable by written notice to Owner and subject to the receipt of any required regulatory approvals and Third Party Consents.
(b) Upon receipt of such written notice to assume ownership of the NECEC Transmission Line (the “ Acquisition Notice ”), Owner shall (i) provide such documents and information as is reasonably necessary for Purchaser to determine any amount owed pursuant to Section 14.7(c) and (ii) take all necessary action to effect the transfer of the NECEC Transmission Line to Purchaser (or its designated Affiliate), including causing all permits, title to land and property, and interests in all contracts (including Owner’s rights under this Agreement, the 110 MW TSA, the Purchaser TSAs, the Distribution Company TSA and the Additional RFP Sponsor TSAs, as applicable) applicable to the NECEC Transmission Line to be transferred to Purchaser or such designated Affiliate. Each Party shall, and each Party shall use commercially reasonable efforts to cause its Affiliates to, cooperate to obtain any required regulatory approvals and Third Party Consents necessary to effect the transfer of the NECEC Transmission Line to Purchaser.
(c) In consideration for acquiring the NECEC Transmission Line, on the closing date, as reasonably determined by Purchaser and specified in the Acquisition Notice, Purchaser shall pay to Owner an amount equal to (i) if such Owner Default occurs prior to the Commercial Operation Date, all costs prudently incurred by Owner as of the date of the Acquisition Notice in connection with the development and construction of the NECEC Transmission Line or (ii) if such Owner Default occurs on or after the Commercial Operation Date, the lesser of (A) one hundred percent (100%) of Owner’s investment in the NECEC Transmission Line as of the notice date and (B) the fair market value of the NECEC Transmission Line, as reasonably determined by a third party appraiser selected by Purchaser and reasonably acceptable to Owner (which amount shall be net of the costs of any such appraisal). The amount to be paid pursuant to this clause (c) shall be in satisfaction of any consideration required to be paid pursuant to Section 14.7 of all Purchaser TSAs and shall be determined within fifteen (15) days after the delivery of the Acquisition Notice or such other time period as is reasonably practicable.
52
(d) Upon receipt of all required regulatory approvals and Third Party Consents and the payment set forth in clause (c) above, Owner shall transfer to Purchaser (or its designated Affiliate), without recourse or warranty (except as to title and the absence of any liens other than liens arising in the ordinary course), all of Owner’s right, title and interest in and to the NECEC Transmission Line free and clear of all liens other than liens arising in the ordinary course and Purchaser (or such designated Affiliate) shall be assigned all rights of Owner under all contracts required for the ownership and operation of the NECEC Transmission Line and shall assume all liabilities and obligations of Owner arising under such contracts after the transfer (other than applicable contracts between Owner and its lenders, the liabilities and obligations of Owner thereunder to be completely satisfied and discharged by Owner as of closing) and Owner shall cease to be a Party.
(e) Upon Purchaser (or its designated Affiliate) assuming ownership and control of the NECEC Transmission Line:
(i) (A) Purchaser (or its designated Affiliate) shall have the right to terminate this Agreement and Purchaser may recover, as applicable, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 or (B) Purchaser (or its designated Affiliate) shall assume Owner’s obligations under this Agreement pursuant to this Section 14.7 and Purchaser shall enter into such amendments to this Agreement as are reasonably necessary in order to give effect to such rights and that are consistent with the terms and conditions of this Agreement and are subject to applicable regulatory approvals;
(ii) Purchaser (or its designated Affiliate) shall assume the rights and obligations of Owner under the Distribution Company TSA, the Additional RFP Sponsor TSAs, the 110 MW TSA and the Purchaser TSAs for the remainder of the term thereof (excluding any rights and obligations accrued prior to such assumption).
(f) In connection with an event occurring that gives rise to Purchaser’s step-in rights pursuant to Section 14.7(a) (a “ Step-In Trigger Event ”) and the exercise by Purchaser of its rights under this Section 14.7 , Owner shall pay liquidated damages to Purchaser (without duplication of any amounts paid under Section 14.7 of any other Purchaser TSA) in an amount equal to:
(i) if such Step-In Trigger Event occurs on or before December 31, 2019, Twelve Million Dollars ($12,000,000);
(ii) if such Step-In Trigger Event occurs after December 31, 2019, but on or before December 31, 2020, Thirty Million Dollars ($30,000,000);
(iii) if such Step-In Trigger Event occurs after December 31, 2020, but on or before December 31,2021, Seventy-Three Million Dollars ($73,000,000);
53
(iv) if such Step-In Trigger Event occurs after December 31, 2021 but before the Commercial Operation Date, Ninety Million Dollars ($90,000,000); or
(v) if such Step-In Trigger Event occurs on or after the Commercial Operation Date, One Hundred Million Dollars ($100,000,000).
The assumption by Purchaser (or its designated Affiliate) of ownership and control of the NECEC Transmission Line under this Section 14.7 shall constitute a waiver by Purchaser of all other remedies or damages that may be available at law or in equity against Owner; provided , however , that Purchaser shall not waive any right to, and Owner shall remain liable for, the liquidated damages set forth in this Section 14.7(f) , any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.2 , or Section 7.3.1 hereof or any express modification of Purchaser’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Purchaser under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover such damages or such indemnified or other amounts owed to Purchaser by Owner.
(g) Notwithstanding this Section 14.7 , in the event that an Owner Default occurs and at any time prior to Purchaser (or its designated Affiliate) assuming ownership and control of the NECEC Transmission Line, (i) Purchaser may exercise its termination rights pursuant to Section 14.6(a) and the exercise of such termination rights shall result in a revocation of Purchaser’s step-in rights under Section 14.7(a) or (ii) Purchaser may revoke the exercise of its step-in rights under Section 14.7(a) .
(h) Owner shall not grant any Person, other than a secured party in accordance with Section 22.3 , a right to assume control of, possess and operate the NECEC Transmission Line that is equal to or superior to Purchaser’s right under this Section 14.7 .
(i) As requested by Purchaser following its purchase of the NECEC Transmission Line pursuant to this Section 14.7 , Owner agrees to grant to Purchaser (or its designated Affiliate) any such other rights of way, and assign to Purchaser or such designated Affiliate such other contracts to which it is then a party, as shall be necessary for the ownership, operation, and maintenance of the NECEC Transmission Line.
(j) Owner shall deliver true, correct and complete copies of all applicable contracts and books and records to Purchaser for its review no later than ten (10) days after receipt of the Acquisition Notice. Following the timely delivery by Owner to Purchaser of all such contracts and books and records, Purchaser shall be required to notify Owner at least twenty (20) days prior to the expected closing date if the terms and conditions of the assignment and assumption of any such contracts will not be satisfactory to Purchaser (or its designated Affiliate) and, if Purchaser does so notify Owner, such notice shall result in the revocation of the Acquisition Notice, and the Parties shall be deemed to be in the same position as if Purchaser had not delivered such Acquisition Notice. As a condition of closing, Owner shall completely satisfy and discharge its
54
liabilities and obligations under all applicable contracts between Owner and its lenders and Owner shall obtain written releases, in recordable form reasonably acceptable to Purchaser, of all liens (whether for the benefit of its lenders or otherwise) on the NECEC Transmission Line and the applicable contracts other than liens arising in the ordinary course, and Owner obligates itself to satisfy such liabilities and obligations and to obtain such releases as of closing.
Section 14.8 Early Termination of Distribution Company TSA .
(a) Upon any termination of the Distribution Company TSA as a result of a Distribution Company default thereunder, Purchaser shall have the right, exercisable in its sole discretion, to assume the rights and obligations (subject to the adjustment set forth in Section 8.2 ) of Distribution Company under the Distribution Company TSA for the remainder of the term thereunder by written notice to Owner; provided that Purchaser shall have no obligations for amounts owed by Distribution Company to Owner prior to Purchaser’s assumption in accordance with this Section 14.8(a) , including any amounts owed as a result of a Distribution Company default thereunder, and provided that Hydro-Québec shall execute and deliver an amendment to the Hydro-Québec Guaranty, in form and substance reasonably satisfactory to Owner, to guarantee such assumed obligations.
(b) During any suspension of all or part of Owner’s obligations or Distribution Company’s rights under the Distribution Company TSA, Purchaser shall have the right, exercisable in its sole discretion, to assume the rights and obligations (subject to the adjustment set forth in Section 8.2 ) of Distribution Company under the Distribution Company TSA by written notice to Owner, and, in the event Purchaser elects to assume such Distribution Company’s obligations, Owner shall thereafter resume performance of its obligations thereunder. For the avoidance of doubt, the exercise by Purchaser of any rights hereunder shall be without prejudice to the rights of Purchaser under the PPA.
Section 14.9 Disputes . Any Dispute over whether or not an Owner Default or Purchaser Default has occurred shall be resolved in accordance with Article XVII .
Section 14.10 Limitations on Total Liability.
Section 14.10.1 Purchaser Liability . Notwithstanding anything herein to the contrary, Purchaser’s liability for any payments made to Owner pursuant (x) to Sections 3.3.3 , 3.3.4 , 3.4 , 4.4.2 , 4.4.3 and 14.4 , (y) Sections 3.3.3 , 3.3.4 , 3.4 , 4.4.2 , 4.4.3 and 14.4 of the Purchaser TSAs and (z) Sections 3.3.4 , 3.4 , 4.4.2 and 14.4 of the 110 MW TSA shall not exceed, in aggregate, an amount equal to Two Hundred Million Dollars ($200,000,000), which $200,000,000 shall be adjusted in accordance with the following:
(a) increased by the total amount of Credit Support provided by Owner pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs;
(b) reduced by the amount drawn on any Credit Support provided by Owner pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs as a result of an Owner Default hereunder and thereunder;
55
(c) reduced by any amount of Credit Support that has been returned to Owner pursuant to Section 4.1(c) of the Distribution Company TSA and Section 4.1(c) of the Additional TSAs with the RFP Sponsors; and
(d) reduced by any Delay Damages (as defined in the PPA) paid by Purchaser to Distribution Company under the PPA.
Section 14.10.2 Owner Liability . Notwithstanding anything herein to the contrary, Owner’s liability for any payments made to Purchaser pursuant to (x) Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.3(b)(iii) , 7.3 , 14.11 and 14.6 , (y) Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.3(b)(iii), 7.3 , 14.11 and 14.6 of the Purchaser TSAs and (z) Sections 3.3.5 , 3.4 , 4.4.1 , 7.3 , 14.11 and 14.6 of the 110 MW TSA shall not exceed, in aggregate, an amount equal to Sixty Million Dollars ($60,000,000), which $60,000,000 shall be adjusted in accordance with the following:
(a) increased by the total amount of Credit Support provided by Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs;
(b) reduced by the amount drawn on any Credit Support provided by Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs as a result of a Purchaser Default hereunder and thereunder;
(c) reduced by any amount of Credit Support that has been returned to Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs; and
(d) reduced by any amounts paid by Owner pursuant to Section 14.7(f) of this Agreement and Section 14.7(f) of the Purchaser TSAs.
Exceptions to Total Liability . Section 14.10.4 The limits on liability set forth in Sections 4.4 , 14.10.1 and 14.10.2 shall not apply to any liability of a Party arising out of such Party’s gross negligence, willful misconduct (including willful breach of this Agreement) or fraud.
Section 14.11 Modified Terms Applicable During Forbearance Period .
(a) In the event that Owner exercises its rights pursuant to Section 14.2(e) of the Distribution Company TSA or Section 14.3(e) of this Agreement, during the continuation of the period of forbearance by Purchaser of its rights as contemplated by Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA, an additional $3 shall be available in clause (b) of the definition of Non-Excused Outage Payment for the calculation of such payment by Owner, and an additional Ten Million Dollars ($10,000,000) per Contract Year shall be available with respect to the limitation of liability contained in Section 7.3.1 . If Owner is successful in providing Firm Transmission Service under this Agreement or Firm Transmission Service (as defined in the Distribution Company TSA), as applicable, in full at or prior to the end of such period of forbearance, all such amounts shall revert at the time Firm Transmission Service or Firm Transmission Service (as defined in the Distribution Company TSA), as applicable, is provided in full to the amounts applicable under this Agreement prior to Owner’s exercise of its rights under Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA.
56
FORCE MAJEURE
Section 15.1 Definition; Conditions .
(a) The term “ Force Majeure ” means an event or circumstance (i) that is not within the reasonable control of the Party claiming its occurrence; (ii) that could not have been prevented or avoided by such Party through the exercise of reasonable diligence and (iii) that prohibits or prevents such Party from performing its obligations under this Agreement. Under no circumstances shall Force Majeure include (w) any full or partial curtailment in the operation of the NECEC Transmission Line that is caused by or arises from a mechanical or equipment breakdown or other mishap or events or conditions attributable to normal wear and tear or flaws of the NECEC Transmission Line, unless such curtailment or mishap is caused by one of the following: acts of God such as floods, hurricanes, tornados, or other significantly unusual and abnormal weather conditions, such as severe blizzards and severe ice storms; sabotage; terrorism or war; national or regional general strikes, lockouts or other labor disputes, (x) any occurrence or event that increases the costs or causes an economic hardship to a Party but is not otherwise a Force Majeure, (y) Owner’s ability to sell transmission service involving the NECEC Transmission Line at a price greater than that set out in this Agreement or (z) Purchaser’s ability to procure transmission service at a price lower than that provided in this Agreement or Purchaser’s ability to sell generation at a price higher than that provided in the PPA. In addition, a delay or inability to perform attributable to a Party’s lack of preparation, a Party’s failure to timely obtain and maintain all necessary permits (excepting the Regulatory Approval other than the obligations to file for Regulatory Approval) or qualifications, any delay or failure of Owner to obtain the Owner Approvals or of Purchaser to obtain the Canadian Approvals, a failure to satisfy contractual conditions or commitments, or lack or deficiency in funding or other resources shall each not constitute a Force Majeure or be the basis for a claim of Force Majeure. Neither Party may raise a claim of Force Majeure based in whole or in part on the failure of Purchaser to fulfill any of its obligations under the PPA (including related to the availability of the Québec Line) unless such failure is due to “force majeure” or “uncontrollable force” or a similar term as defined under the PPA.
(b) Subject to Section 15.1(a) , if a Party is unable, wholly or in part, by Force Majeure to perform its obligations under this Agreement, such performance shall be excused and suspended so long as the circumstances that give rise to such inability exist or would exist if the Party claiming the Force Majeure used commercially reasonable efforts to cure such circumstances, but for no longer period. The Party whose performance is affected shall give prompt notice thereof to the other Party; such notice may be given orally or in writing but, if given orally, it shall be promptly confirmed in writing, providing details regarding the nature, extent and expected duration of the Force Majeure, its anticipated effect on the ability of such Party to perform its obligations under this Agreement, and the estimated duration of any interruption in service or other adverse effects resulting from such Force Majeure, and shall be updated or supplemented to keep the other Party advised of the effect and remedial measures being undertaken to overcome
57
the Force Majeure. Such inability to perform shall be promptly corrected to the extent it may be corrected through the exercise of due diligence consistent with Good Utility Practice. Neither Party shall be liable for any losses or damages arising out of a suspension of performance that occurs because of Force Majeure. Notwithstanding any such suspension of performance, Purchaser shall be obligated to make Transmission Service Payments as though Firm Transmission Service was then being provided at or greater than the Minimum Average Availability.
(c) Notwithstanding the foregoing, if the Force Majeure prevents full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, the Party whose performance is not prevented by Force Majeure shall have the right to terminate this Agreement upon written notice to the other Party and without further recourse, provided , however , that if (i) Owner presents a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan reasonably acceptable to Purchaser and Distribution Company (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, to Purchaser and Distribution Company before the end of a period in which Owner’s provision of Firm Transmission Service has been prevented in whole or in part by an event of Force Majeure, Purchaser shall forbear terminating this Agreement under this clause (c) for such period, provided that, during any such period, Purchaser’s obligation to make Transmission Service Payments shall be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, Purchaser may terminate this Agreement under this clause (c) . In no event will any delay or failure of performance caused by any conditions or events of Force Majeure extend this Agreement beyond its stated Term.
(d) A Party shall not be required to settle any strike, walkout, lockout or other labor dispute on terms that, in the sole judgment of such Party, are contrary to its interest. The settlement of strikes, walkouts, lockouts or other labor disputes shall be entirely within the discretion of the Party involved in such dispute.
Article XVI
FINANCIAL ASSURANCES
Section 16.1 Purchaser’s Guaranty . Concurrently with the execution of this Agreement, Purchaser shall cause Purchaser Guarantor to deliver to Owner a guaranty by Purchaser Guarantor of Purchaser’s payment obligations under this Agreement substantially in the form of Attachment J (the “ Hydro-Québec Guaranty ”).
Section 16.2 [Intentionally Omitted] .
58
Section 16.3 Credit Downgrade Event . Purchaser Guarantor and Owner shall at all times meet the Credit Rating Requirements.
(a) In the event Owner fails to meet the Credit Rating Requirements, Owner shall promptly furnish to Purchaser, in an amount equal to the Proportionate Share multiplied by Two Hundred Fifty Million Dollars ($250,000,000), Additional Credit Support.
(b) In the event Purchaser Guarantor fails to meet the Credit Rating Requirements, Purchaser shall promptly furnish to Owner, in an amount equal to the Proportionate Share multiplied by Two Hundred Fifty Million Dollars ($250,000,000), Additional Credit Support.
For the purposes of this Section 16.3 , the denominator in “Proportionate Share” shall be 1,200 MW.
Article XVII
DISPUTE RESOLUTION
Section 17.1 Consultation .
(a) The Parties shall initially attempt to resolve any Dispute through consultations between the Parties. Subject to Section 17.2 and except as expressly provided otherwise in this Agreement, if a Dispute has not been timely resolved pursuant to this clause (a) within fifteen (15) Business Days after written notice of such Dispute has been given, then either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction; provided, however, if the Dispute is subject to Section 17.2 , then either Party may elect to proceed with the mediation through FERC's Dispute Resolution Service. If one Party fails to participate in the consultations provided for in this Section 17.1 , the other Party can initiate mediation prior to the expiration of the fifteen (15) Business Days. Unless otherwise agreed, the Parties will select a mediator from the FERC panel. The Parties may, by written agreement signed by both Parties, alter any time deadline, location(s) for meeting(s) or procedure outlined herein or in FERC’s rules for mediation. The procedure specified herein shall be the sole and exclusive procedure for the resolution of Disputes.
(b) All negotiations, consultations, and mediations pursuant to this Section 17.1 shall be deemed to be confidential and shall be treated as compromise and settlement negotiations, and no evidence with regard to any proposal made during such negotiations, consultations or mediations shall be admissible in any FERC proceeding or filing under Section 17.2 or in any other judicial or other proceeding.
59
Section 17.2 Disputes to be Resolved by FERC .
(a) In the event a Dispute over any matter is not resolved in accordance with Section 17.1 , either Party shall have the right to file for relief with FERC to the extent that matter is within the primary or exclusive jurisdiction of the FERC. Nothing contained in this Agreement shall be construed as precluding a Party from filing any answer, protest or other opposition to any FERC filing made by the other Party, unless expressly prohibited under the terms of this Agreement.
(b) In the event any Dispute is submitted to FERC for resolution as provided in Section 17.2(a) , the Party submitting the Dispute to FERC shall be responsible for providing written notice of such filing to the other Interested Parties. Unless both Parties agree that the Dispute does not implicate any of the Proposal Agreements other than this Agreement, each Party consents and agrees that (i) each Interested Party is an interested party in the Dispute and (ii) in order to avoid inconsistent interpretations and adjudications of the Proposal Agreements, any Interested Party may, without objection from any other Interested Party, whether by means of joinder, consolidation or otherwise, submit such matters as it considers sufficiently related to the Dispute to FERC to be jointly determined by FERC with the Dispute. Notwithstanding the foregoing, in the event FERC determines that it does not have the jurisdiction to, or otherwise does not want to, hear or determine any portion of a Dispute or other matter so referred to FERC, either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction.
Section 17.3 Consent to Jurisdiction . Subject to Section 17.2 , each Party agrees that any legal action or proceeding with respect to or arising out of this Agreement or any other Proposal Agreement shall be brought in or removed to the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts that has subject matter jurisdiction and any appellate court from any thereof. By execution and delivery of this Agreement, each Party hereby accepts for itself and in respect of its property, generally and unconditionally, the jurisdiction of the aforesaid courts. The Parties irrevocably consent to the service of process out of any of the aforementioned courts in any such action or proceeding by the mailing of copies thereof by registered or certified airmail, postage prepaid, to the applicable Party at its respective addresses for notices as specified in Section 23.4 . Nothing herein shall affect the right to serve process in any other manner permitted by law. Each Party hereby waives any right to stay or dismiss any action or proceeding under or in connection with this Agreement or any other Proposal Agreement brought before the foregoing courts on the basis of forum non-conveniens.
Section 17.4 WAIVER OF JURY TRIAL . EACH PARTY IRREVOCABLY AND UNCONDITIONALLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY LEGAL ACTION, PROCEEDING, CAUSE OF ACTION , OR COUNTERCLAIM ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.
60
LIMITATION OF REMEDIES
NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, NEITHER PARTY NOR ANY OF ITS AGENTS, SUBCONTRACTORS, REPRESENTATIVES OR AFFILIATES SHALL BE LIABLE TO THE OTHER PARTY FOR PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE (EXCEPT AS EXPRESSLY CONTEMPLATED IN THIS AGREEMENT, INCLUDING IN Section 4.4 OR Section 7.3 , OR FOR ANY DIRECT DAMAGES SUFFERED BY PURCHASER AS A RESULT OF A BREACH BY OWNER OF ITS OBLIGATIONS UNDER Section 6.2 , Article X OR Section 11.2 ), IN EACH CASE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OF THIS AGREEMENT, AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY).
FOR THE AVOIDANCE OF DOUBT, THE PARTIES ACKNOWLEDGE AND AGREE THAT Section 4.4 OR Section 7.3 PROVIDE THE SOLE AND EXCLUSIVE REMEDIES FOR ANY LOSS OF USE CONTEMPLATED BY Section 4.4 OR Section 7.3 AND NOTHING IN Section 6.2 , Article X OR Section 11.2 SHALL SUPERSEDE, SUPPLEMENT OR AMEND SUCH SOLE AND EXCLUSIVE REMEDIES.
THIS Article XVIII IS IN ADDITION TO THE SPECIFIC LIMITATIONS ON REMEDIES REFERENCED IN Article XIV , Section 4.4.1 AND Section 4.4.2 .
OWNER ACKNOWLEDGES THAT (A) PURCHASER (OR ITS AFFILIATES) MAY BE A PROPONENT OF OR PARTICIPATE IN OTHER BIDS WITH OTHER TRANSMISSION DEVELOPERS IN RESPONSE TO THE RFP (“ ADDITIONAL BIDS ”), EITHER ON ITS OWN OR WITH ONE OR MORE THIRD PARTIES AND (B) PURCHASER SHALL NOT BE LIABLE TO OWNER FOR ANY PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE, INCLUDING LOST PROFITS, IN EACH CASE, ARISING FROM OR RELATING TO ANY ADDITIONAL BIDS (INCLUDING IF ANY ADDITIONAL BIDS ARE SELECTED PURSUANT TO THE RFP), AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY). OWNER ACKNOWLEDGES AND AGREES THAT AS PART OF PURCHASER’S PARTICIPATION IN ADDITIONAL BIDS, PURCHASER SHALL EMPLOY MATERIALLY SIMILAR LANGUAGE IN DOCUMENTS PREPARED PURSUANT TO ADDITIONAL BIDS, FOR WHICH NO LIABILITY OR OBLIGATION OF ANY KIND, INCLUDING FOR COMPENSATION, SHALL BE IMPOSED UPON PURCHASER.
PURCHASER ACKNOWLEDGES THAT (A) OWNER (OR ITS AFFILIATES) MAY BE A PROPONENT OF OR PARTICIPATE IN OTHER BIDS WITH OTHER GENERATION DEVELOPERS IN RESPONSE TO THE RFP, EITHER ON ITS OWN OR WITH ONE OR MORE THIRD PARTIES AND (B) OWNER SHALL NOT BE LIABLE TO PURCHASER
61
FOR ANY PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE, INCLUDING LOST PROFITS, IN EACH CASE ARISING FROM OR RELATING TO ANY SUCH OTHER BIDS (INCLUDING IF ANY SUCH OTHER BID IS SELECTED PURSUANT TO THE RFP) AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY). PURCHASER ACKNOWLEDGES AND AGREES THAT AS PART OF OWNER’S PARTICIPATION IN OTHER BIDS, OWNER MAY EMPLOY MATERIALLY SIMILAR LANGUAGE IN DOCUMENTS PREPARED PURSUANT TO OTHER BIDS, FOR WHICH NO LIABILITY OR OBLIGATION OF ANY KIND, INCLUDING FOR COMPENSATION, SHALL BE IMPOSED UPON OWNER.
Article XIX
MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES.
Section 19.1 Modifications . The Parties specifically intend and acknowledge and agree that, except as otherwise expressly provided in this Agreement, (a) this Agreement shall not be subject to amendment or other modification, absent the written agreement of both Parties and (b) neither Party shall be permitted to make a filing with FERC under any provision of the Federal Power Act or the regulations promulgated thereunder that seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement at any time during the Term, except to implement an amendment or other modification to this Agreement that has been reduced to writing and signed by both Parties. In addition, to the extent any third party, or FERC acting sua sponte , seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement, the standard of review for any proposed amendment or other modification shall be the “public interest” standard of review set forth in United Gas Pipe Line Co. v. Mobile Gas Service Corp ., 350 U.S. 332 (1956), and Federal Power Commission v. Sierra Pacific Power Co ., 350 U.S. 348 (1956), and as further defined in Morgan Stanley Capital Group, Inc. v. Public Utility District No. 1 of Snohomish County , 128 S. Ct. 2733 (2008) and NRG Power Marketing, LLC v. Maine Public Utilities Commission , 130 S. Ct. 693 (2010).
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment .
(a) This Agreement is subject to the ISO-NE Rules. If, during the Term, any ISO-NE Rule is terminated, modified or amended, or is otherwise no longer applicable, resulting in a material alteration of a material right or obligation of a Party hereunder, the Parties agree to negotiate in good faith in an attempt to amend or clarify this Agreement to embody the Parties’ original intent regarding their respective rights and obligations under this Agreement; provided that neither Party shall have any obligation to agree to any particular amendment or clarification of this Agreement. The intent of the Parties is that any such amendment or clarification reflect, as closely as possible, the intent, substance and effect of the ISO-NE Rule being replaced, modified, amended or made inapplicable as such ISO-NE Rule was in effect prior to such termination,
62
modification, amendment or inapplicability; provided that such amendment or clarification shall not in any event alter (i) the purchase and sale obligations of the Parties pursuant to this Agreement or (ii) the Transmission Service Payment. In the event the Parties cannot agree upon such amendments within sixty (60) days after such ISO-NE Rule or ISO-NE Practice change described above, the Dispute shall be resolved in accordance with Article XVII .
(b) If, during the Term, there is a change in Applicable Law (other than tax laws or regulations) or accounting standards or rules or a change in the interpretation or applicability thereof that would result in a (A) material adverse balance sheet or creditworthiness impacts on Purchaser associated with this Agreement or the amounts paid for Firm Transmission Service purchased hereunder, or (B) an adverse impact on the economic benefits (including those stemming from the fiscal conditions provided for herein) that any Party enjoys under this Agreement or that are provided for herein for any Party during the Term, the Parties shall use commercially reasonable efforts to agree to an amendment to the Agreement to avoid or mitigate such impacts and restore the economic benefits to each affected Party; provided that such amendment mitigates any material adverse effect(s) on each non-affected Party (as identified by each such Party, acting reasonably) that could reasonably be expected to result from such amendment, but only to the extent that such mitigation can be accomplished in a manner that is consistent with the purpose of such amendment. In the event the Parties cannot agree on an amendment in accordance with this Section 19.2(b) , the Dispute shall be resolved in accordance with Article XVII .
(c) Upon a determination by a court or regulatory body having jurisdiction over this Agreement or any of the Parties, or over the establishment and enforcement of any of the statutes or regulations or orders or actions of regulatory agencies (including the MDPU) supporting this Agreement or the rights or obligations of the Parties hereunder that any of the statutes or regulations supporting this Agreement or the rights or obligations of the Parties hereunder, or orders of or actions of regulatory agencies (including the MDPU) implementing such statutes or regulations, or this Agreement on its face or as applied, violates any Applicable Law (including the State or Federal Constitution) (an “ Adverse Determination ”), each Party shall have the right to suspend performance under this Agreement without liability. Owner may provide transmission service to a third party during any period of time for which Purchaser suspends payments under this Section 19.2(c) . Upon an Adverse Determination becoming final and non-appealable, this Agreement shall be rendered null and void.
(d) For the avoidance of doubt, it is understood that the provisions of Article XVII regarding dispute resolution apply to any Dispute under this Article XIX .
63
INDEMNIFICATION
Section 20.1 Purchaser Indemnity . Purchaser shall indemnify, defend and hold harmless Owner and Owner’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, an “ Owner Indemnified Party ”) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Owner Indemnified Party, and arising out of the negligence, willful misconduct or criminal misconduct of Purchaser or its agents. Purchaser shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Owner Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, an Owner Indemnified Party. This Section 20.1 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPA, the Additional PPAs, the Distribution Company TSA or the Additional RFP Sponsor TSAs.
Section 20.2 Owner Indemnity . Owner shall indemnify, defend and hold harmless Purchaser and Purchaser’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives and permitted successors and assigns (each, a “ Purchaser Indemnified Party ”) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party, including any such liabilities incurred by a Purchaser Indemnified Party under the PPA, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents, including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Purchaser Indemnified Party. This Section 20.2 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPA, the Additional PPAs, the Distribution Company TSA or the Additional RFP Sponsor TSAs.
64
Section 20.3 [Intentionally Omitted] .
Section 20.4 Procedures . Promptly after the receipt by any Person seeking indemnification under this Article XX (the “ Indemnified Party ”) of written notice of the assertion of any claim by a third party with respect to any matter in respect of which indemnification may be sought hereunder (a “ Third Party Claim ”), the Indemnified Party shall give written notice (the “ Indemnification Notice ”) to the Party from which indemnification is sought (the “ Indemnifying Party ”), and shall thereafter keep the Indemnifying Party reasonably informed with respect thereto; provided, however, that the failure of the Indemnified Party to give the Indemnifying Party notice as provided herein shall not relieve the Indemnifying Party of any of its obligations hereunder, except to the extent that the Indemnifying Party is materially prejudiced by such failure. The Indemnifying Party shall be entitled to assume the defense of any Third Party Claim by written notice to the Indemnified Party of such intention given within thirty (30) days after the receipt by the Indemnifying Party of the Indemnification Notice; provided , however , that counsel selected by the Indemnifying Party shall be reasonably satisfactory to the Indemnified Party. The Indemnifying Party shall be liable for the fees and expenses of counsel employed by the Indemnified Party for any period during which the Indemnifying Party has not assumed the defense of any Third Party Claim (other than during any period during which the Indemnified Party has failed to give notice of such Third Party Claim as provided above). If the Indemnifying Party shall assume the defense of the Third Party Claim, then the Indemnifying Party shall not compromise or settle such Third Party Claim without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld, delayed or conditioned; provided , however , that the Indemnified Party shall have no obligation to consent to any settlement that (a) does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff of a release of the Indemnified Party from all liability with respect to such Third Party Claim or (b) involves the imposition of equitable remedies or the imposition of any material obligations on such Indemnified Party other than financial obligations for which such Indemnified Party is indemnified hereunder. As long as the Indemnifying Party is contesting any such Third Party Claim on a timely basis, the Indemnified Party shall not pay, compromise or settle any claims brought under such Third Party Claim. Notwithstanding the assumption by the Indemnifying Party of the defense of any Third Party Claim as provided in this Section 20.4 , the Indemnified Party shall be permitted to participate in the defense of such Third Party Claim and to employ counsel at its own expense (it being understood that the Indemnifying Party controls such defense); provided , however , that, if the defendants in any Third Party Claim shall include both an Indemnifying Party and any Indemnified Party, and such Indemnified Party shall have reasonably concluded that counsel selected by the Indemnifying Party has a conflict of interest because of the availability of different or additional defenses to such Indemnified Party, such Indemnified Party shall then have the right to select separate counsel to participate in the defense of such Third Party Claim on its behalf, at the expense of the Indemnifying Party; provided that the Indemnifying Party shall not be obligated to pay the expenses of more than one separate counsel for all Indemnified Parties, taken together.
Section 20.5 Defenses . If the Indemnifying Party shall fail to notify the Indemnified Party of its desire to assume the defense of any Third Party Claim within the prescribed period of time, or shall notify the Indemnified Party that it will not assume the defense of any such Third Party Claim, then the Indemnified Party may assume the defense of any such Third Party Claim, in which case it may do so acting in good faith and otherwise in such manner as it may deem appropriate, and the Indemnifying Party shall be bound by any determination made in such Third Party Claim.
65
Section 20.6 Cooperation . The Indemnified Party and the Indemnifying Party shall each cooperate fully (and shall each cause its Affiliates to cooperate fully) with the other in the defense of any Third Party Claim pursuant to this Article XX . Without limiting the generality of the foregoing, each such Person shall furnish the other such Person (at the expense of the Indemnifying Party) with such documentary or other evidence as is then in its or any of its Affiliates’ possession, as may reasonably be requested by the other Person for the purpose of defending against any such Third Party Claim.
Section 20.7 Recovery . The amount of any indemnity hereunder shall be reduced by any insurance proceeds actually recovered by the Indemnified Party in connection with the Third Party Claim. If at any time subsequent to the receipt by an Indemnified Party of an indemnity payment hereunder, such Indemnified Party (or any Affiliate thereof) receives any recovery, settlement or other similar payment with respect to the Third Party Claim for which it received such indemnity payment (a “ Recovery ”), such Indemnified Party shall then promptly pay to the Indemnifying Party the amount of such Recovery, less any expenses incurred by such Indemnified Party (or its Affiliates) in connection with such Recovery, but in no event shall any such payment exceed the amount of such indemnity payment.
Section 20.8 Subrogation . To the extent the Indemnifying Party makes or is required to make any indemnity payment to the Indemnified Party, the Indemnifying Party shall be entitled to exercise, and shall be subrogated to, any rights and remedies (including rights of indemnity, rights of contribution and other rights of recovery) that the Indemnified Party or any of its Affiliates may have against any other Person with respect thereto, whether directly or indirectly related. The Indemnified Party shall permit the Indemnifying Party to use the name of the Indemnified Party and the names of the Indemnified Party’s Affiliates in any transaction or in any proceeding or other matter involving any of such rights or remedies; and the Indemnified Party shall take such actions as the Indemnifying Party may reasonably request for the purpose of enabling the Indemnifying Party to perfect or exercise its right of subrogation hereunder.
Article XXI
REPRESENTATIONS, WARRANTIES AND COVENANTS
Section 21.1 Mutual Representations and Warranties . Each Party hereby represents and warrants to the other Party that all of the statements in this Section 21.1 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of (i) the Effective Date, (ii) the Commercial Operation Date and (iii) the start of the Purchaser Term , but not as of any other date:
(a) It has knowledge and experience in financial matters and in the electric industry that enable it to evaluate the merits and risks of this Agreement and the transactions contemplated hereby, and is capable of evaluating such merits and risks and assuming such risks. It is acting for its own account, has made its own independent decision to enter into this Agreement as to whether this Agreement is appropriate and proper for it based upon its own judgment, is not relying upon the advice or recommendations of the other Party in doing so, and understands and accepts the terms, conditions, and risks of this Agreement and the transactions contemplated hereby;
66
(b) It has entered into this Agreement in connection with the conduct of its business;
(c) It is not acting as a fiduciary or an advisor with respect to this Agreement or the transactions contemplated hereby;
(d) It is not subject to an Insolvency Event and there are no proceedings pending or being contemplated by it or, to its knowledge, threatened against it that could result in the occurrence of an Insolvency Event with respect to it; and
(e) It is an entity subject to the procedures and substantive provisions of the Bankruptcy Code applicable to U.S. corporations or limited liability companies, as applicable, generally.
Section 21.2 Additional Representations and Warranties of Purchaser . Purchaser hereby represents and warrants to Owner that all of the statements in this Section 21.2 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Purchaser is duly organized, validly existing, and in good standing under the laws of the State of Delaware and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Purchaser, and Purchaser has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Purchaser has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Purchaser;
(c) Assuming due authorization, execution and delivery by Owner, this Agreement constitutes Purchaser’s legal, valid and binding obligation enforceable against Purchaser in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Purchaser or any of its Affiliates that could have a Material Adverse Effect on Purchaser;
(e) No event with respect to Purchaser has occurred or is continuing that would constitute a Purchaser Default, and no Purchaser Default will occur as a result of Purchaser entering into or performing its obligations under this Agreement;
67
(f) The execution, delivery and performance of this Agreement by Purchaser does not and will not (i) violate any provisions of its certificate of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) To the best of Purchaser’s knowledge, the Canadian Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary for TransÉnergie to commence construction of and to own and operate the Québec Line in a manner consistent with Attachment A and this Agreement; and
(h) Purchaser is in compliance with all Applicable Laws, except such noncompliance as could not reasonably be expected to have a Material Adverse Effect on Purchaser. Purchaser has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Purchaser.
Section 21.3 Additional Representations and Warranties of Owner . Owner hereby represents and warrants to Purchaser that all of the statements in this Section 21.3 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Owner is duly organized, validly existing, and in good standing under the laws of the State of Maine and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Owner, and Owner has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Owner has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Owner;
(c) Assuming due authorization, execution and delivery by Purchaser, this Agreement constitutes Owner’s legal, valid and binding obligation enforceable against Owner in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Owner or any of its Affiliates that could have a Material Adverse Effect on Owner;
(e) No event with respect to Owner has occurred or is continuing that would constitute an Owner Default, and no Owner Default will occur as a result of Owner entering into or performing its obligations under this Agreement;
68
(f) The execution, delivery and performance of this Agreement by Owner does not and will not (i) violate any provisions of its articles of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The FERC Authorization, the Owner Approvals (other than the Municipal Owner Approvals) and the AC Upgrade Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary to commence construction of and operate the NECEC Transmission Line (other than the Municipal Owner Approvals);
(h) To the best of Owner’s knowledge, the Municipal Owner Approvals identified in paragraph 10 of Attachment C constitute all of the Municipal Owner Approvals that are necessary to commence construction of and operate the NECEC Transmission Line;
(i) Owner is in compliance with all Applicable Laws, except such noncompliance as could not reasonably be expected to have a Material Adverse Effect on Owner. Owner has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Owner; and
(j) Owner has acquired all required real property rights necessary for construction and operation of the NECEC Transmission Line, and the interconnection of the NECEC Transmission Line with (A) the Québec Line (other than real property rights to be held by TransÉnergie) and (B) the Delivery Point, in full and final form with all options or contingencies having been exercised as set forth in Attachment I .
Section 21.4 [Intentionally Omitted] .
Section 21.5 NO OTHER REPRESENTATIONS OR WARRANTIES . THE REPRESENTATIONS AND WARRANTIES OF OWNER SET FORTH IN Section 21.1 AND Section 21.3 ARE OWNER’S SOLE REPRESENTATIONS AND WARRANTIES ASSOCIATED WITH THE NECEC TRANSMISSION LINE AND ARE MADE IN LIEU OF ALL OTHER REPRESENTATIONS, WARRANTIES AND GUARANTEES, EXPRESS OR IMPLIED, ASSOCIATED WITH THE NECEC TRANSMISSION LINE, INCLUDING REPRESENTATIONS OR WARRANTIES AS TO MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE. THE FOREGOING SENTENCE SHALL NOT BE CONSTRUED IN ANY WAY TO LIMIT OWNER’S EXPRESS OBLIGATIONS UNDER THIS AGREEMENT.
69
TRANSFER OF INTERESTS
Section 22.1 No Transfer of Interests .
(a) Any (i) direct or indirect change of Control of any Party (whether voluntary or by operation of law), (ii) sale, transfer or other disposition of all or substantially all of the assets of any Party or (iii) except as provided in Section 22.2 or Section 22.3 , assignment, transfer or other disposition of, whether to one or more assignees or transferees, all or any portion of any Party’s rights, interests or obligations under this Agreement (each of the foregoing, a “ Transfer ”), shall require the prior written consent of the other Party, which consent shall not be unreasonably withheld, delayed or conditioned when viewed in light of all reasonable considerations, including the security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer); provided that any direct or indirect transfer of securities or other ownership interests in a Party to a Person Controlled by a Party’s ultimate parent company (for Purchaser, currently Hydro-Québec, and for Owner, currently Iberdrola, S.A.), as applicable, shall not be considered a Transfer for the purposes of this Section 22.1(a) and shall not require consent. Any Transfer in contravention of this Article XXII shall be null and void. The Parties agree that the provision by or for the account of an assignee or transferee of any Party of Additional Credit Support in an amount equal to the Maximum Amount provided under, and as defined in, the Hydro-Québec Guaranty, as such Maximum Amount may vary from time to time, shall be deemed to satisfy the criterion set forth herein with respect to security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer).
(b) If Owner consents to a Transfer by Purchaser pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Purchaser’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Owner of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that a Purchaser Default shall not have occurred and be continuing, (x) the obligations of Purchaser shall terminate to the extent of the Transferred portion of this Agreement, and Purchaser shall be fully, finally, and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Purchaser, Owner shall execute and deliver to Purchaser a full, final, and unconditional release of any credit support or guarantees provided by Purchaser, in such form as Purchaser may reasonably request, with respect to the Transferred portion of this Agreement.
70
(c) If Purchaser consents to a Transfer by Owner pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Owner’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Purchaser of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that an Owner Default shall not have occurred and be continuing, (x) the obligations of Owner shall terminate to the extent of the Transferred portion of this Agreement, and Owner shall be fully, finally, and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Owner, Purchaser shall execute and deliver to Owner a full, final, and unconditional release of any credit support or guarantees provided by Owner hereunder, in such form as Owner may reasonably request, with respect to the Transferred portion of this Agreement.
(d) [Intentionally Omitted].
(e) Nothing herein shall prevent Purchaser or any assignee thereof from transferring or assigning transmission service rights pursuant to FERC rules and regulations.
Section 22.2 Exceptions . Notwithstanding Section 22.1 , consent shall not be required for any of the following:
(a) an assignment by Purchaser to any of its Affiliates; provided that Hydro-Québec confirms in a writing satisfactory to Owner that the Hydro-Québec Guaranty applies with respect to the assignee’s obligations under this Agreement;
(b) [intentionally omitted];
(c) any (i) change of Control of Owner or (ii) transfer or other disposition of all or substantially all of the assets of Owner, in each case, resulting from a collateral assignment in favor of a financing party in accordance with Section 22.3 ;
(d) any change of Control of Owner resulting from any direct or indirect change of Control in Owner’s ultimate parent company (currently Iberdrola, S.A.), Owner’s ultimate parent company in the United States (currently AVANGRID, Inc.) or in the parent company for the network business in the United States of which Owner is part (currently Avangrid Networks, Inc.);
(e) any change of Control of Purchaser resulting from the direct or indirect transfer of interests in Hydro-Québec; or
(f) the exercise of any of Purchaser’s rights pursuant to Section 14.7 , 14.8(a) or 14.8(b) .
71
Section 22.3 Collateral Assignment . Owner shall be entitled, without restriction, to make one or more assignments of this Agreement for purposes of collateral security or any or all of its rights and benefits hereunder to or for the benefit of any and all secured lenders to Owner, or grant to or for the benefit of any and all secured lenders to Owner a lien on, or security interest in, any right, title or interest in all or any part of Owner’s rights hereunder for the purpose of the financing or successive refinancing of the ownership, development, engineering, construction or operation of the NECEC Transmission Line; provided , however , that such assignment for purposes of collateral security shall recognize Purchaser’s rights under this Agreement on terms and conditions as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner. To facilitate Owner’s obtaining of financing or successive refinancing for the ownership, development, engineering, construction or operation of the NECEC Transmission Line, Purchaser shall cooperate with Owner and shall execute and deliver such consents, acknowledgements, direct agreements or similar documents as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner.
Article XXIII
MISCELLANEOUS
Section 23.1 Governing Law . This Agreement and each of its provisions shall be governed by, and construed in accordance with, the laws of the Commonwealth of Massachusetts.
Section 23.2 Entire Agreement . This Agreement, together with the Attachments, constitutes the entire Agreement and understanding between the Parties with respect to all subjects covered hereby and thereby and supersedes all prior discussions, agreements and understandings between the Parties with respect to such matters. Notwithstanding the foregoing, each Party is subject to obligations under different Proposal Agreements.
Section 23.3 Severability . Except as otherwise provided in Section 2.2 or Section 19.2 , (a) in the event any part of this Agreement is held to be illegal, invalid or unenforceable to any extent, the legality, validity and enforceability of the remainder of this Agreement shall not be affected thereby, and shall remain in full force and effect and shall be enforced to the greatest extent permitted by Applicable Law and (b) with respect to any provision found to be illegal, invalid or unenforceable, the Parties shall endeavor to replace such invalid, illegal or unenforceable provision with the valid, legal and enforceable provision that achieves, as nearly as practicable, the commercial intent of this Agreement (as it may be amended from time to time).
Section 23.4 Notices . All notices, billings, requests, demands, waivers, consents and other communications under this Agreement shall be in writing and shall be effective (a) upon personal delivery thereof, including by overnight mail or courier service, with a record of receipt, (b) in the case of notice by United States mail, certified or registered, postage prepaid, return receipt requested, upon the fourth (4th) day after mailing, (c) in the case of notice by facsimile for any communications other than billings, upon transmission; provided that such facsimile transmission is promptly confirmed by either of the methods set forth in the foregoing clause (a) or (b), in each case, addressed to each Party and copy party hereto at its address set forth below or at such other address as a Party may from time to time designate by written notice to the other Party pursuant to this Section 23.4 , (d) in the case of notice by facsimile for billings only (but not
72
any other communication, including any subsequent demand notice for any unpaid amounts), upon receipt of confirmation of successful transmission, but without any further requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b), or (e) in the case of notice by electronic mail for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon transmission, without any requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b); provided that the Party delivering such notice did not receive any notice of unsuccessful or delayed transmission. A notice given in connection with this Section 23.4 but received on a day other than a Business Day, or after business hours at the location of receipt, shall be deemed to be received on the next Business Day.
If to Owner: |
|
|
Central Maine Power Company |
|
Attn: Douglas Herling, President & CEO |
|
83 Edison Drive, Augusta ME 04336 |
|
207-626-9779 |
|
|
With a copy to: |
|
|
Central Maine Power Company |
|
Attn: Legal Department |
|
83 Edison Drive, Augusta ME 04336 |
|
|
With a further copy to: |
|
|
Pierce Atwood LLP |
|
Attn: Jared des Rosiers |
|
254 Commercial St., Portland ME 04101 |
|
|
If to Purchaser: |
|
|
H.Q. Energy Services (U.S.) Inc. |
|
75, René-Lévesque Boulevard West, 18th Floor |
|
Montréal (Québec) Canada |
|
H2Z 1A4 |
|
Attention: President |
|
Facsimile: (514) 289-6723 |
Section 23.5 Waiver; Cumulative Remedies . Any term or condition of this Agreement may be waived at any time by the Party that is entitled to the benefit thereof, but such waiver shall not be effective unless set forth in a written instrument duly executed by or on behalf of the Party waiving such term or condition. No waiver by any Party of any term or condition of this Agreement, in any one or more instances, shall be deemed to be, or construed as, a subsequent waiver of, or estoppel with respect to, the same or any other term or by Applicable Law. Except as otherwise provided in Section 13.2(b) , the failure of or delay on the part of any Party to enforce or insist upon compliance with or strict performance of any term or condition of this Agreement, or to take advantage of any of its rights thereunder, shall not constitute a waiver or relinquishment of any such terms, conditions, or rights, but the same shall be and remain at all times in full force and effect. Except as otherwise provided herein, the remedies provided in this Agreement are cumulative and not exclusive of any remedies provided by law or in equity.
73
Section 23.6 Confidential Information . Each Party hereby agrees that it shall not disclose, or cause to be disclosed, to third parties any Confidential Information with respect to the other Party or any material or information identified as Critical Energy Infrastructure Information (other than to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential). Notwithstanding the foregoing, each Party may disclose information related to this Agreement to another party to a Proposal Agreement or to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential, only if necessary to comply with its obligations hereunder or thereunder or to coordinate the parties’ obligations under different Proposal Agreements. Each Party shall be responsible for ensuring that any Person to whom it discloses any Confidential Information shall comply with the restrictions in this Section 23.6 . The restrictions in this Section 23.6 shall not apply (w) to the extent disclosure is required by Applicable Law or the requirements of a Governmental Authority (including a court order, oral questions, written interrogatories, request for information or documents, subpoena or similar process, or the requirements of any stock exchange or other Governmental Authority to which the Parties, or any of their Affiliates are subject), (x) to the extent reasonably deemed by the disclosing Party to be required or desirable in connection with regulatory proceedings (including proceedings relating to FERC or any other national, federal, provincial, state or regulatory agency), (y) to the extent reasonably deemed by the disclosing Party to be required to be disclosed in connection with a Dispute between the Parties, or the defense of any litigation or dispute, or (z) as approved for release or disclosure by the Party whose Confidential Information is at issue. In the event disclosure is made pursuant to this Section 23.6 , and except for disclosures pursuant to the requirements of securities laws or any stock exchange, the disclosing Party shall use reasonable efforts to minimize the scope of any disclosure and advise recipients of any applicable confidentiality restrictions provided herein. Notwithstanding the foregoing, this Section 23.6 shall not apply to the following information:
(a) Information that is a matter of public knowledge at the time of its disclosure or is thereafter published in or otherwise ascertainable from a source available to the public without breach of this Section 23.6 ;
(b) Information that is obtained from a Person other than by or as a result of unauthorized disclosure; or
(c) Information that, prior to the time of disclosure, had been independently developed or obtained by the disclosing Party or its Affiliates independent of information obtained as a result of unauthorized disclosure.
Section 23.7 No Third-Party Rights . Except for any secured lenders contemplated by Section 22.3 and any Owner Indemnified Party or Purchaser Indemnified Party contemplated by Article XX , the Parties do not intend for this Agreement to confer a third-party beneficiary status or rights of action upon any Person whatsoever other than the Parties and their permitted successors and assigns, and nothing contained herein, either express or implied, shall be construed to confer upon any Person, other than the Parties and their permitted successors and assigns, any rights of action or remedies under this Agreement or in any manner, or any duty, standard of care, or liability with respect thereto. This Agreement does not create any third-party rights, except as expressly stated above in this Section 23.7 .
74
Section 23.8 Permitted Successors and Assigns . This Agreement shall be binding upon and inure to the benefit of each of the Parties and their permitted successors, legal representatives and assigns.
Section 23.9 Relationship of the Parties . This Agreement shall not be construed as creating an association, joint venture, trust or partnership between the Parties or as imposing any partnership obligation or liability upon either Party. Except as contemplated by Article X or Section 14.7 , neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.
Section 23.10 Construction . No presumption shall operate in favor of or against either Party as a result of any responsibility for drafting this Agreement.
Section 23.11 Counterparts . This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument. The Parties acknowledge and agree that any document or signature delivered by facsimile or electronic transmission shall be deemed to be an original executed document for all purposes hereof.
Section 23.12 Survival . The provisions of Section 3.3 , Section 3.4 , Article IX , Article XIII , Article XIV , Article XVII , Article XVIII , Article XIX , Article XX and this Article XXIII shall survive the expiration or earlier termination of this Agreement.
Section 23.13 Language . All notices, requests, demands, waivers, consents and other communications between Owner and Purchaser under this Agreement shall be conducted in English.
Section 23.14 Headings and Table of Contents . The headings of the articles and sections of this Agreement and the Table of Contents are inserted for purposes of convenience only, and shall not be construed to affect the meaning or construction of any of the provisions hereof.
Section 23.15 Waiver of Immunities . The Parties acknowledge and agree that this Agreement and the transactions contemplated hereby constitute a commercial transaction. To the extent a Party (including any assignees of a Party’s rights or obligations under this Agreement) may be entitled, in any jurisdiction, to claim for itself, or any of its assets, revenues or properties, sovereign or other immunity, as the case may be, from service of process, suit, the jurisdiction of any court or arbitral tribunal, attachment (whether in aid of execution or otherwise) or enforcement of a judgment (interlocutory or final) or award or any other legal process in a matter arising out of or relating to this Agreement, each Party agrees not to claim or assert, and hereby waives, such immunity. Without limiting the generality of the foregoing, each Party agrees that the waivers set forth in this Section 23.15 shall have the fullest scope permitted under the Immunities Act and under any other Applicable Law related to sovereign immunity.
[Signature pages follow]
75
IN WITNESS WHEREOF , Owner and Purchaser have executed this Agreement as of the Execution Date.
OWNER:
CENTRAL MAINE POWER COMPANY
By: |
|
/s/ Douglas Herling |
Name: |
|
Douglas Herling |
Title: |
|
President & CEO |
By: |
|
/s/ Eric N. Stinneford |
Name: |
|
Eric N. Stinneford |
Title: |
|
Vice President, Controller, Treasurer & Clerk |
PURCHASER:
H.Q. ENERGY SERVICES (U.S.) INC.
By: |
|
/s/ David Murray |
Name: |
|
David Murray |
Title: |
|
Chairman of the Board and President |
1
Description of Transmission Projects
The Québec Line and the NECEC Transmission Line consist in their entirety of:
|
(1) |
New 207 mile (145.3 miles in Maine) +/- 320 kV overhead HVDC transmission line that will run between the existing Appalaches Substation in Thetford Mines, Québec and a new HVDC converter station approximately 1.6 miles from the existing Larrabee Road Substation in Lewiston, Maine; |
|
(2) |
New HVDC converter stations at both ends of the transmission line; and |
|
(3) |
Certain upgrades to the existing high voltage alternating current (AC) New England transmission system necessary to permit the interconnection and transmission of Hydro Generation to the New England Control Area (as defined in the ISO-NE Tariff) at the existing Larrabee Road substation under the requirements of Section I.3.9 and the CCIS of ISO-NE Tariff. |
|
(4) |
System upgrades to the existing Québec transmission system as determined by the Hydro-Québec TransÉnergie System Impact Study (OASIS #203T), as it may be updated. |
Owner is the developer of the portion of the NECEC Transmission Line from the Québec-Maine border to the Lewiston area and all transmission upgrades on the U.S. side of the border. The NECEC Transmission Line and the Québec Line are expected to connect at the Québec-Maine border in the northwest corner of Maine in Beattie Township.
The Québec Line will be constructed by TransÉnergie, a division of Hydro-Québec and an Affiliate of Purchaser.
Owner will construct, own, operate and maintain the NECEC Transmission Line, which will be constructed in existing transmission corridors owned by Owner.
The NECEC Transmission Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 145.3 mile +/-320 kV HVDC transmission line from the Canadian Border to a new converter substation located on Merrill Road in Lewiston |
|
ii. |
New 1.6 mile 345 kV AC transmission line from the new Merrill Road converter substation to the existing Larrabee Road substation |
|
i. |
New 345 kV AC to +/-320 kV HVDC 1200 MW Merrill Road converter substation |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Larrabee Road substation |
|
(2) |
Network Upgrades (subject to change based on ISO-NE system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
New 26.5 mile 345 kV AC transmission line from the existing Coopers Mills substation in Windsor to the existing Maine Yankee substation in Wiscasset |
|
ii. |
New 0.3 mile 345 kV AC transmission line from the existing Surowiec substation in Pownal to a new substation on Fickett Road in Pownal |
|
iii. |
Rebuild 9.3 mile 115 kV Section 62 AC transmission line from the existing Crowley Road substation in Sabattus to the existing Surowiec substation |
|
iv. |
Rebuild 16.1 mile 115 kV Section 64 AC transmission line from the existing Larrabee Road substation to the existing Surowiec substation |
|
v. |
Partial rebuild of 0.8 mile each of 115 kV Section 60/88 outside Coopers Mills substation |
|
vi. |
Partial rebuild of 0.3 miles of 345 kV Section 392 AC transmission line between the Coopers Mills substation and the Maine Yankee substation and approximately 3.5 miles of reconductor work on existing double circuit lattice steel towers outside of the Maine Yankee substation |
|
vii. |
Partial rebuild of 0.3 miles of 345 kV Section 3025 between Coopers Mills substation and Larrabee Road substation |
|
viii. |
Partial rebuild 0.8 miles of 34.5 kV Section 72 AC transmission line outside of the Larrabee Road substation |
|
i. |
Replace existing Larrabee Road 345/115 kV 448 MVA autotransformer with a 600 MVA autotransformer |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Maine Yankee substation |
|
iii. |
Add 345 kV AC transmission line terminal and 115 kV switch replacements at the existing Surowiec substation |
|
iv. |
115 kV Switch and bus wire replacements at Crowley substation |
|
v. |
New 345 kV Fickett Road substation with 345 kV +/-200 MVAr Static Compensator (STATCOM) |
|
vi. |
Add 345 kV AC transmission line terminal and additional 345 kV +/-200 MVAr STATCOM (+/-400 MVAr total with the +/-200 MVAr existing) at the existing Coopers Mills substation |
|
vii. |
Add 345/115 kV 448 MVA autotransformer, associated 115 kV buswork and terminate existing 115 kV Sections 164, 164A and 165 into three new breaker-and-a-half bays at the existing Raven Farm substation |
The NECEC transmission components located in Maine are depicted geographically in relationship to the existing Owner transmission system in Figure 1 below.
Figure 1 – Map Depicting the Components of the NECEC Transmission Line
The Québec Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 65 mile +/-320 kV HVDC transmission line from the Appalaches substation located in Thetford Mines to the U.S. border |
|
b. |
Substation Equipment : |
|
i. |
New +/-320 kV, 1200 MW HVDC converter connected to the 735 kV AC bus of the Appalaches substation and associated 735 kV bus work |
|
(2) |
Network Upgrades (subject to change based on additional system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
Thermal upgrade of existing 735 kV lines 7005 and 7035 (68 miles from Lévis substation to Nicolet substation) |
|
ii. |
Thermal upgrade of existing 735 kV line 7049 (44 miles from Montérégie substation to Hertel substation) |
|
b. |
Substation Equipment: |
|
i. |
Add two 200 MVAr shunt capacitor banks at the Carignan substation |
|
ii. |
Add one 330 MVAr shunt reactor at the Carignan substation |
Attachment B
Critical Milestones
Item |
Critical Milestone* |
Due Date** |
1. |
Closing of Any Required Financing |
March 7, 2019 |
2. |
Receipt of all Owner Approvals (other than Municipal Owner Approvals) and AC Upgrade Approvals in Final Form |
December 14, 2019 |
3. |
Receipt of all Canadian Approvals |
March 11, 2021 |
4. |
Receipt of all Municipal Owner Approvals |
March 31, 2022 |
5. |
Execution of Contract with the Manufacturer of the Converter Station at the Southern End of the HVDC Line and associated minimum 5% contract value payment |
July 30, 2019 |
6. |
Execution of Contract for the Engineering, Procurement, or Construction of the Converter Station on the Québec Line |
July 30, 2019 |
7. |
Commercial Operation Date |
December 13, 2022 |
* As defined in Section 4.1(a)
** Subject to extension in accordance with the Agreement
Owner Approvals
Set forth below are the Governmental Approvals and Third Party Consents, in each case, required to commence construction of and operate the NECEC Transmission Line:
|
1. |
ISO-NE: Approval pursuant to Section I.3.9 of the ISO-NE Tariff to interconnect and operate the NECEC Transmission Line at no fewer than 1,040 MW |
|
2. |
Maine Public Utilities Commission (MPUC): Certificate of Public Convenience and Necessity (CPCN) |
|
3. |
U.S. Department of Energy (DOE): Presidential Permit |
|
4. |
Maine Department of Environmental Protection (MDEP): |
|
a. |
Site Location of Development Act (SLODA) Permit |
|
b. |
Stormwater Management Permit |
|
c. |
Natural Resources Protection Act (NRPA) Permit |
|
d. |
Clean Water Act (CWA) Section 401 Water Quality Certification |
|
e. |
Maine Construction General Permit |
The SLODA Permit, Stormwater Management Permit, NRPA Permit, and CWA Section 401 Water Quality Certification may be combined into one permit.
|
5. |
Maine Land Use Planning Commission (LUPC): Certificate of Compliance |
|
6. |
Maine Department of Agriculture, Conservation and Forestry: |
|
a. |
Submerged Lands Lease |
|
b. |
Public Reserved Land Lease |
|
7. |
Maine Department of Transportation (DOT): |
|
a. |
Utility Location/Road Opening Permits |
|
b. |
Driveway/Entrance Permits |
|
8. |
U.S. Army Corps of Engineers: |
|
a. |
CWA Section 404 - Individual Permit |
|
b. |
Section 10 Rivers & Harbors Act of 1899 |
|
9. |
Federal Aviation Administration Infrastructure in Vicinity of Airports: Determination of No Hazard to Air Navigation |
|
10. |
Municipal Owner Approvals: |
|
a. |
The Municipal Owner Approvals consist of the following types of permits: |
|
i. |
Shoreland zoning permits |
|
ii. |
Building permits |
|
iii. |
Flood hazard development permits |
|
v. |
Site plan / subdivision approvals |
|
vi. |
Driveway / entrance permits |
|
vii. |
Street opening, blasting and demolition permits |
|
viii. |
Utility location permits |
|
b. |
Owner shall obtain the Municipal Owner Approvals listed above that are necessary (if any) in the following municipalities for the NECEC Transmission Line, subject to any necessary exemptions issued by the MPUC relating to any Municipal Owner Approvals that are denied in any such municipalities or relating to any conditions contained in any Municipal Owner Approvals that are unacceptable to Owner: |
|
i. |
Alna |
|
ii. |
Lewiston |
|
iii. |
Anson |
|
iv. |
Livermore Falls |
|
v. |
Auburn |
|
vi. |
Moscow |
|
vii. |
Caratunk |
|
viii. |
New Gloucester |
|
ix. |
Chesterville |
|
x. |
New Sharon |
|
xi. |
Durham |
|
xii. |
|
|
|
xiii. |
Embden |
|
xiv. |
Starks |
|
xv. |
Farmington |
|
xvi. |
Whitefield |
|
xvii. |
Greene |
|
xviii. |
Wilton |
|
xix. |
Industry |
|
xx. |
Windsor |
|
xxi. |
Jay |
|
xxii. |
Wiscasset |
|
xxiii. |
Leeds |
|
xxiv. |
Woolwich |
Canadian Approvals
Set forth below are, to the best of Purchaser’s knowledge, the Governmental Approvals and Third Party Consents, in each case, required to commence construction of the Québec Line:
|
• |
Permit from the National Energy Board to construct, operate, maintain or connect an international power line pursuant to the National Energy Board Act (R.S. C., 1985, c. N-7); |
|
• |
Permit from the International Boundary Commission required to cross the Canada-U.S. border pursuant to Article 5 of the International Boundary Commission Act; |
|
• |
Authorization from the Régie de l’énergie to acquire, construct or dispose of transmission assets pursuant to an Act respecting the Régie de l’énergie (R.S.Q., chapter R-6.01); |
|
• |
Expropriation Order in council, if required, to acquire by expropriation any immovable, servitude or construction required for the transmission of power pursuant to Hydro-Québec Act (R.S.Q., chapter H-5) and the Expropriation act (R.S.Q., chapter E-24); |
|
• |
Certificate of authorization issued by the Government of Québec to construct the transmission line under Section 31.5 of the Environmental Quality Act subject to the environmental and social impact assessment and review procedure; |
|
• |
Certificate of authorization issued by the Ministère du Développement durable, de l’Environnement et de la Lutte contre les changements climatiques approving the plans and specifications of the transmission line pursuant to Section 22 of the Environmental Quality Act; |
|
• |
Authorization of the Commission de protection du territoire agricole du Québec , if required, approving the use of land situated in an agricultural zone for purposes other than agriculture under Sections 58 and 62 of the Act respecting the preservation of agricultural land and agricultural activities; |
|
• |
Opinion on project compliance with objectives of the city or regional county municipalities’ land-use and development plan. |
Attachment E
Owner’s Preliminary Project Schedule and Construction Schedule
Attachment F
Required Insurance
Owner shall obtain and maintain with qualified insurers authorized to issue insurance of the types described below in the State of Maine.
During construction of the NECEC Transmission Line Owner shall maintain or effect to be maintained the following insurance coverages:
|
• |
Primary and Excess Liability |
|
• |
Construction All Risk / Builders Risk |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
|
• |
Pollution / Environmental Liability |
After the Commercial Operation Date Owner shall provide coverage both in terms of scope and limits of coverage that are in accordance with Good Utility Practice and the long-standing practice of Owner. Operational coverage shall include the following insurance types:
|
• |
Excess Liability |
|
• |
Operational All Risk Property Damage |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
Note : At any time after the Commercial Operation Date Owner may choose, as far as it is consistent with Good Utility Practice, to self-insure on customary terms and conditions any coverage (or coverage part) where it meets any state or regulatory requirements of self-insurers.
Attachment G
Rate Adjustment Formula
In the event that a Transmission Service Payment is subject to reduction pursuant to Section 8.1 , such reduced payment shall equal the Transmission Service Payment that would otherwise be payable under the Agreement for a particular month multiplied by the lesser of 1 or the following fraction:
|
|
(Contract Capacity x 0.90) |
1 - |
|
minus (Contract Capacity x A) |
|
|
(Contract Capacity x 0.90) |
Where A = |
|
∑ Hourly Availability for all hours in such month |
|
∑ Hours in such month |
For purposes of calculating A, Excused Outages (for which Owner is paid full Transmission Service Payments pursuant to the terms of the Agreement) will be regarded as hours in which one hundred percent (100%) of Contract Capacity was provided.
Attachment H
Refund Calculation
This example is intended to illustrate the methodology for the calculation of a subsequent refund of a late payment. This example and the numbers used in this example are purely illustrative and are in no way intended to supersede any part of the Agreement, including Section 13.3 .
Assumptions
|
• |
Interest Rate = 12 percent per annum (compounded monthly) |
June 2043 Billing
Invoice Amount |
$1,000 |
Date of Invoice |
June 1, 2043 |
Due Date |
June 15, 2043 |
Payment Date |
July 1, 2043 |
The total amount due on the date of payment is $1,005, which amount is computed by adding $1,000 (the original amount invoiced) and $5 (the ½ month late interest fee).
Subsequent Refund
If later, on July 1, 2044, the aforesaid payment is required to be refunded, the refund will equal the $1,000 payment made on July 1, 2043 (the original amount invoiced), plus the interest accrued on that $1,000 payment from the due date of June 15, 2043 to the date of refund on July 1, 2044. To ensure that the refund does not double recover interest, the following language has been included in Section 13.3 of the Agreement: “[I]f all or a portion of the amount [ here, the $1,000 payment due on June 15, 2043 ] to which such interest relates [ here, the $5 late interest fee ] is later refunded pursuant to this Agreement [ here, on July 1, 2044 ], then, in calculating that refund, such interest [ here, $5 ] shall not be included in the refund.”
Attachment I
Real Estate Rights
Form of Purchaser Guaranty
See attached.
|
|
Hydro-Québec 75, boulevard René-Lévesque ouest 5 ième étage Montréal, Québec, Canada H2Z 1A4 |
|
CONVENTION DE CAUTIONNEMENT La présente convention de cautionnement (« Cautionnement »), portant la date du juin 2018, est conclue entre Hydro-Québec , société dûment constituée et régie par la Loi sur Hydro-Québec (L.R.Q., chapitre H-5) ayant son siège social et son principal lieu d’affaires au 75, boulevard René-Lévesque Ouest, Montréal, Québec, Canada, H2Z 1A4 (ci-après appelée « Caution »), et Central Maine Power Company, société dûment constituée en vertu des lois de l’État du Maine, ayant son principal lieu d'affaires au 83 Edison Drive, Augusta ME 04336, États-Unis d'Amérique (ci-après appelée « Bénéficiaire »). |
|
GUARANTY AGREEMENT This Guaranty Agreement («Guaranty»), dated as of June 2018, is made and entered into between Hydro-Québec , a body politic and corporate, duly incorporated and regulated by Hydro-Québec Act (R.S.Q., chapter H-5) and having its head office and principal place of business at 75, René-Lévesque Boulevard West, Montréal, Québec, Canada, H2Z 1A4, hereinafter referred to as the «Guarantor» and Central Maine Power Company, a corporation duly organized under the laws of the State of Maine, having its principal place of business at 83 Edison Drive, Augusta ME 04336, United States of America, (hereinafter referred to as the «Beneficiary»). |
|
ATTENDU QUE le Bénéficiaire et H.Q. ENERGY SERVICES (U.S.) INC. , société créée en vertu des lois de l’état du Delaware, ayant son lieu d’affaires au 225 Asylum Street, 27 th étage, Hartford, CT 06103 (ci-après appelée « HQUS »), filiale en propriété indirecte de la Caution, ont signé les ententes suivantes: (a) une entente de service de transport pour l’achat de 579.335 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (b) une entente de service de transport pour l’achat de 498.348 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (c) une entente de service de transport pour l’achat de 12.317 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (d) une entente de service de transport pour l’achat de 110 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018 (ci-après appelées collectivement les « Conventions »); |
|
WHEREAS the Beneficiary and H.Q. ENERGY SERVICES (U.S.) INC., a corporation created under the laws of the State of Delaware, having its place of business at 225 Asylum Street, 27 th Floor, Hartford, CT 06103, (hereinafter referred to as «HQUS»), an indirectly owned subsidiary of the Guarantor, have executed the following agreements: (a) a Transmission Service Agreement for the purchase of 579.335 MW of firm transmission service from the Beneficiary dated as of June 13, 2018; (b) a Transmission Service Agreement for the purchase of 498.348 MW of firm transmission service from the Beneficiary dated as of June 13, 2018; (c) a Transmission Service Agreement for the purchase of 12.317 MW of firm transmission service from the Beneficiary dated as of June 13, 2018, and (d) a Transmission Service Agreement for the purchase of 110 MW of firm transmission service from the Beneficiary dated as of June 13, 2018 (hereinafter collectively referred to as the «Agreements»); |
|
ATTENDU QUE la Caution bénéficiera directement ou indirectement des Conventions ; |
|
WHEREAS the Guarantor will directly or indirectly benefit from the Agreements; |
|
ATTENDU QUE le Bénéficiaire a exigé que la Caution garantisse inconditionnellement au Bénéficiaire toutes les obligations de paiement qui incombent à HQUS en vertu des Conventions, sous réserve de la somme maximale prévue à l’article 1 du présent Cautionnement; |
|
WHEREAS the Beneficiary has required that the Guarantor unconditionally guarantee to the Beneficiary all payment obligations of HQUS under the Agreements; subject to a maximum dollar limitation as provided in Section 1 of this Guaranty; |
S’ils sont destinés à la Caution : HYDRO-QUÉBEC À l’attention du vice‑président Financement, trésorerie et caisse de retraite 75, boulevard René-Lévesque Ouest 5 e étage Montréal (Québec) Canada H2Z 1A4 Télécopieur : 514 289-5409 |
S’ils sont destinés au Bénéficiaire :
Douglas Herling President & CEO Central Maine Power Company 83 Edison Drive Augusta, Maine 04336 Télécopieur : 207-626-9779 |
|
If to the Guarantor : HYDRO-QUÉBEC Attention : Vice-President Financing, Treasury and Pension Fund 75, René-Lévesque Boulevard West 5 th floor Montréal (Québec) Canada H2Z 1A4 Facsimile: 514 289-5409 |
If to the Beneficiary :
Douglas Herling President & CEO Central Maine Power Company 83 Edison Drive Augusta, Maine 04336 fax 207-626-9779 |
ou à l’adresse dont la Caution ou le Bénéficiaire peut notifier l’autre partie de temps à autre. |
|
or such address as the Guarantor or the Beneficiary may give notice to the other party, from time to time. |
Article 12. Ayants droit; lois applicables. Le présent Cautionnement lie la Caution, ses ayants droit et ses cessionnaires, et est régie par et doit être interprétée conformément aux lois de l'État de New York. |
|
Section 12. Successors; Governing Law . This Guarantee shall be binding upon the Guarantor, its successors and assignees, and shall be governed by and construed in accordance with the laws of the State of New York. |
Article 13. Convention intégrale . Le présent Cautionnement constitue la convention intégrale intervenue entre la Caution et le Bénéficiaire quant à son objet et remplace toutes les conventions et ententes antérieures, écrites ou verbales, entre la Caution et le Bénéficiaire quant à l’objet des présentes. |
|
Section 13. Entire agreement . This Guaranty constitutes the entire agreement of the Guarantor and the Beneficiary pertaining to the subject matter hereof and supersedes all prior written or oral agreements and understandings between the Guarantor and the Beneficiary with respect to the subject matter hereof. |
HYDRO-QUÉBEC
Par / |
By : |
|
|
Nom / |
Name : |
|
|
Titre / |
Title: |
|
|
Par / |
By : |
|
|
Nom / |
Name : |
|
|
Titre / |
Title: |
|
|
Exhibit 10.7
TRANSMISSION SERVICE AGREEMENT (Eversource Energy - 579.335 MW)
by and between
CENTRAL MAINE POWER COMPANY,
as Owner,
and
H.Q. ENERGY SERVICES (U.S.) INC.,
as Purchaser
Dated: as of June 13, 2018
|
Page |
|
Article I DEFINITIONS AND RULES OF INTERPRETATION |
2 |
|
|
|
|
Section 1.1 |
Definitions |
2 |
Section 1.2 |
Interpretation |
16 |
|
|
|
Article II REGULATORY FILINGS AND REQUIRED APPROVALS |
18 |
|
|
|
|
Section 2.1 |
MDPU Filing; FERC Filings |
18 |
Section 2.2 |
Modifications to FERC Order |
18 |
Section 2.3 |
Modifications Pursuant to Unfavorable MDPU Order or FERC Order |
19 |
Section 2.4 |
Cooperation |
19 |
Section 2.5 |
No Inconsistent Action |
20 |
|
|
|
Article III EFFECTIVE DATE; TERM |
20 |
|
|
|
|
Section 3.1 |
Effective Date |
20 |
Section 3.2 |
Term |
21 |
Section 3.3 |
Termination Rights |
21 |
Section 3.4 |
Termination Payments |
23 |
Section 3.5 |
Effect of Termination |
24 |
|
|
|
Article IV COMMERCIAL OPERATION |
24 |
|
|
|
|
Section 4.1 |
Critical Milestones |
24 |
Section 4.2 |
Commercial Operation Date |
27 |
Section 4.3 |
Conditions Precedent to Commercial Operation |
27 |
Section 4.4 |
Delay in Commercial Operation; Reduced Level of Operation |
28 |
|
|
|
Article V GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES |
33 |
|
|
|
|
Section 5.1 |
Responsibilities of the Parties |
33 |
Section 5.2 |
Schedules and Reports |
34 |
Section 5.3 |
Québec Line Reports; Joint Development Agreement |
35 |
Section 5.4 |
Insurance and Events of Loss |
35 |
Section 5.5 |
Compliance with Laws |
35 |
Section 5.6 |
Third Party Contracts |
36 |
Section 5.7 |
Purchaser’s Losses. |
36 |
Section 5.8 |
Continuity of Rights and Responsibilities |
36 |
Section 5.9 |
Right of First Offer to Purchase NECEC Transmission Line |
36 |
Section 5.10 |
Amendment to the PPA |
37 |
Section 5.11 |
Amendment to the Distribution Company TSA |
37 |
i
|
|
|
Article VI PROCEDURES FOR OPERATION AND MAINTENANCE OF THE NECEC TRANSMISSION LINE |
37 |
|
|
|
|
Section 6.1 |
Transmission Operating Agreement; ISO-NE Operational Control |
37 |
Section 6.2 |
Good Utility Practice; Regulatory and Reliability Requirements |
38 |
Section 6.3 |
Scheduled Maintenance |
38 |
|
|
|
Article VII PURCHASER’S TRANSMISSION RIGHTS OVER THE NECEC TRANSMISSION LINE |
38 |
|
|
|
|
Section 7.1 |
Transmission Service |
38 |
Section 7.2 |
Excused Outages or Reductions |
39 |
Section 7.3 |
Non-Excused Outages or Reductions |
40 |
Section 7.4 |
Allocation of Outages |
41 |
Section 7.5 |
Metering |
41 |
Section 7.6 |
Line Availability Information and Reporting |
41 |
|
|
|
Article VIII PAYMENTS FOR TRANSMISSION SERVICE OVER THE NECEC TRANSMISSION LINE |
41 |
|
|
|
|
Section 8.1 |
Transmission Service Payments |
41 |
Section 8.2 |
Adjustment to Rate Upon Purchaser Step-in |
42 |
Section 8.3 |
Elective Upgrade Status; No Regional Rates |
42 |
|
|
|
Article IX RIGHTS UPON EXPIRATION OF TERM |
43 |
|
|
|
|
Section 9.1 |
Rollover Rights |
43 |
|
|
|
Article X RESALE OF TRANSMISSION SERVICE |
43 |
|
|
|
|
Section 10.1 |
Resale Rights of Purchaser |
43 |
Section 10.2 |
Capacity Releases for Daily and Hourly Use |
43 |
Section 10.3 |
OASIS |
43 |
Section 10.4 |
Proceeds from Capacity Releases and Transmission Resales |
44 |
Section 10.5 |
Owner’s Rights and Obligations |
44 |
|
|
|
Article XI REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS |
44 |
|
|
|
|
Section 11.1 |
Real Power Losses |
44 |
Section 11.2 |
Other Rights |
44 |
ii
|
|
|
Article XII [INTENTIONALLY OMITTED] |
45 |
|
|
|
|
Article XIII BILLING AND PAYMENTS |
45 |
|
|
|
|
Section 13.1 |
Invoices |
45 |
Section 13.2 |
Procedures for Billing Disputes |
45 |
Section 13.3 |
Interest |
46 |
Section 13.4 |
Obligation to Make Payments |
46 |
Section 13.5 |
Offsets |
46 |
|
|
|
Article XIV EVENTS OF DEFAULT AND REMEDIES |
46 |
|
|
|
|
Section 14.1 |
Purchaser Defaults |
46 |
Section 14.2 |
[Intentionally Omitted] |
47 |
Section 14.3 |
Owner Defaults |
47 |
Section 14.4 |
Remedies Upon Purchaser Default |
49 |
Section 14.5 |
[Intentionally Omitted] |
50 |
Section 14.6 |
Remedies Upon Owner Default |
50 |
Section 14.7 |
Purchaser Step-in Rights |
51 |
Section 14.8 |
Early Termination of Distribution Company TSA |
54 |
Section 14.9 |
Disputes |
55 |
Section 14.10 |
Limitations on Total Liability |
55 |
Section 14.11 |
Modified Terms Applicable During Forbearance Period. |
56 |
|
|
|
Article XV FORCE MAJEURE |
56 |
|
|
|
|
Section 15.1 |
Definition; Conditions |
56 |
|
|
|
Article XVI FINANCIAL ASSURANCES |
58 |
|
|
|
|
Section 16.1 |
[Purchaser’s Guaranty |
58 |
Section 16.2 |
[Intentionally Omitted] |
58 |
Section 16.3 |
Credit Downgrade Event |
58 |
|
|
|
Article XVII DISPUTE RESOLUTION |
58 |
|
|
|
|
Section 17.1 |
Consultation |
58 |
Section 17.2 |
Disputes to be Resolved by FERC |
59 |
Section 17.3 |
Consent to Jurisdiction |
59 |
Section 17.4 |
WAIVER OF JURY TRIAL |
60 |
iii
|
|
|
Article XVIII LIMITATION OF REMEDIES |
60 |
|
|
|
|
Article XIX MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES. |
61 |
|
|
|
|
Section 19.1 |
Modifications |
61 |
Section 19.2 |
Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment |
61 |
|
|
|
Article XX INDEMNIFICATION |
63 |
|
|
|
|
Section 20.1 |
Purchaser Indemnity |
63 |
Section 20.2 |
Owner Indemnity |
63 |
Section 20.3 |
[Intentionally Omitted] |
63 |
Section 20.4 |
Procedures |
64 |
Section 20.5 |
Defenses |
64 |
Section 20.6 |
Cooperation |
65 |
Section 20.7 |
Recovery |
65 |
Section 20.8 |
Subrogation |
65 |
|
|
|
Article XXI REPRESENTATIONS, WARRANTIES AND COVENANTS |
65 |
|
|
|
|
Section 21.1 |
Mutual Representations and Warranties |
65 |
Section 21.2 |
Additional Representations and Warranties of Purchaser |
66 |
Section 21.3 |
Additional Representations and Warranties of Owner |
67 |
Section 21.4 |
[Intentionally Omitted] |
68 |
Section 21.5 |
NO OTHER REPRESENTATIONS OR WARRANTIES |
68 |
|
|
|
Article XXII TRANSFER OF INTERESTS |
68 |
|
|
|
|
Section 22.1 |
No Transfer of Interests |
68 |
Section 22.2 |
Exceptions |
70 |
Section 22.3 |
Collateral Assignment |
70 |
|
|
iv
71 |
||
|
|
|
Section 23.1 |
Governing Law |
71 |
Section 23.2 |
Entire Agreement |
71 |
Section 23.3 |
Severability |
71 |
Section 23.4 |
Notices |
71 |
Section 23.5 |
Waiver; Cumulative Remedies |
72 |
Section 23.6 |
Confidential Information |
72 |
Section 23.7 |
No Third-Party Rights |
73 |
Section 23.8 |
Permitted Successors and Assigns |
73 |
Section 23.9 |
Relationship of the Parties |
74 |
Section 23.10 |
Construction |
74 |
Section 23.11 |
Counterparts |
74 |
Section 23.12 |
Survival |
74 |
Section 23.13 |
Language |
74 |
Section 23.14 |
Headings and Table of Contents |
74 |
Section 23.15 |
Waiver of Immunities |
74 |
v
Attachment A |
Description of Transmission Projects |
Attachment B |
Critical Milestones |
Attachment C |
Owner Approvals |
Attachment D |
Canadian Approvals |
Attachment E |
Owner’s Preliminary Project Schedule and Construction Schedule |
Attachment F |
Required Insurance |
Attachment G |
Rate Adjustment Formula |
Attachment H |
Refund Calculation |
Attachment I |
Real Estate Rights |
Attachment J |
Form of Purchaser Guaranty |
vi
TRANSMISSION SERVICE AGREEMENT
This TRANSMISSION SERVICE AGREEMENT (this “ Agreement ”), dated as of June 13, 2018 (the “ Execution Date ”), is made and entered into by and between Central Maine Power Company, a corporation organized and existing under the laws of the State of Maine (“ Owner ”), and H.Q. Energy Services (U.S.) Inc. , a corporation organized and existing under the laws of the State of Delaware (“ HQ-US ” or “ Purchaser ”). Owner and Purchaser are hereinafter sometimes also referred to individually as a “ Party ” or collectively as the “ Parties .”
WITNESSETH
WHEREAS, Purchaser is an indirect, wholly-owned subsidiary of Hydro-Québec (as defined below);
WHEREAS, pursuant to “An Act to Promote Energy Diversity” that was signed into law in the Commonwealth of Massachusetts on August 8, 2016 (the “ Energy Diversity Act ”), Fitchburg Gas and Electric Light Company (d/b/a Unitil), Massachusetts Electric Company and Nantucket Electric Company (d/b/a National Grid), and NSTAR Electric Company (d/b/a Eversource Energy) (collectively, the “ RFP Sponsors ”) have solicited competitive proposals for clean energy generation for an annual amount of electricity equal to approximately 9.45 TWh;
WHEREAS, Owner and an Affiliate of HQ-US jointly submitted a proposal pursuant to such solicitation that includes up to 1,090 MW of clean energy generation obtained by HQ-US from its affiliate Hydro-Québec Production (a division of Hydro-Québec (as defined below), “ HQP ” and such generation, the “ Hydro Generation ”);
WHEREAS, concurrently with the execution and delivery of this Agreement, HQ-US has entered into a power purchase agreement (the “ PPA ”) with Eversource Energy (“ Distribution Company ”) and additional power purchase agreements (the “ Additional PPAs ”) with the other RFP Sponsors with respect to an aggregate of 1,090 MW of Hydro Generation (and related renewable energy credits and environmental attributes);
WHEREAS, as part of the delivery of 1,090 MW of Hydro Generation for sale into the U.S. pursuant to the PPA and the Additional PPAs, Hydro-Québec TransÉnergie (“ TransÉnergie ”), a division of Hydro-Québec, intends to develop, construct, own and maintain a 1,200 MW +/-320 kV high-voltage direct current (“ HVDC ”) transmission line from the converter station at the Appalaches substation in Thetford Mines, Québec to the U.S. Border (as defined below) at Beattie Township, Maine (as further delineated in the diagram or described in Attachment A , the “ Québec Line ”);
WHEREAS, HQP has acquired from TransÉnergie firm transmission service over the Québec Line to permit the delivery of at least 1,200 MW of power into the U.S.;
WHEREAS, Owner intends to develop, construct, own and maintain a 1,200 MW +/-320 kV HVDC transmission line extending from the U.S. Border at Beattie Township, Maine to a new direct current to alternating current (“ AC ”) converter station to be located at Merrill Road in the City of Lewiston in the State of Maine (the transmission line and converter station, as more fully described in Attachment A , the “ HVDC Line ”);
1
WHEREAS, in order to interconnect the HVDC Line with the bulk power systems in New England, Owner intends to develop, construct, own and maintain additional 345 kV AC transmission lines, rebuilt 115 kV AC transmission lines and other substation equipment more fully described in Attachment A (together with the Merrill Road substation at its northern terminus and the associated equipment, as more fully described in Attachment A , the “ AC Line ” and, together with the HVDC Line, the “ NECEC Transmission Line ” );
WHEREAS, although Owner has performed studies believed to replicate those utilized by ISO-NE and does not believe that AC Upgrades (as defined below) or CCIS Capacity Upgrades (as defined below) will be required as a consequence of the construction and operation of the NECEC Transmission Line and the consummation of the transactions contemplated by this Agreement, this Agreement, the Distribution Company TSA (as defined below), the Additional RFP Sponsor TSAs (as defined below), the Purchaser TSAs, the 110 MW TSA, the PPA or the Additional PPAs, ISO-NE (as defined below) may require certain AC Upgrades or CCIS Capacity Upgrades to be developed, constructed, owned and maintained by certain transmission owners other than Owner (which may include Affiliates of Owner) within their existing service territories in New England in order to interconnect the NECEC Transmission Line with the New England Transmission System (as defined below) in a safe and reliable manner, which AC Upgrades or CCIS Capacity Upgrades (if any) will be performed at Owner’s sole expense;
WHEREAS, concurrently with the execution and delivery of this Agreement, Owner has entered into a transmission service agreement (the “ Distribution Company TSA ”) with Distribution Company to sell 579.335 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date (as defined below) and additional transmission service agreements (the “ Additional RFP Sponsor TSAs ”) with the other RFP Sponsors to sell an aggregate of 510.665 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date; and
WHEREAS, Owner desires to sell Firm Transmission Service (as defined below) to Purchaser for years twenty-one (21) through forty (40) following the Commercial Operation Date, and Purchaser desires to acquire such Firm Transmission Service from Owner, at the rates and on the terms and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the foregoing and the respective representations, warranties, covenants, agreements and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound hereby, the Parties hereby agree as follows:
Article I
DEFINITIONS AND RULES OF INTERPRETATION
Section 1.1 Definitions . As used herein, the following terms shall have the following respective meanings:
“ 110 MW TSA ” means that certain Transmission Service Agreement between Purchaser and Owner, dated as of the date hereof, pursuant to which Purchaser has acquired transmission service for up to 110 MW of capacity for forty (40) years following the Commercial Operation Date.
2
“ 110 MW TSA Capacity ” means the firm capacity of the NECEC Transmission Line of up to 110 MW that Purchaser has committed in the 110 MW TSA to purchase in the forty (40) years following the Commercial Operation Date .
“ 110 MW TSA FERC Order ” means an order accepting or approving the 110 MW TSA for filing.
“ AC ” has the meaning provided in the recitals to this Agreement.
“ AC Line ” has the meaning provided in the recitals to this Agreement.
“ AC Upgrade Approvals ” means, collectively, any Governmental Approvals or Third Party Consents, in each case, that are required to commence construction of the AC Upgrades.
“ AC Upgrade Owners ” means, collectively, any Person responsible for constructing one or more AC Upgrades pursuant to a facilities agreement.
“ AC Upgrades ” means any additions, upgrades, reinforcements or other modifications to the New England Transmission System that ISO-NE determines, pursuant to Section I.3.9 of the ISO-NE Tariff, to be required, at a minimum, to interconnect the NECEC Transmission Line at the Delivery Point with the New England Transmission System.
“ Acquisition Notice ” has the meaning provided in Section 14.7(b) .
“ Additional Bids ” has the meaning provided in Article XVIII .
“ Additional Credit Support ” means one or more of the following, issued in favor of or otherwise held by or for the benefit of Owner or Purchaser, as applicable:
(a) a guaranty, in form and substance reasonably satisfactory to Purchaser or Owner (as applicable), issued by an Affiliate of Owner or Purchaser (as applicable) that meets the Credit Rating Requirements;
(b) a Letter of Credit, in form and substance reasonably satisfactory to Purchaser or Owner (as applicable); or
(c) Cash.
“ Additional RFP Sponsor TSAs ” has the meaning provided in the recitals to this Agreement.
“ Additional RFP Sponsor TSA FERC Order ” means an order accepting or approving one or more Additional RFP Sponsor TSAs for filing.
“ Additional PPAs ” has the meaning provided in the recitals to this Agreement.
“ Adverse Determination ” has the meaning provided in Section 19.2(c) .
3
“ Affiliate ” means, with respect to a specified Person, any other Person that directly or indirectly Controls, is Controlled by or is under common Control with the specified Person; provided , however , that, with respect to Purchaser, a Person shall not be an “Affiliate” of Purchaser unless such Person is Hydro-Québec (including, for the avoidance of doubt, a division of Hydro-Québec) or Controlled by Hydro-Québec.
“ Agreement ” has the meaning provided in the preamble to this Agreement.
“ Applicable Law ” means any duly promulgated federal, national, state, provincial or local law, regulation, rule, ordinance, code, decree, judgment, directive or judicial or administrative order, permit or other duly authorized and valid action of any Governmental Authority, including any binding interpretation of any of the foregoing by any Governmental Authority, which is applicable to a Person, its property or a transaction, and also including Section 83D, the regulations promulgated under Section 83D, the Regulatory Approval and any other orders of the MDPU with respect to this Agreement.
“ Approval Deadline ” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Available Transfer Capability ” means the lesser of (a) 1,090 MW or (b) the Total Transfer Capability.
“ Bankruptcy Code ” means the United States Bankruptcy Code, 11 U.S.C. § 101 et seq.
“ Business Day ” means any day except Saturday, Sunday or any other day on which the Federal Reserve member banks are required or authorized to close for business.
“ Canadian Approval Deadline ” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Canadian Approvals ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the Québec Line in a manner consistent with Attachment A , all as set forth in Attachment D .
“ Cash ” means U.S. dollars held by or on behalf of a Party as Credit Support hereunder.
“ CCIS Capacity Upgrade ” means any upgrade determined by ISO-NE as necessary in order for the NECEC Transmission Line Capacity to satisfy the Capacity Capability Interconnection Standard under and as defined in the ISO-NE Tariff.
“ COD Notice ” has the meaning provided in Section 4.2(c) .
“ Commercial Operation ” means the availability of the NECEC Transmission Line for the provision of Firm Transmission Service in accordance with this Agreement and the Distribution Company TSA.
“ Commercial Operation Date ” has the meaning provided in Section 4.2(c) .
4
“ Commissioning ” means (a) with respect to the NECEC Transmission Line, the start-up and testing activities required to demonstrate that the NECEC Transmission Line is ready for Commercial Operation and (b) with respect to the Québec Line, the start-up and testing activities required to demonstrate that the Québec Line is ready for commercial operation, consistent with Section 4.3(f) .
“ Concurrent Delay ” has the meaning provided in Section 4.4.3 .
“ Confidential Information ” means (a) this Agreement, (b) any documents, analyses, compilations, studies, or other materials prepared by or information received from a Party or its representatives that contain or reflect written or oral data or information that is privileged, confidential or proprietary and that is marked or otherwise clearly identified as “confidential” or “proprietary” or with words of like meaning, or (c) any subsequently prepared documents, analyses, compilations, studies or other materials or information that are derived from any of the documents, analyses, compilations, studies or other materials or information described in the foregoing clause (b). Without limiting the generality of the foregoing, all information provided to Purchaser or Owner under Sections 2.4 , 5.2 and 6.3 hereof shall be deemed to be Confidential Information, whether or not such information is marked as “confidential” or “proprietary.”
“ Consent ” means, with respect to a Person, any approval, consent, permit, license, decree, certificate or other authorization of or from such Person.
“ Construction Authorizations ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the NECEC Transmission Line, other than the ISO-NE Approval, including the approvals of the Maine Department of Environmental Protection, the U.S. Army Corp of Engineers, the Maine Public Utilities Commission and the U.S. Department of Energy (the Presidential Permit), as more fully set forth in Attachment C .
“ Construction Contract ” means any contract entered into by Owner that provides for the engineering, procurement or construction of the NECEC Transmission Line.
“ Construction Phase ” means the period commencing upon the receipt of the FERC Authorization or such other date to which the Parties shall mutually agree in writing, and ending on the day immediately preceding the Commercial Operation Date or upon the earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Contract Capacity ” means the Proportionate Share multiplied by the NECEC Transmission Line Capacity.
“ Contract Year ” means each twelve-month period during the Term, with the first Contract Year commencing on the Commercial Operation Date and with each Contract Year after the first commencing on the anniversary of the Commercial Operation Date.
“ Control ” (including its correlative meanings “Controlled by” and “under common Control with”) means, with respect to a Person, the possession, directly or indirectly, of the power to direct or cause the direction of the management or policies of the specified Person, whether through ownership of voting securities or partnership or other ownership interests, by contract or Applicable Law or otherwise.
5
“ Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , Section 4.1(d) or Section 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Credit Rating Requirements ” means a long-term credit rating of at least “BBB-” by S&P or “Baa3” by Moody’s.
“ Credit Support ” means collateral in the form of (a) Cash or (b) a Letter of Credit issued by a Qualified Bank in a form reasonably satisfactory to the beneficiary.
“ Critical Energy Infrastructure Information ” means any information defined as Critical Energy Infrastructure Information by FERC pursuant to 18 C.F.R. § 388.113, and shall include all Critical Infrastructure Protection (CIP) standards (CIP-002 through CIP-009) established by NERC.
“ Critical Milestone ” has the meaning provided in Section 4.1(a) .
“ Delivery Point ” means the southern terminus of the NECEC Transmission Line at the Larrabee Road substation in Lewiston, Maine, as illustrated in Attachment A .
“ Design Capability ” means the maximum amount of electric power that the materials, equipment and structures comprising the HVDC Transmission Project will be designed to transfer bi-directionally in a safe and reliable manner, which amount shall be sufficient to permit the north-to-south delivery of all amounts scheduled for delivery in an aggregate amount of at least 1,090 MW, but not to exceed 1,200 MW, of electrical energy at the Delivery Point.
“ Discount Rate ” means the prime rate specified in the “Money and Investing” section of the Wall Street Journal, determined as of the date of the notice of default, plus 300 basis points.
“ Dispute ” means any dispute, controversy or claim of any kind whatsoever arising out of or relating to a Proposal Agreement, including relating to the interpretation of the terms thereof or any Applicable Law that affects such Proposal Agreement, or the transactions contemplated thereunder, or the breach, termination or validity thereof.
“ Distribution Company ” has the meaning provided in the recitals to this Agreement.
“ Distribution Company TSA ” has the meaning provided in the recitals to this Agreement.
“ Distribution Company TSA Amendment ” has the meaning provided in Section 2.3 .
“ Distribution Company TSA Critical Milestones ” means the “Critical Milestones” as defined in the Distribution Company TSA.
“ Distribution Company TSA FERC Order ” has the meaning provided in Section 2.3 .
“ Effective Date ” has the meaning provided in Section 3.1 .
“ Energy Diversity Act ” has the meaning provided in the recitals to this Agreement.
6
“ Excused Outages ” has the meaning provided in Section 7.2(a) .
“ Execution Date ” has the meaning provided in the preamble to this Agreement.
“ Federal Power Act ” means the United States Federal Power Act of 1935, as amended, 16 U.S.C. § 791a et seq.
“ FERC ” means the Federal Energy Regulatory Commission, or any successor regulatory agency that administers the Federal Power Act.
“ FERC Amendment ” has the meaning provided in Section 2.2(b) .
“ FERC Authorization ” means, collectively, any FERC order that is not subject to rehearing or appeal authorizing Owner to provide Firm Transmission Service, including the FERC Order, the Distribution Company TSA FERC Order, any Additional RFP Sponsor TSA FERC Order, any Purchaser TSA FERC Order and the 110 MW TSA FERC Order , and any authorization from FERC with respect to the Transmission Operating Agreement or Interconnection Agreements.
“ FERC Order ” has the meaning provided in Section 2.2(a) .
“ Financial Transmission Rights ” means Financial Transmission Rights, as defined in the ISO-NE Tariff.
“ Financing Deadline ” has the meaning provided in the Distribution Company TSA and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Firm Transmission Service ” has the meaning provided in Section 7.1.1 .
“ Fixed Credit Support ” has the meaning provided in the PPA.
“ Force Majeure ” has the meaning provided in Section 15.1(a) .
“ Good Utility Practice ” means those design, construction, operation, maintenance, repair, removal and disposal practices, methods and acts that are engaged in by a significant portion of the electric transmission industry in the United States during the relevant time period, or any other practices, methods or acts that, in the exercise of reasonable judgment in light of the facts known at the time a decision is made, could have been expected to accomplish a desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Good Utility Practice is not intended to be the optimum practice, method or act to the exclusion of others but rather to be a spectrum of acceptable practices, methods or acts generally accepted in such electric transmission industry for the design, construction, operation, maintenance, repair, removal and disposal of electric transmission facilities in the United States. Good Utility Practice shall not be determined after the fact in light of the results achieved by the practices, methods, or acts undertaken, but rather shall be determined based upon the consistency of (a) the practices, methods, or acts when undertaken with (b) the standard set forth in the first two (2) sentences of this definition at such time.
7
“ Governmental Approval ” means (a) any authorization, consent, approval, license, lease, ruling, permit, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with or (d) any registration by or with, any Governmental Authority, including any FERC Authorization.
“ Governmental Authority ” means any government or agency or other political subdivision thereof, including any province, state or municipality, or any other governmental, quasi-governmental, judicial, executive, legislative, administrative, regulatory, public or statutory instrumentality, authority, body, agency, commission, department, board, bureau or entity exercising judicial, executive, legislative, administrative or regulatory functions, any court or arbitrator with authority to bind a party at law, and shall include, to the extent exercising powers delegated by any Governmental Authority acting under Applicable Law, NERC and ISO-NE.
“ Hourly Availability ” means, with respect to any hour, the availability of the NECEC Transmission Line for the purposes of this Agreement, which shall equal (a) the Proportionate Share of the Available Transfer Capability for such hour, divided by (b) the Contract Capacity, expressed as a percentage; provided , however , that, for any hour, such availability of the NECEC Transmission Line shall not exceed one hundred percent (100%).
“ HQ-US ” has the meaning provided in the preamble to this Agreement.
“ HQE ” means Hydro-Québec Équipment, a division of Hydro-Québec .
“ HQP ” has the meaning provided in the recitals to this Agreement.
“ HVDC ” has the meaning provided in the recitals to this Agreement.
“ HVDC Line ” has the meaning provided in the recitals to this Agreement.
“ HVDC Transmission Project ” means, collectively, (a) the Québec Line and (b) the NECEC Transmission Line.
“ Hydro Generation ” has the meaning provided in the recitals to this Agreement.
“ Hydro-Québec ” means Hydro-Québec, a body politic and corporate, duly incorporated and regulated by the Hydro-Québec Act (R.S.Q., Chapter H-5). As of the Execution Date, Hydro-Québec has four divisions: HQP, TransÉnergie, Hydro-Québec Distribution and HQE.
“ Hydro-Quebec Guaranty ” has the meaning provided in Section 16.1 .
“ Immunities Act ” means the United States Foreign Sovereign Immunities Act of 1976, 28 U.S.C. § 1602 et seq.
“ Indemnification Notice ” has the meaning provided in Section 20.4 .
“ Indemnified Party ” has the meaning provided in Section 20.4 .
“ Indemnifying Party ” has the meaning provided in Section 20.4 .
8
“ Insolvency Event ” means, with respect to a Person, such Person (a) becomes “insolvent,” as defined in the Bankruptcy Code, or otherwise becomes bankrupt or insolvent under any Insolvency Laws, (b) has a liquidator, administrator, receiver, custodian, trustee, conservator or similar official appointed with respect to such Person or any material portion of such Person’s assets or such Person consents to such appointment, or a foreclosure action is instituted with respect to any material portion of such Person’s assets and is not dismissed within thirty (30) days of commencement thereof, (c) files a voluntary petition or otherwise authorizes or commences a proceeding or cause of action under the Bankruptcy Code or Insolvency Laws, (d) has an involuntary petition filed against it or acquiesces in the commencement of a proceeding or cause of action as the subject debtor under the Bankruptcy Code or Insolvency Laws, which petition is not dismissed within thirty (30) days after the filing thereof or results in the issuance of an order for relief against such Person, (e) makes or consents to an assignment of its assets in whole or in part, for the benefit of creditors or any general arrangement for the benefit of creditors, or a common law composition of creditors or (f) generally is unable to pay its debts as they fall due, or admits in writing to such inability.
“ Insolvency Laws ” means any bankruptcy, insolvency, reorganization or similar laws of the U.S., Canada, or other Governmental Authority, as applicable, other than the Bankruptcy Code.
“ Interconnection Agreements ” means, collectively, (a) an agreement by and among Owner, TransÉnergie and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the U.S. Border of the NECEC Transmission Line with the Québec Line and (b) an agreement by and between Owner and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the Delivery Point of the NECEC Transmission Line with certain transmission facilities operated by ISO-NE. The Interconnection Agreements shall address cost responsibilities among entities other than the Distribution Company and the other RFP Sponsors and shall include provisions, both technical and otherwise, for safe and reliable interconnected operations of the HVDC Transmission Project following Commercial Operation (including use of the HVDC Transmission Project for the delivery of electric power in emergency circumstances).
“ Interested Party ” means, collectively, the Parties and, if and as applicable, the RFP Sponsors.
“ Invoice ” means, with respect to a calendar month, an invoice that sets forth the amounts owed to the applicable Party with respect to such month in reasonable detail to evidence the basis for individual billings and charges.
“ ISO-NE ” means ISO New England Inc., or its successor organization.
“ ISO-NE Approval ” means approval by ISO-NE to operate the NECEC Transmission Line up to 1,200 MW.
“ ISO-NE Definitions Manual ” means the ISO New England Manual for Definitions and Abbreviations, Manual M-35, as in effect from time to time.
9
“ ISO-NE Rules ” means the ISO-NE Tariff and all ISO-NE manuals, rules, procedures, agreements or other documents relating to the reliable operation of the electric system in New England and the purchase and sale of electrical energy, electrical capacity and ancillary services, as such govern market participants with respect thereto in the operating jurisdiction of ISO-NE, as in effect from time to time, including the ISO-NE Definitions Manual; provided that such documents are publicly accessible.
“ ISO-NE Tariff ” means the ISO New England Inc. Transmission, Markets and Services Tariff, FERC Electric Tariff No. 3, as in effect from time to time, on file with FERC, or its successor tariff.
“ Joint Development Agreement ” has the meaning provided in Section 5.3 .
“ kV ” means kilovolt.
“ K W ” means kilowatt.
“ Letter of Credit ” means an irrevocable, non-transferable standby letter of credit issued by a Qualified Bank utilizing a form acceptable to the Party in whose favor such letter of credit is issued. All costs relating to any Letter of Credit shall be for the account of the Party providing that Letter of Credit.
“ Maintenance Plan ” means an annual plan for the management, operation and ordinary maintenance of the NECEC Transmission Line, which plan shall include a description of the scope and nature of the planned operating and maintenance programs and planned and preventive maintenance procedures for the NECEC Transmission Line, and the scheduled maintenance and other planned outages of the NECEC Transmission Line, in each case, in accordance with Section 6.3 hereof and the requirements of the PPA.
“ Market Products ” means, collectively, all products (however entitled and whether existing now or in the future) that (a) are recognized under ISO-NE Rules, (b) derive from the acquisition of transmission service over the NECEC Transmission Line under this Agreement and (c) can be sold for consideration or otherwise have economic value, including electrical energy, electrical capacity and ancillary services, including reserve products (including spinning and non-spinning reserves).
“ Marketing Activities ” means a specific offering by Owner of the NECEC Transmission Line (without any other material assets) for purchase by one or more third parties (other than an Affiliate of Owner).
“ Marketing Notice ” has the meaning provided in Section 5.9(a) .
“ Material Adverse Effect ” means, with respect to a Party, a material adverse effect on the ability of such Party to perform any of its obligations under this Agreement.
“ MDPU ” means the Massachusetts Department of Public Utilities.
10
“ Minimum Average Availability ” means ninety percent (90%) of the Contract Capacity, provided that, during the Remediation Period, if applicable, for every ten (10) MW that the maximum operating agreement of the NECEC Transmission Line is below 1,090 MW, the Minimum Average Availability shall be increased by one percent (1%), and provided further that, if, at the earlier of the Owner Remediation Date or the end of the Remediation Period, the NECEC Transmission Line is operating at an operating capacity below 1090 MW in any of the circumstances described in Section 4.4.1(c)(ii), the Minimum Average Availability shall be increased by one-half of one percent (0.5%) for each 5 MW by which the operating capacity of the NECEC Transmission Line is below 1,090 MW.
“ Municipal Owner Approval Deadline ” means March 31, 2022 (as the same may be extended in accordance with Section 4.1(c) or Section 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Municipal Owner Approvals ” means the Owner Approvals identified in paragraph 10 of Attachment C that are required to construct, own, and operate the NECEC Transmission Line.
“ MW ” means megawatt.
“ NECEC Facilities ” has the meaning provided in Section 8.3 .
“ NECEC Transmission Line ” has the meaning provided in the recitals to this Agreement.
“ NECEC Transmission Line Capacity ” means (a) 1,090 MW or (b) such lesser amount as may be established by the Commissioning of the NECEC Transmission Line, in each case as measured at the Delivery Point; provided that the amount under clause (b) shall be increased if the capacity is increased after the Commercial Operation Date pursuant to Section 4.4.1(c) , Section 4.4.2(b) or Section 4.4.3(b) .
“ NERC ” means the North American Electric Reliability Corporation, or its successor organization.
“ Net Book Value ” means, at any time, an amount equal to the original cost of construction minus depreciation (using a forty (40)-year depreciation schedule), as calculated in accordance with generally accepted accounting principles.
“ New England Transmission System ” means New England Transmission System, as defined in the ISO-NE Tariff.
“ Non-Excused Outage ” means any outage of the NECEC Transmission Line or reduction in the Total Transfer Capability below the NECEC Transmission Line Capacity, except due to an Excused Outage.
“ Non-Excused Outage Payment ” means, with respect to any month during which a Non-Excused Outage occurs, an amount equal to:
(a) the excess, in MW, if any, of (i) the Contract Capacity multiplied by the Minimum Average Availability over (ii) the Contract Capacity multiplied by the average Hourly Availability of the NECEC Transmission Line for such month, multiplied by
11
(c) the number of hours in such month.
“ OASIS ” means the Open Access Same-Time Information System.
“ OASIS Administrator ” has the meaning provided in Section 10.3(a) .
“ Offer Price ” has the meaning provided in Section 5.9(a) .
“ Other Transmission Rights ” means, collectively, any Financial Transmission Rights (or any similar concept), auction revenue rights or other financial or physical transmission rights, in each case, whether existing now or in the future, associated with the NECEC Transmission Line or AC Upgrades.
“ Owner ” has the meaning provided in the preamble to this Agreement.
“ Owner Approvals ” means, collectively, (a) the Construction Authorizations and (b) the ISO-NE Approval, all as set forth in Attachment C .
“ Owner Default ” has the meaning provided in Section 14.3 .
“ Owner Delay ” has the meaning provided in Section 4.4.1 .
“ Owner Indemnified Party ” has the meaning provided in Section 20.1 .
“ Owner Remediation Date ” has the meaning provided in Section 4.4.1(c)(i) .
“ Owner Security ” has the meaning provided in the Distribution Company TSA.
“ Owner Termination Payment ” means (a) if prior to the Commercial Operation Date, (i) liquidated damages in an amount equal to the Proportionate Share multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the termination date in connection with the development and construction of the Québec Line, and (ii) if the PPA has also been terminated pursuant to Section 9.2(b) thereof or, if due to a default by Owner under the Distribution Company TSA, Section 9.2(c) of the PPA, an amount equal to any Fixed Credit Support or (b) if on or after the Commercial Operation Date, an amount equal to the amounts paid by Purchaser to Distribution Company under the PPA (including any amounts drawn on any Credit Support provided by Purchaser under the PPA), arising out of or in connection with the Owner Default and termination of this Agreement. For the avoidance of doubt, the amounts described in the foregoing clause (b) shall be without duplication of any amounts paid by Owner to Distribution Company under the Distribution Company TSA in satisfaction of any liabilities to Distribution Company under the PPA. For purposes of calculating the Owner Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW.
“ Owner’s Construction Progress Report ” has the meaning provided in Section 5.2.3(a) .
“ Owner’s Construction Schedule ” has the meaning provided in Section 5.2.2 .
12
“ Owner’s Prelimi nary Schedule ” has the meaning provided in Section 5.2.1 .
“ Parties ” and “ Party ” have the meanings provided in the preamble to this Agreement.
“ Person ” means any legal person, including any natural person, domestic or foreign corporation, limited liability company, general or limited partnership, joint venture, association, joint stock company, business trust, estate, trust, enterprise, unincorporated organization, any Governmental Authority, or any other legal or commercial entity.
“ Physical Transmission Line Capacity ” means the sum of the NECEC Transmission Line Capacity and the 110 MW TSA Capacity.
“ Power Cost Reconciliation Tariff ” means a fully reconciling cost recovery tariff mechanism that authorizes the establishment of a distribution charge that fully recovers Distribution Company’s net costs under the Distribution Company TSA (including annual remuneration of up to two and three-quarters percent (2.75%)). The rate reconciliation shall be designed in such a way as to limit the build-up of any under or over-recoveries over the course of the year. A reconciliation shall occur at least annually, but may also be reconciled quarterly or monthly, to the extent necessary to eliminate regulatory lag for the recovery of costs or crediting of over-recoveries to customers.
“ PPA ” has the meaning provided in the recitals to this Agreement.
“ PPA Contract Maximum Amount ” means 579.335 MW, as such amount may be adjusted in accordance with the terms of the PPA.
“ Presidential Permit ” means the permit granted by the U.S. Department of Energy, pursuant to Executive Order 10485 as amended by Executive Order 12038, authorizing the construction, operation, maintenance and connection of facilities for the transmission of electric energy at the international border between the United States and Canada.
“ Project Schedule ” means a schedule setting forth the proposed engineering, procurement, construction and testing milestone schedule for (a) the NECEC Transmission Line based upon the Construction Contracts, (b) the Québec Line and (c) the AC Upgrades and the CCIS Capacity Upgrades based upon such information as can reasonably be obtained by Owner from the AC Upgrade Owners, recognizing that one or more Project Schedules will be completed and delivered before the date on which the AC Upgrades and the CCIS Capacity Upgrades are formally identified under this Agreement.
“ Proportionate Share ” means a fraction with the numerator equal to 579.335 MW and the denominator equal to 1,090 MW.
“ Proposal Agreements ” means, collectively, this Agreement, the 110 MW TSA, the Distribution Company TSA, the Additional RFP Sponsor TSAs, the Purchaser TSAs, the PPA and the Additional PPAs.
13
“ Purchased Power Accounting Authorization ” means authorization for Distribution Company, at Distribution Company’s sole discretion, to take appropriate steps to assure avoidance of a material, negative balance sheet impact on Distribution Company or Distribution Company’s direct or indirect parent company, upon appropriate filing with and approval by the MDPU.
“ Purchaser ” has the meaning provided in the preamble to this Agreement.
“ Purchaser Default ” has the meaning provided in Section 14.1 .
“ Purchaser Delay ” has the meaning provided in Section 4.4.2(a) .
“ Purchaser Guarantor ” means Hydro-Québec.
“ Purchaser Indemnified Party ” has the meaning provided in Section 20.2 .
“ Purchaser Term ” has the meaning provided in Section 8.1 .
“ Purchaser Termination Payment ” means (a) if prior to the Commercial Operation Date, an amount equal to the Proportionate Share of all costs prudently incurred by Owner as of the termination date in connection with the development and construction of the NECEC Transmission Line or (b) if on or after the Commercial Operation Date, an amount equal to the Proportionate Share multiplied by the Net Book Value of the NECEC Transmission Line minus the present value, discounted at the Discount Rate, of the Proportionate Share of revenues (if any) to be received by Owner, acting in a commercially reasonable manner, pursuant to contracts (if any) entered into by Owner during the sixty (60) day period immediately following the delivery of the termination notice, from one or more other purchasers or payors over the remainder of the Term for transmission service utilizing the NECEC Transmission Line up to an amount of generation at the Contract Capacity (net of operating costs in respect of such revenues), provided that, for purposes of calculating the Purchaser Termination Payment, the denominator in “Proportionate Share” shall be 1,200 MW.
“ Purchaser TSA ” means any transmission service agreement entered into between Purchaser and Owner (other than this Agreement), pursuant to which Purchaser acquires firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date.
“ Purchaser TSA FERC Order ” means an order issued by FERC accepting or approving one or more Purchaser TSAs for filing.
“ Qualified Bank ” means a U.S. commercial bank (or the U.S. branch of a foreign bank) having (a) assets on its most recent balance sheet of at least $10 billion and (b) a long-term credit rating of at least “A-” by S&P or “A3” by Moody’s (or its equivalent).
“ Québec Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
14
“ Québec Line ” has the meaning provided in the recitals to this Agreement.
“ Québec Line Capacity Deficiency Payment ” means the Proportionate Share of (i) all costs prudently incurred by Owner as of the Commercial Operation Date in connection with the development and construction of the NECEC Transmission Line, multiplied by (ii) a fraction, the numerator of which is (A) the difference between the lesser of (x) the operating capacity of the NECEC Transmission Line and (y) 1,090 MW, and the operating capacity of the Québec Line, and the denominator of which is (B) the lesser of (x) the operating capacity of the NECEC Transmission Line or (y) 1,090 MW.
“ Real Power Losses ” means energy consumed by the electrical impedance characteristics of the NECEC Transmission Line.
“ Recovery ” has the meaning provided in Section 20.7 .
“ Regulatory Approval ” means the MDPU approval of the Distribution Company TSA , which approval shall include: (1) confirmation that the Distribution Company TSA has been approved under Section 83D and the regulations promulgated thereunder and that all of the terms of such Section 83D and such regulations apply to the Distribution Company TSA; (2) definitive regulatory authorization for Distribution Company to recover all of its costs incurred under and in connection with the Distribution Company TSA for the entire term of the Distribution Company TSA through the implementation of a Power Cost Reconciliation Tariff or other cost recovery or reconciliation mechanisms; (3) definitive regulatory authorization for Distribution Company to recover remuneration of up to two and three-quarters percent (2.75%) of Distribution Company’s annual payments under the Distribution Company TSA for the term of the Distribution Company TSA through the Power Cost Reconciliation Tariff; and (4) approval of any Purchased Power Accounting Authorization requested by Distribution Company in connection with the Regulatory Approval. Such approvals shall be acceptable in form and substance to Distribution Company in its sole discretion and shall not include any conditions or modifications that Distribution Company deems, in its sole discretion, to be unacceptable , and shall be final and not subject to appear or rehearing .
“ Regulatory Approval Delay ” means any delay in the receipt of the Regulatory Approval beyond January 25, 2019.
“ Regulatory Approval Termination Outside Date ” has the meaning provided in Section 3.3.1(a) .
“ RFP Sponsors ” has the meaning provided in the recitals to this Agreement.
“ Section 83D ” means Section 83D of the Energy Diversity Act.
“ Scheduling Rules ” has the meaning provided in Section 7.1.3 .
“ Step-In Trigger Event ” has the meaning provided in Section 14.7(f) .
“ Target Date ” has the meaning provided in Section 4.2(a) .
15
“ Term ” has the meaning provided in Section 3.2 .
“ Third Party Claim ” has the meaning provided in Section 20.4 .
“ Third Party Consent ” means any Consent of a Person other than a Governmental Authority.
“ Total Transfer Capability ” means the Total Transfer Capability of the NECEC Transmission Line, as defined in, and established in accordance with, the ISO-NE Tariff and determined by ISO-NE for each hour.
“ TransÉnergie ” has the meaning provided in the recitals to this Agreement.
“ TransÉnergie OATT ” means the Hydro-Québec Open Access Transmission Tariff, as amended or accepted by the Régie de l’énergie from time to time.
“ Transfer ” has the meaning provided in Section 22.1(a) .
“ Transmission Operating Agreement ” means an agreement entered into by and between Owner and ISO-NE for transmission operating services over the NECEC Transmission Line under which operating control (as defined in such agreement) of the NECEC Transmission Line is transferred from Owner to ISO-NE.
“ Transmission Operator ” means ISO-NE acting in its capacity pursuant to the Transmission Operating Agreement.
“ Transmission Percentage ” means a fraction with the numerator equal to the Contract Capacity and the denominator equal to the Physical Transmission Line Capacity.
“ Transmission Service Payment ” has the meaning provided in Section 8.1 .
“ Unfavorable FERC Decision ” has the meaning provided in Section 2.2(a) .
“ Unfavorable MDPU Order ” has the meaning provided in Section 2.3 .
“ United States ” or “ U.S. ” means the United States of America.
“ U.S. Border ” means the location on or near the international border between the State of Maine and the Province of Québec where the HVDC Line and the Québec Line interconnect.
Section 1.2 Interpretation . In this Agreement, unless the context otherwise requires, the following rules shall apply to the usage of terms:
Section 1.2.1 Singular; Plural; Gender; Corollary Meaning . The singular shall include the plural and vice versa, and any pronoun shall include the corresponding masculine, feminine and neuter forms. If a term is defined as one part of speech (such as a noun), then it shall have a corresponding meaning when used as another part of speech (such as a verb).
Section 1.2.2 Coordinating Conjunctions . The word “or” shall have the inclusive meaning represented by the phrase “and/or.”
16
Section 1.2.3 Self-Reference . The words “hereof,” “herein,” “hereto” and “hereunder” and words of similar import when used in this Agreement shall, unless otherwise expressly specified, refer to this Agreement as a whole and not to any particular provision of this Agreement.
Section 1.2.4 Inclusive References . The words “include,” “includes” and “including” when used in this Agreement shall be deemed to be followed by “without limitation” or “but not limited to,” whether or not they are in fact followed by such words or words of like import.
Section 1.2.5 Incorporation by Reference . Any reference in this Agreement to an “Article,” “Section” or other subdivision or to an “Attachment” or other schedule or attachment shall be references to an article, section or other subdivision of, or to a schedule or attachment to, this Agreement, unless otherwise stated, and all such Articles, Sections and Attachments are incorporated into this Agreement by reference (all of which comprise part of one and the same agreement with equal force and effect). In the event of any conflict or other inconsistency between the main body of this Agreement and any attachment or schedule to this Agreement, the provisions of the main body of this Agreement shall prevail.
Section 1.2.6 Subsequent Acts . Any references in this Agreement to any statute shall be deemed to refer to such statute, as amended or replaced from time to time, including by succession of comparable successor statute, and all rules and regulations promulgated thereunder. In the event any index or publication referenced in this Agreement ceases to be published or a concept defined by reference to any such index or publication ceases to exist, each such reference shall be deemed to be a reference to a successor or alternate index, publication or concept reasonably agreed to by the Parties. Unless specified otherwise, a reference to a given agreement or instrument, and all schedules and attachments thereto, shall be a reference to that agreement or instrument as modified, amended, supplemented and restated, and as in effect from time to time.
Section 1.2.7 Inclusive of Permitted Successors . Unless otherwise expressly stated, references to any Person also include its permitted successors and assigns.
Section 1.2.8 Time Computation . In this Agreement, in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each means “to but excluding.”
Section 1.2.9 Business Days . Whenever this Agreement refers to a number of days, such number shall refer to calendar days unless Business Days are specified. Whenever any action must be taken under this Agreement on or by a day that is not a Business Day, such action may be validly taken on or by the next day that is a Business Day, and in the case of payments (including refunds of payments), no interest shall accrue on the amount due; provided that such payment is made in full on the next day that is a Business Day.
Section 1.2.10 Governmental Approvals . Except as otherwise expressly provided in this Agreement, any Governmental Approval shall be deemed to be received upon issuance, even if such Governmental Approval is subject to appeal or rehearing.
17
Section 1.2.11 Currency . All references to prices, values or monetary amounts referred to in this Agreement shall be paid in United States currency, unless expressly provided otherwise.
Article II
REGULATORY FILINGS AND REQUIRED APPROVALS
Section 2.1 MDPU Filing; FERC Filings .
(a) Owner shall use commercially reasonable efforts to cause Distribution Company to: (i) file for the Regulatory Approval as soon as practicable following the execution of the Distribution Company TSA, and (ii) use commercially reasonable efforts to file within sixty (60) days thereafter.
(b) Owner shall file the Distribution Company TSA with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing with FERC shall include waiver requests for the effective date of the Distribution Company TSA to occur consistent with Section 3.1 thereof, which effective date may be more than one hundred twenty (120) days before the Commercial Operation Date. Owner shall file this Agreement with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when the Distribution Company files for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing shall include waiver requests for the Effective Date to occur consistent with Section 3.1 , which Effective Date may be more than one hundred twenty (120) days before the Commercial Operation Date.
(c) The Parties shall respond promptly to any requests for additional information made by FERC in connection with any such filings.
(d) Upon the filing of this Agreement pursuant to Section 2.1(b) , Purchaser and Owner shall support the approval or acceptance of this Agreement by FERC without modification or condition.
Section 2.2 Modifications to FERC Order .
(a) In the event (i) FERC issues an order accepting or approving this Agreement for filing (the “ FERC Order ” ) and (ii) the FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to a Party, in its sole discretion (an “ Unfavorable FERC Decision ” ), such Party shall deliver a written notice to the other Party specifying the issues, to the extent it is able, set for hearing or the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following the issuance of the Unfavorable FERC Decision.
(b) In the event of an Unfavorable FERC Decision, the Parties may agree upon amendments to this Agreement (each, a “ FERC Amendment ” ) that achieve, as nearly as practicable, the commercial intent of this Agreement as of the Execution Date in
18
a manner consistent with the Unfavorable FERC Decision. Any such amendment shall be subject to applicable regulatory approvals. As soon as practicable after any FERC Amendment(s) have been executed and delivered by the Parties, Owner shall file such FERC Amendment(s) with FERC.
(c) In the event of an Unfavorable FERC Decision, each Party shall retain the right to request a rehearing or reconsideration of the FERC Order regardless of any negotiations that have occurred or are occurring pursuant to clause (b) above; provided , however , that, in the event the Parties execute a FERC Amendment after any one or both of the Parties has filed for rehearing or reconsideration, any such rehearing or reconsideration request shall be withdrawn no later than five (5) Business Days after FERC issues an order accepting or approving the FERC Amendment for filing, if such rehearing or reconsideration request is inconsistent with the terms and conditions of this Agreement, as amended. Unless otherwise agreed in writing by the Parties, a filing by any Party of a request for rehearing or reconsideration of the FERC Order shall not toll or otherwise modify any date or time period set forth in this Agreement, including, for the avoidance of doubt, the date upon which the Construction Phase shall commence.
Section 2.3 Modifications Pursuant to Unfavorable MDPU Order or FERC Order . In the event the Regulatory Approval contains modifications or conditions that are unacceptable to Owner or Distribution Company, or in the event the MDPU issues an order setting for hearing Distribution Company’s submission (an order setting a hearing or containing unacceptable modifications or conditions is hereinafter referred to as “ Unfavorable MDPU Order ”), Owner shall promptly deliver a written notice to Purchaser of such occurrence. In the event (i) FERC issues an order accepting or approving the Distribution Company TSA for filing (the “ Distribution Company TSA FERC Order ”) and (ii) the Distribution Company TSA FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to Owner or Distribution Company, Owner shall promptly deliver a written notice to Purchaser of such occurrence. Owner and Distribution Company may agree to amend the Distribution Company TSA to address such modifications or conditions or to eliminate the issues raised in any such order or hearing, as applicable (any of the foregoing amendments, a “ Distribution Company TSA Amendment ”); provided that any Distribution Company TSA Amendment shall be subject to the prior written approval of Purchaser, which approval shall not be unreasonably withheld, delayed or conditioned. As soon as practicable after any Distribution Company TSA Amendment has been executed, Owner shall file such Distribution Company TSA Amendment with FERC and, if required, Owner shall use commercially reasonable efforts to cause Distribution Company to file such Distribution Company TSA Amendment with the MDPU, and the Parties shall execute and deliver an amendment to this Agreement as necessary to correspond with such Distribution Company TSA Amendment.
Section 2.4 Cooperation .
(a) In addition to their obligations under Section 2.1 , each Party shall, and each Party shall use commercially reasonable efforts to cause its Affiliates to, (i) cooperate with each other to prepare, file and effect any applications, notices, petitions, reports or other filings or documentation required under Applicable Law or otherwise necessary, proper or advisable to consummate the transactions contemplated by this
19
Agreement, (ii) provide updates to the other Party on material developments in connection with any such filings or documentation, (iii) provide any non-privileged information reasonably requested by the other Party in connection with any such filings or documentation, (iv) cooperate with the other Party to use commercially reasonable efforts to obtain all Governmental Approvals and Third Party Consents that are necessary, proper or advisable to consummate the transactions contemplated by this Agreement, including the FERC Authorization (without unacceptable modifications or conditions, except as permitted by this Agreement), the Municipal Owner Approvals, the other Owner Approvals and the Canadian Approvals and (v) provide any support reasonably necessary and requested by the AC Upgrade Owners to obtain the AC Upgrade Approvals.
(b) Each Party shall consult with the other Party with respect to all characterizations of information relating to such other Party, its Affiliates or the transactions contemplated by this Agreement that are proposed to appear in any filings or documentation contemplated by Section 2.1 or Section 2.4(a) . Each Party shall promptly provide comments, if any, to the other Party on any such characterizations of information. Each Party shall make a good faith effort to take into account any comments made by the other Party.
(c) Owner shall, and shall use commercially reasonable efforts to cause its Affiliates to, cooperate with Purchaser, as reasonably requested by Purchaser, to satisfy the conditions precedent in Section 3.4 of PPA and any related reporting requirements in the PPA in order for Purchaser to deliver and track unit specific accounting of environmental attributes, enabling the Massachusetts Department of Environmental Protection to accurately account for qualified clean energy in the state greenhouse gas emissions inventory, and transmit real time meter data and measurements to ISO-NE.
(d) Each Party shall use reasonable efforts to implement the provisions of, and to administer, this Agreement in accordance with the intent of the Parties to minimize all taxes, including delivery of the United States Internal Revenue Service Form W-9 and sales tax exemptions (if applicable), so long as neither Party is materially adversely affected by such efforts.
Section 2.5 No Inconsistent Action . Except as provided in Section 17.2 and Article XIX , from and after the Execution Date, the Parties shall not undertake, and shall use commercially reasonable efforts to cause their Affiliates not to undertake, any action before FERC, ISO-NE, or any other Governmental Authority that is contrary to the Party’s obligations under this Agreement, including, for the avoidance of doubt, Section 2.1(c) and Section 7.1.4 , or support any such contrary action by any Affiliate.
Article III
EFFECTIVE DATE; TERM
Section 3.1 Effective Date . Article I , Article II , this Section 3.1 , Section 3.3.1 , Section 3.3.2 , Article XVII , Article XVIII , Article XIX , Article XXII , and Article XXIII shall become effective and enforceable to the extent permitted by Applicable Law upon the Execution Date. The remaining provisions of this Agreement shall become effective and enforceable to the extent permitted by Applicable Law upon the effective date set forth in the FERC Order (the “ Effective
20
Date ” ). Notwithstanding the first sentence of this Section 3.1 , this Agreement will become effective as a FERC rate schedule upon the effective date set forth in the FERC Order. Notwithstanding any other provision of this Agreement, Purchaser shall have no obligation to make any payment under this Agreement prior to receipt of the Regulatory Approval and the FERC Authorization.
Section 3.2 Term . The term of this Agreement shall commence on the Execution Date and shall expire on the fortieth (40th) anniversary of the Commercial Operation Date, unless earlier terminated (in whole or in part) or extended in accordance with the terms hereof (the “ Term ” ).
Section 3.3 Termination Rights . This Agreement may be terminated in accordance with the ensuing provisions in this Article III , subject to any required regulatory reviews, approvals or acceptances, as applicable. Neither Party shall oppose any termination of this Agreement made in accordance with this Article III before FERC or any other Governmental Authority; provided , however , that the foregoing shall not prohibit any Party from challenging or otherwise Disputing whether or not any such termination is permitted by this Agreement.
Section 3.3.1 Failure to Obtain Satisfactory Regulatory Approval and FERC Authorization .
(a) This Agreement may be terminated by any Party in the event (i) it determines that the Regulatory Approval or the FERC Authorization contain terms and conditions that are, in its sole discretion, unacceptable to such Party, (ii) the Regulatory Approval is denied or is not received by January 25, 2020 (such date, the “ Regulatory Approval Termination Outside Date ”), (iii) the Regulatory Approval of the PPA (as defined in the PPA) is not received within the time frame set forth therein and the PPA is terminated, (iv) the FERC Authorization is denied or is not received by January 25, 2020, or (v) the Distribution Company TSA is terminated pursuant to Section 3.3.1(a) of the Distribution Company TSA; provided that the termination right under this clause (a) is exercised by a Party within thirty (30) days after the effective date of the termination of the Distribution Company TSA.
(b) Upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.2 Mutual Agreement . This Agreement may be terminated at any time upon written agreement of the Parties.
Section 3.3.3 Failure to Obtain Certain Approvals .
(a) Unless otherwise agreed in writing by the Parties, this Agreement shall terminate immediately without further action of the Parties in the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline, any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline, or any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof).
21
(b) In the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline or if any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof), and the Distribution Company TSA has been terminated pursuant to Section 3.3.3(a) of the Distribution Company TSA, Owner shall pay to Distribution Company the amounts contemplated by Section 3.3.3(b) of the Distribution Company TSA, and Owner shall pay to Purchaser (i) an amount equal to the Credit Support provided by Purchaser under this Agreement, including any Credit Support provided by Purchaser pursuant to Section 4.1(c) and (ii) in the event the PPA is terminated pursuant to Section 9.2(b) thereof, an amount equal to the Fixed Credit Support.
(c) In the event any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline (as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof), and the Distribution Company TSA has been terminated pursuant to Section 3.3.3(a) of the Distribution Company TSA, Purchaser shall pay to Owner an amount equal to the Credit Support provided by Owner to Distribution Company under the Distribution Company TSA, including the Owner Security (as defined in the Distribution Company TSA) and any additional Credit Support provided by Owner to Distribution Company pursuant to Section 4.1(c) of the Distribution Company TSA; provided that such amount shall exclude the Credit Support provided by Purchaser under this Agreement including any Credit Support provided by Purchaser pursuant to Section 4.1(c) .
(d) Except as otherwise provided in clause (b) or (c) above, upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.4 Purchaser Default .
(a) Owner shall have the right to terminate this Agreement in accordance with Section 14.4(a) .
(b) [Intentionally Omitted].
(c) Upon the exercise by Owner of its termination rights pursuant to clause (a) above, Owner shall have the right to recover from Purchaser, and Purchaser shall pay to Owner, the Purchaser Termination Payment in accordance with Section 14.4(a) .
(d) The exercise by Owner of its termination rights pursuant to clause (a) above shall constitute a waiver by Owner of all other remedies or damages that may be available at law or in equity against Purchaser; provided , however , that, except as provided in Section 14.7 , Owner shall not waive its right to, and Purchaser shall remain liable for, the Purchaser Termination Payment, any unpaid amounts owed by Purchaser pursuant to Section 8.1 , any amounts owed by Purchaser to Owner under Section 3.4 , Section 4.4.2 , or Section 4.4.3 and any indemnification obligations of Purchaser to Owner under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover the Purchaser Termination Payment or such indemnified or other amounts.
22
(a) Purchaser shall have the right to terminate this Agreement in accordance with Section 14.6(a) or Section 14.7(e)(i) .
(b) Upon the exercise by Purchaser of its termination rights pursuant to clause (a) above, subject to Section 14.7 , Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, the Owner Termination Payment in accordance with Section 14.6(a) .
(c) Subject to Section 14.7 , the exercise by Purchaser of its termination rights pursuant to clause (a) above shall constitute a waiver by Purchaser of all other remedies or damages that may be available at law or in equity against Owner; provided , however , that Purchaser shall not waive any right to, and Owner shall remain liable for, the Owner Termination Payment, any amounts owed by Owner to Purchaser under Section 3.4 or Section 14.7(f) hereof, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 hereof or any express modification of Purchaser’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Purchaser under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover such damages or such indemnified or other amounts owed to Purchaser by Owner.
Section 3.3.6 Force Majeure . This Agreement may be terminated in accordance with Section 15.1(c) .
Section 3.3.7 Extended Excused Outage . This Agreement may be terminated in accordance with Section 7.2(c) .
Section 3.4 Termination Payments .
(a) Within sixty (60) days following the termination of this Agreement pursuant to Section 3.3 , Owner shall deliver to Purchaser an invoice that sets forth Owner’s good faith estimate of the amounts owed to Owner by Purchaser under Section 3.3 , or Purchaser shall deliver to Owner an invoice that sets forth Purchaser’s good faith estimate of the amounts owed to Purchaser by Owner under Section 3.3 . The recipient of such invoice shall pay the amounts set forth in such invoice within thirty (30) days following its receipt of such invoice. Either Party may deduct and setoff payment of such amounts against any accrued but unpaid payment obligation of the payee to such Party hereunder. Upon the other Party’s request, the invoicing Party shall provide documentation describing the basis for the amounts invoiced in reasonable detail.
(b) The Parties acknowledge and agree that the payment of amounts by the defaulting Party to the non-defaulting Party pursuant to Section 3.3 or this Section 3.4 is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for the termination of this Agreement are difficult or impossible to determine and that the damages calculated under Section 3.3 or this Section 3.4 constitute a reasonable approximation of the harm or loss to the non-defaulting Party as a result thereof.
23
Section 3.5 Effect of Termination . Except as provided in Section 3.3 and in Section 23.12 for the survival of provisions, upon expiration or other termination of this Agreement pursuant to its terms, each of the Parties shall be released from all of its obligations under this Agreement, other than any accrued but unpaid payment obligation. Notwithstanding the foregoing sentence, upon such expiration or termination of this Agreement, either Party shall have the right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by such Party to recover any amounts owed to such Party by the other Party hereunder or to secure the release of any security or performance assurance provided by or on behalf of such Party after the later to occur of the end of the Term or the date on which any accrued but unpaid payment obligation of such Party to the other Party hereunder shall have been fully, finally and indefeasibly satisfied.
Article IV
COMMERCIAL OPERATION
Section 4.1 Critical Milestones .
(a) Subject to Section 4.1(c) , Section 4.1(d) and Section 4.1(e) , commencing on the Effective Date, Owner shall develop the NECEC Transmission Line in order to achieve the milestones set forth in clauses (i), (iii)-(v) and (vii) below, and Purchaser shall cause its Affiliates to develop the Québec Line in order to achieve the milestones set forth in clauses (ii), (vi) and (vii) below (each clause, a “ Critical Milestone ”) on or before the dates set forth in this Section 4.1(a) :
(i) Receipt of all Owner Approvals (other than the Municipal Owner Approvals) and AC Upgrade Approvals in final form by the Approval Deadline;
(ii) Receipt of all Canadian Approvals in final form by the Canadian Approval Deadline;
(iii) Receipt of the Municipal Owner Approvals in final form by the Municipal Owner Approval Deadline;
(iv) Closing of any financing required for the construction and operation of the NECEC Transmission Line or other demonstration to Purchaser’s reasonable satisfaction of the financial capability of Owner to construct the NECEC Transmission Line, including, as applicable, Owner’s financial obligations with respect to interconnection of the NECEC Transmission Line and construction of the AC Upgrades and the CCIS Capacity Upgrades by the Financing Deadline;
(v) Execution by Owner and a contractor of an agreement for the engineering, procurement, and construction of the converter station at the southern end of the HVDC Line and payment by Owner to the contractor of an initial payment of at least 5% of the total price of the agreement, both by the Converter Station Contract Deadline;
24
(vi) Execution by HQE of a contract that provides for the engineering, procurement, or construction of the converter station associated with the Québec Line by the Québec Converter Station Contract Deadline; and
(vii) Achievement of the Commercial Operation Date by the Target Date.
(b) Except for the achievement of the Commercial Operation Date, which shall be governed by the provisions of Section 4.2 , the Party responsible for achieving a Critical Milestone shall provide the other Party with written notice of the achievement of such Critical Milestone as set forth in Attachment B within seven (7) days after that achievement, which notice shall include information demonstrating with reasonable specificity that such Critical Milestone has been achieved. Each Party acknowledges that: (i) the Party receiving such notice does so solely to monitor progress toward the Commercial Operation Date; (ii) Purchaser shall not have any responsibility or liability for the development, construction, operation, and maintenance of the NECEC Transmission Line; and (iii) Owner shall not have any responsibility or liability for the development, construction, operation, and maintenance of the Québec Line.
(c) The following provisions shall govern the rights and obligations of the Parties to extend any of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA and the Critical Milestones not yet achieved under this Agreement:
(i) Purchaser may elect to require Owner to extend all of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA by up to four (4) six-month periods for a maximum combined period of two (2) years from the applicable dates set forth in Section 4.1(a) thereof by delivering Credit Support to Owner for the benefit of Distribution Company (in addition to the Twenty-One Million, Eight Hundred Thousand Dollars ($21,800,000) of security delivered to Distribution Company and the other RFP Sponsors by Purchaser pursuant to the PPA and the Additional PPAs) in an amount equal to $5,000 per MW of PPA Contract Maximum Amount for each such six-month period, with a pro rata adjustment of the amount of any such additional Credit Support for any partial reduction of the applicable six-month period pursuant to Section 4.1(e) . Any such election shall be made in a written notice to Owner on or prior to the first date for a Distribution Company TSA Critical Milestone that has not yet been achieved (as such date may have previously been extended). Such additional Credit Support shall be provided by Purchaser if there is a Purchaser Delay and Purchaser wishes to extend any Distribution Company TSA Critical Milestone date. In the event that there is both an Owner Delay and a Purchaser Delay and either Party wishes to extend any Distribution Company TSA Critical Milestone date by delivering additional Credit Support to Distribution Company, the additional Credit Support shall be provided in equal parts by Owner and Purchaser. Owner shall cause any additional Credit Support provided by Purchaser pursuant to this Section 4.1(c) to be returned to Purchaser upon the Commercial Operation Date; provided that, in the event the
25
Commercial Operation Date is not achieved by the Target Date, Distribution Company shall have the rights and remedies set forth in Article XIV of the Distribution Company TSA, which, for the avoidance of doubt, shall include recourse against any Credit Support provided to Distribution Company.
(ii) Owner may elect to extend all of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA in accordance with Section 4.1(c) of the Distribution Company TSA. Such additional Credit Support shall be provided by Owner if there is an Owner Delay and Owner wishes to extend any Distribution Company TSA Critical Milestone date. In the event that there is both an Owner Delay and a Purchaser Delay and either Party wishes to extend any Distribution Company TSA Critical Milestone date by delivering additional Credit Support to Distribution Company, the additional Credit Support shall be provided in equal parts by Owner and Purchaser.
(iii) Upon any extension of any of the dates for the Distribution Company TSA Critical Milestones not yet achieved under the Distribution Company TSA, the corresponding dates for the Critical Milestones not yet achieved hereunder shall be extended accordingly; provided that Owner shall not agree to any extension of the Distribution Company TSA Critical Milestones beyond what is permitted under the Distribution Company TSA or this Agreement without the prior written consent of Purchaser, such consent not to be unreasonably withheld, conditioned or delayed.
(d) To the extent a Force Majeure event pursuant to Section 15.1 has occurred that prevents Owner or Purchaser from achieving the Critical Milestone dates for execution of the contract to purchase the converter station for the NECEC Transmission Line ( Section 4.1(a)(v) ), execution of the contract to purchase the converter station for the Québec Line ( Section 4.1(a)(vi) ) or the Commercial Operation Date ( Section 4.1(a)(vii) ) by the applicable Critical Milestone date, the Critical Milestone date(s) impacted by such Force Majeure event shall be extended for the duration of the Force Majeure event, but under no circumstances shall extensions of those Critical Milestone dates exceed twelve (12) months beyond the applicable Critical Milestone date provided that (i) Owner shall not have the right to declare a Force Majeure event related to the Critical Milestone for Owner Approvals ( Section 4.1(a)(i) ), Municipal Owner Approvals ( Section 4.1(a)(iii) ), or the financing Critical Milestones ( Section 4.1(a)(iv) ); and (ii) Purchaser shall not have the right to declare a Force Majeure event related to the Critical Milestone for Canadian Approvals ( Section 4.1(a)(ii) ).
(e) In the event of a Regulatory Approval Delay, the date for each Critical Milestone not yet achieved shall be extended for the duration of the delay. The number of days of extension pursuant to the six-month extensions available under Section 4.1(c) shall be reduced by one day for each day of Regulatory Approval Delay pursuant to this subsection (e) up to a maximum reduction of 365 days. For purposes of illustration, Regulatory Approval Delay of two hundred ten (210) days would allow the Parties two six-month extensions and one extension of five months .
26
Section 4.2 Commercial Operation Date .
(a) The “ Target Date ” for Commercial Operation is December 13, 2022 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing. Absent written agreement by the Parties, the Target Date may not be extended beyond December 13, 2024 unless such extension is due to Regulatory Approval Delay or an event of Force Majeure as set forth in Sections 4.1(d) and 4.1(e) . The provisions of Sections 4.1(c) , 4.1(d) and 4.1(e) and all other provisions of this Agreement are subordinate to this Section 4.2(a) and the aforesaid Section 4.1 provisions and such other provisions shall be construed in a manner that is consistent with this Section 4.2(a) . Owner shall provide a written non-binding notice to Purchaser no later than sixty (60) days before the date Owner reasonably expects the Commercial Operation Date to occur.
(b) At the request of Owner made in writing, Purchaser shall, and shall use commercially reasonable efforts to cause its Affiliates to, cooperate with Owner, TransÉnergie and ISO-NE to support the Commissioning of the HVDC Transmission Project.
(c) As soon as practicable after Owner is of the opinion that the conditions to Commercial Operation, as set forth in Section 4.3 , have been satisfied, or such conditions have been waived in writing by the Parties (except in the case of Section 4.3(b) , Section 4.3(e) , Section 4.3(g) , Section 4.3(h) and Section 4.3(i) , which conditions may be waived in writing by Purchaser in its sole discretion), Owner shall deliver a written notice to Purchaser specifying the date upon which Commercial Operation shall commence (the “ COD Notice ” ), which commencement date shall occur no earlier than ten (10) Business Days after the receipt by Purchaser of the COD Notice or on such other date as agreed upon by the Parties in writing (such date, the “ Commercial Operation Date ” ).
(d) Within five (5) Business Days after the receipt by Purchaser of the COD Notice, Purchaser shall deliver a certificate to Owner either (i) confirming that the conditions set forth in Section 4.3 have been satisfied or duly waived and that Commercial Operation may commence on the Commercial Operation Date or (ii) objecting with reasonable detail to the COD Notice. Purchaser’s failure to respond in writing to a COD Notice within such five (5) Business Day period shall be deemed to be a confirmation that the conditions set forth in Section 4.3 have been satisfied or duly waived. Any Dispute over whether or not the conditions set forth in Section 4.3 have been satisfied or duly waived shall be resolved in accordance with Article XVII .
Section 4.3 Conditions Precedent to Commercial Operation . The items set forth in clauses (a) through (i) below shall be conditions precedent to the Commercial Operation of the NECEC Transmission Line:
(a) Completion of the Commissioning of the HVDC Transmission Project by Owner (in coordination with ISO-NE) and TransÉnergie;
27
(b) The NECEC Transmission Line has been constructed in accordance with Attachment A and Good Utility Practice, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(c) and Section 4.4.3(b) ;
(c) Completion of the AC Upgrades and the CCIS Capacity Upgrades;
(d) The Interconnection Agreements shall be in full force and effect;
(e) The Transmission Operating Agreement shall be in full force and effect and ISO-NE shall have informed Owner that ISO-NE (i) is prepared to assume operational control over the NECEC Transmission Line, as defined in, and in accordance with, the Transmission Operating Agreement and (ii) will assume such operational control as of the Commercial Operation Date;
(f) The Québec Line has been constructed in accordance with Attachment A , and is capable of operating at, the Design Capability, except as otherwise permitted pursuant to Section 4.4.2(b) and Section 4.4.3(b) ;
(g) Receipt by Purchaser of copies of certificates evidencing all outstanding insurance required or otherwise obtained under Section 5.4 ;
(h) Receipt by Purchaser of an opinion of legal counsel, reasonably satisfactory to Purchaser, that all Governmental Approvals and Third Party Consents required to own and operate the NECEC Transmission Line have been obtained;
(i) Distribution Company has confirmed (or has been deemed to have confirmed) that the conditions set forth in Section 4.3 of the Distribution Company TSA have been satisfied or duly waived; and
(j) The PPA is in full force and effect and binding against the parties thereto (except where the PPA has been terminated by mutual agreement of the parties to the PPA).
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation .
Section 4.4.1 Owner Delay . If, other than solely as a result of a Purchaser Delay, Force Majeure, or Concurrent Delay, any conditions set forth in Section 4.3 shall not have been satisfied or duly waived by the Target Date (such delay, an “ Owner Delay ”):
(a) Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, for each day (or part thereof) following the Target Date during which the Owner Delay is continuing and, but for such Owner Delay, Purchaser would then be capable of delivering the energy and providing the environmental attributes to Distribution Company as provided in the PPA, an amount equal to Fifty Dollars ($50) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Purchaser terminates this Agreement pursuant to Section 14.6 or Distribution Company terminates the Distribution Company TSA pursuant to Section 14.4 thereof and (z) the date that is twelve (12) months after the Target Date.
28
(c) Owner’s Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the Québec Line is capable of operating at or above 1,090 MW and the NECEC Transmission Line is only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line is capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the NECEC Transmission Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then Owner shall have twenty-four (24) months from the Commercial Operation Date to attempt to increase such operating capacity to 1,090 MW (the “ Remediation Period ”); provided that upon any extension of the Remediation Period (as defined in the Distribution Company TSA) under the Distribution Company TSA, the Remediation Period hereunder shall be extended accordingly. Owner shall pay to Purchaser, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period, or such earlier date designated by Owner in writing to Distribution Company (the “ Owner Remediation Date ”), an amount equal to Fifty Dollars ($50) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and the operating capacity of the NECEC Transmission Line as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Purchaser to Owner. Owner’s payments shall be based on the actual operating capacity of the NECEC Transmission Line, as is stated in Section 8.1 .
(ii) If, on the earlier of the Owner Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line has been increased to at or above 1,075 MW but less than 1,090 MW, then Owner shall be liable to Purchaser for an amount equal to the Proportionate Share multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the Commercial Operation Date in connection with the development and construction of the Québec Line multiplied by the percentage equal to (A) the difference between (x) the 1,090 MW and (y) the operating capacity of the NECEC Transmission Line divided by (B) the 1,090 MW. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(d) The Parties acknowledge and agree that the payment of amounts by Owner to Purchaser under clauses (a) and (c) above are an appropriate remedy and that any such modification or payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for an Owner Delay or a reduction in operating capacity, as described in clause (c), are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Purchaser as a result thereof.
29
(e) The rights provided in Section 3.3.5 , this Section 4.4.1 , and Section 4.4.3 shall collectively be the sole and exclusive remedies of Purchaser with respect to an Owner Delay or a reduction in operating capacity, as described in clause (c). The foregoing sentence shall not be construed in any way to limit (i) Purchaser’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement, or (ii) Purchaser’s rights to recover payment of any indemnification obligations of Owner to Purchaser pursuant to Section 20.2 .
Section 4.4.2 Purchaser Delays .
(a) Subject to any extension of any Critical Milestone date pursuant to the Distribution Company TSA or Section 4.1(c) , Section 4.1(d) , or Section 4.1(e) hereof, if, except in the event of Force Majeure, on the Target Date, solely as a result of delays in completing the Québec Line or operational difficulties with the Québec Line (a “ Purchaser Delay ” ), the Commercial Operation Date is delayed, for each day (or part thereof) during which the Purchaser Delay is continuing, Purchaser will pay to Owner an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity per day for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Owner terminates this Agreement pursuant to Section 14.4 or Distribution Company terminates the Distribution Company TSA pursuant to Section 3.3.8 thereof and (z) twelve (12) months after the Target Date.
(b) Purchaser’s Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line is capable of operating at or above 1,090 MW and the Québec Line is only capable of operating below 1,090 MW, and (A) the Québec Line is capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the Québec Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then Purchaser shall have the Remediation Period to attempt to increase the operating capacity of the Québec Line to 1,090 MW; provided that upon any extension of the Remediation Period (as defined in the Distribution Company TSA) under the Distribution Company TSA, the Remediation Period hereunder shall be extended accordingly. Purchaser shall pay to Owner, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period, or such earlier date designated by Owner pursuant to the Distribution Company TSA (the “ Purchaser Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between 1,090 MW and the operating capacity of the Québec Line.
30
(ii) If, on the earlier of the Purchaser Remediation Date and the end of the Remediation Period, the operating capacity of the Québec Line has been increased to at or above 1,075 MW but less than 1,090 MW, then Purchaser shall be liable to Owner for the Qu é bec Line Capacity Deficiency Payment. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the Québec Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(c) The Parties acknowledge and agree that the payment of amounts by Purchaser to Owner under clauses (a) and (b) above, respectively, are an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Purchaser Delay or a reduction in operating capacity, as described in clause (b) , are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Owner as a result thereof.
(d) The rights provided in Section 3.3.4 , this Section 4.4.2 and Section 4.4.3 shall collectively be the sole and exclusive remedies of Owner with respect to a Purchaser Delay or a reduction in operating capacity, as described in clause (b) . The foregoing sentence shall not be construed in any way to limit (i) Owner’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Purchaser under this Agreement, or (ii) Owner’s rights to recover payment of any indemnification obligations of Purchaser to Owner pursuant to Section 20.1 .
Section 4.4.3 Concurrent Delays .
(a) In the event of a concurrent Purchaser Delay and Owner Delay (a “ Concurrent Delay ”), for each day (or part thereof) during which a Concurrent Delay is continuing, Owner shall pay to Distribution Company the amounts required under Section 4.4.2(a) of the Distribution Company TSA; provided , however , that Purchaser shall be liable to Owner for such portion of the amounts paid by Owner to Distribution Company under Section 4.4.2(a) of the Distribution Company TSA that is in proportion to Purchaser’s share of liability for the Concurrent Delay.
(b) Concurrent Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are both only capable of operating below 1,090 MW, and (A) the NECEC Transmission Line and the Québec Line are both capable of operating at or above 1,040 MW and despite such condition Owner elects to begin transmission service under the Distribution Company TSA or (B) the NECEC Transmission Line or the Québec Line, or both, are capable of operating at less than 1,040 MW and despite such condition Owner requests and Distribution Company provides written consent to begin transmission service under the Distribution Company TSA, then the Parties
31
shall have the Remediation Period to attempt to increase the operating capacity of their respective lines to 1,090 MW. If the actual capacity of the Québec Line is less than the actual capacity of the NECEC Transmission Line as of the Commercial Operation Date, Purchaser shall pay to Owner, for each day (or part thereof) following the Commercial Operation Date and until the end of the Remediation Period or such earlier date designated by Owner pursuant to the Distribution Company TSA (the “ Concurrent Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the Proportionate Share of the difference between the lesser of (x) the actual capacity of the NECEC Transmission Line and (y) 1,090 MW and the actual capacity of the Québec Line as of the Commercial Operation Date. Such payments shall be made on a monthly basis pursuant to invoices delivered by Owner to Purchaser.
(ii) Québec Line Capacity is Lower . If, on the earlier of the Concurrent Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW (and Distribution Company has waived any deficiency in capacity of the Québec Line or the NECEC Transmission Line), and the actual capacity of the Québec Line is less than the actual capacity of the NECEC Transmission Line, then Purchaser shall be liable to Owner for the Québec Line Capacity Deficiency Payment. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the Québec Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(iii) NECEC Transmission Line Capacity is Lower . If, on the earlier of the Concurrent Remediation Date and the end of the Remediation Period, the operating capacity of the NECEC Transmission Line and the Québec Line have been increased to at or above 1,075 MW but less than 1,090 MW, and the actual capacity of the NECEC Transmission Line is less than the actual capacity of the Québec Line, then Owner shall be liable to Purchaser for an amount equal to the Proportionate Share of the difference between the actual capacity of the Québec Line and the actual capacity of the NECEC Transmission Line as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period, divided by an amount equal to 1,090 MW minus the actual capacity of the NECEC Transmission Line, multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period in connection with the development and construction of the Québec Line. Upon the making of such payment, this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line that was considered for the purpose of determining such payment, and the Contract Capacity shall be deemed modified accordingly.
(iv) Both Lines Have Capacity Shortfall . If: (1) as of the Commercial Operation Date, the NECEC Transmission Line and the Québec Line are both not capable of operating at or above 1,040 MW, and Distribution Company has not agreed in writing to begin transmission service under the
32
Distribution Company TSA notwithstanding such operating capability, or (2) as of the earlier of the Concurrent Remediation Date or the end of the Remediation Period, the NECEC Transmission Line and the Québec Line are both not capable of operating at or above 1,075 MW and Distribution Company has not waived such deficiency under the Distribution Company TSA, then Purchaser shall pay to Owner one-half (1/2) of the Owner Termination Payment (as defined in the Distribution Company TSA) payable to Distribution Company under the Distribution Company TSA as a consequence thereof.
Article V
GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES
Section 5.1 Responsibilities of the Parties .
Section 5.1.1 Construction Phase .
(a) During the Construction Phase, Owner shall (i) exercise Good Utility Practice to complete, or cause the completion of, all tasks required to construct the NECEC Transmission Line, interconnect at least 1,090 MW of capacity with ISO-NE in compliance with the Capacity Capability Interconnection Standard, and achieve Commercial Operation by the Target Date, in each case, in accordance with the Design Capability and in a manner consistent with Attachment A and (ii) use commercially reasonable efforts (A) to obtain all of the Construction Authorizations (other than the Municipal Owner Approvals) by the Approval Deadline and to obtain the Municipal Owner Approvals by the Municipal Owner Approval Deadline, (B) to obtain, in consultation with Purchaser, the ISO-NE Approval by the Approval Deadline and (C) to cause Owner’s Affiliates that are AC Upgrade Owners to obtain any AC Upgrade Approvals for which such Affiliates are responsible by the Approval Deadline and to assist other AC Upgrade Owners in obtaining their respective AC Upgrade Approvals by the Approval Deadline.
(b) Owner will use commercially reasonable efforts to enter into, within a commercially reasonable timeframe, one or more Construction Contracts. Owner will make a copy of any such contract available to Purchaser subject to such redactions as Owner or the contracting party deem necessary to protect confidential information.
(c) [ Intentionally Omitted .]
(d) During the Construction Phase, Purchaser shall take commercially reasonable steps to cause its Affiliate, TransÉnergie, to exercise Good Utility Practice to complete, or cause the completion, of all tasks required to construct the Québec Line in accordance with the applicable design, as set forth in Attachment A , prior to the Target Date and to cooperate with Owner to enable the achievement of Commercial Operation by the Target Date, and Purchaser shall cause TransÉnergie to use commercially reasonable efforts to obtain the Canadian Approvals by the Canadian Approval Deadline.
33
Section 5.2 Schedules and Reports .
Section 5.2.1 Owner’s Preliminary Schedule . Attached hereto as Attachment E is Owner’s Project Schedule (the “ Owner’s Preliminary Schedule ”). At the request of Purchaser, Owner shall make the personnel responsible for preparing the Owner’s Preliminary Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Preliminary Schedule with Purchaser.
Section 5.2.2 Owner’s Construction Schedule . Within ten (10) days after the end of each calendar quarter and sooner if a material change occurs, commencing at least ninety (90) days prior to the commencement of construction, Owner shall prepare and submit to Purchaser for review an update of the Owner’s Preliminary Schedule (such updated schedule as established herein, the “ Owner’s Construction Schedule ”). At the request of Purchaser, Owner shall make the personnel responsible for preparing the Owner’s Construction Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Construction Schedule with Purchaser.
Section 5.2.3 Owner’s Progress Reports .
(a) Promptly following the Execution Date, Owner shall deliver to Purchaser copies of all applications that have been submitted by Owner with respect to any Owner Approvals, as well as all material correspondence and submittals relating to such Owner Approvals. Within ten (10) days after the end of each calendar quarter, commencing at receipt of the Regulatory Approval, Owner shall prepare and submit to Purchaser for review a progress report for informational purposes that sets forth in reasonable detail the current status of the milestones set forth in the Owner’s Construction Schedule, including any changes in the expected timelines and the status of all Owner Approvals and including copies of any Owner Approval applications, material correspondence and submittals relating to Owner Approvals, and any issued Owner Approvals (the “ Owner’s Construction Progress Report ”). Without limitation of the foregoing, Owner shall include in such reports relevant information relating to: (i) Owner’s efforts to mitigate the impacts of the NECEC Transmission Line on natural resources, environmentally sensitive areas, habitats, and wildlife species, and cultural and historic resources; (ii) Owner’s efforts to comply with applicable noise ordinances; (iii) Owner’s communication and community outreach efforts and plans with respect to the construction of the NECEC Transmission Line, including with stakeholders in Massachusetts; and (iv) Owner’s analysis of, and any material developments related to, the Municipal Owner Approvals (or any applications to the Maine Public Utilities Commission to exempt Owner from the requirement to obtain any Municipal Owner Approval). In delivering the Owner’s Construction Progress Report, Owner shall be deemed to certify that the list of required Municipal Owner Approvals identified in paragraph 10 of Attachment C is accurate and complete as of the date of delivery of the Owner’s Construction Progress Report except as supplemented in such report. At the request of Purchaser, Owner shall, or shall cause each contractor to, provide Purchaser with access to, and copies of, all reasonably requested documentation concerning such Owner’s Construction Progress Report.
34
(b) Owner shall, or shall cause the principal contractor to, notify Purchaser promptly, but in no event later than ten (10) days, after Owner, or such contractor, becomes aware that the Commercial Operation of the NECEC Transmission Line is not reasonably likely to occur by the Target Date.
Section 5.3 Québec Line Reports; Joint Development Agreement . Purchaser agrees to cooperate with and support Owner in connection with the negotiation and execution of a joint development agreement between TransÉnergie and Owner relating to the Owner Approvals, the Canadian Approvals and construction and design matters relating to the Québec Line and the NECEC Transmission Line (such agreement, the “ Joint Development Agreement ”). Until the execution of the Joint Development Agreement, Purchaser shall promptly provide to Owner all material information received from TransÉnergie with respect to progress on the construction of the Québec Line, including information related to the Canadian Approvals.
Section 5.4 Insurance and Events of Loss . Owner shall obtain and maintain with reputable insurers authorized to operate in the scope of the Agreement insurance of the type as set forth in Attachment F . Owner shall provide Purchaser with copies of certificates of all outstanding insurance obtained hereunder promptly after the receipt thereof by Owner. Owner shall notify Purchaser as soon as reasonably possible if and whenever an event of loss occurs. Without limitation of any obligations Owner may have under Section 15.1 hereof, in the event of damage to or loss of all or part of the NECEC Transmission Line, Owner shall exercise prompt, diligent commercially reasonable efforts to effectuate, in accordance with Good Utility Practice, such repairs and replacements as are necessary or desirable to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss, including, for the avoidance of doubt, the application to such repairs or replacements of any potential or actual proceeds realized in connection with such damage or loss under any available or applicable insurance policies (subject to insurance contract/policy terms and conditions of coverage) maintained pursuant to this Section 5.4 . Subject to Owner’s compliance, in all material respects, with this Section 5.4 , Section 6.3 and all other material terms and conditions with respect to the operation and maintenance of the NECEC Transmission Line, in the event that the costs to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss exceed the available insurance proceeds by more than the greater of (a) an amount equal to three percent (3%) of the Net Book Value of the NECEC Transmission Line and (b) Thirty Million Dollars ($30,000,000), the Parties will negotiate in good faith an appropriate allocation of financial responsibility for such excess costs. In the event that the Parties do not agree on the allocation of financial responsibility, Purchaser shall be entitled to terminate this Agreement, upon thirty (30) days’ written notice to Owner, without liability to Owner; provided that, if within the thirty (30) day period following receipt of such notice, Owner agrees to assume that portion of the allocation of financial responsibility to which Purchaser objected, then the termination notice shall be deemed revoked and this Agreement shall not be terminated.
Section 5.5 Compliance with Laws . At all times during the Term, the Parties shall comply with all Applicable Laws (including ISO-NE Rules to the extent applicable) and relevant Governmental Approvals and Third Party Consents.
35
Section 5.6 Third Party Contracts . At all times during the Term, Owner shall, in a commercially reasonable manner, (a) satisfy its obligations under all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades, and (b) administer all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades.
Section 5.7 Purchaser’s Losses . Neither Purchaser nor its Affiliates shall be entitled to recover from Owner any losses, damages, costs or expenses related to the Québec Line or arising under the TransÉnergie OATT, except to the extent included in (a) an Owner Termination Payment, or (b) any damages paid pursuant to Section 4.4.1(a) , Section 4.4.1(c) , or Section 4.4.3 .
Section 5.8 Continuity of Rights and Responsibilities . Unless otherwise agreed in writing by the Parties or prohibited by Applicable Law, the Parties shall continue to provide service and honor commitments under this Agreement and continue to make payments in accordance with this Agreement pending resolution of any bona fide Dispute hereunder or relating hereto.
Section 5.9 Right of First Offer to Purchase NECEC Transmission Line .
(a) Subject to the receipt of any required regulatory approvals and Third Party Consents, prior to conducting any Marketing Activities, Owner shall provide Purchaser with the right to offer to buy, directly or through an Affiliate, the NECEC Transmission Line in accordance with this Section 5.9 , by providing Purchaser with written notice of Owner’s intent to sell the NECEC Transmission Line (to the extent that such sale relates only to the NECEC Transmission Line without any other material assets) (such notice, a “ Marketing Notice ”). Upon receipt of the Marketing Notice, Purchaser shall then have forty five (45) days to make an offer to purchase the NECEC Transmission Line, which offer shall contain reasonably detailed information relating to the price (such price, the “ Offer Price ”) and all material economic terms of the transaction upon which Purchaser is willing to purchase the NECEC Transmission Line. If Purchaser elects to make such an offer, Owner shall, within thirty (30) days following the receipt of such offer, either (i) accept such offer, in which case the parties will proceed to close the purchase of the NECEC Transmission Line within the next sixty (60) days (or such longer period as is reasonably necessary to obtain all required approvals and consents) on the terms contained in such offer, or (ii) reject such offer.
(b) If Owner rejects the offer made by Purchaser, then Owner shall be free to thereafter sell the NECEC Transmission Line to third parties (subject to the provisions of this Agreement) within the twelve (12) months following the date of Owner’s rejection of Purchaser’s offer for a price higher than one hundred percent (100%) of the Offer Price, with economic terms not materially less favorable to Owner (taken in the aggregate) than those contained in Purchaser’s offer (or, if materially less favorable, then with such adjustments to the price to account for any such material differences in the economic terms of the sale).
36
Section 5.10 Amendment to the PPA . Purchaser shall not amend or otherwise modify the PPA, or seek or provide any waiver of any term or condition of the PPA, in a manner that adversely and materially affects Purchaser’s rights under this Agreement or that would result in an increase in Owner’s liability pursuant to clause (b) of “Owner Termination Payment,” clause (b)(ii) of “Owner Termination Payment” (as defined in the Distribution Company TSA) or Section 3.3.3 or that would affect Owner’s rights under Section 7.2(b) without the consent of Owner, which consent shall not be unreasonably withheld, conditioned or delayed. Purchaser shall provide Owner with notice of any amendment or other modification to Section 8.3 of the PPA prior to the effective date of such amendment.
Section 5.11 Amendment to the Distribution Company TSA . Owner shall not (a) terminate the Distribution Company TSA pursuant to Section 3.3.2 thereof or (b) agree to any amendment or other modification of the Distribution Company TSA, or seek or provide any waiver of any term or condition of the Distribution Company TSA, that adversely and materially affects Purchaser’s rights under this Agreement (including in a manner that would result in an increase in the credit support provided by Owner under the Distribution Company TSA), in each case without the consent of Purchaser, which consent shall not be unreasonably withheld, conditioned or delayed.
Article VI
PROCEDURES FOR OPERATION AND MAINTENANCE
OF THE NECEC TRANSMISSION LINE
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control .
(a) Prior to entering into the Transmission Operating Agreement, Owner shall consult Purchaser with respect to the proposed terms and conditions thereof and Owner shall make a good faith effort to take into account any comments made by Purchaser. Purchaser shall promptly provide comments, if any, to Owner on such terms and conditions.
(b) As of the Commercial Operation Date, Owner shall transfer operational control over the NECEC Transmission Line, as defined in the Transmission Operating Agreement, to Transmission Operator in accordance with the Transmission Operating Agreement. Owner shall provide, and shall direct its Affiliates to provide, such information as Transmission Operator may require to discharge its obligations under the Transmission Operating Agreement, and Owner shall comply with the instructions of Transmission Operator to the extent provided in the Transmission Operating Agreement and the ISO-NE Tariff. The Parties acknowledge and agree that Owner shall not be in breach of, or be liable to Purchaser under, this Agreement, and no Owner Default shall occur, as a consequence of Owner’s compliance with such instructions of Transmission Operator; provided that Owner did not initiate or support instructions that would otherwise breach Owner’s obligations under this Agreement.
37
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements . From and after the Commercial Operation Date, Owner shall (a) provide Firm Transmission Service, (b) operate and maintain the NECEC Transmission Line in accordance with Good Utility Practice and in compliance with all applicable regulatory requirements, including applicable NERC and Northeast Power Coordinating Council reliability standards, and (c) comply with all applicable operating instructions of ISO-NE and manufacturers’ warranties.
Section 6.3 Scheduled Maintenance . With respect to each calendar year (or portion thereof) following the Construction Phase, Owner will prepare and deliver to Purchaser a Maintenance Plan not later than the Commercial Operation Date and two (2) months prior to the end of each calendar year thereafter, and shall be available for consultation with Purchaser with respect thereto (including for coordination of maintenance schedules). Consistent with Good Utility Practice, Owner shall use commercially reasonable efforts to coordinate with TransÉnergie with respect to scheduled maintenance so as to minimize outages, including by meeting annually (or as otherwise necessary in order to comply with any applicable ISO-NE or Canadian regulatory or system operator requirements) to develop a Maintenance Plan. From and after the Commercial Operation Date, Owner shall coordinate all planned maintenance with ISO-NE, consistent with ISO-NE Rules, and shall promptly provide applicable information concerning scheduled outages, as determined by ISO-NE, to Purchaser. To maximize value, to the extent possible and consistent with ISO-NE Rules, Owner shall not schedule maintenance of the NECEC Transmission Line during the months of December, January and February or June through September and shall operate the NECEC Transmission Line so as to maximize energy production during the hours of anticipated peak load and energy prices in New England; provided , however , that planned maintenance may be scheduled during such period to the extent the failure to perform such planned maintenance is contrary to operation of the NECEC Transmission Line in accordance with Good Utility Practice. Owner may modify a Maintenance Plan in accordance with Good Utility Practice; provided, however, that (a) a Maintenance Plan may not be modified for the purpose of reducing the magnitude or duration of a Non-Excused Outage, (b) any modification shall, to the extent commercially reasonable, maximize value in the manner described in this Section 6.3 and (c) Owner shall provide Purchaser with reasonable notice of any change in a Maintenance Plan. Any maintenance that is not included in the Maintenance Plan for a year and is not otherwise excused under Section 7.2 shall be a Non-Excused Outage.
Article VII
PURCHASER’S TRANSMISSION RIGHTS OVER THE
NECEC TRANSMISSION LINE
Section 7.1 Transmission Service .
Section 7.1.1 Firm Transmission Service . Owner shall make available to Purchaser throughout the Purchaser Term transmission capacity on the NECEC Transmission Line in order to deliver electrical energy, as scheduled by Purchaser or its designee or assignee under the resale provisions of Article X , in such scheduled amount up to the Contract Capacity, measured at the Delivery Point (“ Firm Transmission Service ”). Firm Transmission Service shall be made available over the NECEC Transmission Line during the Purchaser Term, in a north-to-south direction, and to the extent available in a south-to-north direction, between the U.S. Border
38
and the Delivery Point. Firm Transmission Service shall be subject to curtailment or interruption only as a result of an Excused Outage or as provided in Section 14.4(b) . Without limiting Owner’s obligations under this Section 7.1.1 , the quantity of Firm Transmission Service that Owner will provide in any hour shall not exceed the Proportionate Share of the Available Transfer Capability for such hour.
Section 7.1.2 Limitation on Transmission Service . Owner shall have no obligation to provide transmission service under this Agreement other than Firm Transmission Service. Purchaser shall have no right to redirect service to alternate points of delivery or receipt on any portion of the transmission system operated by ISO-NE other than the NECEC Transmission Line.
Section 7.1.3 Scheduling . All Firm Transmission Service shall be scheduled in accordance with the rules relating to the scheduling of electrical energy or capacity transactions over the NECEC Transmission Line, as established under the Transmission Operating Agreement (the “ Scheduling Rules ”).
Section 7.1.4 Owner’s Cooperation . Owner shall provide Purchaser with notice of any FERC or NERC regulatory proceedings relating to the NECEC Transmission Line or this Agreement to which Owner is a party promptly after Owner becomes aware of any such proceedings. Each Party will act in good faith regarding any such proceedings. Neither Party shall take any position in such proceeding that is contrary to such Party’s obligations under this Agreement.
Section 7.2 Excused Outages or Reductions .
(a) Notwithstanding anything herein to the contrary, Owner shall not be in breach of, or be liable to Purchaser for any losses or damages under, this Agreement, and no Owner Default shall occur, as a consequence of an Excused Outage. “ Excused Outages ” means any outages of the NECEC Transmission Line or reductions in the Total Transfer Capability below the NECEC Transmission Line Capacity, whether as a result of a physical condition, legal impediment or otherwise, if and to the extent such outage or reduction is due to:
(i) Events of Force Majeure;
(ii) Scheduled maintenance in accordance with the applicable Maintenance Plan;
(iii) Outages or reductions in the availability of the Québec Line for any reason; or
(iv) Decisions of ISO-NE or any other independent system operator to reduce or suspend scheduling rights over the NECEC Transmission Line or the Québec Line, including as a result of any grid reliability issue, emergency condition as defined in any Interconnection Agreement or the ISO-NE Tariff, or to preserve facilities and equipment from physical damage and including any such decisions that arise from outages or reductions in the use or availability of transmission lines other than the NECEC Transmission Line or the Québec Line, which outage or reduction arises from or is attributable to Force Majeure or scheduled maintenance.
39
(b) Notwithstanding anything in Section 7.3.1 to the contrary, Purchaser shall remain obligated, during and to the extent of any Excused Outage, to pay the Transmission Service Payment without downward adjustment to reflect any such outage, reduction or delay. Owner shall seek to avoid and mitigate or remedy any Excused Outage consistent with Good Utility Practice.
(c) Notwithstanding anything herein to the contrary and without regard to whether an Excused Outage is due to Force Majeure, if an Excused Outage prevents Owner’s full or partial performance under this Agreement during the Purchaser Term for a period of twelve (12) consecutive months or more, Purchaser shall have the right, as provided in Section 15.1(c) herein, to terminate this Agreement upon written notice to Owner and without further recourse.
Section 7.3 Non-Excused Outages or Reductions .
Section 7.3.1 Reduction in Transmission Service Payments. In the event the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), u nless otherwise excused under Section 7.2 or Section 11.1 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 during the Term or firm transmission service contemplated by Section 7.1.1 of the Distribution Company TSA during the term of the Distribution Company TSA, Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, for each such month during which a Non-Excused Outage occurs, the Non-Excused Outage Payment; provided that, in no event, shall the total amount of (a) all Non-Excused Outage Payments made in any Contract Year under this Agreement plus (b) all Non-Excused Outage Payments (as defined in the Purchaser TSAs) made in any Contract Year plus (c) all Non-Excused Outage Payments (as defined in the 110 MW TSA) made in any Contract Year exceed Twenty Million Dollars ($20,000,000); provided further that such cap shall be proportionately reduced in any Contract Year that is less than a full calendar year. Any Dispute over whether or not or to what extent a Non-Excused Outage has occurred shall be resolved in accordance with Article XVII . Such amounts shall be payable on a monthly basis pursuant to invoices delivered by Purchaser to Owner. Owner shall seek to avoid, mitigate and remedy any Non-Excused Outage consistent with Good Utility Practice.
Section 7.3.2 [ Intentionally Omitted ] .
Section 7.3.3 Liquidated Damages . The Parties acknowledge and agree that the payment of amounts by Owner to Purchaser under Section 7.3.1 and the modification of Purchaser’s payment obligations pursuant to Section 8.1 are an appropriate remedy and that any such payment or modification does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Non-Excused Outage are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Purchaser as a result thereof.
40
Section 7.3.4 Sole and Exclusive Remedy . The rights provided in Section 3.3.5 , this Section 7.3 and Section 8.1 shall collectively be the sole and exclusive remedies of Purchaser with respect to a Non-Excused Outage, subject to (a) Purchaser’s right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement, (b) Purchaser’s right to recover payment of any indemnification obligations of Owner to Purchaser pursuant to Section 20.1 , (c) Purchaser’s rights upon the occurrence of an Owner Default as described in Section 14.3 or (d) Purchaser’s rights in the event of Real Power Losses pursuant to Section 11.1 .
Section 7.4 Allocation of Outages . Except as set forth in this Section 7.4 with respect to the 110 MW TSA, the Parties expressly intend and agree that any outages or reductions in Total Transfer Capability shall be borne equitably by all transmission rights holders served by the NECEC Transmission Line (including Owner, if applicable), and Owner acknowledges and agrees that it will not reduce the Firm Transmission Service available to Purchaser in an unduly discriminatory manner as compared with any other transmission rights holder served by the NECEC Transmission Line (including Owner, if applicable). Purchaser’s transmission service under the 110 MW TSA shall be reduced before any reductions are applied to Distribution Company’s transmission service under the Distribution Company TSA or the Additional RFP Sponsor TSAs.
Section 7.5 Metering . Metering and telemetering requirements for the NECEC Transmission Line shall be established by Owner in accordance with Good Utility Practice and as necessary to (a) accomplish the purposes of, and to implement and administer, this Agreement and (b) satisfy the requirements of, and to implement and administer, the PPA, the Interconnection Agreement and the Transmission Operating Agreement.
Section 7.6 Line Availability Information and Reporting . Owner shall make available to Purchaser on a real time basis information relating to the operation and availability of the NECEC Transmission Line and shall provide such additional information as Purchaser shall reasonably request.
Article VIII
PAYMENTS FOR TRANSMISSION SERVICE OVER THE
NECEC TRANSMISSION LINE
Section 8.1 Transmission Service Payments . During the period beginning on the twentieth (20th) anniversary of the Commercial Operation Date and ending on the fortieth (40th) anniversary of the Commercial Operation Date (unless earlier terminated) (the “ Purchaser Term ” ), except to the extent such payment is excused or reduced pursuant to the terms of this Agreement, Purchaser shall pay to Owner a transmission service payment (the “ Transmission Service Payment ” ) on a monthly basis pursuant to invoices delivered by Owner to Purchaser equal to Seven Dollars Thirty Eight Cents ($7.38) per KW of Contract Capacity per month. The Transmission Service Payment shall be reduced in accordance with the formula set forth in Attachment G in the event and to the extent that the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non - Excused Outage is less than the Minimum Average Availability for such calendar month
41
(whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 . To the extent there is a Dispute over whether or not or to what extent a Non-Excused Outage has occurred , Purchaser’s right, pursuant to this Section 8.1 , to any reduction in the Transmission Service Payment shall be implemented upon the resolution of such Dispute and such reduction will be effective as of the date when such Dispute arose . Such adjustments shall be made on a monthly basis pursuant to invoices delivered by Owner to Purchaser.
Section 8.2 Adjustment to Rate Upon Purchaser Step-in . Notwithstanding anything in the Distribution Company TSA to the contrary, in the event Purchaser elects to assume the rights and obligations of Distribution Company under the Distribution Company TSA, as provided in Section 14.8(a) or 14.8(b) , the transmission service payment payable under the Distribution Company TSA by Purchaser for the remainder of the term thereunder shall be equal to that portion of the transmission service payment payable under the Distribution Company TSA comprising Owner’s non-capital expenses related to the NECEC Transmission Line, and Purchaser shall not be required to compensate Owner for any depreciation, equity return or cost of capital during the remainder of the term under the Distribution Company TSA. In the event of such assumption and upon request of Purchaser, the Parties shall amend the Distribution Company TSA to give effect to this Section 8.2 .
Section 8.3 Elective Upgrade Status; No Regional Rates . It is the intent of the Parties that the NECEC Transmission Line has Elective Transmission Upgrade status during the Term and that the AC Upgrades and the CCIS Capacity Upgrades constitute Network Upgrades under the ISO-NE Tariff required to accommodate the interconnection of the NECEC Transmission Line. The Parties acknowledge and agree that (a) as contemplated by the PPA, Purchaser shall participate in such Forward Capacity Auction (as defined in the ISO-NE Rules) qualification process as required to allow Purchaser to qualify a Seasonal Claimed Capability (as defined in the ISO-NE Rules) of not less than 1,200 MW over the NECEC Transmission Line no later than the Guaranteed Delivery Term Start Date (as defined in the PPA), as it may be extended pursuant to Sections 3.1(c) through 3.1(f) of the PPA and (b) such Network Upgrades, if any, shall be at Owner’s sole expense. It is the further intent of the Parties that Owner’s recovery of the investment in and return on the NECEC Facilities and Purchaser’s obligation to pay for the NECEC Facilities, shall be solely governed by this Agreement. The Parties each shall refrain from taking steps to include all or part of the NECEC Facilities in ISO-NE regional transmission rates during the Term. Notwithstanding the foregoing, if during the Term all or part of the NECEC Facilities are included in ISO-NE regional rates paid by Purchaser, the payment required by Section 8.1 shall be reduced by the Proportionate Share of the revenues received by Owner from such ISO-NE rates with respect to the NECEC Facilities. “NECEC Facilities” means the NECEC Transmission Line, the AC Upgrades, and the CCIS Capacity Upgrades.
42
Article IX
RIGHTS UPON EXPIRATION OF TERM
Section 9.1 Rollover Rights .
(a) Unless this Agreement is terminated early under Section 3.3 , Section 14.4 or Section 14.6 , Purchaser shall have rollover rights at the end of the Purchaser Term in accordance with FERC Order No. 890 et seq. and the FERC pro forma open access transmission service tariff, as such rights are defined as of the Effective Date.
(b) Owner shall not enter into any contract or other arrangement for use of the NECEC Transmission Line that is inconsistent with Purchaser’s rollover rights, as provided herein.
Article X
RESALE OF TRANSMISSION SERVICE
Section 10.1 Resale Rights of Purchaser . If and to the extent Purchaser (including, prior to the Purchaser Term, in its capacity as assignee of transmission rights under Section 20 of the PPA) determines from time to time, and in its sole discretion, that the transmission capacity available to Purchaser relevant to the receipt of Firm Transmission Service over the NECEC Transmission Line pursuant to this Agreement exceeds Purchaser’s needs, Purchaser shall then offer to resell such unused capacity to third parties in accordance with Applicable Law as may then be in effect (including the terms and conditions of FERC Order No. 890 et seq., if applicable).
Section 10.2 Capacity Releases for Daily and Hourly Use . From and after the Commercial Operation Date, if and to the extent the Proportionate Share of the Available Transfer Capability exceeds the amount of electrical energy that is scheduled by Purchaser for delivery over the NECEC Transmission Line using Firm Transmission Service by the applicable scheduling deadline (as in effect at such time) established pursuant to the Scheduling Rules, then the transmission capacity that is available for resale to third parties for the following day, and the price at which any such resales are offered, shall be posted on the OASIS site established pursuant to Section 10.3 .
Section 10.3 OASIS .
(a) Owner or an Affiliate of Owner (in such capacity, the “ OASIS Administrator ”) shall establish an OASIS site for the NECEC Transmission Line and administer such site in accordance with applicable FERC requirements for the establishment and administration of OASIS sites. None of Owner, the OASIS Administrator or Purchaser shall be liable to each other or any third party for any decisions the OASIS Administrator makes regarding the appropriate price for resales of unused transmission capacity or the level of any such resales the OASIS Administrator is able to make. The Parties agree that there shall be no damages as between each other or third parties for actions by the OASIS Administrator with respect to resales of unused transmission capacity.
43
(b) To the extent resales are made available by Purchaser pursuant to Section 10.1 , the OASIS Administrator shall post on the OASIS site information regarding such resales, (i) in accordance with written instructions provided by Purchaser from time to time and (ii) at a price established by Purchaser from time to time, and in its sole discretion, as permitted under Applicable Law.
Section 10.4 Proceeds from Capacity Releases and Transmission Resales . Except as otherwise provided in Section 14.4(b), Purchaser’s proceeds received by Owner of any capacity releases and transmission resales that are made during the Purchaser Term pursuant to this Article X shall be credited, net of reasonable fees (including attorneys’ fees) and other expenses incurred in connection with performance of the functions described in Section 10.2 and Section 10.3, against any Transmission Service Payment or other amounts owed to Owner by Purchaser for the calendar month subsequent to the calendar month in which such proceeds were received.
Section 10.5 Owner’s Rights and Obligations . Except as expressly provided in the Proposal Agreements, Owner shall have no right or obligation to offer any transmission service over the NECEC Transmission Line for sale or resale to any Person other than Purchaser, as provided herein.
Article XI
REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS
Section 11.1 Real Power Losses . Purchaser shall be responsible for all Real Power Losses associated with Firm Transmission Service; provided , however , that, if and to the extent any Real Power Losses associated with Firm Transmission Service between the U.S. Border and the Delivery Point are due to Owner’s failure to exercise Good Utility Practice or otherwise discharge its obligations under this Agreement, (a) such incremental Real Power Losses shall be treated as Non-Excused Outages for which Owner shall be liable in accordance with Section 7.3 and (b) the Transmission Service Payments owed by Purchaser shall be reduced pursuant to Section 8.1 ; and provided , further , that during the Term Owner shall (x) exercise diligent, commercially reasonable efforts to maximize the warranty or similar obligations of its vendors and suppliers for the NECEC Transmission Line with respect to such Real Power Losses under any Construction Contract or otherwise and (y) credit, assign or pay over to Purchaser any amounts receivable by or paid to Owner under such warranties or similar obligations, including liquidated damages under any Construction Contract, related to such Real Power Losses, and the rights and remedies contemplated by Section 3.3.5 , Section 7.3 , Section 8.1 and this Section 11.1 , shall collectively be the sole and exclusive remedy of Purchaser with respect to any such incremental Real Power Losses.
Section 11.2 Other Rights .
(a) Purchaser shall be entitled during the Purchaser Term to its Transmission Percentage of the following, without duplication and without additional cost to Purchaser or compensation to Owner: (i) all Other Transmission Rights associated with the NECEC Transmission Line or the AC Upgrades, in each case, that are issued in accordance with the ISO-NE Tariff or otherwise granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE and (ii) all other Market Products that are issued
44
in accordance with the ISO-NE Tariff or granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, that derive from the acquisition of transmission service over the NECEC Transmission Line. As Owner’s sole obligation under this clause (a), upon its receipt of any of the entitlements or rights described in the foregoing sentence, Owner shall promptly convey such entitlements or rights to Purchaser.
(b) In the event tie benefits or interconnection capability credits (or any similar concept) are ever deemed applicable to the NECEC Transmission Line and to the extent allocated to any Party during the Purchaser Term, Purchaser shall be entitled to its Transmission Percentage of one hundred percent (100%) of the economic benefits associated therewith (however entitled and whether existing now or in the future), without additional cost to Purchaser or compensation to Owner.
(c) Owner shall have no obligation to support the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above, but Owner may not oppose the creation or establishment of any such right, unless otherwise agreed in writing by Purchaser. Neither Section 2.5 nor the foregoing sentence shall be construed in any way to limit the right of any Affiliate of Owner to oppose the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above.
Article XII
[INTENTIONALLY OMITTED]
Article XIII
BILLING AND PAYMENTS
Section 13.1 Invoices . Within seven (7) Business Days after the first day of each calendar month following the commencement of the Purchaser Term, Owner shall submit an Invoice to Purchaser for the Transmission Service Payments owed for the preceding calendar month, and Purchaser shall pay the amounts set forth in the Invoice to Owner within fourteen (14) Business Days following its receipt of such Invoice. All payments shall be made in immediately available funds payable to Owner by wire transfer to a bank named by Owner, in accordance with wiring instructions provided to Purchaser by Owner in writing. Owner shall be entitled to change the place or recipient for payment by thirty (30) days’ prior written notice to Purchaser.
Section 13.2 Procedures for Billing Disputes .
(a) In the event of any Dispute with respect to the amount owed to Owner by Purchaser under this Agreement, Purchaser shall have no right to withhold payment of the Disputed amount pending resolution of the Dispute; provided , however , that, in the event such Dispute is resolved in favor of Purchaser, Owner shall complete the following tasks consistent with the resolution of such Dispute: (i) retroactively adjust all payments previously made by Purchaser; (ii) promptly refund all overpayments previously made by Purchaser, together with interest thereon in immediately available funds or by wire transfer, in each case, in accordance with wiring instructions provided to Owner by Purchaser in writing; and (iii) thereafter conform all future Invoices to reflect the resolution of such Dispute, as applicable. Purchaser’s payment of any Disputed amounts shall be without prejudice to any right or remedy that Purchaser may have under this Agreement to contest any such amount.
45
(b) Purchaser shall not have the right to challenge any Invoice or to bring any action of any kind challenging the propriety of any Invoice after the second (2nd) anniversary of the receipt of such Invoice. If an Invoice is not rendered within two (2) years after the end of the calendar month during which such Invoice should have been rendered hereunder, then the right to payment of such Invoice is waived.
Section 13.3 Interest . All interest payable under this Section 13.3 shall be calculated pursuant to 18 C.F.R. § 35.19a(a), as such regulation (or any successor thereto) is in effect during the period during which such interest is due. Amounts not paid when due to Owner or Purchaser under this Agreement shall bear interest from the date such amount was due until the date of payment of such overdue amount. For the avoidance of doubt, as illustrated in Attachment H , if all or a portion of the amount to which such interest relates is later refunded pursuant to this Agreement, then, in calculating that refund, such interest shall not be included in the refund. Refunds of overpayments owed to Purchaser by Owner under this Agreement shall begin to accrue interest on the amount subject to refund, as originally invoiced, from the earlier to occur of the due date or the date of payment of the monthly Invoices to which the overpayment relates and shall continue to accrue interest until the date of payment of such refund.
Section 13.4 Obligation to Make Payments . The Parties acknowledge and agree that, except as set forth in Section 8.1 , Section 13.5 and Section 14.6(d) , no cause or event whatsoever shall excuse or suspend Purchaser’s obligation to pay Transmission Service Payments or any other amounts payable by Purchaser under this Agreement. The Parties also acknowledge and agree that no cause or event whatsoever shall excuse or suspend any amounts payable by Owner under this Agreement.
Section 13.5 Offsets . Except as otherwise provided in Section 3.4(a) and Section 14.6(d) , neither Party shall be entitled to deduct or set-off payment of any amount owed to the other Party under this Agreement against payment of any amount owing under this Agreement. The Parties shall have the right to deduct or set-off payments of amounts owed hereunder against payments of amounts owing under the 110 MW TSA or the Purchaser TSAs.
Article XIV
EVENTS OF DEFAULT AND REMEDIES
Section 14.1 Purchaser Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Purchaser under this Agreement (a “ Purchaser Default ” ); provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (e), clause (f) or clause (g):
(a) Purchaser’s failure to pay any undisputed amount due to Owner under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Purchaser of a written demand from Owner that such amount is due and owing and has not been timely paid.
(b) Purchaser’s failure to comply in any material respect with the provisions of Article XVI .
46
(c) The failure of the Québec Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date (where the NECEC Transmission Line is capable of operating at or above 1,040 MW as of the Commercial Operation Date), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Purchaser Remediation Date or the end of the Remediation Period (where the NECEC Transmission Line is capable of operating at or above 1,075 MW as of the earlier of the Purchaser Remediation Date or the end of the Remediation Period), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability .
(d) Purchaser’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), and (c) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Purchaser of written notice thereof from Owner, unless such cure shall reasonably require a longer period, in which case Purchaser shall be provided an additional thirty (30) days to complete such cure so long as Purchaser has promptly commenced such cure and thereafter diligently pursues such cure.
(e) Any representation or warranty made by Purchaser in this Agreement is false or misleading at the time made in any material respect.
(f) Any Insolvency Event occurs with respect to Purchaser.
(g) An Event of Default (as defined in the PPA) by Purchaser under the PPA that does not result from a TSA Delivery Shortfall (as defined in the PPA) or a Transmission Delay (as defined in the PPA), or a Purchaser Default (as defined in the 110 MW TSA), occurs and is continuing.
Section 14.2 [Intentionally Omitted] .
Section 14.3 Owner Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Owner under this Agreement (an “ Owner Default ” ); provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (h) or clause (i):
(a) Owner’s failure to pay any undisputed amount due to Purchaser under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Owner of a written demand from Purchaser that such amount is due and owing and has not been timely paid.
(b) Owner’s failure to satisfy (other than as a result of a Purchaser Delay) any of the Critical Milestones in clauses (i), (iii), (iv), (v), or (vii) of Section 4.1(a) by the dates set forth therefor, as the same may be extended in accordance with Section 4.1(c) , Section 4.1(d) , or Section 4.1(e) .
47
(c) The failure of the NECEC Transmission Line to be capable of operating at or above 1,040 MW as of the Commercial Operation Date (where the Québec Line is capable of operating at or above 1,040 MW as of the Commercial Operation Date), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability, or to be capable of operating at or above 1,075 MW as of the earlier of the Owner Remediation Date or the end of the Remediation Period (where the Québec Line is capable of operating at or above 1,075 MW as of the earlier of the Owner Remediation Date or the end of the Remediation Period), where Distribution Company has also not agreed in writing to begin transmission service under the Distribution Company TSA notwithstanding such operating capability .
(d) Owner’s failure to comply in any material respect with the provisions of Section 5.1.1(a)(ii) and, if such failure is susceptible to cure, such failure continues for thirty (30) days after receipt by Owner of written notice thereof from Purchaser, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(e) A Non-Excused Outage pursuant to which (A) the Hourly Availability of the NECEC Transmission Line is less than one hundred percent (100%) for more than ninety (90) consecutive days and the average Hourly Availability of the NECEC Transmission Line over each calendar month in which the ninety (90) consecutive days occur is less than the Minimum Average Availability for each such month (whether as a result of a physical condition, legal impediment or otherwise), or (B) the Hourly Availability of the NECEC Transmission Line is less than one hundred percent (100%) for more than hundred twenty (120) days in any twelve (12) month period and the average Hourly Availability of the NECEC Transmission Line over each calendar month in which any such day occurs is less than the Minimum Average Availability for each such month (whether as a result of a physical condition, legal impediment or otherwise) in each case, unless otherwise excused under Section 7.2 , provided , however , that if (i) Owner presents to Purchaser and Distribution Company (before the Purchaser Term) or Purchaser (during the Purchaser Term) before the end of a Non-Excused Outage that would otherwise constitute an Owner Default under this clause (e) , a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to Distribution Company and Purchaser (before the Purchaser Term) or Purchaser (during the Purchaser Term), each acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, and (ii) prior to the start of the Purchaser Term, Owner posts Credit Support with Distribution Company as set forth in Section 14.2(e) of the Distribution Company TSA, Purchaser shall forbear terminating this Agreement under this clause (e) for such period, provided that, during any such period, Purchaser’s obligation to make Transmission Service Payments shall continue to be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, an Owner Default shall be deemed to have occurred and Purchaser shall have the rights and remedies set forth in Section 14.6 and Section 14.7 .
48
(f) Owner’s failure to comply in any material respect with the provisions of Article XVI .
(g) Owner’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), (c), (d), or (e) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Owner of written notice thereof from Purchaser, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(h) Any representation or warranty made by Owner in this Agreement is false or misleading at the time made in any material respect.
(i) Any Insolvency Event occurs with respect to Owner.
(j) An Owner Default (as defined in the Distribution Company TSA) that is not attributable to the operating capability of the Québec Line, or an Owner Default (as defined in the 110 MW TSA), occurs and is continuing.
Section 14.4 Remedies Upon Purchaser Default . Upon the occurrence of a Purchaser Default and at any time thereafter so long as the same is continuing, Owner shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Owner shall elect:
(a) In the case of a Purchaser Default, and subject to Section 5.8 , Owner may terminate this Agreement by written notice to Purchaser.
(b) In the case of a Purchaser Default pursuant to Section 14.1(a) , and subject to Section 5.8 , Owner may suspend all or part of Owner’s obligations or Purchaser’s rights under this Agreement during the period during which such Purchaser Default is continuing. During any such period of suspension occurring after the Commercial Operation Date, (i) Purchaser shall not be entitled to schedule, and shall not schedule, any transactions over the NECEC Transmission Line and (ii) the OASIS Administrator shall be directed to post any portion of the transmission capacity that would have otherwise been available to Purchaser over the NECEC Transmission Line pursuant to this Agreement and to attempt to sell such capacity to one or more third parties consistent with Article X . The proceeds of any capacity releases and transmission resales made pursuant to the foregoing sentence and received by Owner, net of reasonable fees (including attorneys’ fees) and other expenses incurred by Owner in connection with this Section 14.4(b) , shall be credited against any accrued but unpaid payment obligation of Purchaser to Owner hereunder. Any such proceeds in excess of such accrued but unpaid payment obligation of Purchaser shall be credited in accordance with Section 10.4 .
(c) Subject to Article XVIII and this Section 14.4 , as applicable, Owner may recover from Purchaser the Purchaser Termination Payment and, to the extent applicable, all other amounts not waived in accordance with Section 3.3.4(d) or, in the absence of a termination pursuant to a Purchaser Default, all damages suffered by Owner
49
that are due to a Purchaser Default, including, for the avoidance of doubt, any amounts payable under Section 4.4.2 and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Purchaser under this Agreement.
(d) Owner may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Additional Credit Support held by Owner and (ii) the right to liquidate any and all Additional Credit Support held by Owner and to apply the proceeds of such liquidation to any amounts payable to Owner with respect to Purchaser’s obligations hereunder in such order as Owner may elect. Owner may draw on the undrawn portion of any Letter of Credit provided as Additional Credit Support up to the amount of Purchaser’s outstanding obligations hereunder. Purchaser shall remain liable for amounts due and owed to Owner that remain unpaid after the application of Additional Credit Support.
(e) Owner may exercise and enforce any and all of its rights and remedies under the Hydro-Québec Guaranty.
(f) Owner may exercise any and all other rights and remedies that may be available to Owner against Purchaser at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Owner shall have no right to (i) terminate this Agreement based upon a Purchaser Default, except as provided in clause (a) above, or (ii) suspend transmission service under this Agreement based upon a Purchaser Default, except as provided in clause (b) above.
Section 14.5 [Intentionally Omitted] .
Section 14.6 Remedies Upon Owner Default . Upon the occurrence of an Owner Default and at any time thereafter so long as the same is continuing, Purchaser shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Purchaser shall elect:
(a) In the case of an Owner Default, and subject to Section 5.8 and Section 14.7 , Purchaser may terminate this Agreement by written notice to Owner and may recover, as applicable, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 and the Owner Termination Payment.
(b) Subject to the limitations provided in Section 4.4.1(e) , Section 7.3.4 , Article XVIII or this Section 14.6 , as applicable, Purchaser may recover from Owner any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement.
(c) Purchaser may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Additional Credit Support held by Purchaser and (ii) the right to liquidate
50
any and all Additional Credit Support held by Purchaser and to apply the proceeds of such liquidation to any amounts payable to Purchaser with respect to Owner’s obligations hereunder in such order as Purchaser may elect. Purchaser may draw on the undrawn portion of any Letter of Credit or apply Cash, in each case that has been provided as Additional Credit Support up to the amount of Owner’s outstanding obligations hereunder. Owner shall remain liable for amounts due and owed to Purchaser that remain unpaid after the application of Additional Credit Support.
(d) Pursuant to Section 13.2 , to the extent there is a Dispute over the amount of the damages suffered by Purchaser as a result of an Owner Default, Purchaser may deduct and setoff payment of such amount against any Transmission Service Payment upon resolution of that Dispute.
(e) Purchaser may exercise any and all other rights and remedies that may be available to Purchaser at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Purchaser shall have no right to (i) terminate this Agreement based upon an Owner Default, except as provided in clause (a) above or Section 14.7(e)(i) , or (ii) any reduction of or offset against payments under this Agreement based upon an Owner Default, except as contemplated by Section 8.1 , Section 13.5 and Section 14.6(d) , as applicable.
Section 14.7 Purchaser Step-in Rights .
(a) In the event that (i) an Owner Default or an Owner Default (as defined in the Distribution Company TSA) occurs or (ii)(A) Owner exercises its rights pursuant to Section 14.2(e) of the Distribution Company TSA or Section 14.3(e) of this Agreement and (B) at the end of the first six (6) months of the period of forbearance by Purchaser of its rights as contemplated by Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA, Owner is not providing Firm Transmission Service in full, then Purchaser shall have the right, but not the obligation, to (x) assume control of and possess and operate the NECEC Transmission Line as agent for Owner (in accordance with Owner’s rights, obligations and interest under this Agreement, the Distribution Company TSA and the Additional RFP Sponsor TSAs, as applicable) during the period provided for herein, pursuant to an agreement to be negotiated in good faith between Owner and Purchaser or (y) assume ownership, control of, possession and operation of the NECEC Transmission Line, in each case, which right shall be exercisable by written notice to Owner and subject to the receipt of any required regulatory approvals and Third Party Consents.
(b) Upon receipt of such written notice to assume ownership of the NECEC Transmission Line (the “ Acquisition Notice ”), Owner shall (i) provide such documents and information as is reasonably necessary for Purchaser to determine any amount owed pursuant to Section 14.7(c) and (ii) take all necessary action to effect the transfer of the NECEC Transmission Line to Purchaser (or its designated Affiliate), including causing all permits, title to land and property, and interests in all contracts (including Owner’s rights under this Agreement, the 110 MW TSA, the Purchaser TSAs,
51
the Distribution Company TSA and the Additional RFP Sponsor TSAs, as applicable) applicable to the NECEC Transmission Line to be transferred to Purchaser or such designated Affiliate. Each Party shall, and each Party shall use commercially reasonable efforts to cause its Affiliates to, cooperate to obtain any required regulatory approvals and Third Party Consents necessary to effect the transfer of the NECEC Transmission Line to Purchaser.
(c) In consideration for acquiring the NECEC Transmission Line, on the closing date, as reasonably determined by Purchaser and specified in the Acquisition Notice, Purchaser shall pay to Owner an amount equal to (i) if such Owner Default occurs prior to the Commercial Operation Date, all costs prudently incurred by Owner as of the date of the Acquisition Notice in connection with the development and construction of the NECEC Transmission Line or (ii) if such Owner Default occurs on or after the Commercial Operation Date, the lesser of (A) one hundred percent (100%) of Owner’s investment in the NECEC Transmission Line as of the notice date and (B) the fair market value of the NECEC Transmission Line, as reasonably determined by a third party appraiser selected by Purchaser and reasonably acceptable to Owner (which amount shall be net of the costs of any such appraisal). The amount to be paid pursuant to this clause (c) shall be in satisfaction of any consideration required to be paid pursuant to Section 14.7 of all Purchaser TSAs and shall be determined within fifteen (15) days after the delivery of the Acquisition Notice or such other time period as is reasonably practicable.
(d) Upon receipt of all required regulatory approvals and Third Party Consents and the payment set forth in clause (c) above, Owner shall transfer to Purchaser (or its designated Affiliate), without recourse or warranty (except as to title and the absence of any liens other than liens arising in the ordinary course), all of Owner’s right, title and interest in and to the NECEC Transmission Line free and clear of all liens other than liens arising in the ordinary course and Purchaser (or such designated Affiliate) shall be assigned all rights of Owner under all contracts required for the ownership and operation of the NECEC Transmission Line and shall assume all liabilities and obligations of Owner arising under such contracts after the transfer (other than applicable contracts between Owner and its lenders, the liabilities and obligations of Owner thereunder to be completely satisfied and discharged by Owner as of closing) and Owner shall cease to be a Party.
(e) Upon Purchaser (or its designated Affiliate) assuming ownership and control of the NECEC Transmission Line:
(i) (A) Purchaser (or its designated Affiliate) shall have the right to terminate this Agreement and Purchaser may recover, as applicable, any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.3 , or Section 7.3.1 or (B) Purchaser (or its designated Affiliate) shall assume Owner’s obligations under this Agreement pursuant to this Section 14.7 and Purchaser shall enter into such amendments to this Agreement as are reasonably necessary in order to give effect to such rights and that are consistent with the terms and conditions of this Agreement and are subject to applicable regulatory approvals;
52
(ii) Purchaser (or its designated Affiliate) shall assume the rights and obligations of Owner under the Distribution Company TSA, the Additional RFP Sponsor TSAs, the 110 MW TSA and the Purchaser TSAs for the remainder of the term thereof (excluding any rights and obligations accrued prior to such assumption).
(f) In connection with an event occurring that gives rise to Purchaser’s step-in rights pursuant to Section 14.7(a) (a “ Step-In Trigger Event ”) and the exercise by Purchaser of its rights under this Section 14.7 , Owner shall pay liquidated damages to Purchaser (without duplication of any amounts paid under Section 14.7 of any other Purchaser TSA) in an amount equal to:
(i) if such Step-In Trigger Event occurs on or before December 31, 2019, Twelve Million Dollars ($12,000,000);
(ii) if such Step-In Trigger Event occurs after December 31, 2019, but on or before December 31, 2020, Thirty Million Dollars ($30,000,000);
(iii) if such Step-In Trigger Event occurs after December 31, 2020, but on or before December 31,2021, Seventy-Three Million Dollars ($73,000,000);
(iv) if such Step-In Trigger Event occurs after December 31, 2021 but before the Commercial Operation Date, Ninety Million Dollars ($90,000,000); or
(v) if such Step-In Trigger Event occurs on or after the Commercial Operation Date, One Hundred Million Dollars ($100,000,000).
The assumption by Purchaser (or its designated Affiliate) of ownership and control of the NECEC Transmission Line under this Section 14.7 shall constitute a waiver by Purchaser of all other remedies or damages that may be available at law or in equity against Owner; provided , however , that Purchaser shall not waive any right to, and Owner shall remain liable for, the liquidated damages set forth in this Section 14.7(f) , any accrued but unpaid amounts under Section 4.4.1 , Section 4.4.2 , or Section 7.3.1 hereof or any express modification of Purchaser’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Purchaser under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover such damages or such indemnified or other amounts owed to Purchaser by Owner.
(g) Notwithstanding this Section 14.7 , in the event that an Owner Default occurs and at any time prior to Purchaser (or its designated Affiliate) assuming ownership and control of the NECEC Transmission Line, (i) Purchaser may exercise its termination rights pursuant to Section 14.6(a) and the exercise of such termination rights shall result in a revocation of Purchaser’s step-in rights under Section 14.7(a) or (ii) Purchaser may revoke the exercise of its step-in rights under Section 14.7(a) .
53
(h) Owner shall not grant any Person, other than a secured party in accordance with Section 22.3 , a right to assume control of, possess and operate the NECEC Transmission Line that is equal to or superior to Purchaser’s right under this Section 14.7 .
(i) As requested by Purchaser following its purchase of the NECEC Transmission Line pursuant to this Section 14.7 , Owner agrees to grant to Purchaser (or its designated Affiliate) any such other rights of way, and assign to Purchaser or such designated Affiliate such other contracts to which it is then a party, as shall be necessary for the ownership, operation, and maintenance of the NECEC Transmission Line.
(j) Owner shall deliver true, correct and complete copies of all applicable contracts and books and records to Purchaser for its review no later than ten (10) days after receipt of the Acquisition Notice. Following the timely delivery by Owner to Purchaser of all such contracts and books and records, Purchaser shall be required to notify Owner at least twenty (20) days prior to the expected closing date if the terms and conditions of the assignment and assumption of any such contracts will not be satisfactory to Purchaser (or its designated Affiliate) and, if Purchaser does so notify Owner, such notice shall result in the revocation of the Acquisition Notice, and the Parties shall be deemed to be in the same position as if Purchaser had not delivered such Acquisition Notice. As a condition of closing, Owner shall completely satisfy and discharge its liabilities and obligations under all applicable contracts between Owner and its lenders and Owner shall obtain written releases, in recordable form reasonably acceptable to Purchaser, of all liens (whether for the benefit of its lenders or otherwise) on the NECEC Transmission Line and the applicable contracts other than liens arising in the ordinary course, and Owner obligates itself to satisfy such liabilities and obligations and to obtain such releases as of closing.
Section 14.8 Early Termination of Distribution Company TSA.
(a) Upon any termination of the Distribution Company TSA as a result of a Distribution Company default thereunder, Purchaser shall have the right, exercisable in its sole discretion, to assume the rights and obligations (subject to the adjustment set forth in Section 8.2 ) of Distribution Company under the Distribution Company TSA for the remainder of the term thereunder by written notice to Owner; provided that Purchaser shall have no obligations for amounts owed by Distribution Company to Owner prior to Purchaser’s assumption in accordance with this Section 14.8(a) , including any amounts owed as a result of a Distribution Company default thereunder, and provided that Hydro-Québec shall execute and deliver an amendment to the Hydro-Québec Guaranty, in form and substance reasonably satisfactory to Owner, to guarantee such assumed obligations.
(b) During any suspension of all or part of Owner’s obligations or Distribution Company’s rights under the Distribution Company TSA, Purchaser shall have the right, exercisable in its sole discretion, to assume the rights and obligations (subject to the adjustment set forth in Section 8.2 ) of Distribution Company under the Distribution Company TSA by written notice to Owner, and, in the event Purchaser elects to assume such Distribution Company’s obligations, Owner shall thereafter resume performance of its obligations thereunder. For the avoidance of doubt, the exercise by Purchaser of any rights hereunder shall be without prejudice to the rights of Purchaser under the PPA.
54
Section 14.9 Disputes . Any Dispute over whether or not an Owner Default or Purchaser Default has occurred shall be resolved in accordance with Article XVII .
Section 14.10 Limitations on Total Liability .
Section 14.10.1 Purchaser Liability . Notwithstanding anything herein to the contrary, Purchaser’s liability for any payments made to Owner pursuant (x) to Sections 3.3.3 , 3.3.4 , 3.4 , 4.4.2 , 4.4.3 and 14.4 , (y) Sections 3.3.3 , 3.3.4 , 3.4 , 4.4.2 , 4.4.3 and 14.4 of the Purchaser TSAs and (z) Sections 3.3.4 , 3.4 , 4.4.2 and 14.4 of the 110 MW TSA shall not exceed, in aggregate, an amount equal to Two Hundred Million Dollars ($200,000,000), which $200,000,000 shall be adjusted in accordance with the following:
(a) increased by the total amount of Credit Support provided by Owner pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs;
(b) reduced by the amount drawn on any Credit Support provided by Owner pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs as a result of an Owner Default hereunder and thereunder;
(c) reduced by any amount of Credit Support that has been returned to Owner pursuant to Section 4.1(c) of the Distribution Company TSA and Section 4.1(c) of the Additional TSAs with the RFP Sponsors; and
(d) reduced by any Delay Damages (as defined in the PPA) paid by Purchaser to Distribution Company under the PPA.
Section 14.10.2 Owner Liability . Notwithstanding anything herein to the contrary, Owner’s liability for any payments made to Purchaser pursuant to (x) Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.3(b)(iii) , 7.3 , 14.11 and 14.6 , (y) Sections 3.3.3 , 3.3.5 , 3.4 , 4.4.1 , 4.4.3(b)(iii) , 7.3 , 14.11 and 14.6 of the Purchaser TSAs and (z) Sections 3.3.5 , 3.4 , 4.4.1 , 7.3 , 14.11 and 14.6 of the 110 MW TSA shall not exceed, in aggregate, an amount equal to Sixty Million Dollars ($60,000,000), which $60,000,000 shall be adjusted in accordance with the following:
(a) increased by the total amount of Credit Support provided by Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs;
(b) reduced by the amount drawn on any Credit Support provided by Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs as a result of a Purchaser Default hereunder and thereunder;
(c) reduced by any amount of Credit Support that has been returned to Purchaser pursuant to Section 4.1(c) of this Agreement and Section 4.1(c) of the Purchaser TSAs; and
(d) reduced by any amounts paid by Owner pursuant to Section 14.7(f) of this Agreement and Section 14.7(f) of the Purchaser TSAs.
55
Section 14.10.3 Exceptions to Total Liability . The limits on liability set forth in Sections 4.4 , 14.10.1 and 14.10.2 shall not apply to any liability of a Party arising out of such Party’s gross negligence, willful misconduct (including willful breach of this Agreement) or fraud.
Section 14.11 Modified Terms Applicable During Forbearance Period . In the event that Owner exercises its rights pursuant to Section 14.2(e) of the Distribution Company TSA or Section 14.3(e) of this Agreement, during the continuation of the period of forbearance by Purchaser of its rights as contemplated by Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA, an additional $3 shall be available in clause (b) of the definition of Non-Excused Outage Payment for the calculation of such payment by Owner, and an additional Ten Million Dollars ($10,000,000) per Contract Year shall be available with respect to the limitation of liability contained in Section 7.3.1 . If Owner is successful in providing Firm Transmission Service under this Agreement or Firm Transmission Service (as defined in the Distribution Company TSA), as applicable, in full at or prior to the end of such period of forbearance, all such amounts shall revert at the time Firm Transmission Service or Firm Transmission Service (as defined in the Distribution Company TSA), as applicable, is provided in full to the amounts applicable under this Agreement prior to Owner’s exercise of its rights under Section 14.3(e) of this Agreement or Section 14.2(e) of the Distribution Company TSA.
Article XV
FORCE MAJEURE
Section 15.1 Definition; Conditions .
(a) The term “ Force Majeure ” means an event or circumstance (i) that is not within the reasonable control of the Party claiming its occurrence; (ii) that could not have been prevented or avoided by such Party through the exercise of reasonable diligence and (iii) that prohibits or prevents such Party from performing its obligations under this Agreement. Under no circumstances shall Force Majeure include (w) any full or partial curtailment in the operation of the NECEC Transmission Line that is caused by or arises from a mechanical or equipment breakdown or other mishap or events or conditions attributable to normal wear and tear or flaws of the NECEC Transmission Line, unless such curtailment or mishap is caused by one of the following: acts of God such as floods, hurricanes, tornados, or other significantly unusual and abnormal weather conditions, such as severe blizzards and severe ice storms; sabotage; terrorism or war; national or regional general strikes, lockouts or other labor disputes, (x) any occurrence or event that increases the costs or causes an economic hardship to a Party but is not otherwise a Force Majeure, (y) Owner’s ability to sell transmission service involving the NECEC Transmission Line at a price greater than that set out in this Agreement or (z) Purchaser’s ability to procure transmission service at a price lower than that provided in this Agreement or Purchaser’s ability to sell generation at a price higher than that provided in the PPA. In addition, a delay or inability to perform attributable to a Party’s lack of preparation, a Party’s failure to timely obtain and maintain all necessary permits (excepting the Regulatory Approval other than the obligations to file for Regulatory Approval) or qualifications, any delay or failure of Owner to obtain the Owner Approvals or of Purchaser to obtain the Canadian Approvals, a failure to satisfy contractual conditions or commitments, or lack or
56
deficiency in funding or other resources shall each not constitute a Force Majeure or be the basis for a claim of Force Majeure. Neither Party may raise a claim of Force Majeure based in whole or in part on the failure of Purchaser to fulfill any of its obligations under the PPA (including related to the availability of the Québec Line) unless such failure is due to “force majeure” or “uncontrollable force” or a similar term as defined under the PPA.
(b) Subject to Section 15.1(a) , if a Party is unable, wholly or in part, by Force Majeure to perform its obligations under this Agreement, such performance shall be excused and suspended so long as the circumstances that give rise to such inability exist or would exist if the Party claiming the Force Majeure used commercially reasonable efforts to cure such circumstances, but for no longer period. The Party whose performance is affected shall give prompt notice thereof to the other Party; such notice may be given orally or in writing but, if given orally, it shall be promptly confirmed in writing, providing details regarding the nature, extent and expected duration of the Force Majeure, its anticipated effect on the ability of such Party to perform its obligations under this Agreement, and the estimated duration of any interruption in service or other adverse effects resulting from such Force Majeure, and shall be updated or supplemented to keep the other Party advised of the effect and remedial measures being undertaken to overcome the Force Majeure. Such inability to perform shall be promptly corrected to the extent it may be corrected through the exercise of due diligence consistent with Good Utility Practice. Neither Party shall be liable for any losses or damages arising out of a suspension of performance that occurs because of Force Majeure. Notwithstanding any such suspension of performance, Purchaser shall be obligated to make Transmission Service Payments as though Firm Transmission Service was then being provided at or greater than the Minimum Average Availability.
(c) Notwithstanding the foregoing, if the Force Majeure prevents full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, the Party whose performance is not prevented by Force Majeure shall have the right to terminate this Agreement upon written notice to the other Party and without further recourse, provided , however , that if (i) Owner presents a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan reasonably acceptable to Purchaser and Distribution Company (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, to Purchaser and Distribution Company before the end of a period in which Owner’s provision of Firm Transmission Service has been prevented in whole or in part by an event of Force Majeure, Purchaser shall forbear terminating this Agreement under this clause (c) for such period, provided that, during any such period, Purchaser’s obligation to make Transmission Service Payments shall be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, Purchaser may terminate this Agreement under this clause (c) . In no event will any delay or failure of performance caused by any conditions or events of Force Majeure extend this Agreement beyond its stated Term.
57
(d) A Party shall not be required to settle any strike, walkout, lockout or other labor dispute on terms that, in the sole judgment of such Party, are contrary to its interest. The settlement of strikes, walkouts, lockouts or other labor disputes shall be entirely within the discretion of the Party involved in such dispute.
Article XVI
FINANCIAL ASSURANCES
Section 16.1 Purchaser’s Guaranty . Concurrently with the execution of this Agreement, Purchaser shall cause Purchaser Guarantor to deliver to Owner a guaranty by Purchaser Guarantor of Purchaser’s payment obligations under this Agreement substantially in the form of Attachment J (the “ Hydro-Québec Guaranty ”).
Section 16.2 [Intentionally Omitted] .
Section 16.3 Credit Downgrade Event . Purchaser Guarantor and Owner shall at all times meet the Credit Rating Requirements.
(a) In the event Owner fails to meet the Credit Rating Requirements, Owner shall promptly furnish to Purchaser, in an amount equal to the Proportionate Share multiplied by Two Hundred Fifty Million Dollars ($250,000,000), Additional Credit Support.
(b) In the event Purchaser Guarantor fails to meet the Credit Rating Requirements, Purchaser shall promptly furnish to Owner, in an amount equal to the Proportionate Share multiplied by Two Hundred Fifty Million Dollars ($250,000,000), Additional Credit Support.
For the purposes of this Section 16.3 , the denominator in “Proportionate Share” shall be 1,200 MW.
Article XVII
DISPUTE RESOLUTION
Section 17.1 Consultation .
(a) The Parties shall initially attempt to resolve any Dispute through consultations between the Parties. Subject to Section 17.2 and except as expressly provided otherwise in this Agreement, if a Dispute has not been timely resolved pursuant to this clause (a) within fifteen (15) Business Days after written notice of such Dispute has been given, then either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction; provided, however, if the Dispute is subject to Section 17.2 , then either Party may elect to proceed with the mediation through FERC's Dispute Resolution Service. If one Party fails to participate in the consultations provided for in this Section 17.1 , the other Party can initiate mediation prior to the expiration of the fifteen (15) Business Days.
58
Unless otherwise agreed, the Parties will select a mediator from the FERC panel. The Parties may, by written agreement signed by both Parties, alter any time deadline, location(s) for meeting(s) or procedure outlined herein or in FERC’s rules for mediation. The procedure specified herein shall be the sole and exclusive procedure for the resolution of Disputes.
(b) All negotiations, consultations, and mediations pursuant to this Section 17.1 shall be deemed to be confidential and shall be treated as compromise and settlement negotiations, and no evidence with regard to any proposal made during such negotiations, consultations or mediations shall be admissible in any FERC proceeding or filing under Section 17.2 or in any other judicial or other proceeding.
Section 17.2 Disputes to be Resolved by FERC .
(a) In the event a Dispute over any matter is not resolved in accordance with Section 17.1 , either Party shall have the right to file for relief with FERC to the extent that matter is within the primary or exclusive jurisdiction of the FERC. Nothing contained in this Agreement shall be construed as precluding a Party from filing any answer, protest or other opposition to any FERC filing made by the other Party, unless expressly prohibited under the terms of this Agreement.
(b) In the event any Dispute is submitted to FERC for resolution as provided in Section 17.2(a) , the Party submitting the Dispute to FERC shall be responsible for providing written notice of such filing to the other Interested Parties. Unless both Parties agree that the Dispute does not implicate any of the Proposal Agreements other than this Agreement, each Party consents and agrees that (i) each Interested Party is an interested party in the Dispute and (ii) in order to avoid inconsistent interpretations and adjudications of the Proposal Agreements, any Interested Party may, without objection from any other Interested Party, whether by means of joinder, consolidation or otherwise, submit such matters as it considers sufficiently related to the Dispute to FERC to be jointly determined by FERC with the Dispute. Notwithstanding the foregoing, in the event FERC determines that it does not have the jurisdiction to, or otherwise does not want to, hear or determine any portion of a Dispute or other matter so referred to FERC, either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction.
Section 17.3 Consent to Jurisdiction . Subject to Section 17.2 , each Party agrees that any legal action or proceeding with respect to or arising out of this Agreement or any other Proposal Agreement shall be brought in or removed to the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts that has subject matter jurisdiction and any appellate court from any thereof. By execution and delivery of this Agreement, each Party hereby accepts for itself and in respect of its property, generally and unconditionally, the jurisdiction of the aforesaid courts. The Parties irrevocably consent to the service of process out of any of the aforementioned courts in any such action or proceeding by the mailing of copies thereof by registered or certified airmail, postage prepaid, to the applicable Party at its respective addresses for notices as specified in Section 23.4 . Nothing herein shall affect the right to serve process in any other manner permitted by law. Each Party hereby waives any right to stay or dismiss any action or proceeding under or in connection with this Agreement or any other Proposal Agreement brought before the foregoing courts on the basis of forum non-conveniens.
59
Section 17.4 WAIVER OF JURY TRIAL . EACH PARTY IRREVOCABLY AND UNCONDITIONALLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY LEGAL ACTION, PROCEEDING, CAUSE OF ACTION , OR COUNTERCLAIM ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.
Article XVIII
LIMITATION OF REMEDIES
NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, NEITHER PARTY NOR ANY OF ITS AGENTS, SUBCONTRACTORS, REPRESENTATIVES OR AFFILIATES SHALL BE LIABLE TO THE OTHER PARTY FOR PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE (EXCEPT AS EXPRESSLY CONTEMPLATED IN THIS AGREEMENT, INCLUDING IN Section 4.4 OR Section 7.3 , OR FOR ANY DIRECT DAMAGES SUFFERED BY PURCHASER AS A RESULT OF A BREACH BY OWNER OF ITS OBLIGATIONS UNDER Section 6.2 , Article X OR Section 11.2 ), IN EACH CASE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OF THIS AGREEMENT, AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY).
FOR THE AVOIDANCE OF DOUBT, THE PARTIES ACKNOWLEDGE AND AGREE THAT Section 4.4 OR Section 7.3 PROVIDE THE SOLE AND EXCLUSIVE REMEDIES FOR ANY LOSS OF USE CONTEMPLATED BY Section 4.4 OR Section 7.3 AND NOTHING IN Section 6.2 , Article X OR Section 11.2 SHALL SUPERSEDE, SUPPLEMENT OR AMEND SUCH SOLE AND EXCLUSIVE REMEDIES.
THIS Article XVIII IS IN ADDITION TO THE SPECIFIC LIMITATIONS ON REMEDIES REFERENCED IN Article XIV , Section 4.4.1 AND Section 4.4.2 .
OWNER ACKNOWLEDGES THAT (A) PURCHASER (OR ITS AFFILIATES) MAY BE A PROPONENT OF OR PARTICIPATE IN OTHER BIDS WITH OTHER TRANSMISSION DEVELOPERS IN RESPONSE TO THE RFP (“ ADDITIONAL BIDS ”), EITHER ON ITS OWN OR WITH ONE OR MORE THIRD PARTIES AND (B) PURCHASER SHALL NOT BE LIABLE TO OWNER FOR ANY PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE, INCLUDING LOST PROFITS, IN EACH CASE, ARISING FROM OR RELATING TO ANY ADDITIONAL BIDS (INCLUDING IF ANY ADDITIONAL BIDS ARE SELECTED PURSUANT TO THE RFP), AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY). OWNER ACKNOWLEDGES AND AGREES THAT AS PART OF PURCHASER’S PARTICIPATION IN ADDITIONAL BIDS, PURCHASER SHALL EMPLOY MATERIALLY SIMILAR LANGUAGE IN DOCUMENTS PREPARED PURSUANT TO ADDITIONAL BIDS, FOR WHICH NO LIABILITY OR OBLIGATION OF ANY KIND, INCLUDING FOR COMPENSATION, SHALL BE IMPOSED UPON PURCHASER.
60
PURCHASER ACKNOWLEDGES THAT (A) OWNER (OR ITS AFFILIATES) MAY BE A PROPONENT OF OR PARTICIPATE IN OTHER BIDS WITH OTHER GENERATION DEVELOPERS IN RESPONSE TO THE RFP, EITHER ON ITS OWN OR WITH ONE OR MORE THIRD PARTIES AND (B) OWNER SHALL NOT BE LIABLE TO PURCHASER FOR ANY PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE, INCLUDING LOST PROFITS, IN EACH CASE ARISING FROM OR RELATING TO ANY SUCH OTHER BIDS (INCLUDING IF ANY SUCH OTHER BID IS SELECTED PURSUANT TO THE RFP) AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY). PURCHASER ACKNOWLEDGES AND AGREES THAT AS PART OF OWNER’S PARTICIPATION IN OTHER BIDS, OWNER MAY EMPLOY MATERIALLY SIMILAR LANGUAGE IN DOCUMENTS PREPARED PURSUANT TO OTHER BIDS, FOR WHICH NO LIABILITY OR OBLIGATION OF ANY KIND, INCLUDING FOR COMPENSATION, SHALL BE IMPOSED UPON OWNER.
Article XIX
MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES.
Section 19.1 Modifications . The Parties specifically intend and acknowledge and agree that, except as otherwise expressly provided in this Agreement, (a) this Agreement shall not be subject to amendment or other modification, absent the written agreement of both Parties and (b) neither Party shall be permitted to make a filing with FERC under any provision of the Federal Power Act or the regulations promulgated thereunder that seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement at any time during the Term, except to implement an amendment or other modification to this Agreement that has been reduced to writing and signed by both Parties. In addition, to the extent any third party, or FERC acting sua sponte , seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement, the standard of review for any proposed amendment or other modification shall be the “public interest” standard of review set forth in United Gas Pipe Line Co. v. Mobile Gas Service Corp ., 350 U.S. 332 (1956), and Federal Power Commission v. Sierra Pacific Power Co. , 350 U.S. 348 (1956), and as further defined in Morgan Stanley Capital Group, Inc. v. Public Utility District No. 1 of Snohomish County , 128 S. Ct. 2733 (2008) and NRG Power Marketing, LLC v. Maine Public Utilities Commission , 130 S. Ct. 693 (2010).
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment .
(a) This Agreement is subject to the ISO-NE Rules. If, during the Term, any ISO-NE Rule is terminated, modified or amended, or is otherwise no longer applicable, resulting in a material alteration of a material right or obligation of a Party hereunder, the Parties agree to negotiate in good faith in an attempt to amend or clarify this Agreement to embody the Parties’ original intent regarding their respective rights and obligations under this Agreement; provided that neither Party shall have any obligation to
61
agree to any particular amendment or clarification of this Agreement. The intent of the Parties is that any such amendment or clarification reflect, as closely as possible, the intent, substance and effect of the ISO-NE Rule being replaced, modified, amended or made inapplicable as such ISO-NE Rule was in effect prior to such termination, modification, amendment or inapplicability; provided that such amendment or clarification shall not in any event alter (i) the purchase and sale obligations of the Parties pursuant to this Agreement or (ii) the Transmission Service Payment. In the event the Parties cannot agree upon such amendments within sixty (60) days after such ISO-NE Rule or ISO-NE Practice change described above, the Dispute shall be resolved in accordance with Article XVII .
(b) If, during the Term, there is a change in Applicable Law (other than tax laws or regulations) or accounting standards or rules or a change in the interpretation or applicability thereof that would result in a (A) material adverse balance sheet or creditworthiness impacts on Purchaser associated with this Agreement or the amounts paid for Firm Transmission Service purchased hereunder, or (B) an adverse impact on the economic benefits (including those stemming from the fiscal conditions provided for herein) that any Party enjoys under this Agreement or that are provided for herein for any Party during the Term, the Parties shall use commercially reasonable efforts to agree to an amendment to the Agreement to avoid or mitigate such impacts and restore the economic benefits to each affected Party; provided that such amendment mitigates any material adverse effect(s) on each non-affected Party (as identified by each such Party, acting reasonably) that could reasonably be expected to result from such amendment, but only to the extent that such mitigation can be accomplished in a manner that is consistent with the purpose of such amendment. In the event the Parties cannot agree on an amendment in accordance with this Section 19.2(b) , the Dispute shall be resolved in accordance with Article XVII .
(c) Upon a determination by a court or regulatory body having jurisdiction over this Agreement or any of the Parties, or over the establishment and enforcement of any of the statutes or regulations or orders or actions of regulatory agencies (including the MDPU) supporting this Agreement or the rights or obligations of the Parties hereunder that any of the statutes or regulations supporting this Agreement or the rights or obligations of the Parties hereunder, or orders of or actions of regulatory agencies (including the MDPU) implementing such statutes or regulations, or this Agreement on its face or as applied, violates any Applicable Law (including the State or Federal Constitution) (an “ Adverse Determination ”), each Party shall have the right to suspend performance under this Agreement without liability. Owner may provide transmission service to a third party during any period of time for which Purchaser suspends payments under this Section 19.2(c) . Upon an Adverse Determination becoming final and non-appealable, this Agreement shall be rendered null and void.
(d) For the avoidance of doubt, it is understood that the provisions of Article XVII regarding dispute resolution apply to any Dispute under this Article XIX .
62
Section 20.1 Purchaser Indemnity . Purchaser shall indemnify, defend and hold harmless Owner and Owner’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, an “ Owner Indemnified Party ” ) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Owner Indemnified Party, and arising out of the negligence, willful misconduct or criminal misconduct of Purchaser or its agents. Purchaser shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Owner Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, an Owner Indemnified Party. This Section 20.1 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPA, the Additional PPAs, the Distribution Company TSA or the Additional RFP Sponsor TSAs.
Section 20.2 Owner Indemnity . Owner shall indemnify, defend and hold harmless Purchaser and Purchaser’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives and permitted successors and assigns (each, a “ Purchaser Indemnified Party ” ) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party, including any such liabilities incurred by a Purchaser Indemnified Party under the PPA, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents, including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Purchaser Indemnified Party. This Section 20.2 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPA, the Additional PPAs, the Distribution Company TSA or the Additional RFP Sponsor TSAs .
Section 20.3 [Intentionally Omitted] .
63
Section 20.4 Procedures . Promptly after the receipt by any Person seeking indemnification under this Article XX (the “ Indemnified Party ” ) of written notice of the assertion of any claim by a third party with respect to any matter in respect of which indemnification may be sought hereunder (a “ Third Party Claim ” ), the Indemnified Party shall give written notice (the “ Indemnification Notice ” ) to the Party from which indemnification is sought (the “ Indemnifying Party ” ), and shall thereafter keep the Indemnifying Party reasonably informed with respect thereto; provided , however , that the failure of the Indemnified Party to give the Indemnifying Party notice as provided herein shall not relieve the Indemnifying Party of any of its obligations hereunder, except to the extent that the Indemnifying Party is materially prejudiced by such failure. The Indemnifying Party shall be entitled to assume the defense of any Third Party Claim by written notice to the Indemnified Party of such intention given within thirty (30) days after the receipt by the Indemnifying Party of the Indemnification Notice; provided , however , that counsel selected by the Indemnifying Party shall be reasonably satisfactory to the Indemnified Party. The Indemnifying Party shall be liable for the fees and expenses of counsel employed by the Indemnified Party for any period during which the Indemnifying Party has not assumed the defense of any Third Party Claim (other than during any period during which the Indemnified Party has failed to give notice of such Third Party Claim as provided above). If the Indemnifying Party shall assume the defense of the Third Party Claim, then the Indemnifying Party shall not compromise or settle such Third Party Claim without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld, delayed or conditioned; provided , however , that the Indemnified Party shall have no obligation to consent to any settlement that (a) does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff of a release of the Indemnified Party from all liability with respect to such Third Party Claim or (b) involves the imposition of equitable remedies or the imposition of any material obligations on such Indemnified Party other than financial obligations for which such Indemnified Party is indemnified hereunder. As long as the Indemnifying Party is contesting any such Third Party Claim on a timely basis, the Indemnified Party shall not pay, compromise or settle any claims brought under such Third Party Claim. Notwithstanding the assumption by the Indemnifying Party of the defense of any Third Party Claim as provided in this Section 20.4 , the Indemnified Party shall be permitted to participate in the defense of such Third Party Claim and to employ counsel at its own expense (it being understood that the Indemnifying Party controls such defense); provided , however , that, if the defendants in any Third Party Claim shall include both an Indemnifying Party and any Indemnified Party, and such Indemnified Party shall have reasonably concluded that counsel selected by the Indemnifying Party has a conflict of interest because of the availability of different or additional defenses to such Indemnified Party, such Indemnified Party shall then have the right to select separate counsel to participate in the defense of such Third Party Claim on its behalf, at the expense of the Indemnifying Party; provided that the Indemnifying Party shall not be obligated to pay the expenses of more than one separate counsel for all Indemnified Parties, taken together.
Section 20.5 Defenses . If the Indemnifying Party shall fail to notify the Indemnified Party of its desire to assume the defense of any Third Party Claim within the prescribed period of time, or shall notify the Indemnified Party that it will not assume the defense of any such Third Party Claim, then the Indemnified Party may assume the defense of any such Third Party Claim, in which case it may do so acting in good faith and otherwise in such manner as it may deem appropriate, and the Indemnifying Party shall be bound by any determination made in such Third Party Claim.
64
Section 20.6 Cooperation . The Indemnified Party and the Indemnifying Party shall each cooperate fully (and shall each cause its Affiliates to cooperate fully) with the other in the defense of any Third Party Claim pursuant to this Article XX . Without limiting the generality of the foregoing, each such Person shall furnish the other such Person (at the expense of the Indemnifying Party) with such documentary or other evidence as is then in its or any of its Affiliates’ possession, as may reasonably be requested by the other Person for the purpose of defending against any such Third Party Claim.
Section 20.7 Recovery . The amount of any indemnity hereunder shall be reduced by any insurance proceeds actually recovered by the Indemnified Party in connection with the Third Party Claim. If at any time subsequent to the receipt by an Indemnified Party of an indemnity payment hereunder, such Indemnified Party (or any Affiliate thereof) receives any recovery, settlement or other similar payment with respect to the Third Party Claim for which it received such indemnity payment (a “ Recovery ” ), such Indemnified Party shall then promptly pay to the Indemnifying Party the amount of such Recovery, less any expenses incurred by such Indemnified Party (or its Affiliates) in connection with such Recovery, but in no event shall any such payment exceed the amount of such indemnity payment.
Section 20.8 Subrogation . To the extent the Indemnifying Party makes or is required to make any indemnity payment to the Indemnified Party, the Indemnifying Party shall be entitled to exercise, and shall be subrogated to, any rights and remedies (including rights of indemnity, rights of contribution and other rights of recovery) that the Indemnified Party or any of its Affiliates may have against any other Person with respect thereto, whether directly or indirectly related. The Indemnified Party shall permit the Indemnifying Party to use the name of the Indemnified Party and the names of the Indemnified Party’s Affiliates in any transaction or in any proceeding or other matter involving any of such rights or remedies; and the Indemnified Party shall take such actions as the Indemnifying Party may reasonably request for the purpose of enabling the Indemnifying Party to perfect or exercise its right of subrogation hereunder.
Article XXI
REPRESENTATIONS, WARRANTIES AND COVENANTS
Section 21.1 Mutual Representations and Warranties . Each Party hereby represents and warrants to the other Party that all of the statements in this Section 21.1 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of (i) the Effective Date, (ii) the Commercial Operation Date and (iii) the start of the Purchaser Term , but not as of any other date:
(a) It has knowledge and experience in financial matters and in the electric industry that enable it to evaluate the merits and risks of this Agreement and the transactions contemplated hereby, and is capable of evaluating such merits and risks and assuming such risks. It is acting for its own account, has made its own independent decision to enter into this Agreement as to whether this Agreement is appropriate and proper for it based upon its own judgment, is not relying upon the advice or recommendations of the other Party in doing so, and understands and accepts the terms, conditions, and risks of this Agreement and the transactions contemplated hereby;
65
(b) It has entered into this Agreement in connection with the conduct of its business;
(c) It is not acting as a fiduciary or an advisor with respect to this Agreement or the transactions contemplated hereby;
(d) It is not subject to an Insolvency Event and there are no proceedings pending or being contemplated by it or, to its knowledge, threatened against it that could result in the occurrence of an Insolvency Event with respect to it; and
(e) It is an entity subject to the procedures and substantive provisions of the Bankruptcy Code applicable to U.S. corporations or limited liability companies, as applicable, generally.
Section 21.2 Additional Representations and Warranties of Purchaser . Purchaser hereby represents and warrants to Owner that all of the statements in this Section 21.2 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Purchaser is duly organized, validly existing, and in good standing under the laws of the State of Delaware and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Purchaser, and Purchaser has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Purchaser has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Purchaser;
(c) Assuming due authorization, execution and delivery by Owner, this Agreement constitutes Purchaser’s legal, valid and binding obligation enforceable against Purchaser in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Purchaser or any of its Affiliates that could have a Material Adverse Effect on Purchaser;
(e) No event with respect to Purchaser has occurred or is continuing that would constitute a Purchaser Default, and no Purchaser Default will occur as a result of Purchaser entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Purchaser does not and will not (i) violate any provisions of its certificate of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
66
(g) To the best of Purchaser’s knowledge, the Canadian Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary for TransÉnergie to commence construction of and to own and operate the Québec Line in a manner consistent with Attachment A and this Agreement; and
(h) Purchaser is in compliance with all Applicable Laws, except such noncompliance as could not reasonably be expected to have a Material Adverse Effect on Purchaser. Purchaser has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Purchaser.
Section 21.3 Additional Representations and Warranties of Owner . Owner hereby represents and warrants to Purchaser that all of the statements in this Section 21.3 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Owner is duly organized, validly existing, and in good standing under the laws of the State of Maine and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Owner, and Owner has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Owner has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Owner;
(c) Assuming due authorization, execution and delivery by Purchaser, this Agreement constitutes Owner’s legal, valid and binding obligation enforceable against Owner in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Owner or any of its Affiliates that could have a Material Adverse Effect on Owner;
(e) No event with respect to Owner has occurred or is continuing that would constitute an Owner Default, and no Owner Default will occur as a result of Owner entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Owner does not and will not (i) violate any provisions of its articles of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
67
(g) The FERC Authorization, the Owner Approvals (other than the Municipal Owner Approvals) and the AC Upgrade Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary to commence construction of and operate the NECEC Transmission Line (other than the Municipal Owner Approvals);
(h) To the best of Owner’s knowledge, the Municipal Owner Approvals identified in paragraph 10 of Attachment C constitute all of the Municipal Owner Approvals that are necessary to commence construction of and operate the NECEC Transmission Line;
(i) Owner is in compliance with all Applicable Laws, except such noncompliance as could not reasonably be expected to have a Material Adverse Effect on Owner. Owner has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Owner; and
(j) Owner has acquired all required real property rights necessary for construction and operation of the NECEC Transmission Line, and the interconnection of the NECEC Transmission Line with (A) the Québec Line (other than real property rights to be held by TransÉnergie) and (B) the Delivery Point, in full and final form with all options or contingencies having been exercised as set forth in Attachment I .
Section 21.4 [Intentionally Omitted] .
Section 21.5 NO OTHER REPRESENTATIONS OR WARRANTIES . THE REPRESENTATIONS AND WARRANTIES OF OWNER SET FORTH IN Section 21.1 AND Section 21.3 ARE OWNER’S SOLE REPRESENTATIONS AND WARRANTIES ASSOCIATED WITH THE NECEC TRANSMISSION LINE AND ARE MADE IN LIEU OF ALL OTHER REPRESENTATIONS, WARRANTIES AND GUARANTEES, EXPRESS OR IMPLIED, ASSOCIATED WITH THE NECEC TRANSMISSION LINE, INCLUDING REPRESENTATIONS OR WARRANTIES AS TO MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE. THE FOREGOING SENTENCE SHALL NOT BE CONSTRUED IN ANY WAY TO LIMIT OWNER’S EXPRESS OBLIGATIONS UNDER THIS AGREEMENT.
Article XXII
TRANSFER OF INTERESTS
Section 22.1 No Transfer of Interests .
(a) Any (i) direct or indirect change of Control of any Party (whether voluntary or by operation of law), (ii) sale, transfer or other disposition of all or substantially all of the assets of any Party or (iii) except as provided in Section 22.2 or Section 22.3 , assignment, transfer or other disposition of, whether to one or more assignees or transferees, all or any portion of any Party’s rights, interests or obligations under this Agreement (each of the foregoing, a “ Transfer ” ), shall require the prior written
68
consent of the other Party, which consent shall not be unreasonably withheld, delayed or conditioned when viewed in light of all reasonable considerations, including the security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer); provided that any direct or indirect transfer of securities or other ownership interests in a Party to a Person Controlled by a Party’s ultimate parent company (for Purchaser, currently Hydro-Qu é bec, and for Owner, currently Iberdrola, S.A.), as applicable, shall not be considered a Transfer for the purposes of this Section 22.1(a) and shall not require consent. Any Transfer in contravention of this Article XXII shall be null and void. The Parties agree that the provision by or for the account of an assignee or transferee of any Party of Additional Credit Support in an amount equal to the Maximum Amount provided under, and as defined in, the Hydro-Québec Guaranty, as such Maximum Amount may vary from time to time, shall be deemed to satisfy the criterion set forth herein with respect to security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer).
(b) If Owner consents to a Transfer by Purchaser pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Purchaser’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Owner of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that a Purchaser Default shall not have occurred and be continuing, (x) the obligations of Purchaser shall terminate to the extent of the Transferred portion of this Agreement, and Purchaser shall be fully, finally, and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Purchaser, Owner shall execute and deliver to Purchaser a full, final, and unconditional release of any credit support or guarantees provided by Purchaser, in such form as Purchaser may reasonably request, with respect to the Transferred portion of this Agreement.
(c) If Purchaser consents to a Transfer by Owner pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Owner’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Purchaser of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that an Owner Default shall not have occurred and be continuing, (x) the obligations of Owner shall terminate to the extent of the Transferred portion of this Agreement, and Owner shall be fully, finally, and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Owner, Purchaser shall execute and deliver to Owner a full, final, and unconditional release of any credit support or guarantees provided by Owner hereunder, in such form as Owner may reasonably request, with respect to the Transferred portion of this Agreement.
(d) [Intentionally Omitted].
69
(e) Nothing herein shall prevent Purchaser or any assignee thereof from transferring or assigning transmission service rights pursuant to FERC rules and regulations.
Section 22.2 Exceptions . Notwithstanding Section 22.1 , consent shall not be required for any of the following:
(a) an assignment by Purchaser to any of its Affiliates; provided that Hydro-Québec confirms in a writing satisfactory to Owner that the Hydro-Québec Guaranty applies with respect to the assignee’s obligations under this Agreement;
(b) [intentionally omitted];
(c) any (i) change of Control of Owner or (ii) transfer or other disposition of all or substantially all of the assets of Owner, in each case, resulting from a collateral assignment in favor of a financing party in accordance with Section 22.3 ;
(d) any change of Control of Owner resulting from any direct or indirect change of Control in Owner’s ultimate parent company (currently Iberdrola, S.A.), Owner’s ultimate parent company in the United States (currently AVANGRID, Inc.) or in the parent company for the network business in the United States of which Owner is part (currently Avangrid Networks, Inc.);
(e) any change of Control of Purchaser resulting from the direct or indirect transfer of interests in Hydro-Québec; or
(f) the exercise of any of Purchaser’s rights pursuant to Section 14.7 , 14.8(a) or 14.8(b) .
Section 22.3 Collateral Assignment . Owner shall be entitled, without restriction, to make one or more assignments of this Agreement for purposes of collateral security or any or all of its rights and benefits hereunder to or for the benefit of any and all secured lenders to Owner, or grant to or for the benefit of any and all secured lenders to Owner a lien on, or security interest in, any right, title or interest in all or any part of Owner’s rights hereunder for the purpose of the financing or successive refinancing of the ownership, development, engineering, construction or operation of the NECEC Transmission Line; provided , however , that such assignment for purposes of collateral security shall recognize Purchaser’s rights under this Agreement on terms and conditions as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner. To facilitate Owner’s obtaining of financing or successive refinancing for the ownership, development, engineering, construction or operation of the NECEC Transmission Line, Purchaser shall cooperate with Owner and shall execute and deliver such consents, acknowledgements, direct agreements or similar documents as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner.
70
Section 23.1 Governing Law . This Agreement and each of its provisions shall be governed by, and construed in accordance with, the laws of the Commonwealth of Massachusetts.
Section 23.2 Entire Agreement . This Agreement, together with the Attachments, constitutes the entire Agreement and understanding between the Parties with respect to all subjects covered hereby and thereby and supersedes all prior discussions, agreements and understandings between the Parties with respect to such matters. Notwithstanding the foregoing, each Party is subject to obligations under different Proposal Agreements.
Section 23.3 Severability . Except as otherwise provided in Section 2.2 or Section 19.2 , (a) in the event any part of this Agreement is held to be illegal, invalid or unenforceable to any extent, the legality, validity and enforceability of the remainder of this Agreement shall not be affected thereby, and shall remain in full force and effect and shall be enforced to the greatest extent permitted by Applicable Law and (b) with respect to any provision found to be illegal, invalid or unenforceable, the Parties shall endeavor to replace such invalid, illegal or unenforceable provision with the valid, legal and enforceable provision that achieves, as nearly as practicable, the commercial intent of this Agreement (as it may be amended from time to time).
Section 23.4 Notices . All notices, billings, requests, demands, waivers, consents and other communications under this Agreement shall be in writing and shall be effective (a) upon personal delivery thereof, including by overnight mail or courier service, with a record of receipt, (b) in the case of notice by United States mail, certified or registered, postage prepaid, return receipt requested, upon the fourth (4th) day after mailing, (c) in the case of notice by facsimile for any communications other than billings, upon transmission; provided that such facsimile transmission is promptly confirmed by either of the methods set forth in the foregoing clause (a) or (b), in each case, addressed to each Party and copy party hereto at its address set forth below or at such other address as a Party may from time to time designate by written notice to the other Party pursuant to this Section 23.4 , (d) in the case of notice by facsimile for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon receipt of confirmation of successful transmission, but without any further requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b), or (e) in the case of notice by electronic mail for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon transmission, without any requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b); provided that the Party delivering such notice did not receive any notice of unsuccessful or delayed transmission. A notice given in connection with this Section 23.4 but received on a day other than a Business Day, or after business hours at the location of receipt, shall be deemed to be received on the next Business Day.
71
Central Maine Power Company
Attn: Douglas Herling, President & CEO
83 Edison Drive, Augusta ME 04336
207-626-9779
With a copy to:
Central Maine Power Company
Attn: Legal Department
83 Edison Drive, Augusta ME 04336
With a further copy to:
Pierce Atwood LLP
Attn: Jared des Rosiers
254 Commercial St., Portland ME 04101
If to Purchaser:
H.Q. Energy Services (U.S.) Inc.
75, René-Lévesque Boulevard West, 18th Floor
Montréal (Québec) Canada
H2Z 1A4
Attention: President
Facsimile: (514) 289-6723
Section 23.5 Waiver; Cumulative Remedies . Any term or condition of this Agreement may be waived at any time by the Party that is entitled to the benefit thereof, but such waiver shall not be effective unless set forth in a written instrument duly executed by or on behalf of the Party waiving such term or condition. No waiver by any Party of any term or condition of this Agreement, in any one or more instances, shall be deemed to be, or construed as, a subsequent waiver of, or estoppel with respect to, the same or any other term or by Applicable Law. Except as otherwise provided in Section 13.2(b) , the failure of or delay on the part of any Party to enforce or insist upon compliance with or strict performance of any term or condition of this Agreement, or to take advantage of any of its rights thereunder, shall not constitute a waiver or relinquishment of any such terms, conditions, or rights, but the same shall be and remain at all times in full force and effect. Except as otherwise provided herein, the remedies provided in this Agreement are cumulative and not exclusive of any remedies provided by law or in equity.
Section 23.6 Confidential Information . Each Party hereby agrees that it shall not disclose, or cause to be disclosed, to third parties any Confidential Information with respect to the other Party or any material or information identified as Critical Energy Infrastructure Information (other than to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential). Notwithstanding the foregoing, each Party may disclose information related to this
72
Agreement to another party to a Proposal Agreement or to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential, only if necessary to comply with its obligations hereunder or thereunder or to coordinate the parties’ obligations under different Proposal Agreements. Each Party shall be responsible for ensuring that any Person to whom it discloses any Confidential Information shall comply with the restrictions in this Section 23.6 . The restrictions in this Section 23.6 shall not apply (w) to the extent disclosure is required by Applicable Law or the requirements of a Governmental Authority (including a court order, oral questions, written interrogatories, request for information or documents, subpoena or similar process, or the requirements of any stock exchange or other Governmental Authority to which the Parties, or any of their Affiliates are subject), (x) to the extent reasonably deemed by the disclosing Party to be required or desirable in connection with regulatory proceedings (including proceedings relating to FERC or any other national, federal, provincial, state or regulatory agency), (y) to the extent reasonably deemed by the disclosing Party to be required to be disclosed in connection with a Dispute between the Parties, or the defense of any litigation or dispute, or (z) as approved for release or disclosure by the Party whose Confidential Information is at issue. In the event disclosure is made pursuant to this Section 23.6 , and except for disclosures pursuant to the requirements of securities laws or any stock exchange, the disclosing Party shall use reasonable efforts to minimize the scope of any disclosure and advise recipients of any applicable confidentiality restrictions provided herein. Notwithstanding the foregoing, this Section 23.6 shall not apply to the following information:
(a) Information that is a matter of public knowledge at the time of its disclosure or is thereafter published in or otherwise ascertainable from a source available to the public without breach of this Section 23.6 ;
(b) Information that is obtained from a Person other than by or as a result of unauthorized disclosure; or
(c) Information that, prior to the time of disclosure, had been independently developed or obtained by the disclosing Party or its Affiliates independent of information obtained as a result of unauthorized disclosure.
Section 23.7 No Third-Party Rights . Except for any secured lenders contemplated by Section 22.3 and any Owner Indemnified Party or Purchaser Indemnified Party contemplated by Article XX , the Parties do not intend for this Agreement to confer a third-party beneficiary status or rights of action upon any Person whatsoever other than the Parties and their permitted successors and assigns, and nothing contained herein, either express or implied, shall be construed to confer upon any Person, other than the Parties and their permitted successors and assigns, any rights of action or remedies under this Agreement or in any manner, or any duty, standard of care, or liability with respect thereto. This Agreement does not create any third-party rights, except as expressly stated above in this Section 23.7 .
Section 23.8 Permitted Successors and Assigns . This Agreement shall be binding upon and inure to the benefit of each of the Parties and their permitted successors, legal representatives and assigns.
73
Section 23.9 Relationship of the Parties . This Agreement shall not be construed as creating an association, joint venture, trust or partnership between the Parties or as imposing any partnership obligation or liability upon either Party. Except as contemplated by Article X or Section 14.7 , neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.
Section 23.10 Construction . No presumption shall operate in favor of or against either Party as a result of any responsibility for drafting this Agreement.
Section 23.11 Counterparts . This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument. The Parties acknowledge and agree that any document or signature delivered by facsimile or electronic transmission shall be deemed to be an original executed document for all purposes hereof.
Section 23.12 Survival . The provisions of Section 3.3 , Section 3.4 , Article IX , Article XIII , Article XIV , Article XVII , Article XVIII , Article XIX , Article XX and this Article XXIII shall survive the expiration or earlier termination of this Agreement.
Section 23.13 Language . All notices, requests, demands, waivers, consents and other communications between Owner and Purchaser under this Agreement shall be conducted in English.
Section 23.14 Headings and Table of Contents . The headings of the articles and sections of this Agreement and the Table of Contents are inserted for purposes of convenience only, and shall not be construed to affect the meaning or construction of any of the provisions hereof.
Section 23.15 Waiver of Immunities . The Parties acknowledge and agree that this Agreement and the transactions contemplated hereby constitute a commercial transaction. To the extent a Party (including any assignees of a Party’s rights or obligations under this Agreement) may be entitled, in any jurisdiction, to claim for itself, or any of its assets, revenues or properties, sovereign or other immunity, as the case may be, from service of process, suit, the jurisdiction of any court or arbitral tribunal, attachment (whether in aid of execution or otherwise) or enforcement of a judgment (interlocutory or final) or award or any other legal process in a matter arising out of or relating to this Agreement, each Party agrees not to claim or assert, and hereby waives, such immunity. Without limiting the generality of the foregoing, each Party agrees that the waivers set forth in this Section 23.15 shall have the fullest scope permitted under the Immunities Act and under any other Applicable Law related to sovereign immunity.
[Signature pages follow]
74
IN WITNESS WHEREOF , Owner and Purchaser have executed this Agreement as of the Execution Date.
OWNER: |
||
|
||
CENTRAL MAINE POWER COMPANY |
||
|
|
|
By: |
|
/s/ Douglas Herling |
Name: |
|
Douglas Herling |
Title: |
|
President & CEO |
By: |
|
/s/ Eric N. Stinneford |
Name: |
|
Eric N. Stinneford |
Title: |
|
Vice President, Controller, Treasurer & Clerk |
PURCHASER: |
||
|
||
H.Q. ENERGY SERVICES (U.S.) INC. |
||
|
||
By: |
|
/s/ David Murray |
Name: |
|
David Murray |
Title: |
|
Chairman of the Board and President |
Attachment A
Description of Transmission Projects
The Québec Line and the NECEC Transmission Line consist in their entirety of:
|
(1) |
New 207 mile (145.3 miles in Maine) +/- 320 kV overhead HVDC transmission line that will run between the existing Appalaches Substation in Thetford Mines, Québec and a new HVDC converter station approximately 1.6 miles from the existing Larrabee Road Substation in Lewiston, Maine; |
|
(2) |
New HVDC converter stations at both ends of the transmission line; and |
|
(3) |
Certain upgrades to the existing high voltage alternating current (AC) New England transmission system necessary to permit the interconnection and transmission of Hydro Generation to the New England Control Area (as defined in the ISO-NE Tariff) at the existing Larrabee Road substation under the requirements of Section I.3.9 and the CCIS of ISO-NE Tariff. |
|
(4) |
System upgrades to the existing Québec transmission system as determined by the Hydro-Québec TransÉnergie System Impact Study (OASIS #203T), as it may be updated. |
Owner is the developer of the portion of the NECEC Transmission Line from the Québec-Maine border to the Lewiston area and all transmission upgrades on the U.S. side of the border. The NECEC Transmission Line and the Québec Line are expected to connect at the Québec-Maine border in the northwest corner of Maine in Beattie Township.
The Québec Line will be constructed by TransÉnergie , a division of Hydro-Québec and an Affiliate of Purchaser.
Owner will construct, own, operate and maintain the NECEC Transmission Line, which will be constructed in existing transmission corridors owned by Owner.
The NECEC Transmission Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 145.3 mile +/-320 kV HVDC transmission line from the Canadian Border to a new converter substation located on Merrill Road in Lewiston |
|
ii. |
New 1.6 mile 345 kV AC transmission line from the new Merrill Road converter substation to the existing Larrabee Road substation |
|
b. |
Substation Equipment : |
|
i. |
New 345 kV AC to +/-320 kV HVDC 1200 MW Merrill Road converter substation |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Larrabee Road substation |
|
a. |
Transmission Line Equipment: |
|
i. |
New 26.5 mile 345 kV AC transmission line from the existing Coopers Mills substation in Windsor to the existing Maine Yankee substation in Wiscasset |
|
ii. |
New 0.3 mile 345 kV AC transmission line from the existing Surowiec substation in Pownal to a new substation on Fickett Road in Pownal |
|
iii. |
Rebuild 9.3 mile 115 kV Section 62 AC transmission line from the existing Crowley Road substation in Sabattus to the existing Surowiec substation |
|
iv. |
Rebuild 16.1 mile 115 kV Section 64 AC transmission line from the existing Larrabee Road substation to the existing Surowiec substation |
|
v. |
Partial rebuild of 0.8 mile each of 115 kV Section 60/88 outside Coopers Mills substation |
|
vi. |
Partial rebuild of 0.3 miles of 345 kV Section 392 AC transmission line between the Coopers Mills substation and the Maine Yankee substation and approximately 3.5 miles of reconductor work on existing double circuit lattice steel towers outside of the Maine Yankee substation |
|
vii. |
Partial rebuild of 0.3 miles of 345 kV Section 3025 between Coopers Mills substation and Larrabee Road substation |
|
viii. |
Partial rebuild 0.8 miles of 34.5 kV Section 72 AC transmission line outside of the Larrabee Road substation |
|
b. |
Substation Equipment: |
|
i. |
Replace existing Larrabee Road 345/115 kV 448 MVA autotransformer with a 600 MVA autotransformer |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Maine Yankee substation |
|
iii. |
Add 345 kV AC transmission line terminal and 115 kV switch replacements at the existing Surowiec substation |
|
iv. |
115 kV Switch and bus wire replacements at Crowley substation |
|
v. |
New 345 kV Fickett Road substation with 345 kV +/-200 MVAr Static Compensator (STATCOM) |
|
vi. |
Add 345 kV AC transmission line terminal and additional 345 kV +/-200 MVAr STATCOM (+/-400 MVAr total with the +/-200 MVAr existing) at the existing Coopers Mills substation |
|
vii. |
Add 345/115 kV 448 MVA autotransformer, associated 115 kV buswork and terminate existing 115 kV Sections 164, 164A and 165 into three new breaker-and-a-half bays at the existing Raven Farm substation |
The NECEC transmission components located in Maine are depicted geographically in relationship to the existing Owner transmission system in Figure 1 below.
Figure 1 – Map Depicting the Components of the NECEC Transmission Line
The Québec Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 65 mile +/-320 kV HVDC transmission line from the Appalaches substation located in Thetford Mines to the U.S. border |
|
b. |
Substation Equipment : |
|
i. |
New +/-320 kV, 1200 MW HVDC converter connected to the 735 kV AC bus of the Appalaches substation and associated 735 kV bus work |
|
(2) |
Network Upgrades (subject to change based on additional system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
Thermal upgrade of existing 735 kV lines 7005 and 7035 (68 miles from Lévis substation to Nicolet substation) |
|
ii. |
Thermal upgrade of existing 735 kV line 7049 (44 miles from Montérégie substation to Hertel substation) |
|
b. |
Substation Equipment: |
|
i. |
Add two 200 MVAr shunt capacitor banks at the Carignan substation |
|
ii. |
Add one 330 MVAr shunt reactor at the Carignan substation |
Critical Milestones
Item |
Critical Milestone* |
Due Date** |
1. |
Closing of Any Required Financing |
March 7, 2019 |
2. |
Receipt of all Owner Approvals (other than Municipal Owner Approvals) and AC Upgrade Approvals in Final Form |
December 14, 2019 |
3. |
Receipt of all Canadian Approvals |
March 11, 2021 |
4. |
Receipt of all Municipal Owner Approvals |
March 31, 2022 |
5. |
Execution of Contract with the Manufacturer of the Converter Station at the Southern End of the HVDC Line and associated minimum 5% contract value payment |
July 30, 2019 |
6. |
Execution of Contract for the Engineering, Procurement, or Construction of the Converter Station on the Québec Line |
July 30, 2019 |
7. |
Commercial Operation Date |
December 13, 2022 |
* |
As defined in Section 4.1(a) |
** |
Subject to extension in accordance with the Agreement |
Owner Approvals
Set forth below are the Governmental Approvals and Third Party Consents, in each case, required to commence construction of and operate the NECEC Transmission Line:
|
1. |
ISO-NE: Approval pursuant to Section I.3.9 of the ISO-NE Tariff to interconnect and operate the NECEC Transmission Line at no fewer than 1,040 MW |
|
2. |
Maine Public Utilities Commission (MPUC): Certificate of Public Convenience and Necessity (CPCN) |
|
3. |
U.S. Department of Energy (DOE): Presidential Permit |
|
4. |
Maine Department of Environmental Protection (MDEP): |
|
a. |
Site Location of Development Act (SLODA) Permit |
|
b. |
Stormwater Management Permit |
|
c. |
Natural Resources Protection Act (NRPA) Permit |
|
d. |
Clean Water Act (CWA) Section 401 Water Quality Certification |
|
e. |
Maine Construction General Permit |
The SLODA Permit, Stormwater Management Permit, NRPA Permit, and CWA Section 401 Water Quality Certification may be combined into one permit.
|
5. |
Maine Land Use Planning Commission (LUPC): Certificate of Compliance |
|
6. |
Maine Department of Agriculture, Conservation and Forestry: |
|
a. |
Submerged Lands Lease |
|
b. |
Public Reserved Land Lease |
|
7. |
Maine Department of Transportation (DOT): |
|
a. |
Utility Location/Road Opening Permits |
|
b. |
Driveway/Entrance Permits |
|
8. |
U.S. Army Corps of Engineers: |
|
a. |
CWA Section 404 - Individual Permit |
|
b. |
Section 10 Rivers & Harbors Act of 1899 |
|
9. |
Federal Aviation Administration Infrastructure in Vicinity of Airports: Determination of No Hazard to Air Navigation |
|
10. |
Municipal Owner Approvals: |
|
a. |
The Municipal Owner Approvals consist of the following types of permits: |
|
i. |
Shoreland zoning permits |
|
ii. |
Building permits |
|
iii. |
Flood hazard development permits |
|
iv. |
Conditional use / rezoning approvals |
|
vi. |
Driveway / entrance permits |
|
vii. |
Street opening, blasting and demolition permits |
|
viii. |
Utility location permits |
|
b. |
Owner shall obtain the Municipal Owner Approvals listed above that are necessary (if any) in the following municipalities for the NECEC Transmission Line, subject to any necessary exemptions issued by the MPUC relating to any Municipal Owner Approvals that are denied in any such municipalities or relating to any conditions contained in any Municipal Owner Approvals that are unacceptable to Owner: |
i. |
Alna |
xiii. |
Embden |
ii. |
Lewiston |
xiv. |
Starks |
iii. |
Anson |
xv. |
Farmington |
iv. |
Livermore Falls |
xvi. |
Whitefield |
v. |
Auburn |
xvii. |
Greene |
vi. |
Moscow |
xviii. |
Wilton |
vii. |
Caratunk |
xix. |
Industry |
viii. |
New Gloucester |
xx. |
Windsor |
ix. |
Chesterville |
xxi. |
Jay |
x. |
New Sharon |
xxii. |
Wiscasset |
xi. |
Durham |
xxiii. |
Leeds |
xii. |
Pownal |
xxiv. |
Woolwich |
Canadian Approvals
Set forth below are, to the best of Purchaser’s knowledge, the Governmental Approvals and Third Party Consents, in each case, required to commence construction of the Québec Line:
|
• |
Permit from the National Energy Board to construct, operate, maintain or connect an international power line pursuant to the National Energy Board Act (R.S. C., 1985, c. N-7); |
|
• |
Permit from the International Boundary Commission required to cross the Canada-U.S. border pursuant to Article 5 of the International Boundary Commission Act; |
|
• |
Authorization from the Régie de l’énergie to acquire, construct or dispose of transmission assets pursuant to an Act respecting the Régie de l’énergie (R.S.Q., chapter R-6.01); |
|
• |
Expropriation Order in council, if required, to acquire by expropriation any immovable, servitude or construction required for the transmission of power pursuant to Hydro-Québec Act (R.S.Q., chapter H-5) and the Expropriation act (R.S.Q., chapter E-24); |
|
• |
Certificate of authorization issued by the Government of Québec to construct the transmission line under Section 31.5 of the Environmental Quality Act subject to the environmental and social impact assessment and review procedure; |
|
• |
Certificate of authorization issued by the Ministère du Développement durable, de l’Environnement et de la Lutte contre les changements climatiques approving the plans and specifications of the transmission line pursuant to Section 22 of the Environmental Quality Act; |
|
• |
Authorization of the Commission de protection du territoire agricole du Québec , if required, approving the use of land situated in an agricultural zone for purposes other than agriculture under Sections 58 and 62 of the Act respecting the preservation of agricultural land and agricultural activities; |
|
• |
Opinion on project compliance with objectives of the city or regional county municipalities’ land-use and development plan. |
Owner’s Preliminary Project Schedule and Construction Schedule
Required Insurance
Owner shall obtain and maintain with qualified insurers authorized to issue insurance of the types described below in the State of Maine.
During construction of the NECEC Transmission Line Owner shall maintain or effect to be maintained the following insurance coverages:
|
• |
Primary and Excess Liability |
|
• |
Construction All Risk / Builders Risk |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
|
• |
Pollution / Environmental Liability |
After the Commercial Operation Date Owner shall provide coverage both in terms of scope and limits of coverage that are in accordance with Good Utility Practice and the long-standing practice of Owner. Operational coverage shall include the following insurance types:
|
• |
Excess Liability |
|
• |
Operational All Risk Property Damage |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
Note : At any time after the Commercial Operation Date Owner may choose, as far as it is consistent with Good Utility Practice, to self-insure on customary terms and conditions any coverage (or coverage part) where it meets any state or regulatory requirements of self-insurers.
Rate Adjustment Formula
In the event that a Transmission Service Payment is subject to reduction pursuant to Section 8.1 , such reduced payment shall equal the Transmission Service Payment that would otherwise be payable under the Agreement for a particular month multiplied by the lesser of 1 or the following fraction:
1 - |
(Contract Capacity x 0.90) |
minus (Contract Capacity x A) |
|
|
|
(Contract Capacity x 0.90) |
Where A = |
∑ Hourly Availability for all hours in such month |
∑ Hours in such month |
For purposes of calculating A, Excused Outages (for which Owner is paid full Transmission Service Payments pursuant to the terms of the Agreement) will be regarded as hours in which one hundred percent (100%) of Contract Capacity was provided.
Refund Calculation
This example is intended to illustrate the methodology for the calculation of a subsequent refund of a late payment. This example and the numbers used in this example are purely illustrative and are in no way intended to supersede any part of the Agreement, including Section 13.3 .
Assumptions
|
• |
Interest Rate = 12 percent per annum (compounded monthly) |
June 2043 Billing
Invoice Amount |
$1,000 |
Date of Invoice |
June 1, 2043 |
Due Date |
June 15, 2043 |
Payment Date |
July 1, 2043 |
The total amount due on the date of payment is $1,005, which amount is computed by adding $1,000 (the original amount invoiced) and $5 (the ½ month late interest fee).
Subsequent Refund
If later, on July 1, 2044, the aforesaid payment is required to be refunded, the refund will equal the $1,000 payment made on July 1, 2043 (the original amount invoiced), plus the interest accrued on that $1,000 payment from the due date of June 15, 2043 to the date of refund on July 1, 2044. To ensure that the refund does not double recover interest, the following language has been included in Section 13.3 of the Agreement: “[I]f all or a portion of the amount [ here, the $1,000 payment due on June 15, 2043 ] to which such interest relates [ here, the $5 late interest fee ] is later refunded pursuant to this Agreement [ here, on July 1, 2044 ], then, in calculating that refund, such interest [ here, $5 ] shall not be included in the refund.”
Attachment I
Real Estate Rights
Form of Purchaser Guaranty
CONVENTION DE CAUTIONNEMENT La présente convention de cautionnement (« Cautionnement »), portant la date du juin 2018, est conclue entre Hydro-Québec , société dûment constituée et régie par la Loi sur Hydro-Québec (L.R.Q., chapitre H-5) ayant son siège social et son principal lieu d’affaires au 75, boulevard René-Lévesque Ouest, Montréal, Québec, Canada, H2Z 1A4 (ci-après appelée « Caution »), et Central Maine Power Company, société dûment constituée en vertu des lois de l’État du Maine, ayant son principal lieu d'affaires au 83 Edison Drive, Augusta ME 04336, États-Unis d'Amérique (ci-après appelée « Bénéficiaire »). |
|
GUARANTY AGREEMENT This Guaranty Agreement («Guaranty»), dated as of June 2018, is made and entered into between Hydro-Québec , a body politic and corporate, duly incorporated and regulated by Hydro-Québec Act (R.S.Q., chapter H-5) and having its head office and principal place of business at 75, René-Lévesque Boulevard West, Montréal, Québec, Canada, H2Z 1A4, hereinafter referred to as the «Guarantor» and Central Maine Power Company, a corporation duly organized under the laws of the State of Maine, having its principal place of business at 83 Edison Drive, Augusta ME 04336, United States of America, (hereinafter referred to as the «Beneficiary»). |
ATTENDU QUE le Bénéficiaire et H.Q. ENERGY SERVICES (U.S.) INC. , société créée en vertu des lois de l’état du Delaware, ayant son lieu d’affaires au 225 Asylum Street, 27 th étage, Hartford, CT 06103 (ci-après appelée « HQUS »), filiale en propriété indirecte de la Caution, ont signé les ententes suivantes: (a) une entente de service de transport pour l’achat de 579.335 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (b) une entente de service de transport pour l’achat de 498.348 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (c) une entente de service de transport pour l’achat de 12.317 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (d) une entente de service de transport pour l’achat de 110 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018 (ci-après appelées collectivement les « Conventions »); |
|
WHEREAS the Beneficiary and H.Q. ENERGY SERVICES (U.S.) INC., a corporation created under the laws of the State of Delaware, having its place of business at 225 Asylum Street, 27 th Floor, Hartford, CT 06103, (hereinafter referred to as «HQUS»), an indirectly owned subsidiary of the Guarantor, have executed the following agreements: (a) a Transmission Service Agreement for the purchase of 579.335 MW of firm transmission service from the Beneficiary dated as of June 13, 2018; (b) a Transmission Service Agreement for the purchase of 498.348 MW of firm transmission service from the Beneficiary dated as of June 13, 2018; (c) a Transmission Service Agreement for the purchase of 12.317 MW of firm transmission service from the Beneficiary dated as of June 13, 2018, and (d) a Transmission Service Agreement for the purchase of 110 MW of firm transmission service from the Beneficiary dated as of June 13, 2018 (hereinafter collectively referred to as the «Agreements»); |
ATTENDU QUE la Caution bénéficiera directement ou indirectement des Conventions ; |
|
WHEREAS the Guarantor will directly or indirectly benefit from the Agreements; |
ATTENDU QUE le Bénéficiaire a exigé que la Caution garantisse inconditionnellement au Bénéficiaire toutes les obligations de paiement qui incombent à HQUS en vertu des Conventions, sous réserve de la somme maximale prévue à l’article 1 du présent Cautionnement; |
|
WHEREAS the Beneficiary has required that the Guarantor unconditionally guarantee to the Beneficiary all payment obligations of HQUS under the Agreements; subject to a maximum dollar limitation as provided in Section 1 of this Guaranty; |
EN CONSÉQUENCE, eu égard à ce qui précède, la Caution s’entend avec le Bénéficiaire sur ce qui suit : |
|
NOW THEREFORE, in consideration of the premises, the Guarantor hereby agrees with the Beneficiary as follows: |
HYDRO-QUÉBEC |
||
|
||
Par / By: |
|
|
Nom / Name: |
|
|
Titre / Title: |
|
|
Par / By: |
|
|
Nom / Name: |
|
|
Titre / Title: |
|
|
Exhibit 10.8
ADDITIONAL TRANSMISSION SERVICE AGREEMENT
by and between
CENTRAL MAINE POWER COMPANY,
as Owner,
and
H.Q. ENERGY SERVICES (U.S.) INC.,
as Purchaser
Dated: as of June 13, 2018
|
|
|
Page |
|
|
||
Article I DEFINITIONS AND RULES OF INTERPRETATION |
2 |
||
|
|
||
|
Section 1.1 |
Definitions |
2 |
|
Section 1.2 |
Interpretation |
15 |
|
|
||
Article II REGULATORY FILINGS AND REQUIRED APPROVALS |
17 |
||
|
|
||
|
Section 2.1 |
MDPU Filing; FERC Filings |
17 |
|
Section 2.2 |
Modifications to FERC Order |
17 |
|
Section 2.3 |
[Intentionally Omitted.] |
18 |
|
Section 2.4 |
Cooperation |
18 |
|
Section 2.5 |
No Inconsistent Action |
19 |
|
|
||
Article III EFFECTIVE DATE; TERM |
18 |
||
|
|
||
|
Section 3.1 |
Effective Date |
19 |
|
Section 3.2 |
Term |
19 |
|
Section 3.3 |
Termination Rights |
19 |
|
Section 3.4 |
Termination Payments |
22 |
|
Section 3.5 |
Effect of Termination |
22 |
|
|
||
Article IV COMMERCIAL OPERATION |
22 |
||
|
|
||
|
Section 4.1 |
Critical Milestones |
22 |
|
Section 4.2 |
Commercial Operation Date |
24 |
|
Section 4.3 |
Conditions Precedent to Commercial Operation |
25 |
|
Section 4.4 |
Delay in Commercial Operation; Reduced Level of Operation |
26 |
|
|
||
Article V GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES |
30 |
||
|
|
||
|
Section 5.1 |
Responsibilities of the Parties |
30 |
|
Section 5.2 |
Schedules and Reports |
30 |
|
Section 5.3 |
Québec Line Reports; Joint Development Agreement |
32 |
|
Section 5.4 |
Insurance and Events of Loss |
32 |
|
Section 5.5 |
Compliance with Laws |
32 |
|
Section 5.6 |
Third Party Contracts |
32 |
|
Section 5.7 |
Purchaser’s Losses |
33 |
|
Section 5.8 |
Continuity of Rights and Responsibilities |
33 |
|
|
i
ii
Section 13.1 |
Invoices |
41 |
|
|
Section 13.2 |
Procedures for Billing Disputes |
41 |
|
Section 13.3 |
Interest |
42 |
|
Section 13.4 |
Obligation to Make Payments |
42 |
|
Section 13.5 |
Offsets |
42 |
|
|
||
Article XIV EVENTS OF DEFAULT AND REMEDIES |
42 |
||
|
|
||
|
Section 14.1 |
Purchaser Defaults |
42 |
|
Section 14.2 |
[Intentionally Omitted] |
43 |
|
Section 14.3 |
Owner Defaults |
43 |
|
Section 14.4 |
Remedies Upon Purchaser Default |
45 |
|
Section 14.5 |
[Intentionally Omitted] |
46 |
|
Section 14.6 |
Remedies Upon Owner Default |
46 |
|
Section 14.7 |
Purchaser Step-in Rights. |
47 |
|
Section 14.8 |
[Intentionally Omitted]. |
47 |
|
Section 14.9 |
Disputes |
47 |
|
Section 14.10 |
Limitations on Total Liability |
47 |
|
Section 14.11 |
Modified Terms Applicable During Forbearance Period |
48 |
|
|
||
Article XV FORCE MAJEURE |
49 |
||
|
|
||
|
Section 15.1 |
Definition; Conditions |
49 |
|
|
||
Article XVI FINANCIAL ASSURANCES |
50 |
||
|
|
||
|
Section 16.1 |
Purchaser’s Guaranty |
50 |
|
Section 16.2 |
[Intentionally Omitted] |
50 |
|
Section 16.3 |
Credit Downgrade Event |
50 |
|
|
||
Article XVII DISPUTE RESOLUTION |
51 |
||
|
|
||
|
Section 17.1 |
Consultation |
51 |
|
Section 17.2 |
Disputes to be Resolved by FERC |
51 |
|
Section 17.3 |
Consent to Jurisdiction |
52 |
|
Section 17.4 |
WAIVER OF JURY TRIAL |
52 |
|
|
||
Article XVIII LIMITATION OF REMEDIES |
52 |
||
|
|
||
Article XIX MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES. |
54 |
||
|
|
||
|
Section 19.1 |
Modifications |
54 |
iii
Section 19.2 |
Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment |
54 |
|
|
|
||
Article XX INDEMNIFICATION |
55 |
||
|
|
||
|
Section 20.1 |
Purchaser Indemnity |
55 |
|
Section 20.2 |
Owner Indemnity |
56 |
|
Section 20.3 |
Procedures |
56 |
|
Section 20.4 |
Defenses |
57 |
|
Section 20.5 |
Cooperation |
57 |
|
Section 20.6 |
Recovery |
57 |
|
Section 20.7 |
Subrogation |
57 |
|
|
||
Article XXI REPRESENTATIONS, WARRANTIES, AND COVENANTS |
58 |
||
|
|
||
|
Section 21.1 |
Mutual Representations and Warranties |
58 |
|
Section 21.2 |
Additional Representations and Warranties of Purchaser |
58 |
|
Section 21.3 |
Additional Representations and Warranties of Owner |
59 |
|
Section 21.4 |
[Intentionally Omitted] |
60 |
|
Section 21.5 |
NO OTHER REPRESENTATIONS OR WARRANTIES |
61 |
|
|
||
Article XXII TRANSFER OF INTERESTS |
61 |
||
|
|
||
|
Section 22.1 |
No Transfer of Interests |
61 |
|
Section 22.2 |
Exceptions |
62 |
|
Section 22.3 |
Collateral Assignment |
63 |
|
|
||
Article XXIII MISCELLANEOUS |
63 |
||
|
|
||
|
Section 23.1 |
Governing Law |
63 |
|
Section 23.2 |
Entire Agreement |
63 |
|
Section 23.3 |
Severability |
63 |
|
Section 23.4 |
Notices |
63 |
|
Section 23.5 |
Waiver; Cumulative Remedies |
64 |
|
Section 23.6 |
Confidential Information |
65 |
|
Section 23.7 |
No Third-Party Rights |
66 |
|
Section 23.8 |
Permitted Successors and Assigns |
66 |
|
Section 23.9 |
Relationship of the Parties |
66 |
|
Section 23.10 |
Construction |
66 |
|
Section 23.11 |
Counterparts |
66 |
|
Section 23.12 |
Survival |
66 |
|
Section 23.13 |
Language |
66 |
|
Section 23.14 |
Headings and Table of Contents |
66 |
|
Section 23.15 |
Waiver of Immunities |
66 |
iv
ATTACHMENTS
Attachment A |
Description of Transmission Projects |
Attachment B |
Critical Milestones |
Attachment C |
Owner Approvals |
Attachment D |
Canadian Approvals |
Attachment E |
Owner’s Preliminary Project Schedule and Construction Schedule |
Attachment F |
Required Insurance |
Attachment G |
Rate Adjustment Formula |
Attachment H |
Refund Calculation |
Attachment I |
Real Estate Rights |
Attachment J |
Form of Purchaser Guaranty |
Attachment K |
Transmission Service Payment Calculation |
v
ADDITIONAL TRANSMISSION SERVICE AGREEMENT
This ADDITIONAL TRANSMISSION SERVICE AGREEMENT (this “ Agreement ”), dated as of June 13, 2018 (the “ Execution Date ”), is made and entered into by and between Central Maine Power Company, a corporation organized and existing under the laws of the State of Maine (“ Owner ”), and H.Q. Energy Services (U.S.) Inc. , a corporation organized and existing under the laws of the State of Delaware (“ HQ-US ” or “ Purchaser ”). Owner and Purchaser are hereinafter sometimes also referred to individually as a “ Party ” or collectively as the “ Parties .”
WITNESSETH
WHEREAS, Purchaser is an indirect, wholly-owned subsidiary of Hydro-Québec (as defined below);
WHEREAS, pursuant to “An Act to Promote Energy Diversity” that was signed into law in the Commonwealth of Massachusetts on August 8, 2016 (the “ Energy Diversity Act ”), Fitchburg Gas and Electric Light Company (d/b/a Unitil), Massachusetts Electric Company and Nantucket Electric Company (d/b/a National Grid), and NSTAR Electric Company (d/b/a Eversource Energy) (collectively, the “ RFP Sponsors ”) have solicited competitive proposals for clean energy generation for an annual amount of electricity equal to approximately 9.45 TWh;
WHEREAS, Owner and an Affiliate of HQ-US jointly submitted a proposal pursuant to such solicitation that includes up to 1,090 MW of clean energy generation obtained by HQ-US from its affiliate Hydro-Québec Production (a division of Hydro-Québec (as defined below), “ HQP ” and such generation, the “ Hydro Generation ”);
WHEREAS, concurrently with the execution and delivery of this Agreement, HQ-US has entered into power purchase agreements (the “ PPAs ”) with the RFP Sponsors with respect to an aggregate of 1,090 MW of Hydro Generation (and related renewable energy credits and environmental attributes);
WHEREAS, as part of the delivery of 1,090 MW of Hydro Generation for sale into the U.S. pursuant to the PPAs, Hydro-Québec TransÉnergie (“ TransÉnergie ”), a division of Hydro-Québec, intends to develop, construct, own, and maintain a 1,200 MW +/-320 kV high-voltage direct current (“ HVDC ”) transmission line from the converter station at the Appalaches substation in Thetford Mines, Québec to the U.S. Border (as defined below) at Beattie Township, Maine (as further delineated in the diagram or described in Attachment A , the “ Québec Line ”);
WHEREAS, HQP has acquired from TransÉnergie firm transmission service over the Québec Line to permit the delivery of at least 1,200 MW of power into the U.S.;
WHEREAS, Owner intends to develop, construct, own and maintain a 1,200 MW +/-320 kV HVDC transmission line extending from the U.S. Border at Beattie Township, Maine to a new direct current to alternating current (“ AC ”) converter station to be located at Merrill Road in the City of Lewiston in the State of Maine (the transmission line and converter station, as more fully described in Attachment A , the “ HVDC Line ”);
1
WHEREAS, in order to interconnect the HVDC Line with the bulk power systems in New England, Owner intends to develop, construct, own and, maintain additional 345 kV AC transmission lines, rebuilt 115 kV AC transmission lines and other substation equipment more fully described in Attachment A (together with the Merrill Road substation at its northern terminus and the associated equipment, as more fully described in Attachment A , the “ AC Line ” and, together with the HVDC Line, the “ NECEC Transmission Line ” );
WHEREAS, although Owner has performed studies believed to replicate those utilized by ISO-NE and does not believe that AC Upgrades (as defined below) or CCIS Capacity Upgrades (as defined below) will be required as a consequence of the construction and operation of the NECEC Transmission Line and the consummation of the transactions contemplated by this Agreement, this Agreement, the RFP Sponsor TSAs (as defined below), the Purchaser TSAs (as defined below) and the PPAs, ISO-NE (as defined below) may require certain AC Upgrades or CCIS Capacity Upgrades to be developed, constructed, owned and maintained by certain transmission owners other than Owner (which may include Affiliates of Owner) within their existing service territories in New England in order to interconnect the NECEC Transmission Line with the New England Transmission System (as defined below) in a safe and reliable manner, which AC Upgrades or CCIS Capacity Upgrades (if any) will be performed at Owner’s sole expense;
WHEREAS, Owner has entered into transmission service agreements (the “ RFP Sponsor TSAs ”) with the RFP Sponsors to sell an aggregate of 1,090 MW of firm transmission service for the first twenty (20) years following the Commercial Operation Date (as defined below);
WHEREAS, Owner has entered into transmission service agreements (the “ Purchaser TSAs ”) with Purchaser to sell an aggregate of 1,090 MW of firm transmission service for years twenty-one (21) through forty (40) following the Commercial Operation Date; and
WHEREAS, Owner desires to sell Firm Transmission Service (as defined below) of up to 110 MW to Purchaser for the first forty (40) years following the Commercial Operation Date, and Purchaser desires to acquire such Firm Transmission Service from Owner, at the rates and on the terms and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the foregoing and the respective representations, warranties, covenants, agreements and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound hereby, the Parties hereby agree as follows:
DEFINITIONS AND RULES OF INTERPRETATION
Section 1.1 Definitions . As used herein, the following terms shall have the following respective meanings:
“ AC ” has the meaning provided in the recitals to this Agreement.
“ AC Line ” has the meaning provided in the recitals to this Agreement.
2
“ AC Upgrade Approvals ” means, collectively, any Governmental Approvals or Third Party Consents, in each case, that are required to commence construction of the AC Upgrades.
“ AC Upgrade Owners ” means, collectively, any Person responsible for constructing one or more AC Upgrades pursuant to a facilities agreement.
“ AC Upgrades ” means any additions, upgrades, reinforcements or other modifications to the New England Transmission System that ISO-NE determines, pursuant to Section I.3.9 of the ISO-NE Tariff, to be required, at a minimum, to interconnect the NECEC Transmission Line at the Delivery Point with the New England Transmission System.
“ Additional Bids ” has the meaning provided in Article XVIII .
“ Additional Credit Support ” means one or more of the following, issued in favor of or otherwise held by or for the benefit of Owner or Purchaser, as applicable:
(a) a guaranty, in form and substance reasonably satisfactory to Purchaser or Owner (as applicable), issued by an Affiliate of Owner or Purchaser (as applicable) that meets the Credit Rating Requirements;
(b) a Letter of Credit, in form and substance reasonably satisfactory to Purchaser or Owner (as applicable); or
(c) Cash.
“ Adverse Determination ” has the meaning provided in Section 19.2(c) .
“ Affiliate ” means, with respect to a specified Person, any other Person that directly or indirectly Controls, is Controlled by or is under common Control with the specified Person; provided , however , that, with respect to Purchaser, a Person shall not be an “Affiliate” of Purchaser unless such Person is Hydro-Québec (including, for the avoidance of doubt, a division of Hydro-Québec) or Controlled by Hydro-Québec.
“ Agreement ” has the meaning provided in the preamble to this Agreement.
“ Applicable Law ” means any duly promulgated federal, national, state, provincial or local law, regulation, rule, ordinance, code, decree, judgment, directive or judicial or administrative order, permit or other duly authorized and valid action of any Governmental Authority, including any binding interpretation of any of the foregoing by any Governmental Authority, which is applicable to a Person, its property, or a transaction, and also including Section 83D, the regulations promulgated under Section 83D, the Regulatory Approval and any other orders of the MDPU with respect to this Agreement.
“ Approval Deadline ” has the meaning provided in the RFP Sponsor TSAs and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Available Transfer Capability ” means the Total Transfer Capability minus 1,090 MW, with any negative number treated as zero (0).
3
“ Bankruptcy Code ” means the United States Bankruptcy Code, 11 U.S.C. § 101 et seq .
“ Business Day ” means any day except Saturday, Sunday or any other day on which the Federal Reserve member banks are required or authorized to close for business.
“ Canadian Approval Deadline ” has the meaning provided in the RFP Sponsor TSAs and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Canadian Approvals ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the Québec Line in a manner consistent with Attachment A , all as set forth in Attachment D .
“ Cash ” means U.S. dollars held by or on behalf of a Party as Credit Support hereunder.
“ CCIS Capacity Upgrade ” means any upgrade determined by ISO-NE as necessary in order for the NECEC Transmission Line Capacity to satisfy the Capacity Capability Interconnection Standard under and as defined in the ISO-NE Tariff.
“ COD Notice ” has the meaning provided in Section 4.2(c) .
“ Commercial Operation ” means the availability of the NECEC Transmission Line for the provision of Firm Transmission Service in accordance with this Agreement and the RFP Sponsor TSAs.
“ Commercial Operation Date ” has the meaning provided in Section 4.2(c) .
“ Commissioning ” means (a) with respect to the NECEC Transmission Line, the start-up and testing activities required to demonstrate that the NECEC Transmission Line is ready for Commercial Operation and (b) with respect to the Québec Line, the start-up and testing activities required to demonstrate that the Québec Line is ready for commercial operation, consistent with Section 4.3(f) .
“ Concurrent Delay ” has the meaning provided in Section 4.4.3 .
“ Concurrent Remediation Date ” has the meaning provided in Section 4.4.3(b)(ii) .
“ Concurrent Remediation Period ” has the meaning provided in Section 4.4.3(b)(ii) .
“ Confidential Information ” means (a) this Agreement, (b) any documents, analyses, compilations, studies or other materials prepared by or information received from a Party or its representatives that contain or reflect written or oral data or information that is privileged, confidential or proprietary and that is marked or otherwise clearly identified as “confidential” or “proprietary” or with words of like meaning or (c) any subsequently prepared documents, analyses, compilations, studies or other materials or information that are derived from any of the documents, analyses, compilations, studies or other materials or information described in the foregoing clause (b). Without limiting the generality of the foregoing, all information provided to Purchaser or Owner under Sections 2.4 , 5.2 and 6.3 hereof shall be deemed to be Confidential Information, whether or not such information is marked as “confidential” or “proprietary.”
4
“ Consent ” means, with respect to a Person, any approval, consent, permit, license, decree, certificate or other authorization of or from such Person.
“ Construction Authorizations ” means, collectively, those Governmental Approvals and Third Party Consents, in each case, that are required to commence construction of the NECEC Transmission Line, other than the ISO-NE Approval, including the approvals of the Maine Department of Environmental Protection, the U.S. Army Corp of Engineers, the Maine Public Utilities Commission and the U.S. Department of Energy (the Presidential Permit), as more fully set forth in Attachment C .
“ Construction Contract ” means any contract entered into by Owner that provides for the engineering, procurement or construction of the NECEC Transmission Line.
“ Construction Phase ” means the period commencing upon the receipt of the FERC Authorization or such other date to which the Parties shall mutually agree in writing, and ending on the day immediately preceding the Commercial Operation Date or upon the earlier termination of this Agreement pursuant to its terms (regardless of whether or not any such day is a Business Day).
“ Contract Capacity ” means (a) 110 MW or (b) such lesser amount equal to the NECEC Transmission Line Capacity minus 1,090, with any negative number treated as zero.
“ Contract Year ” means each twelve-month period during the Term, with the first Contract Year commencing on the Commercial Operation Date and with each Contract Year after the first commencing on the anniversary of the Commercial Operation Date.
“ Control ” (including its correlative meanings “Controlled by” and “under common Control with”) means, with respect to a Person, the possession, directly or indirectly, of the power to direct or cause the direction of the management or policies of the specified Person, whether through ownership of voting securities or partnership or other ownership interests, by contract or Applicable Law or otherwise.
“ Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , Section 4.1(d) or Section 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Credit Rating Requirements ” means a long-term credit rating of at least “BBB-” by S&P or “Baa3” by Moody’s.
“ Credit Support ” means collateral in the form of (a) Cash or (b) a Letter of Credit issued by a Qualified Bank in a form reasonably satisfactory to the beneficiary.
“ Critical Energy Infrastructure Information ” means any information defined as Critical Energy Infrastructure Information by FERC pursuant to 18 C.F.R. § 388.113, and shall include all Critical Infrastructure Protection (CIP) standards (CIP-002 through CIP-009) established by NERC.
“ Critical Milestone ” has the meaning provided in Section 4.1(a) .
5
“ Delivery Point ” means the southern terminus of the NECEC Transmission Line at the Larrabee Road substation in Lewiston, Maine, as illustrated in Attachment A .
“ Design Capability ” means the maximum amount of electric power that the materials, equipment and structures comprising the HVDC Transmission Project will be designed to transfer bi-directionally in a safe and reliable manner, which amount shall be sufficient to permit the north-to-south delivery of all amounts scheduled for delivery in an aggregate amount of at least 1,090 MW, but not to exceed 1,200 MW, of electrical energy at the Delivery Point.
“ Discount Rate ” means the prime rate specified in the “Money and Investing” section of the Wall Street Journal, determined as of the date of the notice of default, plus 300 basis points.
“ Dispute ” means any dispute, controversy or claim of any kind whatsoever arising out of or relating to a Proposal Agreement, including relating to the interpretation of the terms thereof or any Applicable Law that affects such Proposal Agreement, or the transactions contemplated thereunder, or the breach, termination or validity thereof.
“ Effective Date ” has the meaning provided in Section 3.1 .
“ Energy Diversity Act ” has the meaning provided in the recitals to this Agreement.
“ Excused Outages ” has the meaning provided in Section 7.2(a) .
“ Execution Date ” has the meaning provided in the preamble to this Agreement.
“ Federal Power Act ” means the United States Federal Power Act of 1935, as amended, 16 U.S.C. § 791a et seq.
“ FERC ” means the Federal Energy Regulatory Commission, or any successor regulatory agency that administers the Federal Power Act.
“ FERC Amendment ” has the meaning provided in Section 2.2(b) .
“ FERC Authorization ” means, collectively, any FERC order that is not subject to rehearing or appeal authorizing Owner to provide Firm Transmission Service, including the FERC Order, any RFP Sponsor TSA FERC Order, any Purchaser TSA FERC Order and any authorization from FERC with respect to the Transmission Operating Agreement or Interconnection Agreements.
“ FERC Order ” has the meaning provided in Section 2.2(a) .
“ Financial Transmission Rights ” means Financial Transmission Rights, as defined in the ISO-NE Tariff.
“ Financing Deadline ” has the meaning provided in the RFP Sponsor TSAs and may be extended in accordance with Section 4.1(c) or Section 4.1(e) .
“ Firm Transmission Service ” has the meaning provided in Section 7.1.1 .
6
“ Force Majeure ” has the meaning provided in Section 15.1(a) .
“ Good Utility Practice ” means those design, construction, operation, maintenance, repair, removal, and disposal practices, methods and acts that are engaged in by a significant portion of the electric transmission industry in the United States during the relevant time period, or any other practices, methods or acts that, in the exercise of reasonable judgment in light of the facts known at the time a decision is made, could have been expected to accomplish a desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Good Utility Practice is not intended to be the optimum practice, method or act to the exclusion of others but rather to be a spectrum of acceptable practices, methods or acts generally accepted in such electric transmission industry for the design, construction, operation, maintenance, repair, removal and disposal of electric transmission facilities in the United States. Good Utility Practice shall not be determined after the fact in light of the results achieved by the practices, methods or acts undertaken, but rather shall be determined based upon the consistency of (a) the practices, methods or acts when undertaken with (b) the standard set forth in the first two (2) sentences of this definition at such time.
“ Governmental Approval ” means (a) any authorization, consent, approval, license, lease, ruling, permit, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with or (d) any registration by or with, any Governmental Authority, including any FERC Authorization.
“ Governmental Authority ” means any government or agency or other political subdivision thereof, including any province, state or municipality, or any other governmental, quasi-governmental, judicial, executive, legislative, administrative, regulatory, public or statutory instrumentality, authority, body, agency, commission, department, board, bureau or entity exercising judicial, executive, legislative, administrative or regulatory functions, any court or arbitrator with authority to bind a party at law, and shall include, to the extent exercising powers delegated by any Governmental Authority acting under Applicable Law, NERC and ISO-NE.
“ Hourly Availability ” means, with respect to any hour, the availability of the NECEC Transmission Line for the purposes of this Agreement, which shall equal (a) the Available Transfer Capability for such hour, divided by (b) the Contract Capacity, expressed as a percentage; provided , however , that, for any hour, such availability of the NECEC Transmission Line shall not exceed one hundred percent (100%).
“ HQ-US ” has the meaning provided in the preamble to this Agreement.
“ HQE ” means Hydro-Québec Équipment, a division of Hydro-Québec.
“ HQP ” has the meaning provided in the recitals to this Agreement.
“ HVDC ” has the meaning provided in the recitals to this Agreement.
“ HVDC Line ” has the meaning provided in the recitals to this Agreement.
“ HVDC Transmission Project ” means, collectively, (a) the Québec Line and (b) the NECEC Transmission Line.
7
“ Hydro Generation ” has the meaning provided in the recitals to this Agreement.
“ Hydro-Québec ” means Hydro-Québec, a body politic and corporate, duly incorporated and regulated by the Hydro-Québec Act (R.S.Q., Chapter H-5). As of the Execution Date, Hydro-Québec has four divisions: HQP, TransÉnergie, Hydro-Québec Distribution and HQE.
“ Hydro-Quebec Guaranty ” has the meaning provided in Section 16.1 .
“ Immunities Act ” means the United States Foreign Sovereign Immunities Act of 1976, 28 U.S.C. § 1602 et seq.
“ Indemnification Notice ” has the meaning provided in Section 20.3 .
“ Indemnified Party ” has the meaning provided in Section 20.3 .
“ Indemnifying Party ” has the meaning provided in Section 20.3 .
“ Initial Purchaser Term ” has the meaning provided in Section 8.1 .
“ Initial Transmission Service Payment ” has the meaning provided in Section 8.1.
“ Insolvency Event ” means, with respect to a Person, such Person (a) becomes “insolvent,” as defined in the Bankruptcy Code, or otherwise becomes bankrupt or insolvent under any Insolvency Laws, (b) has a liquidator, administrator, receiver, custodian, trustee, conservator or similar official appointed with respect to such Person or any material portion of such Person’s assets or such Person consents to such appointment, or a foreclosure action is instituted with respect to any material portion of such Person’s assets and is not dismissed within thirty (30) days of commencement thereof, (c) files a voluntary petition or otherwise authorizes or commences a proceeding or cause of action under the Bankruptcy Code or Insolvency Laws, (d) has an involuntary petition filed against it or acquiesces in the commencement of a proceeding or cause of action as the subject debtor under the Bankruptcy Code or Insolvency Laws, which petition is not dismissed within thirty (30) days after the filing thereof or results in the issuance of an order for relief against such Person, (e) makes or consents to an assignment of its assets in whole or in part, for the benefit of creditors or any general arrangement for the benefit of creditors, or a common law composition of creditors or (f) generally is unable to pay its debts as they fall due, or admits in writing to such inability.
“ Insolvency Laws ” means any bankruptcy, insolvency, reorganization or similar laws of the U.S., Canada or other Governmental Authority, as applicable, other than the Bankruptcy Code.
8
“ Interconnection Agreements ” means, collectively, (a) an agreement by and among Owner, TransÉnergie and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the U.S. Border of the NECEC Transmission Line with the Québec Line and (b) an agreement by and between Owner and ISO-NE that sets forth such parties’ respective rights and obligations following the interconnection at the Delivery Point of the NECEC Transmission Line with certain transmission facilities operated by ISO-NE. The Interconnection Agreements shall address cost responsibilities among entities other than the RFP Sponsors and shall include provisions, both technical and otherwise, for safe and reliable interconnected operations of the HVDC Transmission Project following Commercial Operation (including use of the HVDC Transmission Project for the delivery of electric power in emergency circumstances).
“ Interested Party ” means, collectively, the Parties and, if and as applicable, the RFP Sponsors.
“ Invoice ” means, with respect to a calendar month, an invoice that sets forth the amounts owed to the applicable Party with respect to such month in reasonable detail to evidence the basis for individual billings and charges.
“ ISO-NE ” means ISO New England Inc., or its successor organization.
“ ISO-NE Approval ” means approval by ISO-NE to operate the NECEC Transmission Line up to 1,200 MW.
“ ISO-NE Definitions Manual ” means the ISO New England Manual for Definitions and Abbreviations, Manual M-35, as in effect from time to time.
“ ISO-NE Rules ” means the ISO-NE Tariff and all ISO-NE manuals, rules, procedures, agreements or other documents relating to the reliable operation of the electric system in New England and the purchase and sale of electrical energy, electrical capacity and ancillary services, as such govern market participants with respect thereto in the operating jurisdiction of ISO-NE, as in effect from time to time, including the ISO-NE Definitions Manual; provided that such documents are publicly accessible.
“ ISO-NE Tariff ” means the ISO New England Inc. Transmission, Markets and Services Tariff, FERC Electric Tariff No. 3, as in effect from time to time, on file with FERC, or its successor tariff.
“ Joint Development Agreement ” has the meaning provided in Section 5.3 .
“ kV ” means kilovolt.
“ K W ” means kilowatt.
“ Letter of Credit ” means an irrevocable, non-transferable standby letter of credit issued by a Qualified Bank utilizing a form acceptable to the Party in whose favor such letter of credit is issued. All costs relating to any Letter of Credit shall be for the account of the Party providing that Letter of Credit.
9
“ Maintenance Plan ” means an annual plan for the management, operation and ordinary maintenance of the NECEC Transmission Line, which plan shall include a description of the scope and nature of the planned operating and maintenance programs and planned and preventive maintenance procedures for the NECEC Transmission Line, and the scheduled maintenance and other planned outages of the NECEC Transmission Line, in each case, in accordance with Section 6.3 hereof and the requirements of the PPAs.
“ Market Products ” means, collectively, all products (however entitled and whether existing now or in the future) that (a) are recognized under ISO-NE Rules, (b) derive from the acquisition of transmission service over the NECEC Transmission Line under this Agreement and (c) can be sold for consideration or otherwise have economic value, including electrical energy, electrical capacity and ancillary services, including reserve products (including spinning and non-spinning reserves).
“ Material Adverse Effect ” means, with respect to a Party, a material adverse effect on the ability of such Party to perform any of its obligations under this Agreement.
“ MDPU ” means the Massachusetts Department of Public Utilities.
“ Minimum Average Availability ” means ninety percent (90%) of the Contract Capacity.
“ Municipal Owner Approval Deadline ” means March 31, 2022 (as the same may be extended in accordance with Section 4.1(c) or Section 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Municipal Owner Approvals ” means the Owner Approvals identified in paragraph 10 of Attachment C that are required to construct, own and operate the NECEC Transmission Line.
“ MW ” means megawatt.
“ NECEC Transmission Line ” has the meaning provided in the recitals to this Agreement.
“ NECEC Transmission Line Capacity ” means (a) 1,200 MW or (b) such lesser amount as may be established by the Commissioning of the NECEC Transmission Line, in each case, as measured at the Delivery Point; provided that the amount under clause (b) shall be increased if the capacity is increased after the Commercial Operation Date pursuant to Section 4.4.1(c) , Section 4.4.2(b) or Section 4.4.3(b) .
“ NERC ” means the North American Electric Reliability Corporation, or its successor organization.
“ Net Book Value ” means, at any time, an amount equal to the original cost of construction minus depreciation (using a forty (40)-year depreciation schedule), as calculated in accordance with generally accepted accounting principles.
“ New England Transmission System ” means New England Transmission System, as defined in the ISO-NE Tariff.
10
“ Non-Excused Outage ” means any outage of the NECEC Transmission Line or reduction in the Total Transfer Capability below the NECEC Transmission Line Capacity, except due to an Excused Outage.
“ Non-Excused Outage Payment ” means, with respect to any month during which a Non-Excused Outage occurs, an amount equal to:
(a) the excess, in MW, if any, of (i) the Contract Capacity multiplied by the Minimum Average Availability over (ii) the Contract Capacity multiplied by the average Hourly Availability of the NECEC Transmission Line for such month, multiplied by
(b) $6, multiplied by
(c) the number of hours in such month.
“ OASIS ” means the Open Access Same-Time Information System.
“ OASIS Administrator ” has the meaning provided in Section 10.3(a) .
“ Other Transmission Rights ” means, collectively, any Financial Transmission Rights (or any similar concept), auction revenue rights or other financial or physical transmission rights, in each case, whether existing now or in the future, associated with the NECEC Transmission Line or AC Upgrades.
“ Owner ” has the meaning provided in the preamble to this Agreement.
“ Owner Approvals ” means, collectively, (a) the Construction Authorizations and (b) the ISO-NE Approval, all as set forth in Attachment C .
“ Owner Default ” has the meaning provided in Section 14.3 .
“ Owner Delay ” has the meaning provided in Section 4.4.1 .
“ Owner Indemnified Party ” has the meaning provided in Section 20.1 .
“ Owner Remediation Date ” has the meaning provided in Section 4.4.1(c)(i) .
“ Owner Remediation Period ” has the meaning provided in Section 4.4.1(c)(i) .
“ Owner Termination Payment ” means, (a) if prior to the Commercial Operation Date, liquidated damages in an amount equal to the Proportionate Share multiplied by fifty percent (50%) of all costs prudently incurred by TransÉnergie as of the termination date in connection with the development and construction of the Qu é bec Line or (b) if on or after the Commercial Operation Date, an amount equal to Sixty Million Dollars ($60,000,000). For the avoidance of doubt, the amounts described in the foregoing clause (b) shall be without duplication of any amounts paid by Owner to RFP Sponsors under the RFP Sponsor TSAs in satisfaction of any liabilities to RFP Sponsors under the PPAs.
11
“ Owner’s Construction Progress Report ” has the meaning provided in Section 5.2.3(a) .
“ Owner’s Construction Schedule ” has the meaning provided in Section 5.2.2 .
“ Owner’s Prelimi nary Schedule ” has the meaning provided in Section 5.2.1 .
“ Parties ” and “ Party ” have the meanings provided in the preamble to this Agreement.
“ Person ” means any legal person, including any natural person, domestic or foreign corporation, limited liability company, general or limited partnership, joint venture, association, joint stock company, business trust, estate, trust, enterprise, unincorporated organization, any Governmental Authority or any other legal or commercial entity.
“ Power Cost Reconciliation Tariff ” means a fully reconciling cost recovery tariff mechanism that authorizes the establishment of a distribution charge that fully recovers RFP Sponsors’ net costs under the RFP Sponsor TSAs (including annual remuneration of up to two and three-quarters percent (2.75%)). The rate reconciliation shall be designed in such a way as to limit the build-up of any under or over-recoveries over the course of the year. A reconciliation shall occur at least annually, but may also be reconciled quarterly or monthly, to the extent necessary to eliminate regulatory lag for the recovery of costs or crediting of over-recoveries to customers.
“ PPAs ” has the meaning provided in the recitals to this Agreement.
“ Presidential Permit ” means the permit granted by the U.S. Department of Energy, pursuant to Executive Order 10485 as amended by Executive Order 12038, authorizing the construction, operation, maintenance and connection of facilities for the transmission of electric energy at the international border between the United States and Canada.
“ Project Schedule ” means a schedule setting forth the proposed engineering, procurement, construction and testing milestone schedule for (a) the NECEC Transmission Line based upon the Construction Contracts, (b) the Québec Line and (c) the AC Upgrades and the CCIS Capacity Upgrades based upon such information as can reasonably be obtained by Owner from the AC Upgrade Owners, recognizing that one or more Project Schedules will be completed and delivered before the date on which the AC Upgrades and the CCIS Capacity Upgrades are formally identified under this Agreement.
“ Proportionate Share ” means a fraction with the numerator equal to 110 MW and the denominator equal to 1,200 MW.
“ Proposal Agreements ” means, collectively, this Agreement, the RFP Sponsor TSAs, the Purchaser TSAs and the PPAs.
“ Purchased Power Accounting Authorization ” means authorization for the RFP Sponsors, at the RFP Sponsors’ sole discretion, to take appropriate steps to assure avoidance of a material, negative balance sheet impact on the RFP Sponsors or RFP Sponsors’ direct or indirect parent company, upon appropriate filing with and approval by the MDPU.
12
“ Purchaser ” has the meaning provided in the preamble to this Agreement.
“ Purchaser Default ” has the meaning provided in Section 14.1 .
“ Purchaser Delay ” has the meaning provided in Section 4.4.2(a) .
“ Purchaser Guarantor ” means Hydro-Québec.
“ Purchaser Indemnified Party ” has the meaning provided in Section 20.2 .
“ Purchaser Remediation Date ” has the meaning provided in Section 4.4.2(b)(i) .
“ Purchaser Remediation Period ” has the meaning provided in Section 4.4.2(b)(i) .
“ Purchaser Term ” has the meaning provided in Section 8.1 .
“ Purchaser Termination Payment ” means, (a) if prior to the Commercial Operation Date, an amount equal to the Proportionate Share of all costs prudently incurred by Owner as of the termination date in connection with the development and construction of the NECEC Transmission Line or (b) if on or after the Commercial Operation Date, an amount equal to the Proportionate Share multiplied by the Net Book Value of the NECEC Transmission Line minus the present value, discounted at the Discount Rate, of the Proportionate Share of revenues (if any) to be received by Owner, acting in a commercially reasonable manner, pursuant to contracts (if any) entered into by Owner during the sixty (60) day period immediately following the delivery of the termination notice, from one or more other purchasers or payors over the remainder of the Term for transmission service utilizing the NECEC Transmission Line up to an amount of generation at the Contract Capacity (net of operating costs in respect of such revenues).
“ Purchaser TSA FERC Order ” means an order issued by FERC accepting or approving one or more Purchaser TSAs for filing.
“ Purchaser TSAs ” has the meaning provided in the recitals to this Agreement.
“ Qualified Bank ” means a U.S. commercial bank (or the U.S. branch of a foreign bank) having (a) assets on its most recent balance sheet of at least $10 billion and (b) a long-term credit rating of at least “A-” by S&P or “A3” by Moody’s (or its equivalent).
“ Québec Converter Station Contract Deadline ” means July 30, 2019 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) ), or such later date to which the Parties shall mutually agree in writing.
“ Québec Line ” has the meaning provided in the recitals to this Agreement.
“ Real Power Losses ” means energy consumed by the electrical impedance characteristics of the NECEC Transmission Line.
“ Recovery ” has the meaning provided in Section 20.6 .
13
“ Regulatory Approval ” means the MDPU approval of the RFP Sponsor TSAs , which approval shall include: (1) confirmation that the RFP Sponsor TSAs have been approved under Section 83D and the regulations promulgated thereunder and that all of the terms of such Section 83D and such regulations apply to the RFP Sponsor TSAs; (2) definitive regulatory authorization for the RFP Sponsors to recover all of their costs incurred under and in connection with the RFP Sponsor TSAs for the entire term of the RFP Sponsor TSAs through the implementation of a Power Cost Reconciliation Tariff or other cost recovery or reconciliation mechanisms; (3) definitive regulatory authorization for the RFP Sponsors to recover remuneration of up to two and three-quarters percent (2.75%) of the RFP Sponsors’ annual payments under the RFP Sponsor TSAs for the term of the RFP Sponsor TSAs through the Power Cost Reconciliation Tariff; and (4) approval of any Purchased Power Accounting Authorization requested by the RFP Sponsors in connection with the Regulatory Approval. Such approvals shall be acceptable in form and substance to the RFP Sponsors in their sole discretion and shall not include any conditions or modifications that the RFP Sponsors deem, in their sole discretion, to be unacceptable , and shall be final and not subject to appear or rehearing .
“ Regulatory Approval Delay ” means any delay in the receipt of the Regulatory Approval beyond January 25, 2019.
“ Regulatory Approval Termination Outside Date ” has the meaning provided in Section 3.3.1(a) .
“ RFP Sponsor TSA Critical Milestones ” means the “Critical Milestones” as defined in the applicable RFP Sponsor TSA.
“ RFP Sponsor TSA FERC Order ” means an order issued by FERC accepting or approving one or more RFP Sponsor TSAs for filing.
“ RFP Sponsor TSAs ” has the meaning provided in the recitals to this Agreement.
“ RFP Sponsors ” has the meaning provided in the recitals to this Agreement.
“ Scheduling Rules ” has the meaning provided in Section 7.1.3 .
“ Second Purchaser Term ” has the meaning provided in Section 8.1 .
“ Second Transmission Service Payment ” has the meaning provided in Section 8.1.
“ Section 83D ” means Section 83D of the Energy Diversity Act.
“ Target Date ” has the meaning provided in Section 4.2(a) .
“ Term ” has the meaning provided in Section 3.2 .
“ Third Party Claim ” has the meaning provided in Section 20.3 .
“ Third Party Consent ” means any Consent of a Person other than a Governmental Authority.
14
“ Total Transfer Capability ” means the Total Transfer Capability of the NECEC Transmission Line, as defined in, and established in accordance with, the ISO-NE Tariff and determined by ISO-NE for each hour.
“ TransÉnergie ” has the meaning provided in the recitals to this Agreement.
“ TransÉnergie OATT ” means the Hydro-Québec Open Access Transmission Tariff, as amended or accepted by the Régie de l’énergie from time to time.
“ Transfer ” has the meaning provided in Section 22.1(a) .
“ Transmission Operating Agreement ” means an agreement entered into by and between Owner and ISO-NE for transmission operating services over the NECEC Transmission Line under which operating control (as defined in such agreement) of the NECEC Transmission Line is transferred from Owner to ISO-NE.
“ Transmission Operator ” means ISO-NE acting in its capacity pursuant to the Transmission Operating Agreement.
“ Transmission Percentage ” means a fraction with the numerator equal to the Contract Capacity and the denominator equal to the NECEC Transmission Line Capacity.
“ Transmission Service Payment ” has the meaning provided in Section 8.1 .
“ Unfavorable FERC Decision ” has the meaning provided in Section 2.2(a) .
“ United States ” or “ U.S. ” means the United States of America.
“ U.S. Border ” means the location on or near the international border between the State of Maine and the Province of Québec where the HVDC Line and the Québec Line interconnect.
Section 1.2 Interpretation . In this Agreement, unless the context otherwise requires, the following rules shall apply to the usage of terms:
Section 1.2.1 Singular; Plural; Gender; Corollary Meaning . The singular shall include the plural and vice versa, and any pronoun shall include the corresponding masculine, feminine and neuter forms. If a term is defined as one part of speech (such as a noun), then it shall have a corresponding meaning when used as another part of speech (such as a verb).
Section 1.2.2 Coordinating Conjunctions . The word “or” shall have the inclusive meaning represented by the phrase “and/or.”
Section 1.2.3 Self-Reference . The words “hereof,” “herein,” “hereto” and “hereunder” and words of similar import when used in this Agreement shall, unless otherwise expressly specified, refer to this Agreement as a whole and not to any particular provision of this Agreement.
15
Section 1.2.4 Inclusive References . The words “include,” “includes” and “including” when used in this Agreement shall be deemed to be followed by “without limitation” or “but not limited to,” whether or not they are in fact followed by such words or words of like import.
Section 1.2.5 Incorporation by Reference . Any reference in this Agreement to an “Article,” “Section” or other subdivision or to an “Attachment” or other schedule or attachment shall be references to an article, section or other subdivision of, or to a schedule or attachment to, this Agreement, unless otherwise stated, and all such Articles, Sections and Attachments are incorporated into this Agreement by reference (all of which comprise part of one and the same agreement with equal force and effect). In the event of any conflict or other inconsistency between the main body of this Agreement and any attachment or schedule to this Agreement, the provisions of the main body of this Agreement shall prevail.
Section 1.2.6 Subsequent Acts . Any references in this Agreement to any statute shall be deemed to refer to such statute, as amended or replaced from time to time, including by succession of comparable successor statute, and all rules and regulations promulgated thereunder. In the event any index or publication referenced in this Agreement ceases to be published or a concept defined by reference to any such index or publication ceases to exist, each such reference shall be deemed to be a reference to a successor or alternate index, publication or concept reasonably agreed to by the Parties. Unless specified otherwise, a reference to a given agreement or instrument, and all schedules and attachments thereto, shall be a reference to that agreement or instrument as modified, amended, supplemented and restated, and as in effect from time to time.
Section 1.2.7 Inclusive of Permitted Successors . Unless otherwise expressly stated, references to any Person also include its permitted successors and assigns.
Section 1.2.8 Time Computation . In this Agreement, in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each means “to but excluding.”
Section 1.2.9 Business Days . Whenever this Agreement refers to a number of days, such number shall refer to calendar days unless Business Days are specified. Whenever any action must be taken under this Agreement on or by a day that is not a Business Day, such action may be validly taken on or by the next day that is a Business Day, and in the case of payments (including refunds of payments), no interest shall accrue on the amount due; provided that such payment is made in full on the next day that is a Business Day.
Section 1.2.10 Governmental Approvals . Except as otherwise expressly provided in this Agreement, any Governmental Approval shall be deemed to be received upon issuance, even if such Governmental Approval is subject to appeal or rehearing.
Section 1.2.11 Currency . All references to prices, values or monetary amounts referred to in this Agreement shall be paid in United States currency, unless expressly provided otherwise.
16
REGULATORY FILINGS AND REQUIRED APPROVALS
Section 2.1 MDPU Filing; FERC Filings .
(a) Owner shall use commercially reasonable efforts to cause RFP Sponsors to: (i) file for the Regulatory Approval as soon as practicable following the execution of each RFP Sponsor TSA and (ii) use commercially reasonable efforts to file within sixty (60) days thereafter.
(b) Owner shall file the RFP Sponsor TSAs with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when the RFP Sponsors file for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing with FERC shall include waiver requests for the effective date of the RFP Sponsor TSAs to occur consistent with Section 3.1 thereof, which effective date may be more than one hundred twenty (120) days before the Commercial Operation Date. Owner shall file this Agreement with FERC pursuant to Section 205 of the Federal Power Act and 18 C.F.R. Part 35 as soon as practicable following the date when the RFP Sponsors file for the Regulatory Approval, and in any event within thirty (30) days thereafter. Such filing shall include waiver requests for the Effective Date to occur consistent with Section 3.1 , which Effective Date may be more than one hundred twenty (120) days before the Commercial Operation Date.
(c) The Parties shall respond promptly to any requests for additional information made by FERC in connection with any such filings.
(d) Upon the filing of this Agreement pursuant to Section 2.1(b) , Purchaser and Owner shall support the approval or acceptance of this Agreement by FERC without modification or condition.
Section 2.2 Modifications to FERC Order .
(a) In the event (i) FERC issues an order accepting or approving this Agreement for filing (the “ FERC Order ” ) and (ii) the FERC Order makes any acceptance subject to a hearing or contains modifications or conditions that are unacceptable to a Party, in its sole discretion (an “ Unfavorable FERC Decision ” ), such Party shall deliver a written notice to the other Party specifying the issues, to the extent it is able, set for hearing or the unacceptable modifications or conditions, which notice shall be delivered within five (5) Business Days following the issuance of the Unfavorable FERC Decision.
(b) In the event of an Unfavorable FERC Decision, the Parties may agree upon amendments to this Agreement (each, a “ FERC Amendment ” ) that achieve, as nearly as practicable, the commercial intent of this Agreement as of the Execution Date in a manner consistent with the Unfavorable FERC Decision. Any such amendment shall be subject to applicable regulatory approvals. As soon as practicable after any FERC Amendment(s) have been executed and delivered by the Parties, Owner shall file such FERC Amendment(s) with FERC.
17
(c) In the event of an Unfavorable FERC Decision, each Party shall retain the right to request a rehearing or reconsideration of the FERC Order regardless of any negotiations that have occurred or are occurring pursuant to clause (b) above; provided , however , that, in the event the Parties execute a FERC Amendment after any one or both of the Parties has filed for rehearing or reconsideration, any such rehearing or reconsideration request shall be withdrawn no later than five (5) Business Days after FERC issues an order accepting or approving the FERC Amendment for filing, if such rehearing or reconsideration request is inconsistent with the terms and conditions of this Agreement, as amended. Unless otherwise agreed in writing by the Parties, a filing by any Party of a request for rehearing or reconsideration of the FERC Order shall not toll or otherwise modify any date or time period set forth in this Agreement, including, for the avoidance of doubt, the date upon which the Construction Phase shall commence.
Section 2.3 [ Intentionally Omitted ].
(a) In addition to their obligations under Section 2.1 , each Party shall, and each Party shall use commercially reasonable efforts to cause its Affiliates to, (i) cooperate with each other to prepare, file and effect any applications, notices, petitions, reports or other filings or documentation required under Applicable Law or otherwise necessary, proper or advisable to consummate the transactions contemplated by this Agreement, (ii) provide updates to the other Party on material developments in connection with any such filings or documentation, (iii) provide any non-privileged information reasonably requested by the other Party in connection with any such filings or documentation, (iv) cooperate with the other Party to use commercially reasonable efforts to obtain all Governmental Approvals and Third Party Consents that are necessary, proper or advisable to consummate the transactions contemplated by this Agreement, including the FERC Authorization (without unacceptable modifications or conditions, except as permitted by this Agreement), the Municipal Owner Approvals, the other Owner Approvals and the Canadian Approvals, and (v) provide any support reasonably necessary and requested by the AC Upgrade Owners to obtain the AC Upgrade Approvals.
(b) Each Party shall consult with the other Party with respect to all characterizations of information relating to such other Party, its Affiliates or the transactions contemplated by this Agreement that are proposed to appear in any filings or documentation contemplated by Section 2.1 or Section 2.4(a) . Each Party shall promptly provide comments, if any, to the other Party on any such characterizations of information. Each Party shall make a good faith effort to take into account any comments made by the other Party.
(c) Each Party shall use reasonable efforts to implement the provisions of, and to administer, this Agreement in accordance with the intent of the Parties to minimize all taxes, including delivery of the United States Internal Revenue Service Form W-9 and sales tax exemptions (if applicable), so long as neither Party is materially adversely affected by such efforts.
18
Section 2.5 No Inconsistent Action . Except as provided in Section 17.2 and Article XIX , from and after the Execution Date, the Parties shall not undertake, and shall use commercially reasonable efforts to cause their Affiliates not to undertake, any action before FERC, ISO-NE or any other Governmental Authority that is contrary to the Party’s obligations under this Agreement, including, for the avoidance of doubt, Section 2.1(c ) and Section 7.1.4 , or support any such contrary action by any Affiliate.
EFFECTIVE DATE; TERM
Section 3.1 Effective Date . Article I , Article II , this Section 3.1 , Section 3.3.1 , Section 3.3.2 , Article XVII , Article XVIII , Article XIX , Article XXII and Article XXIII shall become effective and enforceable to the extent permitted by Applicable Law upon the Execution Date. The remaining provisions of this Agreement shall become effective and enforceable to the extent permitted by Applicable Law upon the effective date set forth in the FERC Order (the “ Effective Date ”). Notwithstanding the first sentence of this Section 3.1 , this Agreement will become effective as a FERC rate schedule upon the effective date set forth in the FERC Order. Notwithstanding any other provision of this Agreement, Purchaser shall have no obligation to make any payment under this Agreement prior to receipt of the Regulatory Approval and the FERC Authorization.
Section 3.2 Term . The term of this Agreement shall commence on the Execution Date and shall expire on the fortieth (40th) anniversary of the Commercial Operation Date, unless earlier terminated (in whole or in part) or extended in accordance with the terms hereof (the “ Term ”).
Section 3.3 Termination Rights . This Agreement may be terminated in accordance with the ensuing provisions in this Article III , subject to any required regulatory reviews, approvals or acceptances, as applicable. Neither Party shall oppose any termination of this Agreement made in accordance with this Article III before FERC or any other Governmental Authority; provided , however , that the foregoing shall not prohibit any Party from challenging or otherwise Disputing whether or not any such termination is permitted by this Agreement.
Section 3.3.1 Failure to Obtain Satisfactory Regulatory Approval and FERC Authorization .
(a) This Agreement may be terminated by any Party in the event (i) it determines that the Regulatory Approval or the FERC Authorization contain terms and conditions that are, in its sole discretion, unacceptable to such Party, (ii) the Regulatory Approval is denied or is not received by January 25, 2020 (such date, the “ Regulatory Approval Termination Outside Date ”), (iii) the Regulatory Approval of the PPAs (as defined in the PPAs) is not received within the time frame set forth therein and the PPAs are terminated, (iv) the FERC Authorization is denied or is not received by January 25, 2020, ( v) in the event of a capacity shortfall as provided in Section 4.4.1(c)(ii) , Section 4.4.2(b)(ii) or Section 4.4.3(b)(ii) or (vi) any RFP Sponsor TSA is terminated pursuant to Section 3.3.1 of such RFP Sponsor TSA; provided that the termination right under this clause (a) is exercised by a Party within thirty (30) days after the effective date of the termination of the RFP Sponsor TSA.
19
(b) Upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.2 Mutual Agreement . This Agreement may be terminated at any time upon written agreement of the Parties.
Section 3.3.3 Failure to Obtain Certain Approvals .
(a) Unless otherwise agreed in writing by the Parties, this Agreement shall terminate immediately without further action of the Parties in the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline, any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline, or any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof).
(b) In the event any of the Owner Approvals (other than the Municipal Owner Approvals) has not been obtained by the Approval Deadline or if any of the Municipal Owner Approvals has not been obtained by the Municipal Owner Approval Deadline (each of the foregoing as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof), and this Agreement has been terminated pursuant to clause (a) above, Owner’s payment obligations shall be as set forth in Section 3.3.3(b) of the Purchaser TSAs, and Owner shall have no separate or additional payment obligation under this Agreement.
(c) In the event any of the Canadian Approvals has not been obtained by the Canadian Approval Deadline (as extended, if applicable, pursuant to Section 4.1(c) or Section 4.1(e) hereof), and the RFP Sponsor TSAs have been terminated pursuant to Section 3.3.3(a) of the RFP Sponsor TSAs, Purchaser’s payment obligations shall be as set forth in Section 3.3.3(c) of the Purchaser TSAs, and Purchaser shall have no separate or additional payment obligation under this Agreement.
(d) Except as otherwise provided in clause (b) or (c) above, upon termination of this Agreement pursuant to clause (a) above, neither Party shall have any liability to the other Party under this Agreement.
Section 3.3.4 Purchaser Default .
(a) Owner shall have the right to terminate this Agreement in accordance with Section 14.4(a) .
(c) Upon the exercise by Owner of its termination rights pursuant to clause (a) above, Owner shall have the right to recover from Purchaser, and Purchaser shall pay to Owner, the Purchaser Termination Payment in accordance with Section 14.4(a) .
20
(d) The exercise by Owner of its termination rights pursuant to clause (a) above shall constitute a waiver by Owner of all other remedies or damages that may be available at law or in equity against Purchaser; provided , however , that, except as provided in Section 14.7 of the Purchaser TSAs, Owner shall not waive its right to, and Purchaser shall remain liable for, the Purchaser Termination Payment, any unpaid amounts owed by Purchaser pursuant to Section 8.1 , any amounts owed by Purchaser to Owner under Section 3.4 or Section 4.4.2 , and any indemnification obligations of Purchaser to Owner under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover the Purchaser Termination Payment or such indemnified or other amounts.
(a) Purchaser shall have the right to terminate this Agreement in accordance with Section 14.6(a) or Section 14.7(e)(i) .
(b) Upon the exercise by Purchaser of its termination rights pursuant to clause (a) above, subject to Section 14.7 of the Purchaser TSAs, Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, the Owner Termination Payment in accordance with Section 14.6(a) .
(c) Subject to Section 14.7 of the Purchaser TSAs, the exercise by Purchaser of its termination rights pursuant to clause (a) above shall constitute a waiver by Purchaser of all other remedies or damages that may be available at law or in equity against Owner; provided , however , that, Purchaser shall not waive any right to, and Owner shall remain liable for, the Owner Termination Payment, any amounts owed by Owner to Purchaser under Section 3.4 hereof or Section 14.7(f) of the Purchaser TSAs, any accrued but unpaid amounts under Section 4.4.1 or Section 7.3.1 hereof or any express modification of Purchaser’s payment obligations that have accrued under this Agreement before or as of such termination, and any indemnification obligations of Owner to Purchaser under this Agreement, together with any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover such damages or such indemnified or other amounts owed to Purchaser by Owner.
Section 3.3.6 Force Majeure . This Agreement may be terminated in accordance with Section 15.1(c) .
Section 3.3.7 Extended Excused Outage . This Agreement may be terminated in accordance with Section 7.2(c) .
21
Section 3.4 Termination Payments .
(a) Within sixty (60) days following the termination of this Agreement pursuant to Section 3.3 , Owner shall deliver to Purchaser an invoice that sets forth Owner’s good faith estimate of the amounts owed to Owner by Purchaser under Section 3.3 , or Purchaser shall deliver to Owner an invoice that sets forth Purchaser’s good faith estimate of the amounts owed to Purchaser by Owner under Section 3.3 . The recipient of such invoice shall pay the amounts set forth in such invoice within thirty (30) days following its receipt of such invoice. Either Party may deduct and setoff payment of such amounts against any accrued but unpaid payment obligation of the payee to such Party hereunder. Upon the other Party’s request, the invoicing Party shall provide documentation describing the basis for the amounts invoiced in reasonable detail.
(b) The Parties acknowledge and agree that the payment of amounts by the defaulting Party to the non-defaulting Party pursuant to Section 3.3 or this Section 3.4 is an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for the termination of this Agreement are difficult or impossible to determine and that the damages calculated under Section 3.3 or this Section 3.4 constitute a reasonable approximation of the harm or loss to the non-defaulting Party as a result thereof.
Section 3.5 Effect of Termination . Except as provided in Section 3.3 and in Section 23.12 for the survival of provisions, upon expiration or other termination of this Agreement pursuant to its terms, each of the Parties shall be released from all of its obligations under this Agreement, other than any accrued but unpaid payment obligation. Notwithstanding the foregoing sentence, upon such expiration or termination of this Agreement, either Party shall have the right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by such Party to recover any amounts owed to such Party by the other Party hereunder or to secure the release of any security or performance assurance provided by or on behalf of such Party after the later to occur of the end of the Term or the date on which any accrued but unpaid payment obligation of such Party to the other Party hereunder shall have been fully, finally, and indefeasibly satisfied.
COMMERCIAL OPERATION
Section 4.1 Critical Milestones .
(a) Subject to Section 4.1(c) , Section 4.1(d) , and Section 4.1(e) , commencing on the Effective Date, Owner shall develop the NECEC Transmission Line in order to achieve the milestones set forth in clauses (i), (iii)-(v), and (vii) below, and Purchaser shall cause its Affiliates to develop the Québec Line in order to achieve the milestones set forth in clauses (ii), (vi), and (vii) below (each clause, a “ Critical Milestone ”) on or before the dates set forth in this Section 4.1(a) :
22
(i) Receipt of all Owner Approvals (other than the Municipal Owner Approvals) and AC Upgrade Approvals in final form by the Approval Deadline;
(ii) Receipt of all Canadian Approvals in final form by the Canadian Approval Deadline;
(iii) Receipt of the Municipal Owner Approvals in final form by the Municipal Owner Approval Deadline;
(iv) Closing of any financing required for the construction and operation of the NECEC Transmission Line or other demonstration to Purchaser’s reasonable satisfaction of the financial capability of Owner to construct the NECEC Transmission Line, including, as applicable, Owner’s financial obligations with respect to interconnection of the NECEC Transmission Line and construction of the AC Upgrades and the CCIS Capacity Upgrades by the Financing Deadline;
(v) Execution by Owner and a contractor of an agreement for the engineering, procurement, and construction of the converter station at the southern end of the HVDC Line and payment by Owner to the contractor of an initial payment of at least 5% of the total price of the agreement, both by the Converter Station Contract Deadline;
(vi) Execution by HQE of a contract that provides for the engineering, procurement, or construction of the converter station associated with the Québec Line by the Québec Converter Station Contract Deadline; and
(vii) Achievement of the Commercial Operation Date by the Target Date.
(b) Except for the achievement of the Commercial Operation Date, which shall be governed by the provisions of Section 4.2 , the Party responsible for achieving a Critical Milestone shall provide the other Party with written notice of the achievement of such Critical Milestone as set forth in Attachment B within seven (7) days after that achievement, which notice shall include information demonstrating with reasonable specificity that such Critical Milestone has been achieved. Each Party acknowledges that: (i) the Party receiving such notice does so solely to monitor progress toward the Commercial Operation Date; (ii) Purchaser shall not have any responsibility or liability for the development, construction, operation, and maintenance of the NECEC Transmission Line; and (iii) Owner shall not have any responsibility or liability for the development, construction, operation, and maintenance of the Québec Line.
(c) Upon any extension of the RFP Sponsor TSA Critical Milestones not yet achieved under the RFP Sponsor TSAs, the corresponding dates for the Critical Milestones not yet achieved hereunder shall be extended accordingly; provided that Owner shall not agree to any extension of the RFP Sponsor TSA Critical Milestones beyond what is permitted under the RFP Sponsor TSAs or this Agreement without the prior written consent of Purchaser, such consent not to be unreasonably withheld, conditioned or delayed.
23
(d) To the extent a Force Majeure event pursuant to Section 15.1 has occurred that prevents Owner or Purchaser from achieving the Critical Milestone dates for execution of the contract to purchase the converter station for the NECEC Transmission Line ( Section 4.1(a)(v) ), execution of the contract to purchaser the converter station for the Québec Line ( Section 4.1(a)(vi) ), or the Commercial Operation Date ( Section 4.1(a)(vii) ) by the applicable Critical Milestone date, the Critical Milestone date(s) impacted by such Force Majeure event shall be extended for the duration of the Force Majeure event, but under no circumstances shall extensions of those Critical Milestone dates exceed twelve (12) months beyond the applicable Critical Milestone date provided that (i) Owner shall not have the right to declare a Force Majeure event related to the Critical Milestone for Owner Approvals ( Section 4.1(a)(i) ), Municipal Owner Approvals ( Section 4.1(a)(iii) ), or the financing Critical Milestones ( Section 4.1(a)(iv) ); and (ii) Purchaser shall not have the right to declare a Force Majeure event related to the Critical Milestone for Canadian Approvals ( Section 4.1(a)(ii) ).
(e) In the event of a Regulatory Approval Delay, the date for each Critical Milestone not yet achieved shall be extended for the duration of the delay. The number of days of extension pursuant to the six-month extensions available under Section 4.1(c) shall be reduced by one day for each day of Regulatory Approval Delay pursuant to this subsection (e) up to a maximum reduction of 365 days. For purposes of illustration, Regulatory Approval Delay of two hundred ten (210) days would allow the Parties two six-month extensions and one extension of five months .
Section 4.2 Commercial Operation Date .
(a) The “ Target Date ” for Commercial Operation is December 13, 2022 (as the same may be extended in accordance with Section 4.1(c) , 4.1(d) or 4.1(e) ) or such later date to which the Parties shall mutually agree in writing. Absent written agreement by the Parties, the Target Date may not be extended beyond December 13, 2024 unless such extension is due to Regulatory Approval Delay or an event of Force Majeure as set forth in Sections 4.1(d) and 4.1(e) . The provisions of Sections 4.1(c) , 4.1(d) and 4.1(e) and all other provisions of this Agreement are subordinate to this Section 4.2(a) and the aforesaid Section 4.1 provisions and such other provisions shall be construed in a manner that is consistent with this Section 4.2(a) . Owner shall provide a written non-binding notice to Purchaser no later than sixty (60) days before the date Owner reasonably expects the Commercial Operation Date to occur.
(b) At the request of Owner made in writing, Purchaser shall, and shall use commercially reasonable efforts to cause its Affiliates to, cooperate with Owner, TransÉnergie and ISO-NE to support the Commissioning of the HVDC Transmission Project.
24
(c) As soon as practicable after Owner is of the opinion that the conditions to Commercial Operation, as set forth in Section 4.3 , have been satisfied, or such conditions have been waived in writing by the Parties (except in the case of Section 4.3(b) , Section 4.3(e) , Section 4.3(g) , Section 4.3(h) and Section 4.3(i) , which conditions may be waived in writing by Purchaser in its sole discretion), Owner shall deliver a written notice to Purchaser specifying the date upon which Commercial Operation shall commence (the “ COD Notice ” ), which commencement date shall occur no earlier than ten (10) Business Days after the receipt by Purchaser of the COD Notice or on such other date as agreed upon by the Parties in writing (such date, the “ Commercial Operation Date ” ).
(d) Within five (5) Business Days after the receipt by Purchaser of the COD Notice, Purchaser shall deliver a certificate to Owner either (i) confirming that the conditions set forth in Section 4.3 have been satisfied or duly waived and that Commercial Operation may commence on the Commercial Operation Date or (ii) objecting with reasonable detail to the COD Notice. Purchaser’s failure to respond in writing to a COD Notice within such five (5) Business Day period shall be deemed to be a confirmation that the conditions set forth in Section 4.3 have been satisfied or duly waived. Any Dispute over whether or not the conditions set forth in Section 4.3 have been satisfied or duly waived shall be resolved in accordance with Article XVII .
Section 4.3 Conditions Precedent to Commercial Operation . The items set forth in clauses (a) through (i) below shall be conditions precedent to the Commercial Operation of the NECEC Transmission Line:
(a) Completion of the Commissioning of the HVDC Transmission Project by Owner (in coordination with ISO-NE) and TransÉnergie;
(b) The NECEC Transmission Line has been constructed in accordance with Attachment A and Good Utility Practice, and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.1(c) and Section 4.4.3(b) ;
(c) Completion of the AC Upgrades and the CCIS Capacity Upgrades;
(d) The Interconnection Agreements shall be in full force and effect;
(e) The Transmission Operating Agreement shall be in full force and effect, and ISO-NE shall have informed Owner that ISO-NE (i) is prepared to assume operational control over the NECEC Transmission Line, as defined in, and in accordance with, the Transmission Operating Agreement and (ii) will assume such operational control as of the Commercial Operation Date;
(f) The Québec Line has been constructed in accordance with Attachment A , and is capable of operating at the Design Capability, except as otherwise permitted pursuant to Section 4.4.2(b) and Section 4.4.3(b) ;
(g) Receipt by Purchaser of copies of certificates evidencing all outstanding insurance required or otherwise obtained under Section 5.4 ;
25
(h) Receipt by Purchaser of an opinion of legal counsel, reasonably satisfactory to Purchaser, that all Governmental Approvals and Third Party Consents required to own and operate the NECEC Transmission Line have been obtained;
(i) Each of the RFP Sponsors have confirmed (or have been deemed to have confirmed) that the conditions set forth in Section 4.3 of the applicable RFP Sponsor TSA has been satisfied or duly waived; and
(j) The PPAs are in full force and effect and binding against the parties thereto (except where any PPA has been terminated by mutual agreement of the parties to such PPA).
Section 4.4 Delay in Commercial Operation; Reduced Level of Operation .
Section 4.4.1 Owner Delay . If, other than solely as a result of a Purchaser Delay, Force Majeure, or Concurrent Delay, any conditions set forth in Section 4.3 shall not have been satisfied or duly waived by the Target Date (such delay, an “ Owner Delay ”):
(a) Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, for each day (or part thereof) following the Target Date during which the Owner Delay is continuing and, but for such Owner Delay, Purchaser would then be capable of delivering the energy and providing the environmental attributes to potential buyers via the NECEC Transmission Line, an amount equal to Seventy-Five Dollars ($75) per MW of Contract Capacity for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Purchaser terminates this Agreement pursuant to Section 14.6 and (z) the date that is twelve (12) months after the Target Date.
(b) [ Intentionally Omitted ].
(c) Owner’s Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the Québec Line is capable of operating at or above 1,200 MW and (A) the NECEC Transmission Line is capable of operating below 1,200 MW and at or above 1,040 MW, or (B) the NECEC Transmission Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and the RFP Sponsors provide written consent to begin transmission service under the RFP Sponsor TSAs, Owner may elect to begin transmission service hereunder, and Owner shall have twenty-four (24) months from the Commercial Operation Date to attempt to increase such operating capacity to 1,200 MW (the “ Owner Remediation Period ”); provided that upon any extension of the Remediation Period (as defined in the RFP Sponsor TSAs) under the RFP Sponsor TSAs, the Owner Remediation Period hereunder shall be extended accordingly. Owner shall pay to Purchaser, for each day (or part thereof) following the Commercial Operation Date and until the end of the Owner Remediation Period, or such earlier date designated by Owner in writing to Purchaser (the “ Owner Remediation Date ”), an amount equal to Seventy Five Dollars ($75) per MW per day multiplied by the difference
26
between 1,200 MW and the operating capacity of the NECEC Transmission Line as of the Commercial Operation Date (but not to exceed 110 MW). Such payments shall be made on a monthly basis pursuant to invoices delivered by Purchaser to Owner. Owner’s payments shall be based on the actual operating capacity of the NECEC Transmission Line, as is stated in Section 8.1 .
(ii) If, on the earlier of the Owner Remediation Date and the end of the Owner Remediation Period, (A) the NECEC Transmission Line is not capable of operating at or above 1,090 MW, either Party may terminate this Agreement without further recourse by either Party against the other, or (B) the operating capacity of the NECEC Transmission Line is more than 1,090 MW but less than 1,200 MW, this Agreement shall continue in effect at the actual operating capacity of the NECEC Transmission Line and the Contract Capacity shall be deemed modified accordingly .
(d) The Parties acknowledge and agree that the payment of amounts by Owner to Purchaser under clauses (a) and (c) above are an appropriate remedy and that any such modification or payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for an Owner Delay or a reduction in operating capacity, as described in clause (c), are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Purchaser as a result thereof.
(e) The rights provided in Section 3.3.5 and this Section 4.4.1 shall collectively be the sole and exclusive remedies of Purchaser with respect to an Owner Delay or a reduction in operating capacity, as described in clause (c). The foregoing sentence shall not be construed in any way to limit (i) Purchaser’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement, or (ii) Purchaser’s rights to recover payment of any indemnification obligations of Owner to Purchaser pursuant to Section 20.2 .
Section 4.4.2 Purchaser Delays .
(a) Subject to any extension of any Critical Milestone date pursuant to Section 4.1(c) , Section 4.1(d) or Section 4.1(e) , if, except in the event of Force Majeure, on the Target Date, solely as a result of delays in completing the Québec Line or operational difficulties with the Québec Line (a “ Purchaser Delay ” ), the Commercial Operation Date is delayed, for each day (or part thereof) during which the Purchaser Delay is continuing, Purchaser will pay to Owner an amount equal to One Hundred Dollars ($100) per MW of Contract Capacity for the period commencing on the Target Date and ending on the earliest of (x) the Commercial Operation Date, (y) the date on which Owner terminates this Agreement pursuant to Section 14.4 and (z) twelve (12) months after the Target Date.
27
(b) Purchaser’s Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date, the NECEC Transmission Line is capable of operating at or above 1,200 MW and (A) the Québec Line is capable of operating below 1,200 MW and at or above 1,040 MW, or (B) the Québec Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and the RFP Sponsors provide written consent to begin transmission service under the RFP Sponsor TSAs, Owner may elect to begin transmission service hereunder, and Purchaser shall have twenty-four (24) months from the Commercial Operation Date to attempt to increase such operating capacity to 1,200 MW (the “ Purchaser Remediation Period ”); provided that upon any extension of the Remediation Period (as defined in the RFP Sponsor TSAs) under the RFP Sponsor TSAs, the Purchaser Remediation Period hereunder shall be extended accordingly. Purchaser shall pay to Owner, for each day (or part thereof) following the Commercial Operation Date and until the end of the Purchaser Remediation Period, or such earlier date designated by Purchaser in writing to Owner (the “ Purchaser Remediation Date ”), an amount equal to One Hundred Dollars ($100) per MW per day multiplied by the difference between 1,200 MW and the operating capacity of the Québec Line as of the Commercial Operation Date (but not to exceed 110 MW). Such payments shall be made on a monthly basis pursuant to invoices delivered by Owner to Purchaser.
(ii) If, on the earlier of the Purchaser Remediation Date and the end of the Purchaser Remediation Period, (A) the Québec Line is not capable of operating at or above 1,090 MW and Purchaser fails to pay the Transmission Service Payment on a monthly basis without downward adjustment to reflect such reduced capacity, either Party may terminate this Agreement without further recourse by either Party against the other, or (B) the operating capacity of the Québec Line is more than 1,090 MW but less than 1,200 MW, this Agreement shall continue in effect at the actual operating capacity of the Québec Line, the Contract Capacity shall be deemed modified accordingly and Purchaser shall pay the Transmission Service Payment on a monthly basis without downward adjustment to reflect such reduced capacity.
(c) The Parties acknowledge and agree that the payment of amounts by Purchaser to Owner under clauses (a) and (b) above are an appropriate remedy and that any such payment does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Purchaser Delay or a reduction in operating capacity, as described in clause (b), are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Owner as a result thereof.
(d) The rights provided in Section 3.3.4 and this Section 4.4.2 shall collectively be the sole and exclusive remedies of Owner with respect to a Purchaser Delay or a reduction in operating capacity, as described in clause (b). The foregoing sentence shall not be construed in any way to limit (i) Owner’s rights to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Purchaser under this Agreement, or (ii) Owner’s rights to recover payment of any indemnification obligations of Purchaser to Owner pursuant to Section 20.1 .
28
Section 4.4.3 Concurrent Delays .
(a) In the event of a concurrent Purchaser Delay and Owner Delay (a “ Concurrent Delay ”), neither Party shall owe the other the payments set forth in Sections 4.4.1(a) and 4.4.2(a) .
(b) Concurrent Design Capacity Shortfall .
(i) In the event and to the extent that, as of the Commercial Operation Date:
(A) (1) the NECEC Transmission Line is capable of operating below 1,200 MW and at or above 1,040 MW, or (2) the NECEC Transmission Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and the RFP Sponsors provide written consent to begin transmission service under the RFP Sponsor TSAs; and
(B) (1) the Québec Line is capable of operating below 1,200 MW and at or above 1,040 MW, or (2) the NECEC Transmission Line is capable of operating at less than 1,040 MW and despite such condition Owner requests and the RFP Sponsors provide written consent to begin transmission service under the RFP Sponsor TSAs;
then Owner may elect to begin transmission service hereunder, and each Party shall have twenty-four (24) months from the Commercial Operation Date (the “ Concurrent Remediation Period ”), or such earlier date designated by the Parties in writing (the “ Concurrent Remediation Date ”) to attempt to increase the operating capacities of their respective lines to 1,200 MW.
(ii) If, on the earlier of the Concurrent Remediation Date and the end of the Concurrent Remediation Period, (A) (x) Owner is unable to increase the operating capacity of the NECEC Transmission Line to more than 1,090 MW or in the event Owner elects not to cure such reduction in operating capacity or (y) Purchaser is unable to increase the operating capacity of the Québec Line to more than 1,090 MW or in the event Purchaser elects not to cure such reduction in operating capacity and Purchaser fails to pay the Transmission Service Payment on a monthly basis without downward adjustment to reflect such reduced capacity, then either Party may terminate this Agreement on written notice without further recourse by either Party against the other or (B) the operating capacity of the NECEC Transmission Line is more than 1,090 MW but less than 1,200 MW or the operating capacity of the Québec Line is more than 1,090 MW but less than 1,200 MW, this Agreement shall continue in effect at the lower of the capacity of the NECEC Transmission Line and the Québec Line, and the Contract Capacity shall be deemed modified accordingly.
29
GENERAL RIGHTS AND RESPONSIBILITIES OF THE PARTIES
Section 5.1 Responsibilities of the Parties .
Section 5.1.1 Construction Phase .
(a) During the Construction Phase, Owner shall (i) exercise Good Utility Practice to complete, or cause the completion of, all tasks required to construct the NECEC Transmission Line, interconnect at least 1,200 MW of capacity with ISO-NE in compliance with the Capacity Capability Interconnection Standard, and achieve Commercial Operation by the Target Date, in each case, in accordance with the Design Capability and in a manner consistent with Attachment A and (ii) use commercially reasonable efforts (A) to obtain all of the Construction Authorizations (other than the Municipal Owner Approvals) by the Approval Deadline and to obtain the Municipal Owner Approvals by the Municipal Owner Approval Deadline, (B) to obtain, in consultation with Purchaser, the ISO-NE Approval by the Approval Deadline and (C) to cause Owner’s Affiliates that are AC Upgrade Owners to obtain any AC Upgrade Approvals for which such Affiliates are responsible by the Approval Deadline and to assist other AC Upgrade Owners in obtaining their respective AC Upgrade Approvals by the Approval Deadline
(b) Owner will use commercially reasonable efforts to enter into, within a commercially reasonable timeframe, one or more Construction Contracts. Owner will make a copy of any such contract available to Purchaser subject to such redactions as Owner or the contracting party deem necessary to protect confidential information.
(d) During the Construction Phase, Purchaser shall take commercially reasonable steps to cause its Affiliate, TransÉnergie, to exercise Good Utility Practice to complete, or cause the completion, of all tasks required to construct the Québec Line in accordance with the applicable design, as set forth in Attachment A , prior to the Target Date and to cooperate with Owner to enable the achievement of Commercial Operation by the Target Date, and Purchaser shall cause TransÉnergie to use commercially reasonable efforts to obtain the Canadian Approvals by the Canadian Approval Deadline.
Section 5.2 Schedules and Reports .
Section 5.2.1 Owner’s Preliminary Schedule . Attached hereto as Attachment E is Owner’s Project Schedule (the “ Owner’s Preliminary Schedule ”). At the request of Purchaser, Owner shall make the personnel responsible for preparing the Owner’s Preliminary Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Preliminary Schedule with Purchaser.
30
Section 5.2.2 Owner’s Construction Schedule . Within ten (10) days after the end of each calendar quarter and sooner if a material change occurs, commencing at least ninety (90) days prior to the commencement of construction , Owner shall prepare and submit to Purchaser for review an update of the Owner’s Preliminary Schedule (such updated schedule as established herein, the “ Owner’s Construction Schedule ”). At the request of Purchaser, Owner shall make the personnel responsible for preparing the Owner’s Construction Schedule available during normal business hours and upon reasonable advance notice to discuss the Owner’s Construction Schedule with Purchaser.
Section 5.2.3 Owner’s Progress Reports .
(a) Promptly following the Execution Date, Owner shall deliver to Purchaser copies of all applications that have been submitted by Owner with respect to any Owner Approvals, as well as all material correspondence and submittals relating to such Owner Approvals. Within ten (10) days after the end of each calendar quarter, commencing at receipt of the Regulatory Approval, Owner shall prepare and submit to Purchaser for review a progress report for informational purposes that sets forth in reasonable detail the current status of the milestones set forth in the Owner’s Construction Schedule, including any changes in the expected timelines and the status of all Owner Approvals, and including copies of any Owner Approval applications, material correspondence and submittals relating to Owner Approvals, and any issued Owner Approvals (the “ Owner’s Construction Progress Report ”). Without limitation of the foregoing, Owner shall include in such reports relevant information relating to: (i) Owner’s efforts to mitigate the impacts of the NECEC Transmission Line on natural resources, environmentally sensitive areas, habitats, and wildlife species, and cultural and historic resources; (ii) Owner’s efforts to comply with applicable noise ordinances; (iii) Owner’s communication and community outreach efforts and plans with respect to the construction of the NECEC Transmission Line, including with stakeholders in Massachusetts; and (iv) Owner’s analysis of, and any material developments related to, the Municipal Owner Approvals (or any applications to the Maine Public Utilities Commission to exempt Owner from the requirement to obtain any Municipal Owner Approval). In delivering the Owner’s Construction Progress Report, Owner shall be deemed to certify that the list of required Municipal Owner Approvals identified in paragraph 10 of Attachment C is accurate and complete as of the date of delivery of the Owner’s Construction Progress Report except as supplemented in such report. At the request of Purchaser, Owner shall, or shall cause each contractor to, provide Purchaser with access to, and copies of, all reasonably requested documentation concerning such Owner’s Construction Progress Report.
(b) Owner shall, or shall cause the principal contractor to, notify Purchaser promptly, but in no event later than ten (10) days, after Owner, or such contractor, becomes aware that the Commercial Operation of the NECEC Transmission Line is not reasonably likely to occur by the Target Date.
31
Section 5.3 Québec Line Reports; Joint Development Agreement
. Purchaser agrees to cooperate with and support Owner in connection with the negotiation and execution of a joint development agreement between TransÉnergie and Owner relating to the Owner Approvals, the Canadian Approvals and construction and design matters relating to the Québec Line and the NECEC Transmission Line (such agreement, the “ Joint Development Agreement ”). Until the execution of the Joint Development Agreement, Purchaser shall promptly provide to Owner all material information received from TransÉnergie with respect to progress on the construction of the Québec Line, including information related to the Canadian Approvals.
Section 5.4 Insurance and Events of Loss . Owner shall obtain and maintain with reputable insurers authorized to operate in the scope of the Agreement insurance of the type as set forth in Attachment F . Owner shall provide Purchaser with copies of certificates of all outstanding insurance obtained hereunder promptly after the receipt thereof by Owner. Owner shall notify Purchaser as soon as reasonably possible if and whenever an event of loss occurs. Without limitation of any obligations Owner may have under Section 15.1 hereof, in the event of damage to or loss of all or part of the NECEC Transmission Line, Owner shall exercise prompt, diligent commercially reasonable efforts to effectuate, in accordance with Good Utility Practice, such repairs and replacements as are necessary or desirable to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss, including, for the avoidance of doubt, the application to such repairs or replacements of any potential or actual proceeds realized in connection with such damage or loss under any available or applicable insurance policies (subject to insurance contract/policy terms and conditions of coverage) maintained pursuant to this Section 5.4 . Subject to Owner’s compliance, in all material respects, with this Section 5.4 , Section 6.3 and all other material terms and conditions with respect to the operation and maintenance of the NECEC Transmission Line, in the event that the costs to restore the NECEC Transmission Line to its operating condition immediately prior to such damage or loss exceed the available insurance proceeds by more than the greater of (a) an amount equal to three percent (3%) of the Net Book Value of the NECEC Transmission Line and (b) Thirty Million Dollars ($30,000,000), the Parties will negotiate in good faith an appropriate allocation of financial responsibility for such excess costs. In the event that the Parties do not agree on the allocation of financial responsibility, Purchaser shall be entitled to terminate this Agreement, upon thirty (30) days’ written notice to Owner, without liability to Owner; provided that, if within the thirty (30) day period following receipt of such notice, Owner agrees to assume that portion of the allocation of financial responsibility to which Purchaser objected, then the termination notice shall be deemed revoked and this Agreement shall not be terminated.
Section 5.5 Compliance with Laws . At all times during the Term, the Parties shall comply with all Applicable Laws (including ISO-NE Rules to the extent applicable) and relevant Governmental Approvals and Third Party Consents.
Section 5.6 Third Party Contracts . At all times during the Term, Owner shall, in a commercially reasonable manner, (a) satisfy its obligations under all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades and (b) administer all third-party contracts entered into in connection with the NECEC Transmission Line, the AC Upgrades or CCIS Capacity Upgrades.
32
Section 5.7 Purchaser’s Losses . Neither Purchaser nor its Affiliates shall be entitled to recover from Owner any losses, damages, costs or expenses related to the Québec Line or arising under the TransÉnergie OATT, except to the extent included in (a) an Owner Termination Payment, or (b) any damages paid pursuant to Section 4.4.1(a) or Section 4.4.1(c) .
Section 5.8 Continuity of Rights and Responsibilities . Unless otherwise agreed in writing by the Parties or prohibited by Applicable Law, the Parties shall continue to provide service and honor commitments under this Agreement and continue to make payments in accordance with this Agreement pending resolution of any bona fide Dispute hereunder or relating hereto.
PROCEDURES FOR OPERATION AND MAINTENANCE
OF THE NECEC TRANSMISSION LINE
Section 6.1 Transmission Operating Agreement; ISO-NE Operational Control .
(a) Prior to entering into the Transmission Operating Agreement, Owner shall consult Purchaser with respect to the proposed terms and conditions thereof and Owner shall make a good faith effort to take into account any comments made by Purchaser. Purchaser shall promptly provide comments, if any, to Owner on such terms and conditions.
(b) As of the Commercial Operation Date, Owner shall transfer operational control over the NECEC Transmission Line, as defined in the Transmission Operating Agreement, to Transmission Operator in accordance with the Transmission Operating Agreement. Owner shall provide, and shall direct its Affiliates to provide, such information as Transmission Operator may require to discharge its obligations under the Transmission Operating Agreement, and Owner shall comply with the instructions of Transmission Operator to the extent provided in the Transmission Operating Agreement and the ISO-NE Tariff. The Parties acknowledge and agree that Owner shall not be in breach of, or be liable to Purchaser under, this Agreement, and no Owner Default shall occur, as a consequence of Owner’s compliance with such instructions of Transmission Operator; provided that Owner did not initiate or support instructions that would otherwise breach Owner’s obligations under this Agreement.
Section 6.2 Good Utility Practice; Regulatory and Reliability Requirements . From and after the Commercial Operation Date, Owner shall (a) provide Firm Transmission Service, (b) operate and maintain the NECEC Transmission Line in accordance with Good Utility Practice and in compliance with all applicable regulatory requirements, including applicable NERC and Northeast Power Coordinating Council reliability standards and (c) comply with all applicable operating instructions of ISO-NE and manufacturers’ warranties.
Section 6.3 Scheduled Maintenance . With respect to each calendar year (or portion thereof) following the Construction Phase, Owner will prepare and deliver to Purchaser a Maintenance Plan not later than the Commercial Operation Date and two (2) months prior to the end of each calendar year thereafter, and shall be available for consultation with Purchaser with
33
respect thereto (including for coordination of maintenance schedules). Consistent with Good Utility Practice, Owner shall use commercially reasonable efforts to coordinate with Trans É nergie with respect to scheduled maintenance so as to minimize outages, including by meeting annually (or as otherwise necessary in order to comply with any applicable ISO-NE or Canadian regulatory or system operator requirements) to develop a Maintenance Plan. From and after the Commercial Operation Date, Owner shall coordinate all planned maintenance with ISO-NE, consistent with ISO-NE Rules, and shall promptly provide applicable information concerning scheduled outages, as determined by ISO-NE, to Purchaser. To maximize value, to the extent possible and consistent with ISO-NE Rules, Owner shall not schedule maintenance of the NECEC Transmission Line during the months of December, January and February or June through September and shall operate the NECEC Transmission Line so as to maximize energy production during the hours of anticipated peak load and energy prices in New England; provided , however , that planned maintenance may be scheduled during such period to the extent the failure to perform such planned maintenance is contrary to operation of the NECEC Transmission Line in accordance with Good Utility Practice. Owner may modify a Maintenance Plan in accordance with Good Utility Practice; provided, however, that (a) a Maintenance Plan may not be modified for the purpose of reducing the magnitude or duration of a Non-Excused Outage, (b) any modification shall, to the extent commercially reasonable, maximize value in the manner described in this Section 6.3 and (c) Owner shall provide Purchaser with reasonable notice of any change in a Maintenance Plan. Any maintenance that is not included in the Maintenance Plan for a year and is not otherwise excused under Section 7.2 shall be a Non-Excused Outage.
PURCHASER’S TRANSMISSION RIGHTS OVER THE
NECEC TRANSMISSION LINE
Section 7.1 Transmission Service .
Section 7.1.1 Firm Transmission Service . Owner shall make available to Purchaser throughout the Purchaser Term transmission capacity on the NECEC Transmission Line in order to deliver electrical energy, as scheduled by Purchaser or its designee or assignee under the resale provisions of Article X , in such scheduled amount up to the Contract Capacity, measured at the Delivery Point (“ Firm Transmission Service ”). Firm Transmission Service shall be made available over the NECEC Transmission Line at any time from and after the Commercial Operation Date, in a north-to-south direction, and to the extent available in a south-to-north direction, between the U.S. Border and the Delivery Point. Firm Transmission Service shall be subject to curtailment or interruption only as a result of an Excused Outage or as provided in Section 14.4(b) . Without limiting Owner’s obligations under this Section 7.1.1 , the quantity of Firm Transmission Service that Owner will provide in any hour shall not exceed the Available Transfer Capability for such hour.
Section 7.1.2 Limitation on Transmission Service . Owner shall have no obligation to provide transmission service under this Agreement other than Firm Transmission Service. Purchaser shall have no right to redirect service to alternate points of delivery or receipt on any portion of the transmission system operated by ISO-NE other than the NECEC Transmission Line.
34
Section 7.1.3 Scheduling . All Firm Transmission Service shall be scheduled in accordance with the rules relating to the scheduling of electrical energy or capacity transactions over the NECEC Transmission Line, as established under the Transmission Operating Agreement (the “ Scheduling Rules ” ).
Section 7.1.4 Owner’s Cooperation . Owner shall provide Purchaser with notice of any FERC or NERC regulatory proceedings relating to the NECEC Transmission Line or this Agreement to which Owner is a party promptly after Owner becomes aware of any such proceedings. Each Party will act in good faith regarding any such proceedings. Neither Party shall take any position in such proceeding that is contrary to such Party’s obligations under this Agreement.
Section 7.2 Excused Outages or Reductions .
(a) Notwithstanding anything herein to the contrary, Owner shall not be in breach of, or be liable to Purchaser for any losses or damages under, this Agreement, and no Owner Default shall occur, as a consequence of an Excused Outage. “ Excused Outages ” means any outages of the NECEC Transmission Line or reductions in the Total Transfer Capability below the NECEC Transmission Line Capacity, whether as a result of a physical condition, legal impediment or otherwise, if and to the extent such outage or reduction is due to:
(i) Events of Force Majeure;
(ii) Scheduled maintenance in accordance with the applicable Maintenance Plan;
(iii) Outages or reductions in the availability of the Québec Line for any reason; or
(iv) Decisions of ISO-NE or any other independent system operator to reduce or suspend scheduling rights over the NECEC Transmission Line or the Québec Line, including as a result of any grid reliability issue, emergency condition as defined in any Interconnection Agreement or the ISO-NE Tariff, or to preserve facilities and equipment from physical damage and including any such decisions that arise from outages or reductions in the use or availability of transmission lines other than the NECEC Transmission Line or the Québec Line, which outage or reduction arises from or is attributable to Force Majeure or scheduled maintenance.
(b) Notwithstanding anything in Section 7.3.1 to the contrary, Purchaser shall remain obligated, during and to the extent of any Excused Outage, to pay the Transmission Service Payment without downward adjustment to reflect any such outage, reduction or delay. Owner shall seek to avoid and mitigate or remedy any Excused Outage consistent with Good Utility Practice.
35
(c) Notwithstanding anything herein to the contrary and without regard to whether an Excused Outage is due to Force Majeure, if an Excused Outage prevents Owner’s full or partial performance under this Agreement during the Purchaser Term for a period of twelve (12) consecutive months or more, Purchaser shall have the right, as provided in Section 15.1(c) herein, to terminate this Agreement upon written notice to Owner and without further recourse.
Section 7.3 Non-Excused Outages or Reductions .
Section 7.3.1 Reduction in Transmission Service Payments . In the event the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), u nless otherwise excused under Section 7.2 or Section 11.1 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 during the Term or firm transmission service contemplated by Section 7.1.1 of the RFP Sponsor TSAs during the term of the RFP Sponsor TSAs, Purchaser shall have the right to recover from Owner, and Owner shall pay to Purchaser, for each such month during which a Non-Excused Outage occurs, the Non-Excused Outage Payment; provided that, in no event, shall the total amount of (a) all Non-Excused Outage Payments made in any Contract Year under this Agreement, plus (b) all Non-Excused Outage Payments (as defined in the Purchaser TSAs) made in any Contract Year pursuant to the Purchaser TSAs exceed Twenty Million Dollars ($20,000,000); provided further that such cap shall be proportionately reduced in any Contract Year that is less than a full calendar year . Any Dispute over whether or not or to what extent a Non-Excused Outage has occurred shall be resolved in accordance with Article XVII . Such amounts shall be payable on a monthly basis pursuant to invoices delivered by Purchaser to Owner. Owner shall seek to avoid, mitigate and remedy any Non-Excused Outage consistent with Good Utility Practice.
Section 7.3.2 [ Intentionally Omitted ] .
Section 7.3.3 Liquidated Damages . The Parties acknowledge and agree that the payment of amounts by Owner to Purchaser under Section 7.3.1 and the modification of Purchaser’s payment obligations pursuant to Section 8.1 are an appropriate remedy and that any such payment or modification does not constitute a forfeiture or penalty of any kind. The Parties further acknowledge and agree that the damages for a Non-Excused Outage are difficult or impossible to determine and that the damages calculated hereunder constitute a reasonable approximation of the harm or loss to Purchaser as a result thereof.
Section 7.3.4 Sole and Exclusive Remedy . The rights provided in Section 3.3.5 , this Section 7.3 and Section 8.1 shall collectively be the sole and exclusive remedies of Purchaser with respect to a Non-Excused Outage, subject to (a) Purchaser’s right to recover any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement, (b) Purchaser’s right to recover payment of any indemnification obligations of Owner to Purchaser pursuant to Section 20.2 , (c) Purchaser’s rights upon the occurrence of an Owner Default as described in Section 14.3 or (d) Purchaser’s rights in the event of Real Power Losses pursuant to Section 11.1 .
36
Section 7.4 Allocation of Outages . The Parties expressly intend and agree that Purchaser’s transmission service under this Agreement shall be reduced before any reductions are applied to any RFP Sponsor’s transmission service under any RFP Sponsor TSA. Except as otherwise set forth in this Section 7.4 , the Parties expressly intend and agree that any outages or reductions in Total Transfer Capability shall be borne equitably by all transmission rights holders served by the NECEC Transmission Line (including Owner, if applicable), and Owner acknowledges and agrees that it will not reduce the Firm Transmission Service available to Purchaser in an unduly discriminatory manner as compared with any other transmission rights holder served by the NECEC Transmission Line (including Owner, if applicable).
Section 7.5 Metering . Metering and telemetering requirements for the NECEC Transmission Line shall be established by Owner in accordance with Good Utility Practice and as necessary to (a) accomplish the purposes of, and to implement and administer, this Agreement and (b) satisfy the requirements of, and to implement and administer, the PPAs, the Interconnection Agreement and the Transmission Operating Agreement.
Section 7.6 Line Availability Information and Reporting . Owner shall make available to Purchaser on a real time basis information relating to the operation and availability of the NECEC Transmission Line and shall provide such additional information as Purchaser shall reasonably request.
PAYMENTS FOR TRANSMISSION SERVICE OVER THE
NECEC TRANSMISSION LINE
Section 8.1 Transmission Service Payments . During the period beginning on the Commercial Operation Date and ending on the twentieth (20th) anniversary of the Commercial Operation Date (unless earlier terminated) (the “ Initial Purchaser Term ”), except to the extent such payment is excused or reduced pursuant to the terms of this Agreement, Purchaser shall pay to Owner a transmission service payment (the “ Initial Transmission Service Payment ”) on a monthly basis in an amount calculated as set forth in Attachment K pursuant to invoices delivered by Owner to Purchaser. During the period beginning on the twentieth (20th) anniversary of the Commercial Operation Date and ending on the fortieth (40th) anniversary of the Commercial Operation Date (unless earlier terminated) (the “ Second Purchaser Term ”), except to the extent such payment is excused or reduced pursuant to the terms of this Agreement, Purchaser shall pay to Owner a transmission service payment (the “ Second Transmission Service Payment ”) on a monthly basis pursuant to invoices delivered by Owner to Purchaser equal to Seven Dollars Thirty Eight Cents ($7.38) per KW of Contract Capacity per month. The Initial Transmission Service Payment or the Second Transmission Service Payment, as applicable, shall be reduced in accordance with the formula set forth in Attachment G in the event and to the extent that the average Hourly Availability of the NECEC Transmission Line over any calendar month following the Commercial Operation Date due to a Non-Excused Outage is less than the Minimum Average Availability for such calendar month (whether as a result of a physical condition, legal impediment or otherwise), unless otherwise excused under Section 7.2 , and as a result thereof Owner is unable (in whole or in part) to provide the full Contract Capacity of Firm Transmission Service contemplated by Section 7.1.1 . To the extent there is a Dispute over whether or not or to
37
what extent a Non-Excused Outage has occurred , Purchaser’s right, pursuant to this Section 8.1 , to any reduction in the Initial Transmission Service Payment or the Second Transmission Service Payment shall be implemented upon the resolution of such Dispute and such reduction will be effective as of the date when such Dispute arose . Such adjustments shall be made on a monthly basis pursuant to invoices delivered by Owner to Purchaser. The Initial Purchaser Term and the Second Purchaser Term shall mean collectively the “ Purchaser Term .” “ Transmission Service Payment ” means, as the context requires, the Initial Transmission Service Payment or the Second Transmission Service Payment.
Section 8.2 Elective Upgrade Status; No Regional Rates . It is the intent of the Parties that the NECEC Transmission Line has Elective Transmission Upgrade status during the Term and that the AC Upgrades and the CCIS Capacity Upgrades constitute Network Upgrades under the ISO-NE Tariff required to accommodate the interconnection of the NECEC Transmission Line. The Parties acknowledge and agree that (a) as contemplated by the PPAs, Purchaser shall participate in such Forward Capacity Auction (as defined in the ISO-NE Rules) qualification process as required to allow Purchaser to qualify a Seasonal Claimed Capability (as defined in the ISO-NE Rules) of not less than 1,200 MW over the NECEC Transmission Line no later than the Guaranteed Delivery Term Start Date (as defined in the PPAs), as it may be extended pursuant to Sections 3.1(c) through 3.1(f) of the PPAs and (b) such Network Upgrades, if any, shall be at Owner’s sole expense. It is the further intent of the Parties that Owner’s recovery of the investment in and return on the NECEC Facilities and Purchaser’s obligation to pay for the NECEC Facilities, shall be solely governed by this Agreement. The Parties each shall refrain from taking steps to include all or part of the NECEC Facilities in ISO-NE regional transmission rates during the Purchaser Term. Notwithstanding the foregoing, if during the Purchaser Term all or part of the NECEC Facilities are included in ISO-NE regional rates paid by Purchaser, the payment required by Section 8.1 shall be reduced by the Proportionate Share of the revenues received by Owner from such ISO-NE rates with respect to the NECEC Facilities. “NECEC Facilities” means the NECEC Transmission Line, the AC Upgrades and the CCIS Capacity Upgrades.
RIGHTS UPON EXPIRATION OF TERM
(a) Unless this Agreement is terminated early under Section 3.3 , Section 14.4 or Section 14.6 , Purchaser shall have rollover rights at the end of the Purchaser Term in accordance with FERC Order No. 890 et seq. and the FERC pro forma open access transmission service tariff, as such rights are defined as of the Effective Date.
(b) Owner shall not enter into any contract or other arrangement for use of the NECEC Transmission Line that is inconsistent with Purchaser’s rollover rights, as provided herein.
38
RESALE OF TRANSMISSION SERVICE
Section 10.1 Resale Rights of Purchaser . If and to the extent Purchaser determines from time to time, and in its sole discretion, that the transmission capacity available to Purchaser over the NECEC Transmission Line pursuant to this Agreement exceeds Purchaser’s needs, Purchaser shall then offer to resell such unused capacity to third parties in accordance with Applicable Law as may then be in effect (including the terms and conditions of FERC Order No. 890 et seq., if applicable).
Section 10.2 Capacity Releases for Daily and Hourly Use . From and after the Commercial Operation Date, if and to the extent the Available Transfer Capability exceeds the amount of electrical energy that is scheduled by Purchaser for delivery over the NECEC Transmission Line using Firm Transmission Service by the applicable scheduling deadline (as in effect at such time) established pursuant to the Scheduling Rules, then the transmission capacity that is available for resale to third parties for the following day, and the price at which any such resales are offered, shall be posted on the OASIS site established pursuant to Section 10.3 .
(a) Owner or an Affiliate of Owner (in such capacity, the “ OASIS Administrator ”) shall establish an OASIS site for the NECEC Transmission Line and administer such site in accordance with applicable FERC requirements for the establishment and administration of OASIS sites. None of Owner, the OASIS Administrator or Purchaser shall be liable to each other or any third party for any decisions the OASIS Administrator makes regarding the appropriate price for resales of unused transmission capacity or the level of any such resales the OASIS Administrator is able to make. The Parties agree that there shall be no damages as between each other or third parties for actions by the OASIS Administrator with respect to resales of unused transmission capacity.
(b) To the extent resales are made available by Purchaser pursuant to Section 10.1 , the OASIS Administrator shall post on the OASIS site information regarding such resales, (i) in accordance with written instructions provided by Purchaser from time to time and (ii) at a price established by Purchaser from time to time, and in its sole discretion, as permitted under Applicable Law.
Section 10.4 Proceeds from Capacity Releases and Transmission Resales . Except as otherwise provided in Section 14.4(b) , the proceeds received by Owner of any capacity releases and transmission resales that are made during the Purchaser Term pursuant to this Article X shall be credited, net of reasonable fees (including attorneys’ fees) and other expenses incurred in connection with performance of the functions described in Section 10.2 and Section 10.3 , against any Transmission Service Payment or other amounts owed to Owner by Purchaser for the calendar month subsequent to the calendar month in which such proceeds were received.
39
Section 10.5 Owner’s Rights and Obligations . Except as expressly provided in the Proposal Agreements, Owner shall have no right or obligation to offer any transmission service over the NECEC Transmission Line for sale or resale to any Person other than Purchaser, as provided herein.
REAL POWER LOSSES, CONGESTION AND CAPACITY RIGHTS
Section 11.1 Real Power Losses . Purchaser shall be responsible for all Real Power Losses associated with Firm Transmission Service; provided , however , that, if and to the extent any Real Power Losses associated with Firm Transmission Service between the U.S. Border and the Delivery Point are due to Owner’s failure to exercise Good Utility Practice or otherwise discharge its obligations under this Agreement, (a) such incremental Real Power Losses shall be treated as Non-Excused Outages for which Owner shall be liable in accordance with Section 7.3 and (b) the Transmission Service Payments owed by Purchaser shall be reduced pursuant to Section 8.1 ; and provided , further , that during the Term Owner shall (x) exercise diligent, commercially reasonable efforts to maximize the warranty or similar obligations of its vendors and suppliers for the NECEC Transmission Line with respect to such Real Power Losses under any Construction Contract or otherwise and (y) credit, assign or pay over to Purchaser any amounts receivable by or paid to Owner under such warranties or similar obligations, including liquidated damages under any Construction Contract, related to such Real Power Losses, and the rights and remedies contemplated by Section 3.3.5 , Section 7.3 , Section 8.1 and this Section 11.1 , shall collectively be the sole and exclusive remedy of Purchaser with respect to any such incremental Real Power Losses.
(a) Purchaser shall be entitled during the Purchaser Term to the Transmission Percentage of the following, without duplication and without additional cost to Purchaser or compensation to Owner: (i) all Other Transmission Rights associated with the NECEC Transmission Line or the AC Upgrades, in each case, that are issued in accordance with the ISO-NE Tariff or otherwise granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE and (ii) all other Market Products that are issued in accordance with the ISO-NE Tariff or granted under the ISO-NE Rules, or otherwise created or awarded by ISO-NE, that derive from the acquisition of transmission service over the NECEC Transmission Line. As Owner’s sole obligation under this clause (a), upon its receipt of any of the entitlements or rights described in the foregoing sentence, Owner shall promptly convey such entitlements or rights to Purchaser.
(b) In the event tie benefits or interconnection capability credits (or any similar concept) are ever deemed applicable to the NECEC Transmission Line and to the extent allocated to any Party during the Purchaser Term, Purchaser shall be entitled to the Transmission Percentage of one hundred percent (100%) of the economic benefits associated therewith (however entitled and whether existing now or in the future), without additional cost to Purchaser or compensation to Owner.
40
(c) Owner shall have no obligation to support the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above, but Owner may not oppose the creation or establishment of any such right, unless otherwise agreed in writing by Purchaser. Neither Section 2.5 nor the foregoing sentence shall be construed in any way to limit the right of any Affiliate of Owner to oppose the creation or establishment of any of the rights described in clauses (a)(ii) and (b) above.
[INTENTIONALLY OMITTED]
BILLING AND PAYMENTS
Section 13.1 Invoices . Within seven (7) Business Days after the first day of each calendar month following the commencement of the Purchaser Term, Owner shall submit an Invoice to Purchaser for the Transmission Service Payments owed for the preceding calendar month, and Purchaser shall pay the amounts set forth in the Invoice to Owner within fourteen (14) Business Days following its receipt of such Invoice. All payments shall be made in immediately available funds payable to Owner by wire transfer to a bank named by Owner, in accordance with wiring instructions provided to Purchaser by Owner in writing. Owner shall be entitled to change the place or recipient for payment by thirty (30) days’ prior written notice to Purchaser.
Section 13.2 Procedures for Billing Disputes .
(a) In the event of any Dispute with respect to the amount owed to Owner by Purchaser under this Agreement, Purchaser shall have no right to withhold payment of the Disputed amount pending resolution of the Dispute; provided , however , that, in the event such Dispute is resolved in favor of Purchaser, Owner shall complete the following tasks consistent with the resolution of such Dispute: (i) retroactively adjust all payments previously made by Purchaser; (ii) promptly refund all overpayments previously made by Purchaser, together with interest thereon in immediately available funds or by wire transfer, in each case, in accordance with wiring instructions provided to Owner by Purchaser in writing; and (iii) thereafter conform all future Invoices to reflect the resolution of such Dispute, as applicable. Purchaser’s payment of any Disputed amounts shall be without prejudice to any right or remedy that Purchaser may have under this Agreement to contest any such amount.
(b) Purchaser shall not have the right to challenge any Invoice or to bring any action of any kind challenging the propriety of any Invoice after the second (2nd) anniversary of the receipt of such Invoice. If an Invoice is not rendered within two (2) years after the end of the calendar month during which such Invoice should have been rendered hereunder, then the right to payment of such Invoice is waived.
41
Section 13.3 Interest . All interest payable under this Section 13.3 shall be calculated pursuant to 18 C.F.R. § 35.19a(a), as such regulation (or any successor thereto) is in effect during the period during which such interest is due. Amounts not paid when due to Owner or Purchaser under this Agreement shall bear interest from the date such amount was due until the date of payment of such overdue amount. For the avoidance of doubt, as illustrated in Attachment H , if all or a portion of the amount to which such interest relates is later refunded pursuant to this Agreement, then, in calculating that refund, such interest shall not be included in the refund. Refunds of overpayments owed to Purchaser by Owner under this Agreement shall begin to accrue interest on the amount subject to refund, as originally invoiced, from the earlier to occur of the due date or the date of payment of the monthly Invoices to which the overpayment relates and shall continue to accrue interest until the date of payment of such refund.
Section 13.4 Obligation to Make Payments . The Parties acknowledge and agree that, except as set forth in Section 8.1 , Section 13.5 and Section 14.6(d) , no cause or event whatsoever shall excuse or suspend Purchaser’s obligation to pay Transmission Service Payments or any other amounts payable by Purchaser under this Agreement. The Parties also acknowledge and agree that no cause or event whatsoever shall excuse or suspend any amounts payable by Owner under this Agreement.
Section 13.5 Offsets . Except as otherwise provided in Section 3.4(a) and Section 14.6(d) , neither Party shall be entitled to deduct or set-off payment of any amount owed to the other Party under this Agreement against payment of any amount owing under this Agreement. The Parties shall have the right to deduct or set-off payments of amounts owed hereunder against payments of amounts owing under the Purchaser TSAs.
EVENTS OF DEFAULT AND REMEDIES
Section 14.1 Purchaser Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV , the occurrence of one or more of the following events shall constitute a default by Purchaser under this Agreement (a “ Purchaser Default ”); provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (d), clause (e) or clause (f):
(a) Purchaser’s failure to pay any undisputed amount due to Owner under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Purchaser of a written demand from Owner that such amount is due and owing and has not been timely paid.
(b) Purchaser’s failure to comply in any material respect with the provisions of Article XVI .
42
(c) Purchaser’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a) or (b) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Purchaser of written notice thereof from Owner, unless such cure shall reasonably require a longer period, in which case Purchaser shall be provided an additional thirty (30) days to complete such cure so long as Purchaser has promptly commenced such cure and thereafter diligently pursues such cure.
(d) Any representation or warranty made by Purchaser in this Agreement is false or misleading at the time made in any material respect.
(e) Any Insolvency Event occurs with respect to Purchaser.
(f) An Event of Default (as defined in any PPA) by Purchaser under any PPA that does not result from a TSA Delivery Shortfall (as defined in any PPA) or a Transmission Delay (as defined in any PPA),or a Purchaser Default (as defined in any Purchaser TSA) occurs and is continuing.
Section 14.2 [ Intentionally Omitted] .
Section 14.3 Owner Defaults . Except to the extent excused as a result of an event of Force Majeure in accordance with Article XV, the occurrence of one or more of the following events shall constitute a default by Owner under this Agreement (an “ Owner Default ” ); provided that an event of Force Majeure shall not excuse an event described in clause (a), clause (g) or clause (h):
(a) Owner’s failure to pay any undisputed amount due to Purchaser under this Agreement by the due date, which failure is not cured within ten (10) days after the receipt by Owner of a written demand from Purchaser that such amount is due and owing and has not been timely paid.
(b) Owner’s failure to satisfy (other than as a result of a Purchaser Delay) any of the Critical Milestones in clauses (i), (iii), (iv), (v), or (vii) of Section 4.1(a) by the dates set forth therefor, as the same may be extended in accordance with Section 4.1(c) , Section 4.1(d) or Section 4.1(e) .
(c) Owner’s failure to comply in any material respect with the provisions of Section 5.1.1(a)(ii) and, if such failure is susceptible to cure, such failure continues for thirty (30) days after receipt by Owner of written notice thereof from Purchaser, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
43
(d) A Non-Excused Outage pursuant to which (A) the Hourly Availability of the NECEC Transmission Line is less than one hundred percent (100%) for more than ninety (90) consecutive days and the average Hourly Availability of the NECEC Transmission Line over each calendar month in which the ninety (90) consecutive days occur is less than the Minimum Average Availability for each such month (whether as a result of a physical condition, legal impediment or otherwise), or (B) the Hourly Availability of the NECEC Transmission Line is less than one hundred percent (100%) for more than hundred twenty (120) days in any twelve (12) month period and the average Hourly Availability of the NECEC Transmission Line over each calendar month in which any such day occurs is less than the Minimum Average Availability for each such month (whether as a result of a physical condition, legal impediment or otherwise) in each case, unless otherwise excused under Section 7.2 , provided , however , that if (i) Owner presents to RFP Sponsors and Purchaser (during the Initial Purchaser Term) or Purchaser (during the Second Purchaser Term) before the end of a Non-Excused Outage that would otherwise constitute an Owner Default under this clause (d), a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) acceptable to RFP Sponsors and Purchaser (during the Initial Purchaser Term) or Purchaser (during the Second Purchaser Term), each acting reasonably, to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, and (ii) during the Initial Purchaser Term, Owner posts Credit Support with RFP Sponsors as set forth in Section 14.2(e) of the RFP Sponsor TSAs, Purchaser shall forbear terminating this Agreement under this clause (d) for such period, provided that, during any such period, Purchaser’s obligation to make Transmission Service Payments shall continue to be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, an Owner Default shall be deemed to have occurred and Purchaser shall have the rights and remedies set forth in Section 14.6 and Section 14.7 of the Purchaser TSAs.
(e) Owner’s failure to comply in any material respect with the provisions of Article XVI .
(f) Owner’s failure to perform or comply with any of its obligations under this Agreement, other than those described in clauses (a), (b), (c) or (d) above, in each case, in any material respect, and, if such failure is susceptible to cure, such failure continues for thirty (30) days after the receipt by Owner of written notice thereof from Purchaser, unless such cure shall reasonably require a longer period, in which case Owner shall be provided an additional thirty (30) days to complete such cure so long as Owner has promptly commenced such cure and thereafter diligently pursues such cure.
(g) Any representation or warranty made by Owner in this Agreement is false or misleading at the time made in any material respect.
(h) Any Insolvency Event occurs with respect to Owner.
(i) An Owner Default (as defined in) any Purchaser TSA occurs and is continuing.
44
Section 14.4 Remedies Upon Purchaser Default . Upon the occurrence of a Purchaser Default and at any time thereafter so long as the same is continuing, Owner shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Owner shall elect:
(a) In the case of a Purchaser Default, and subject to Section 5.8 , Owner may terminate this Agreement by written notice to Purchaser.
(b) In the case of a Purchaser Default pursuant to Section 14.1(a) , and subject to Section 5.8 , Owner may suspend all or part of Owner’s obligations or Purchaser’s rights under this Agreement during the period during which such Purchaser Default is continuing. During any such period of suspension occurring after the Commercial Operation Date, (i) Purchaser shall not be entitled to schedule, and shall not schedule, any transactions over the NECEC Transmission Line and (ii) the OASIS Administrator shall be directed to post any portion of the transmission capacity that would have otherwise been available to Purchaser over the NECEC Transmission Line pursuant to this Agreement and to attempt to sell such capacity to one or more third parties consistent with Article X . The proceeds of any capacity releases and transmission resales made pursuant to the foregoing sentence and received by Owner, net of reasonable fees (including attorneys’ fees) and other expenses incurred by Owner in connection with this Section 14.4(b) , shall be credited against any accrued but unpaid payment obligation of Purchaser to Owner hereunder. Any such proceeds in excess of such accrued but unpaid payment obligation of Purchaser shall be credited in accordance with Section 10.4 .
(c) Subject to Article XVIII and this Section 14.4 , as applicable, Owner may recover from Purchaser the Purchaser Termination Payment and, to the extent applicable, all other amounts not waived in accordance with Section 3.3.4(d) or, in the absence of a termination pursuant to a Purchaser Default, all damages suffered by Owner that are due to a Purchaser Default, including, for the avoidance of doubt, any amounts payable under Section 4.4.2 and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Owner to recover any amounts owed to Owner by Purchaser under this Agreement.
(d) Owner may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Additional Credit Support held by Owner and (ii) the right to liquidate any and all Additional Credit Support held by Owner and to apply the proceeds of such liquidation to any amounts payable to Owner with respect to Purchaser’s obligations hereunder in such order as Owner may elect. Owner may draw on the undrawn portion of any Letter of Credit provided as Additional Credit Support up to the amount of Purchaser’s outstanding obligations hereunder. Purchaser shall remain liable for amounts due and owed to Owner that remain unpaid after the application of Additional Credit Support.
(e) Owner may exercise and enforce any and all of its rights and remedies under the Hydro-Québec Guaranty.
45
(f) Owner may exercise any and all other rights and remedies that may be available to Owner against Purchaser at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Owner shall have no right to (i) terminate this Agreement based upon a Purchaser Default, except as provided in clause (a) above or (ii) suspend transmission service under this Agreement based upon a Purchaser Default, except as provided in clause (b) above.
Section 14.5 [Intentionally Omitted] .
Section 14.6 Remedies Upon Owner Default . Upon the occurrence of an Owner Default and at any time thereafter so long as the same is continuing, Purchaser shall be entitled, to the extent permitted by Applicable Law, to exercise one or more of the following remedies, as Purchaser shall elect:
(a) In the case of an Owner Default, and subject to Section 5.8 and Section 14.7 of the Purchaser TSAs, Purchaser may terminate this Agreement by written notice to Owner and may recover, as applicable, any accrued but unpaid amounts under Section 4.4.1 and the Owner Termination Payment.
(b) Subject to the limitations provided in Section 4.4.1(e) , Section 7.3.4 , Article XVIII or this Section 14.6 , as applicable, Purchaser may recover from Owner any accrued but unpaid amounts under Section 4.4.1 and Section 7.3.1 (as applicable) and any costs or expenses (including reasonable attorneys’ fees) reasonably incurred by Purchaser to recover any amounts owed to Purchaser by Owner under this Agreement.
(c) Purchaser may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable Law with respect to Additional Credit Support held by Purchaser and (ii) the right to liquidate any and all Additional Credit Support held by Purchaser and to apply the proceeds of such liquidation to any amounts payable to Purchaser with respect to Owner’s obligations hereunder in such order as Purchaser may elect. Purchaser may draw on the undrawn portion of any Letter of Credit or apply Cash, in each case that has been provided as Additional Credit Support up to the amount of Owner’s outstanding obligations hereunder. Owner shall remain liable for amounts due and owed to Purchaser that remain unpaid after the application of Additional Credit Support.
(d) Pursuant to Section 13.2 , to the extent there is a Dispute over the amount of the damages suffered by Purchaser as a result of an Owner Default, Purchaser may deduct and setoff payment of such amount against any Transmission Service Payment upon resolution of that Dispute.
(e) Purchaser may exercise any and all other rights and remedies that may be available to Purchaser at law or in equity for non-monetary relief, unless expressly prohibited or otherwise restricted by Article XVIII or any other provision of this Agreement. Notwithstanding the foregoing sentence, Purchaser shall have no right to (i)
46
terminate this Agreement based upon an Owner Default, except as provided in clause (a) above or Section 14.7(e)(i) , or (ii) any reduction of or offset against payments under this Agreement based upon an Owner Default, except as contemplated by Section 8.1 , Section 13.5 and Section 14.6(d) , as applicable.
Section 14.7 Purchaser Step-in Rights .
(e) Upon Purchaser (or its designated Affiliate) assuming ownership and control of the NECEC Transmission Line pursuant to Section 14.7 of any Purchaser TSA:
(i) (A) Purchaser (or its designated Affiliate) shall have the right to terminate this Agreement and Purchaser may recover, as applicable, any accrued but unpaid amounts under Section 4.4.1 or (B) Purchaser (or its designated Affiliate) shall assume Owner’s obligations under this Agreement pursuant to Section 14.7 of any Purchaser TSA and Purchaser shall enter into such amendments to this Agreement as are reasonably necessary in order to give effect to such rights and that are consistent with the terms and conditions of this Agreement and are subject to applicable regulatory approvals;
(ii) Purchaser (or its designated Affiliate) shall assume the rights and obligations of Owner under the RFP Sponsor TSAs and the Purchaser TSAs for the remainder of the term thereof (excluding any rights and obligations accrued prior to such assumption).
Section 14.8 [ Intentionally Omitted ].
Section 14.9 Disputes . Any Dispute over whether or not an Owner Default or Purchaser Default has occurred shall be resolved in accordance with Article XVII .
Section 14.10 Limitations on Total Liability .
Section 14.10.1 Purchaser Liability . Notwithstanding anything herein to the contrary, Purchaser’s liability for any payments made to Owner pursuant to (x) Sections 3.3.4 , 3.4 , 4.4.2 and 14.4 and (y) Sections 3.3.3, 3.3.4, 3.4, 4.4.2, 4.4.3 and 14.4 of the Purchaser TSAs shall not exceed, in aggregate, an amount equal to Two Hundred Million Dollars ($200,000,000), which $200,000,000 shall be adjusted in accordance with the following:
(a) increased by the total amount of Credit Support provided by Owner pursuant to Section 4.1(c) of the Purchaser TSAs;
47
(b) reduced by the amount drawn on any Credit Support provided by Owner pursuant to Section 4.1(c) of the Purchaser TSAs as a result of an Owner Default thereunder;
(c) reduced by any amount of Credit Support that has been returned to Owner pursuant to Section 4.1(c) of the RFP Sponsor TSAs; and
(d) reduced by any Delay Damages (as defined in the PPAs) paid by Purchaser to the RFP Sponsors under the PPAs.
Section 14.10.2 Owner Liability . Notwithstanding anything herein to the contrary, Owner’s liability for any payments made to Purchaser pursuant to (x) Sections 3.3.5 , 3.4 , 4.4.1 , 7.3 , 14.11 , and 14.6 and (y) Sections 3.3.3, 3.3.5, 3.4, 4.4.1, 4.4.3(b)(iii), 7.3, 14.11 and 14.6 of the Purchaser TSAs shall not exceed, in aggregate, an amount equal to Sixty Million Dollars ($60,000,000), which $60,000,000 shall be adjusted in accordance with the following:
(a) increased by the total amount of Credit Support provided by Purchaser pursuant to Section 4.1(c) of the Purchaser TSAs;
(b) reduced by the amount drawn on any Credit Support provided by Purchaser pursuant to Section 4.1(c) of the Purchaser TSAs as a result of a Purchaser Default thereunder;
(c) reduced by any amount of Credit Support that has been returned to Purchaser pursuant to Section 4.1(c) of the Purchaser TSAs; and
(d) reduced by any amounts paid by Owner pursuant to Section 14.7(f) of the Purchaser TSAs.
Section 14.10.3 Exceptions to Total Liability . The limits on liability set forth in Sections 4.4 , 14.10.1 and 14.10.2 shall not apply to any liability of a Party arising out of such Party’s gross negligence, willful misconduct (including willful breach of this Agreement) or fraud.
Section 14.11 Modified Terms Applicable During Forbearance Period . In the event that Owner exercises its rights pursuant to Section 14.2(e) of the RFP Sponsor TSAs or Section 14.3(d) of this Agreement, during the continuation of the period of forbearance by Purchaser of its rights as contemplated by Section 14.3(d) of this Agreement or Section 14.2(e) of the RFP Sponsor TSAs, an additional $3 shall be available in clause (b) of the definition of Non-Excused Outage Payment for the calculation of such payment by Owner, and an additional Ten Million Dollars ($10,000,000) per Contract Year shall be available with respect to the limitation of liability contained in Section 7.3.1. If Owner is successful in providing Firm Transmission Service under this Agreement or Firm Transmission Service (as defined in the RFP Sponsor TSAs), as applicable, in full at or prior to the end of such period of forbearance, all such amounts shall revert at the time Firm Transmission Service or Firm Transmission Service (as defined in the RFP Sponsor TSAs), as applicable, is provided in full to the amounts applicable under this Agreement prior to Owner’s exercise of its rights under Section 14.3(d) of this Agreement or Section 14.2(e) of the RFP Sponsor TSAs.
48
FORCE MAJEURE
Section 15.1 Definition; Conditions .
(a) The term “ Force Majeure ” means an event or circumstance (i) that is not within the reasonable control of the Party claiming its occurrence, (ii) that could not have been prevented or avoided by such Party through the exercise of reasonable diligence and (iii) that prohibits or prevents such Party from performing its obligations under this Agreement. Under no circumstances shall Force Majeure include (w) any full or partial curtailment in the operation of the NECEC Transmission Line that is caused by or arises from a mechanical or equipment breakdown or other mishap or events or conditions attributable to normal wear and tear or flaws of the NECEC Transmission Line, unless such curtailment or mishap is caused by one of the following: acts of God such as floods, hurricanes, tornados, or other significantly unusual and abnormal weather conditions, such as severe blizzards and severe ice storms; sabotage; terrorism or war; national or regional general strikes, lockouts or other labor disputes, (x) any occurrence or event that increases the costs or causes an economic hardship to a Party but is not otherwise a Force Majeure, (y) Owner’s ability to sell transmission service involving the NECEC Transmission Line at a price greater than that set out in this Agreement or (z) Purchaser’s ability to procure transmission service at a price lower than that provided in this Agreement. In addition, a delay or inability to perform attributable to a Party’s lack of preparation, a Party’s failure to timely obtain and maintain all necessary permits (excepting the Regulatory Approval other than the obligations to file for Regulatory Approval) or qualifications, any delay or failure of Owner to obtain the Owner Approvals or of Purchaser to obtain the Canadian Approvals, a failure to satisfy contractual conditions or commitments, or lack or deficiency in funding or other resources shall each not constitute a Force Majeure or be the basis for a claim of Force Majeure.
(b) Subject to Section 15.1(a) , if a Party is unable, wholly or in part, by Force Majeure to perform its obligations under this Agreement, such performance shall be excused and suspended so long as the circumstances that give rise to such inability exist or would exist if the Party claiming the Force Majeure used commercially reasonable efforts to cure such circumstances, but for no longer period. The Party whose performance is affected shall give prompt notice thereof to the other Party; such notice may be given orally or in writing but, if given orally, it shall be promptly confirmed in writing, providing details regarding the nature, extent and expected duration of the Force Majeure, its anticipated effect on the ability of such Party to perform its obligations under this Agreement, and the estimated duration of any interruption in service or other adverse effects resulting from such Force Majeure, and shall be updated or supplemented to keep the other Party advised of the effect and remedial measures being undertaken to overcome the Force Majeure. Such inability to perform shall be promptly corrected to the extent it may be corrected through the exercise of due diligence consistent with Good Utility Practice. Neither Party shall be liable for any losses or damages arising out of a suspension of performance that occurs because of Force Majeure. Notwithstanding any such suspension of performance, Purchaser shall be obligated to make Transmission Service Payments as though Firm Transmission Service was then being provided at or greater than the Minimum Average Availability.
49
(c) Notwithstanding the foregoing, if the Force Majeure prevents full or partial performance under this Agreement for a period of twelve (12) consecutive months or more, the Party whose performance is not prevented by Force Majeure shall have the right to terminate this Agreement upon written notice to the other Party and without further recourse, provided , however , that if Owner presents a request to delay termination of this Agreement for a period not to exceed twelve (12) months, together with a detailed plan reasonably acceptable to Purchaser and RFP Sponsors (during the Initial Purchaser Term) or Purchaser (during the Second Purchaser Term) (including reasonably satisfactory evidence of Owner’s financial and technical capability to timely effectuate such plan) to restore the capability of the NECEC Transmission Line to provide Firm Transmission Service in full within such period, to Purchaser and RFP Sponsors (during the Initial Purchaser Term) or Purchaser (during the Second Purchaser Term) before the end of a period in which Owner’s provision of Firm Transmission Service has been prevented in whole or in part by an event of Force Majeure, Purchaser shall forbear terminating this Agreement under this clause (c) for such period, provided that, during any such period, Purchaser’s obligation to make Transmission Service Payments shall be reduced to the extent Firm Transmission Service is then being provided at less than the Minimum Average Availability. In the event Owner is not providing Firm Transmission Service in full at the end of such period of forbearance, or if Owner fails to exercise diligent, commercially reasonable efforts consistent with Good Utility Practice to timely effectuate such plan, Purchaser may terminate this Agreement under this clause (c). In no event will any delay or failure of performance caused by any conditions or events of Force Majeure extend this Agreement beyond its stated Term.
(d) A Party shall not be required to settle any strike, walkout, lockout or other labor dispute on terms that, in the sole judgment of such Party, are contrary to its interest. The settlement of strikes, walkouts, lockouts or other labor disputes shall be entirely within the discretion of the Party involved in such dispute.
Section 16.1 Purchaser’s Guaranty . Concurrently with the execution of this Agreement, Purchaser shall cause Purchaser Guarantor to deliver to Owner a guaranty by Purchaser Guarantor of Purchaser’s payment obligations under this Agreement substantially in the form of Attachment J (the “Hydro-Québec Guaranty”).
Section 16.2 [Intentionally Omitted] .
Section 16.3 Credit Downgrade Event . Purchaser Guarantor and Owner shall at all times meet the Credit Rating Requirements.
(a) In the event Owner fails to meet the Credit Rating Requirements, Owner shall promptly furnish to Purchaser, in an amount equal to the Proportionate Share multiplied by Two Hundred Fifty Million Dollars ($250,000,000), Additional Credit Support.
50
(b) In the event Purchaser Guarantor fails to meet the Credit Rating Requirements, Purchaser shall promptly furnish to Owner, in an amount equal to the Proportionate Share multiplied by Two Hundred Fifty Million Dollars ($250,000,000), Additional Credit Support.
DISPUTE RESOLUTION
(a) The Parties shall initially attempt to resolve any Dispute through consultations between the Parties. Subject to Section 17.2 and except as expressly provided otherwise in this Agreement, if a Dispute has not been timely resolved pursuant to this clause (a) within fifteen (15) Business Days after written notice of such Dispute has been given, then either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction; provided , however , if the Dispute is subject to Section 17.2 , then either Party may elect to proceed with the mediation through FERC’s Dispute Resolution Service. If one Party fails to participate in the consultations provided for in this Section 17.1 , the other Party can initiate mediation prior to the expiration of the fifteen (15) Business Days. Unless otherwise agreed, the Parties will select a mediator from the FERC panel. The Parties may, by written agreement signed by both Parties, alter any time deadline, location(s) for meeting(s) or procedure outlined herein or in FERC’s rules for mediation. The procedure specified herein shall be the sole and exclusive procedure for the resolution of Disputes.
(b) All negotiations, consultations and mediations pursuant to this Section 17.1 shall be deemed to be confidential and shall be treated as compromise and settlement negotiations, and no evidence with regard to any proposal made during such negotiations, consultations or mediations shall be admissible in any FERC proceeding or filing under Section 17.2 or in any other judicial or other proceeding.
Section 17.2 Disputes to be Resolved by FERC .
(a) In the event a Dispute over any matter is not resolved in accordance with Section 17.1 , either Party shall have the right to file for relief with FERC to the extent that matter is within the primary or exclusive jurisdiction of the FERC. Nothing contained in this Agreement shall be construed as precluding a Party from filing any answer, protest or other opposition to any FERC filing made by the other Party, unless expressly prohibited under the terms of this Agreement.
(b) In the event any Dispute is submitted to FERC for resolution as provided in Section 17.2(a) , the Party submitting the Dispute to FERC shall be responsible for providing written notice of such filing to the other Interested Parties. Unless both Parties agree that the Dispute does not implicate any of the Proposal Agreements other than this Agreement, each Party consents and agrees that (i) each Interested Party is an
51
interested party in the Dispute and (ii) in order to avoid inconsistent interpretations and adjudications of the Proposal Agreements, any Interested Party may, without objection from any other Interested Party, whether by means of joinder, consolidation or otherwise, submit such matters as it considers sufficiently related to the Dispute to FERC to be jointly determined by FERC with the Dispute. Notwithstanding the foregoing, in the event FERC determines that it does not have the jurisdiction to, or otherwise does not want to, hear or determine any portion of a Dispute or other matter so referred to FERC, either Party may seek to resolve such Dispute in the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts and any appellate court from any thereof that has subject matter jurisdiction.
Section 17.3 Consent to Jurisdiction . Subject to Section 17.2, each Party agrees that any legal action or proceeding with respect to or arising out of this Agreement or any other Proposal Agreement shall be brought in or removed to the courts of the Commonwealth of Massachusetts or a U.S. District Court in the Commonwealth of Massachusetts that has subject matter jurisdiction and any appellate court from any thereof. By execution and delivery of this Agreement, each Party hereby accepts for itself and in respect of its property, generally and unconditionally, the jurisdiction of the aforesaid courts. The Parties irrevocably consent to the service of process out of any of the aforementioned courts in any such action or proceeding by the mailing of copies thereof by registered or certified airmail, postage prepaid, to the applicable Party at its respective addresses for notices as specified in Section 23.4. Nothing herein shall affect the right to serve process in any other manner permitted by law. Each Party hereby waives any right to stay or dismiss any action or proceeding under or in connection with this Agreement or any other Proposal Agreement brought before the foregoing courts on the basis of forum non-conveniens.
Section 17.4 WAIVER OF JURY TRIAL . EACH PARTY IRREVOCABLY AND UNCONDITIONALLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY LEGAL ACTION, PROCEEDING, CAUSE OF ACTION OR COUNTERCLAIM ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.
LIMITATION OF REMEDIES
NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, NEITHER PARTY NOR ANY OF ITS AGENTS, SUBCONTRACTORS, REPRESENTATIVES OR AFFILIATES SHALL BE LIABLE TO THE OTHER PARTY FOR PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE (EXCEPT AS EXPRESSLY CONTEMPLATED IN THIS AGREEMENT, INCLUDING IN Section 4.4 OR Section 7.3 , OR FOR ANY DIRECT DAMAGES SUFFERED BY PURCHASER AS A RESULT OF A BREACH BY OWNER OF ITS OBLIGATIONS UNDER Section 6.2 , Article X OR Section 11.2 ), IN EACH CASE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OF THIS AGREEMENT, AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY).
52
FOR THE AVOIDANCE OF DOUBT, THE PARTIES ACKNOWLEDGE AND AGREE THAT Section 4.4 OR Section 7.3 PROVIDE THE SOLE AND EXCLUSIVE REMEDIES FOR ANY LOSS OF USE CONTEMPLATED BY Section 4.4 OR Section 7.3 AND NOTHING IN Section 6.2 , Article X OR Section 11.2 SHALL SUPERSEDE, SUPPLEMENT OR AMEND SUCH SOLE AND EXCLUSIVE REMEDIES.
THIS Article XVIII IS IN ADDITION TO THE SPECIFIC LIMITATIONS ON REMEDIES REFERENCED IN Article XIV , Section 4.4.1 AND Section 4.4.2 .
OWNER ACKNOWLEDGES THAT (A) PURCHASER (OR ITS AFFILIATES) MAY BE A PROPONENT OF OR PARTICIPATE IN OTHER BIDS WITH OTHER TRANSMISSION DEVELOPERS IN RESPONSE TO THE RFP (“ ADDITIONAL BIDS ”), EITHER ON ITS OWN OR WITH ONE OR MORE THIRD PARTIES AND (B) PURCHASER SHALL NOT BE LIABLE TO OWNER FOR ANY PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE, INCLUDING LOST PROFITS, IN EACH CASE, ARISING FROM OR RELATING TO ANY ADDITIONAL BIDS (INCLUDING IF ANY ADDITIONAL BIDS ARE SELECTED PURSUANT TO THE RFP), AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY). OWNER ACKNOWLEDGES AND AGREES THAT AS PART OF PURCHASER’S PARTICIPATION IN ADDITIONAL BIDS, PURCHASER SHALL EMPLOY MATERIALLY SIMILAR LANGUAGE IN DOCUMENTS PREPARED PURSUANT TO ADDITIONAL BIDS, FOR WHICH NO LIABILITY OR OBLIGATION OF ANY KIND, INCLUDING FOR COMPENSATION, SHALL BE IMPOSED UPON PURCHASER.
PURCHASER ACKNOWLEDGES THAT (A) OWNER (OR ITS AFFILIATES) MAY BE A PROPONENT OF OR PARTICIPATE IN OTHER BIDS WITH OTHER GENERATION DEVELOPERS IN RESPONSE TO THE RFP, EITHER ON ITS OWN OR WITH ONE OR MORE THIRD PARTIES AND (B) OWNER SHALL NOT BE LIABLE TO PURCHASER FOR ANY PUNITIVE, CONSEQUENTIAL, SPECIAL, MULTIPLE, EXEMPLARY, INCIDENTAL OR INDIRECT DAMAGES OF ANY NATURE, INCLUDING LOST PROFITS, IN EACH CASE ARISING FROM OR RELATING TO ANY SUCH OTHER BIDS (INCLUDING IF ANY SUCH OTHER BID IS SELECTED PURSUANT TO THE RFP) AND WHETHER SUCH LIABILITY IS CLAIMED IN CONTRACT OR TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY, WARRANTY, FAILURE OF GOOD UTILITY PRACTICE OR ANY OTHER LEGAL OR EQUITABLE THEORY). PURCHASER ACKNOWLEDGES AND AGREES THAT AS PART OF OWNER’S PARTICIPATION IN OTHER BIDS, OWNER MAY EMPLOY MATERIALLY SIMILAR LANGUAGE IN DOCUMENTS PREPARED PURSUANT TO OTHER BIDS, FOR WHICH NO LIABILITY OR OBLIGATION OF ANY KIND, INCLUDING FOR COMPENSATION, SHALL BE IMPOSED UPON OWNER.
53
MODIFICATION OF THIS AGREEMENT; CHANGES IN LAW, ISO-NE RULES.
Section 19.1 Modifications . The Parties specifically intend and acknowledge and agree that, except as otherwise expressly provided in this Agreement, (a) this Agreement shall not be subject to amendment or other modification, absent the written agreement of both Parties and (b) neither Party shall be permitted to make a filing with FERC under any provision of the Federal Power Act or the regulations promulgated thereunder that seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement at any time during the Term, except to implement an amendment or other modification to this Agreement that has been reduced to writing and signed by both Parties. In addition, to the extent any third party, or FERC acting sua sponte , seeks to amend or otherwise modify, or requests FERC to amend or otherwise modify, any provision of this Agreement, the standard of review for any proposed amendment or other modification shall be the “public interest” standard of review set forth in United Gas Pipe Line Co. v. Mobile Gas Service Corp ., 350 U.S. 332 (1956), and Federal Power Commission v. Sierra Pacific Power Co ., 350 U.S. 348 (1956), and as further defined in Morgan Stanley Capital Group, Inc. v. Public Utility District No. 1 of Snohomish County , 128 S. Ct. 2733 (2008) and NRG Power Marketing, LLC v. Maine Public Utilities Commission , 130 S. Ct. 693 (2010).
Section 19.2 Change in ISO-NE Rules; Change in Applicable Law or Accounting Treatment .
(a) This Agreement is subject to the ISO-NE Rules. If, during the Term, any ISO-NE Rule is terminated, modified or amended, or is otherwise no longer applicable, resulting in a material alteration of a material right or obligation of a Party hereunder, the Parties agree to negotiate in good faith in an attempt to amend or clarify this Agreement to embody the Parties’ original intent regarding their respective rights and obligations under this Agreement; provided that neither Party shall have any obligation to agree to any particular amendment or clarification of this Agreement. The intent of the Parties is that any such amendment or clarification reflect, as closely as possible, the intent, substance and effect of the ISO-NE Rule being replaced, modified, amended or made inapplicable as such ISO-NE Rule was in effect prior to such termination, modification, amendment or inapplicability; provided that such amendment or clarification shall not in any event alter (i) the purchase and sale obligations of the Parties pursuant to this Agreement or (ii) the Transmission Service Payment. In the event the Parties cannot agree upon such amendments within sixty (60) days after such ISO-NE Rule or ISO-NE Practice change described above, the Dispute shall be resolved in accordance with Article XVII .
(b) If, during the Term, there is a change in Applicable Law (other than tax laws or regulations) or accounting standards or rules or a change in the interpretation or applicability thereof that would result in a (A) material adverse balance sheet or creditworthiness impacts on Purchaser associated with this Agreement or the amounts paid for Firm Transmission Service purchased hereunder, or (B) an adverse impact on the economic benefits (including those stemming from the fiscal conditions provided for
54
herein) that any Party enjoys under this Agreement or that are provided for herein for any Party during the Term, the Parties shall use commercially reasonable efforts to agree to an amendment to the Agreement to avoid or mitigate such impacts and restore the economic benefits to each affected Party; provided that such amendment mitigates any material adverse effect(s) on each non-affected Party (as identified by each such Party, acting reasonably) that could reasonably be expected to result from such amendment, but only to the extent that such mitigation can be accomplished in a manner that is consistent with the purpose of such amendment. I n the event the Parties cannot agree on an amendment in accordance with this Section 19.2(b) , the Dispute shall be resolved in accordance with Article XVII .
(c) Upon a determination by a court or regulatory body having jurisdiction over this Agreement or any of the Parties, or over the establishment and enforcement of any of the statutes or regulations or orders or actions of regulatory agencies supporting this Agreement or the rights or obligations of the Parties hereunder that any of the statutes or regulations supporting this Agreement or the rights or obligations of the Parties hereunder, or orders of or actions of regulatory agencies implementing such statutes or regulations, or this Agreement on its face or as applied, violates any Applicable Law (including the State or Federal Constitution) (an “ Adverse Determination ”), each Party shall have the right to suspend performance under this Agreement without liability. Owner may provide transmission service to a third party during any period of time for which Purchaser suspends payments under this Section 19.2(c) . Upon an Adverse Determination becoming final and non-appealable, this Agreement shall be rendered null and void.
(d) For the avoidance of doubt, it is understood that the provisions of Article XVII regarding dispute resolution apply to any Dispute under this Article XIX .
INDEMNIFICATION
Section 20.1 Purchaser Indemnity . Purchaser shall indemnify, defend and hold harmless Owner and Owner’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, an “ Owner Indemnified Party ” ) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Owner Indemnified Party, and arising out of the negligence, willful misconduct or criminal misconduct of Purchaser or its agents. Purchaser shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Owner Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, an Owner Indemnified Party. This Section 20.1 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPAs or the RFP Sponsor TSAs.
55
Section 20.2 Owner Indemnity . Owner shall indemnify, defend and hold harmless Purchaser and Purchaser’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives and permitted successors and assigns (each, a “ Purchaser Indemnified Party ” ) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party, including any such liabilities incurred by a Purchaser Indemnified Party under the PPAs, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents, including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Purchaser Indemnified Party. This Section 20.2 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPAs or the RFP Sponsor TSAs.
Section 20.3 Procedures . Promptly after the receipt by any Person seeking indemnification under this Article XX (the “ Indemnified Party ” ) of written notice of the assertion of any claim by a third party with respect to any matter in respect of which indemnification may be sought hereunder (a “ Third Party Claim ” ), the Indemnified Party shall give written notice (the “ Indemnification Notice ” ) to the Party from which indemnification is sought (the “ Indemnifying Party ” ), and shall thereafter keep the Indemnifying Party reasonably informed with respect thereto; provided , however , that the failure of the Indemnified Party to give the Indemnifying Party notice as provided herein shall not relieve the Indemnifying Party of any of its obligations hereunder, except to the extent that the Indemnifying Party is materially prejudiced by such failure. The Indemnifying Party shall be entitled to assume the defense of any Third Party Claim by written notice to the Indemnified Party of such intention given within thirty (30) days after the receipt by the Indemnifying Party of the Indemnification Notice; provided , however , that counsel selected by the Indemnifying Party shall be reasonably satisfactory to the Indemnified Party. The Indemnifying Party shall be liable for the fees and expenses of counsel employed by the Indemnified Party for any period during which the Indemnifying Party has not assumed the defense of any Third Party Claim (other than during any period during which the Indemnified Party has failed to give notice of such Third Party Claim as provided above). If the Indemnifying Party shall assume the defense of the Third Party Claim, then the Indemnifying Party shall not compromise or settle such Third Party Claim without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld, delayed or conditioned; provided , however , that the Indemnified Party shall have no obligation to consent to any settlement that (a) does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff of a release of the Indemnified Party from all liability with respect to such Third Party Claim or (b) involves the imposition of equitable remedies or the imposition of any material obligations on such Indemnified Party other than financial obligations for which such Indemnified Party is indemnified hereunder. As long as the Indemnifying Party is contesting any such Third Party Claim on a timely basis, the Indemnified Party shall not pay, compromise or settle any claims brought under such Third Party Claim. Notwithstanding the assumption by the Indemnifying
56
Party of the defense of any Third Party Claim as provided in this Section 20.3 , the Indemnified Party shall be permitted to participate in the defense of such Third Party Claim and to employ counsel at its own expense (it being understood that the Indemnifying Party controls such defense); provided , however , that, if the defendants in any Third Party Claim shall include both an Indemnifying Party and any Indemnified Party, and such Indemnified Party shall have reasonably concluded that counsel selected by the Indemnifying Party has a conflict of interest because of the availability of different or additional defenses to such Indemnified Party, such Indemnified Party shall then have the right to select separate counsel to participate in the defense of such Third Party Claim on its behalf, at the expense of the Indemnifying Party; provided that the Indemnifying Party shall not be obligated to pay the expenses of more than one separate counsel for all Indemnified Parties, taken together.
Section 20.4 Defenses . If the Indemnifying Party shall fail to notify the Indemnified Party of its desire to assume the defense of any Third Party Claim within the prescribed period of time, or shall notify the Indemnified Party that it will not assume the defense of any such Third Party Claim, then the Indemnified Party may assume the defense of any such Third Party Claim, in which case it may do so acting in good faith and otherwise in such manner as it may deem appropriate, and the Indemnifying Party shall be bound by any determination made in such Third Party Claim.
Section 20.5 Cooperation . The Indemnified Party and the Indemnifying Party shall each cooperate fully (and shall each cause its Affiliates to cooperate fully) with the other in the defense of any Third Party Claim pursuant to this Article XX . Without limiting the generality of the foregoing, each such Person shall furnish the other such Person (at the expense of the Indemnifying Party) with such documentary or other evidence as is then in its or any of its Affiliates’ possession, as may reasonably be requested by the other Person for the purpose of defending against any such Third Party Claim.
Section 20.6 Recovery . The amount of any indemnity hereunder shall be reduced by any insurance proceeds actually recovered by the Indemnified Party in connection with the Third Party Claim. If at any time subsequent to the receipt by an Indemnified Party of an indemnity payment hereunder, such Indemnified Party (or any Affiliate thereof) receives any recovery, settlement or other similar payment with respect to the Third Party Claim for which it received such indemnity payment (a “ Recovery ” ), such Indemnified Party shall then promptly pay to the Indemnifying Party the amount of such Recovery, less any expenses incurred by such Indemnified Party (or its Affiliates) in connection with such Recovery, but in no event shall any such payment exceed the amount of such indemnity payment.
Section 20.7 Subrogation . To the extent the Indemnifying Party makes or is required to make any indemnity payment to the Indemnified Party, the Indemnifying Party shall be entitled to exercise, and shall be subrogated to, any rights and remedies (including rights of indemnity, rights of contribution and other rights of recovery) that the Indemnified Party or any of its Affiliates may have against any other Person with respect thereto, whether directly or indirectly related. The Indemnified Party shall permit the Indemnifying Party to use the name of the Indemnified Party and the names of the Indemnified Party’s Affiliates in any transaction or in any proceeding or other matter involving any of such rights or remedies; and the Indemnified Party shall take such actions as the Indemnifying Party may reasonably request for the purpose of enabling the Indemnifying Party to perfect or exercise its right of subrogation hereunder.
57
REPRESENTATIONS, WARRANTIES, AND COVENANTS
Section 21.1 Mutual Representations and Warranties . Each Party hereby represents and warrants to the other Party that all of the statements in this Section 21.1 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of (i) the Effective Date and (ii) the Commercial Operation Date, but not as of any other date:
(a) It has knowledge and experience in financial matters and in the electric industry that enable it to evaluate the merits and risks of this Agreement and the transactions contemplated hereby, and is capable of evaluating such merits and risks and assuming such risks. It is acting for its own account, has made its own independent decision to enter into this Agreement as to whether this Agreement is appropriate and proper for it based upon its own judgment, is not relying upon the advice or recommendations of the other Party in doing so, and understands and accepts the terms, conditions, and risks of this Agreement and the transactions contemplated hereby;
(b) It has entered into this Agreement in connection with the conduct of its business;
(c) It is not acting as a fiduciary or an advisor with respect to this Agreement or the transactions contemplated hereby;
(d) It is not subject to an Insolvency Event and there are no proceedings pending or being contemplated by it or, to its knowledge, threatened against it that could result in the occurrence of an Insolvency Event with respect to it; and
(e) It is an entity subject to the procedures and substantive provisions of the Bankruptcy Code applicable to U.S. corporations or limited liability companies, as applicable, generally.
Section 21.2 Additional Representations and Warranties of Purchaser . Purchaser hereby represents and warrants to Owner that all of the statements in this Section 21.2 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Purchaser is duly organized, validly existing, and in good standing under the laws of the State of Delaware and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Purchaser, and Purchaser has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Purchaser has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Purchaser;
58
(c) Assuming due authorization, execution and delivery by Owner, this Agreement constitutes Purchaser’s legal, valid and binding obligation enforceable against Purchaser in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Purchaser or any of its Affiliates that could have a Material Adverse Effect on Purchaser;
(e) No event with respect to Purchaser has occurred or is continuing that would constitute a Purchaser Default, and no Purchaser Default will occur as a result of Purchaser entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Purchaser does not and will not (i) violate any provisions of its certificate of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) To the best of Purchaser’s knowledge, the Canadian Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary for TransÉnergie to commence construction of and to own and operate the Québec Line in a manner consistent with Attachment A and this Agreement; and
(h) Purchaser is in compliance with all Applicable Laws, except such noncompliance as could not reasonably be expected to have a Material Adverse Effect on Purchaser. Purchaser has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Purchaser.
Section 21.3 Additional Representations and Warranties of Owner . Owner hereby represents and warrants to Purchaser that all of the statements in this Section 21.3 are true and correct as of the Execution Date (unless another date is expressly indicated) and will be true and correct as of the Effective Date and as of the Commercial Operation Date, but not as of any other date:
(a) Owner is duly organized, validly existing, and in good standing under the laws of the State of Maine and is qualified to do business in each other jurisdiction where the failure to so qualify would have a Material Adverse Effect on Owner, and Owner has all requisite power and authority to conduct its business, own its properties, and to execute, deliver, and perform its obligations under this Agreement;
(b) Owner has all requisite corporate power and authority necessary to authorize the execution and delivery of this Agreement and the performance of its obligations hereunder, and to consummate the transactions contemplated hereby, and this Agreement has been duly executed and delivered by Owner;
59
(c) Assuming due authorization, execution and delivery by Purchaser, this Agreement constitutes Owner’s legal, valid and binding obligation enforceable against Owner in accordance with its terms, subject to applicable bankruptcy, insolvency, reorganization and other laws of general application relating to or affecting creditors’ rights generally and to general principles of equity (regardless of whether considered in a proceeding in equity or at law);
(d) No legal proceeding is pending or, to its knowledge, threatened against Owner or any of its Affiliates that could have a Material Adverse Effect on Owner;
(e) No event with respect to Owner has occurred or is continuing that would constitute an Owner Default, and no Owner Default will occur as a result of Owner entering into or performing its obligations under this Agreement;
(f) The execution, delivery and performance of this Agreement by Owner does not and will not (i) violate any provisions of its articles of incorporation or bylaws, or any Applicable Law; or (ii) violate, or result in any breach of, or constitute any default under, any agreement or instrument to which it is a party or by which it or any of its properties may be bound or affected;
(g) The FERC Authorization, Owner Approvals (other than the Municipal Owner Approvals) and the AC Upgrade Approvals constitute all of the Consents, notifications, waivers, orders, and filings that are necessary to commence construction of and operate the NECEC Transmission Line (other than the Municipal Owner Approvals);
(h) To the best of Owner’s knowledge, the Municipal Owner Approvals identified in paragraph 10 of Attachment C constitute all of the Municipal Owner Approvals that are necessary to commence construction of and operate the NECEC Transmission Line;
(i) Owner is in compliance with all Applicable Laws, except such noncompliance as could not reasonably be expected to have a Material Adverse Effect on Owner. Owner has not received any written notice that it is under investigation with respect to a violation of any Applicable Law that could reasonably be expected to have a Material Adverse Effect on Owner; and
(j) Owner has acquired all required real property rights necessary for construction and operation of the NECEC Transmission Line, and the interconnection of the NECEC Transmission Line with (A) the Québec Line (other than real property rights to be held by TransÉnergie) and (B) the Delivery Point, in full and final form with all options or contingencies having been exercised as set forth in Attachment I .
Section 21.4 [Intentionally Omitted] .
60
Section 21.5 NO OTHER REPRESENTATIONS OR WARRANTIES . THE REPRESENTATIONS AND WARRANTIES OF OWNER SET FORTH IN Section 21.1 AND Section 21.3 ARE OWNER’S SOLE REPRESENTATIONS AND WARRANTIES ASSOCIATED WITH THE NECEC TRANSMISSION LINE AND ARE MADE IN LIEU OF ALL OTHER REPRESENTATIONS, WARRANTIES, AND GUARANTEES, EXPRESS OR IMPLIED, ASSOCIATED WITH THE NECEC TRANSMISSION LINE, INCLUDING REPRESENTATIONS OR WARRANTIES AS TO MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE. THE FOREGOING SENTENCE SHALL NOT BE CONSTRUED IN ANY WAY TO LIMIT OWNER’S EXPRESS OBLIGATIONS UNDER THIS AGREEMENT.
TRANSFER OF INTERESTS
Section 22.1 No Transfer of Interests .
(a) Any (i) direct or indirect change of Control of any Party (whether voluntary or by operation of law), (ii) sale, transfer or other disposition of all or substantially all of the assets of any Party or (iii) except as provided in Section 22.2 or Section 22.3 , assignment, transfer or other disposition of, whether to one or more assignees or transferees, all or any portion of any Party’s rights, interests or obligations under this Agreement (each of the foregoing, a “ Transfer ” ), shall require the prior written consent of the other Party, which consent shall not be unreasonably withheld, delayed or conditioned when viewed in light of all reasonable considerations, including the security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer); provided that any direct or indirect transfer of securities or other ownership interests in a Party to a Person Controlled by a Party’s ultimate parent company (for Purchaser, currently Hydro-Québec, and for Owner, currently Iberdrola, S.A.), as applicable, shall not be considered a Transfer for the purposes of this Section 22.1(a) and shall not require consent. Any Transfer in contravention of this Article XXII shall be null and void. The Parties agree that the provision by or for the account of an assignee or transferee of any Party of Additional Credit Support in an amount equal to the Maximum Amount provided under, and as defined in, the Hydro-Québec Guaranty, as such Maximum Amount may vary from time to time, shall be deemed to satisfy the criterion set forth herein with respect to security or other financial assurances to be provided by or on behalf of any proposed successor or assign (including the net worth and creditworthiness of the issuer).
(b) If Owner consents to a Transfer by Purchaser pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Purchaser’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Owner of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that a Purchaser Default shall not have occurred and be continuing, (x) the obligations of Purchaser shall terminate to the extent of the Transferred portion of this Agreement, and
61
Purchaser shall be fully, finally, and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Purchaser, Owner shall execute and deliver to Purchaser a full, final and unconditional release of any credit support or guarantees provided by Purchaser, in such form as Purchaser may reasonably request, with respect to the Transferred portion of this Agreement.
(c) If Purchaser consents to a Transfer by Owner pursuant to this Section 22.1 , then, upon such Transfer, including (i) the assumption, in writing by the transferee, of Owner’s obligations under this Agreement with respect to the Transferred portion of this Agreement, which assumption is not subject to conditions that have not been satisfied or waived, and (ii) delivery to Purchaser of any replacement security or other financial assurances to be provided by or on behalf of such transferee, then, provided that an Owner Default shall not have occurred and be continuing, (x) the obligations of Owner shall terminate to the extent of the Transferred portion of this Agreement, and Owner shall be fully, finally, and unconditionally released from all liability associated therewith to the extent of the Transferred portion of this Agreement, and (y) at the request of Owner, Purchaser shall execute and deliver to Owner a full, final, and unconditional release of any credit support or guarantees provided by Owner hereunder, in such form as Owner may reasonably request, with respect to the Transferred portion of this Agreement.
(e) Nothing herein shall prevent Purchaser or any assignee thereof from transferring or assigning transmission service rights pursuant to FERC rules and regulations.
Section 22.2 Exceptions . Notwithstanding Section 22.1 , consent shall not be required for any of the following:
(a) an assignment by Purchaser to any of its Affiliates; provided that Hydro-Québec confirms in a writing satisfactory to Owner that the Hydro-Québec Guaranty applies with respect to the assignee’s obligations under this Agreement;
(c) any (i) change of Control of Owner or (ii) transfer or other disposition of all or substantially all of the assets of Owner, in each case, resulting from a collateral assignment in favor of a financing party in accordance with Section 22.3 ;
(d) any change of Control of Owner resulting from any direct or indirect change of Control in Owner’s ultimate parent company (currently Iberdrola, S.A.), Owner’s ultimate parent company in the United States (currently AVANGRID, Inc.) or in the parent company for the network business in the United States of which Owner is part (currently Avangrid Networks, Inc.);
(e) any change of Control of Purchaser resulting from the direct or indirect transfer of interests in Hydro-Québec; or
(f) the exercise of any of Purchaser’s rights pursuant to Section 14.7 .
62
Section 22.3 Collateral Assignment . Owner shall be entitled, without restriction, to make one or more assignments of this Agreement for purposes of collateral security or any or all of its rights and benefits hereunder to or for the benefit of any and all secured lenders to Owner, or grant to or for the benefit of any and all secured lenders to Owner a lien on, or security interest in, any right, title or interest in all or any part of Owner’s rights hereunder for the purpose of the financing or successive refinancing of the ownership, development, engineering, construction or operation of the NECEC Transmission Line; provided , however , that such assignment for purposes of collateral security shall recognize Purchaser’s rights under this Agreement on terms and conditions as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner. To facilitate Owner’s obtaining of financing or successive refinancing for the ownership, development, engineering, construction or operation of the NECEC Transmission Line, Purchaser shall cooperate with Owner and shall execute and deliver such consents, acknowledgements, direct agreements or similar documents as may be customary for financings of a similar nature and reasonably requested by any secured lenders to Owner.
MISCELLANEOUS
Section 23.1 Governing Law . This Agreement and each of its provisions shall be governed by, and construed in accordance with, the laws of the Commonwealth of Massachusetts.
Section 23.2 Entire Agreement . This Agreement, together with the Attachments, constitutes the entire Agreement and understanding between the Parties with respect to all subjects covered hereby and thereby and supersedes all prior discussions, agreements and understandings between the Parties with respect to such matters. Notwithstanding the foregoing, each Party is subject to obligations under different Proposal Agreements.
Section 23.3 Severability . Except as otherwise provided in Section 2.2 or Section 19.2 , (a) in the event any part of this Agreement is held to be illegal, invalid or unenforceable to any extent, the legality, validity and enforceability of the remainder of this Agreement shall not be affected thereby, and shall remain in full force and effect and shall be enforced to the greatest extent permitted by Applicable Law and (b) with respect to any provision found to be illegal, invalid or unenforceable, the Parties shall endeavor to replace such invalid, illegal or unenforceable provision with the valid, legal and enforceable provision that achieves, as nearly as practicable, the commercial intent of this Agreement (as it may be amended from time to time).
Section 23.4 Notices . All notices, billings, requests, demands, waivers, consents and other communications under this Agreement shall be in writing and shall be effective (a) upon personal delivery thereof, including by overnight mail or courier service, with a record of receipt, (b) in the case of notice by United States mail, certified or registered, postage prepaid, return receipt requested, upon the fourth (4th) day after mailing, (c) in the case of notice by facsimile for any communications other than billings, upon transmission; provided that such facsimile transmission is promptly confirmed by either of the methods set forth in the foregoing clause (a) or (b), in each case, addressed to each Party and copy party hereto at its address set forth below or at such other address as a Party may from time to time designate by written notice to the other Party pursuant to this Section 23.4 , (d) in the case of notice by facsimile for billings only (but not
63
any other communication, including any subsequent demand notice for any unpaid amounts), upon receipt of confirmation of successful transmission, but without any further requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b), or (e) in the case of notice by electronic mail for billings only (but not any other communication, including any subsequent demand notice for any unpaid amounts), upon transmission, without any requirement for evidence of receipt or confirmation by either of the methods set forth in the foregoing clause (a) or (b); provided that the Party delivering such notice did not receive any notice of unsuccessful or delayed transmission. A notice given in connection with this Section 23.4 but received on a day other than a Business Day, or after business hours at the location of receipt, shall be deemed to be received on the next Business Day.
If to Owner:
Central Maine Power Company
Attn: Douglas Herling, President & CEO
83 Edison Drive, Augusta ME 04336
207-626-9779
With a copy to:
Central Maine Power Company
Attn: Legal Department
83 Edison Drive, Augusta ME 04336
With a further copy to:
Pierce Atwood LLP
Attn: Jared des Rosiers
254 Commercial St., Portland ME 04101
If to Purchaser:
H.Q. Energy Services (U.S.) Inc.
75, René-Lévesque Boulevard West, 18th Floor
Montréal (Québec) Canada
H2Z 1A4
Attention: President
Facsimile: (514) 289-6723
Section 23.5 Waiver; Cumulative Remedies . Any term or condition of this Agreement may be waived at any time by the Party that is entitled to the benefit thereof, but such waiver shall not be effective unless set forth in a written instrument duly executed by or on behalf of the Party waiving such term or condition. No waiver by any Party of any term or condition of this Agreement, in any one or more instances, shall be deemed to be, or construed as, a subsequent waiver of, or estoppel with respect to, the same or any other term or by Applicable Law. Except as otherwise provided in Section 13.2(b) , the failure of or delay on the part of any Party to enforce or insist upon compliance with or strict performance of any term or condition of this Agreement, or to take advantage of any of its rights thereunder, shall not constitute a waiver or relinquishment
64
of any such terms, conditions or rights, but the same shall be and remain at all times in full force and effect. Except as otherwise provided herein, the remedies provided in this Agreement are cumulative and not exclusive of any remedies provided by law or in equity.
Section 23.6 Confidential Information . Each Party hereby agrees that it shall not disclose, or cause to be disclosed, to third parties any Confidential Information with respect to the other Party or any material or information identified as Critical Energy Infrastructure Information (other than to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential). Notwithstanding the foregoing, each Party may disclose information related to this Agreement to another party to a Proposal Agreement or to the disclosing Party’s Affiliates and its and their respective counsel, directors, officers, employees, lenders, advisors, suppliers, subcontractors, vendors, or consultants, in each case, who have a need to know such information and have agreed to keep such information confidential, only if necessary to comply with its obligations hereunder or thereunder or to coordinate the parties’ obligations under different Proposal Agreements. Each Party shall be responsible for ensuring that any Person to whom it discloses any Confidential Information shall comply with the restrictions in this Section 23.6 . The restrictions in this Section 23.6 shall not apply (w) to the extent disclosure is required by Applicable Law or the requirements of a Governmental Authority (including a court order, oral questions, written interrogatories, request for information or documents, subpoena or similar process, or the requirements of any stock exchange or other Governmental Authority to which the Parties, or any of their Affiliates are subject), (x) to the extent reasonably deemed by the disclosing Party to be required or desirable in connection with regulatory proceedings (including proceedings relating to FERC or any other national, federal, provincial, state or regulatory agency), (y) to the extent reasonably deemed by the disclosing Party to be required to be disclosed in connection with a Dispute between the Parties, or the defense of any litigation or dispute, or (z) as approved for release or disclosure by the Party whose Confidential Information is at issue. In the event disclosure is made pursuant to this Section 23.6 , and except for disclosures pursuant to the requirements of securities laws or any stock exchange, the disclosing Party shall use reasonable efforts to minimize the scope of any disclosure and advise recipients of any applicable confidentiality restrictions provided herein. Notwithstanding the foregoing, this Section 23.6 shall not apply to the following information:
(a) Information that is a matter of public knowledge at the time of its disclosure or is thereafter published in or otherwise ascertainable from a source available to the public without breach of this Section 23.6 ;
(b) Information that is obtained from a Person other than by or as a result of unauthorized disclosure; or
(c) Information that, prior to the time of disclosure, had been independently developed or obtained by the disclosing Party or its Affiliates independent of information obtained as a result of unauthorized disclosure.
65
Section 23.7 No Third-Party Rights . Except for any secured lenders contemplated by Section 22.3 and any Owner Indemnified Party or Purchaser Indemnified Party contemplated by Article XX , the Parties do not intend for this Agreement to confer a third-party beneficiary status or rights of action upon any Person whatsoever other than the Parties and their permitted successors and assigns, and nothing contained herein, either express or implied, shall be construed to confer upon any Person, other than the Parties and their permitted successors and assigns, any rights of action or remedies under this Agreement or in any manner, or any duty, standard of care, or liability with respect thereto. This Agreement does not create any third-party rights, except as expressly stated above in this Section 23.7 .
Section 23.8 Permitted Successors and Assigns . This Agreement shall be binding upon and inure to the benefit of each of the Parties and their permitted successors, legal representatives, and assigns.
Section 23.9 Relationship of the Parties . This Agreement shall not be construed as creating an association, joint venture, trust or partnership between the Parties or as imposing any partnership obligation or liability upon either Party. Except as contemplated by Article X or Section 14.7 , neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.
Section 23.10 Construction . No presumption shall operate in favor of or against either Party as a result of any responsibility for drafting this Agreement.
Section 23.11 Counterparts . This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument. The Parties acknowledge and agree that any document or signature delivered by facsimile or electronic transmission shall be deemed to be an original executed document for all purposes hereof.
Section 23.12 Survival . The provisions of Section 3.3 , Section 3.4 , Article IX , Article XIII , Article XIV , Article XVII , Article XVIII , Article XIX , Article XX and this Article XXIII shall survive the expiration or earlier termination of this Agreement.
Section 23.13 Language . All notices, requests, demands, waivers, consents and other communications between Owner and Purchaser under this Agreement shall be conducted in English.
Section 23.14 Headings and Table of Contents . The headings of the articles and sections of this Agreement and the Table of Contents are inserted for purposes of convenience only, and shall not be construed to affect the meaning or construction of any of the provisions hereof.
Section 23.15 Waiver of Immunities . The Parties acknowledge and agree that this Agreement and the transactions contemplated hereby constitute a commercial transaction. To the extent a Party (including any assignees of a Party’s rights or obligations under this Agreement) may be entitled, in any jurisdiction, to claim for itself, or any of its assets, revenues or properties, sovereign or other immunity, as the case may be, from service of process, suit, the jurisdiction of any court or arbitral tribunal, attachment (whether in aid of execution or otherwise) or
66
enforcement of a judgment (interlocutory or final), or award or any other legal process in a matter arising out of or relating to this Agreement, each Party agrees not to claim or assert, and hereby waives, such immunity. Without limiting the generality of the foregoing, each Party agrees that the waivers set forth in this Section 23.15 shall have the fullest scope permitted under the Immunities Act and under any other Applicable Law related to sovereign immunity.
[Signature pages follow]
67
IN WITNESS WHEREOF , Owner and Purchaser have executed this Agreement as of the Execution Date.
|
OWNER: |
||
|
|
||
|
|
||
|
CENTRAL MAINE POWER COMPANY |
||
|
|
||
|
|
||
|
By: |
|
/s/ Douglas Herling |
|
Name: |
|
Douglas Herling |
|
Title: |
|
President & CEO |
|
|
||
|
|
||
|
By: |
|
/s/ Eric N. Stinneford |
|
Name: |
|
Eric N. Stinneford |
|
Title: |
|
Vice President, Controller, Treasurer & Clerk |
|
|
||
|
|
||
|
PURCHASER: |
||
|
|
||
|
|
||
|
H.Q. ENERGY SERVICES (U.S.) INC. |
||
|
|
||
|
|
||
|
By: |
|
/s/ David Murray |
|
Name: |
|
David Murray |
|
Title: |
|
Chairman of the Board and President |
1
Description of Transmission Projects
The Québec Line and the NECEC Transmission Line consist in their entirety of:
|
(1) |
New 207 mile (145.3 miles in Maine) +/- 320 kV overhead HVDC transmission line that will run between the existing Appalaches Substation in Thetford Mines, Québec and a new HVDC converter station approximately 1.6 miles from the existing Larrabee Road Substation in Lewiston, Maine; |
|
(2) |
New HVDC converter stations at both ends of the transmission line; and |
|
(3) |
Certain upgrades to the existing high voltage alternating current (AC) New England transmission system necessary to permit the interconnection and transmission of Hydro Generation to the New England Control Area (as defined in the ISO-NE Tariff) at the existing Larrabee Road substation under the requirements of Section I.3.9 and the CCIS of ISO-NE Tariff. |
|
(4) |
System upgrades to the existing Québec transmission system as determined by the Hydro-Québec TransÉnergie System Impact Study (OASIS #203T), as it may be updated. |
Owner is the developer of the portion of the NECEC Transmission Line from the Québec-Maine border to the Lewiston area and all transmission upgrades on the U.S. side of the border. The NECEC Transmission Line and the Québec Line are expected to connect at the Québec-Maine border in the northwest corner of Maine in Beattie Township.
The Québec Line will be constructed by TransÉnergie, a division of Hydro-Québec and an Affiliate of Purchaser.
Owner will construct, own, operate and maintain the NECEC Transmission Line, which will be constructed in existing transmission corridors owned by Owner.
The NECEC Transmission Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 145.3 mile +/-320 kV HVDC transmission line from the Canadian Border to a new converter substation located on Merrill Road in Lewiston |
|
ii. |
New 1.6 mile 345 kV AC transmission line from the new Merrill Road converter substation to the existing Larrabee Road substation |
|
b. |
Substation Equipment : |
|
i. |
New 345 kV AC to +/-320 kV HVDC 1200 MW Merrill Road converter substation |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Larrabee Road substation |
1
|
a. |
Transmission Line Equipment: |
|
i. |
New 26.5 mile 345 kV AC transmission line from the existing Coopers Mills substation in Windsor to the existing Maine Yankee substation in Wiscasset |
|
ii. |
New 0.3 mile 345 kV AC transmission line from the existing Surowiec substation in Pownal to a new substation on Fickett Road in Pownal |
|
iii. |
Rebuild 9.3 mile 115 kV Section 62 AC transmission line from the existing Crowley Road substation in Sabattus to the existing Surowiec substation |
|
iv. |
Rebuild 16.1 mile 115 kV Section 64 AC transmission line from the existing Larrabee Road substation to the existing Surowiec substation |
|
v. |
Partial rebuild of 0.8 mile each of 115 kV Section 60/88 outside Coopers Mills substation |
|
vi. |
Partial rebuild of 0.3 miles of 345 kV Section 392 AC transmission line between the Coopers Mills substation and the Maine Yankee substation and approximately 3.5 miles of reconductor work on existing double circuit lattice steel towers outside of the Maine Yankee substation |
|
vii. |
Partial rebuild of 0.3 miles of 345 kV Section 3025 between Coopers Mills substation and Larrabee Road substation |
|
viii. |
Partial rebuild 0.8 miles of 34.5 kV Section 72 AC transmission line outside of the Larrabee Road substation |
|
b. |
Substation Equipment: |
|
i. |
Replace existing Larrabee Road 345/115 kV 448 MVA autotransformer with a 600 MVA autotransformer |
|
ii. |
Add 345 kV AC transmission line terminal at the existing Maine Yankee substation |
|
iii. |
Add 345 kV AC transmission line terminal and 115 kV switch replacements at the existing Surowiec substation |
|
iv. |
115 kV Switch and bus wire replacements at Crowley substation |
|
v. |
New 345 kV Fickett Road substation with 345 kV +/-200 MVAr Static Compensator (STATCOM) |
2
|
vi. |
Add 345 kV AC transmission line terminal and additional 345 kV +/-200 MVAr STATCOM (+/-400 MVAr total with the +/-200 MVAr existing) at the existing Coopers Mills substation |
|
vii. |
Add 345/115 kV 448 MVA autotransformer, associated 115 kV buswork and terminate existing 115 kV Sections 164, 164A and 165 into three new breaker-and-a-half bays at the existing Raven Farm substation |
The NECEC transmission components located in Maine are depicted geographically in relationship to the existing Owner transmission system in Figure 1 below.
3
Figure 1 – Map Depicting the Components of the NECEC Transmission Line
4
The Québec Line consists of the following transmission facilities:
|
(1) |
Core Project Elements: |
|
a. |
Transmission Line Equipment: |
|
i. |
New 65 mile +/-320 kV HVDC transmission line from the Appalaches substation located in Thetford Mines to the U.S. border |
|
b. |
Substation Equipment : |
|
i. |
New +/-320 kV, 1200 MW HVDC converter connected to the 735 kV AC bus of the Appalaches substation and associated 735 kV bus work |
|
(2) |
Network Upgrades (subject to change based on additional system impact study analysis): |
|
a. |
Transmission Line Equipment: |
|
i. |
Thermal upgrade of existing 735 kV lines 7005 and 7035 (68 miles from Lévis substation to Nicolet substation) |
|
ii. |
Thermal upgrade of existing 735 kV line 7049 (44 miles from Montérégie substation to Hertel substation) |
|
b. |
Substation Equipment: |
|
i. |
Add two 200 MVAr shunt capacitor banks at the Carignan substation |
|
ii. |
Add one 330 MVAr shunt reactor at the Carignan substation |
5
Critical Milestones
Item |
Critical Milestone* |
Due Date** |
1. |
Closing of Any Required Financing |
March 7, 2019 |
2. |
Receipt of all Owner Approvals (other than Municipal Owner Approvals) and AC Upgrade Approvals in Final Form |
December 14, 2019 |
3. |
Receipt of all Canadian Approvals |
March 11, 2021 |
4. |
Receipt of all Municipal Owner Approvals |
March 31, 2022 |
5. |
Execution of Contract with the Manufacturer of the Converter Station at the Southern End of the HVDC Line and associated minimum 5% contract value payment |
July 30, 2019 |
6. |
Execution of Contract for the Engineering, Procurement, or Construction of the Converter Station on the Québec Line |
July 30, 2019 |
7. |
Commercial Operation Date |
December 13, 2022 |
* As defined in Section 4.1(a)
** Subject to extension in accordance with the Agreement
1
Owner Approvals
Set forth below are the Governmental Approvals and Third Party Consents, in each case, required to commence construction of and operate the NECEC Transmission Line:
|
1. |
ISO-NE: Approval pursuant to Section I.3.9 of the ISO-NE Tariff to interconnect and operate the NECEC Transmission Line at no fewer than 1,040 MW |
|
2. |
Maine Public Utilities Commission (MPUC): Certificate of Public Convenience and Necessity (CPCN) |
|
3. |
U.S. Department of Energy (DOE): Presidential Permit |
|
4. |
Maine Department of Environmental Protection (MDEP): |
|
a. |
Site Location of Development Act (SLODA) Permit |
|
b. |
Stormwater Management Permit |
|
c. |
Natural Resources Protection Act (NRPA) Permit |
|
d. |
Clean Water Act (CWA) Section 401 Water Quality Certification |
|
e. |
Maine Construction General Permit |
The SLODA Permit, Stormwater Management Permit, NRPA Permit, and CWA Section 401 Water Quality Certification may be combined into one permit.
|
5. |
Maine Land Use Planning Commission (LUPC): Certificate of Compliance |
|
6. |
Maine Department of Agriculture, Conservation and Forestry: |
|
a. |
Submerged Lands Lease |
|
b. |
Public Reserved Land Lease |
|
7. |
Maine Department of Transportation (DOT): |
|
a. |
Utility Location/Road Opening Permits |
|
b. |
Driveway/Entrance Permits |
|
8. |
U.S. Army Corps of Engineers: |
|
a. |
CWA Section 404 - Individual Permit |
|
b. |
Section 10 Rivers & Harbors Act of 1899 |
|
9. |
Federal Aviation Administration Infrastructure in Vicinity of Airports: Determination of No Hazard to Air Navigation |
|
a. |
The Municipal Owner Approvals consist of the following types of permits: |
|
i. |
Shoreland zoning permits |
|
ii. |
Building permits |
|
iii. |
Flood hazard development permits |
2
|
v. |
Site plan / subdivision approvals |
|
vi. |
Driveway / entrance permits |
|
vii. |
Street opening, blasting and demolition permits |
|
viii. |
Utility location permits |
|
b. |
Owner shall obtain the Municipal Owner Approvals listed above that are necessary (if any) in the following municipalities for the NECEC Transmission Line, subject to any necessary exemptions issued by the MPUC relating to any Municipal Owner Approvals that are denied in any such municipalities or relating to any conditions contained in any Municipal Owner Approvals that are unacceptable to Owner: |
|
i. |
Alna |
|
xvi. |
Whitefield |
|
ii. |
Lewiston |
|
xvii. |
Greene |
|
iii. |
Anson |
|
xviii. |
Wilton |
|
iv. |
Livermore Falls |
|
xix. |
Industry |
|
v. |
Auburn |
|
xx. |
Windsor |
|
vi. |
Moscow |
|
xxi. |
Jay |
|
vii. |
Caratunk |
|
xxii. |
Wiscasset |
|
viii. |
New Gloucester |
|
xxiii. |
Leeds |
|
ix. |
Chesterville |
|
xxiv. |
Woolwich |
|
x. |
New Sharon |
|
|
|
|
xi. |
Durham |
|
|
|
|
xii. |
Pownal |
|
|
|
|
xiii. |
Embden |
|
|
|
|
xiv. |
Starks |
|
|
|
|
xv. |
Farmington |
|
|
|
3
Canadian Approvals
Set forth below are, to the best of Purchaser’s knowledge, the Governmental Approvals and Third Party Consents, in each case, required to commence construction of the Québec Line:
|
• |
Permit from the National Energy Board to construct, operate, maintain or connect an international power line pursuant to the National Energy Board Act (R.S.C., 1985, c. N-7); |
|
• |
Permit from the International Boundary Commission required to cross the Canada-U.S. border pursuant to Article 5 of the International Boundary Commission Act; |
|
• |
Authorization from the Régie de l’énergie to acquire, construct or dispose of transmission assets pursuant to an Act respecting the Régie de l’énergie (R.S.Q., chapter R-6.01); |
|
• |
Expropriation Order in council, if required, to acquire by expropriation any immovable, servitude or construction required for the transmission of power pursuant to Hydro-Québec Act (R.S.Q., chapter H-5) and the Expropriation act (R.S.Q., chapter E-24); |
|
• |
Certificate of authorization issued by the Government of Québec to construct the transmission line under Section 31.5 of the Environmental Quality Act subject to the environmental and social impact assessment and review procedure; |
|
• |
Certificate of authorization issued by the Ministère du Développement durable, de l’Environnement et de la Lutte contre les changements climatiques approving the plans and specifications of the transmission line pursuant to Section 22 of the Environmental Quality Act; |
|
• |
Authorization of the Commission de protection du territoire agricole du Québec , if required, approving the use of land situated in an agricultural zone for purposes other than agriculture under Sections 58 and 62 of the Act respecting the preservation of agricultural land and agricultural activities; |
|
• |
Opinion on project compliance with objectives of the city or regional county municipalities’ land-use and development plan. |
1
Owner’s Preliminary Project Schedule and Construction Schedule
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
1
Required Insurance
Owner shall obtain and maintain with qualified insurers authorized to issue insurance of the types described below in the State of Maine.
During construction of the NECEC Transmission Line Owner shall maintain or effect to be maintained the following insurance coverages:
|
• |
Primary and Excess Liability |
|
• |
Construction All Risk / Builders Risk |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
|
• |
Pollution / Environmental Liability |
After the Commercial Operation Date Owner shall provide coverage both in terms of scope and limits of coverage that are in accordance with Good Utility Practice and the long-standing practice of Owner. Operational coverage shall include the following insurance types:
|
• |
Excess Liability |
|
• |
Operational All Risk Property Damage |
|
• |
Worker’s Compensation, Employers’ Liability and any other mandatory insurances |
Note : At any time after the Commercial Operation Date Owner may choose, as far as it is consistent with Good Utility Practice, to self-insure on customary terms and conditions any coverage (or coverage part) where it meets any state or regulatory requirements of self-insurers.
2
Rate Adjustment Formula
In the event that a Transmission Service Payment is subject to reduction pursuant to Section 8.1 , such reduced payment shall equal the Transmission Service Payment that would otherwise be payable under the Agreement for a particular month multiplied by the lesser of 1 or the following fraction:
|
|
(Contract Capacity x 0.90) |
1 - |
|
minus (Contract Capacity x A) |
|
|
(Contract Capacity x 0.90) |
|
|
|
Where A = |
|
∑ Hourly Availability for all hours in such month |
|
∑ Hours in such month |
For purposes of calculating A, Excused Outages (for which Owner is paid full Transmission Service Payments pursuant to the terms of the Agreement) will be regarded as hours in which one hundred percent (100%) of Contract Capacity was provided.
1
Refund Calculation
This example is intended to illustrate the methodology for the calculation of a subsequent refund of a late payment. This example and the numbers used in this example are purely illustrative and are in no way intended to supersede any part of the Agreement, including Section 13.3 .
Assumptions
|
• |
Interest Rate = 12 percent per annum (compounded monthly) |
June 2023 Billing
Invoice Amount
|
$1,000 |
Date of Invoice |
June 1, 2023
|
Due Date |
June 15, 2023
|
Payment Date |
July 1, 2023
|
The total amount due on the date of payment is $1,005, which amount is computed by adding $1,000 (the original amount invoiced) and $5 (the ½ month late interest fee).
Subsequent Refund
If later, on July 1, 2024, the aforesaid payment is required to be refunded, the refund will equal the $1,000 payment made on July 1, 2023 (the original amount invoiced), plus the interest accrued on that $1,000 payment from the due date of June 15, 2023 to the date of refund on July 1, 2024. To ensure that the refund does not double recover interest, the following language has been included in Section 13.3 of the Agreement: “[I]f all or a portion of the amount [ here, the $1,000 payment due on June 15, 2023 ] to which such interest relates [ here, the $5 late interest fee ] is later refunded pursuant to this Agreement [ here, on July 1, 2024 ], then, in calculating that refund, such interest [ here, $5 ] shall not be included in the refund.”
Real Estate Rights
Form of Purchaser Guaranty
See attached.
|
|
Hydro-Québec 75, boulevard René-Lévesque ouest 5 ième étage Montréal, Québec, Canada H2Z 1A4 |
CONVENTION DE CAUTIONNEMENT La présente convention de cautionnement (« Cautionnement »), portant la date du juin 2018, est conclue entre Hydro-Québec , société dûment constituée et régie par la Loi sur Hydro-Québec (L.R.Q., chapitre H-5) ayant son siège social et son principal lieu d’affaires au 75, boulevard René-Lévesque Ouest, Montréal, Québec, Canada, H2Z 1A4 (ci-après appelée « Caution »), et Central Maine Power Company, société dûment constituée en vertu des lois de l’État du Maine, ayant son principal lieu d'affaires au 83 Edison Drive, Augusta ME 04336, États-Unis d'Amérique (ci-après appelée « Bénéficiaire »). |
|
GUARANTY AGREEMENT This Guaranty Agreement («Guaranty»), dated as of June 2018, is made and entered into between Hydro-Québec , a body politic and corporate, duly incorporated and regulated by Hydro-Québec Act (R.S.Q., chapter H-5) and having its head office and principal place of business at 75, René-Lévesque Boulevard West, Montréal, Québec, Canada, H2Z 1A4, hereinafter referred to as the «Guarantor» and Central Maine Power Company, a corporation duly organized under the laws of the State of Maine, having its principal place of business at 83 Edison Drive, Augusta ME 04336, United States of America, (hereinafter referred to as the «Beneficiary»). |
ATTENDU QUE le Bénéficiaire et H.Q. ENERGY SERVICES (U.S.) INC. , société créée en vertu des lois de l’état du Delaware, ayant son lieu d’affaires au 225 Asylum Street, 27 th étage, Hartford, CT 06103 (ci-après appelée « HQUS »), filiale en propriété indirecte de la Caution, ont signé les ententes suivantes: (a) une entente de service de transport pour l’achat de 579.335 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (b) une entente de service de transport pour l’achat de 498.348 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (c) une entente de service de transport pour l’achat de 12.317 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018, (d) une entente de service de transport pour l’achat de 110 MW de service de transport ferme du Bénéficiaire en date du 13 juin 2018 (ci-après appelées collectivement les « Conventions »); |
|
WHEREAS the Beneficiary and H.Q. ENERGY SERVICES (U.S.) INC., a corporation created under the laws of the State of Delaware, having its place of business at 225 Asylum Street, 27 th Floor, Hartford, CT 06103, (hereinafter referred to as «HQUS»), an indirectly owned subsidiary of the Guarantor, have executed the following agreements: (a) a Transmission Service Agreement for the purchase of 579.335 MW of firm transmission service from the Beneficiary dated as of June 13, 2018; (b) a Transmission Service Agreement for the purchase of 498.348 MW of firm transmission service from the Beneficiary dated as of June 13, 2018; (c) a Transmission Service Agreement for the purchase of 12.317 MW of firm transmission service from the Beneficiary dated as of June 13, 2018, and (d) a Transmission Service Agreement for the purchase of 110 MW of firm transmission service from the Beneficiary dated as of June 13, 2018 (hereinafter collectively referred to as the «Agreements»); |
ATTENDU QUE la Caution bénéficiera directement ou indirectement des Conventions ; |
|
WHEREAS the Guarantor will directly or indirectly benefit from the Agreements; |
ATTENDU QUE le Bénéficiaire a exigé que la Caution garantisse inconditionnellement au Bénéficiaire toutes les obligations de paiement qui incombent à HQUS en vertu des Conventions, sous réserve de la somme maximale prévue à l’article 1 du présent Cautionnement; |
|
WHEREAS the Beneficiary has required that the Guarantor unconditionally guarantee to the Beneficiary all payment obligations of HQUS under the Agreements; subject to a maximum dollar limitation as provided in Section 1 of this Guaranty; |
EN CONSÉQUENCE, eu égard à ce qui précède, la Caution s’entend avec le Bénéficiaire sur ce qui suit : |
|
NOW THEREFORE, in consideration of the premises, the Guarantor hereby agrees with the Beneficiary as follows: |
S’ils sont destinés à la Caution : HYDRO-QUÉBEC À l’attention du vice‑président Financement, trésorerie et caisse de retraite 75, boulevard René-Lévesque Ouest 5 e étage Montréal (Québec) Canada H2Z 1A4 Télécopieur : 514 289-5409 |
S’ils sont destinés au Bénéficiaire :
Douglas Herling President & CEO Central Maine Power Company 83 Edison Drive Augusta, Maine 04336 Télécopieur : 207-626-9779 |
|
If to the Guarantor : HYDRO-QUÉBEC Attention : Vice-President Financing, Treasury and Pension Fund 75, René-Lévesque Boulevard West 5 th floor Montréal (Québec) Canada H2Z 1A4 Facsimile: 514 289-5409 |
If to the Beneficiary :
Douglas Herling President & CEO Central Maine Power Company 83 Edison Drive Augusta, Maine 04336 fax 207-626-9779 |
ou à l’adresse dont la Caution ou le Bénéficiaire peut notifier l’autre partie de temps à autre. |
|
or such address as the Guarantor or the Beneficiary may give notice to the other party, from time to time. |
Article 12. Ayants droit; lois applicables. Le présent Cautionnement lie la Caution, ses ayants droit et ses cessionnaires, et est régie par et doit être interprétée conformément aux lois de l'État de New York. |
|
Section 12. Successors; Governing Law . This Guarantee shall be binding upon the Guarantor, its successors and assignees, and shall be governed by and construed in accordance with the laws of the State of New York. |
Article 13. Convention intégrale . Le présent Cautionnement constitue la convention intégrale intervenue entre la Caution et le Bénéficiaire quant à son objet et remplace toutes les conventions et ententes antérieures, écrites ou verbales, entre la Caution et le Bénéficiaire quant à l’objet des présentes. |
|
Section 13. Entire agreement . This Guaranty constitutes the entire agreement of the Guarantor and the Beneficiary pertaining to the subject matter hereof and supersedes all prior written or oral agreements and understandings between the Guarantor and the Beneficiary with respect to the subject matter hereof. |
HYDRO-QUÉBEC |
||
|
||
Par / By : |
|
|
Nom / Name : |
|
|
Titre / Title : |
|
|
|
|
|
Par / By : |
|
|
Nom / Name : |
|
|
Titre / Title : |
|
|
Transmission Service Payment Calculation
The Transmission Service Payment for a given calendar month shall be equal to the unit price per kW-month for the then-current Contract Year (the “ Unit Price ”), as set forth in the table below, multiplied by the Contract Capacity expressed in kW.
Contract Year |
Unit Price
|
Contract Year 1 |
$9.16 |
Contract Year 2 |
$9.35 |
Contract Year 3 |
$9.53 |
Contract Year 4 |
$9.73 |
Contract Year 5 |
$9.92 |
Contract Year 6 |
$10.12 |
Contract Year 7 |
$10.32 |
Contract Year 8 |
$10.53 |
Contract Year 9 |
$10.74 |
Contract Year 10 |
$10.95 |
Contract Year 11 |
$11.17 |
Contract Year 12 |
$11.40 |
Contract Year 13 |
$11.62 |
Contract Year 14 |
$11.86 |
Contract Year 15 |
$12.09 |
Contract Year 16 |
$12.33 |
Contract Year 17 |
$12.58 |
Contract Year 18 |
$12.83 |
Contract Year 19 |
$13.09 |
Contract Year 20 |
$13.35 |
In the event the anniversary of the Commercial Operation Date falls within the middle of a calendar month (month M), the Unit Price for each month M shall be equal to: the Unit Price for the Contract Year that is ending (Contract Year Y), multiplied by the proportion of the days of the calendar month M that are part of that Contract Year Y, plus the Unit Price for the Contract Year that is beginning (Contract Year Y+1), multiplied by the proportion of the days of the calendar month M that are part of that Contract Year Y+1, the resulting calculation being rounded to the nearest cent.
Examples . For all examples, assume the Commercial Operation Date is December 13, 2022, with December being month M.
• Example 1 . The Unit Price for the month of December 2022 is as follows: (($0 [no Transmission Service Payment prior to Contract Year 1] * 12/31 [proportion of days in December 2022 that are prior to Contract Year 1]) + ($9.16 [Unit Price for Contract Year 1] * 19/31 [proportion of days in December that are part of Contract Year 1])) = $5.61/kW-month.
• Example 2 . The Unit Price for the month of December 2023 is as follows: (($9.16 [Unit Price for Contract Year 1] * 12/31 [proportion of days in December that are part of Contract Year 1]) + ($9.35 [Unit Price for Contract Year 2] * 19/31 [proportion of days in December that are part of Contract Year 2])) = $9.28/kW-month.
• Example 3 . The Unit Price for the month of December 2041 is as follows: (($13.35 [Unit Price for Contract Year 20] * 12/31 [proportion of days in December that are part of Contract Year 20]) + ($0 [no Transmission Service Payment after Contract Year 20] * 19/31 [proportion of days in December that are after end of Contract Year 20])) = $5.17/kW-month.
EXHIBIT 31.1
CERTIFICATION
I, James P. Torgerson, certify that:
1. I have reviewed this quarterly report on Form 10-Q of Avangrid, Inc.;
2. Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;
3. Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;
4. The registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the registrant and have:
a) Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
b) Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;
c) Evaluated the effectiveness of the registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and
d) Disclosed in this report any change in the registrant’s internal control over financial reporting that occurred during the registrant’s most recent fiscal quarter (the registrant’s fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the registrant’s internal control over financial reporting; and
5. The registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant’s auditors and the audit committee of the registrant’s board of directors (or persons performing the equivalent functions):
a) All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant’s ability to record, process, summarize and report financial information; and
b) Any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant’s internal control over financial reporting.
Date: August 2, 2018 |
|
/s/ James P. Torgerson |
|
|
James P. Torgerson |
|
|
Director and Chief Executive Officer |
EXHIBIT 31.2
CERTIFICATION
I, Douglas K. Stuver , certify that:
1. I have reviewed this quarterly report on Form 10-Q of Avangrid, Inc.;
2. Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;
3. Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;
4. The registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the registrant and have:
a) Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
b) Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;
c) Evaluated the effectiveness of the registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and
d) Disclosed in this report any change in the registrant’s internal control over financial reporting that occurred during the registrant’s most recent fiscal quarter (the registrant’s fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the registrant’s internal control over financial reporting; and
5. The registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant’s auditors and the audit committee of the registrant’s board of directors (or persons performing the equivalent functions):
a) All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant’s ability to record, process, summarize and report financial information; and
b) Any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant’s internal control over financial reporting.
Date: August 2, 2018 |
|
/s/ Douglas K. Stuver |
|
|
Douglas K. Stuver |
|
|
Senior Vice President - Chief Financial Officer |
EXHIBIT 32
CERTIFICATION OF CHIEF EXECUTIVE OFFICER AND CHIEF FINANCIAL OFFICER
Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002
Pursuant to 18 U.S.C. Section 1350, the undersigned, James P. Torgerson and Douglas K. Stuver , the Chief Executive Officer and Chief Financial Officer, respectively, of Avangrid, Inc. (the “issuer”), do each hereby certify that the issuer’s quarterly report on Form 10-Q for the quarter ended June 30, 2018, to which this certification is attached as an exhibit (the “report”), fully complies with the requirements of section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m or 78o(d)) and that information contained in the report fairly presents, in all material respects, the financial condition and results of operations of the issuer.
/s/ James P. Torgerson |
James P. Torgerson |
Director and Chief Executive Officer |
Avangrid, Inc. |
August 2, 2018 |
/s/ Douglas K. Stuver |
Douglas K. Stuver |
Senior Vice President - Chief Financial Officer |
Avangrid, Inc. |
August 2, 2018 |